diff --git "a/reports/chunks/Annual Consolidated OAG audit reports 2021.chunks.json" "b/reports/chunks/Annual Consolidated OAG audit reports 2021.chunks.json" --- "a/reports/chunks/Annual Consolidated OAG audit reports 2021.chunks.json" +++ "b/reports/chunks/Annual Consolidated OAG audit reports 2021.chunks.json" @@ -1 +1 @@ -{"paragraphs": [{"content": "THE REPUBLIC OF UGANDA", "metadata": {"headings": [{"headings_0": {"content": "THE REPUBLIC OF UGANDA", "page": 1, "level": 2}}], "page": 1, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "REPORT OF THE AUDITOR GENERAL TO PARLIAMENT", "metadata": {"headings": [{"headings_0": {"content": "REPORT OF THE AUDITOR GENERAL TO PARLIAMENT", "page": 1, "level": 2}}, {"headings_1": {"content": "THE REPUBLIC OF UGANDA", "page": 1, "level": 2}}], "page": 1, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "FOR THE FINANCIAL YEAR ENDED 30 TH JUNE 2021", "metadata": {"headings": [{"headings_0": {"content": "REPORT OF THE AUDITOR GENERAL TO PARLIAMENT", "page": 1, "level": 2}}, {"headings_1": {"content": "THE REPUBLIC OF UGANDA", "page": 1, "level": 2}}], "page": 1, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "OFFICE OF THE AUDITOR GENERAL UGANDA", "metadata": {"headings": [{"headings_0": {"content": "OFFICE OF THE AUDITOR GENERAL UGANDA", "page": 1, "level": 4}}, {"headings_1": {"content": "REPORT OF THE AUDITOR GENERAL TO PARLIAMENT", "page": 1, "level": 2}}], "page": 1, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "DECEMBER, 2021", "metadata": {"headings": [{"headings_0": {"content": "OFFICE OF THE AUDITOR GENERAL UGANDA", "page": 1, "level": 4}}, {"headings_1": {"content": "REPORT OF THE AUDITOR GENERAL TO PARLIAMENT", "page": 1, "level": 2}}], "page": 1, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ii", "metadata": {"headings": [{"headings_0": {"content": "ii", "page": 2, "level": 2}}, {"headings_1": {"content": "OFFICE OF THE AUDITOR GENERAL UGANDA", "page": 1, "level": 4}}], "page": 2, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "TABLE OF CONTENTS", "metadata": {"headings": [{"headings_0": {"content": "TABLE OF CONTENTS", "page": 3, "level": 3}}, {"headings_1": {"content": "ii", "page": 2, "level": 2}}], "page": 3, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "iii", "metadata": {"headings": [{"headings_0": {"content": "iii", "page": 3, "level": 2}}, {"headings_1": {"content": "TABLE OF CONTENTS", "page": 3, "level": 3}}], "page": 3, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Report on the Audit of Compliance with Legislation ................................................................................33", "metadata": {"headings": [{"headings_0": {"content": "iii", "page": 3, "level": 2}}, {"headings_1": {"content": "TABLE OF CONTENTS", "page": 3, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.1.9.", "metadata": {"headings": [{"headings_0": {"content": "2.1.9.", "page": 4, "level": 3}}, {"headings_1": {"content": "iii", "page": 3, "level": 2}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Use of prior financial years unspent funds ..............................................................................33", "metadata": {"headings": [{"headings_0": {"content": "Use of prior financial years unspent funds ..............................................................................33", "page": 4, "level": 3}}, {"headings_1": {"content": "2.1.9.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "2.2 \nREPORT AND OPINION OF THE AUDITOR GENERAL ON THE GOVERNMENT OF UGANDA CONSOLIDATED FINANCIAL STATEMENTS OF THE LOCAL GOVTS FOR THE YEAR ENDED 30 TH JUNE 2021 ...35 Opinion \u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026 35 Basis for Opinion............................................................................................................................................35", "metadata": {"headings": [{"headings_0": {"content": "Use of prior financial years unspent funds ..............................................................................33", "page": 4, "level": 3}}, {"headings_1": {"content": "2.1.9.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Key Audit Matters ..........................................................................................................................................35", "metadata": {"headings": [{"headings_0": {"content": "Key Audit Matters ..........................................................................................................................................35", "page": 4, "level": 3}}, {"headings_1": {"content": "Use of prior financial years unspent funds ..............................................................................33", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "2.2.1. Payroll management in Local Governments..........................................................................................35 Other Matter..................................................................................................................................................40 2.2.2. Implementation of the approved budget .............................................................................................40", "metadata": {"headings": [{"headings_0": {"content": "Key Audit Matters ..........................................................................................................................................35", "page": 4, "level": 3}}, {"headings_1": {"content": "Use of prior financial years unspent funds ..............................................................................33", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.2.3. Operationalization of New Cities.......................................................................................................44 2.2.4.", "metadata": {"headings": [{"headings_0": {"content": "2.2.3. Operationalization of New Cities.......................................................................................................44 2.2.4.", "page": 4, "level": 3}}, {"headings_1": {"content": "Key Audit Matters ..........................................................................................................................................35", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Capitation Grant for Printing of Home Study Materials .......................................................................44", "metadata": {"headings": [{"headings_0": {"content": "2.2.3. Operationalization of New Cities.......................................................................................................44 2.2.4.", "page": 4, "level": 3}}, {"headings_1": {"content": "Key Audit Matters ..........................................................................................................................................35", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.2.5. Un-Accounted for Funds ..................................................................................................................45 2.2.6. Irregular payment of Salary and Salary arrears to staff in Apac DLG ..................................................45 2.2.7. Failure to submit Financial Statements for consolidation ....................................................................46 2.2.8.", "metadata": {"headings": [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds ..................................................................................................................45 2.2.6. Irregular payment of Salary and Salary arrears to staff in Apac DLG ..................................................45 2.2.7. Failure to submit Financial Statements for consolidation ....................................................................46 2.2.8.", "page": 4, "level": 3}}, {"headings_1": {"content": "2.2.3. Operationalization of New Cities.......................................................................................................44 2.2.4.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Implementation of UgIFT project activities .......................................................................................47 Other Information ..........................................................................................................................................49 Management Responsibilities for the Financial Statements................................................................................49", "metadata": {"headings": [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds ..................................................................................................................45 2.2.6. Irregular payment of Salary and Salary arrears to staff in Apac DLG ..................................................45 2.2.7. Failure to submit Financial Statements for consolidation ....................................................................46 2.2.8.", "page": 4, "level": 3}}, {"headings_1": {"content": "2.2.3. Operationalization of New Cities.......................................................................................................44 2.2.4.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements....................................................................49 Other Reporting Responsibilities .....................................................................................................................51", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements....................................................................49 Other Reporting Responsibilities .....................................................................................................................51", "page": 4, "level": 2}}, {"headings_1": {"content": "2.2.5. Un-Accounted for Funds ..................................................................................................................45 2.2.6. Irregular payment of Salary and Salary arrears to staff in Apac DLG ..................................................45 2.2.7. Failure to submit Financial Statements for consolidation ....................................................................46 2.2.8.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Report on the Audit of Compliance with Legislation ..........................................................................................51 2.3 \nREPORT OF THE AUDITOR GENERAL ON THE CONSOLIDATED SUMMARY STATEMENT OF FINANCIAL PERFORMANCE OF PUBLIC CORPORATIONS AND STATE ENTERPRISES FOR THE YEAR ENDED 30 TH JUNE 2021", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements....................................................................49 Other Reporting Responsibilities .....................................................................................................................51", "page": 4, "level": 2}}, {"headings_1": {"content": "2.2.5. Un-Accounted for Funds ..................................................................................................................45 2.2.6. Irregular payment of Salary and Salary arrears to staff in Apac DLG ..................................................45 2.2.7. Failure to submit Financial Statements for consolidation ....................................................................46 2.2.8.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026..52 2.3.1.", "metadata": {"headings": [{"headings_0": {"content": "\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026..52 2.3.1.", "page": 4, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements....................................................................49 Other Reporting Responsibilities .....................................................................................................................51", "page": 4, "level": 2}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Review of the Consolidated Summary Statement of Financial Performance of Public Corporations and State Enterprises ........................................................................................................................ 52", "metadata": {"headings": [{"headings_0": {"content": "\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026..52 2.3.1.", "page": 4, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements....................................................................49 Other Reporting Responsibilities .....................................................................................................................51", "page": 4, "level": 2}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.4.1", "metadata": {"headings": [{"headings_0": {"content": "2.4.1", "page": 4, "level": 3}}, {"headings_1": {"content": "\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026..52 2.3.1.", "page": 4, "level": 2}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Review of Financial Performance of Public Corporations and State Enterprises ............................... 54", "metadata": {"headings": [{"headings_0": {"content": "Review of Financial Performance of Public Corporations and State Enterprises ............................... 54", "page": 4, "level": 3}}, {"headings_1": {"content": "2.4.1", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "PART 3: SECTORAL AND LOCAL GOVERNMENTS CROSS CUTTING FINDINGS ............................................60", "metadata": {"headings": [{"headings_0": {"content": "Review of Financial Performance of Public Corporations and State Enterprises ............................... 54", "page": 4, "level": 3}}, {"headings_1": {"content": "2.4.1", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.1.", "metadata": {"headings": [{"headings_0": {"content": "3.1.", "page": 4, "level": 3}}, {"headings_1": {"content": "Review of Financial Performance of Public Corporations and State Enterprises ............................... 54", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "PUBLIC SECTOR MANAGEMENT ........................................................................................... 60", "metadata": {"headings": [{"headings_0": {"content": "3.1.", "page": 4, "level": 3}}, {"headings_1": {"content": "Review of Financial Performance of Public Corporations and State Enterprises ............................... 54", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.1.1.", "metadata": {"headings": [{"headings_0": {"content": "3.1.1.", "page": 4, "level": 3}}, {"headings_1": {"content": "3.1.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Government readiness to implement the programmatic approach ................................................60 3.1.2.", "metadata": {"headings": [{"headings_0": {"content": "Government readiness to implement the programmatic approach ................................................60 3.1.2.", "page": 4, "level": 3}}, {"headings_1": {"content": "3.1.1.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Limited efforts to build the capacity of planning units within Government ......................................61", "metadata": {"headings": [{"headings_0": {"content": "Limited efforts to build the capacity of planning units within Government ......................................61", "page": 4, "level": 3}}, {"headings_1": {"content": "Government readiness to implement the programmatic approach ................................................60 3.1.2.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "3.2. SECURITY SECTOR ............................................................................................................62", "metadata": {"headings": [{"headings_0": {"content": "Limited efforts to build the capacity of planning units within Government ......................................61", "page": 4, "level": 3}}, {"headings_1": {"content": "Government readiness to implement the programmatic approach ................................................60 3.1.2.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.2.1.", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 4, "level": 3}}, {"headings_1": {"content": "Limited efforts to build the capacity of planning units within Government ......................................61", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Monitoring and Supervision of Government Programmes under Office of the President ....................62", "metadata": {"headings": [{"headings_0": {"content": "Monitoring and Supervision of Government Programmes under Office of the President ....................62", "page": 4, "level": 3}}, {"headings_1": {"content": "3.2.1.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "3.3. AGRICULTURE SECTOR ......................................................................................................62", "metadata": {"headings": [{"headings_0": {"content": "Monitoring and Supervision of Government Programmes under Office of the President ....................62", "page": 4, "level": 3}}, {"headings_1": {"content": "3.2.1.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.3.1.", "metadata": {"headings": [{"headings_0": {"content": "3.3.1.", "page": 4, "level": 3}}, {"headings_1": {"content": "Monitoring and Supervision of Government Programmes under Office of the President ....................62", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Mainstreaming of Agriculture Sector agencies ..........................................................................62", "metadata": {"headings": [{"headings_0": {"content": "3.3.1.", "page": 4, "level": 3}}, {"headings_1": {"content": "Monitoring and Supervision of Government Programmes under Office of the President ....................62", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.3.2.", "metadata": {"headings": [{"headings_0": {"content": "3.3.2.", "page": 4, "level": 3}}, {"headings_1": {"content": "3.3.1.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Over dependence on the Public Private Partnership in the Cotton sector .......................................63 3.3.3.", "metadata": {"headings": [{"headings_0": {"content": "Over dependence on the Public Private Partnership in the Cotton sector .......................................63 3.3.3.", "page": 4, "level": 3}}, {"headings_1": {"content": "3.3.2.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Management of Foot and Mouth Disease (FMD) Outbreaks in the Country .....................................64", "metadata": {"headings": [{"headings_0": {"content": "Management of Foot and Mouth Disease (FMD) Outbreaks in the Country .....................................64", "page": 4, "level": 3}}, {"headings_1": {"content": "Over dependence on the Public Private Partnership in the Cotton sector .......................................63 3.3.3.", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "iv", "metadata": {"headings": [{"headings_0": {"content": "iv", "page": 4, "level": 2}}, {"headings_1": {"content": "Management of Foot and Mouth Disease (FMD) Outbreaks in the Country .....................................64", "page": 4, "level": 3}}], "page": 4, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "3.4.", "metadata": {"headings": [{"headings_0": {"content": "3.4.", "page": 5, "level": 3}}, {"headings_1": {"content": "iv", "page": 4, "level": 2}}], "page": 5, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Performance of the collaborating institutions under the Tax Registration and Expansion Programme ..69 3.6.4.", "metadata": {"headings": [{"headings_0": {"content": "Performance of the collaborating institutions under the Tax Registration and Expansion Programme ..69 3.6.4.", "page": 5, "level": 3}}, {"headings_1": {"content": "3.4.", "page": 5, "level": 3}}], "page": 5, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Bottlenecks in the Compensation of Project Affected Persons(PAPs) under Transmission Line Projects 74 3.8.", "metadata": {"headings": [{"headings_0": {"content": "Bottlenecks in the Compensation of Project Affected Persons(PAPs) under Transmission Line Projects 74 3.8.", "page": 5, "level": 3}}, {"headings_1": {"content": "Performance of the collaborating institutions under the Tax Registration and Expansion Programme ..69 3.6.4.", "page": 5, "level": 3}}], "page": 5, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Value for Money Audit of Urban Infrastructure projects implemented by 22 Municipal Councils \u2026\u2026.... 94 4.2.", "metadata": {"headings": [{"headings_0": {"content": "Value for Money Audit of Urban Infrastructure projects implemented by 22 Municipal Councils \u2026\u2026.... 94 4.2.", "page": 6, "level": 3}}, {"headings_1": {"content": "Bottlenecks in the Compensation of Project Affected Persons(PAPs) under Transmission Line Projects 74 3.8.", "page": 5, "level": 3}}], "page": 6, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Value for Money audit and assessment of Infrastructure projects under the UgIFT Program \u2026\u2026.\u2026\u2026. 95 4.3.", "metadata": {"headings": [{"headings_0": {"content": "Value for Money audit and assessment of Infrastructure projects under the UgIFT Program \u2026\u2026.\u2026\u2026. 95 4.3.", "page": 6, "level": 3}}, {"headings_1": {"content": "Value for Money Audit of Urban Infrastructure projects implemented by 22 Municipal Councils \u2026\u2026.... 94 4.2.", "page": 6, "level": 3}}], "page": 6, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "7.5.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 7, "level": 3}}, {"headings_1": {"content": "Value for Money audit and assessment of Infrastructure projects under the UgIFT Program \u2026\u2026.\u2026\u2026. 95 4.3.", "page": 6, "level": 3}}], "page": 7, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "vii", "metadata": {"headings": [{"headings_0": {"content": "vii", "page": 7, "level": 2}}, {"headings_1": {"content": "7.5.", "page": 7, "level": 3}}], "page": 7, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "LIST OF TABLES", "metadata": {"headings": [{"headings_0": {"content": "vii", "page": 7, "level": 2}}, {"headings_1": {"content": "7.5.", "page": 7, "level": 3}}], "page": 8, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "viii", "metadata": {"headings": [{"headings_0": {"content": "viii", "page": 8, "level": 2}}, {"headings_1": {"content": "vii", "page": 7, "level": 2}}], "page": 8, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "LIST OF ACRONYMS", "metadata": {"headings": [{"headings_0": {"content": "viii", "page": 8, "level": 2}}, {"headings_1": {"content": "vii", "page": 7, "level": 2}}], "page": 9, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["ACRONYM", "DESCRIPTION"], ["AG", "Auditor General"], ["AO Accounting Officer", null], ["Bn", "Billion"], ["BoU Bank of Uganda", null], ["CAs", "Contracting Authorities"], ["CFR Central Forest Reserve", null], ["DGAL", "Directorate of Government Analytical Laboratory"], ["DLB District Land Board", null], ["FY", "Financial Year"], ["GDP Gross Domestic Product", null], ["GoU", "Government of Uganda"], ["ICT Information Communication Technology", null], ["IDA", "International Development Association"], ["IESBA International Ethics Standards Board for Accountants", null], ["IFMS", "Integrated Financial Management System"], ["IMF International Monetary Fund", null], ["KIS", "Kalangala Infrastructure Services"], ["MAAIF Ministry of Agriculture Animal Industry and Fisheries", null], ["MDAs", "Ministries, Departments and Agencies"], ["MEMD Ministry of Energy and Mineral Development", null], ["MOFPED", "Ministry of Finance, Planning, and Economic Development"], ["MoGLSD Ministry of Gender Labour and Social Development", null], ["MoU", "Memoranda of Understanding"], ["MTEF Medium Term Expenditure Framework", null], ["NAA", "National Audit Act"], ["NBI National Backbone Infrastructure", null], ["NDP", "National Development Plan"], ["NDPII Second National Development Plan", null], ["NEF", "National Environment Fund"], ["NEMA National Environment Management Authority", null], ["NFA", "National Forestry Authority"], ["NGO Non-Governmental Organisation", null], ["NIN", "National Identification Number"], ["NIRA National Identification Registration Authority", null], ["NPA", "National Planning Authority"], ["NWSC National Water and Sewerage Corporation", null], ["OAG", "Office of the Auditor General"], ["PAPs Project Affected Persons", null], ["PDMF", "Public Debt Management Framework"], ["PFMA Public Finance Management Act, 2015", null], ["PS/ST", "Permanent Secretary/Secretary to the Treasury"], ["PSST Permanent Secretary and Secretary to Treasury", null], ["TAI", "Treasury Accounting Instructions, 2016"], ["TIN Tax Identification Number", null], ["Tn", "Trillion"], ["TWGs Technical Working Groups", null], ["UCC", "Uganda Communications Commission"]], "metadata": {"headings": [{"headings_0": {"content": "viii", "page": 8, "level": 2}}, {"headings_1": {"content": "vii", "page": 7, "level": 2}}], "page": 9, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1"], "type": "table"}}, {"content": "ix", "metadata": {"headings": [{"headings_0": {"content": "ix", "page": 9, "level": 2}}, {"headings_1": {"content": "viii", "page": 8, "level": 2}}], "page": 9, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["UCF Uganda Consolidated Fund", null], ["UDC", "Uganda Development Corporation"], ["UETCL Uganda Electricity Transmission Company Limited", null], ["UGX", "Uganda Shillings"], ["URA Uganda Revenue Authority", null], ["USD", "United States Dollars"], ["USMID Uganda Support for Municipal Infrastructure Development", null], ["WMD", "Wetlands Management Department"], ["YIGs Youth Interest Groups", null], ["YLP", "Youth Livelihood Programme"]], "metadata": {"headings": [{"headings_0": {"content": "ix", "page": 9, "level": 2}}, {"headings_1": {"content": "viii", "page": 8, "level": 2}}], "page": 10, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["ACRONYM", "DESCRIPTION"], "type": "table"}}, {"content": "x \nGLOSSARY OF TERMS", "metadata": {"headings": [{"headings_0": {"content": "ix", "page": 9, "level": 2}}, {"headings_1": {"content": "viii", "page": 8, "level": 2}}, [{"headings_0": {"content": "ix", "page": 9, "level": 2}}, {"headings_1": {"content": "viii", "page": 8, "level": 2}}]], "page": 10, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Term", "Definition"], ["Classified Expenditure", "The expenses and commitments incurred by an authorised agency for the"], ["", "collection and dissemination of information related to national security"], [null, "interests"], ["Contingent Liability A potential liability that may occur depending on the outcome of an uncertain future event.", null], ["Domestic Arrears", "Domestic arrears refer to short-term debts incurred by Governments against"], ["", "unpaid procurement invoices for supply of goods and services during the"], [null, "financial year"], ["External Debt Portion of a country's debt that was borrowed from foreign lenders including commercial banks, Governments or international financial institutions.", null], ["Garnishee order", "A form of enforcing a judgment debt against a creditor to recover money."], ["Nugatory Expenditure Expenditure that does not achieve any result", null], ["Off-budget financing", "Off-buget refers to expenditure that is not funded through the budget"], ["Recruitment Refers to the process of attracting, screening, selecting, and on boarding a qualified person for a job, provided by an employer in another territory and the preparation for their departure.", null], ["Revolving Fund", "A fund that is continually replenished as withdrawals are made."], ["", null]], "metadata": {"headings": [{"headings_0": {"content": "ix", "page": 9, "level": 2}}, {"headings_1": {"content": "viii", "page": 8, "level": 2}}], "page": 11, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["ACRONYM", "DESCRIPTION"], "type": "table"}}, {"content": "xi", "metadata": {"headings": [{"headings_0": {"content": "xi", "page": 11, "level": 2}}, {"headings_1": {"content": "ix", "page": 9, "level": 2}}], "page": 11, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "FOREWORD BY THE AUDITOR GENERAL", "metadata": {"headings": [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}, {"headings_1": {"content": "xi", "page": 11, "level": 2}}], "page": 12, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "In accordance with my audit mandate set out under Article 163 of the Constitution of the Republic of Uganda, 1995 (as amended) and the National Audit Act, 2008, I hereby present to you the Annual Audit Report on the Consolidated Public Accounts of Uganda; Local Government; and Summary Statement of Financial Performance of Public Corporations, and State Enterprises and Companies in which Government has a controlling interest. \nIn delivering my mandate, I audited financial statements for 128 MDAs, 107 Statutory Corporations 145 Local Governments and 2048 Lower Local Governments. In addition, I undertook four (4) thematic audits covering, Management of Covid-19 pandemic intervention, compensations of Project Affected Persons, implementation of the approved budget, and Payroll and Pension payments. \nThe Office reviewed its audit process to comply with the Covid-19 guidelines from the Ministry of Health and Ministry of Public Service, by conducting some critical meetings virtually and coping with a lean staff. In addition, Stakeholders have increased their call to strengthen accountability in the wake of the Pandemic triggering special audits and investigations relating to Covid-19 expenditure. \nDue to the impact of the Pandemic, some audits were not conducted as planned, but we are committed to continuously adding value to society by making recommendations that enhance accountability and improved service delivery through audit services. \nI extend my gratitude to the Government of Uganda and all other stakeholders for the support rendered to my office during the audit year. I also thank my staff for their unwavering commitment during this challenging period. \nJohn F.S. Muwanga AUDITOR GENERAL \n31 st December 2021", "metadata": {"headings": [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}, {"headings_1": {"content": "xi", "page": 11, "level": 2}}, [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}, {"headings_1": {"content": "xi", "page": 11, "level": 2}}], [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}, {"headings_1": {"content": "xi", "page": 11, "level": 2}}], [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}, {"headings_1": {"content": "xi", "page": 11, "level": 2}}], [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}, {"headings_1": {"content": "xi", "page": 11, "level": 2}}], [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}, {"headings_1": {"content": "xi", "page": 11, "level": 2}}], [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}, {"headings_1": {"content": "xi", "page": 11, "level": 2}}]], "page": 12, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "xii", "metadata": {"headings": [{"headings_0": {"content": "xii", "page": 12, "level": 2}}, {"headings_1": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}], "page": 12, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "metadata": {"headings": [{"headings_0": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}, {"headings_1": {"content": "xii", "page": 12, "level": 2}}], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "1.1 General Introduction \nI am required by Article 163(3) of the Constitution of the Republic of Uganda and Section 13 and 19 of the National Audit Act 2008 to audit and report on the public accounts of Uganda and of all public offices including the Courts, the Central and Local Government Administrations, Universities and Public Institutions of like nature and any Public Corporations or other bodies established by an Act of Parliament. \nSection 13 (b) of the National Audit Act 2008 further requires me to conduct the following audits: \n", "metadata": {"headings": [{"headings_0": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}, {"headings_1": {"content": "xii", "page": 12, "level": 2}}, [{"headings_0": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}, {"headings_1": {"content": "xii", "page": 12, "level": 2}}], [{"headings_0": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}, {"headings_1": {"content": "xii", "page": 12, "level": 2}}], [{"headings_0": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}, {"headings_1": {"content": "xii", "page": 12, "level": 2}}]], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Financial audits\n- Value for money", "metadata": {"headings": [{"headings_0": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}, {"headings_1": {"content": "xii", "page": 12, "level": 2}}], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 Engineering", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Engineering", "page": 13, "level": 1}}, {"headings_1": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- Information Systems\n- Special/Forensic Audits\n- Gender and Environment and any other audits in respect of any project or activity involving public funds\n- Classified expenditure\n- Government investments\n- Procurement audits, and\n- Treasury Memoranda", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Engineering", "page": 13, "level": 1}}, {"headings_1": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nUnder Article 163 (4) of the Constitution, I am also required to submit to Parliament annually a report of the accounts audited by me for the year immediately preceding. I am therefore, issuing this report in accordance with the above provisions. \n1.2 Purpose \nThe purpose of this report is to provide:", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Engineering", "page": 13, "level": 1}}, {"headings_1": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}, [{"headings_0": {"content": "\uf0b7 Engineering", "page": 13, "level": 1}}, {"headings_1": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}], [{"headings_0": {"content": "\uf0b7 Engineering", "page": 13, "level": 1}}, {"headings_1": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}]], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "(i)", "metadata": {"headings": [{"headings_0": {"content": "(i)", "page": 13, "level": 2}}, {"headings_1": {"content": "\uf0b7 Engineering", "page": 13, "level": 1}}], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "A summary of audit results and opinions for audits done in the year", "metadata": {"headings": [{"headings_0": {"content": "(i)", "page": 13, "level": 2}}, {"headings_1": {"content": "\uf0b7 Engineering", "page": 13, "level": 1}}], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "(ii)", "metadata": {"headings": [{"headings_0": {"content": "(ii)", "page": 13, "level": 2}}, {"headings_1": {"content": "(i)", "page": 13, "level": 2}}], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "A report and Opinion of the Auditor General on the; \n", "metadata": {"headings": [{"headings_0": {"content": "(ii)", "page": 13, "level": 2}}, {"headings_1": {"content": "(i)", "page": 13, "level": 2}}, [{"headings_0": {"content": "(ii)", "page": 13, "level": 2}}, {"headings_1": {"content": "(i)", "page": 13, "level": 2}}]], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Consolidated Financial Statements of the Government of the Republic of Uganda for the year ended 30 th June 2021\n- Consolidated Financial Statements of Local Governments for the year ended 30 th June 2021\n- The Consolidated Summary Statement of Financial Performance of Public Corporations and State Enterprises for the year ended 30 th June 2021", "metadata": {"headings": [{"headings_0": {"content": "(ii)", "page": 13, "level": 2}}, {"headings_1": {"content": "(i)", "page": 13, "level": 2}}], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "(iii) \nA summary of audit results from audit of thematic and focus areas \n1 \n(iv) Sectoral and cross cutting findings, implications and recommendations from the audit of Ministries, Departments, Agencies, Commissions, Statutory Corporations and Local Governments and other specialised audit findings. For the first time, a summary of IT Audit findings have been included in the report under Part 4 of the report.", "metadata": {"headings": [{"headings_0": {"content": "(ii)", "page": 13, "level": 2}}, {"headings_1": {"content": "(i)", "page": 13, "level": 2}}, [{"headings_0": {"content": "(ii)", "page": 13, "level": 2}}, {"headings_1": {"content": "(i)", "page": 13, "level": 2}}], [{"headings_0": {"content": "(ii)", "page": 13, "level": 2}}, {"headings_1": {"content": "(i)", "page": 13, "level": 2}}]], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "(v)", "metadata": {"headings": [{"headings_0": {"content": "(v)", "page": 14, "level": 2}}, {"headings_1": {"content": "(ii)", "page": 13, "level": 2}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "A summary of findings of completed audits which include opinions from the audit of Ministries, Departments, Agencies, Commissions, Statutory Corporations (Annexure I) and Local Governments (Annexure II). \n1.3", "metadata": {"headings": [{"headings_0": {"content": "(v)", "page": 14, "level": 2}}, {"headings_1": {"content": "(ii)", "page": 13, "level": 2}}, [{"headings_0": {"content": "(v)", "page": 14, "level": 2}}, {"headings_1": {"content": "(ii)", "page": 13, "level": 2}}]], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Summary of Audit Results", "metadata": {"headings": [{"headings_0": {"content": "Summary of Audit Results", "page": 14, "level": 2}}, {"headings_1": {"content": "(v)", "page": 14, "level": 2}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "1.3.1 General Performance \nDuring the current year, I planned to undertake 4,165 audits. I was able to undertake 2,692 audits which made up 88.1% of the annual approved budget of Government. The summary is in Table 1 below and details are in Annexure I, II. \nA total of 1,473 audits, of which 50% are schools and tertiary institutions, could not be undertaken due to the effects of Covid-19 pandemic and resource constraints. This significantly affected the flow of work from the entities and within the offices. The summary is shown in Table 1 below. \nThe forensic investigations and special audit reports have been issued to the respective stakeholders who requested for them.", "metadata": {"headings": [{"headings_0": {"content": "Summary of Audit Results", "page": 14, "level": 2}}, {"headings_1": {"content": "(v)", "page": 14, "level": 2}}, [{"headings_0": {"content": "Summary of Audit Results", "page": 14, "level": 2}}, {"headings_1": {"content": "(v)", "page": 14, "level": 2}}], [{"headings_0": {"content": "Summary of Audit Results", "page": 14, "level": 2}}, {"headings_1": {"content": "(v)", "page": 14, "level": 2}}], [{"headings_0": {"content": "Summary of Audit Results", "page": 14, "level": 2}}, {"headings_1": {"content": "(v)", "page": 14, "level": 2}}]], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Table 1: Status of audit performance for audit year 2021", "metadata": {"headings": [{"headings_0": {"content": "Table 1: Status of audit performance for audit year 2021", "page": 14, "level": 3}}, {"headings_1": {"content": "Summary of Audit Results", "page": 14, "level": 2}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Type of Entity/Audit Planned Revised Planned Actual", "metadata": {"headings": [{"headings_0": {"content": "Type of Entity/Audit Planned Revised Planned Actual", "page": 14, "level": 3}}, {"headings_1": {"content": "Table 1: Status of audit performance for audit year 2021", "page": 14, "level": 3}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Audits deferred Audits for the Audits for the \naudit year year 2021 \n2021 \nPerformance as during the", "metadata": {"headings": [{"headings_0": {"content": "Type of Entity/Audit Planned Revised Planned Actual", "page": 14, "level": 3}}, {"headings_1": {"content": "Table 1: Status of audit performance for audit year 2021", "page": 14, "level": 3}}, [{"headings_0": {"content": "Type of Entity/Audit Planned Revised Planned Actual", "page": 14, "level": 3}}, {"headings_1": {"content": "Table 1: Status of audit performance for audit year 2021", "page": 14, "level": 3}}]], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "at December 31, year", "metadata": {"headings": [{"headings_0": {"content": "at December 31, year", "page": 14, "level": 3}}, {"headings_1": {"content": "Type of Entity/Audit Planned Revised Planned Actual", "page": 14, "level": 3}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "2021", "metadata": {"headings": [{"headings_0": {"content": "at December 31, year", "page": 14, "level": 3}}, {"headings_1": {"content": "Type of Entity/Audit Planned Revised Planned Actual", "page": 14, "level": 3}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "MDAs 123 170 128 42 Funds 3 3 3 0", "metadata": {"headings": [{"headings_0": {"content": "MDAs 123 170 128 42 Funds 3 3 3 0", "page": 14, "level": 3}}, {"headings_1": {"content": "at December 31, year", "page": 14, "level": 3}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Classified entities 13 13 0 13 International Audits 2 2 2 0 Commissions, Statutory 95 121 107 14 Authorities and State", "metadata": {"headings": [{"headings_0": {"content": "MDAs 123 170 128 42 Funds 3 3 3 0", "page": 14, "level": 3}}, {"headings_1": {"content": "at December 31, year", "page": 14, "level": 3}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Enterprises Projects 167 257 146 111 PSAs 4 8 4 4 Districts 135 135 115 20 Municipal Councils and 41 41 24 17 Cities Lower Local Governments 1,662 2,291 2,048 243 for 18/19 and 19/20", "metadata": {"headings": [{"headings_0": {"content": "Enterprises Projects 167 257 146 111 PSAs 4 8 4 4 Districts 135 135 115 20 Municipal Councils and 41 41 24 17 Cities Lower Local Governments 1,662 2,291 2,048 243 for 18/19 and 19/20", "page": 14, "level": 3}}, {"headings_1": {"content": "MDAs 123 170 128 42 Funds 3 3 3 0", "page": 14, "level": 3}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Regional Referral hospitals 14 14 6 8", "metadata": {"headings": [{"headings_0": {"content": "Enterprises Projects 167 257 146 111 PSAs 4 8 4 4 Districts 135 135 115 20 Municipal Councils and 41 41 24 17 Cities Lower Local Governments 1,662 2,291 2,048 243 for 18/19 and 19/20", "page": 14, "level": 3}}, {"headings_1": {"content": "MDAs 123 170 128 42 Funds 3 3 3 0", "page": 14, "level": 3}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Schools/Tertiary 379 746 0 746", "metadata": {"headings": [{"headings_0": {"content": "Schools/Tertiary 379 746 0 746", "page": 14, "level": 3}}, {"headings_1": {"content": "Enterprises Projects 167 257 146 111 PSAs 4 8 4 4 Districts 135 135 115 20 Municipal Councils and 41 41 24 17 Cities Lower Local Governments 1,662 2,291 2,048 243 for 18/19 and 19/20", "page": 14, "level": 3}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "institutions \nForensics/Special Audit 71 71 8 63 VFM Studies 20 41 8 33 Engineering Audits 230 240 90 150 IT Audits 10 12 3 9", "metadata": {"headings": [{"headings_0": {"content": "Schools/Tertiary 379 746 0 746", "page": 14, "level": 3}}, {"headings_1": {"content": "Enterprises Projects 167 257 146 111 PSAs 4 8 4 4 Districts 135 135 115 20 Municipal Councils and 41 41 24 17 Cities Lower Local Governments 1,662 2,291 2,048 243 for 18/19 and 19/20", "page": 14, "level": 3}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "TOTAL 2,969 4,165 2,692 1,473", "metadata": {"headings": [{"headings_0": {"content": "TOTAL 2,969 4,165 2,692 1,473", "page": 14, "level": 3}}, {"headings_1": {"content": "Schools/Tertiary 379 746 0 746", "page": 14, "level": 3}}], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "2 \n1.3.2 Summary of Opinions \nOf the financial audits concluded (MDA, Commissions, Statutory Authorities and State Enterprises, Projects, Districts and Municipalities), 502 (95%) entities had unqualified opinions while twenty-seven (27) entities had qualified opinions. Table 2 and figure 1 below provides the summary of the Opinions:", "metadata": {"headings": [{"headings_0": {"content": "TOTAL 2,969 4,165 2,692 1,473", "page": 14, "level": 3}}, {"headings_1": {"content": "Schools/Tertiary 379 746 0 746", "page": 14, "level": 3}}, [{"headings_0": {"content": "TOTAL 2,969 4,165 2,692 1,473", "page": 14, "level": 3}}, {"headings_1": {"content": "Schools/Tertiary 379 746 0 746", "page": 14, "level": 3}}]], "page": 14, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Table 2: Summary of Current Year Opinions", "metadata": {"headings": [{"headings_0": {"content": "Table 2: Summary of Current Year Opinions", "page": 15, "level": 3}}, {"headings_1": {"content": "TOTAL 2,969 4,165 2,692 1,473", "page": 14, "level": 3}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["Category of Audited entities", "Type of Opinions", null, null, null, "Total"], ["", "Unqualified", "Qualified", "Adverse", "Disclaimer", ""], ["Ministries, Departments and Agencies 116 12 0 0 128", null, null, null, null, null], ["Commissions, Statutory", "100", "7", "0", "0", "107"], ["Authorities and State", null, null, null, null, null], ["Enterprises", null, null, null, null, null], ["Projects 144 2 0 0 146", null, null, null, null, null], ["Districts Local Governments", "110", "5", "0", "0", "115"], ["Regional Referral hospitals 6 0 0 0 6", null, null, null, null, null], ["Municipal Councils and Cities", "23", "1", "0", "0", "24"], ["Funds 3 0 0 0 3", null, null, null, null, null], ["TOTAL", "502", "27", "0", "0", "529"]], "metadata": {"headings": [{"headings_0": {"content": "Table 2: Summary of Current Year Opinions", "page": 15, "level": 3}}, {"headings_1": {"content": "TOTAL 2,969 4,165 2,692 1,473", "page": 14, "level": 3}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5"], "type": "table"}}, {"content": "\\*The table above excludes Lower Local Governments", "metadata": {"headings": [{"headings_0": {"content": "Table 2: Summary of Current Year Opinions", "page": 15, "level": 3}}, {"headings_1": {"content": "TOTAL 2,969 4,165 2,692 1,473", "page": 14, "level": 3}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Table 3: Trend of Opinions for MDAs, Higher Local Governments for the last three years", "metadata": {"headings": [{"headings_0": {"content": "Table 3: Trend of Opinions for MDAs, Higher Local Governments for the last three years", "page": 15, "level": 3}}, {"headings_1": {"content": "Table 2: Summary of Current Year Opinions", "page": 15, "level": 3}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["Type of Opinion", "2020/21", "2019/20", "2018/19"], ["Unqualified", "502", "420", "433"], ["Qualified 27 33 54", null, null, null], ["Adverse", "0", "0", "0"], ["Disclaimer 0 0 0", null, null, null], ["Total", "529", "453", "487"]], "metadata": {"headings": [{"headings_0": {"content": "Table 3: Trend of Opinions for MDAs, Higher Local Governments for the last three years", "page": 15, "level": 3}}, {"headings_1": {"content": "Table 2: Summary of Current Year Opinions", "page": 15, "level": 3}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "Figure 1: Summary of opinions for the last 3 years", "metadata": {"headings": [{"headings_0": {"content": "Figure 1: Summary of opinions for the last 3 years", "page": 15, "level": 3}}, {"headings_1": {"content": "Table 3: Trend of Opinions for MDAs, Higher Local Governments for the last three years", "page": 15, "level": 3}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "600 500 400 300", "metadata": {"headings": [{"headings_0": {"content": "Figure 1: Summary of opinions for the last 3 years", "page": 15, "level": 3}}, {"headings_1": {"content": "Table 3: Trend of Opinions for MDAs, Higher Local Governments for the last three years", "page": 15, "level": 3}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Unqualified qualified", "metadata": {"headings": [{"headings_0": {"content": "Unqualified qualified", "page": 15, "level": 4}}, {"headings_1": {"content": "Figure 1: Summary of opinions for the last 3 years", "page": 15, "level": 3}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "200 100 0", "metadata": {"headings": [{"headings_0": {"content": "Unqualified qualified", "page": 15, "level": 4}}, {"headings_1": {"content": "Figure 1: Summary of opinions for the last 3 years", "page": 15, "level": 3}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2018/19 2019/20 2020/21", "metadata": {"headings": [{"headings_0": {"content": "2018/19 2019/20 2020/21", "page": 15, "level": 4}}, {"headings_1": {"content": "Unqualified qualified", "page": 15, "level": 4}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "3", "metadata": {"headings": [{"headings_0": {"content": "2018/19 2019/20 2020/21", "page": 15, "level": 4}}, {"headings_1": {"content": "Unqualified qualified", "page": 15, "level": 4}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "metadata": {"headings": [{"headings_0": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}, {"headings_1": {"content": "2018/19 2019/20 2020/21", "page": 15, "level": 4}}], "page": 16, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "2.0 \nREPORT OF THE AUDITOR GENERAL ON THE CONSOLIDATED FINANCIAL STATEMENTS \n2.1 \nREPORT AND OPINION OF THE AUDITOR GENERAL ON THE GOVERNMENT OF UGANDA CONSOLIDATED FINANCIAL STATEMENTS FOR THE YEAR ENDED 30 TH JUNE 2021 \nTHE RT. HON. SPEAKER OF PARLIAMENT", "metadata": {"headings": [{"headings_0": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}, {"headings_1": {"content": "2018/19 2019/20 2020/21", "page": 15, "level": 4}}, [{"headings_0": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}, {"headings_1": {"content": "2018/19 2019/20 2020/21", "page": 15, "level": 4}}], [{"headings_0": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}, {"headings_1": {"content": "2018/19 2019/20 2020/21", "page": 15, "level": 4}}]], "page": 16, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Opinion", "metadata": {"headings": [{"headings_0": {"content": "Opinion", "page": 16, "level": 2}}, {"headings_1": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}], "page": 16, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I have audited the accompanying Consolidated Financial Statements of the Government of the Republic of Uganda for the year ended 30 th June 2021. These financial statements comprise of the Consolidated Statement of Financial Position as at 30 th June 2021, the Consolidated Statement of Financial Performance, and Consolidated Cash Flow Statement together with other accompanying statements, notes, and accounting policies. \nIn my opinion, the Consolidated Financial statements of the Government of the Republic of Uganda for the financial year ended 30th June 2021 are prepared, in all material respects, in accordance with Section 52 of the Public Finance Management Act, 2015 and the Financial Reporting Guide, 2018. \nBasis for Opinion", "metadata": {"headings": [{"headings_0": {"content": "Opinion", "page": 16, "level": 2}}, {"headings_1": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}, [{"headings_0": {"content": "Opinion", "page": 16, "level": 2}}, {"headings_1": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}], [{"headings_0": {"content": "Opinion", "page": 16, "level": 2}}, {"headings_1": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}]], "page": 16, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "I conducted my audit in accordance with International Standards of Supreme Audit Institutions (ISSAIs). My responsibilities under those standards are further described in the Auditor\u2019s Responsibilities for the Audit of the Financial Statement\u2019s section of my report. I am independent of the Treasury in accordance with the Constitution of the Republic of Uganda (1995) as amended, the National Audit Act, 2008, the International Ethics Standards Board for Accountants (IESBA) Code of Ethics for Professional Accountants (Parts A and B), the International Organization of Supreme Audit Institutions (INTOSAI) Code of Ethics and other independence requirements applicable to performing audits of Financial Statements in Uganda. I have fulfilled my other ethical responsibilities in accordance with the IESBA Code, and in accordance with other ethical requirements applicable to performing audits in Uganda. I believe that the audit evidence I have obtained is sufficient and appropriate to provide a basis for my qualified opinion. \nKey Audit Matter \nKey audit matters are those matters that, in my professional judgment, were of most significance in my audit of the financial statements of the current period. These matters were addressed in the context of my audit of the financial statements as a whole, and in forming my opinion thereon, and I do not provide a separate opinion on these matters. I have determined the matters described below to be key audit matters communicated in my report.", "metadata": {"headings": [{"headings_0": {"content": "Opinion", "page": 16, "level": 2}}, {"headings_1": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}, [{"headings_0": {"content": "Opinion", "page": 16, "level": 2}}, {"headings_1": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}], [{"headings_0": {"content": "Opinion", "page": 16, "level": 2}}, {"headings_1": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}]], "page": 16, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.1.1.", "metadata": {"headings": [{"headings_0": {"content": "2.1.1.", "page": 16, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 16, "level": 2}}], "page": 16, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Implementation of the approved budget \nOn the 24 th April 2020, Parliament approved the annual budget for MDAs and LGs that contained the specific resource envelope allocated to each vote to implement agreed on \n4 \noutputs. Subsequently, the PS/ST issued a Budget Execution Circular that communicated the budget strategy, policy, and administrative issues to guide the budget implementation for the financial year 2020/2021. \nDuring my overall risk assessment exercise, I noted that MDAs and LGs are still experiencing challenges in implementing the budgets approved by parliament and policy guidance\u2019s issued by PS/ST, which has continued to affect the performance and credibility of the budget negatively. These challenges include; lack of strategic plans that are aligned to the National Development Plans, underperformance of revenue, implementation of off-budget activities, under absorption of funds, insufficient quantification of outputs, partial and non- implementation of outputs, diversion of funds and challenges in budget monitoring and reporting of performance. \nI am aware that the Covid-19 Pandemic continues to significantly affect the implementation of several activities. Consequently, a number of activities were not implemented due to budget cuts and lockdown measures instituted to control the spread of the pandemic. It is against this background that the implementation of the budget was again considered a key audit area during the office-wide planning for the current audit year. \nConsequently, I developed procedures to address the performance of the budget of the entity (Detailed reports are provided in individual entity reports). \nFrom the procedures undertaken, I noted the following; \nSN Finding Recommendation a) Revenue performance \nI advised the Secretary to the", "metadata": {"headings": [{"headings_0": {"content": "2.1.1.", "page": 16, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 16, "level": 2}}, [{"headings_0": {"content": "2.1.1.", "page": 16, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 16, "level": 2}}], [{"headings_0": {"content": "2.1.1.", "page": 16, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 16, "level": 2}}], [{"headings_0": {"content": "2.1.1.", "page": 16, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 16, "level": 2}}], [{"headings_0": {"content": "2.1.1.", "page": 16, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 16, "level": 2}}], [{"headings_0": {"content": "2.1.1.", "page": 16, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 16, "level": 2}}], [{"headings_0": {"content": "2.1.1.", "page": 16, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 16, "level": 2}}], [{"headings_0": {"content": "2.1.1.", "page": 16, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 16, "level": 2}}], [{"headings_0": {"content": "2.1.1.", "page": 16, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 16, "level": 2}}]], "page": 16, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "A review of the approved budget estimates of the Government of Treasury to devise Uganda for the financial year ended 30 th June 2021 revealed that the means of ensuring", "metadata": {"headings": [{"headings_0": {"content": "A review of the approved budget estimates of the Government of Treasury to devise Uganda for the financial year ended 30 th June 2021 revealed that the means of ensuring", "page": 17, "level": 3}}, {"headings_1": {"content": "2.1.1.", "page": 16, "level": 2}}], "page": 17, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "initial approved budget (resource envelope) for the financial year that all budgeted", "metadata": {"headings": [{"headings_0": {"content": "A review of the approved budget estimates of the Government of Treasury to devise Uganda for the financial year ended 30 th June 2021 revealed that the means of ensuring", "page": 17, "level": 3}}, {"headings_1": {"content": "2.1.1.", "page": 16, "level": 2}}], "page": 17, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2020/21 was UGX.45,493.69 Bn. The funding was later revised to revenue is always UGX.48,726.77 Bn, following approval for additional domestic collected to fund the financing of UGX.3,234 Bn. It was estimated that Tax and Non Tax budget as approved. revenue amounted to UGX.22,024.66 Bn, domestic borrowing would finance UGX.6,794 Bn while external financing would provide grants", "metadata": {"headings": [{"headings_0": {"content": "2020/21 was UGX.45,493.69 Bn. The funding was later revised to revenue is always UGX.48,726.77 Bn, following approval for additional domestic collected to fund the financing of UGX.3,234 Bn. It was estimated that Tax and Non Tax budget as approved. revenue amounted to UGX.22,024.66 Bn, domestic borrowing would finance UGX.6,794 Bn while external financing would provide grants", "page": 17, "level": 3}}, {"headings_1": {"content": "A review of the approved budget estimates of the Government of Treasury to devise Uganda for the financial year ended 30 th June 2021 revealed that the means of ensuring", "page": 17, "level": 3}}], "page": 17, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "of UGX.1,719.91Bn and loans of UGX.10,702.10Bn.", "metadata": {"headings": [{"headings_0": {"content": "2020/21 was UGX.45,493.69 Bn. The funding was later revised to revenue is always UGX.48,726.77 Bn, following approval for additional domestic collected to fund the financing of UGX.3,234 Bn. It was estimated that Tax and Non Tax budget as approved. revenue amounted to UGX.22,024.66 Bn, domestic borrowing would finance UGX.6,794 Bn while external financing would provide grants", "page": 17, "level": 3}}, {"headings_1": {"content": "A review of the approved budget estimates of the Government of Treasury to devise Uganda for the financial year ended 30 th June 2021 revealed that the means of ensuring", "page": 17, "level": 3}}], "page": 17, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The table below summaries the performance of revenue by source;", "metadata": {"headings": [{"headings_0": {"content": "The table below summaries the performance of revenue by source;", "page": 17, "level": 3}}, {"headings_1": {"content": "2020/21 was UGX.45,493.69 Bn. The funding was later revised to revenue is always UGX.48,726.77 Bn, following approval for additional domestic collected to fund the financing of UGX.3,234 Bn. It was estimated that Tax and Non Tax budget as approved. revenue amounted to UGX.22,024.66 Bn, domestic borrowing would finance UGX.6,794 Bn while external financing would provide grants", "page": 17, "level": 3}}], "page": 17, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Funding source Approved Revised Actual (Bn) Variance Perform Budget (Bn) - budget", "metadata": {"headings": [{"headings_0": {"content": "The table below summaries the performance of revenue by source;", "page": 17, "level": 3}}, {"headings_1": {"content": "2020/21 was UGX.45,493.69 Bn. The funding was later revised to revenue is always UGX.48,726.77 Bn, following approval for additional domestic collected to fund the financing of UGX.3,234 Bn. It was estimated that Tax and Non Tax budget as approved. revenue amounted to UGX.22,024.66 Bn, domestic borrowing would finance UGX.6,794 Bn while external financing would provide grants", "page": 17, "level": 3}}], "page": 17, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UGX (Bn) - ance UGX (Bn)-UGX UGX (%)", "metadata": {"headings": [{"headings_0": {"content": "The table below summaries the performance of revenue by source;", "page": 17, "level": 3}}, {"headings_1": {"content": "2020/21 was UGX.45,493.69 Bn. The funding was later revised to revenue is always UGX.48,726.77 Bn, following approval for additional domestic collected to fund the financing of UGX.3,234 Bn. It was estimated that Tax and Non Tax budget as approved. revenue amounted to UGX.22,024.66 Bn, domestic borrowing would finance UGX.6,794 Bn while external financing would provide grants", "page": 17, "level": 3}}], "page": 17, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Domestic Resources \nTaxes 20,218.68 20,218.68 18,252 1,966.68 90 \nNon-Tax 1,805.98 1,805.98 1,648 157.98 91 revenue 1 \nDomestic 3,560.32 6,794 6,794 - 100 financing \nDomestic 7,486.1 7,486.1 7,420 66.1 99 refinancing", "metadata": {"headings": [{"headings_0": {"content": "The table below summaries the performance of revenue by source;", "page": 17, "level": 3}}, {"headings_1": {"content": "2020/21 was UGX.45,493.69 Bn. The funding was later revised to revenue is always UGX.48,726.77 Bn, following approval for additional domestic collected to fund the financing of UGX.3,234 Bn. It was estimated that Tax and Non Tax budget as approved. revenue amounted to UGX.22,024.66 Bn, domestic borrowing would finance UGX.6,794 Bn while external financing would provide grants", "page": 17, "level": 3}}, [{"headings_0": {"content": "The table below summaries the performance of revenue by source;", "page": 17, "level": 3}}, {"headings_1": {"content": "2020/21 was UGX.45,493.69 Bn. The funding was later revised to revenue is always UGX.48,726.77 Bn, following approval for additional domestic collected to fund the financing of UGX.3,234 Bn. It was estimated that Tax and Non Tax budget as approved. revenue amounted to UGX.22,024.66 Bn, domestic borrowing would finance UGX.6,794 Bn while external financing would provide grants", "page": 17, "level": 3}}]], "page": 17, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "1 Includes Appropriation in Aid of UGX 215 billion.", "metadata": {"headings": [{"headings_0": {"content": "1 Includes Appropriation in Aid of UGX 215 billion.", "page": 17, "level": 3}}, {"headings_1": {"content": "The table below summaries the performance of revenue by source;", "page": 17, "level": 3}}], "page": 17, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "5", "metadata": {"headings": [{"headings_0": {"content": "1 Includes Appropriation in Aid of UGX 215 billion.", "page": 17, "level": 3}}, {"headings_1": {"content": "The table below summaries the performance of revenue by source;", "page": 17, "level": 3}}], "page": 17, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN Finding", null, null, null, null, null, null, "Recommendation"], ["\uf0b7 \uf0b7 A \uf0b7 \uf0b7 A \uf0b7", "External Resources", null, null, null, null, null, null], [null, "Budget support", null, null, null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "1 Includes Appropriation in Aid of UGX 215 billion.", "page": 17, "level": 3}}, {"headings_1": {"content": "The table below summaries the performance of revenue by source;", "page": 17, "level": 3}}], "page": 18, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4", "column_7", "column_8", "column_9", "column_10", "column_11"], "type": "table"}}, {"content": [["SN Finding", null, null, null, null, null, null, "Recommendation"], ["\uf0b7 \uf0b7 A \uf0b7 \uf0b7 A \uf0b7", "External Resources", null, null, null, null, null, null], [null, "Budget support", null, null, null, null, null, null], [null, "Grants", "133.56", "133.56", "62.85", "70.71", "47", null], [null, "", null, null, null, null, null, null], [null, "Loans", "2,773.12", "2,773.12", "3,134.13", "-361.01", "113", null], [null, "Project support", "", "", "", "", "", null], [null, "", null, null, null, null, null, null], [null, "Grants", "1,586.35", "1,586.35", "1,026.04", "560.31", "65", null], [null, "Loans", "7,928.98", "7,928.98", "6,822.23", "1,106.75", "86", null], [null, "", null, null, null, null, null, null], [null, "Grand Total", "45,493.09", "48,726.77", "45,159.25", "1,667.06", "93", null], [null, "", null, null, null, null, null, null], [null, "Actual funding for the budget during the financial year was UGX.", null, null, null, null, null, null], [null, "45,159.25Bn (93%) against a revised revenue budget of UGX.", null, null, null, null, null, null], [null, "48,726.77Bn, indicating a shortfall of UGX. 3,567.52Bn. The details of", null, null, null, null, null, null], [null, "funding source are provided below.", null, null, null, null, null, null], [null, "", null, null, null, null, null, null], [null, "Taxes total tax revenue collected during the year was UGX.", null, null, null, null, null, null], [null, "19,697.7Bn, representing 90% of the approved estimates.", null, null, null, null, null, null], [null, "", null, null, null, null, null, null], [null, "Non-tax revenue total of UGX.1,605.42Bn was realised from this source against a", null, null, null, null, null, null], [null, "target of UGX.1,805.98Bn representing a performance of 89%.", null, null, null, null, null, null], [null, "Budgeting for NTR remains a challenge at the Treasury, as the", null, null, null, null, null, null], [null, "figures included in the revenue estimates are not agreed with", null, null, null, null, null, null], [null, "individual votes, and a number of entities do not reflect NTR in their", null, null, null, null, null, null], [null, "budgets.", null, null, null, null, null, null], [null, "", null, null, null, null, null, null], [null, "Budget support Government planned to raise a total of UGX.2,906.68 Bn for budget", null, null, null, null, null, null], [null, "support of which 5% was grants while 95% was from loans. Grants", null, null, null, null, null, null], [null, "underperformed by 52% while Government acquired loans of", null, null, null, null, null, null], [null, "UGX.361 Bn in excess of what was planned translating into a 113%", null, null, null, null, null, null], [null, "performance. The increase in loans for budget support related to", null, null, null, null, null, null], [null, "additional borrowing that was secured in light of COVID -19", null, null, null, null, null, null], [null, "disruptions.", null, null, null, null, null, null], [null, "", null, null, null, null, null, null], [null, "Project support total of UGX.9,515.33 Bn (20%) of the approved budget was", null, null, null, null, null, null], [null, "planned for project support of which grants and loans were", null, null, null, null, null, null], [null, "UGX.1,586.35 Bn and UGX.7,928.98 Bn respectively. Grants", null, null, null, null, null, null], [null, "underperformed by 60% (UGX.1,026.04 Bn) while UGX.6,822.23 Bn", null, null, null, null, null, null], [null, "(83%) was realised from the loans.", null, null, null, null, null, null], [null, "", null, null, null, null, null, null], [null, "Domestic refinancing Government planned to pay back maturing Treasury Instruments by", null, null, null, null, null, null], [null, "borrowing afresh from the market (domestic refinance) to a tune of", null, null, null, null, null, null], [null, "UGX.7,486.1 Bn, of which UGX.7,420Bn (99%) was realised.", null, null, null, null, null, null], [null, "", null, null, null, null, null, null], [null, "Management attributed the Tax and Non tax Revenue shortfall", null, null, null, null, null, null], [null, "mainly to the lockdown measures that were instituted by government", null, null, null, null, null, null], [null, "curb the spread of the COVID 19 that constrained revenue major", null, null, null, null, null, null], [null, "sources and the slow Economic growth which is a major contributor", null, null, null, null, null, null], [null, "taxes that declined from the projected 6.4% to 3.1%. Deficits", null, null, null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "1 Includes Appropriation in Aid of UGX 215 billion.", "page": 17, "level": 3}}, {"headings_1": {"content": "The table below summaries the performance of revenue by source;", "page": 17, "level": 3}}], "page": 18, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4", "column_7", "column_8", "column_9", "column_10", "column_11"], "type": "table"}}, {"content": "each The", "metadata": {"headings": [{"headings_0": {"content": "each The", "page": 18, "level": 3}}, {"headings_1": {"content": "1 Includes Appropriation in Aid of UGX 215 billion.", "page": 17, "level": 3}}], "page": 18, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "to", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "each The", "page": 18, "level": 3}}], "page": 18, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "to", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 18, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "6", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 18, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN Finding", "Recommendation"], ["were registered in CIT, VAT, excise duty and Corporation Tax since companies were not working. The EFRIS has now been rolled out and Digital stamps implementation is under way to revive revenue collection. Management also indicated that NTR Budget estimates books have been revised and the budget process for NTR enhanced to incorporate Universities fees collection which was a major challenge in terms of providing the right estimates. The NTR Budget consultation process for FY 2022/23 had been concluded for all Votes and a realistic target set for NTR collections.", null], ["b) Unfunded approved budget During the year under review, Government budgeted to spend a total of UGX.45,439 Bn, which was later revised to UGX.51,625 Bn. An analysis of warrants approved revealed that a total of UGX.46,657 Bn was approved against the budgeted amounts, thus representing 90% performance. A sum of UGX.4,968 Bn was not availed for expenditure. See table below; Entity Percenta ge Total Revised Budget \u2013 UGX(bn) Total warrants - UGX(bn) Variance- UGX(bn) Central Govt 73.42% 37,904.70 35,717.10 2,187.7 Local Govt 8.38% 4,327.80 4,218.40 109.4 Local Revenue 0.42% 217.4 115.3 102.0 Project Financing 17.77% 9,176.00 6,606.80 2,569.2 Total 51,626.00 46,657.60 4,968.4 Failure to fully fund the revised budget affected the implementation of the planned activities which were intended to contribute to the achievement of the NDP III and Vision 2040. The detailed impact of this shortfall on the entity activities has been reported in the individual entity reports. Notably, there was a significant variance in project financing which is explained by under absorption by the various implementing MDAs. It was observed that whereas the performance contracts with Accounting Officers are premised on availing the appropriated budgets during the year, such contracts are not revised in situations of shortfalls in budgets. The Secretary to Treasury indicated that the funds releases to Votes are in line with the available resources issued in quarterly expenditure limits which are supported by actual revenue collections from URA and also indicated that Ministry of finance provides guidance by way of circulars to all Votes to fund only critical activities within the work plans in line with the available resources. The Secretary to Treasury committed to improving releases as I advised the PSST to provide guidance to MDAs in regard to the prioritization of activities to the levels of availed resources in cases of shortfalls.", null]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 19, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_7"], "type": "table"}}, {"content": "7", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 19, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN Finding", "Recommendation"], ["revenue collections improve with the economy recovering from the current economic shocks.", null], ["c) Unspent warrants/under absorption of funds UGX .3,018.44Bn Section 45 (3) of the Public Finance Management Act, 2015 states that an Accounting Officer shall enter into an annual budget performance contract with the Secretary to the Treasury which shall bind the Accounting Officer to deliver on the activities in the work plan of the vote for a Financial year. It was observed that warrants worth UGX.46,657.6 billion were approved in respect of various entities for which only UGX.43,639.2 billion was paid out leaving UGX.3,018.4 billion (6.5% of approved warrants) unspent. The details are indicated in the table below; Approved Warrants (UGX\u2019 billion) Total Payments (UGX\u2019 billion) Unspent funds (UGX\u2019 billion) ENTI TY Wage Non - Wage Develop ment wage Non - Wage Develo pment wag e Non- Wage Dev CG 2,710 23,647 15,771 2,637 21,32 15,725 73 2,327 45 Missi ons 28 149 18 28 149 17.9 - - - LG 2,271 1,071 992.1 2,151 1,025 586 119 46 406 TOTA L 5,009 24,867 16,781 4,816 22,494 16,329 193 2,373 452 From the above, it can be seen that 79% of the unspent funds related to non-wage expenditure while wage and development expenditure posted underperformance of 6% and 15% respectively. 98% of the unspent funds under non-wage related to Vote 130 (Treasury Operations) and were meant to settle interest costs and treasury bills and Bonds redemptions. The occurrence has an implication of increasing financing costs incurred by the government since the interest costs and redemptions are done by Bank of Uganda which in turn charges the treasury for the advance. Most of the unspent funds under wage related to pension payments casting doubt on the existence of the said pensioners. Under absorption negatively affects service delivery since some of the planned projects and activities are not undertaken. The Secretary to Treasury indicated that GoU operates a Cash budget which is based on actual inflows. The year under audit experienced cash shortfalls arising from, Domestic revenue shortfall as a result of the Covid -19 pandemic , late disbursements from IMF ,which came in on 30 June 2021 & Non disbursement from Afri-Exim Bank and African Development Fund. The occurrence contributed to delay in implementation of planned activities hence the under absorption of funds.", "I advised the"]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 20, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_11"], "type": "table"}}, {"content": [["SN Finding", "Recommendation"], ["revenue collections improve with the economy recovering from the current economic shocks.", null], ["c) Unspent warrants/under absorption of funds UGX .3,018.44Bn Section 45 (3) of the Public Finance Management Act, 2015 states that an Accounting Officer shall enter into an annual budget performance contract with the Secretary to the Treasury which shall bind the Accounting Officer to deliver on the activities in the work plan of the vote for a Financial year. It was observed that warrants worth UGX.46,657.6 billion were approved in respect of various entities for which only UGX.43,639.2 billion was paid out leaving UGX.3,018.4 billion (6.5% of approved warrants) unspent. The details are indicated in the table below; Approved Warrants (UGX\u2019 billion) Total Payments (UGX\u2019 billion) Unspent funds (UGX\u2019 billion) ENTI TY Wage Non - Wage Develop ment wage Non - Wage Develo pment wag e Non- Wage Dev CG 2,710 23,647 15,771 2,637 21,32 15,725 73 2,327 45 Missi ons 28 149 18 28 149 17.9 - - - LG 2,271 1,071 992.1 2,151 1,025 586 119 46 406 TOTA L 5,009 24,867 16,781 4,816 22,494 16,329 193 2,373 452 From the above, it can be seen that 79% of the unspent funds related to non-wage expenditure while wage and development expenditure posted underperformance of 6% and 15% respectively. 98% of the unspent funds under non-wage related to Vote 130 (Treasury Operations) and were meant to settle interest costs and treasury bills and Bonds redemptions. The occurrence has an implication of increasing financing costs incurred by the government since the interest costs and redemptions are done by Bank of Uganda which in turn charges the treasury for the advance. Most of the unspent funds under wage related to pension payments casting doubt on the existence of the said pensioners. Under absorption negatively affects service delivery since some of the planned projects and activities are not undertaken. The Secretary to Treasury indicated that GoU operates a Cash budget which is based on actual inflows. The year under audit experienced cash shortfalls arising from, Domestic revenue shortfall as a result of the Covid -19 pandemic , late disbursements from IMF ,which came in on 30 June 2021 & Non disbursement from Afri-Exim Bank and African Development Fund. The occurrence contributed to delay in implementation of planned activities hence the under absorption of funds.", "I advised the"], [null, "Secretary to the"], [null, "Treasury to"], [null, "strengthen the cash"], [null, "forecasting function"], [null, "to avoid issuing"], [null, "warrants that cannot"], [null, "be financed."], [null, ""], [null, ""], ["d) Approval of supplementary funding without matching revenue Section 25(1) of the Public Finance and Accountability Act (PFMA) stipulates that the total supplementary expenditure that requires additional resources over and above what is approved by Parliament I await the outcome of the new measures.", null]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 20, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_11"], "type": "table"}}, {"content": "8", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 20, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN", "Finding", "Recommendation"], ["shall not exceed 3% of the total approved budget for that financial year, without the approval of Parliament. It was established that during the financial year ended 30 th June 2021, supplementary funding totalling UGX.6.13Tn was granted by the Minister of Finance, Planning and Economic Development. It was, however, noted that the source of the funding for the supplementary expenditure was not clearly shown before approval was granted. As a result, the supplementary expenditure was instead financed by internal budget cuts from various votes thus affecting implementation of plans/ activities by the affected votes. I noted that, although the budget was increased to UGX.51.625Tn, it was only funded to the tune of UGX.46.6Tn (90%funding). Continued approval of supplementary budgets without a corresponding increase in revenue/financing could be attributed to fiscal indiscipline which leads to increased funding gap affecting the earlier budget objectives and plans. The Secretary to Treasury responded that for the Financial Year 2022/23, the Ministry of Finance was using zero based budgeting approach to prioritize critical activities and expenditures to avoid supplementary requests during execution. The budget for 2022/23 is being used as a launchpad for restricting supplementary budgets to stabilize GoU budget execution going forward.", null, null], ["e)", "Budgeting for Non-Tax Revenue", "I advised the PSST"]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 21, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["SN", "Finding", "Recommendation"], ["shall not exceed 3% of the total approved budget for that financial year, without the approval of Parliament. It was established that during the financial year ended 30 th June 2021, supplementary funding totalling UGX.6.13Tn was granted by the Minister of Finance, Planning and Economic Development. It was, however, noted that the source of the funding for the supplementary expenditure was not clearly shown before approval was granted. As a result, the supplementary expenditure was instead financed by internal budget cuts from various votes thus affecting implementation of plans/ activities by the affected votes. I noted that, although the budget was increased to UGX.51.625Tn, it was only funded to the tune of UGX.46.6Tn (90%funding). Continued approval of supplementary budgets without a corresponding increase in revenue/financing could be attributed to fiscal indiscipline which leads to increased funding gap affecting the earlier budget objectives and plans. The Secretary to Treasury responded that for the Financial Year 2022/23, the Ministry of Finance was using zero based budgeting approach to prioritize critical activities and expenditures to avoid supplementary requests during execution. The budget for 2022/23 is being used as a launchpad for restricting supplementary budgets to stabilize GoU budget execution going forward.", null, null], ["e)", "Budgeting for Non-Tax Revenue", "I advised the PSST"], [null, "", "to ensure that all"], [null, "Section 6 of the Budget Execution Circular for the FY 2020/21", "Ministries,"], [null, "provides that all work plans and Budgets for FY2020/21 are prepared", "Departments and"], [null, "and approved using the Program Budgeting System (PBS). All", "Agencies budget for"], [null, "Budgets, irrespective of the source of financing (GoU, NTR/AIA,", "the Non-Tax Revenue"], [null, "Donor or LG Revenue), will be migrated and loaded into the", "and have the details"], [null, "Integrated Financial Management System (IFMS) to facilitate Budget", "provided in the IFMS"], [null, "Implementation and reporting.", "and the PBS."], [null, "", ""], [null, "According to the approved budget estimates for the FY2020/21, it", null], [null, "was projected that a total of UGX.1.590 Tn would be collected as", null], [null, "NTR. Review of the Performance Budgeting System(PBS) tool used", null], [null, "by the Government and IFMS records revealed that that NTR Budgets", null], [null, "for the respective MDAs were neither uploaded on PBS nor IFMS. The", null], [null, "budgeting tool only had details regarding expenditure, and no", null], [null, "revenue was included. I further noted that several Accounting", null], [null, "Officers disowned the figures incorporated in the NTR Estimates", null], [null, "book, indicating that they had not been consulted in arriving at the", null], [null, "estimates incorporated therein.", null], [null, "", null], [null, "As a result, I was unable to compare respective entity budget figures", null], [null, "with the URA NTR collections that totalled to UGX.1.605Tn. The", null], [null, "absence of revenue estimates for each entity undermines", null], [null, "transparency, affects motivation of staff, and hampers performance", null], [null, "assessment.", null], [null, "", null], [null, "Management responded that for the budget of FY 2022/23,", null]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 21, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "9", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 21, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN", "Finding", "Recommendation"], ["", "respective MDAs had been requested to submit their NTR estimates", null], [null, "which will be uploaded and reflected on the PBS as had been done", null]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 22, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": [["SN", "Finding", "Recommendation"], ["", "respective MDAs had been requested to submit their NTR estimates", null], [null, "which will be uploaded and reflected on the PBS as had been done", null], [null, "in the NTR estimates booklets. PBS has been upgraded to include the", null], [null, "NTR budgets for Votes. The approved estimates will also be uploaded", null], [null, "on the IFMS for follow up on monthly performance reports.", null], [null, "", null], [null, "", null], [null, "", null], [null, "", null], ["f) Quantification of activities and Implementation of planned outputs Section 13 (15, b) of the PFMA 2015 states that a policy statement submitted by a vote shall contain the annual and three months\u2019 work plans, outputs, targets and performance indicators of the work plans. Regulation 11 (3) of PFMR 2016 requires that a vote prepares a work plan that indicates the outputs of the vote for the financial year; the indicators to be used to gauge the performance of the outputs and funds allocated to each activity. I sampled 94 entities for purposes of assessing the extent of quantification and implementation of planned outputs I noted that out of the 1,681 outputs worth UGX.9.8tn sampled for review, 1,151 outputs (68.5%) worth UGX.6.8tn were fully quantified, 307 outputs (18.3%) worth UGX.2.1tn were partially quantified while 223 out puts (13.2%) worth UGX.902Bn were not quantified at all. Out of a total of 1,151 quantified out-puts worth UGX.6.8tn assessed, 465 (40.4%) output worth UGX.2.5tn were fully implemented, 592 outputs (51.4%) worth UGX.4.1tn were partially implemented, while 94 (8.2%) out-puts worth UGX.146bn were not implemented at all. The graph below shows the extent of implementation; Failure to fully quantify the planned activities makes the assessment of implementation difficult. The Accounting Officers indicated that the outbreak of the Covid-19 Pandemic affected the implementation of the 2019/2020 budget, especially activities in the last half of the financial year. I advised the PSST to follow up the matter with the Accounting Officers of the various MDAs to ensure that there is full quantification of activities and outputs.", null, null], ["g)", "Existence of Strategic plans that are aligned to NDP-III", "I advised the PSST"], [null, null, "to follow up the"], [null, "Paragraph 5 of the budget execution circular for the financial year", "matter with NPA and"], [null, "2020/2021 cites poor alignment of Government Budgets with the", "ensure that the"], [null, "National Development Plans. The PS/ST urged Accounting Officers to", "entities have"], [null, "ensure that all activities for Financial Year 2020/2021 are aligned", "strategic plans that"], [null, "with NDP III and implemented accordingly. Regulation 26 (1) of the", "are aligned to NDP-"], [null, "National Planning Authority (development of Plans) regulations", "III and certified by"], [null, "require entities to submit to NPA their five-year development plans", "NPA."], [null, "for certification before approval.", ""], [null, "", null], [null, "This being the first year of implementation of the NDP-III, MDAs", null], [null, "were expected to prepare strategic plans aligned to NDP III and", null], [null, "ensure that these plans are certified by NPA before approval. These", null], [null, "plans would then be the basis for preparation of the entity annual", null]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 22, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": "10", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 22, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN", "Finding", "Recommendation"], ["", "plans.", null], [null, "", null], [null, "From the procedures undertaken I noted that out of 94 entities", null], [null, "sampled, 75 were supposed to prepare strategic plans that were", null], [null, "aligned to NDPII. However, out of 75 only 25 (33%) had their", null], [null, "strategic plans certified by NPA. The balance of 50 representing 67%", null], [null, "were not certified by NPA. There is a risk that activities implemented", null], [null, "by these entities during the financial year 2020/2021 were not", null], [null, "aligned to the NDP-III which negatively affects the achievement of", null], [null, "NDP-III objectives.", null], [null, "", null], ["h) Off Budget Financing/Receipts Section 43 (1) of the PFMA 2015 states that all expenditure incurred by the government on externally financed projects in a financial year shall be appropriated by parliament. Paragraph 29 of the Budget Execution Circular for the Financial year states that if an external agency provides funds in the course of implementation of the budget or any funds remain unspent at the expiry of an appropriation, these must be declared and a supplementary issued in line with the Public Finance Management Act 2015. I noted that 30 entities received off-budget financing to a tune of UGX.627.124Bn, which was never declared to the PS/ST and was also not appropriated by Parliament. As such, no supplementary appropriation was issued as guided by the PS/ST. These funds were received directly from development partners for undertaking activities not budgeted for. Off-budget financing distorts planning, may result in duplication of activities, contrary to Section 43(1) of the PFMA 2015 and the budget execution guidelines. The Accounting Officers explained that this was due to limitations of the PBS system which has no provision for inputting such receipts and in some cases funds are received during the year which were not expected at the time of planning. I advised the Accounting Officers to comply with the law and guidance given by the PSST and ensure that in future, all funds received outside the approved budget are appropriated by way of a supplementary.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 23, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "2.1.2. COVID 19 expenditure \nThe emergence of the Global Covid-19 pandemic presented a social and economic threat to many countries in the world, including Uganda. In response, the Government of Uganda developed and instituted several interventions to control and avert the effects of the pandemic on the economic and social wellbeing of its citizens. The interventions included instituting a total lockdown, closure of airports, restriction of cross boarder movements, and increased surveillance among others which in turn necessitated additional funding. Mobilisation of revenue was also negatively affected due to low economic activity. \nIn addition to the local revenue raised by the Government to support the budget, Government proceeded to secure additional funding to facilitate the efforts and interventions \n11 \nbeing undertaken to manage and control COVID-19 and its effects on the economy and the society in general. \nIn a letter dated 09th August 2021, the PSST advised me that the total amount released for COVID expenditure in the FY 2020/21 was UGX.2,371Bn of which a total of UGX.677Bn was disbursed for the settlement of domestic arrears. \nDuring the audit, I designed and performed procedures that I considered appropriate under the circumstances to enable me to gather evidence to address the specific objectives listed below; \ni) Confirm whether the funds received by Treasury were dully appropriated by parliament.", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}, [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}]], "page": 23, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ii)", "metadata": {"headings": [{"headings_0": {"content": "ii)", "page": 24, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Establish whether funds appropriated and allocated were received by the different votes", "metadata": {"headings": [{"headings_0": {"content": "ii)", "page": 24, "level": 3}}, {"headings_1": {"content": "to", "page": 18, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii)", "metadata": {"headings": [{"headings_0": {"content": "iii)", "page": 24, "level": 3}}, {"headings_1": {"content": "ii)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Establish whether the appropriated funds were utilised for the purpose for which they were approved.", "metadata": {"headings": [{"headings_0": {"content": "iii)", "page": 24, "level": 3}}, {"headings_1": {"content": "ii)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iv)", "metadata": {"headings": [{"headings_0": {"content": "iv)", "page": 24, "level": 3}}, {"headings_1": {"content": "iii)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Assess the existence and effectiveness of internal control systems.", "metadata": {"headings": [{"headings_0": {"content": "iv)", "page": 24, "level": 3}}, {"headings_1": {"content": "iii)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "v)", "metadata": {"headings": [{"headings_0": {"content": "v)", "page": 24, "level": 3}}, {"headings_1": {"content": "iv)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Assess the extent of achievement of planned output by the different entities \nvi) Establish whether all funds disbursed were properly accounted for and value for money was attained.", "metadata": {"headings": [{"headings_0": {"content": "v)", "page": 24, "level": 3}}, {"headings_1": {"content": "iv)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "vii)", "metadata": {"headings": [{"headings_0": {"content": "vii)", "page": 24, "level": 3}}, {"headings_1": {"content": "v)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Make appropriate recommendations to strengthen accountability and transparency. \nFrom the procedures undertaken the following summarised key findings were noted, the detailed report was issued separately as the COVID 19 thematic report; \nSummary of key findings", "metadata": {"headings": [{"headings_0": {"content": "vii)", "page": 24, "level": 3}}, {"headings_1": {"content": "v)", "page": 24, "level": 3}}, [{"headings_0": {"content": "vii)", "page": 24, "level": 3}}, {"headings_1": {"content": "v)", "page": 24, "level": 3}}], [{"headings_0": {"content": "vii)", "page": 24, "level": 3}}, {"headings_1": {"content": "v)", "page": 24, "level": 3}}]], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- USD 345million received by GoU in respect of support to Bank of Uganda for Balance of Payment was confirmed received and banked intact in Citi bank New York to enhance", "metadata": {"headings": [{"headings_0": {"content": "vii)", "page": 24, "level": 3}}, {"headings_1": {"content": "v)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "vii)", "page": 24, "level": 3}}, {"headings_1": {"content": "v)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "the Country\u2019s foreign reserves.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- A total of UGX 676Bn was allocated and disbursed to various MDAs to settle domestic arrears with a view of improving liquidity within the local business community. I noted that 90% of funds used appropriately for the intended puropose; however, I noted diversion of funds to pay for unrelated expenditure worth UGX 4.897Bn (0.7%), unsupported domestic arrears of UGX 27.38Bn(4%), and Payment for contested/rejected domestic arrears of UGX.1.245Bn(0.2%). I also noted that UGX 33.8Bn (5%) was used to settle international obligations thus did not contribute to the stated objective since the funds were externalised.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UGX 260Bn allocated for the Emyooga programme was disbursed to Microfinance Support Centre with a goal of transforming household incomes by increasing employment opportunities and access to financial services to the rural areas. Audit confirmed that UGX 219.40Bn (84%) had so far been disbursed to 6,326 EMYOOGA SACCOs. It was, however, noted that the SACCOs were in the process of obtaining operational licenses; no MoUs had been entered into between the disbursing entity and the beneficiary SACCOs; UGX.34,716,666,049 (1.3%), though disbursed, remained un- accessed by the beneficiary SACCO.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n12", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}, [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}]], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A total of UGX.56.8Bn was disbursed to MSc to increase the funds available for on- lending to different businesses. I noted that MSc lacked capacity at zonal offices to appraise loans which was also manifested in the unbalanced approach for loan appraisals. A total of UGX 13b (23%) was disbursed to applicants without MSC finalising the perfection of securities for the collaterals. UGX.2.5Bn (4%) was irregularly advanced to applicants contrary to the credit policy. A total of UGX 3.149Bn (6%) was advanced to applicants with no collateral.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}, [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}]], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A total of UGX.31.033Bn was disbursed to the Ministry of Science Technology and innovation to support 23 selected projects of scientists and innovators engaged in CoVID-I9 scientific research, including the procurement of specialized machinery and equipment, development of vaccines, drug diagnostics, and other operational costs. The funds were divided into UGX.15.787Bn for purchase of Equipment and UGX.15.245Bn for Operational Costs. An MOU was entered with Presidential Scientific Initiative on Epidemics (PRESIDE) to provide technical and administrative oversight at an operational level. It was noted that most projects were progressing well. It was also noted that due to the general weaknesses identified, there was a need to provide more guidance to the beneficiaries on how to account for Government funds.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of UGX 558.68Bn appropriated, 531.8Bn was disbursed to Uganda Development Bank for recapitalization, leaving UGX 26.87Bn unremitted by the Ministry of Finance and Economic Development. From the amount disbursed, funds worth UGX 234bn had been paid out to various beneficiaries; by the time of the audit, the balance of UGX 292.66Bn was still deposited in commercial banks.\n- Of the amounts paid out, UGX95bn was sent to financial institutions and SACCOs following MoUs entered into by UDB and the financial Institutions, for the latter to on lend to stated beneficiaries.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Euros 1,602,370 (equivalent to UGX.7,136,910,000) received by UDBL from the European Union for the Tourism Sector. As at 10 th June 2021, 25 applications worth UGX 9.55 Bn had been approved, and grant disbursements worth UGX 4.34 Bn. had been processed to 14 projects.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Furthermore, the Ministry of Finance and Economic Development disbursed UGX.126.9Bn to Uganda Development Corporation, to finance projects aimed at supporting the private sector to avert the effects of Covid-19. I noted that the capitalisation grants to UDC are assigned to specific projects thereby nullifying the internal appraisal processes of UDC. 54% of the funds remained unutilised as the projects were not ready for investment.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UGX 253.59bn was released and received by the Ministry of Health. MoH used the money to procure medical supplies, 282 motor vehicles, pay allowances to medical workers, masks, intensive care equipment and build modular houses at 6 border points. All the planned activities were undertaken amidst many challenges. I noted a diversion of funds totalling UGX 7.98Bn. Though funds were paid for the acquisition of vaccines, there were delays in the delivery of the vaccines due to the global demand. There was a delay in the installation of intensive care equipment in Gulu, Mbarara, Bombo, and Lacor hospitals due to building inadequacies.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Whereas medical workers requested to be given UGX.150,000 per day as risk allowance, this was not possible and they were instead paid UGX.80,000 per day. They made a", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "13 \nrequest to parliament to have this amount exempted from taxes, but the issue was never resolved. In the meantime, UGX.2.2Bn meant for PAYE was not deducted from the allowances paid to medical workers in the period under review. \nKey Recommendations", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}, [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}]], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Management should ensure that compensating controls are put in place in times where conventional controls cannot be implemented.\n- Sensitisation of private individuals and organisations to whom public resources are entrusted should be done prior to disbursement of the funds.\n- The PS/ST should clearly communicate the intentions of given initiatives before funds are disbursed to implementing agencies to avoid a mismatch between the intended objectives and actual outputs.\n- Government entities and projects should be assessed for capacity to implement given tasks before funds are disbursed to them.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 26, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, {"headings_1": {"content": "vii)", "page": 24, "level": 3}}], "page": 26, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.1.3.", "metadata": {"headings": [{"headings_0": {"content": "2.1.3.", "page": 26, "level": 2}}, {"headings_1": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 26, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Compensations/Acquisition of Right of Way for Selected Transmission Lines Projects \nThe Government, through the Ministry of Energy and Minerals Development, is responsible for provision of policy guidance in the development and exploitation of the energy resources, creation of an enabling environment to attract investment, and provision and utilization of energy resources. \nCurrently, UETCL\u2019s network consists of 2,989.2Km of high voltage lines distributed as; 1,008km of 220kv, 1,946km of 132kv and 35km of 66kv , with 25 substations with a total transformation capacity of 2829.5 MVA. However, this is still low, given that Uganda still has one of the lowest per capita electricity consumption in the world with 215 KWh per capita per year, given that the Sub-Saharan Africa\u2019s average is 552Kwh 2 . \nGovernment has spent significant amounts in compensation of Projected Affected Persons. In a period of 5 years, financial years between 2016/17 to 2019/20, a total of UGX.564.57Bn has been spent in compensations of PAPs. \nThe delays in undertaking the construction of the transmission lines has been largely attributed to inadequacies in the compensation of Project Affected Persons. The challenges", "metadata": {"headings": [{"headings_0": {"content": "2.1.3.", "page": 26, "level": 2}}, {"headings_1": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, [{"headings_0": {"content": "2.1.3.", "page": 26, "level": 2}}, {"headings_1": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], [{"headings_0": {"content": "2.1.3.", "page": 26, "level": 2}}, {"headings_1": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], [{"headings_0": {"content": "2.1.3.", "page": 26, "level": 2}}, {"headings_1": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], [{"headings_0": {"content": "2.1.3.", "page": 26, "level": 2}}, {"headings_1": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}]], "page": 26, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "metadata": {"headings": [{"headings_0": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}, {"headings_1": {"content": "2.1.3.", "page": 26, "level": 2}}], "page": 26, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "number of projects in the Energy Sector. \nOwing to concerns over the progress of the implementation of the transmission", "metadata": {"headings": [{"headings_0": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}, {"headings_1": {"content": "2.1.3.", "page": 26, "level": 2}}, [{"headings_0": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}, {"headings_1": {"content": "2.1.3.", "page": 26, "level": 2}}]], "page": 26, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "metadata": {"headings": [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}, {"headings_1": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}], "page": 26, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "compensation of PAPs under selected transmission line projects. The overall objective of the audit was to ascertain whether the compensation process of the Project Affected Persons (PAPs) was implemented in accordance with the Compensation Guidelines and other Government Legal Frameworks to enable efficient and effective service delivery. \nThe scope of the audit included the Grid Extension and Reinforcement Project (GERP) and the Mputa Transmission lines. The following are the summary of the key findings and recommendations made, and the details are in the thematic report on compensations; \n2 Uganda energy situation-energypedia. \n14 \nSummary of Key Findings:", "metadata": {"headings": [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}, {"headings_1": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}, [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}, {"headings_1": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}], [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}, {"headings_1": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}], [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}, {"headings_1": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}]], "page": 26, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- 56% of the PAPs for GERP and Mputa projects were not properly identified, and this resulted in a mismatch between the number of PAPs appearing on the payment files and the survey reports and Valuation Reports prepared by the Chief Government Valuer.", "metadata": {"headings": [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}, {"headings_1": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}, {"headings_1": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}, [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}, {"headings_1": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}]], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The valuation process was marred with a number of irregularities, which included; the use of un-updated district compensation rates; and unverified legal interests in the land; resulting in unnecessary revaluations and ligation which in turn delayed the RAP processes, thus affecting timely project completion.", "metadata": {"headings": [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}, {"headings_1": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}, {"headings_1": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The budgeting, disbursement, and absorption of compensation funds were not properly", "metadata": {"headings": [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}, {"headings_1": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "metadata": {"headings": [{"headings_0": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}, {"headings_1": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Reports are supposed to guide the budgeting for compensations, management prepared budget estimates which were not supported, this resulted in over budgeting to the tune of UGX.111.3Bn.", "metadata": {"headings": [{"headings_0": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}, {"headings_1": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that of the released compensation amount of UGX.21.5Bn for both GERP and Mputa Projects, only UGX.5.86Bn (27%) was paid to PAPs, thus resulting in unspent funds to the tune of UGX.15.64Bn (73%). This mostly affected the GERP Project which had UGX.13.17Bn not utilized, while Mputa had UGX.1.66Bn.", "metadata": {"headings": [{"headings_0": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}, {"headings_1": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}, {"headings_1": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I also noted significant delays in compensation of PAPs. 1,109 PAPs (52.2%) for Mputa and 821 (35%) for the GERP Transmission Line remained unpaid by the time of concluding the audit (November, 2021). This was mainly caused by outstanding", "metadata": {"headings": [{"headings_0": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}, {"headings_1": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}, {"headings_1": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "metadata": {"headings": [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}, {"headings_1": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Mputa Projects, respectively. Relatedly, Compensations in kind also delayed whereby out of 149 PAPs identified, only 93 were resettled, leaving 56 PAPs not resettled. \n", "metadata": {"headings": [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}, {"headings_1": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}, [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}, {"headings_1": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}]], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted a number of inadequacies in the construction of the resettlement houses which included; irregular payments to contractors, delayed progress of works, discrepancies in drawing specifications and BOQs, poor materials used for construction, and a number of defects which were not rectified.", "metadata": {"headings": [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}, {"headings_1": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Key Recommendations", "metadata": {"headings": [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}, {"headings_1": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Management should always ensure that the RAP consultants thoroughly validate the preliminary information obtained during social survey and valuation processes, to enable", "metadata": {"headings": [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}, {"headings_1": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}, {"headings_1": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "accurate justification of PAPs", "metadata": {"headings": [{"headings_0": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, {"headings_1": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- The District Land Boards should ensure compensation rates are regularly updated and communicated to the CGV, to enable appropriate valuation of the land and properties.\n- Management should streamline its RAP processes, including proper identification of PAPs, clear valuation processes, and timely submission of PAP documentation, among others.\n- Management should ensure proper supervision and monitoring of construction works.", "metadata": {"headings": [{"headings_0": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, {"headings_1": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n15 \nEmphasis of Matter \nWithout qualifying my opinion, I draw attention to the following matters in the consolidated", "metadata": {"headings": [{"headings_0": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, {"headings_1": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}, [{"headings_0": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, {"headings_1": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}], [{"headings_0": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, {"headings_1": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}], [{"headings_0": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, {"headings_1": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}]], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "understanding of the financial statements;", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Government Loans (Borrowings) \u2013 UGX 69.6Tn", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nAs disclosed in the statement of financial performance, the government Loans have increased from UGX.56.9Tn, in 2020 to UGX UGX 69.6Tn in 2021 constituting an increase of UGX 12,718Bn (22.4%) increase. This position reflects the country\u2019s increased borrowing to combat the effects of the Covid19 pandemic.", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}]], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Domestic arrears \u2013 UGX 4.65Tn", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nAs disclosed in the statement of financial performance, the domestic arrears have increased from UGX.3.83Tn in 2020 to UGX 4.65Tn in 2021 constituting a 21% increase. The amount represents 9% of the revised budget of government of Uganda for the financial year 2020/21. This is an indication of the failed commitment control system. The growth trend appears unsustainable and on the rise. This could also be as a result of approving supplementary budgets with no matching funding. \nThe PS/ST explained that government is currently implementing a Domestic Arrears Strategy to clear significant amounts of the verified arrears. \n", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}]], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Contingent Liabilities \u2013 UGX 160Tn", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "As disclosed in the statement of contingent liabilities, Government contingent liabilities have increased to UGX160Tn up from UGX.11.5Tn reported in the previous year, representing a 1,290% increase. Most of the contigent Liabilities are arising out of court awards and compensations. The trend continues to appear unsustainable in the event that a significant percentage crystallises into liabilities. \n", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}]], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Classified Expenditure \u2013 UGX 840.8 Bn", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "As disclosed under note 8, a total of UGX 840.8 Bn relates to classified expenditure. In compliance with Section 24 of the Public Finance Management Act, 2015 (Classified Expenditure), this expenditure is to be audited separately and a separate audit report issued. \n", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}]], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Non-Consolidation of Subventions", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "It should be noted that this opinion excludes the details of expenditure worth UGX. 955Bn for subventions whose financial statements are not consolidated in the financial statements of the parent votes. Separate opinions were given on the individual financial Statements of the subventions. 16 Other Matter I consider it necessary to communicate the following matters other than those presented or disclosed in the financial statements; 2.1.4. Tax policy a) Absence of clear policies to guide the Tax Exemptions and other Investor Incentives Audit observed that there is no clear policy guideline for the issuance, management, and monitoring of the different tax benefits and incentives issued by the Government to different individuals. The absence of a clear mechanism and framework exposes the scheme to mismanagement and abuse. For example, there were inconsistencies in the grant of tax benefits to the various beneficiaries, and some conflicted with earlier policy decisions that were made by Government. A review of the letter of undertaking/commitment signed by the Minister of Finance relating to an Industrial park establishment revealed that Government was taking over import duty and VAT on all materials and machinery imported by the beneficiary with the exception of steel items. However, a review of the Memorandum of understanding signed by the GoU and an Industrial park company investor revealed that there was no exception relating to steel. It was also established that Government had offered a 10 year tax holiday to the steel sector with the aim of promoting the growth of the sector as well as boosting employment. In light of the above, there is conflict in policy as presented in the above agreements and commitments. The Government may not achieve the objectives for having granted the 10 year tax holiday for the steel sector. It was also noted that there is no mechanism in place for evaluating and or assessing the impact of the benefits granted. I noted 20 beneficiaries whose benefit period has since expired without follow up. In the absence of a monitoring framework, Government is not in position to assess the impact of the tax benefits granted to the various beneficiaries. Government is bound to lose revenues that would have accrued if the beneficiaries were effecting payments and this may also cause unfair competition in the market. Management indicated that the issue at hand would be solved by the ongoing development and implementation of the tax governance framework.", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}]], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The Government of Uganda (GOU), through the Ministry of Finance Planning and Economic Development, entered an agreement on 4 th April, 2003 with Oil Refinery company for the development of oil palm industry in Uganda. Under Article 5(7) of the Agreement, GOU was required to pay VAT on the products of the all companies envisaged under the project from the first year of the project activities and ending after a period of eleven (11) years from the year of handing over the 26,500 hectares of land. It was agreed that the company would then refund (subject to clause 3 of article 4) the VAT paid by the Government with interest over a period of eight (8) years in eight equal installments, including accrued interest starting in the twelfth (12 th ) year. \nHowever, Government has breached the contract by failing to provide the balance of the 10,000 hectares of land as agreed. There is no documentation to show that the Ministry has made any follow-up on this matter.", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, {"headings_1": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}]], "page": 30, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "metadata": {"headings": [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], "page": 30, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Finance, Planning and Economic Development has continued to settle all tax obligations on behalf of the Company. In the financial year 2019/20, the Minister wrote off a total of UGX.194Bn in line with the Tax Procedures Code Act (2019), being arrears as at 30 th June 2019 and also a total of UGX.79.8Bn was accumulated in the year under audit in arrears. Under the circumstances, it is apparent that instead of paying for 11 years, Government has so far paid for 17 years and is still continuing while the chances of recovery appear to be slim. The continued failure to provide land continues to affect the Uganda Revenue Authority in its revenue collection efforts and also affects Government of Uganda revenue performance. Management explained that Government has provided additional Land in Sango Bay bringing the total land provided to 22,500 hectares. The balance of 4,000 hectares is being sought in collaboration with Ministry of Agriculture Animal Industry and Fisheries. Once this is completed, the Company shall start refunding GoU taxes accumulated accordingly. The Ministry has further written to the Attorney General seeking advice on how the agreement can be amended. I advised the Accounting Officer to liaise with the responsible agencies and ministries to expeditiously address the land issue. In the meantime, the PS/ST should also follow up with the Attorney General on the possibility of reviewing the terms of the agreement. c) Continued build up of Government tax arrears; UGX.212.747Bn Article 17 of the 1995 Constitution of the Republic of Uganda (as amended) provides that it is the duty of every Citizen to pay taxes. Article 152(1) provides that no tax shall be imposed except under the authority of an Act of Parliament. The same Article provides that where a law enacted under the provision of the Article empowers any person to waive or vary a tax imposed by that law, that person or authority shall report to parliament periodically on the exercise of those powers as is provided for by the law. The tax procedures Code Act (as amended in 2019) provides that the Minister shall pay taxes due and payable by the Government arising from any commitment made by the 18 Government to pay taxes on behalf of a person, or owing from the Government through the acquisition of goods and services. In addition, Section 40A (2) of the same Act provides that all unpaid taxes by", "metadata": {"headings": [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}]], "page": 30, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Nature of Tax", "Total Amount written off (UGX)"], ["Value Added tax (VAT)", "348,986,568,013"], ["Stamp Duty 8,460,910,000", null], ["Pay As You Earn (PAYE)", "158,293,699,210"], ["Import Duty 98,569,989,826", null], ["Excise Duty", "52,685,114,511"], ["Income Tax 114,133,374,978", null], ["Withholding Tax", "28,604,598,593"], ["Total 809,734,255,131", null]], "metadata": {"headings": [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], "page": 31, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1"], "type": "table"}}, {"content": "It has however been noted, that one year later, a total of UGX.212.747Bn has already been accumulated at the Ministry of Finance, Planning and Economic Development in tax arrears as 30 th June 2021. The occurrence is a manifestation that a tax write off is not the solution for the issue at hand. The tax arrears build up continues to negatively affect the revenue collection efforts of Uganda Revenue Authority. \nManagement responded that the writing off of tax arrears by the minister was consistent with the law, specifically Article 152 (1) of the Constitution and Section 40 of the Tax procedures Code Act. This discretionary power is useful because it addresses strategic circumstances which merit government interventions that were not provided for in the tax acts. Exercise of this discretion by the minister is reported to parliament every end of the quarter. \nI advised the Accounting Officer to review the practice and come up with a lasting solution in respect of companies to which tax incentives and other benefits a granted.", "metadata": {"headings": [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, {"headings_1": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}]], "page": 31, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.1.5.", "metadata": {"headings": [{"headings_0": {"content": "2.1.5.", "page": 31, "level": 2}}, {"headings_1": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}], "page": 31, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Audit of public debt", "metadata": {"headings": [{"headings_0": {"content": "2.1.5.", "page": 31, "level": 2}}, {"headings_1": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}], "page": 31, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "a) Public Debt Portfolio Analysis", "metadata": {"headings": [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}, {"headings_1": {"content": "2.1.5.", "page": 31, "level": 2}}], "page": 31, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The reported total public debt as at 30 th June, 2021 stood at UGX.69,600 Bn, of which Domestic Debt Stock was UGX.25,288 Bn and the External Debt Stock was valued at UGX.44,312 Bn. This is an increase of UGX.13,429 Bn, equivalent to 23.9% when compared to the debt stock of UGX.56,892 Bn reported as at 30 th June 2020. The table below shows the details; \n19 \nTable 5: Debt portfolio analysis", "metadata": {"headings": [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}, {"headings_1": {"content": "2.1.5.", "page": 31, "level": 2}}, [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}, {"headings_1": {"content": "2.1.5.", "page": 31, "level": 2}}], [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}, {"headings_1": {"content": "2.1.5.", "page": 31, "level": 2}}]], "page": 31, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Financial year", "Domestic debt (UGX Bn)", "Foreign debt (UGX", "Total (UGX Bn)", "%"], ["ended", null, "Bn)", null, "change"], ["June 21", "25,288", "44,312", "69,600", "23.90%"], ["June 20 17,975 38,196 56,171 23.50%", null, null, null, null], ["June 19", "15,221", "30,905", "46,126", "11.10%"], ["June 18 13,059 28,386 41,445 23.60%", null, null, null, null], ["June 17", "11,407", "22,102", "33,509", ""]], "metadata": {"headings": [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}, {"headings_1": {"content": "2.1.5.", "page": 31, "level": 2}}], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "Source: Audited financial statements of Vote 130 \nFrom the above, I noted that there was a consistent increase in the total debt and from financial year 19/20 to 20/21, there was an increment of UGX. 13,429Bn (23.90%). The net increase in the debt is due to increased borrowing from both the domestic and external sources, with domestic debt accounting for a higher increase. \nPublic debt is continuously on the rise, a fact that is attributed to persistent budget deficits (mismatch of government revenue and expenditure), rollover of liquidity papers, new borrowings for various development projects and foreign exchange loss arising from the depreciation of Ugandan Shilling against stronger currencies. The graph below illustrates the trend of public debt stock by type over the past five years; \nFigure 2: The trend of public debt", "metadata": {"headings": [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}, {"headings_1": {"content": "2.1.5.", "page": 31, "level": 2}}, [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}, {"headings_1": {"content": "2.1.5.", "page": 31, "level": 2}}], [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}, {"headings_1": {"content": "2.1.5.", "page": 31, "level": 2}}], [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}, {"headings_1": {"content": "2.1.5.", "page": 31, "level": 2}}]], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "80,000", "metadata": {"headings": [{"headings_0": {"content": "80,000", "page": 32, "level": 4}}, {"headings_1": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "70,000 60,000", "metadata": {"headings": [{"headings_0": {"content": "70,000 60,000", "page": 32, "level": 4}}, {"headings_1": {"content": "80,000", "page": 32, "level": 4}}], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "50,000", "metadata": {"headings": [{"headings_0": {"content": "50,000", "page": 32, "level": 4}}, {"headings_1": {"content": "70,000 60,000", "page": 32, "level": 4}}], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Domestic debt (UGX Bn)", "metadata": {"headings": [{"headings_0": {"content": "50,000", "page": 32, "level": 4}}, {"headings_1": {"content": "70,000 60,000", "page": 32, "level": 4}}], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "40,000", "metadata": {"headings": [{"headings_0": {"content": "40,000", "page": 32, "level": 4}}, {"headings_1": {"content": "50,000", "page": 32, "level": 4}}], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Foreign debt (UGX Bn)", "metadata": {"headings": [{"headings_0": {"content": "40,000", "page": 32, "level": 4}}, {"headings_1": {"content": "50,000", "page": 32, "level": 4}}], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "30,000 Total (UGX Bn)", "metadata": {"headings": [{"headings_0": {"content": "30,000 Total (UGX Bn)", "page": 32, "level": 4}}, {"headings_1": {"content": "40,000", "page": 32, "level": 4}}], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "20,000 10,000", "metadata": {"headings": [{"headings_0": {"content": "20,000 10,000", "page": 32, "level": 4}}, {"headings_1": {"content": "30,000 Total (UGX Bn)", "page": 32, "level": 4}}], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "0", "metadata": {"headings": [{"headings_0": {"content": "20,000 10,000", "page": 32, "level": 4}}, {"headings_1": {"content": "30,000 Total (UGX Bn)", "page": 32, "level": 4}}], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "metadata": {"headings": [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}, {"headings_1": {"content": "20,000 10,000", "page": 32, "level": 4}}], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Although government has developed a domestic revenue mobilisation strategy, this appears not to be in harmony with the spending, raising concerns of sustainability. \nManagement indicated that revenue Mobilization had recently been affected by reduced economic activity as a result of restrictions imposed to slowdown the spread of COVID 19. COVID 19 has also led to additional expenditure pressures, which necessitated increased borrowing. Going forward, Government will focus on reducing expenditure and increasing revenues in a bid to bridge the fiscal gap and reduce the rate of debt accumulation. These commitments have been clearly spelt out in the Charter for Fiscal Responsibility, which is \n20 \nawaiting Parliamentary approval. Further to the above, Government is finalising the Public Investment Financing Strategy (PIFS) that will improve alignment of government programmes and projects to suitable financing options. The Strategy will in turn enhance the efforts in resources allocation, utilisation and address issues on debt sustainability. \nI await implementation of the Charter for Fiscal Responsibility. b) Assessment of debt sustainability", "metadata": {"headings": [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}, {"headings_1": {"content": "20,000 10,000", "page": 32, "level": 4}}, [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}, {"headings_1": {"content": "20,000 10,000", "page": 32, "level": 4}}], [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}, {"headings_1": {"content": "20,000 10,000", "page": 32, "level": 4}}], [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}, {"headings_1": {"content": "20,000 10,000", "page": 32, "level": 4}}], [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}, {"headings_1": {"content": "20,000 10,000", "page": 32, "level": 4}}]], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Debt to GDP Ratio", "metadata": {"headings": [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}, {"headings_1": {"content": "20,000 10,000", "page": 32, "level": 4}}], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Debt to GDP ratios is a measure that compares what a country owes (total debt) and what it", "metadata": {"headings": [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}, {"headings_1": {"content": "20,000 10,000", "page": 32, "level": 4}}], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "produces (manufactures or a service). The ratio reliably indicates a country\u2019s ability to pay", "metadata": {"headings": [{"headings_0": {"content": "produces (manufactures or a service). The ratio reliably indicates a country\u2019s ability to pay", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "back its debt. A high debt-to-GDP ratio may make it more difficult for a country to pay both internal and external debts and may lead creditors to seek higher interest rates when lending due to the low credit rating of the country that pushes its lending risk high. \nThough the IMF has recommended 50% as the point of safety, many developed countries have gone up to 200%. However, according to the IMF, the developing countries are more prone to economic shocks and exchange rate risk, thus advising on a 50% threshold.", "metadata": {"headings": [{"headings_0": {"content": "produces (manufactures or a service). The ratio reliably indicates a country\u2019s ability to pay", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}, [{"headings_0": {"content": "produces (manufactures or a service). The ratio reliably indicates a country\u2019s ability to pay", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}]], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "A review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the", "metadata": {"headings": [{"headings_0": {"content": "A review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the", "page": 33, "level": 2}}, {"headings_1": {"content": "produces (manufactures or a service). The ratio reliably indicates a country\u2019s ability to pay", "page": 33, "level": 2}}], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "year under review. The graph below illustrates the movement; \nFigure 3: Debt to GDP ratio 160 \n140 \n120 \n100", "metadata": {"headings": [{"headings_0": {"content": "A review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the", "page": 33, "level": 2}}, {"headings_1": {"content": "produces (manufactures or a service). The ratio reliably indicates a country\u2019s ability to pay", "page": 33, "level": 2}}, [{"headings_0": {"content": "A review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the", "page": 33, "level": 2}}, {"headings_1": {"content": "produces (manufactures or a service). The ratio reliably indicates a country\u2019s ability to pay", "page": 33, "level": 2}}], [{"headings_0": {"content": "A review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the", "page": 33, "level": 2}}, {"headings_1": {"content": "produces (manufactures or a service). The ratio reliably indicates a country\u2019s ability to pay", "page": 33, "level": 2}}]], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Total Debt(UGX Bn)", "metadata": {"headings": [{"headings_0": {"content": "Total Debt(UGX Bn)", "page": 33, "level": 4}}, {"headings_1": {"content": "A review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the", "page": 33, "level": 2}}], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "80 \n60", "metadata": {"headings": [{"headings_0": {"content": "Total Debt(UGX Bn)", "page": 33, "level": 4}}, {"headings_1": {"content": "A review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the", "page": 33, "level": 2}}, [{"headings_0": {"content": "Total Debt(UGX Bn)", "page": 33, "level": 4}}, {"headings_1": {"content": "A review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the", "page": 33, "level": 2}}]], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "40 29.0 31.0 34.0 35.0", "metadata": {"headings": [{"headings_0": {"content": "40 29.0 31.0 34.0 35.0", "page": 33, "level": 4}}, {"headings_1": {"content": "Total Debt(UGX Bn)", "page": 33, "level": 4}}], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "20 \n-", "metadata": {"headings": [{"headings_0": {"content": "40 29.0 31.0 34.0 35.0", "page": 33, "level": 4}}, {"headings_1": {"content": "Total Debt(UGX Bn)", "page": 33, "level": 4}}, [{"headings_0": {"content": "40 29.0 31.0 34.0 35.0", "page": 33, "level": 4}}, {"headings_1": {"content": "Total Debt(UGX Bn)", "page": 33, "level": 4}}]], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "GDP", "metadata": {"headings": [{"headings_0": {"content": "GDP", "page": 33, "level": 4}}, {"headings_1": {"content": "40 29.0 31.0 34.0 35.0", "page": 33, "level": 4}}], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "47.0 \nDebt to GDP Ratio 41.0", "metadata": {"headings": [{"headings_0": {"content": "GDP", "page": 33, "level": 4}}, {"headings_1": {"content": "40 29.0 31.0 34.0 35.0", "page": 33, "level": 4}}, [{"headings_0": {"content": "GDP", "page": 33, "level": 4}}, {"headings_1": {"content": "40 29.0 31.0 34.0 35.0", "page": 33, "level": 4}}]], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "metadata": {"headings": [{"headings_0": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}, {"headings_1": {"content": "GDP", "page": 33, "level": 4}}], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "From the above, it can be seen that though Uganda\u2019s GDP has been increasing over the years since 2013/14, its debt position has also increased. The rate of increase of debt is higher than the rate of increment in the GDP levels, which creates a risk of reaching unsustainable levels in the future.", "metadata": {"headings": [{"headings_0": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}, {"headings_1": {"content": "GDP", "page": 33, "level": 4}}], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "program under National Development Plans I and II that were particularly focused on the energy (dams and power lines) and transport sectors. In addition, the need to expedite \n21 \ncommercial production of our oil resources has also necessitated the development of infrastructure which will aid the production process. \nIt was also indicated that the onset of the COVID-19 pandemic had led to a contraction in economic activity and shortfalls in domestic revenue collections while at the same time creating additional spending areas to mitigate the pandemic impact. To maintain debt at sustainable levels, Government had embarked on a fiscal consolidation strategy aimed at accelerating implementation of the Domestic Revenue Mobilisation Strategy and expenditure rationalisation. \nI advised the PSST to consider exploring ways of reducing dependence on debt and expediting the implementation of strategies to enhance revenue generation for the country and/or reducing/rationalising government expenditures.", "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}, [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}]], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Interest to Total revenue ratio", "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}], "page": 34, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nThis benchmark shows the proportion of the domestic revenue that goes into servicing domestic interest costs. Since donor grants are inherently subject to uncertainty, the interest cost of domestic debt is considered in relation to the domestically-raised component of the budget only. Government set the ceiling to be 12.5% in its debt strategy. The table 6 below shows the assessment of the benchmark over the years; \nTable 6: Total revenue ratio", "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}, [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}]], "page": 34, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Financial year", "Total domestic", "Total Interest - UGX", "% of Interest to", "Benchmark"], ["", "Revenue - UGX", null, "revenue", null], ["2020/21", "20,199,013,110,066", "3,118,535,556,062", "15.4", "< 12.5"], ["2019/20 17,453,981,414,553 2,475,531,497,733 14.2 < 12.5", null, null, null, null], ["2018/19", "17,128,743,726,614", "2,005,380,900,988", "11.71", "< 12.5"], ["2017/18 15,219,588,786,381 1,937,371,886,367 12.73 < 12.5", null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}], "page": 34, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "It has been established that the interest to revenue benchmark has been breached as evidenced above. Almost 15% of the revenue being collected is going into servicing interest payments. This is gradually reducing the funds available for funding other critical government expenditures, given that 25% goes to salaries and wages. \nManagement indicated that efforts were being made to reduce the interest to revenue ratio by taking steps to reduce the level of domestic borrowing a view to attaining the operational ceiling of 1% of GDP and also working to increase domestic revenues through the operationalization of the Domestic Revenue Mobilization Strategy (DRMS). The implementation of the DRMS had stalled in the last two years due to the pandemic-induced shocks. The DRMS aims to increase to tax to GDP ratio by 0.5 percentage points every year largely through the improvement of revenue administration. \nI advised the PS/ST to implement strategies of reducing the growth of interest expenditures at the same time increasing revenue mobilisation. \n", "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}, [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}]], "page": 34, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Low Tax to GDP ratio", "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}], "page": 34, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Section 2.1 (i) Public Debt and other Financial Liabilities Management Framework for the FY2018/19 to FY2022/23 provides that the Government of Uganda shall work towards 22", "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, {"headings_1": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}], "page": 34, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "raising its tax-to-GDP ratio to the Sub-Sahara Africa\u2019s (SSA) average of 15.1% as part of Uganda\u2019s Financing Strategy to limit on borrowing.", "metadata": {"headings": [{"headings_0": {"content": "raising its tax-to-GDP ratio to the Sub-Sahara Africa\u2019s (SSA) average of 15.1% as part of Uganda\u2019s Financing Strategy to limit on borrowing.", "page": 35, "level": 2}}, {"headings_1": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}], "page": 35, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "metadata": {"headings": [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}, {"headings_1": {"content": "raising its tax-to-GDP ratio to the Sub-Sahara Africa\u2019s (SSA) average of 15.1% as part of Uganda\u2019s Financing Strategy to limit on borrowing.", "page": 35, "level": 2}}], "page": 35, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "noted that from the start of the implementation of the framework in the FY2018/19, Uganda had made an improvement and currently stands at 13%; however, more strides have to be made to make it to 15% and more. Refer to the table 7 below; \nTable 7: Tax to GDP ratio", "metadata": {"headings": [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}, {"headings_1": {"content": "raising its tax-to-GDP ratio to the Sub-Sahara Africa\u2019s (SSA) average of 15.1% as part of Uganda\u2019s Financing Strategy to limit on borrowing.", "page": 35, "level": 2}}, [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}, {"headings_1": {"content": "raising its tax-to-GDP ratio to the Sub-Sahara Africa\u2019s (SSA) average of 15.1% as part of Uganda\u2019s Financing Strategy to limit on borrowing.", "page": 35, "level": 2}}]], "page": 35, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Financial year", "GDP at Current Prices", "TAX collections", "Tax/GDP"], ["", "(UGX) Billions", "(UGX) Billions", null], ["2020/21", "147,962", "18,594", "13%"], ["2019/20 139,689 16,042 11%", null, null, null], ["2018/19", "132,090", "16,146", "12%"]], "metadata": {"headings": [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}, {"headings_1": {"content": "raising its tax-to-GDP ratio to the Sub-Sahara Africa\u2019s (SSA) average of 15.1% as part of Uganda\u2019s Financing Strategy to limit on borrowing.", "page": 35, "level": 2}}], "page": 35, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "The continued failure to collect sufficient revenue will imply more borrowing and creates a risk that the Country may not achieve the World Bank Sustainable Development Goals by 2030.", "metadata": {"headings": [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}, {"headings_1": {"content": "raising its tax-to-GDP ratio to the Sub-Sahara Africa\u2019s (SSA) average of 15.1% as part of Uganda\u2019s Financing Strategy to limit on borrowing.", "page": 35, "level": 2}}], "page": 35, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Management indicated that the Ministry\u2019s tax expenditure analysis revealed that government was losing up to 1 to 2 percentage points of GDP per year, besides the fact that Government of Uganda informal economy is close to 50% of GDP. In addition, a VAT gap analysis carried out discovered a 40% compliance gap. The Ministry is implementing tax administration measures as part of the measures within the Domestic revenue mobilization strategy to improve tax to GDP ratio that include Automation of URA revenue collection systems through EFRIS, Digital Tax Stamps, Enhancement of ICT infrastructure, Installation of scanners at all customers border entry points, Improved Tax payer education, Implementation of a project to improve record-keeping by SMEs for improving compliance. \nManagement through URA also committed to ensuring increased tax compliance. \nI advised the PSST to formulate policies that will further enhance domestic revenue mobilization. In the meantime, government should consider limiting its expenditure to within the limits of sustainable financing.", "metadata": {"headings": [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}, {"headings_1": {"content": "raising its tax-to-GDP ratio to the Sub-Sahara Africa\u2019s (SSA) average of 15.1% as part of Uganda\u2019s Financing Strategy to limit on borrowing.", "page": 35, "level": 2}}, [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}, {"headings_1": {"content": "raising its tax-to-GDP ratio to the Sub-Sahara Africa\u2019s (SSA) average of 15.1% as part of Uganda\u2019s Financing Strategy to limit on borrowing.", "page": 35, "level": 2}}], [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}, {"headings_1": {"content": "raising its tax-to-GDP ratio to the Sub-Sahara Africa\u2019s (SSA) average of 15.1% as part of Uganda\u2019s Financing Strategy to limit on borrowing.", "page": 35, "level": 2}}]], "page": 35, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "c)", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 35, "level": 2}}, {"headings_1": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}], "page": 35, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Continued securing of High cost Temporary advance from Bank of Uganda \nSection 36 (3) of the PFMA 2015, stipulates that the Minister of Finance may raise a loan by issuing Government bills, bonds or stock or using any other method the Minister may deem expedient, including a fluctuating overdraft. \nMinistry of Finance, Planning and Economic Development requested for a temporary advance of UGX.2.1 Trillion from Bank of Uganda in line with the Public finance Management Act, 2015. The advance was granted on 1 st October 2020, the Bank of Uganda granted the request based on an average interest rate of the 272 day Treasury bill rate of 9.999%. Government paid an amount of UGX.98,770,218,774 as interest for the temporary advance due to delayed pay back. \n23 \nThe Accounting Officer indicated that the Ministry had embarked on negotiation with the central bank to adjust the interest rate to a fairer benchmark, though this still has to be in line with the Bank of Uganda Act which stipulates use of a market rate. \nI await the outcome of the negotiations.", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 35, "level": 2}}, {"headings_1": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}, [{"headings_0": {"content": "c)", "page": 35, "level": 2}}, {"headings_1": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}], [{"headings_0": {"content": "c)", "page": 35, "level": 2}}, {"headings_1": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}], [{"headings_0": {"content": "c)", "page": 35, "level": 2}}, {"headings_1": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}], [{"headings_0": {"content": "c)", "page": 35, "level": 2}}, {"headings_1": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}], [{"headings_0": {"content": "c)", "page": 35, "level": 2}}, {"headings_1": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}]], "page": 35, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "d)", "metadata": {"headings": [{"headings_0": {"content": "d)", "page": 36, "level": 2}}, {"headings_1": {"content": "c)", "page": 35, "level": 2}}], "page": 36, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Absence of Policy to manage Interest rate risk \nA Policy Framework serves as the guiding policy document for institutional development. The Policy Framework translates goals and objectives into attainable targets with outreaching impacts. Audit noted that the Treasury did not have a policy to manage interest rate risk. Without a Policy, there are no streamlined and institutionalized interventions that foster proper safe guards of public resources. \nIt was noted that the country continues to engage in the acquisition of debt with floating", "metadata": {"headings": [{"headings_0": {"content": "d)", "page": 36, "level": 2}}, {"headings_1": {"content": "c)", "page": 35, "level": 2}}, [{"headings_0": {"content": "d)", "page": 36, "level": 2}}, {"headings_1": {"content": "c)", "page": 35, "level": 2}}], [{"headings_0": {"content": "d)", "page": 36, "level": 2}}, {"headings_1": {"content": "c)", "page": 35, "level": 2}}]], "page": 36, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "interest rates from Bilateral countries and Commercial Banks that use the \u2018Libor\u2019 and", "metadata": {"headings": [{"headings_0": {"content": "interest rates from Bilateral countries and Commercial Banks that use the \u2018Libor\u2019 and", "page": 36, "level": 2}}, {"headings_1": {"content": "d)", "page": 36, "level": 2}}], "page": 36, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\u2018Eurobor\u2019 interest rates and thus the need for safeguards to be imposed. \nIt was further noted that the Government debt management policy on external debt does", "metadata": {"headings": [{"headings_0": {"content": "interest rates from Bilateral countries and Commercial Banks that use the \u2018Libor\u2019 and", "page": 36, "level": 2}}, {"headings_1": {"content": "d)", "page": 36, "level": 2}}, [{"headings_0": {"content": "interest rates from Bilateral countries and Commercial Banks that use the \u2018Libor\u2019 and", "page": 36, "level": 2}}, {"headings_1": {"content": "d)", "page": 36, "level": 2}}]], "page": 36, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "metadata": {"headings": [{"headings_0": {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "page": 36, "level": 2}}, {"headings_1": {"content": "interest rates from Bilateral countries and Commercial Banks that use the \u2018Libor\u2019 and", "page": 36, "level": 2}}], "page": 36, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "As a result, most products are market-driven which is exposing Government further to new risks. \nI noted that Government entered into a SWAP arrangement with two commercial banks towards the repayment a loan. A review of interest movements on the LIBOR revealed that Government has since made a financial loss of UGX.65,627,696,205 and has not yet benefited from the SWAP agreements with the two banks.", "metadata": {"headings": [{"headings_0": {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "page": 36, "level": 2}}, {"headings_1": {"content": "interest rates from Bilateral countries and Commercial Banks that use the \u2018Libor\u2019 and", "page": 36, "level": 2}}, [{"headings_0": {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "page": 36, "level": 2}}, {"headings_1": {"content": "interest rates from Bilateral countries and Commercial Banks that use the \u2018Libor\u2019 and", "page": 36, "level": 2}}]], "page": 36, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The Accounting Officer responded that the conclusion of the 15-year Interest Rate Swap transaction in June 2016 was a risk mitigating action against possible increases in US$ LIBOR which was made on the basis of historical US$ LIBOR rates. It could not take into account the ramifications of the CoVID-19 pandemic and the associated interventionist changes in US Monetary policy; as they were not evident in 2016. Current Indications are that restoration of market based interest rates will occur in the near future and hence pointing to the necessity to keep the SWAP in place as insurance against likely future interest rate increases. Government is currently undertaking a midterm review of the Public Debt Management Framework (PDMF) 2018. The proposed measure will therefore be considered and appropriate policy actions will be instituted for the remaining period of the framework and the longer term. \nI advised management is to develop a policy on management of interest rate risk to minimise the exposure. \ne) Failed on-lending scheme \nGovernment of Uganda has over the years, secured funds for on-lending to various ministries, departments and agencies to undertake various projects. Whereas MDAs signed", "metadata": {"headings": [{"headings_0": {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "page": 36, "level": 2}}, {"headings_1": {"content": "interest rates from Bilateral countries and Commercial Banks that use the \u2018Libor\u2019 and", "page": 36, "level": 2}}, [{"headings_0": {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "page": 36, "level": 2}}, {"headings_1": {"content": "interest rates from Bilateral countries and Commercial Banks that use the \u2018Libor\u2019 and", "page": 36, "level": 2}}], [{"headings_0": {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "page": 36, "level": 2}}, {"headings_1": {"content": "interest rates from Bilateral countries and Commercial Banks that use the \u2018Libor\u2019 and", "page": 36, "level": 2}}], [{"headings_0": {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "page": 36, "level": 2}}, {"headings_1": {"content": "interest rates from Bilateral countries and Commercial Banks that use the \u2018Libor\u2019 and", "page": 36, "level": 2}}]], "page": 36, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "the on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay", "metadata": {"headings": [{"headings_0": {"content": "the on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay", "page": 36, "level": 2}}, {"headings_1": {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "page": 36, "level": 2}}], "page": 36, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "metadata": {"headings": [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}, {"headings_1": {"content": "the on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay", "page": 36, "level": 2}}], "page": 36, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "found to be compliant with the repayment of the loans. \n24 \nIt was further noted that; \n", "metadata": {"headings": [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}, {"headings_1": {"content": "the on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay", "page": 36, "level": 2}}, [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}, {"headings_1": {"content": "the on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay", "page": 36, "level": 2}}], [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}, {"headings_1": {"content": "the on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay", "page": 36, "level": 2}}], [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}, {"headings_1": {"content": "the on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay", "page": 36, "level": 2}}]], "page": 36, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- There were no criteria in place to assess which MDAs to lend to.\n- There was no record of assessment/ feasibility studies undertaken to establish whether the choice of on-lent financing was the best modality to finance the infrastructure projects.\n- I noted that Government used non-concessional loans for on-lending, which attracted higher interest rates and shorter grace periods for the loan repayments as compared to the concessional loans which made it very costly. Some MDAs have had challenges with absorption and thus repayment.", "metadata": {"headings": [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}, {"headings_1": {"content": "the on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay", "page": 36, "level": 2}}], "page": 37, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Without a clear policy in place, the above shortcomings will continue to occur. This is causing a strain on government as funds are diverted to pay the loan obligations. \nThe Accounting Officer noted the observation and indicated that some of the beneficiary agencies that were not servicing the loans were taking various steps to have the issues resolved including seeking cancellations, write off loans by Government, and conversion of loan into equity among others. \nGovernment should develop a clear on-lending policy if it continues to use the above option as a channel for funding projects.", "metadata": {"headings": [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}, {"headings_1": {"content": "the on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay", "page": 36, "level": 2}}, [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}, {"headings_1": {"content": "the on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay", "page": 36, "level": 2}}], [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}, {"headings_1": {"content": "the on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay", "page": 36, "level": 2}}]], "page": 37, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.1.6.", "metadata": {"headings": [{"headings_0": {"content": "2.1.6.", "page": 37, "level": 2}}, {"headings_1": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], "page": 37, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Management of ICT in government \na) Failure to rationalize IT investments \nAudit observed that there is massive duplication of IT systems and projects by the different MDAs attributable to implementation of IT initiatives in silos by the different MDAs. This has the effect of resulting into wastage of resources. \nThe isolated implementation of ICT initiatives also has the effect of compromising the standard of ICT infrastructure used by Government, which has the effect of compromising service delivery and wasteful expenditure on ICT systems that are not to be used. \nAudit noted that several MDAs have procured several systems with the same functionality, established data centers, server rooms and disaster recovery sites to which the government has spent billions of shillings and the same continue claiming an annual maintenance fee. The major challenges, however, are that due to rapid technological changes, the investments require frequent upgrade infrastructure. \nAudit noted that whereas the ICT strategy gives guidelines on the budgeting and acquisition of ICT systems including the involvement of the Ministry of ICT and NITA in ensuring standardization of systems and prevention of duplication of government systems, the continued individual actions by some MDAs has resulted in uncoordinated budgets and procurements of systems. \nIt is important to standardize, streamline and harmonize the budgeting, acquisition, deployment and disposal of IT services in Government to eliminate duplication; enhance information sharing and interoperability of e-government applications. \n25 \nManagement explained that rationalization of IT investments has been an ongoing activity spearheaded by NITAU. This activity resulted in a report which is still under discussion. Despite the desire by NITAU to rationalize IT investments, it is true that some Government Ministries, Departments and other Agencies have continued to procure own systems and Infrastructure. However, with the ongoing discussion, it is expected that rationalization of", "metadata": {"headings": [{"headings_0": {"content": "2.1.6.", "page": 37, "level": 2}}, {"headings_1": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}, [{"headings_0": {"content": "2.1.6.", "page": 37, "level": 2}}, {"headings_1": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], [{"headings_0": {"content": "2.1.6.", "page": 37, "level": 2}}, {"headings_1": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], [{"headings_0": {"content": "2.1.6.", "page": 37, "level": 2}}, {"headings_1": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], [{"headings_0": {"content": "2.1.6.", "page": 37, "level": 2}}, {"headings_1": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], [{"headings_0": {"content": "2.1.6.", "page": 37, "level": 2}}, {"headings_1": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], [{"headings_0": {"content": "2.1.6.", "page": 37, "level": 2}}, {"headings_1": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], [{"headings_0": {"content": "2.1.6.", "page": 37, "level": 2}}, {"headings_1": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], [{"headings_0": {"content": "2.1.6.", "page": 37, "level": 2}}, {"headings_1": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}]], "page": 37, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "government\u2019s investments in IT systems will be achieved.", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I advised Government to expedite the ongoing rationalization and also streamline the budgeting and procurement of different ICT systems through seeking concurrence of the Ministry responsible for ICT and NITAU before funds for system acquisition are included in the budgets of MDAs. \nb) Weaknesses in management of recoveries arising out of anti-corruption cases \nSection 10(4) of the Anti-corruption Act, provides that in addition to any other penalty imposed upon conviction on a person order that person to make good the loss occasioned to the property; and the value of the property or damage to the property shall constitute a civil debt from the person to the Government or public body concerned and shall be recoverable from that person. \nA review of decisions from the Anti-corruption Division of the High Court revealed that on several instances, the court has made orders as to refund of proceeds of corrupt practices by persons convicted. The following were observed; \n", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}, [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}]], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A sample of the cases reviewed revealed that a total of UGX.24,734,116,888 is outstanding as a result of decisions of the courts for refund of proceeds of corrupt practices but these are not provided for in the consolidated accounts as receivable.", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- In my 2019/20 report for the DPP, I also observed that a total of UGX.18,940,206,109 remained uncollected in spite of the setup of a department within the Office of the DPP responsible for enforcing the recovery of compensation orders.", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The gaps in the collection were partly attributed to the lack of a clear mandate to the DPP, especially in so far as recoveries of compensation would require civil processes which are outside the mandate of the criminal mandate of the Office of the DPP.", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Whereas the mandate of recovery would be a reserve of the Attorney General who is vested with the mandate to litigate civil matters, it was noted that the ODDP has in place a unit for recovery of funds arising out of prosecutions in DPP while IGG also has another.", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nFailure to enforce the recovery of court orders, denies government the funds that should have been generated and undermine the objective of recovering losses incurred by the government due to corrupt practices. \nIt is therefore important that the Government comes up with a regulatory framework that addresses the inadequate legislation on recovery of proceeds of crime, provide for: civil asset recovery, detailed procedures in conviction based recovery, asset management and \n26 \ndisposal, recovery of consequential benefits, and how to apply the recovered proceeds, among others. \nThe Accounting Officer responded that the Ministry had initiated consultations with the Office of DPP, IGG and Attorney General for establishment of comprehensive procedures for recovery of proceeds of crime, provide for civil asset recovery, provide for detailed guidelines in conviction based recovery, provide for asset management and disposal, recovery of consequential benefits including application of the recovered proceeds. \nI await the outcome of the consultations.", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}, [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, {"headings_1": {"content": "2.1.6.", "page": 37, "level": 2}}]], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.1.7.", "metadata": {"headings": [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}, {"headings_1": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], "page": 39, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Audit of public investments \na) Failure to Appraise Projects before funding - UGX.643,434Bn \nSection 3.18 of the Development Committee Guidelines provides that assessment of the project viability shall be measured by the following key indicators including: The Financial Cost Benefit Ratio (CBR), the financial Net Present Value (NPV) and the financial Internal Rate of Return (IRR). \nThe guide further requires that all new Projects requiring funding should undergo four levels of approvals before they can be admitted into the Public Investment Plan (PIP). The four levels include; preparing a project concept in line with NDP (II), preparing a Project Profile demonstrating Key results, undertaking a prefeasibility study and undertaking feasibility study. \nReview of the Public Investment Plan for the year ended 30 th /06/2021, revealed that out of a sample of 371 projects, 245 projects (66%) with total Project values of UGX.643,434 Bn did not have feasibility studies undertaken. \nFailure to conduct feasibility studies may lead to the projects failing to achieve the desired project output, duplication or conflicting Government interventions thus causing wasteful expenditure. \nManagement committed that going forward all projects will be appraised before inclusion in the PIP. In addition, the DC guidelines were being revised to take into consideration other exceptions, such as social projects, IT solutions among others. \nI await the outcome of the commitment.", "metadata": {"headings": [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}, {"headings_1": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}, {"headings_1": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}, {"headings_1": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}, {"headings_1": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}, {"headings_1": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}, {"headings_1": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}, {"headings_1": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}, {"headings_1": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}]], "page": 39, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "b) Non-compliance with the 70% Capital Threshold", "metadata": {"headings": [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}, {"headings_1": {"content": "2.1.7.", "page": 39, "level": 2}}], "page": 39, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Section 2.2: Scope and Institutional arrangements of the Development Committee guidelines requires that Public investments admissible into the PIP shall be limited to public spending to acquire or establish physical assets necessary to facilitate production and delivery of economic, social and administrative services. Interventions that can be undertaken in the recurrent budget shall not be accommodated in the PIP. In this regard, for a project to be admitted into the PIP, its capital component shall account for at least 70% of the total project cost. It further states that interventions that can be undertaken in the recurrent budget shall not be accommodated in the PIP. \n27 \nAudit reviewed the Public Investment Plan for the year ending 30 th June 2021 and noted that 125 projects in the PIP with total budgets of UGX.4,410Bn did not meet the requirement of 70% capital intervention. The aggregate project expenditure on administrative functions was 75% while the aggregate capital expenditure requirements were only 25% of the entire total budget. I noted that some projects had 100% administrative expenditure. Refer to the table 8 below; \nTable 8 : Noncompliance with the 70% capital threshold", "metadata": {"headings": [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}, {"headings_1": {"content": "2.1.7.", "page": 39, "level": 2}}, [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}, {"headings_1": {"content": "2.1.7.", "page": 39, "level": 2}}], [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}, {"headings_1": {"content": "2.1.7.", "page": 39, "level": 2}}], [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}, {"headings_1": {"content": "2.1.7.", "page": 39, "level": 2}}]], "page": 39, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["No. of projects", "Total Budget -", "Capital", "Administrative", "% of"], ["", "UGX", "Expenditure - UGX", "expenditure - UGX", "administrative"], [null, "", null, null, "expenditure"], ["125", "4,410,809,884", "1,087,332,424", "3,323,477,460", "75%"]], "metadata": {"headings": [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}, {"headings_1": {"content": "2.1.7.", "page": 39, "level": 2}}], "page": 40, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "If this remains unchecked by the development committee, the government runs a risk of spending project funds on recurrent expenditure and thus failing to meet the targets set in", "metadata": {"headings": [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}, {"headings_1": {"content": "2.1.7.", "page": 39, "level": 2}}], "page": 40, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "the National Development Plan III.", "metadata": {"headings": [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], "page": 40, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "In addition, it was noted that the Development Committee does not consider software and intellectual properties as assets. This implies that any innovations in the ICT sector will continue to be unfunded, despite their potential to generative substantial returns. \nManagement explained that Section 2.2 applies to new projects to be admitted into the PIP and the budget. This requirement is fully adhered to by the DC but as projects continue into execution, recurrent costs can go higher, depending on the requirements between OPEX and CAPEX. The current DC guidelines are currently under review to provide for among others social projects, Grants, software investments and intangible assets, among others. \nI advised the PS/ST to review the guidelines taking into account the project lifecycle and classification of assets to include intangible assets. \nc) Overstay of projects in the PIP - UGX.39,011Bn \nThe Public Investment Management Reform Strategy provides that projects are supposed to be delivered on budget and on time in order to achieve the desired goals and objectives. \nAudit observed that in the sample of 371 projects, 342 projects (92.2%) with budgets totalling to UGX.39,011Bn had gone past their planned exit periods, that date as far back as the FY2010/11, with some projects having been extended for more than 12 years. Audit noted that the projects continued to receive DC approval for continued stay on the PIP It was noted that only 40% of the projects in the Public Investment Plan (PIP) were still within their expected time period. \nThis was attributed to lack of adequate planning and readiness, delays in procurements, late acquisition of right of way, poor contract management and inadequate capacity to implement and evaluate ongoing projects, and unauthorized change in the scope, among others. \n28 \nThis has caused delays in the completion of key projects, cost overruns and high commitment fees on foreign debt on account of low absorption and failure to complete projects on time.", "metadata": {"headings": [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}, [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}]], "page": 40, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Management attributed the overstay to implementation challenges which often lead to extensions in the PIP. Management also informed me that the Ministry had now adopted the resolution not to admit any project into the PIP and budget before completion of all required feasibility studies and ensuring that challenges that often lead to project extensions such as delays in acquisition of right of way, Environmental and Social impact assessment, among others are fulfilled before project commencement. In addition, the Ministry\u2019s leadership had directed that all old projects which continue to face implementation challenges either be cancelled and or renegotiated with the respective funders. \nI advised the PS/ST to devise a mechanism to improve the efficiency with which projects are implemented by ensuring that the causes identified above are addressed. \nd) Under absorption of funds by projects \nAccording to the approved Budget estimates of the FY2020/21, the Resource Envelope of Financial year 2020/21 approved by Parliament totals UGX.45,493.7Bn of which External Financing consists of Project Support of UGX.9,515.3Bn and General Budget Support", "metadata": {"headings": [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}, [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, {"headings_1": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}]], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UGX.2,906.7Bn.", "metadata": {"headings": [{"headings_0": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}, {"headings_1": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Audit obtained and reviewed cash inflows and expenditures of externally funded projects and noted poor absorption/performance of externally funded projects. Out of UGX.9,515.3Bn that was appropriated by Parliament, only UGX.4,516.5Bn (47%) was released. Relatedly, absorption of externally funded projects further declined in the year under audit. Out of the UGX.4,516.5Bn Disbursed for donor-funded projects, only UGX.2,937Bn was spent, representing 65.0% as compared to the 71% observed in the FY2019/20. The table 9 refers to; \nTable 9: Absorption of fund", "metadata": {"headings": [{"headings_0": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}, {"headings_1": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["External", "Release", "Expenditure", "Release", "Expenditure", "%of funds", "%of funds"], ["financing", "(UGX) Bn", "(UGX)Bn", "Variance", "Variance", "not", "not"], ["Budget", null, null, "(UGX) Bn", "(UGX) Bn", "released", "Absorbed"], ["(UGX)Bn", null, null, null, null, "(UGX) Bn", "(UGX) Bn"], ["9,515.30", "4,516.50", "2,937", "4,998.80", "1,579.50", "53%", "35%"]], "metadata": {"headings": [{"headings_0": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}, {"headings_1": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5", "column_6"], "type": "table"}}, {"content": "The under absorption of externally funded projects in the FY2020/21 was mainly due to the following; \n", "metadata": {"headings": [{"headings_0": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}, {"headings_1": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, [{"headings_0": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}, {"headings_1": {"content": "the National Development Plan III.", "page": 40, "level": 2}}]], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Implementation of unready projects, unrealistic conditions precedent to disbursements of funds which constrains decision making during project execution;\n- Covid-19 restrictions that affected implementation of projects\n- Delayed land acquisition;\n- Failure to quantify counterpart funding requirements at the time of project appraisal", "metadata": {"headings": [{"headings_0": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}, {"headings_1": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "and;", "metadata": {"headings": [{"headings_0": {"content": "and;", "page": 41, "level": 2}}, {"headings_1": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "and;", "page": 41, "level": 2}}, {"headings_1": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Cumbersome procurement processes as well as failure to undertake a comprehensive appraisal of projects.", "metadata": {"headings": [{"headings_0": {"content": "and;", "page": 41, "level": 2}}, {"headings_1": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Continued underutilization of external financing may lead to an increase in commitment charges and disadvantage other projects that could have utilized those resources efficiently. 29 \nManagement explained that a number of measures have been introduced to improve project absorption as follows;", "metadata": {"headings": [{"headings_0": {"content": "and;", "page": 41, "level": 2}}, {"headings_1": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}, [{"headings_0": {"content": "and;", "page": 41, "level": 2}}, {"headings_1": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}]], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "i)", "metadata": {"headings": [{"headings_0": {"content": "i)", "page": 42, "level": 2}}, {"headings_1": {"content": "and;", "page": 41, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "All projects to have feasibility studies before commencement and entry into the PIP,", "metadata": {"headings": [{"headings_0": {"content": "i)", "page": 42, "level": 2}}, {"headings_1": {"content": "and;", "page": 41, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ii)", "metadata": {"headings": [{"headings_0": {"content": "ii)", "page": 42, "level": 2}}, {"headings_1": {"content": "i)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Only sign loan agreements when conditions precedent have been fulfilled.", "metadata": {"headings": [{"headings_0": {"content": "ii)", "page": 42, "level": 2}}, {"headings_1": {"content": "i)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii)", "metadata": {"headings": [{"headings_0": {"content": "iii)", "page": 42, "level": 2}}, {"headings_1": {"content": "ii)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "All readiness conditions including acquisition of right of way, availability of adequate financing etc. as stipulated in the Project Selection criteria should be met before admission into the PIP and budget,", "metadata": {"headings": [{"headings_0": {"content": "iii)", "page": 42, "level": 2}}, {"headings_1": {"content": "ii)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iv)", "metadata": {"headings": [{"headings_0": {"content": "iv)", "page": 42, "level": 2}}, {"headings_1": {"content": "iii)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Enforce and enhance contract management through adhering to procurement regulations and training of contract managers.", "metadata": {"headings": [{"headings_0": {"content": "iv)", "page": 42, "level": 2}}, {"headings_1": {"content": "iii)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "v)", "metadata": {"headings": [{"headings_0": {"content": "v)", "page": 42, "level": 2}}, {"headings_1": {"content": "iv)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "A project management module in the Integrated Bank of Projects has been developed that will flag delay in a milestone and remind project managers on the required steps to facilitate expenditure.", "metadata": {"headings": [{"headings_0": {"content": "v)", "page": 42, "level": 2}}, {"headings_1": {"content": "iv)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "vi)", "metadata": {"headings": [{"headings_0": {"content": "vi)", "page": 42, "level": 2}}, {"headings_1": {"content": "v)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The Ministry is encouraging that Project management and implementation is undertaken by certified Project Management Professionals (PMP) who have the right skills, professionals and belong to a body that updates management knowledge. In this way project managers will be charged for underperformance which leads to low absorption.", "metadata": {"headings": [{"headings_0": {"content": "vi)", "page": 42, "level": 2}}, {"headings_1": {"content": "v)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "vii)", "metadata": {"headings": [{"headings_0": {"content": "vii)", "page": 42, "level": 2}}, {"headings_1": {"content": "vi)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Training of staff involved in loan and contract negotiations, \nviii) \nUndertake continuous training of staff in project appraisal, selection, execution, and ex-post evaluation,", "metadata": {"headings": [{"headings_0": {"content": "vii)", "page": 42, "level": 2}}, {"headings_1": {"content": "vi)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ix)", "metadata": {"headings": [{"headings_0": {"content": "ix)", "page": 42, "level": 2}}, {"headings_1": {"content": "vii)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Establish a Project Preparation Fund to support preparation of feasibility studies and provide resources for preliminary activities.", "metadata": {"headings": [{"headings_0": {"content": "ix)", "page": 42, "level": 2}}, {"headings_1": {"content": "vii)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "x)", "metadata": {"headings": [{"headings_0": {"content": "x)", "page": 42, "level": 2}}, {"headings_1": {"content": "ix)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Enforce the use of the Integrated Bank of Projects (IBP) for submission, preparation, execution and ex-post evaluation of projects,", "metadata": {"headings": [{"headings_0": {"content": "x)", "page": 42, "level": 2}}, {"headings_1": {"content": "ix)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "xi)", "metadata": {"headings": [{"headings_0": {"content": "xi)", "page": 42, "level": 2}}, {"headings_1": {"content": "x)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Adjusting to alternative strategies and approaches for project execution in light of Covid -19 restrictions and protocols e.g. virtual platforms, shifts for workers, embracing mass vaccination among others,", "metadata": {"headings": [{"headings_0": {"content": "xi)", "page": 42, "level": 2}}, {"headings_1": {"content": "x)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "xii)", "metadata": {"headings": [{"headings_0": {"content": "xii)", "page": 42, "level": 2}}, {"headings_1": {"content": "xi)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Fast track approval of the revised PPDA regulations, train staff on timely initiation of procurement processes and execution of contracts, \nxiii) Applying sanctions and rewards to efficient and inefficient Accounting Officers, respectively. \nI await the outcome of the above measures.", "metadata": {"headings": [{"headings_0": {"content": "xii)", "page": 42, "level": 2}}, {"headings_1": {"content": "xi)", "page": 42, "level": 2}}, [{"headings_0": {"content": "xii)", "page": 42, "level": 2}}, {"headings_1": {"content": "xi)", "page": 42, "level": 2}}]], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.1.8.", "metadata": {"headings": [{"headings_0": {"content": "2.1.8.", "page": 42, "level": 2}}, {"headings_1": {"content": "xii)", "page": 42, "level": 2}}], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Continued expenditure off the IFMS \u2013 UGX. 695,372,792,876 \nThe government of Uganda introduced the IFMS with a core objective of ensuring accurate, reliable and complete financial information for Government Ministries, Departments, Agencies and Local Authorities as well as an increase in the transparency of public spending. \nFrom a sample of ministries, it was observed that several entities which are already on the IFMS system, continue to send huge block figures outside the system after charging expenditure codes on the system; however, the ultimate expenditure cannot be restricted to what was charged. It was also noted that a number of entities post these funds to commercial bank accounts a practice that was stopped many years back. \n30 \nIt was also noted that a number of projects run by the various Ministries, departments and agencies are all spending off the IFMS. Although some of the bank accounts are held at Bank of Uganda, there are challenges of monitoring expenditure. \nManagement explained that whereas a significant amount of projects and subventions have been set up on IFMS either directly through being converted into Votes, the remaining subventions and Institutions are undergoing rationalization which will reduce the number of agencies off the IFMS. As explained, GoU is also undertaking a re-implementation of the IFMS which will have all projects aligned to departments under the parent Ministry. \nThe Ministry was to progressively set up the remaining agencies and stations as the exercise is ongoing coupled with resource availability to finance the IFMS rollout. \nI advised the PS/ST to ensure that all government expenditure is made on the IFMS and also provide a road map to ensure integration of all projects onto the IFMS. \nOther Information \nThe Accounting Officer is responsible for the other information. The other information comprises the statement of responsibilities, a statement from the Hon. Minister of Finance, Planning and Economic Development, a statement from the Secretary to the Treasury, a statement from the Accountant General, and other supplementary information. The other information does not include", "metadata": {"headings": [{"headings_0": {"content": "2.1.8.", "page": 42, "level": 2}}, {"headings_1": {"content": "xii)", "page": 42, "level": 2}}, [{"headings_0": {"content": "2.1.8.", "page": 42, "level": 2}}, {"headings_1": {"content": "xii)", "page": 42, "level": 2}}], [{"headings_0": {"content": "2.1.8.", "page": 42, "level": 2}}, {"headings_1": {"content": "xii)", "page": 42, "level": 2}}], [{"headings_0": {"content": "2.1.8.", "page": 42, "level": 2}}, {"headings_1": {"content": "xii)", "page": 42, "level": 2}}], [{"headings_0": {"content": "2.1.8.", "page": 42, "level": 2}}, {"headings_1": {"content": "xii)", "page": 42, "level": 2}}], [{"headings_0": {"content": "2.1.8.", "page": 42, "level": 2}}, {"headings_1": {"content": "xii)", "page": 42, "level": 2}}], [{"headings_0": {"content": "2.1.8.", "page": 42, "level": 2}}, {"headings_1": {"content": "xii)", "page": 42, "level": 2}}], [{"headings_0": {"content": "2.1.8.", "page": 42, "level": 2}}, {"headings_1": {"content": "xii)", "page": 42, "level": 2}}], [{"headings_0": {"content": "2.1.8.", "page": 42, "level": 2}}, {"headings_1": {"content": "xii)", "page": 42, "level": 2}}], [{"headings_0": {"content": "2.1.8.", "page": 42, "level": 2}}, {"headings_1": {"content": "xii)", "page": 42, "level": 2}}]], "page": 42, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "the financial statements and my auditors\u2019 report thereon.", "metadata": {"headings": [{"headings_0": {"content": "the financial statements and my auditors\u2019 report thereon.", "page": 43, "level": 2}}, {"headings_1": {"content": "2.1.8.", "page": 42, "level": 2}}], "page": 43, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "My opinion on the financial statements does not cover the other information and I do not express an audit opinion or any form of assurance conclusion thereon. \nIn connection with my audit of the financial statements, my responsibility is to read the other information and, in doing so, consider whether the other information is materially consistent with the financial statements or my knowledge obtained in the audit, or otherwise appears to be materially misstated. If, based on the work I have performed, I conclude that there is a material misstatement of this other information; I am required to report that fact. I have nothing to report in this regard.", "metadata": {"headings": [{"headings_0": {"content": "the financial statements and my auditors\u2019 report thereon.", "page": 43, "level": 2}}, {"headings_1": {"content": "2.1.8.", "page": 42, "level": 2}}, [{"headings_0": {"content": "the financial statements and my auditors\u2019 report thereon.", "page": 43, "level": 2}}, {"headings_1": {"content": "2.1.8.", "page": 42, "level": 2}}]], "page": 43, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Responsibilities of Management for the Consolidated Financial Statements", "metadata": {"headings": [{"headings_0": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}, {"headings_1": {"content": "the financial statements and my auditors\u2019 report thereon.", "page": 43, "level": 2}}], "page": 43, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Under Article 164 of the Constitution of the Republic of Uganda, 1995 (as amended) and Section 45 of the Public Finance Management Act, 2015 (as amended), the Accounting Officers are accountable to Parliament for the funds and resources of the Government of Uganda. \nThe Accountant General is appointed as the Accounting Officer and Receiver of Revenue for the Consolidated Fund. The Accountant General is therefore responsible for the preparation of financial statements in accordance with the requirements of the Public Finance Management Act 2015, and the Financial Reporting Guide 2018, and for such internal control as management determines is necessary to enable the preparation of financial statements that are free from material misstatements, whether due to fraud or error. \nIn preparing the financial statements, the Accountant General is responsible for assessing the Government\u2019s ability to continue delivering its mandate, disclosing, as applicable, matters related to affecting the delivery of the mandate of the Government of Uganda, and using the Financial Reporting Guide 2018 unless the Accountant General has a realistic alternative to the contrary. \n31 \nThe Accountant General is responsible for overseeing the Government\u2019s financial reporting process.", "metadata": {"headings": [{"headings_0": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}, {"headings_1": {"content": "the financial statements and my auditors\u2019 report thereon.", "page": 43, "level": 2}}, [{"headings_0": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}, {"headings_1": {"content": "the financial statements and my auditors\u2019 report thereon.", "page": 43, "level": 2}}], [{"headings_0": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}, {"headings_1": {"content": "the financial statements and my auditors\u2019 report thereon.", "page": 43, "level": 2}}], [{"headings_0": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}, {"headings_1": {"content": "the financial statements and my auditors\u2019 report thereon.", "page": 43, "level": 2}}], [{"headings_0": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}, {"headings_1": {"content": "the financial statements and my auditors\u2019 report thereon.", "page": 43, "level": 2}}]], "page": 43, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}, {"headings_1": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "My objectives are to obtain reasonable assurance about whether the consolidated financial statements of government as a whole are free from material misstatement, whether due to fraud or error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is a high level of assurance, but is not a guarantee that an audit conducted in accordance with ISSAIs will always detect a material misstatement when it exists. Misstatements can arise from fraud or error and are considered material if, individually or in the aggregate, they could reasonably be expected to influence the economic decisions of users taken on the basis of these financial statements. \nAs part of an audit in accordance with ISSAIs, I exercise professional judgment and maintain professional skepticism throughout the audit. I also;", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}, {"headings_1": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}, [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}, {"headings_1": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}]], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Identify and assess the risks of material misstatement of the consolidated financial statements, whether due to fraud or error, design and perform audit procedures responsive to those risks, and obtain audit evidence that is sufficient and appropriate to provide a basis for my opinion. The risk of not detecting a material misstatement resulting from fraud is higher than for one resulting from error, as fraud may involve collusion, forgery, intentional omissions, misrepresentations, or the override of internal control.", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}, {"headings_1": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}, {"headings_1": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Obtain an understanding of internal control relevant to the audit in order to design audit procedures that are appropriate in the circumstances, but not for the purpose of expressing", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}, {"headings_1": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}, {"headings_1": {"content": "Responsibilities of Management for the Consolidated Financial Statements", "page": 43, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "an opinion on the effectiveness of the government\u2019s internal control.", "metadata": {"headings": [{"headings_0": {"content": "an opinion on the effectiveness of the government\u2019s internal control.", "page": 44, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "an opinion on the effectiveness of the government\u2019s internal control.", "page": 44, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Evaluate the appropriateness of accounting policies used and the reasonableness of accounting estimates and related disclosures made by management.", "metadata": {"headings": [{"headings_0": {"content": "an opinion on the effectiveness of the government\u2019s internal control.", "page": 44, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern basis of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern basis of", "page": 44, "level": 2}}, {"headings_1": {"content": "an opinion on the effectiveness of the government\u2019s internal control.", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "accounting and, based on the audit evidence obtained, whether a material uncertainty exists", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern basis of", "page": 44, "level": 2}}, {"headings_1": {"content": "an opinion on the effectiveness of the government\u2019s internal control.", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "metadata": {"headings": [{"headings_0": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}, {"headings_1": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern basis of", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "deliver its mandate. If I conclude that a material uncertainty exists, I am required to draw attention in my auditor\u2019s report to the related disclosures in the financial statements or, if such disclosures are inadequate, to modify my opinion. My conclusions are based on the", "metadata": {"headings": [{"headings_0": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}, {"headings_1": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern basis of", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "metadata": {"headings": [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}, {"headings_1": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "conditions may cause the government to fail to deliver its mandate. \n", "metadata": {"headings": [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}, {"headings_1": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}, [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}, {"headings_1": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}]], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Evaluate the overall presentation, structure, and content of the financial statements, including the disclosures, and whether the financial statements represent the underlying transactions and events in a manner that achieves a fair presentation.", "metadata": {"headings": [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}, {"headings_1": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "I communicate with the Accounting Officer regarding, among other matters, the planned scope and timing of the audit and significant audit findings, including any significant deficiencies in internal control that I identify during my audit. \nI also provide the Accounting Officer with a statement that I have complied with relevant ethical requirements regarding independence, and to communicate with him/her all relationships and other \n32 \nmatters that may reasonably be thought to bear on my independence, and where applicable, related safeguards. \nFrom the matters communicated with the Accounting Officer, I determine those matters that were of most significance in the audit of the financial statements of the current period and are therefore the key audit matters. I describe these matters in my auditor\u2019s report unless law or regulation precludes public disclosure about the matter or when, in extremely rare circumstances, I determine that a matter should not be communicated in my report because the adverse consequences of doing so would reasonably be expected to outweigh the public interest benefits of such communication. \nOther Reporting Responsibilities \nIn accordance with Section 19(1) of the National Audit Act, 2008, I report to you, based on my work described on the audit of the GoU Consolidated Financial Statements that; except for the matters raised in the compliance with legislation section below, and whose effect has been considered in forming my opinion on the GoU consolidated financial statements, the activities, financial transactions and information reflected in the consolidated financial statements that have come to my notice during the audit, are in all material respects, in compliance with the authorities which govern them.", "metadata": {"headings": [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}, {"headings_1": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}, [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}, {"headings_1": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}], [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}, {"headings_1": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}], [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}, {"headings_1": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}], [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}, {"headings_1": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}], [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}, {"headings_1": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}], [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}, {"headings_1": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}]], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Report on the Audit of Compliance with Legislation", "metadata": {"headings": [{"headings_0": {"content": "Report on the Audit of Compliance with Legislation", "page": 45, "level": 2}}, {"headings_1": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}], "page": 45, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "In accordance with Section 19 of the NAA 2008, I have a responsibility to report material findings on the compliance of Government, with specific matters in key legislations. I performed procedures primarily to identify findings but not to gather evidence to express assurance. \nThe material findings in respect of the compliance criteria for the applicable subject matters are as follows;", "metadata": {"headings": [{"headings_0": {"content": "Report on the Audit of Compliance with Legislation", "page": 45, "level": 2}}, {"headings_1": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}, [{"headings_0": {"content": "Report on the Audit of Compliance with Legislation", "page": 45, "level": 2}}, {"headings_1": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}]], "page": 45, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.1.9.", "metadata": {"headings": [{"headings_0": {"content": "2.1.9.", "page": 45, "level": 2}}, {"headings_1": {"content": "Report on the Audit of Compliance with Legislation", "page": 45, "level": 2}}], "page": 45, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Use of prior financial years unspent funds \nArticle 154(1)(b) of the 1995 Constitution of the Republic of Uganda (as amended), provides that no monies shall be withdrawn from the Consolidated Fund except where the issue of those monies has been authorised by an Appropriation Act, a Supplementary Appropriation Act or as provided under clause (4) of this article. The Article further provides that no monies shall be withdrawn from any public fund of Uganda other than the Consolidated Fund, unless the issue of those monies has been authorised by law. \nSection 17(3) of the Public Finance Management Act requires Votes which return funds to consolidated fund to revise their annual work plan, procurement plan and recruitment plan to take into account the unexpended money and the Minister responsible for the vote shall submit, as part of the budget for the preceding year, the revised work plan, procurement plan and recruitment plan. \nIn the FY 20/21, it was observed that a total of UGX.26,098,586,831 was repaid into the consolidated funds from unspent monies from different votes. The said funds were however consequently utilized by the GOU without any form of appropriation. \nThe spending of funds by the GOU without appropriation of the said funds is irregular. \n33 \nI advised the PSST to always seek supplementary approval from Parliament before using returned funds.", "metadata": {"headings": [{"headings_0": {"content": "2.1.9.", "page": 45, "level": 2}}, {"headings_1": {"content": "Report on the Audit of Compliance with Legislation", "page": 45, "level": 2}}, [{"headings_0": {"content": "2.1.9.", "page": 45, "level": 2}}, {"headings_1": {"content": "Report on the Audit of Compliance with Legislation", "page": 45, "level": 2}}], [{"headings_0": {"content": "2.1.9.", "page": 45, "level": 2}}, {"headings_1": {"content": "Report on the Audit of Compliance with Legislation", "page": 45, "level": 2}}], [{"headings_0": {"content": "2.1.9.", "page": 45, "level": 2}}, {"headings_1": {"content": "Report on the Audit of Compliance with Legislation", "page": 45, "level": 2}}], [{"headings_0": {"content": "2.1.9.", "page": 45, "level": 2}}, {"headings_1": {"content": "Report on the Audit of Compliance with Legislation", "page": 45, "level": 2}}], [{"headings_0": {"content": "2.1.9.", "page": 45, "level": 2}}, {"headings_1": {"content": "Report on the Audit of Compliance with Legislation", "page": 45, "level": 2}}], [{"headings_0": {"content": "2.1.9.", "page": 45, "level": 2}}, {"headings_1": {"content": "Report on the Audit of Compliance with Legislation", "page": 45, "level": 2}}]], "page": 45, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "John F. S. Muwanga", "metadata": {"headings": [{"headings_0": {"content": "John F. S. Muwanga", "page": 46, "level": 2}}, {"headings_1": {"content": "2.1.9.", "page": 45, "level": 2}}], "page": 46, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "AUDITOR GENERAL \n31 st December, 2021 \n34 \n2.2 REPORT AND OPINION OF THE AUDITOR GENERAL ON THE GOVERNMENT OF", "metadata": {"headings": [{"headings_0": {"content": "John F. S. Muwanga", "page": 46, "level": 2}}, {"headings_1": {"content": "2.1.9.", "page": 45, "level": 2}}, [{"headings_0": {"content": "John F. S. Muwanga", "page": 46, "level": 2}}, {"headings_1": {"content": "2.1.9.", "page": 45, "level": 2}}], [{"headings_0": {"content": "John F. S. Muwanga", "page": 46, "level": 2}}, {"headings_1": {"content": "2.1.9.", "page": 45, "level": 2}}], [{"headings_0": {"content": "John F. S. Muwanga", "page": 46, "level": 2}}, {"headings_1": {"content": "2.1.9.", "page": 45, "level": 2}}]], "page": 46, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UGANDA CONSOLIDATED FINANCIAL STATEMENTS OF THE LOCAL GOVERNMENTS", "metadata": {"headings": [{"headings_0": {"content": "UGANDA CONSOLIDATED FINANCIAL STATEMENTS OF THE LOCAL GOVERNMENTS", "page": 47, "level": 2}}, {"headings_1": {"content": "John F. S. Muwanga", "page": 46, "level": 2}}], "page": 47, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "FOR THE YEAR ENDED 30 TH JUNE 2021 \nTHE RT. HON. SPEAKER OF PARLIAMENT", "metadata": {"headings": [{"headings_0": {"content": "UGANDA CONSOLIDATED FINANCIAL STATEMENTS OF THE LOCAL GOVERNMENTS", "page": 47, "level": 2}}, {"headings_1": {"content": "John F. S. Muwanga", "page": 46, "level": 2}}, [{"headings_0": {"content": "UGANDA CONSOLIDATED FINANCIAL STATEMENTS OF THE LOCAL GOVERNMENTS", "page": 47, "level": 2}}, {"headings_1": {"content": "John F. S. Muwanga", "page": 46, "level": 2}}]], "page": 47, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Opinion", "metadata": {"headings": [{"headings_0": {"content": "Opinion", "page": 47, "level": 2}}, {"headings_1": {"content": "UGANDA CONSOLIDATED FINANCIAL STATEMENTS OF THE LOCAL GOVERNMENTS", "page": 47, "level": 2}}], "page": 47, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I have audited the accompanying consolidated financial statements of Local Governments, which comprise the Consolidated Statement of Financial Position as at 30 th June 2021, the Consolidated Statement of Financial Performance, the Consolidated Statement of Changes in Equity, the Consolidated Statement of Cash Flows, together with other accompanying Consolidated statements for the year then ended, and notes to the Consolidated financial statements, including a summary of significant accounting policies. \nIn my opinion, the consolidated financial statements of Local Governments for the year ended 30 th June, 2021 are prepared in all material respects, in accordance with Section 52(b) of the Public Finance Management Act (PFMA), 2015 (as amended) and the", "metadata": {"headings": [{"headings_0": {"content": "Opinion", "page": 47, "level": 2}}, {"headings_1": {"content": "UGANDA CONSOLIDATED FINANCIAL STATEMENTS OF THE LOCAL GOVERNMENTS", "page": 47, "level": 2}}, [{"headings_0": {"content": "Opinion", "page": 47, "level": 2}}, {"headings_1": {"content": "UGANDA CONSOLIDATED FINANCIAL STATEMENTS OF THE LOCAL GOVERNMENTS", "page": 47, "level": 2}}]], "page": 47, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Financial Reporting Guide, 2018.", "metadata": {"headings": [{"headings_0": {"content": "Financial Reporting Guide, 2018.", "page": 47, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 47, "level": 2}}], "page": 47, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Basis for Opinion \nI conducted my audit in accordance with International Standards of Supreme Audit Institutions (ISSAIs). My responsibilities under those standards are further described in the Auditor\u2019s Responsibilities for the audit of the Financial Statements section of my report. I am independent of the Local Governments in accordance with the Constitution of the Republic of Uganda (1995) as amended, the National Audit Act, 2008, the International Organisation of Supreme Audit Institutions (INTOSAI) Code of Ethics, the", "metadata": {"headings": [{"headings_0": {"content": "Financial Reporting Guide, 2018.", "page": 47, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 47, "level": 2}}, [{"headings_0": {"content": "Financial Reporting Guide, 2018.", "page": 47, "level": 2}}, {"headings_1": {"content": "Opinion", "page": 47, "level": 2}}]], "page": 47, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "metadata": {"headings": [{"headings_0": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}, {"headings_1": {"content": "Financial Reporting Guide, 2018.", "page": 47, "level": 2}}], "page": 47, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Accountants (IESBA Code) and other independence requirements applicable to performing audits of Financial Statements in Uganda. I have fulfilled my ethical responsibilities in accordance with the other requirements and the IESBA Code. I believe that the audit evidence I have obtained is sufficient and appropriate to provide a basis for my opinion. \nKey Audit Matters \nKey audit matters are those matters that, in my professional judgment, were of most significance in my audit of the consolidated financial statements of the current period. These matters were addressed in the context of my audit of the consolidated financial statements as a whole, and in forming my opinion thereon, and I do not provide a separate opinion on these matters.", "metadata": {"headings": [{"headings_0": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}, {"headings_1": {"content": "Financial Reporting Guide, 2018.", "page": 47, "level": 2}}, [{"headings_0": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}, {"headings_1": {"content": "Financial Reporting Guide, 2018.", "page": 47, "level": 2}}], [{"headings_0": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}, {"headings_1": {"content": "Financial Reporting Guide, 2018.", "page": 47, "level": 2}}]], "page": 47, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.2.1.", "metadata": {"headings": [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}, {"headings_1": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}], "page": 47, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Payroll management in Local Governments \nOver the years, several reforms have been implemented in payroll management including salary, pension and gratuity payroll management decentralisation. Despite these reforms, challenges have persisted in the management of payroll in the Local Governments (LGs). \nAs a result, I considered payroll management in Local Governments as a Key Audit Matter and identified crosscutting risks including; unrealistic budgeting for employees and pension costs, under absorption of wage funds, delayed access \n35 \nto the payroll, over payment of salaries, non-payment of salary and pension arrears, among others. \nThe wage and Pension Payrolls of UGX.2,586.47 Bn constituted 46.1% of the overall Local Governments budget for 2020/2021 of UGX.5,615.86 Bn. \nI am aware that the Covid-19 Pandemic continues to significantly affect the implementation of payroll management activities. A number of Local Governments did not carry out planned recruitments resulting into huge unspent balances. \nConsequently, I designed procedures to address the risks in the payroll management in Local Governments. (Detailed findings are provided in individual entity reports) \nBased on the audit procedures performed, I made the following significant audit findings;", "metadata": {"headings": [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}, {"headings_1": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}, [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}, {"headings_1": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}], [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}, {"headings_1": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}], [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}, {"headings_1": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}], [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}, {"headings_1": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}], [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}, {"headings_1": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}], [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}, {"headings_1": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}], [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}, {"headings_1": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}]], "page": 47, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["No Observations", "Recommendations"], ["a) Payroll management in Local Governments", "I advised the"], ["Absorption of the released funds for payroll I reviewed funds absorption in 100 LGs and noted an under absorption of UGX79.62Bn. Out of the total receipts of UGX.1,539.37Bn, UGX.1,459.79Bn (94.8%) was absorbed. The unabsorbed balance was subsequently returned to the Consolidated Fund account as shown in the Table below. Table 10: Showing Level of Absorption for Wage, Pension and Gratuity Categ ory Approved Estimates (UGX) Bn Releases (UGX) Bn Expenditure (UGX) Bn Variance (UGX) Bn %age Absorpti on Wage 1,327.65 1,337.68 1,272.10 65.57 95.1 Pensi on/ gratu ity 204.20 201.69 187.63 14.05 93.0 1,531.85 1,539.37 1,459.73 79.62 94.8 Source: OAG analysis The under absorbed funds, denied the use of funds for other deserving service delivery areas. The under absorption was mainly attributed to Covid-19 pandemic and the lockdown, especially in the education sector. There was delayed deployment or non-recruitment of secondary school teachers for seed schools that had been recently constructed under the UgIFT projects.", "Accounting Officers to"], [null, "liaise with the relevant"], [null, "authorities and rollover"], [null, "the un-implemented"], [null, "activities to the"], [null, "subsequent period."], [null, ""], [null, ""], ["b) Management of Payroll Deductions i) Under/delayed remittance of Deduction Out of a sample of 84 LGs, I noted that whereas UGX 259.65 Bn was deducted from employees\u2019 salaries to be remitted to URA, UCLA/UBA and other beneficiaries, I noted that contrary to I advised the Accounting Officers to ensure that necessary payroll changes are made timely before payments are effected.", null]], "metadata": {"headings": [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}, {"headings_1": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}], "page": 48, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_7"], "type": "table"}}, {"content": "36", "metadata": {"headings": [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}, {"headings_1": {"content": "International Ethics Standards Board for Accountants\u2019 Code of Ethics for Professional", "page": 47, "level": 2}}], "page": 48, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Paragraph B-a(17) of the Uganda Public Standing Orders, 2010 I further advised the", "metadata": {"headings": [{"headings_0": {"content": "Paragraph B-a(17) of the Uganda Public Standing Orders, 2010 I further advised the", "page": 49, "level": 3}}, {"headings_1": {"content": "2.2.1.", "page": 47, "level": 2}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "there were:", "metadata": {"headings": [{"headings_0": {"content": "Paragraph B-a(17) of the Uganda Public Standing Orders, 2010 I further advised the", "page": 49, "level": 3}}, {"headings_1": {"content": "2.2.1.", "page": 47, "level": 2}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "page": 49, "level": 3}}, {"headings_1": {"content": "Paragraph B-a(17) of the Uganda Public Standing Orders, 2010 I further advised the", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "page": 49, "level": 3}}, {"headings_1": {"content": "Paragraph B-a(17) of the Uganda Public Standing Orders, 2010 I further advised the", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Under remittances of UGX 7.33 Bn as shown in table below.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "page": 49, "level": 3}}, {"headings_1": {"content": "Paragraph B-a(17) of the Uganda Public Standing Orders, 2010 I further advised the", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Table 11: Showing over and under remittance of deductions", "metadata": {"headings": [{"headings_0": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}, {"headings_1": {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Over remittance \nUnder remittance \nAccounting Officers to initiate strategies that ensure timely remittances of payroll deductions and the over remittances should Number of Amount Number of Amount be recovered. \nDetails Entities with (UGX) Bn Entities with (UGX) \nover under Bn \nremittance \nremittance \nPAYE 13 0.92 65 5.76 UCLA/ \n0 \nUBA 27 .92 48 1.15 \nLST 33 0.27 41 0.20 \nOthers 31 0.50 49 0.22 Total 2.16 7.33 Source: OAG Analysis", "metadata": {"headings": [{"headings_0": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}, {"headings_1": {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "page": 49, "level": 3}}, [{"headings_0": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}, {"headings_1": {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "page": 49, "level": 3}}], [{"headings_0": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}, {"headings_1": {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "page": 49, "level": 3}}], [{"headings_0": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}, {"headings_1": {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "page": 49, "level": 3}}], [{"headings_0": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}, {"headings_1": {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "page": 49, "level": 3}}]], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "In addition, 85 LGs (79.4%) out of 107 delayed to remit the funds to UCLA/UBA, contrary to the requirement that payroll deductions are remitted concurrently with salary payments. The extreme", "metadata": {"headings": [{"headings_0": {"content": "In addition, 85 LGs (79.4%) out of 107 delayed to remit the funds to UCLA/UBA, contrary to the requirement that payroll deductions are remitted concurrently with salary payments. The extreme", "page": 49, "level": 3}}, {"headings_1": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "delays were noted in the districts shown in the table below.", "metadata": {"headings": [{"headings_0": {"content": "In addition, 85 LGs (79.4%) out of 107 delayed to remit the funds to UCLA/UBA, contrary to the requirement that payroll deductions are remitted concurrently with salary payments. The extreme", "page": 49, "level": 3}}, {"headings_1": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Table 12: Average delay in remittance to UCLA", "metadata": {"headings": [{"headings_0": {"content": "Table 12: Average delay in remittance to UCLA", "page": 49, "level": 3}}, {"headings_1": {"content": "In addition, 85 LGs (79.4%) out of 107 delayed to remit the funds to UCLA/UBA, contrary to the requirement that payroll deductions are remitted concurrently with salary payments. The extreme", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Vote Number Vote Name \nAverage Delay (in Days) \n564 Amolatar DLG \n38 604 Napak dlg \n35 623 Nabilatuk dlg \n46 610 Buhweju DLG \n41 629 Obongi DLG \n55 556 Yumbe DLG \n35 633 Madi-Okollo DLG \n35 572 Oyam DLG \n36 Source: OAG Analysis", "metadata": {"headings": [{"headings_0": {"content": "Table 12: Average delay in remittance to UCLA", "page": 49, "level": 3}}, {"headings_1": {"content": "In addition, 85 LGs (79.4%) out of 107 delayed to remit the funds to UCLA/UBA, contrary to the requirement that payroll deductions are remitted concurrently with salary payments. The extreme", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "I further noted that 48 LGs (45%) out of 107 delayed to remit the funds to URA, contrary to the requirement that withholding agents remit to URA any tax that has been withheld or that should have", "metadata": {"headings": [{"headings_0": {"content": "I further noted that 48 LGs (45%) out of 107 delayed to remit the funds to URA, contrary to the requirement that withholding agents remit to URA any tax that has been withheld or that should have", "page": 49, "level": 3}}, {"headings_1": {"content": "Table 12: Average delay in remittance to UCLA", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "been withheld within fifteen days after the end of the month in which the payment subject to withholding tax was made by the", "metadata": {"headings": [{"headings_0": {"content": "I further noted that 48 LGs (45%) out of 107 delayed to remit the funds to URA, contrary to the requirement that withholding agents remit to URA any tax that has been withheld or that should have", "page": 49, "level": 3}}, {"headings_1": {"content": "Table 12: Average delay in remittance to UCLA", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "withholding agent. The extreme delays were noted in Mbarara MC,", "metadata": {"headings": [{"headings_0": {"content": "withholding agent. The extreme delays were noted in Mbarara MC,", "page": 49, "level": 3}}, {"headings_1": {"content": "I further noted that 48 LGs (45%) out of 107 delayed to remit the funds to URA, contrary to the requirement that withholding agents remit to URA any tax that has been withheld or that should have", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Kaberamaido DLG, Buyende DLG and Buhweju DLG of 8, 9, 8 and 11 months respectively.", "metadata": {"headings": [{"headings_0": {"content": "withholding agent. The extreme delays were noted in Mbarara MC,", "page": 49, "level": 3}}, {"headings_1": {"content": "I further noted that 48 LGs (45%) out of 107 delayed to remit the funds to URA, contrary to the requirement that withholding agents remit to URA any tax that has been withheld or that should have", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Delayed/ non remittance of deductions to UCLA/UBA could lead to", "metadata": {"headings": [{"headings_0": {"content": "Delayed/ non remittance of deductions to UCLA/UBA could lead to", "page": 49, "level": 3}}, {"headings_1": {"content": "withholding agent. The extreme delays were noted in Mbarara MC,", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "delays in up-dating loan status with the various financial institutions causing un-necessary default charges on employees", "metadata": {"headings": [{"headings_0": {"content": "Delayed/ non remittance of deductions to UCLA/UBA could lead to", "page": 49, "level": 3}}, {"headings_1": {"content": "withholding agent. The extreme delays were noted in Mbarara MC,", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "metadata": {"headings": [{"headings_0": {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "page": 49, "level": 3}}, {"headings_1": {"content": "Delayed/ non remittance of deductions to UCLA/UBA could lead to", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "that had not been paid by 30 th June 2021. \n37", "metadata": {"headings": [{"headings_0": {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "page": 49, "level": 3}}, {"headings_1": {"content": "Delayed/ non remittance of deductions to UCLA/UBA could lead to", "page": 49, "level": 3}}, [{"headings_0": {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "page": 49, "level": 3}}, {"headings_1": {"content": "Delayed/ non remittance of deductions to UCLA/UBA could lead to", "page": 49, "level": 3}}]], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["The Accounting Officers did not provide satisfactory explanations to justify the over remittances. For the under payments, the Accounting Officers attributed it mainly to suspension of staff salaries due to disciplinary issues, delayed removal of staff from the payroll and delays in resolving issues such as abscondment where payments were withheld. For delays in remittance of deductions, the Accounting Officers attributed it to delays in reconciliation of interface deduction files. ii) Un-authorized loans deductions I noted that 48 LGs made unauthorised loans deductions totaling UGX 11.10 Bn. The deductions were from 6,835 employees that lacked letters of consent/ undertaking. I further noted that out of the 48 LGs, 23 LGs (48%) registered 1,916 employees with deductions totaling to UGX 3.77 Bn that did not exist in the Payroll Deduction Management System (PDMS), operated by PCA-Payroll Consults Africa. There is a risk of making deductions from staff that have no loans, which deprives them of their earnings. The inconsistencies in the PDMS undermine the relevance of the system and affect the integrity of the data therein. The Accounting Officers acknowledged the shortcoming and explained that letters of undertaking were being signed although file copies were not being retained for future reference. They further explained that the inconsistencies in the PDMS data were attributed to PCA who largely control and manage the system. I advised Government through MoPS to ensure that PCA makes the necessary data reconciliation and update the information on the PDMS regarding the deductions. I further advised the Accounting Officers to ensure that all loan applications are backed by letters of undertaking and approved through the PDMS.", null, null, null, null, null, null], ["c) Access to Payrolls i) Delayed access to salary payroll I noted that 2,178 newly recruited employees in 75 LGs delayed to access payroll, with delays ranging from 1-34 months. I further noted that 407 employees in 17 LGs had not yet accessed the payroll by the close of the financial year. Delayed access to payroll leads to demotivation of the affected staff and accumulation of salary arrears. The Accounting Officers attributed the shortcoming mainly to delayed submission of key personnel documents and data mismatch between IPPS & NIRA. I advised the Accounting Officers to sensitise the newly recruited employees on the timely submission of the key documents. I further urged the Accounting Officers to ensure timely validation of the newly recruited employees and to liaise with the relevant authorities to improve effectiveness and reliability of the MoPS/NID interface.", null, null, null, null, null, null], ["", "ii) Delayed access to pension payroll noted that 780 pensioners delayed to access the pension payroll,", null, null, null, null, "I advised the"]], "metadata": {"headings": [{"headings_0": {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "page": 49, "level": 3}}, {"headings_1": {"content": "Delayed/ non remittance of deductions to UCLA/UBA could lead to", "page": 49, "level": 3}}], "page": 50, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5", "column_6"], "type": "table"}}, {"content": [["The Accounting Officers did not provide satisfactory explanations to justify the over remittances. For the under payments, the Accounting Officers attributed it mainly to suspension of staff salaries due to disciplinary issues, delayed removal of staff from the payroll and delays in resolving issues such as abscondment where payments were withheld. For delays in remittance of deductions, the Accounting Officers attributed it to delays in reconciliation of interface deduction files. ii) Un-authorized loans deductions I noted that 48 LGs made unauthorised loans deductions totaling UGX 11.10 Bn. The deductions were from 6,835 employees that lacked letters of consent/ undertaking. I further noted that out of the 48 LGs, 23 LGs (48%) registered 1,916 employees with deductions totaling to UGX 3.77 Bn that did not exist in the Payroll Deduction Management System (PDMS), operated by PCA-Payroll Consults Africa. There is a risk of making deductions from staff that have no loans, which deprives them of their earnings. The inconsistencies in the PDMS undermine the relevance of the system and affect the integrity of the data therein. The Accounting Officers acknowledged the shortcoming and explained that letters of undertaking were being signed although file copies were not being retained for future reference. They further explained that the inconsistencies in the PDMS data were attributed to PCA who largely control and manage the system. I advised Government through MoPS to ensure that PCA makes the necessary data reconciliation and update the information on the PDMS regarding the deductions. I further advised the Accounting Officers to ensure that all loan applications are backed by letters of undertaking and approved through the PDMS.", null, null, null, null, null, null], ["c) Access to Payrolls i) Delayed access to salary payroll I noted that 2,178 newly recruited employees in 75 LGs delayed to access payroll, with delays ranging from 1-34 months. I further noted that 407 employees in 17 LGs had not yet accessed the payroll by the close of the financial year. Delayed access to payroll leads to demotivation of the affected staff and accumulation of salary arrears. The Accounting Officers attributed the shortcoming mainly to delayed submission of key personnel documents and data mismatch between IPPS & NIRA. I advised the Accounting Officers to sensitise the newly recruited employees on the timely submission of the key documents. I further urged the Accounting Officers to ensure timely validation of the newly recruited employees and to liaise with the relevant authorities to improve effectiveness and reliability of the MoPS/NID interface.", null, null, null, null, null, null], ["", "ii) Delayed access to pension payroll noted that 780 pensioners delayed to access the pension payroll,", null, null, null, null, "I advised the"], ["I", null, null, null, null, null, "Accounting Officers to liaise with MoPS to initiate strategies of rectifying the inconsistencies with"], [null, "", "", "", "", "", "NIRA interface and to"], [null, "", "", "", "", "", "cause the beneficiaries"]], "metadata": {"headings": [{"headings_0": {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "page": 49, "level": 3}}, {"headings_1": {"content": "Delayed/ non remittance of deductions to UCLA/UBA could lead to", "page": 49, "level": 3}}], "page": 50, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5", "column_6"], "type": "table"}}, {"content": "with", "metadata": {"headings": [{"headings_0": {"content": "with", "page": 50, "level": 3}}, {"headings_1": {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "page": 49, "level": 3}}], "page": 50, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "107 09 146", "metadata": {"headings": [{"headings_0": {"content": "with", "page": 50, "level": 3}}, {"headings_1": {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "page": 49, "level": 3}}], "page": 50, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "by", "metadata": {"headings": [{"headings_0": {"content": "by", "page": 50, "level": 3}}, {"headings_1": {"content": "with", "page": 50, "level": 3}}], "page": 50, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "38", "metadata": {"headings": [{"headings_0": {"content": "by", "page": 50, "level": 3}}, {"headings_1": {"content": "with", "page": 50, "level": 3}}], "page": 50, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", null, null, null, "to submit the essential"], [null, "Delayed access to the pension payroll leads to poor wellbeing of", null, null, null, "documents in time. I further advised PS/ST to ensure adequate allocation of pension and gratuity funds."], [null, "affected retirees as well as accumulation of pension arrears.", null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "by", "page": 50, "level": 3}}, {"headings_1": {"content": "with", "page": 50, "level": 3}}], "page": 51, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5"], "type": "table"}}, {"content": [["", "", null, null, null, "to submit the essential"], [null, "Delayed access to the pension payroll leads to poor wellbeing of", null, null, null, "documents in time. I further advised PS/ST to ensure adequate allocation of pension and gratuity funds."], [null, "affected retirees as well as accumulation of pension arrears.", null, null, null, null], [null, "", null, null, null, null], [null, "Accounting Officers attributed the shortcoming to mainly mismatch of data between NIRA and IPPS interfaces such as wrong dates of birth, delayed submission of documents and", null, null, null, null], [null, "inadequate budget allocation to cater for all retirees hence phased", null, null, null, null], [null, "access to the pension payroll.", null, null, null, null], [null, "", null, null, null, null], ["d) Delayed deletion of staff from the salary payroll I noted that in 78 LGs, a total of UGX 1.13 Bn was paid to 635 staff who had either retired, transferred, absconded or died. These were payment for services that were not rendered to the LGs, hence loss of funds to Government. This was mainly attributed to delayed communication from supervisors of the affected staff as well as failure to delete affected staff due to lack of validation on the MoPS/ NID interface. I advised the Accounting Officers to sensitise all supervisors on when and how to communicate such cases so as to ensure prompt removal of staff from the payroll. I further urged the Accounting Officers to ensure that all staff are validated on the MoPS/ NID interface. I also advised MoPS to automate the deletion of retirees on mandatory grounds.", null, null, null, null, null], ["e)", "Misclassification of salary, pension and gratuity expenditure 3.60 Bn in 33 LGs was charged on account codes other than", null, null, null, "I advised the"], ["", null, null, null, null, "Accounting Officers to ensure that wage, pension and gratuity expenditure is charged on the appropriate codes."], [null, "", "", "", "", ""], [null, "insufficient budget provisions for pensions and gratuity. I advised", null, null, null, null], [null, "Accounting Officers to liaise with MoFPED to ensure that", null, null, null, null], [null, "sufficient budget provisions are made.", null, null, null, null], ["f) Effectiveness and reliability of the IPPS/NID interface I reviewed the effectiveness and reliability of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification interface and made the following observations; \uf0b7 There was in-adequate sensitization and training in the use and navigation of the system \uf0b7 System was not reliable and effective \uf0b7 Operational challenges were encountered, including; \uf076 Un-reliable network \uf076 Failure to reflect changes in updated staff information \uf076 Mismatches of names that take long to be corrected by NIRA \uf076 Some information on the NIRA interface is sometimes not visible/available for instance date of birth and the I advised the Accounting Officers to engage MoPS and NIRA to have trainings conducted as well as resolve the system challenges.", null, null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "by", "page": 50, "level": 3}}, {"headings_1": {"content": "with", "page": 50, "level": 3}}], "page": 51, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5"], "type": "table"}}, {"content": "the The", "metadata": {"headings": [{"headings_0": {"content": "the The", "page": 51, "level": 3}}, {"headings_1": {"content": "by", "page": 50, "level": 3}}], "page": 51, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX", "metadata": {"headings": [{"headings_0": {"content": "UGX", "page": 51, "level": 3}}, {"headings_1": {"content": "the The", "page": 51, "level": 3}}], "page": 51, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The the", "metadata": {"headings": [{"headings_0": {"content": "The the", "page": 51, "level": 3}}, {"headings_1": {"content": "UGX", "page": 51, "level": 3}}], "page": 51, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "39 \nphoto which delays the verification exercise.", "metadata": {"headings": [{"headings_0": {"content": "The the", "page": 51, "level": 3}}, {"headings_1": {"content": "UGX", "page": 51, "level": 3}}, [{"headings_0": {"content": "The the", "page": 51, "level": 3}}, {"headings_1": {"content": "UGX", "page": 51, "level": 3}}]], "page": 51, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The ineffectiveness of the system my affect the integrity of the", "metadata": {"headings": [{"headings_0": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}, {"headings_1": {"content": "The the", "page": 51, "level": 3}}], "page": 52, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "IPPS payroll. \nThe Accounting Officers noted the finding. \nOther Matter \nI consider it necessary to communicate the following matters other than those presented or disclosed in the financial statements.", "metadata": {"headings": [{"headings_0": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}, {"headings_1": {"content": "The the", "page": 51, "level": 3}}, [{"headings_0": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}, {"headings_1": {"content": "The the", "page": 51, "level": 3}}], [{"headings_0": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}, {"headings_1": {"content": "The the", "page": 51, "level": 3}}]], "page": 52, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.2.2.", "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], "page": 52, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Implementation of the approved budget \nA review of the Local Governments approved budgets of UGX 5,615.86Bn out of which UGX 4,328.01 Bn was warranted/ availed by the end of the financial year. The total expenditure for the year was UGX 4,147.90 Bn out of which UGX 2,853.55Bn was spent on employee costs and transfers to other units implying that only UGX.1,294.35 Bn was available for implementation of service delivery outputs. \nFrom the procedures undertaken, I noted the following significant observations", "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}, [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}]], "page": 52, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["No Observations Recommendations", null, null], ["1.0", "Existence of Strategic plans that are aligned to NDP-III Paragraph 5 of the budget execution circular for the financial", "I advised the"], ["", null, "Accounting Officers to"], [null, "year 2020/2021 cites poor alignment of Government Budgets", "follow up the matter"], [null, "with the National Development Plans. The PS/ST urged", "with NPA and ensure"], [null, "Accounting Officers to ensure that all activities for Financial", "that the entities have"], [null, "Year 2020/2021 are aligned with NDP III and implemented", "strategic plans that are"], [null, "accordingly. Regulation 26 (1) of the National Planning", "aligned to NDP-III and"], [null, "Authority (development of Plans) regulations require entities", "certified by NPA."], [null, "to submit to NPA their five-year development plans for", null], [null, "certification before approval.", null], [null, "", null], [null, "This being the first year of implementation of the NDP-III,", null], [null, "LGs were expected to prepare a strategic plan aligned to", null], [null, "NDP III and ensure that these plans are certified by NPA.", null], [null, "These plans would then be the basis for preparation of the", null], [null, "entity annual plans.", null], [null, "", null], [null, "From the procedures undertaken I noted that out of 86", null], [null, "entities sampled, none had prepared a strategic plan that", null], [null, "was aligned to NDP-III and certified by NPA. There is a risk", null], [null, "that activities implemented by these entities during the", null], [null, "financial year 2020/2021 were not aligned to the NDP-III", null], [null, "which negatively affects the achievement of NDP-III", null], [null, "objectives.", null], [null, "", null], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], "page": 52, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "40", "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], "page": 52, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["2.1 a) Absorption of released funds Out of the total receipts for the financial year of UGX 4,328.01 Bn, UGX 4,147.90 Bn (95.8%) was spent by the Local Governments resulting in an unspent balance of UGX 180.11 Bn (4.2%). The unspent balance at the end of the financial year was remitted back to the consolidated fund account. Under absorption of released funds results in non- implementation of planned activities and negates the purpose for which funds were disbursed, thereby affecting the achievement of the objectives in the NDPIII. For example, implementation of USMID projects in Municipal Councils and UgIFT projects in DLGs was not undertaken. The Accounting Officers attributed failure to utilise funds to COVID-19 which affected the recruitment exercise, late release of USMID funds and delays in the procurement process and lotting policy of contract works under UgIFT. I advised the Accounting Officer to liaise with line Ministries to revote the funds, roll over the activities and ensure they are subsequently implemented.", null, null], ["", "b) Revenue Performance i) Local Revenue performance The local governments budgeted to receive UGX 217.38 Bn", "I await the outcome of"], ["", null, "the interventions"]], "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], "page": 53, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_6"], "type": "table"}}, {"content": [["2.1 a) Absorption of released funds Out of the total receipts for the financial year of UGX 4,328.01 Bn, UGX 4,147.90 Bn (95.8%) was spent by the Local Governments resulting in an unspent balance of UGX 180.11 Bn (4.2%). The unspent balance at the end of the financial year was remitted back to the consolidated fund account. Under absorption of released funds results in non- implementation of planned activities and negates the purpose for which funds were disbursed, thereby affecting the achievement of the objectives in the NDPIII. For example, implementation of USMID projects in Municipal Councils and UgIFT projects in DLGs was not undertaken. The Accounting Officers attributed failure to utilise funds to COVID-19 which affected the recruitment exercise, late release of USMID funds and delays in the procurement process and lotting policy of contract works under UgIFT. I advised the Accounting Officer to liaise with line Ministries to revote the funds, roll over the activities and ensure they are subsequently implemented.", null, null], ["", "b) Revenue Performance i) Local Revenue performance The local governments budgeted to receive UGX 217.38 Bn", "I await the outcome of"], ["", null, "the interventions"], [null, null, "instituted by GoU to"], [null, "(revised) as total revenue for the year. However, only UGX", "stimulate revenue"], [null, "96.28 Bn representing 44.29% of their revised budgets was", "collection."], [null, "received performance.", ""], [null, "", "In addition, I urged the"], [null, "Under collection of local revenue results in non-", "respective Accounting"], [null, "implementation of planned activities which affects service", "Officers to make"], [null, "delivery.", "budget revisions based"], [null, "The Accounting Officers of the respective local government", "on realistic forecasts in"], [null, "votes attributed the shortfall in local revenue to COVID 19", "such unforeseen"], [null, "effects.", "circumstances."], [null, "", ""], [null, "The Accountant General explained that Government of", null], [null, "Uganda (GoU) had provided some interventions including", null], [null, "vaccination and funding to revive the economy for activities", null], [null, "to resume and stimulate revenue collection.", null], [null, "", null], ["ii) Revenue from External financing The Local Governments budgeted to receive UGX 413.94 Bn as external/donor financing, out of which UGX 57 Bn (13.8%), was received Revenue shortfalls affect the implementation of planned activities. The Accounting Officer attributed this to the fact that the Local governments did not receive indicative planning figures from the donors for proper and realistic budgeting for the Financial Year under review.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], "page": 53, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_6"], "type": "table"}}, {"content": "41", "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], "page": 53, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii) Off Budget Financing/Receipts \nI advise Government through the Ministry of Section 43 (1) of the PFMA 2015 states that all expenditure Finance to negotiate incurred by the government on externally financed projects and mainstream Donor in a financial year shall be appropriated by parliament. funding in the Local Paragraph 29 of the Budget Execution Circular for the Governments Budgeting Financial year states that if an external agency provides Process. \nfunds in the course of implementation of the budget or any \nfunds remain unspent at the expiry of an appropriation, \nthese must be declared and a supplementary issued in line \nwith the Public Finance Management Act 2015. \nI noted that 17 of the 86 LGs sampled received off-budget financing to a tune of UGX 14.20 Bn, which was never declared to the PS/ST and was also not appropriated by parliament. As such, no supplementary appropriation was issued as guided by the PS/ST. These funds were received directly from development partners for undertaking activities not budgeted for. Off-budget financing distorts planning, may result in duplication of activities, contrary to Section 43(1) of the PFMA 2015 and the budget execution guidelines issued by the PS/ST. \nThe Accounting Officers explained this was due to limitations of the PBS system which has no provision for inputting such receipts and in some cases funds are received during the year which were not expected at the time of planning. \n42", "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}, [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}]], "page": 54, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iv) Quantification of activities and Implementation of I advised the planned outputs \nAccounting Officers to ensure that work plans Section 13 (15, b) of the PFMA 2015 states that a policy and budgets are fully statement submitted by a vote shall contain the annual and quantified and ensure three months\u2019 work plans, outputs, targets and performance that \nun-implemented indicators of the work plans. Regulation 11 (3) of PFMR 2016 \nactivities are rolled over requires that a vote prepares a work plan that indicates the to the subsequent outputs of the vote for the financial year; the indicators to periods \nfor be used to gauge the performance of the outputs and funds \nimplementation. allocated to each activity. \nI sampled 86 entities for purposes assessing the extent of quantification and implementation of planned outputs I noted that out of the 850 outputs worth UGX 254 Bn sampled for review, 675 outputs (79%) worth UGX 182 Bn were fully quantified, 58 outputs (7%) worth UGX 34 Bn were partially quantified while 117 out puts (14%) worth UGX 38 Bn were not quantified at all. \nOut of a total of 675 quantified out-puts worth UGX.182 Bn assessed, 475 (70.4%) output worth UGX 90.10 Bn were fully implemented, 172 outputs (25.5%) worth UGX 86.70 Bn were partially implemented, while 28 (4%) out-puts worth UGX 4.90 Bn were not implemented at all. The graph below shows the extent of implementation;", "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}, [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, {"headings_1": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}]], "page": 55, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Extent of implementation of quantified out- puts", "metadata": {"headings": [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}, {"headings_1": {"content": "2.2.2.", "page": 52, "level": 2}}], "page": 55, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "4% 26% \n70% \nFully Implemented \nPartially Implemented \nNot implemented \nThe Accounting Officers explained that implementation of activities was affected by the restrictions in movement imposed by government to curb the spread of Covid-19 and the fact that staff at the entities were working at 30% staffing levels. Failure to fully quantify the planned activities makes the assessment of implementation difficult while failure to implement planned activities denies citizens services. \n43", "metadata": {"headings": [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}, {"headings_1": {"content": "2.2.2.", "page": 52, "level": 2}}, [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}, {"headings_1": {"content": "2.2.2.", "page": 52, "level": 2}}], [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}, {"headings_1": {"content": "2.2.2.", "page": 52, "level": 2}}], [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}, {"headings_1": {"content": "2.2.2.", "page": 52, "level": 2}}], [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}, {"headings_1": {"content": "2.2.2.", "page": 52, "level": 2}}], [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}, {"headings_1": {"content": "2.2.2.", "page": 52, "level": 2}}]], "page": 55, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.2.3. Operationalization of New Cities", "metadata": {"headings": [{"headings_0": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}, {"headings_1": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}], "page": 56, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "During the FY 2019/20 Government made a pronouncement upgrading ten (10) Municipal Councils (MCs) to City status effective 1 st July 2020. These include; Arua, Mbarara, Gulu, Jinja Fort portal, Mbale, Masaka, Soroti, Hoima and Lira \nDuring my audit of the above cities for the F/Year 2020/21, I noted the following;", "metadata": {"headings": [{"headings_0": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}, {"headings_1": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}, [{"headings_0": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}, {"headings_1": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}]], "page": 56, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "i) Government did not provide funding in the budgets of the newly created entities to enable them operate as cities. I noted that they continued to operate using the budgets of MCs. \nii) The High Court in Masaka was petitioned by some individuals to review the guidelines issued by the Minister of Local Governments for the new cities on grounds that they contravened the procedures set out in the Local Government Act. \niii) The cities lacked establishment structures against which the recruitment of the required human resource could be undertaken. \niv) There was no guidance on the allocation/sharing of assets. This has become a contentious matter between the councils of the newly created cities and those of the hosting districts. \nAs a result of the above, the high expectations of both the local political leadership and the general public have not been met. \nI advise Government to ensure that the new cities are fully operationalised.", "metadata": {"headings": [{"headings_0": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}, {"headings_1": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}, [{"headings_0": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}, {"headings_1": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}], [{"headings_0": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}, {"headings_1": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}]], "page": 56, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "metadata": {"headings": [{"headings_0": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}, {"headings_1": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}], "page": 56, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The Government through MoES released UGX 23 Bn for printing of home study materials to facilitate home learning during the COVID 19 lockdown. \nHowever, I noted that the study materials were not procured and the districts were advised to send the money to the school bank accounts with a condition that they should not spend until instructed to do so. \nAt the time of writing this report, the home study materials had not been printed", "metadata": {"headings": [{"headings_0": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}, {"headings_1": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}, [{"headings_0": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}, {"headings_1": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}], [{"headings_0": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}, {"headings_1": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}]], "page": 56, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "metadata": {"headings": [{"headings_0": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}, {"headings_1": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}], "page": 56, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Consequently, the objective of ensuring that learners continued to learn during the lockdown was not achieved. \nThe Accounting Officers explained that no instructions were given as indicated by the MoES. \nI advise Government through MoES to always provide timely guidance and coordination in such events that require urgent government interventions. \nI also recommend that schools are given guidance on the utilization of the funds. \n44", "metadata": {"headings": [{"headings_0": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}, {"headings_1": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}, [{"headings_0": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}, {"headings_1": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}], [{"headings_0": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}, {"headings_1": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}], [{"headings_0": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}, {"headings_1": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}]], "page": 56, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.2.5. Un-Accounted for Funds", "metadata": {"headings": [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}, {"headings_1": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}], "page": 57, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Section 43(2) of the of the Local Governments Financial and Accounting Regulations, 2007 require administrative advances to council employees to be authorized by the executive and accounted for within a month. \nI noted expenditure of UGX 3.37 Bn paid out for implementation of various activities in the LGs remained unaccounted at year-end as shown below \nTable 11: Entities with unsupported expenditure \nSn Entity \nAmount (UGX) Bn", "metadata": {"headings": [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}, {"headings_1": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}, [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}, {"headings_1": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}], [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}, {"headings_1": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}], [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}, {"headings_1": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}]], "page": 57, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "1. ABIM DLG \n1.41\n2. BUGWERI DLG \n0.25\n3. BUKEDEA DLG \n0.01\n4. Hoima MC \n0.06\n5. Kikuube DLG \n0.07\n6. Kiryandongo DLG \n0.01\n7. KOLE DLG \n0.26\n8. MADI-OKOLLO DLG \n0.05\n9. MOROTO DLG \n0.03\n10. MOROTO MC \n1.19\n11. OYAM DLG \n0.03\n12. Total 3.37", "metadata": {"headings": [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}, {"headings_1": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}], "page": 57, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "In the circumstances, it was not possible to confirm that the funds were used for the intended purposes. \nI advised the Accounting Officers to ensure that funds are either accounted for or else be recovered from the responsible officers.", "metadata": {"headings": [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}, {"headings_1": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}, [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}, {"headings_1": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}]], "page": 57, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.2.6.", "metadata": {"headings": [{"headings_0": {"content": "2.2.6.", "page": 57, "level": 2}}, {"headings_1": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}], "page": 57, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Irregular payment of Salary and Salary arrears to staff in Apac DLG \nI reviewed the payroll data (IPPS) and the IFMS payments of Apac District Local Government and noted that the district irregularly paid out UGX 0.57 Bn to 25 individuals and to the estate of the deceased staff as salary and salary arrears without any supporting documentation. The amounts were irregularly expended leading to the overstatement of salary expenditure. \nI observed that much as there were no payroll deductions made for Apac Municipal Council, Apac Sub County, Chegere Sub County, Ibuje Sub County and Akokoro Sub County, the district transferred a total UGX 0.06 Bn from the wage provisions to the same entities with no justification. \nAn interview with the Human Resource Officer revealed that these payments were not generated by the Human Resource Department. \nThe Accounting Officer explained that investigations were going on by CID", "metadata": {"headings": [{"headings_0": {"content": "2.2.6.", "page": 57, "level": 2}}, {"headings_1": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}, [{"headings_0": {"content": "2.2.6.", "page": 57, "level": 2}}, {"headings_1": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}], [{"headings_0": {"content": "2.2.6.", "page": 57, "level": 2}}, {"headings_1": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}], [{"headings_0": {"content": "2.2.6.", "page": 57, "level": 2}}, {"headings_1": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}], [{"headings_0": {"content": "2.2.6.", "page": 57, "level": 2}}, {"headings_1": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}]], "page": 57, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Headquarters.", "metadata": {"headings": [{"headings_0": {"content": "Headquarters.", "page": 57, "level": 2}}, {"headings_1": {"content": "2.2.6.", "page": 57, "level": 2}}], "page": 57, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "In the meantime, I have instituted a forensic audit on the matter. \n45", "metadata": {"headings": [{"headings_0": {"content": "Headquarters.", "page": 57, "level": 2}}, {"headings_1": {"content": "2.2.6.", "page": 57, "level": 2}}, [{"headings_0": {"content": "Headquarters.", "page": 57, "level": 2}}, {"headings_1": {"content": "2.2.6.", "page": 57, "level": 2}}]], "page": 57, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.2.7.", "metadata": {"headings": [{"headings_0": {"content": "2.2.7.", "page": 58, "level": 2}}, {"headings_1": {"content": "Headquarters.", "page": 57, "level": 2}}], "page": 58, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Failure to submit Financial Statements for consolidation \nSection 52(1)(b) of the Public Finance Management Act (PFMA), 2015 requires that the Accountant General shall within three months after the end of each financial year prepare and submit to the Minister and the Auditor General the consolidated annual accounts of the local governments. \nA review of the consolidated financial statements of Local Governments revealed that 3 District Local Governments and 6 Municipal Councils with a total actual expenditure of UGX 163.08 Bn were not submitted for consolidation by the respective Accounting Officers as shown table below: \nTable 12 un-consolidated local governments Sn \nSN Entity Category Approved/revised Budget(UGX) Bn Actual Expenditure (UGX) Bn \n1 Arua DLG 71.71 52.29 2 Butaleja DLG 31.68 29.84 3 Bududa DLG 25.82 24.61 4 Arua MC 23.50 21.85 5 Ntungamo MC 8.41 6.68 6 Mityana MC 8.38 8.10 7 Kumi MC 6.11 5.72 8 Ibanda MC 11.00 10.25 9 Nebbi MC 6.08 3.74 Total 192.69 163.08 Source: Consolidated financial statements and schedules \nThe Accountant General explained that without any justification, the above entities failed to submit the financial statements contrary section 51 of the PFMA, 2015. These accounts were therefore not quality checked for compliance", "metadata": {"headings": [{"headings_0": {"content": "2.2.7.", "page": 58, "level": 2}}, {"headings_1": {"content": "Headquarters.", "page": 57, "level": 2}}, [{"headings_0": {"content": "2.2.7.", "page": 58, "level": 2}}, {"headings_1": {"content": "Headquarters.", "page": 57, "level": 2}}], [{"headings_0": {"content": "2.2.7.", "page": 58, "level": 2}}, {"headings_1": {"content": "Headquarters.", "page": 57, "level": 2}}], [{"headings_0": {"content": "2.2.7.", "page": 58, "level": 2}}, {"headings_1": {"content": "Headquarters.", "page": 57, "level": 2}}], [{"headings_0": {"content": "2.2.7.", "page": 58, "level": 2}}, {"headings_1": {"content": "Headquarters.", "page": 57, "level": 2}}], [{"headings_0": {"content": "2.2.7.", "page": 58, "level": 2}}, {"headings_1": {"content": "Headquarters.", "page": 57, "level": 2}}]], "page": 58, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "by the Accountant General.", "metadata": {"headings": [{"headings_0": {"content": "by the Accountant General.", "page": 58, "level": 2}}, {"headings_1": {"content": "2.2.7.", "page": 58, "level": 2}}], "page": 58, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Failure to include all individual local government votes in the consolidated financial statements means that the consolidated balances of revenue, expenditure, assets and liabilities do not represent the actual Local Government consolidated position. \nI advised the Accountant General to identify and address the specific challenges that prevented the entities from submitting their Financial Statements for consolidation. \n46", "metadata": {"headings": [{"headings_0": {"content": "by the Accountant General.", "page": 58, "level": 2}}, {"headings_1": {"content": "2.2.7.", "page": 58, "level": 2}}, [{"headings_0": {"content": "by the Accountant General.", "page": 58, "level": 2}}, {"headings_1": {"content": "2.2.7.", "page": 58, "level": 2}}], [{"headings_0": {"content": "by the Accountant General.", "page": 58, "level": 2}}, {"headings_1": {"content": "2.2.7.", "page": 58, "level": 2}}]], "page": 58, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2.2.8.", "metadata": {"headings": [{"headings_0": {"content": "2.2.8.", "page": 59, "level": 2}}, {"headings_1": {"content": "by the Accountant General.", "page": 58, "level": 2}}], "page": 59, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Implementation of UgIFT project activities", "metadata": {"headings": [{"headings_0": {"content": "2.2.8.", "page": 59, "level": 2}}, {"headings_1": {"content": "by the Accountant General.", "page": 58, "level": 2}}], "page": 59, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "a)", "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}], "page": 59, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Status of completion of projects \nI undertook audit inspections of civil works in 24 Seed Schools and 41 Health Centre IIs located in a sample of 62 Districts and Municipal Councils and noted that 53 projects (80%) had not been completed, 11 projects (17%) had been completed while 01 project (2%) was not implemented. Notably, Amolatar, Oyam, Luwero, Sironko, Kamwenge and Kanungu Districts completed the construction of the seed schools and Health Centres. \nThe inspection results are summarised in the table below; Table 13: Status of implementation of UgIFT projects", "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}, [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}]], "page": 59, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN.", "Sector", "Status of", "No. of", "%age", "Commencement period"], ["", null, "implementation", "projects", "Status", null], ["1", "Education", "Completed", "2", "8.3%", "Previous financial year(s)"], ["Completed and handed over 1 4.2% Previous financial year(s) Incomplete 20 83.3% Previous financial year(s) 1 4.2% 2020/2021 Subtotal 24 100%", null, null, null, null, null], ["2 Health Completed 3 7.3% Previous financial year(s) 3 7.3% 2020/2021 Completed and handed over 1 2.4% Previous financial year(s) 1 2.4% 2020/2021 Incomplete 19 46 % Previous financial year(s) 13 32% 2020/2021 Not implemented 1 2.4% Not started Subtotal 41 100%", null, null, null, null, null], ["Grand Total 65", null, null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}], "page": 59, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5"], "type": "table"}}, {"content": "Source: OAG analysis \nI further noted that out of the 53 incomplete projects, 36projects had exceeded their planned completion dates by an average of 11 months. \nThe Accounting Officers attributed the delays in project completion to; \na) The Covid-19 lockdown measures which limited the movement of materials and labour, \nb) The contractors abandoning the sites, \nc) Funds not being re-voted to the entities in time, \nd) Delayed hybrid procurements, \ne) Late release of funds, \nf) Poor terrain leading to impassable roads to some projects sites, \ng) Low capacity of the contractor in terms of manpower, machinery, and multiple projects. \nConsequently, the projects planned to be completed within the year were not completed, and as such the intended beneficiaries were denied services. \nI advised the Accounting Officers to liaise with the sector Ministries to ensure that the implementation bottlenecks identified above are addressed. \n47 \nb) Land Ownership \nThe Circular issued by the MoFPED in May 2018 requested all Local Governments to ensure that all Government projects are constructed on land with proof of ownership or a Memorandum of Understanding (MOU) with landowners; \nI observed 4 projects that did not have titles or MOUs for the land on which the seed schools and health centers were constructed as shown in the table below: \nTable 14: UgIFT projects without land titles", "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}, [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}]], "page": 59, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN", "District/", "Name of", "Contract price", "Amount spent", "Status"], ["", "Municipal", "project", "(UGX) Bn", "(UGX) Bn", null], [null, "Council", null, null, null, null], ["1", "Kamwenge", "Construction", "2.02", "1.92", "Completed"], ["", "DLG", "of Bwizi Seed", null, null, "and handed"], [null, "", "school", null, null, "over"], ["2 Mityana DLG Upgrade of Busunjju HC II to HC III 0.66 Incomplete", null, null, null, null, null], ["3", "Kyotera", "Upgrade of", "0.66", "0.28", "Incomplete"], ["", "DLG", "Nyangoma HC", null, null, null], [null, "", "II to HC III", null, null, null], ["4 Moroto DLG Construction of Rupa Seed secondary school 1.94 1.70 Incomplete", null, null, null, null, null], ["Total", null, null, "5.28", "3.90", ""]], "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}], "page": 60, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["SN.", "Sector", "Status of", "No. of", "%age", "Commencement period"], "type": "table"}}, {"content": "Source: OAG analysis \nLack of land titles exposes the projects to disputes. \nI advised the Accounting Officers to acquire land titles or MoUs for all the UgIFT projects.", "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}, [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, {"headings_1": {"content": "2.2.8.", "page": 59, "level": 2}}]], "page": 60, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "c)", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 60, "level": 3}}, {"headings_1": {"content": "a)", "page": 59, "level": 3}}], "page": 60, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Procurement of ICT equipment, Laboratory kits, and chemical reagents \nThe guidance on procurement of ICT equipment, science kits, and chemical reagents for seed schools by the Ministry of Education and Sports to all Accounting Officers on 28th August 2020 referenced EPD 192/335/01; which required the procurement to be conducted after successful completion and handover of the facilities. \nI noted that ICT equipment, Science kits and chemicals were procured for seed schools that had not been completed. The equipment were instead being kept in inappropriate storage facilities exposing them to a risk of obsolescence. \nThe Accounting Officers pledged to engage the contractors to ensure that construction works on the laboratories are completed. \nI advised the Accounting Officers to ensure that procurements for the equipment are only effected when the construction works have been \n48 \ncompleted. I also urged the Accounting Officer to ensure that items are properly stored. \nOther Information \nThe Accounting Officer is responsible for the other information. The other information comprises the statement of responsibilities of the Accounting Officer; the commentaries by the Head of Accounts and the Accounting Officer; and other supplementary information. The other information does not include the financial statements and my", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 60, "level": 3}}, {"headings_1": {"content": "a)", "page": 59, "level": 3}}, [{"headings_0": {"content": "c)", "page": 60, "level": 3}}, {"headings_1": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "c)", "page": 60, "level": 3}}, {"headings_1": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "c)", "page": 60, "level": 3}}, {"headings_1": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "c)", "page": 60, "level": 3}}, {"headings_1": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "c)", "page": 60, "level": 3}}, {"headings_1": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "c)", "page": 60, "level": 3}}, {"headings_1": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "c)", "page": 60, "level": 3}}, {"headings_1": {"content": "a)", "page": 59, "level": 3}}]], "page": 60, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "auditors\u2019 report thereon. My opinion on the financial statements does not cover the", "metadata": {"headings": [{"headings_0": {"content": "auditors\u2019 report thereon. My opinion on the financial statements does not cover the", "page": 61, "level": 2}}, {"headings_1": {"content": "c)", "page": 60, "level": 3}}], "page": 61, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "other information and I do not express an audit opinion or any form of assurance conclusion thereon. \nIn connection with my audit of the financial statements, my responsibility is to read the other information and, in doing so, consider whether the other information is materially consistent with the financial statements or my knowledge obtained in the audit, or otherwise appears to be materially misstated. If, based on the work I have performed, I conclude that there is a material misstatement of this other information; I am required to report that fact. \nI have nothing to report in this regard. \nManagement Responsibilities for the Financial Statements \nUnder Article 164 of the Constitution of the Republic of Uganda, 1995 (as amended) and Section 45 of the Public Finance Management Act, 2015, the Accounting Officer is accountable to Parliament for the funds and resources of the local governments. \nThe Accounting Officer is also responsible for the preparation of financial statements in accordance with the requirements of the Public Finance Management Act, 2015 and for such internal control as management determines necessary to enable the preparation of financial statements that are free from material misstatement whether due to fraud or error. \nIn preparing the financial statements, the Accounting Officer is responsible for assessing the local government\u2019s ability to continue as a going concern, disclosing, as applicable, matters related to going concern and using the going concern basis of accounting, unless the Accounting Officer has a realistic alternative to the contrary. \nThe Accounting Officer is responsible for overseeing the local governments\u2019 financial reporting process.", "metadata": {"headings": [{"headings_0": {"content": "auditors\u2019 report thereon. My opinion on the financial statements does not cover the", "page": 61, "level": 2}}, {"headings_1": {"content": "c)", "page": 60, "level": 3}}, [{"headings_0": {"content": "auditors\u2019 report thereon. My opinion on the financial statements does not cover the", "page": 61, "level": 2}}, {"headings_1": {"content": "c)", "page": 60, "level": 3}}], [{"headings_0": {"content": "auditors\u2019 report thereon. My opinion on the financial statements does not cover the", "page": 61, "level": 2}}, {"headings_1": {"content": "c)", "page": 60, "level": 3}}], [{"headings_0": {"content": "auditors\u2019 report thereon. My opinion on the financial statements does not cover the", "page": 61, "level": 2}}, {"headings_1": {"content": "c)", "page": 60, "level": 3}}], [{"headings_0": {"content": "auditors\u2019 report thereon. My opinion on the financial statements does not cover the", "page": 61, "level": 2}}, {"headings_1": {"content": "c)", "page": 60, "level": 3}}], [{"headings_0": {"content": "auditors\u2019 report thereon. My opinion on the financial statements does not cover the", "page": 61, "level": 2}}, {"headings_1": {"content": "c)", "page": 60, "level": 3}}], [{"headings_0": {"content": "auditors\u2019 report thereon. My opinion on the financial statements does not cover the", "page": 61, "level": 2}}, {"headings_1": {"content": "c)", "page": 60, "level": 3}}]], "page": 61, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "page": 61, "level": 2}}, {"headings_1": {"content": "auditors\u2019 report thereon. My opinion on the financial statements does not cover the", "page": 61, "level": 2}}], "page": 61, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "My objectives are to obtain reasonable assurance about whether the financial statements as a whole are free from material misstatement, whether due to fraud or", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "page": 61, "level": 2}}, {"headings_1": {"content": "auditors\u2019 report thereon. My opinion on the financial statements does not cover the", "page": 61, "level": 2}}], "page": 61, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "metadata": {"headings": [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "page": 61, "level": 2}}], "page": 61, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "a high level of assurance but is not a guarantee that an audit conducted in accordance with ISSAIs will always detect a material misstatement, when it exists. Misstatements can arise from fraud or error and are considered material if, individually or in aggregate, they could reasonably be expected to influence the economic decisions of users, taken on the basis of these financial statements. \n49 \nAs part of an audit in accordance with ISSAIs, I exercise professional judgement and maintain professional scepticism throughout the audit. I also;", "metadata": {"headings": [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "page": 61, "level": 2}}, [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "page": 61, "level": 2}}], [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "page": 61, "level": 2}}]], "page": 61, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Identify and assess the risks of material misstatement of the financial statements, whether due to fraud or error, design and perform audit procedures responsive to those risks, and obtain audit evidence that is sufficient and appropriate to provide a basis for my opinion. The risk of not detecting a material misstatement resulting from fraud is higher than for one resulting from error, as fraud may involve collusion, forgery, intentional omissions, misrepresentations, or the override of internal control.", "metadata": {"headings": [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "page": 61, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "page": 61, "level": 2}}, [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "page": 61, "level": 2}}]], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Obtain an understanding of internal control relevant to the audit in order to design audit procedures that are appropriate in the circumstances, but not for the purpose of expressing an opinion on the effectiveness of the local governments\u2019 internal control.", "metadata": {"headings": [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "page": 61, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "page": 61, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Evaluate the appropriateness of accounting policies used and the reasonableness of accounting estimates and related disclosures made by the management.", "metadata": {"headings": [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}, {"headings_1": {"content": "Auditor\u2019s Responsibilities for the Audit of the Financial Statements", "page": 61, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}, {"headings_1": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "basis of accounting and, based on the audit evidence obtained, whether a material uncertainty exists related to events or conditions that may cast significant doubt on the local government\u2019s ability to continue as a going concern. If I conclude that a material uncertainty exists, I am required to draw attention in my auditor\u2019s report to the related disclosures in the financial statements or, if such disclosures are inadequate, to modify my opinion. My conclusions are based on the audit evidence obtained up to the date of my auditor\u2019s report. However, future events or conditions may cause the local government to cease to continue as a going concern.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}, {"headings_1": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Evaluate the overall presentation, structure and content of the financial statements, including the disclosures, and whether the financial statements represent the underlying transactions and events in a manner that achieves fair presentation.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}, {"headings_1": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nI communicate with the Accounting Officer regarding, among other matters, the planned scope and timing of the audit and significant audit findings, including any significant deficiencies in internal control that I identify during my audit. \nI also provide the Accounting Officer with a statement that I have complied with relevant ethical requirements regarding independence, and to communicate with them all relationships and other matters that may reasonably be thought to bear on my independence, and where applicable, related safeguards. \nFrom the matters communicated with the Accounting Officer, I determine those matters that were of most significance in the audit of the financial statements of the current period and are therefore the key audit matters. I describe these matters in my auditor\u2019s report unless law or regulation precludes public disclosure about the matter or when, in extremely rare circumstances, I determine that a matter should not be communicated in my report because the adverse consequences of doing so would reasonably be expected to outweigh the public interest benefits of such communication. \n50 \nOther Reporting Responsibilities \nIn accordance with Section 19 (1) of the National Audit Act, 2008, I report to you, based on my work described on the audit of Financial Statements, that; except for the matters raised in compliance with legislation section below, and whose effect has been considered in forming my opinion on the financial statements, the activities, financial transactions and information reflected in the financial statements that have come to my notice during the audit, are in all material respects, in compliance with the authorities which govern them.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}, {"headings_1": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}, [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}, {"headings_1": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}], [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}, {"headings_1": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}], [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}, {"headings_1": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}], [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}, {"headings_1": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}], [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}, {"headings_1": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}], [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}, {"headings_1": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}]], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Report on the Audit of Compliance with Legislation", "metadata": {"headings": [{"headings_0": {"content": "Report on the Audit of Compliance with Legislation", "page": 63, "level": 2}}, {"headings_1": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}], "page": 63, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "There were no material findings in respect of the compliance with legislation. \nJohn F.S. Muwanga AUDITOR GENERAL \n19 th December, 2021 \n51 \n2.3 \nREPORT OF THE AUDITOR GENERAL ON THE CONSOLIDATED SUMMARY STATEMENT OF FINANCIAL PERFORMANCE OF PUBLIC CORPORATIONS AND STATE ENTERPRISES FOR THE YEAR ENDED 30 TH JUNE 2021 \n2.3.1. Review of the Consolidated Summary Statement of Financial Performance of", "metadata": {"headings": [{"headings_0": {"content": "Report on the Audit of Compliance with Legislation", "page": 63, "level": 2}}, {"headings_1": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}, [{"headings_0": {"content": "Report on the Audit of Compliance with Legislation", "page": 63, "level": 2}}, {"headings_1": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}], [{"headings_0": {"content": "Report on the Audit of Compliance with Legislation", "page": 63, "level": 2}}, {"headings_1": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}], [{"headings_0": {"content": "Report on the Audit of Compliance with Legislation", "page": 63, "level": 2}}, {"headings_1": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}], [{"headings_0": {"content": "Report on the Audit of Compliance with Legislation", "page": 63, "level": 2}}, {"headings_1": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}], [{"headings_0": {"content": "Report on the Audit of Compliance with Legislation", "page": 63, "level": 2}}, {"headings_1": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}]], "page": 63, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Public Corporations and State Enterprises", "metadata": {"headings": [{"headings_0": {"content": "Public Corporations and State Enterprises", "page": 64, "level": 2}}, {"headings_1": {"content": "Report on the Audit of Compliance with Legislation", "page": 63, "level": 2}}], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "According to Section 3 of the Public Finance Management Act (PFMA), 2015 (as amended); \u201cA Public Corporation means an authority established by an Act of Parliament other than a local Government which receives a contribution from public funds, and any public body which in a financial year receives any income", "metadata": {"headings": [{"headings_0": {"content": "Public Corporations and State Enterprises", "page": 64, "level": 2}}, {"headings_1": {"content": "Report on the Audit of Compliance with Legislation", "page": 63, "level": 2}}], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "from public funds\u201d. Similarly, \u201cA State Enterprise means a body established", "metadata": {"headings": [{"headings_0": {"content": "from public funds\u201d. Similarly, \u201cA State Enterprise means a body established", "page": 64, "level": 2}}, {"headings_1": {"content": "Public Corporations and State Enterprises", "page": 64, "level": 2}}], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "under any Act other than the Company\u2019s Act or a local Government council, and", "metadata": {"headings": [{"headings_0": {"content": "under any Act other than the Company\u2019s Act or a local Government council, and", "page": 64, "level": 2}}, {"headings_1": {"content": "from public funds\u201d. Similarly, \u201cA State Enterprise means a body established", "page": 64, "level": 2}}], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "a company registered under the company\u2019s Act in which the Government or a", "metadata": {"headings": [{"headings_0": {"content": "a company registered under the company\u2019s Act in which the Government or a", "page": 64, "level": 2}}, {"headings_1": {"content": "under any Act other than the Company\u2019s Act or a local Government council, and", "page": 64, "level": 2}}], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "state enterprise has controlling interest\u201d.", "metadata": {"headings": [{"headings_0": {"content": "state enterprise has controlling interest\u201d.", "page": 64, "level": 2}}, {"headings_1": {"content": "a company registered under the company\u2019s Act in which the Government or a", "page": 64, "level": 2}}], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "In line with the PFMA, 2015, I reviewed the Consolidated Summary Statement of the Financial Performance of Public Corporations and State Enterprises for the year ended 30 th June 2021, and noted the following;", "metadata": {"headings": [{"headings_0": {"content": "state enterprise has controlling interest\u201d.", "page": 64, "level": 2}}, {"headings_1": {"content": "a company registered under the company\u2019s Act in which the Government or a", "page": 64, "level": 2}}], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "a)", "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 64, "level": 3}}, {"headings_1": {"content": "state enterprise has controlling interest\u201d.", "page": 64, "level": 2}}], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Completeness of the Consolidated Summary Statement of Performance", "metadata": {"headings": [{"headings_0": {"content": "Completeness of the Consolidated Summary Statement of Performance", "page": 64, "level": 2}}, {"headings_1": {"content": "a)", "page": 64, "level": 3}}], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Section 52 (1c) of the Public Finance Management Act (PFMA), 2015 requires the Accountant General, within three months after the end of each financial year, to prepare and submit to the Minister responsible for Finance and the Auditor General the consolidated summary statement of the financial performance of Public Corporations, State Enterprises and Companies where Government has controlling interest. \nI noted that 46 public corporations and state enterprises were supposed to be consolidated in accordance with Section 52 (1c) of the Public Finance Management Act (PFMA), 2015. However, I noted that seven (7) entities were not consolidated in the consolidated summary statement submitted by the Accountant General. \nFurthermore, Government shareholding in twelve (12) Public Corporations and State Enterprises was not disclosed in the consolidated summary statement of performance. This was caused by the absence of a comprehensive register of", "metadata": {"headings": [{"headings_0": {"content": "Completeness of the Consolidated Summary Statement of Performance", "page": 64, "level": 2}}, {"headings_1": {"content": "a)", "page": 64, "level": 3}}, [{"headings_0": {"content": "Completeness of the Consolidated Summary Statement of Performance", "page": 64, "level": 2}}, {"headings_1": {"content": "a)", "page": 64, "level": 3}}], [{"headings_0": {"content": "Completeness of the Consolidated Summary Statement of Performance", "page": 64, "level": 2}}, {"headings_1": {"content": "a)", "page": 64, "level": 3}}]], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Public Corporations and State Enterprises.", "metadata": {"headings": [{"headings_0": {"content": "Public Corporations and State Enterprises.", "page": 64, "level": 2}}, {"headings_1": {"content": "Completeness of the Consolidated Summary Statement of Performance", "page": 64, "level": 2}}], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "In the absence of a complete register of all consolidating public corporations and state enterprises, I was not able to ascertain the completeness of the submitted consolidated summary statement of financial performance of public corporation and state enterprises. \nI advised the Accountant General to establish a comprehensive register of all Public Corporations and State Enterprises with detailed information required for consolidation.", "metadata": {"headings": [{"headings_0": {"content": "Public Corporations and State Enterprises.", "page": 64, "level": 2}}, {"headings_1": {"content": "Completeness of the Consolidated Summary Statement of Performance", "page": 64, "level": 2}}, [{"headings_0": {"content": "Public Corporations and State Enterprises.", "page": 64, "level": 2}}, {"headings_1": {"content": "Completeness of the Consolidated Summary Statement of Performance", "page": 64, "level": 2}}]], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "b)", "metadata": {"headings": [{"headings_0": {"content": "b)", "page": 64, "level": 3}}, {"headings_1": {"content": "Public Corporations and State Enterprises.", "page": 64, "level": 2}}], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Failure to submit financial statements for consolidation \n52 \nSection 51(2) of PFMA, 2015 provides that, the Accounting Officer of a public corporation shall, within two months after the end of each financial year, using the format prescribed by the Accountant-General, prepare and submit to the AccountantGeneral, a summary statement of financial performance of the public corporation and give a copy of the summary statement to the Secretary to the", "metadata": {"headings": [{"headings_0": {"content": "b)", "page": 64, "level": 3}}, {"headings_1": {"content": "Public Corporations and State Enterprises.", "page": 64, "level": 2}}, [{"headings_0": {"content": "b)", "page": 64, "level": 3}}, {"headings_1": {"content": "Public Corporations and State Enterprises.", "page": 64, "level": 2}}], [{"headings_0": {"content": "b)", "page": 64, "level": 3}}, {"headings_1": {"content": "Public Corporations and State Enterprises.", "page": 64, "level": 2}}]], "page": 64, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Treasury.", "metadata": {"headings": [{"headings_0": {"content": "Treasury.", "page": 65, "level": 2}}, {"headings_1": {"content": "b)", "page": 64, "level": 3}}], "page": 65, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "A review of the consolidated summary statement of performance of Public Corporations and State Enterprises revealed that two (2) entities did not submit performance returns to the Accountant General for consolidation as indicated in the table 15 below; \nTable 15: Entities not Consolidated, but Disclosed in summary statement", "metadata": {"headings": [{"headings_0": {"content": "Treasury.", "page": 65, "level": 2}}, {"headings_1": {"content": "b)", "page": 64, "level": 3}}, [{"headings_0": {"content": "Treasury.", "page": 65, "level": 2}}, {"headings_1": {"content": "b)", "page": 64, "level": 3}}]], "page": 65, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["S/N", "Enterprise", "Government Holding"], ["1.", "Uganda Air Cargo Corporation", "Not ascertained"], ["2\\. Uganda Refinery Holding Co Not ascertained", null, null]], "metadata": {"headings": [{"headings_0": {"content": "Treasury.", "page": 65, "level": 2}}, {"headings_1": {"content": "b)", "page": 64, "level": 3}}], "page": 65, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "c)", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}], "page": 65, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Missing Entities in the consolidated summary statement \nSection 52(1) c of PFMA 2015 as amended requires the Accountant General within three months after the end of each financial year to prepare and submit to the Minister and the Auditor General a consolidated summary statement of the financial performance of public corporations and state enterprises and Companies where Government has a controlling interest. \nI noted that three (3) entities were neither reported nor disclosed in the consolidated summary statement of performance. (Table 16 below refers). \nTable 16: Entities neither reported nor Disclosed in the consolidated summary statement", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}, [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}]], "page": 65, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["S/N", "Enterprise", "Remarks"], ["1", "Uganda National Oil Company Limited", "Not reported in the previous year"], ["2 Nakivubo War Memorial Stadium Not reported in the previous year", null, null], ["3", "Uganda Crane Industries Ltd.", "Not reported in the previous year"]], "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}], "page": 65, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "This implies that the consolidated summary statement of financial performance of public corporations and state enterprises does not reflect the accurate status of government ownership and interest and as such I was unable to assess and conclude on their performance. \nI advised the Accountant General to issue comprehensive guidelines in respect of all Public Corporations and state Enterprises to be consolidated to enable assessment of financial performance. \n53 \n2.4.1 Review of Financial Performance of Public Corporations and State Enterprises \nThe Government of Uganda (GoU) owns shares in a number of Public Corporations and State Enterprises. These enterprises, which are independently managed, are supposed to operate efficiently, make profits and pay dividends to Government. Their financial performance is therefore of interest to Government. \nAs noted in my previous reports, the Government Consolidated Summary Statement of financial performance of public corporations and State enterprises only reports on; government shareholding, total income, total expenditure, dividends declared, retained earnings, and net worth of entities. However, key performance assessment parameters, such as; profitability, return on assets, liquidity assessment, long-term debt, and interest cover are not reported on. As a result, I computed these ratios using audited financial statements for further analysis of performance of Public Corporations and State Enterprises, where applicable. \nOut of the 46 Public Corporations and State Enterprises, seven (7) entities were not assessed because they had not submitted audited accounts at the time of writing my report. Table 17 below refers; \nTable 17: Entities not assessed", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}, [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}]], "page": 65, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["S/N", "Entity", "Government Stake"], ["1.", "Uganda National Oil Company Limited", "100%"], ["2\\. Nakivubo War Memorial Stadium 100%", null, null], ["3.", "National Housing and Construction Company Limited", "51%"], ["4\\. Uganda Telecom Limited Not known", null, null], ["5.", "The Micro Finance Support Centre Ltd", "100%"], ["6\\. Uganda Seeds Limited 100%", null, null], ["7.", "Uganda Livestock Industry", "100%"]], "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}], "page": 66, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["S/N", "Enterprise", "Remarks"], "type": "table"}}, {"content": "From the financial performance analysis undertaken, I noted the following;", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, {"headings_1": {"content": "Treasury.", "page": 65, "level": 2}}], "page": 66, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "a) Profitability of Enterprises", "metadata": {"headings": [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}, {"headings_1": {"content": "c)", "page": 65, "level": 3}}], "page": 66, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I noted that thirteen (13) out of the twenty-six (26) Public Corporation and State Enterprises analysed made profits/surplus in the year under review, with Uganda Electricity Transmission Company Limited (UETCL), Uganda Electricity Generation Company (UEGCL) and National Water and Sewerage Corporation (NWSC) posting profits of UGX 112Bn, UGX 91.9Bn and UGX 47.8Bn, respectively. Table 18 below refers. \n54 \nTable 18: Profitability of Public Corporation and State Enterprises", "metadata": {"headings": [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}, {"headings_1": {"content": "c)", "page": 65, "level": 3}}, [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}, {"headings_1": {"content": "c)", "page": 65, "level": 3}}], [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}, {"headings_1": {"content": "c)", "page": 65, "level": 3}}]], "page": 66, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["No", "Entity", "Profit After Tax / Surplus", null, "Increase/"], ["", null, "for the year (UGX", null, "Decrease"], [null, null, "in Bn)", null, null], [null, null, "2020/21", "2019/20", ""], ["1\\. Uganda Electricity Transmission Company Limited (UETCL) 112.00 54.02 57.97", null, null, null, null], ["2.", "Uganda Electricity Generation Company", "91.93", "2.80", "89.14"], ["", "(UEGCL)", null, null, null], ["3\\. National Water and Sewerage Corporation (NWSC) 47.79 27.44 20.35", null, null, null, null], ["4.", "Kira Motors Corporation", "26.09", "", "26.10"], ["5\\. Uganda Development Bank Limited 22.11 10.14 11.97", null, null, null, null], ["6.", "Housing Finance Bank Limited", "20.69", "22.50", "(1.80)"], ["7\\. Pride Micro Finance (Dec 2020) 12.69 12.79 (0.98)", null, null, null, null], ["8.", "Post Bank Uganda Limited (Dec 2020)", "10.07", "8.38", "1.69"], ["9\\. Uganda Printing and Publishing Corporation 6.25 4.22 2.033", null, null, null, null], ["10.", "NEC Luwero", "3.68", "3.38", "0.30"], ["11\\. Insurance Training college 2.42 0.015 2.42", null, null, null, null], ["12.", "Uganda Wildlife Conservation education", "1.44", "1.74", "(0.30)"], ["", "Centre", null, null, null], ["13\\. Mandela National Stadium 1.08 (0.23) 1.38", null, null, null, null], ["14.", "Uganda Property Holdings Limited", "0.85", "", "0.85"], ["15\\. Uganda Development Corporation (Group) 0.63 (7.32) 7.95", null, null, null, null], ["16.", "NEC UZIMA", "0.15", "0.26", "(0.12)"], ["17\\. Nile Hotel International Limited 0.08 1.24 (1.16)", null, null, null, null], ["18.", "Uganda Energy Credit Capitalization Co.", "(0.87)", "(0.59)", "(0.28)"], ["", "Ltd", null, null, null], ["19\\. Kilembe Mines Limited (0.91) (2.81) (1.10)", null, null, null, null], ["20.", "New Vision Printing and Publishing", "(7.11)", "2.66", "(9.76)"], ["", "Company Limited", null, null, null], ["21\\. Uganda Electricity Distribution Company Limited (UEDCL) (10.90) (10.12) (0.78)", null, null, null, null], ["22.", "Uganda Broadcasting Corporation", "(19.32)", "(7.62)", "(11.71)"], ["23\\. Uganda Civil Aviation Authority (UCAA) (27.50) (13.74) (13.78)", null, null, null, null], ["24.", "Uganda Railways Corporation", "(37.78)", "(61.39)", "23.60"], ["25\\. Uganda Wildlife Authority (UWA) (45.05) 5.54 (50.59)", null, null, null, null], ["26.", "Uganda National Airlines Company Limited", "(164.60)", "(102.45)", "(62.12)"]], "metadata": {"headings": [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}, {"headings_1": {"content": "c)", "page": 65, "level": 3}}], "page": 67, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "The general performance of some of the Public Corporations and State enterprises slightly improved compared to the previous year with companies such as Uganda Electricity Transmission Company Limited (UETCL), Uganda Electricity Generation Company (UEGCL) and National Water and Sewerage Corporation (NWSC) posting more than double the profits of the previous year. This was mainly attributed to government efforts to ease several COVID-19 restrictions, allowing certain businesses to reopen and government intervention of revamping the economy. \nI further noted that entities including Uganda Railways Corporation, Kilembe Mines Limited, Uganda Civil Aviation Authority (UCAA) and Uganda National Airlines Company Limited made losses as at the end of the financial year. However, it should be noted that this is the second year of operation of Uganda National Airlines in a highly competitive industry. \n55 \nI advised the entities to develop clear strategies to improve operations and adopt efficient financial management practices to lower operating costs and increase revenue generation. Government should also consider recapitalizing the most affected entities to revamp their operations.", "metadata": {"headings": [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}, {"headings_1": {"content": "c)", "page": 65, "level": 3}}, [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}, {"headings_1": {"content": "c)", "page": 65, "level": 3}}], [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}, {"headings_1": {"content": "c)", "page": 65, "level": 3}}], [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}, {"headings_1": {"content": "c)", "page": 65, "level": 3}}]], "page": 67, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "b) Return on Assets", "metadata": {"headings": [{"headings_0": {"content": "b) Return on Assets", "page": 68, "level": 2}}, {"headings_1": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}], "page": 68, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "metadata": {"headings": [{"headings_0": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}, {"headings_1": {"content": "b) Return on Assets", "page": 68, "level": 2}}], "page": 68, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "initial investments will generally have lower return on assets, ROAs below 5% are generally considered inadequate. \nApart from eleven (11) companies, which include; Uganda Wildlife Conservation education Centre, Uganda Electricity Transmission Company Limited, Kira Motors", "metadata": {"headings": [{"headings_0": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}, {"headings_1": {"content": "b) Return on Assets", "page": 68, "level": 2}}, [{"headings_0": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}, {"headings_1": {"content": "b) Return on Assets", "page": 68, "level": 2}}]], "page": 68, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "metadata": {"headings": [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, {"headings_1": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}], "page": 68, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "College, NEC Constructions Construction Works and Engineering Limited, NEC Uzima, NEC Luwero, Insurance Regulatory Authority of Uganda and National Drug Authority which posted a favourable ROA, the rest of the entities where the ratio is applicable, registered a poor performance on ROA of below 5%. \nTable 19: Returns on Assets", "metadata": {"headings": [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, {"headings_1": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}, [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, {"headings_1": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}]], "page": 68, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["No.", "Entity", "Return on Asset (%)", null], [null, null, "2019/20", "2020/21"], ["1\\. Uganda Wildlife Conservation education Centre 49.9 48.1", null, null, null], ["2.", "Kira Motors Corporation", "41", "43"], ["3\\. NEC Constructions Construction Works and Engineering Limited 10.8 31", null, null, null], ["4.", "Uganda Electricity Transmission Company Limited", "26.2", "26.4"], ["5\\. Uganda Printing and Publishing Corporation 2.16 22.06", null, null, null], ["6.", "NEC UZIMA", "6.3", "12.1"], ["7\\. NEC Luwero 12.5 10", null, null, null], ["8.", "Pride Micro Finance (Dec 2020)", "4", "3.3"], ["9\\. Uganda Development Bank Limited 3.16 2.91", null, null, null], ["10.", "Housing Finance Bank Limited", "2.9", "2.5"], ["11\\. Post Bank Uganda Limited (Dec 2020) 2.57 2.25", null, null, null], ["12.", "Uganda Development Corporation (Group)", "-405.4", "1.8"], ["13\\. Uganda Post Limited 1 1", null, null, null], ["14.", "Uganda Electricity Generation Company", "0.69", "0.79"], ["15\\. Mandela National Stadium -0.16 0.6", null, null, null], ["16.", "Uganda Property Holdings Limited", "0.4", "0.33"], ["17\\. National Water and Sewerage Corporation 1.45 0.26", null, null, null], ["18.", "Nile Hotel International Limited", "0.67", "0.04"], ["19\\. New Vision Printing and Publishing Company Limited 5.28 -0.4", null, null, null], ["20.", "Uganda Electricity Distribution Company Limited", "-0.56", "-0.56"], ["21\\. Uganda Railways Corporation -1.66 -1.03", null, null, null], ["22.", "Uganda Civil Aviation Authority", "0.48", "-2.4"]], "metadata": {"headings": [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, {"headings_1": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}], "page": 68, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "56", "metadata": {"headings": [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, {"headings_1": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}], "page": 68, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["23\\. Uganda Broadcasting Corporation -2.5 -5.88", null, null, null], ["24.", "Kilembe Mines Limited", "-6.72", "-10"], ["25\\. Uganda National Airlines Company Limited -12.2 -13.1", null, null, null], ["26.", "Uganda Wildlife authority", "6.84", "-21.75"], ["27\\. Soroti Fruits Limited -1513 -1590.2", null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, {"headings_1": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}], "page": 69, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["No.", "Entity", "Return on Asset (%)", "None"], "type": "table"}}, {"content": "c) Dividends \nI noted that, only Uganda Property Holdings Limited and Housing Finance Bank Limited proposed a dividend pay-out of, UGX 400,000,000 and UGX 1,495,222,000, respectively, in the year under review, Nile Hotel International Limited, Uganda Development Corporation (Group) and Housing Finance Bank Limited paid out dividends declared for the previous year totalling UGX.", "metadata": {"headings": [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, {"headings_1": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}, [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, {"headings_1": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}]], "page": 69, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2,269,944,381.", "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], "page": 69, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I further noted that although some companies were making significant amount of profits, they were not paying dividends to Government. \nThe enterprises attributed the non-payment of dividends to the loss-making positions and retention of funds to fund planned investments/projects. \nI advised the Accountant General to ensure that profit making enterprises provide a share of government dividend. \nd) Liquidity Assessment \nI analysed the ability of Public Corporations and State enterprises to meet their short-term financial obligations by comparing the current assets and current liabilities using the Current Ratio analysis. Generally, the ratio of Current Assets to Current Liabilities between 1.5 and 2 is desirable, although acceptable current ratios vary between different industries or sectors. \nI noted that eighteen (18) entities were above the ideal threshold, implying that they are able to meet their liabilities as they fall due. three (3) entities had ratios below 1.0 and may have a challenge of paying their obligations as and when they fall due. The table 20 below refers. \nTable 20: Enterprise Liquidity", "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}]], "page": 69, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "Current Ratio", null], ["No", "Entity", "2020/21 26.24", "2019/20 9.9"], ["1\\. Nile Hotel International Limited 26.24 9.9", null, null, null], ["2.", "Soroti Fruits Limited", "25.7", "122.38"], ["3\\. NEC Luwero 11.9 5.1", null, null, null], ["4.", "NEC AGRO", "11.4", "2.7"], ["5\\. Uganda Development Corporation (Group) 9.3 4.3", null, null, null], ["6.", "Uganda Electricity Distribution Company Limited", "6.9", "7.4"]], "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], "page": 69, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "57", "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], "page": 69, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["7\\. Uganda Property Holding 3.9 2.5", null, null, null], ["8.", "Uganda National Airlines Company Limited", "2.7", "6.2"], ["9\\. Uganda Printing and Publishing Corporation 2.64 1.77", null, null, null], ["10.", "New Vision Printing and Publishing Company Limited", "2.6", "2.68"], ["11\\. Uganda Railways Corporation 2.6 3.09", null, null, null], ["12.", "NEC UZIMA", "2.3", "0.8"], ["13\\. Uganda Electricity Transmission Company Limited 1.9 1.66", null, null, null], ["14.", "NEC Constructions Construction Works and", "1.4", "1.3"], ["", "Engineering Limited", null, null], ["15\\. National Water and Sewerage Corporation 1.37 1.18", null, null, null], ["16.", "Uganda Wildlife Conservation education Centre", "1.3", "1.12"], ["17\\. Uganda Post Limited 1.1 1.2", null, null, null], ["18.", "Uganda Wildlife authority", "1.09", "1.93"], ["19\\. Mandela National Stadium 0.73 0.49", null, null, null], ["20.", "Kilembe Mines Limited", "0.56", "1.3"], ["21\\. Uganda Electricity Generation Company 0.43 0.53", null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], "page": 70, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "", "Current Ratio", "None"], "type": "table"}}, {"content": "In addition, I noted that the customer deposits in the four banking institutions grew to an average of UGX.344Bn up from UGX.264 Bn in the prior year. Relatedly, the loan to deposit ratio averaged to 66% up from 64% which is still desirable at individual bank rating. The Table 21 below refers; \nTable 21: Liquidity assessment for financial institutions", "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}]], "page": 70, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Institution", "Liquidity assessment for banking institutions", null, null, null, null, null, null, null], ["SN 1.", "Bank", "Current ratio", null, "CustomerDeposits/loan", null, "Net liquid assets", null, "Loan to deposit", null], [null, "N Housing 1 Finance Bank 1.45 1.44", null, null, "s", null, null, null, null, null], [null, null, null, null, "654.1 559.8 35% 31% 84.10% 98%", null, null, null, null, null], ["2.", "Pride 2 Micro", "1.62", "1.56", "174.37", "140.82", "0", "0", "105%", "80%"], [null, "Finance", null, null, null, null, null, null, null, null], [null, "", null, null, null, null, null, null, null, null], ["3\\. Post 3 Bank 1.11 1.13 0 0 0 0 74.50% 77%", null, null, null, null, null, null, null, null, null], ["4.", "Uganda 4", "6.3", "4.42", "547", "354", "0", "0", "0", "0"], [null, "Development", null, null, null, null, null, null, null, null], [null, "Bank", null, null, null, null, null, null, null, null], ["Total 10 9 1375 1055 35% 31% 264% 255%", null, null, null, null, null, null, null, null, null], ["", "Average", "3", "2", "344", "264", "9%", "8%", "66%", "64%"]], "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], "page": 70, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5", "column_6", "column_7", "column_8", "column_9"], "type": "table"}}, {"content": "I further noted that despite the low activity during the COVID-19 period, Loans and advances to customers increased on average from UGX.336Bn to UGX.405Bn in the current year. \n58 \nTable 22 : Loans and Advances performance", "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}]], "page": 70, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN Bank Prior period (UGX- Billions) Current period (UGX-Billions)", null, null, null], ["1", "Housing finance bank", "550.60", "553.50"], ["2 Pride Micro Finance 171.76 183.39", null, null, null], ["3", "Postbank", "267.00", "334.70"], ["4 Uganda Development Bank 354.00 547.00", null, null, null], ["", "Average", "335.84", "404.65"]], "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], "page": 71, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "The performance of the 4 institutions was commendable. e) Interest cover \nI analysed the interest cover of Public Corporations and State enterprises that had taken loans to establish their ability to service the loans through payment of interest. Interest cover looks at how many times a Company\u2019s operating profits exceed its interest payable. A cover of two (2) times and above is usually considered to be safe, depending on the nature of industry. The implication is that a company is most likely to meet its interest payments. \nI noted that of the 3 companies/enterprises which were financing loans, two (2) (NWSC and the Insurance Training College) were better placed to meet their interest obligations, while the New Vision Printing and Publishing Company Limited was not. The Table 23 below refers. \nTable 23 : Enterprises' ability to service loan obligations", "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}]], "page": 71, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["No. Entity Profit Before Interest Interest (Financing cost) Interest Cover (No. of times) (2020/21 Interest Cover (No. of times) (2019/20", null, null, null, null, null], ["1", "National Water and", "18.68", "6.95", "2.7", "28.3"], ["", "Sewerage", null, null, null, null], [null, "Corporation", null, null, null, null], ["2 New Vision Printing and Publishing Company Limited (0.34) 0.59 -0.6 28.2", null, null, null, null, null], ["3", "Insurance Training", "2.42", "1.06", "2.30", "0.001"], ["", "college", null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], "page": 71, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5"], "type": "table"}}, {"content": "Overall Conclusion/Recommendation \nWhereas government policy to invest in critical sectors of the economy is commendable, it is important to ensure that such investments are operating efficiently and effectively to meet sector objectives. There is need for government to strengthen the supervision and monitoring of these entities. \nAlthough government efforts to ease several COVID-19 restrictions, allowing certain businesses to reopen improved performance of certain enterprises, the COVID 19 pandemic affected operations of a number of entities, and Government needs to assess its impact on the critical enterprises and corporations and provide the necessary guidance and assistance. \n59 \nPART 3: SECTORAL AND LOCAL GOVERNMENTS CROSS CUTTING FINDINGS \nThis part contains cross cutting key findings noted in the respective sectors and cross cutting service delivery issues in Local Governments.", "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, {"headings_1": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}]], "page": 71, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.0. Sectoral Key Findings 3.1. PUBLIC SECTOR MANAGEMENT", "metadata": {"headings": [{"headings_0": {"content": "3.0. Sectoral Key Findings 3.1. PUBLIC SECTOR MANAGEMENT", "page": 72, "level": 4}}, {"headings_1": {"content": "2,269,944,381.", "page": 69, "level": 2}}], "page": 72, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "3.1.1. Government readiness to implement the programmatic approach \nGovernment with effect from 1 st July 2020 started the implementation of NDP III as a successor plan to the NDP II. The overall objective of the NDP III is to increase household income and improving the quality of life of Ugandans. This plan is implemented using the programme approach to planning, budgeting, implementation and results reporting. This programme was also designed to address challenges faced in implementation of prior national development programmes which included uncoordinated planning, weak harmonization, limited sequencing of programmes, and poor linkages between outcomes and outputs. \nI reviewed the readiness of government to effectively implement the NDP III in order to achieve the desired outcomes. From the procedures undertaken, I noted that significant strides have been made towards effective implementation of the plan. \nAreas of commendable performance include; provision of guidelines to entities to facilitate transitioning to programme approach, development of the Programme Implementation Action Plans (PIAPs) for all programmes, development of strategic plans that are aligned to the NDP III by a number of entities in government, operationalization of Programme Working Groups (PWGs) to coordinate programme activities and development of guidelines for the programme working groups. \nDespite these achievements, there are a number of areas that need government attention if the NDP III overall objective is to be achieved. These include; \na) The shift from sector to programme planning and budgeting requires tracking progress towards attainment of results. This therefore implies that accountability and oversight processes should be re-aligned towards achievement of results as defined in the NDP III framework. This realignment has however not been fully attained.", "metadata": {"headings": [{"headings_0": {"content": "3.0. Sectoral Key Findings 3.1. PUBLIC SECTOR MANAGEMENT", "page": 72, "level": 4}}, {"headings_1": {"content": "2,269,944,381.", "page": 69, "level": 2}}, [{"headings_0": {"content": "3.0. Sectoral Key Findings 3.1. PUBLIC SECTOR MANAGEMENT", "page": 72, "level": 4}}, {"headings_1": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "3.0. Sectoral Key Findings 3.1. PUBLIC SECTOR MANAGEMENT", "page": 72, "level": 4}}, {"headings_1": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "3.0. Sectoral Key Findings 3.1. PUBLIC SECTOR MANAGEMENT", "page": 72, "level": 4}}, {"headings_1": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "3.0. Sectoral Key Findings 3.1. PUBLIC SECTOR MANAGEMENT", "page": 72, "level": 4}}, {"headings_1": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "3.0. Sectoral Key Findings 3.1. PUBLIC SECTOR MANAGEMENT", "page": 72, "level": 4}}, {"headings_1": {"content": "2,269,944,381.", "page": 69, "level": 2}}]], "page": 72, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "b)", "metadata": {"headings": [{"headings_0": {"content": "b)", "page": 72, "level": 2}}, {"headings_1": {"content": "3.0. Sectoral Key Findings 3.1. PUBLIC SECTOR MANAGEMENT", "page": 72, "level": 4}}], "page": 72, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The shift from sector to programme planning and budgeting also requires a shift of the current government statistical processes to processes that are capable of delivering outcome statistics as defined in the NDP III. The current data systems therefore have to be revised so that they produce results data rather than output data. In addition, surveys and production of key results statistics need to be aligned to the NDP III M&E processes to enable real time capture of data and monitoring of the achievement of programme results.", "metadata": {"headings": [{"headings_0": {"content": "b)", "page": 72, "level": 2}}, {"headings_1": {"content": "3.0. Sectoral Key Findings 3.1. PUBLIC SECTOR MANAGEMENT", "page": 72, "level": 4}}], "page": 72, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "c)", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], "page": 72, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The shift from sector to programme planning and budgeting also implies that government annual performance reporting will now be based on programmes rather than sectors. The challenge however is that a number of programme 60 working groups are still struggling to constitute themselves in order to do effective programme reporting which is likely to affect effective coordination and supervision of programme activities. d) The shift from sector to programme planning and budgeting also implies that budgets of MDAs and LGs are now developed and approved at programme level although appropriation and spending remain at vote level. However, a number of MDAs are grappling with understanding the new system. With 2 years into the implementation of NDP III, a number of MDAs and LGs have not fully transitioned their operations to the new programme based planning and budgeting and this is likely to affect the achievements of the NDP III objectives. Government should support the National Planning Authority in capacity building of MDAs and LGs staff such as planners, monitoring and evaluation officers among others to equip them with the necessary skills to track and evaluate the implementation of entity plans in line with the NDP III PIAPs. 3.1.2. Limited efforts to build the capacity of planning units within Government Section 7 (2) (d) provides that in pursuance of its primary planning functions, the Authority shall support local capacity development for national planning and, in particular, provide support and guidance to the national and local bodies responsible for the decentralized planning process. I have noted over the years that MDAs and Local Governments face significant challenges in planning, implementing, monitoring and reporting performance due to low capacity of their planning units. I however noted that although the mandate of the Authority provides for supporting the development of local capacity in planning, the Authority had not effectively executed this mandate. No trainings for planners had been undertaken by the Authority in the past three (3) years as a deliberate strategy to build planning capacity both at national and local levels. Failure to build planning capacity within the Government implies that there will be persistent challenges in the development, implementation, monitoring and reporting of performance in relation to the approved budgets, which affects service delivery and the credibility of the budgets both at entity and government-wide level. The Accounting Officer explained that the Authority developed a National Capacity Enhancement Project for strengthening planning", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}, [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}], [{"headings_0": {"content": "c)", "page": 72, "level": 2}}, {"headings_1": {"content": "b)", "page": 72, "level": 2}}]], "page": 72, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.2.1.", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Monitoring and Supervision of Government Programmes under Office of the President \nThe Office of the President is mandated to follow up implementation of government programmes across the Country. However, the Office has staffing as well as office accommodation challenges which has limited adequate monitoring and supervision of the implementation of the programmes. The Office has a staffing gap of 80 positions of Senior Presidential Advisors, Resident District Commissioners and Deputy Resident District Commissioners. \nIn addition to the staffing gap, the RDCs lack enough accommodation. During the year under review, the Office of the President had a deployment of 146 RDCs in Districts and 10 RCCs in newly created cities out of which 107 are renting and 24 lack offices. \nIn order to address the above challenge, the Office envisioned an idea of constructing at least 10 RDC offices per annum in a phased approach starting with FY 2008/09. This idea was not fulfilled because government could not fund the capital budget as anticipated. This has necessitated the Office of the President to revert to constructing only one RDC office per annum as the case is currently and renting office space for the rest. Under this approach, the Office will take 107 years to construct offices for all RDCs and spend approximately UGX.445Million on rent annually. \nI have advised Government to ensure that the RDCs and RCCs are recruited and also develop an action plan for construction of offices in a phased manner to minimise the high operation costs. \n3.3. AGRICULTURE SECTOR \n3.3.1. Mainstreaming of Agriculture Sector agencies \nGovernment is still in the process of rationalizing agencies and public expenditure (RAPEX) under the Agricultural Sector which include Cotton Development Organisation, Uganda Coffee Development Authority, Coordinating Office for Control of Trypanosomiasis and Diary Development Authority. These entities have had challenges of attracting staff to undertake activities. The respective Accounting Officers attributed this challenge to the following:", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}, [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}]], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Some successful candidates did not take up the job offers because the contract period was limited to only 18 months as recommended by Ministry of Public Service.", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Ministry of Public Service and Solicitor General guided that recruitment of staff for the agencies affected by rationalization should only be for a period up to June 2023.", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}, [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}]], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The employment contracts should contain a disclaimer clause to the effect that the employment can be terminated any time without recourse.", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- There is no guarantee of retention of the workforce.", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "The above situation has affected the agencies also in other areas of planning, execution of activities and implementation of the new NDP III strategic plans. \n62 \nI advised Government to fast-track implementation of the policy with a view of ensuring that the on-going rationalization activities are finalized in the shortest time possible to avoid further disruptions in the operations. \n3.3.2. Over dependence on the Public Private Partnership in the Cotton sector \nSection 5 (i) of the Cotton Development Organisation Act, vests the duty to facilitate cotton production, cotton research and extension through the Ministry responsible for", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}, [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}], [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, {"headings_1": {"content": "c)", "page": 72, "level": 2}}]], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "metadata": {"headings": [{"headings_0": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}, {"headings_1": {"content": "3.2.1.", "page": 74, "level": 2}}], "page": 75, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "processing of cotton and represent all aspects of the cotton subsector. \nOver the last 11 years, the Private Sector (Ginners) under their umbrella body Uganda Ginners and Cotton Exporters Association (UGCEA), have been supporting cotton production activities under the Cotton Production Support Program through a Memorandum of Understanding that is signed annually between CDO and UGCEA. The Program, using funds pooled voluntarily by UGCEA members into the Cotton Development Fund (CDF), supports a variety of activities which aim to assist cotton farmers in Uganda to increase cotton production and productivity through; provision of inputs, farmer mobilization and sensitization, extension services and agricultural mechanization. \nIt was noted that UGX.19.649Bn was budgeted to cater for the cotton marketing season 2020/21 out of which, UGX.15.154Bn was budgeted towards provision of planting seed and production inputs. Government was able to contribute only UGX.8.6Bn leaving the balance for the private partner intervention. This is an indication that government is relying more on the ginners to fund the cotton sector. \nDespite the intervention by the private sector, there were shortages in provision of inputs to farmers. From table below, 866 Mt of planting seed, 374.6 Mt of fertilizers and 2,260 spray pumps were not provided as projected in the strategic plan despite the support from the Ginners which directly affected the performance of the sector in achieving the desired cotton production targets.", "metadata": {"headings": [{"headings_0": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}, {"headings_1": {"content": "3.2.1.", "page": 74, "level": 2}}, [{"headings_0": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}, {"headings_1": {"content": "3.2.1.", "page": 74, "level": 2}}], [{"headings_0": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}, {"headings_1": {"content": "3.2.1.", "page": 74, "level": 2}}], [{"headings_0": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}, {"headings_1": {"content": "3.2.1.", "page": 74, "level": 2}}]], "page": 75, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "metadata": {"headings": [{"headings_0": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}, {"headings_1": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}], "page": 75, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["", "Planting", "Pesticides", "Fertilizers", "Spray", "Herbicides"], ["", "seed", null, null, "pumps", null], ["Production inputs needed(Strategic Plan) A 3,200 Mt 222,000 liters 415 Mt 7,000 0", null, null, null, null, null], ["Planned Quantities (MOU-", "2,500Mt", "224,000", "746 Mt", "3,000", "7,500 liters"], ["Ginners) B", null, "liters", null, null, null], ["Actual Quantities provided (Reports) C 2,334 Mt 287,102 liters 40.4 Mt 4,740 6,616 liters", null, null, null, null, null], ["Difference A - C", "866 Mt", "(65,102)", "374.6 Mt", "2,260", "(6,616)"], ["", null, null, null, null, "Liters"]], "metadata": {"headings": [{"headings_0": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}, {"headings_1": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}], "page": 75, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5"], "type": "table"}}, {"content": "Source: OAG analysis of CDO Strategic Plan 2020/21-20, MOU, quarterly reports \n63 \nDependency on the Private sector for a key production activity such as provision of seed for planting and production inputs, risks the sustainability of the sector and enables the private sector to exercise influence over farmers through paying of low prices for the", "metadata": {"headings": [{"headings_0": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}, {"headings_1": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}, [{"headings_0": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}, {"headings_1": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}], [{"headings_0": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}, {"headings_1": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}]], "page": 75, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "metadata": {"headings": [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}, {"headings_1": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}], "page": 76, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "key aspects such as targeted extension services for mobilizing farmers and training them on cotton agronomical practices using demonstration gardens established at village/parish level.", "metadata": {"headings": [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}, {"headings_1": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}], "page": 76, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Management explained that limited government has affected the cotton production in the past 2 years. There was a drop in cotton production from 173,457 bales of lint in FY 2019/20 to 50,709 bales in the year under review largely as a result of heavy rains, meagre funds for procurement and distribution of production inputs as well as provision of extension services. The calamity of drop in the cotton production was brought to the attention of both the Ministry of Agriculture, Animal Industry & Fisheries and the Ministry of Finance, Planning & Economic Development and a request for a supplementary budget of UGX.5 billion was made. \nI advised the Accounting officer to continue liaising with the line Ministry and MoFPED to forge a way forward for the sector. \n3.3.3. Management of Foot and Mouth Disease (FMD) Outbreaks in the Country \nIt is the Mandate of MAAIF to regulate and control the prevalence of FMD within the country. Accordingly, Government intervened by procuring FMD vaccines from Kenya Veterinary Vaccines Production Institute (KEVEVAPI) and Botswana Vaccines Institute (BVI) which were distributed to farmers across the country especially in the areas where FMD has been reported previously. \nIn June 2021, the country was informed of unprecedented outbreaks of FMD along the cattle corridor. A review of management of the outbreak revealed failure of timely interventions as a result of challenges faced in the procurement of vaccines despite the availability of funds. Furthermore, the following shortcomings were noted; \na) During the financial year 2019/2020, 700,000 doses of FMD were procured in November 2019, however, only 500,000 (70%) of the consignment was delivered and significantly late by 4 months. \nb) 2,311,000 doses were planned to be procured in 2019/2020 however the supplier failed to deliver despite emergency situation and sensitivity of the disease. \nc) Although the supplier later delivered 1,700,000 doses (52%) during the year 2020/2021, and 2021/2022 financial year, the balance of 611,000 doses (24%) were still outstanding at the time of writing this report. The deliveries have not been made even after several delivery extensions to the supplier. \nThe continued presence of the FMD and the inadequate response in terms of vaccine availability has denied Ugandans opportunities to export livestock and livestock products", "metadata": {"headings": [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}, {"headings_1": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}, [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}, {"headings_1": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}], [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}, {"headings_1": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}], [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}, {"headings_1": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}], [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}, {"headings_1": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}], [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}, {"headings_1": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}], [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}, {"headings_1": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}], [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}, {"headings_1": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}], [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}, {"headings_1": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}]], "page": 76, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "to the international market and significantly curtails the Ministry\u2019s ability to achieve its", "metadata": {"headings": [{"headings_0": {"content": "to the international market and significantly curtails the Ministry\u2019s ability to achieve its", "page": 76, "level": 2}}, {"headings_1": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}], "page": 76, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "mandate. \n64 \nI advised the Accounting Officer to effectively and efficiently monitor such disease outbreaks within the Country so as to curb the spread and prevent further loss to the Community. Further, research collaborations with NARO should be enhanced for development of a local intervention.", "metadata": {"headings": [{"headings_0": {"content": "to the international market and significantly curtails the Ministry\u2019s ability to achieve its", "page": 76, "level": 2}}, {"headings_1": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}, [{"headings_0": {"content": "to the international market and significantly curtails the Ministry\u2019s ability to achieve its", "page": 76, "level": 2}}, {"headings_1": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}], [{"headings_0": {"content": "to the international market and significantly curtails the Ministry\u2019s ability to achieve its", "page": 76, "level": 2}}, {"headings_1": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}]], "page": 76, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.4. JUSTICE LAW AND ORDER SECTOR", "metadata": {"headings": [{"headings_0": {"content": "3.4. JUSTICE LAW AND ORDER SECTOR", "page": 77, "level": 4}}, {"headings_1": {"content": "to the international market and significantly curtails the Ministry\u2019s ability to achieve its", "page": 76, "level": 2}}], "page": 77, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "3.4.1.", "metadata": {"headings": [{"headings_0": {"content": "3.4.1.", "page": 77, "level": 2}}, {"headings_1": {"content": "3.4. JUSTICE LAW AND ORDER SECTOR", "page": 77, "level": 4}}], "page": 77, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Management of cases and Case backlog \nVarious stakeholders in the Justice Law and Order Sector (JLOS) have implemented a number of management information systems as indicated in the table 25 below. \nTable 25 : Information Systems within the JLOS Sector", "metadata": {"headings": [{"headings_0": {"content": "3.4.1.", "page": 77, "level": 2}}, {"headings_1": {"content": "3.4. JUSTICE LAW AND ORDER SECTOR", "page": 77, "level": 4}}, [{"headings_0": {"content": "3.4.1.", "page": 77, "level": 2}}, {"headings_1": {"content": "3.4. JUSTICE LAW AND ORDER SECTOR", "page": 77, "level": 4}}], [{"headings_0": {"content": "3.4.1.", "page": 77, "level": 2}}, {"headings_1": {"content": "3.4. JUSTICE LAW AND ORDER SECTOR", "page": 77, "level": 4}}]], "page": 77, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN", "Information system", "Purpose", "Entity", "Cost (Bn)"], ["1", "Prosecution Case", "Record and collect information", "ODPP", "26.188"], ["", "Management", "pertaining to cases, and rapidly transfer", null, null], [null, "Information System", "case details from law enforcement", null, null], [null, "(PROCAMIS)", "across the DPP offices.", null, null], ["2 Court Case Administration System (CCAS) Receiving and allocating cases to different Judicial officers for further management. Judiciary No information", null, null, null, null], ["3", "The Electronic Court", "Manage case records, e-filing. The", "Judiciary", "9.277"], ["", "Case Management", "system tracks all aspects of a case life", null, null], [null, "Information System", "cycle from initial filing through", null, null], [null, "(ECCMIS)", "disposition up to appeal.", null, null], ["4 Prisoners Management Information System(PMIS) Recording and classifying of all prisoner related information across all the prisons. Prisons 0.501", null, null, null, null], ["5", "Crime Records", "Automate all paper based processes of", "Uganda", "0.5"], ["", "Management System", "case management.", "Police Force", null], [null, "(CRMS)", null, null, null], ["6 Suspect profiling systems Capture profiles of suspects such as bio data, photographs, and thumbprints among other features, to help in quick identification of suspects. Uganda Police Force No information", null, null, null, null], ["", "TOTAL", "", "", "36.466"]], "metadata": {"headings": [{"headings_0": {"content": "3.4.1.", "page": 77, "level": 2}}, {"headings_1": {"content": "3.4. JUSTICE LAW AND ORDER SECTOR", "page": 77, "level": 4}}], "page": 77, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "Institutions require quick access to accurate, and reliable information in order to function well and promote the objectives of equitable justice for all. In pursuance on the goals of criminal justice, various entities within the sector have acquired computerised information management systems to enable them attain their mandate. \nAlthough Government has invested a sum of UGX.36.46Bn in four of the systems for the administration of Justice across the JLOS sector, I noted that the systems are stand- alone and decentralized without being integrated to enable information sharing across the sector. \nThe lack of systems\u2019 integration inter-linking the various entities such as the Police, Directorate of Prosecution, Judiciary and Prisons implies that the transfer of case details between stakeholders for the quick resolution of cases in the pursuit of Justice cannot be achieved. The absence of shared or integrated management systems may also result in inefficient allocation of resources, higher costs of procurement for IT hardware, network equipment and application software as well as duplications in the nature of service support from the suppliers/vendors of the applications and the hardware. \n65 \nI also observed that the implementation or setup of some of the systems is still ongoing in various entities. For instance, the Crime Records Management System in Uganda", "metadata": {"headings": [{"headings_0": {"content": "3.4.1.", "page": 77, "level": 2}}, {"headings_1": {"content": "3.4. JUSTICE LAW AND ORDER SECTOR", "page": 77, "level": 4}}, [{"headings_0": {"content": "3.4.1.", "page": 77, "level": 2}}, {"headings_1": {"content": "3.4. JUSTICE LAW AND ORDER SECTOR", "page": 77, "level": 4}}], [{"headings_0": {"content": "3.4.1.", "page": 77, "level": 2}}, {"headings_1": {"content": "3.4. JUSTICE LAW AND ORDER SECTOR", "page": 77, "level": 4}}], [{"headings_0": {"content": "3.4.1.", "page": 77, "level": 2}}, {"headings_1": {"content": "3.4. JUSTICE LAW AND ORDER SECTOR", "page": 77, "level": 4}}], [{"headings_0": {"content": "3.4.1.", "page": 77, "level": 2}}, {"headings_1": {"content": "3.4. JUSTICE LAW AND ORDER SECTOR", "page": 77, "level": 4}}]], "page": 77, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "metadata": {"headings": [{"headings_0": {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "page": 78, "level": 2}}, {"headings_1": {"content": "3.4.1.", "page": 77, "level": 2}}], "page": 78, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Electronic Court Case Management Information System in Judiciary, the Suspect Profiling System in Uganda Police were still at the pilot testing stage or were yet to be fully rolled out and operationalised across all the regional offices countrywide. \nThis may have resulted in the non-optimal use of the information assets held on the systems. \nThe JLOS sector should review the existing systems and their functionality vis-\u00e0-vis the sector-wide needs with a view of achieving an integrated approach to information management within the sector, in order to avoid the duplication of data, delays in processing cases, and achieving efficiency in resource allocation across the sector so as to attain the goals of criminal justice administration.", "metadata": {"headings": [{"headings_0": {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "page": 78, "level": 2}}, {"headings_1": {"content": "3.4.1.", "page": 77, "level": 2}}, [{"headings_0": {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "page": 78, "level": 2}}, {"headings_1": {"content": "3.4.1.", "page": 77, "level": 2}}], [{"headings_0": {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "page": 78, "level": 2}}, {"headings_1": {"content": "3.4.1.", "page": 77, "level": 2}}]], "page": 78, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.4.2.", "metadata": {"headings": [{"headings_0": {"content": "3.4.2.", "page": 78, "level": 2}}, {"headings_1": {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "page": 78, "level": 2}}], "page": 78, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Operationalisation of the Joint Venture Agreement \nIn 2017 the Government of Uganda entered into a Joint Venture Agreement resulting in the formulation of the Uganda Securities Printing Company (USPC) for the exclusive production and supply of all security documents for the Government of Uganda, including National Identity Cards and Birth and Deaths Certificates. This venture had delayed to be operationalised and as a result a number of challenges were identified; \na) NIRA was expected to order a minimum of 4,500,000 national ID cards annually, starting with the financial year 2020/2021. However, no order was placed for the financial year under review due to lack of budget provisions for this activity. This is a breach of the contract agreement, which may result in the payment of fines for breach of contract. \nb) USPC was yet to supply IT systems and equipment to support the National ID system and the birth and death registration system. The system in use for Identification Information was supplied by M/S M\u00fchlbauer Uganda Limited, whose contract had expired and was not renewed. There is a risk that NIRA will operate without system support from the system vendor of the legacy (existing) system for an unspecified time. \nThe Accounting Officer explained that the Authority has been engaging USPC to resolve all the issues relating to the Joint Venture Agreement (JVA) and an Adhoc committee had been put in place comprising of all Permanent secretaries, including the Ministry of Internal Affairs, whose objective is to review the status of implementation of the JVA every quarter. \nI advised Government to design a clear road map and strategy to ensure compliance with the terms of the Joint Venture Agreement, including developing support systems to avoid the stalling of operations of the entity. \n66", "metadata": {"headings": [{"headings_0": {"content": "3.4.2.", "page": 78, "level": 2}}, {"headings_1": {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "page": 78, "level": 2}}, [{"headings_0": {"content": "3.4.2.", "page": 78, "level": 2}}, {"headings_1": {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "page": 78, "level": 2}}], [{"headings_0": {"content": "3.4.2.", "page": 78, "level": 2}}, {"headings_1": {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "page": 78, "level": 2}}], [{"headings_0": {"content": "3.4.2.", "page": 78, "level": 2}}, {"headings_1": {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "page": 78, "level": 2}}], [{"headings_0": {"content": "3.4.2.", "page": 78, "level": 2}}, {"headings_1": {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "page": 78, "level": 2}}], [{"headings_0": {"content": "3.4.2.", "page": 78, "level": 2}}, {"headings_1": {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "page": 78, "level": 2}}], [{"headings_0": {"content": "3.4.2.", "page": 78, "level": 2}}, {"headings_1": {"content": "Police, the Prisoner\u2019s Information Management System in the Uganda Prisons, the", "page": 78, "level": 2}}]], "page": 78, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.5. INFORMATION COMMUNICATION TECHNOLOGY SECTOR", "metadata": {"headings": [{"headings_0": {"content": "3.5. INFORMATION COMMUNICATION TECHNOLOGY SECTOR", "page": 79, "level": 2}}, {"headings_1": {"content": "3.4.2.", "page": 78, "level": 2}}], "page": 79, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "3.5.1. Absence of a National IT Governance/Oversight System", "metadata": {"headings": [{"headings_0": {"content": "3.5.1. Absence of a National IT Governance/Oversight System", "page": 79, "level": 4}}, {"headings_1": {"content": "3.5. INFORMATION COMMUNICATION TECHNOLOGY SECTOR", "page": 79, "level": 2}}], "page": 79, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I noted that Government did not have a national IT governance framework that establishes a proper IT governance structure and system. \nThe objective of an IT Governance system is to enable Government to; provide for strategic direction for ICT investments; prioritise and ensure strategic alignment of IT and e-government investments across Government; mitigate risks associated with the use and/or investments in ICT such as duplication of IT systems and wasteful expenditure; and optimise the use of ICT and e-government services, among others. \nAs a result, there is a lack of strategic insight in IT investments, and the Government may fail to optimise the use of existing ICT infrastructure. In addition, the Country lacks competitiveness in harnessing opportunities in ICT. \nI advised Government to consider establishing a national IT Governance Framework and structure to oversee investments in information and communication technologies.", "metadata": {"headings": [{"headings_0": {"content": "3.5.1. Absence of a National IT Governance/Oversight System", "page": 79, "level": 4}}, {"headings_1": {"content": "3.5. INFORMATION COMMUNICATION TECHNOLOGY SECTOR", "page": 79, "level": 2}}, [{"headings_0": {"content": "3.5.1. Absence of a National IT Governance/Oversight System", "page": 79, "level": 4}}, {"headings_1": {"content": "3.5. INFORMATION COMMUNICATION TECHNOLOGY SECTOR", "page": 79, "level": 2}}], [{"headings_0": {"content": "3.5.1. Absence of a National IT Governance/Oversight System", "page": 79, "level": 4}}, {"headings_1": {"content": "3.5. INFORMATION COMMUNICATION TECHNOLOGY SECTOR", "page": 79, "level": 2}}], [{"headings_0": {"content": "3.5.1. Absence of a National IT Governance/Oversight System", "page": 79, "level": 4}}, {"headings_1": {"content": "3.5. INFORMATION COMMUNICATION TECHNOLOGY SECTOR", "page": 79, "level": 2}}]], "page": 79, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.5.2.", "metadata": {"headings": [{"headings_0": {"content": "3.5.2.", "page": 79, "level": 2}}, {"headings_1": {"content": "3.5.1. Absence of a National IT Governance/Oversight System", "page": 79, "level": 4}}], "page": 79, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Failure by MDAs to Pay for National Backbone Infrastructure Services \nNITA-U provides NBI/EGI services to MDAs and Local Governments whose ICT budgets have been either consolidated or not consolidated under NITA-U's ICT budget. Currently, fifty-four (54) entities whose ICT budget is consolidated under the ICT sector budget, while the ICT budget for 72 entities are not consolidated. Out of seventy-two (72) entities, only ten (10) entities have honoured their obligations. This has led to the accumulation of domestic arrears totalling UGX.22.96Bn as of 30th June 2021. \nThe arrears largely relate to the costs of expanding the national backbone/e- Government infrastructure (NBI/EGI). Notably, domestic arrears accounted for 14% of the annual GoU budget for the Authority, which is not only unsustainable but may lead to difficulties in the provision and extension of e-government services throughout the", "metadata": {"headings": [{"headings_0": {"content": "3.5.2.", "page": 79, "level": 2}}, {"headings_1": {"content": "3.5.1. Absence of a National IT Governance/Oversight System", "page": 79, "level": 4}}, [{"headings_0": {"content": "3.5.2.", "page": 79, "level": 2}}, {"headings_1": {"content": "3.5.1. Absence of a National IT Governance/Oversight System", "page": 79, "level": 4}}], [{"headings_0": {"content": "3.5.2.", "page": 79, "level": 2}}, {"headings_1": {"content": "3.5.1. Absence of a National IT Governance/Oversight System", "page": 79, "level": 4}}]], "page": 79, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Country.", "metadata": {"headings": [{"headings_0": {"content": "Country.", "page": 79, "level": 2}}, {"headings_1": {"content": "3.5.2.", "page": 79, "level": 2}}], "page": 79, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I advised management to liaise with MoFPED in consultation with MDAs to ensure that the ICT budgets are consolidated under the ICT Sector budget.", "metadata": {"headings": [{"headings_0": {"content": "Country.", "page": 79, "level": 2}}, {"headings_1": {"content": "3.5.2.", "page": 79, "level": 2}}], "page": 79, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.5.3. Uncollected Revenue from Media Operators", "metadata": {"headings": [{"headings_0": {"content": "3.5.3. Uncollected Revenue from Media Operators", "page": 79, "level": 4}}, {"headings_1": {"content": "Country.", "page": 79, "level": 2}}], "page": 79, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I noted that UCC stopped invoicing government bodies, namely: Uganda Telecom Limited (in-Administration), Uganda Broadcasting Corporation and Uganda Post Limited, for licensing and other charges. A review of the financial statements of these Government agencies revealed an un-invoiced amount of UGX.50.9 Bn. Management attributed it to the financial distress of these companies and the URA's tax policy of invoicing for VAT based on invoices raised by taxpayers, whether paid or not. \nI noted that UCC did not issue invoices worth UGX.421.9Million to 15 operators (4 television operators and 11 FM broadcasting stations) during the period under review, contrary to its financial regulations. \n67 \nRelatedly, UCC has not enforced the payment of a 2% gross annual levy on the licensed Television and FM radio operators gazetted in 2017, contrary to Section 68(1) of the UCC Act 2013. Management explained that the operators had appealed to the Minister", "metadata": {"headings": [{"headings_0": {"content": "3.5.3. Uncollected Revenue from Media Operators", "page": 79, "level": 4}}, {"headings_1": {"content": "Country.", "page": 79, "level": 2}}, [{"headings_0": {"content": "3.5.3. Uncollected Revenue from Media Operators", "page": 79, "level": 4}}, {"headings_1": {"content": "Country.", "page": 79, "level": 2}}], [{"headings_0": {"content": "3.5.3. Uncollected Revenue from Media Operators", "page": 79, "level": 4}}, {"headings_1": {"content": "Country.", "page": 79, "level": 2}}], [{"headings_0": {"content": "3.5.3. Uncollected Revenue from Media Operators", "page": 79, "level": 4}}, {"headings_1": {"content": "Country.", "page": 79, "level": 2}}]], "page": 79, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "of Information, Communication Technology & National Guidance.", "metadata": {"headings": [{"headings_0": {"content": "of Information, Communication Technology & National Guidance.", "page": 80, "level": 2}}, {"headings_1": {"content": "3.5.3. Uncollected Revenue from Media Operators", "page": 79, "level": 4}}], "page": 80, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I advised management to engage all stakeholders and collect the levies due.", "metadata": {"headings": [{"headings_0": {"content": "of Information, Communication Technology & National Guidance.", "page": 80, "level": 2}}, {"headings_1": {"content": "3.5.3. Uncollected Revenue from Media Operators", "page": 79, "level": 4}}], "page": 80, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.5.4. Lack of a Communications Tribunal", "metadata": {"headings": [{"headings_0": {"content": "3.5.4. Lack of a Communications Tribunal", "page": 80, "level": 4}}, {"headings_1": {"content": "of Information, Communication Technology & National Guidance.", "page": 80, "level": 2}}], "page": 80, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "During the audit, I observed that the Commission does not have a Tribunal contrary to Sections 60(1 & 2) and 64(1) of the Uganda Communications Act, 2013. The tribunal would have jurisdiction to hear and determine all matters relating to communications services arising from decisions made by the Commission or the Minister under this Act. \nIn the absence of the tribunal, the Commission lacks jurisdiction to hear and determine matters arising from decisions made by the Commission or the Minister under this Act. Currently, the matters are being heard by the Minister and the Commission, which creates a conflict of interest. \nThe Accounting Officer explained that the responsibility to appoint the tribunal does not reside with the Commission and that the tribunal is to be appointed by the President on the recommendation of the Judicial Service Commission, and that the matter had been brought to the attention of the Minister of ICT and National Guidance. \nI advised management and the Board of Directors to liaise with the relevant authorities to constitute the Communications Tribunal. \n68 \n3.6. ACCOUNTABILITY SECTOR", "metadata": {"headings": [{"headings_0": {"content": "3.5.4. Lack of a Communications Tribunal", "page": 80, "level": 4}}, {"headings_1": {"content": "of Information, Communication Technology & National Guidance.", "page": 80, "level": 2}}, [{"headings_0": {"content": "3.5.4. Lack of a Communications Tribunal", "page": 80, "level": 4}}, {"headings_1": {"content": "of Information, Communication Technology & National Guidance.", "page": 80, "level": 2}}], [{"headings_0": {"content": "3.5.4. Lack of a Communications Tribunal", "page": 80, "level": 4}}, {"headings_1": {"content": "of Information, Communication Technology & National Guidance.", "page": 80, "level": 2}}], [{"headings_0": {"content": "3.5.4. Lack of a Communications Tribunal", "page": 80, "level": 4}}, {"headings_1": {"content": "of Information, Communication Technology & National Guidance.", "page": 80, "level": 2}}], [{"headings_0": {"content": "3.5.4. Lack of a Communications Tribunal", "page": 80, "level": 4}}, {"headings_1": {"content": "of Information, Communication Technology & National Guidance.", "page": 80, "level": 2}}], [{"headings_0": {"content": "3.5.4. Lack of a Communications Tribunal", "page": 80, "level": 4}}, {"headings_1": {"content": "of Information, Communication Technology & National Guidance.", "page": 80, "level": 2}}]], "page": 80, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.6.1.", "metadata": {"headings": [{"headings_0": {"content": "3.6.1.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.5.4. Lack of a Communications Tribunal", "page": 80, "level": 4}}], "page": 81, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Approval of supplementary funding without matching revenue \nIt was established that during the financial year ended 30 th June 2021, supplementary funding totalling UGX.6.13Tn was granted by the Minister of Finance, Planning and Economic Development. It was however, noted that the source of funding for the supplementary expenditure was not clearly shown before approval was granted. \nAs a result, the supplementary expenditure was instead financed by internal budget cuts from various votes, thus affecting the implementation of plans/activities by the affected votes. Although the budget was raised from UGX.45.495Tn to UGX.51.625Tn, only UGX.46.6Tn was realised, resulting in unfunded activities worth UGX.4.98Tn.", "metadata": {"headings": [{"headings_0": {"content": "3.6.1.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.5.4. Lack of a Communications Tribunal", "page": 80, "level": 4}}, [{"headings_0": {"content": "3.6.1.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.5.4. Lack of a Communications Tribunal", "page": 80, "level": 4}}], [{"headings_0": {"content": "3.6.1.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.5.4. Lack of a Communications Tribunal", "page": 80, "level": 4}}]], "page": 81, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.6.2. Underperformance in Revenue Collection", "metadata": {"headings": [{"headings_0": {"content": "3.6.2. Underperformance in Revenue Collection", "page": 81, "level": 4}}, {"headings_1": {"content": "3.6.1.", "page": 81, "level": 2}}], "page": 81, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I observed that, URA had a total revenue collection target of UGX.22.04Tn for the financial year 2020/21 and collected total gross revenue of UGX.19.65Tn (89%) hence a shortfall of UGX.2.39Tn (11%). Under collection of revenue affects cash flow performance of Government and realisation of the planned service delivery targets. In addition, it may increase the national debt burden as the Country may fail to honour its obligations and borrow more to address revenue shortfalls. Management attributed the performance to the adverse impact of the COVID-19 pandemic. \nI advised management to continue implementing strategies to enhance revenue collection.", "metadata": {"headings": [{"headings_0": {"content": "3.6.2. Underperformance in Revenue Collection", "page": 81, "level": 4}}, {"headings_1": {"content": "3.6.1.", "page": 81, "level": 2}}, [{"headings_0": {"content": "3.6.2. Underperformance in Revenue Collection", "page": 81, "level": 4}}, {"headings_1": {"content": "3.6.1.", "page": 81, "level": 2}}]], "page": 81, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.6.3.", "metadata": {"headings": [{"headings_0": {"content": "3.6.3.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.6.2. Underperformance in Revenue Collection", "page": 81, "level": 4}}], "page": 81, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Performance of the collaborating institutions under the Tax Registration and Expansion Programme (TREP)", "metadata": {"headings": [{"headings_0": {"content": "3.6.3.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.6.2. Underperformance in Revenue Collection", "page": 81, "level": 4}}], "page": 81, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "During the financial year 2020/2021, the collaborating institutions under the Tax Registration and Expansion Programme (TREP) registered only 167,211 taxpayers against a target of 436,869 taxpayers representing 38.27% registration success a shortfall of 61.7%. In revenue terms, although TREP had a revenue target of UGX.124.58 Bn in FY 2020/21, it had only collected UGX.49.93Bn by 30th June 2021, representing a 40% performance rate. In addition, the Ministry of Local Government had planned to implement activities worth UGX.4.4Bn under TREP activities but only implemented activities worth UGX.3.3Bn, leaving un-implemented activities worth UGX.1.1Bn despite receiving full funding. As a result, the e-LogRev objective of simplifying and strengthening the local revenue collection systems for Local Governments may not be achieved in time. \nThe paltry performance was attributed to the effects of the COVID-19 pandemic that has set back many businesses, political riots and limited staff at the various stations because URA TREP officers had been laid off, thus resulting in limited staff capacity to conduct enforcement. \nI advised the project management to review their strategies to enhance performance by agreeing on improvement plans to meet the project target.", "metadata": {"headings": [{"headings_0": {"content": "3.6.3.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.6.2. Underperformance in Revenue Collection", "page": 81, "level": 4}}, [{"headings_0": {"content": "3.6.3.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.6.2. Underperformance in Revenue Collection", "page": 81, "level": 4}}]], "page": 81, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.6.4.", "metadata": {"headings": [{"headings_0": {"content": "3.6.4.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.6.3.", "page": 81, "level": 2}}], "page": 81, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Overstay of projects in the Public Investment Plan (PIP)-UGX.39.01Tn \nThe Public Investment Management Reform Strategy provides that projects are supposed to be delivered on budget and on time in order to achieve the desired goals and objectives. \n69 \nAudit observed that in the sample of 371 projects, 342 projects with budgets totalling to UGX.39Tn had gone past their planned exit periods that date as far back as the FY2010/11, with some projects having been extended for more than 12 years. The audit noted that the projects continued to receive Development Committee approval for a continued stay on the PIP. It was noted that only 40% of the projects in the PIP were still within their expected time period. \nAs a result, this has caused delays in the completion of key projects, cost overruns and high commitment fees on foreign debt on account of low Absorption and failure to complete projects on time. It should also be noted that the effectiveness of some projects dwindles as time goes by. \nThe PS/ST was advised to critically review the justification for maintaining certain projects within the Country's Public Investment Plan.", "metadata": {"headings": [{"headings_0": {"content": "3.6.4.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.6.3.", "page": 81, "level": 2}}, [{"headings_0": {"content": "3.6.4.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.6.3.", "page": 81, "level": 2}}], [{"headings_0": {"content": "3.6.4.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.6.3.", "page": 81, "level": 2}}], [{"headings_0": {"content": "3.6.4.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.6.3.", "page": 81, "level": 2}}], [{"headings_0": {"content": "3.6.4.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.6.3.", "page": 81, "level": 2}}], [{"headings_0": {"content": "3.6.4.", "page": 81, "level": 2}}, {"headings_1": {"content": "3.6.3.", "page": 81, "level": 2}}]], "page": 81, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.6.5.", "metadata": {"headings": [{"headings_0": {"content": "3.6.5.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.4.", "page": 81, "level": 2}}], "page": 82, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Un recovered Advances; UGX.2,819,193,074 \nMoFPED introduced a policy to advance funds to entities before actual collection of Appropriation in Aid on the condition that these funds will be recovered after collection. The policy failed in the FY2018/19 and 2019/20 due to failure to recover funds fully. \nDuring the financial year 2018/19, entities were advanced Appropriation in Aid, of which UGX.22.16Bn remained outstanding as at year-end. During the year 19/20, UGX.21.31Bn was recovered, leaving UGX.849 million outstanding. \nIt was also noted that during the financial year 2020/21, a total of UGX.116.9Bn was again advanced in disregard of what had happened earlier to various Local Governments. Out of the funds advanced, UGX.114.07Bn was recovered, leaving UGX.2.81Bn outstanding.", "metadata": {"headings": [{"headings_0": {"content": "3.6.5.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.4.", "page": 81, "level": 2}}, [{"headings_0": {"content": "3.6.5.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.4.", "page": 81, "level": 2}}], [{"headings_0": {"content": "3.6.5.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.4.", "page": 81, "level": 2}}], [{"headings_0": {"content": "3.6.5.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.4.", "page": 81, "level": 2}}]], "page": 82, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.6.6.", "metadata": {"headings": [{"headings_0": {"content": "3.6.6.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.5.", "page": 82, "level": 2}}], "page": 82, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Absence of a monitoring and evaluation framework for impact assessment for tax exemptions \nThe Government of Uganda has offered many beneficiaries' tax benefits, including tax holidays, waivers for tax payments, and refunding of various taxes as stipulated in various agreements and memorandum of understanding. The benefits are granted based on intended objectives that include promotion of economic growth, increasing employment, facilitation for extension of social services by Non-Government Organisations, among others. \nIt was, however, noted that there is no mechanism in place for evaluating and or assessing the impact of the benefits granted. Analysis revealed that a number of beneficiaries have since had their benefit period expired without any follow up. \nIn the absence of a monitoring framework, Government is not in a position to assess the impact of the tax benefits granted to the various beneficiaries. \nThe Accounting Officer was advised to review the tax exemption Policy and set up a monitoring mechanism to follow up all tax incentive beneficiaries. \n70 \n3.7. ENERGY SECTOR", "metadata": {"headings": [{"headings_0": {"content": "3.6.6.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.5.", "page": 82, "level": 2}}, [{"headings_0": {"content": "3.6.6.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.5.", "page": 82, "level": 2}}], [{"headings_0": {"content": "3.6.6.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.5.", "page": 82, "level": 2}}], [{"headings_0": {"content": "3.6.6.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.5.", "page": 82, "level": 2}}], [{"headings_0": {"content": "3.6.6.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.5.", "page": 82, "level": 2}}], [{"headings_0": {"content": "3.6.6.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.5.", "page": 82, "level": 2}}], [{"headings_0": {"content": "3.6.6.", "page": 82, "level": 2}}, {"headings_1": {"content": "3.6.5.", "page": 82, "level": 2}}]], "page": 82, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.7.1.", "metadata": {"headings": [{"headings_0": {"content": "3.7.1.", "page": 83, "level": 2}}, {"headings_1": {"content": "3.6.6.", "page": 82, "level": 2}}], "page": 83, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Capitalization of Uganda National Oil Company and its Subsidiary Companies \nUganda National Oil Company (UNOC) is charged with a mandate of representing", "metadata": {"headings": [{"headings_0": {"content": "3.7.1.", "page": 83, "level": 2}}, {"headings_1": {"content": "3.6.6.", "page": 82, "level": 2}}, [{"headings_0": {"content": "3.7.1.", "page": 83, "level": 2}}, {"headings_1": {"content": "3.6.6.", "page": 82, "level": 2}}]], "page": 83, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Government of Uganda\u2019s Commercial interests in Oil and Gas Sector. The Company is", "metadata": {"headings": [{"headings_0": {"content": "Government of Uganda\u2019s Commercial interests in Oil and Gas Sector. The Company is", "page": 83, "level": 2}}, {"headings_1": {"content": "3.7.1.", "page": 83, "level": 2}}], "page": 83, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "strategically positioned to participate in the down-stream, middle-stream and the up- stream of the oil and gas value chain, thereby engaging in the exploration, production and commercialization activities. The Company is anticipated to fully participate in the exploration and production in the Albertine Graben; the oil refinery and the oil pipeline. As a result, UNOC has registered two flag ship Subsidiary Companies to champion its commercial interests. These include; the Uganda Refinery Holding Company for the refinery business, and the East African Crude Oil Pipeline Company to lead in the pipeline business. \nI noted that despite the significant initial investment requirements by UNOC and its subsidiary companies, the government has not fully capitalized the companies to enable their full participation in the sector. The companies are consistently facing funding constraints. For the period under review, I noted that out of the Budget of UGX.76.38Bn for UNOC, only UGX.34.4Bn was availed, resulting in a funding gap of UGX41.98Bn, which is 54.96% of the budget. \nAfter the Final Investment Decision for the Upstream and EACOP Project, which is envisaged to be undertaken in February 2022, there will be a rapid increase of oil and gas activities which will cause an exponential growth in the financing needs of the", "metadata": {"headings": [{"headings_0": {"content": "Government of Uganda\u2019s Commercial interests in Oil and Gas Sector. The Company is", "page": 83, "level": 2}}, {"headings_1": {"content": "3.7.1.", "page": 83, "level": 2}}, [{"headings_0": {"content": "Government of Uganda\u2019s Commercial interests in Oil and Gas Sector. The Company is", "page": 83, "level": 2}}, {"headings_1": {"content": "3.7.1.", "page": 83, "level": 2}}], [{"headings_0": {"content": "Government of Uganda\u2019s Commercial interests in Oil and Gas Sector. The Company is", "page": 83, "level": 2}}, {"headings_1": {"content": "3.7.1.", "page": 83, "level": 2}}]], "page": 83, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Companies.", "metadata": {"headings": [{"headings_0": {"content": "Companies.", "page": 83, "level": 2}}, {"headings_1": {"content": "Government of Uganda\u2019s Commercial interests in Oil and Gas Sector. The Company is", "page": 83, "level": 2}}], "page": 83, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UNOC has proposed a capitalization plan to MOFPED in its annual work programme and budget for the FY 2021/22 of UGX.914.18Bn comprising Capital expenditure (UGX.304.08Bn) and Operating expenditure (UGX.129.10Bn). \nThe Accounting Officer explained that he was engaging MOFPED and other stakeholders to secure finances to that magnitude, and a plan has been agreed with government on a phased approach towards capitalizing UNOC and its subsidiary companies. \nI advised the Accounting Officer to fast-track their discussions with MoFPED to ensure adequate capitalization of the companies to enable government commercial participation in the strategic oil and gas sector.", "metadata": {"headings": [{"headings_0": {"content": "Companies.", "page": 83, "level": 2}}, {"headings_1": {"content": "Government of Uganda\u2019s Commercial interests in Oil and Gas Sector. The Company is", "page": 83, "level": 2}}, [{"headings_0": {"content": "Companies.", "page": 83, "level": 2}}, {"headings_1": {"content": "Government of Uganda\u2019s Commercial interests in Oil and Gas Sector. The Company is", "page": 83, "level": 2}}], [{"headings_0": {"content": "Companies.", "page": 83, "level": 2}}, {"headings_1": {"content": "Government of Uganda\u2019s Commercial interests in Oil and Gas Sector. The Company is", "page": 83, "level": 2}}]], "page": 83, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.7.2.", "metadata": {"headings": [{"headings_0": {"content": "3.7.2.", "page": 83, "level": 2}}, {"headings_1": {"content": "Companies.", "page": 83, "level": 2}}], "page": 83, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Implementation of the Electricity Connection Policy(ECP) \nThe Government of Uganda established the Electricity Connections Policy (ECP), 2018 which is expected to run from 2018 to 2027. The primary objective of the policy is to increase electricity access, and provide cleaner energy to Ugandans. The policy aims at achieving the 26% rural access target by 2022, 30% national coverage target by 2020 and accelerating access after 2020 in order to achieve 60% access rate by the year 2027. \nI noted from the review of the Connections Department work plans and progress reports for the year under review that out of the 97,000 annual planned connections, only 3,683 (3.7%) connections were undertaken. The dismal performance may frustrate the", "metadata": {"headings": [{"headings_0": {"content": "3.7.2.", "page": 83, "level": 2}}, {"headings_1": {"content": "Companies.", "page": 83, "level": 2}}, [{"headings_0": {"content": "3.7.2.", "page": 83, "level": 2}}, {"headings_1": {"content": "Companies.", "page": 83, "level": 2}}], [{"headings_0": {"content": "3.7.2.", "page": 83, "level": 2}}, {"headings_1": {"content": "Companies.", "page": 83, "level": 2}}]], "page": 83, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Government\u2019s initiatives under the Policy and NDP III of increasing electricity access to", "metadata": {"headings": [{"headings_0": {"content": "Government\u2019s initiatives under the Policy and NDP III of increasing electricity access to", "page": 83, "level": 2}}, {"headings_1": {"content": "3.7.2.", "page": 83, "level": 2}}], "page": 83, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the population to 60% by 2027. \n71 \nI further noted that the ECP was facing challenges in delayed procurement of connection materials, under funding of compensations for the Project Affected Persons (PAPs), vandalism of the distribution network, among others. \nThe Accounting Officer explained that the funding for the Connection Policy got exhausted and the Policy was first suspended by Government. However, it resumed in March 2021 to facilitate connections by utilizing materials procured with funding from African Development Bank (ADB). He further explained, that Rural Electrification Program (REP) had secured approval from AFD to utilize the grant for connections intended to benefit 45,000 customers under the result-based implementation arrangement with the expected implementation to start by March 2022, and the connection materials are expected under the TBEA/Exim Bank contract which will benefit over 172,000 customers by June 2022. \nI advised the Accounting Officer to liaise with the relevant stakeholders such as MoFPED and MEMD, to devise Sustainable funding strategies and ensure that implementation of the ECP is fast tracked for the achievement of policy objectives and service delivery.", "metadata": {"headings": [{"headings_0": {"content": "Government\u2019s initiatives under the Policy and NDP III of increasing electricity access to", "page": 83, "level": 2}}, {"headings_1": {"content": "3.7.2.", "page": 83, "level": 2}}, [{"headings_0": {"content": "Government\u2019s initiatives under the Policy and NDP III of increasing electricity access to", "page": 83, "level": 2}}, {"headings_1": {"content": "3.7.2.", "page": 83, "level": 2}}], [{"headings_0": {"content": "Government\u2019s initiatives under the Policy and NDP III of increasing electricity access to", "page": 83, "level": 2}}, {"headings_1": {"content": "3.7.2.", "page": 83, "level": 2}}], [{"headings_0": {"content": "Government\u2019s initiatives under the Policy and NDP III of increasing electricity access to", "page": 83, "level": 2}}, {"headings_1": {"content": "3.7.2.", "page": 83, "level": 2}}], [{"headings_0": {"content": "Government\u2019s initiatives under the Policy and NDP III of increasing electricity access to", "page": 83, "level": 2}}, {"headings_1": {"content": "3.7.2.", "page": 83, "level": 2}}]], "page": 83, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.7.3. Vandalism and Theft of UETCL Grid Assets", "metadata": {"headings": [{"headings_0": {"content": "3.7.3. Vandalism and Theft of UETCL Grid Assets", "page": 84, "level": 4}}, {"headings_1": {"content": "Government\u2019s initiatives under the Policy and NDP III of increasing electricity access to", "page": 83, "level": 2}}], "page": 84, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Uganda Electricity Transmission Company Ltd (UECTCL is charged with bulk evacuation of power using High Voltage (220Kv and 132Kv). The Company majorly uses steel Towers for the construction of the Transmission Lines. During the year it incurred UGX.0.5Bn in purchase of Galvanized Angle bars to replace vandalized tower members. Further analysis revealed that the Company incurred UGX 1.56Bn in replacement costs on assorted transmission line items vandalized between 2017 and 2021. \nThe Accounting Officer explained that this was a nationwide vice that has been brought to the attention of Cabinet and Security Agencies. In addition, Management installed a pilot security system on transmission lines, however the system was itself vandalized. Nevertheless, management continues to engage security agencies and also community policing to protect UETCL installations. \nVandalism impedes continuity and reliability of electricity supply to the country and strains company resources used to replace vandalized items and associated works. In addition, energy not transmitted due to infrastructure breakdown translates into loss in revenue to the company. \nI advised the Accounting Officer to continue engaging the MoFPED and MEMD in order to obtain funding for Implementation of Key Projects and follow up with the relevant stakeholders to fast-track amendment of the relevant legislation and promotion of Joint Ventures and negotiation of Commercial Partnerships.", "metadata": {"headings": [{"headings_0": {"content": "3.7.3. Vandalism and Theft of UETCL Grid Assets", "page": 84, "level": 4}}, {"headings_1": {"content": "Government\u2019s initiatives under the Policy and NDP III of increasing electricity access to", "page": 83, "level": 2}}, [{"headings_0": {"content": "3.7.3. Vandalism and Theft of UETCL Grid Assets", "page": 84, "level": 4}}, {"headings_1": {"content": "Government\u2019s initiatives under the Policy and NDP III of increasing electricity access to", "page": 83, "level": 2}}], [{"headings_0": {"content": "3.7.3. Vandalism and Theft of UETCL Grid Assets", "page": 84, "level": 4}}, {"headings_1": {"content": "Government\u2019s initiatives under the Policy and NDP III of increasing electricity access to", "page": 83, "level": 2}}], [{"headings_0": {"content": "3.7.3. Vandalism and Theft of UETCL Grid Assets", "page": 84, "level": 4}}, {"headings_1": {"content": "Government\u2019s initiatives under the Policy and NDP III of increasing electricity access to", "page": 83, "level": 2}}]], "page": 84, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.7.4.", "metadata": {"headings": [{"headings_0": {"content": "3.7.4.", "page": 84, "level": 2}}, {"headings_1": {"content": "3.7.3. Vandalism and Theft of UETCL Grid Assets", "page": 84, "level": 4}}], "page": 84, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Deemed Energy Purchases: UGX.87.7 Billion and Power Evacuation Losses UGX.15.29", "metadata": {"headings": [{"headings_0": {"content": "3.7.4.", "page": 84, "level": 2}}, {"headings_1": {"content": "3.7.3. Vandalism and Theft of UETCL Grid Assets", "page": 84, "level": 4}}], "page": 84, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Billion", "metadata": {"headings": [{"headings_0": {"content": "Billion", "page": 84, "level": 2}}, {"headings_1": {"content": "3.7.4.", "page": 84, "level": 2}}], "page": 84, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Deemed energy refers to the electric power that is available for dispatch by an Independent Power Producer (IPP), but due to; non-existent or a weak grid infrastructure, and/ or insufficient demand, the power is not dispatched. This effectively transfers the market risk from the investors to Government, especially when the Power Purchase Agreement states so. \n72 \nAccording to several Power Purchase Agreements (PPAs) and other implementation agreements signed between the IPPs, GOU, and UETCL; GOU committed to construct power evacuation infrastructure from the IPP\u2019s generation facilities to the distribution network upon commencement of generation and dispatch of power by IPPs. The failure to dispatch generated power constitutes deemed energy, and UETCL shall make payments to IPPs for such energy generated and not dispatched in accordance with the power purchase agreement. \nI noted that UETCL continues to pay significant amounts relating to deemed energy purchases. As a result, deemed energy costs of UGX.87.7 billion in regard to thirteen (13) Power Purchase Agreements (PPAs), save for one Hydro Power Plant (HPP), were financed through the electricity tariff system, hence negatively impacting on the electricity price to the final consumer. \nSimilarly, I noted that UEDCL incurred an amount UGX.15.20Bn from power evacuation losses payable to UETCL for bulk power purchases. The amount is due to power evacuation losses stemming from absence of transmission lines to evacuate electricity from PA Technical, Siti 1 and Arpe Power Plants which resulted into wheeling power over a lower capacity and weaker distribution lines operated by UEDCL. These are significant losses for which the Company did not generate economic value. Payment of", "metadata": {"headings": [{"headings_0": {"content": "Billion", "page": 84, "level": 2}}, {"headings_1": {"content": "3.7.4.", "page": 84, "level": 2}}, [{"headings_0": {"content": "Billion", "page": 84, "level": 2}}, {"headings_1": {"content": "3.7.4.", "page": 84, "level": 2}}], [{"headings_0": {"content": "Billion", "page": 84, "level": 2}}, {"headings_1": {"content": "3.7.4.", "page": 84, "level": 2}}], [{"headings_0": {"content": "Billion", "page": 84, "level": 2}}, {"headings_1": {"content": "3.7.4.", "page": 84, "level": 2}}], [{"headings_0": {"content": "Billion", "page": 84, "level": 2}}, {"headings_1": {"content": "3.7.4.", "page": 84, "level": 2}}]], "page": 84, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "this amount would significantly affect the Company\u2019s cash flows.", "metadata": {"headings": [{"headings_0": {"content": "this amount would significantly affect the Company\u2019s cash flows.", "page": 85, "level": 2}}, {"headings_1": {"content": "Billion", "page": 84, "level": 2}}], "page": 85, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I advised the Accounting Officer to continue engaging the Regulator and other sector players to address the infrastructural constraints in the transmission network to ensure efficient evacuation of generated power.", "metadata": {"headings": [{"headings_0": {"content": "this amount would significantly affect the Company\u2019s cash flows.", "page": 85, "level": 2}}, {"headings_1": {"content": "Billion", "page": 84, "level": 2}}], "page": 85, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.7.5. Delayed Commissioning of Karuma HPP", "metadata": {"headings": [{"headings_0": {"content": "3.7.5. Delayed Commissioning of Karuma HPP", "page": 85, "level": 4}}, {"headings_1": {"content": "this amount would significantly affect the Company\u2019s cash flows.", "page": 85, "level": 2}}], "page": 85, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "According to the 4th Quarter Progress Report, I noted that the completion date for Karuma Dam was further extended to 15th June 2022, resulting in a delay of 3 years and 6 months from the initial planned completion date due to unfinished works such as the spillway rehabilitation and other minor defects. \nI noted that the completion of land acquisition process or the Resettlement Action Plan (RAP) for the 132kV Karuma-Lira Transmission Line and Karuma Dam Reservoir by UTECL and MEMD, respectively, remain outstanding. These when not completed will affect the commissioning of the Karuma Dam and is a breach of the employer\u2019s obligations under the EPC Contract with significant risk to the overall project completion. \nThe delays in Project completion are likely to result in increased supervision costs, by the supervising consultant, and increased commitment fees payable on undrawn balances of the loan, of which GoU had already paid commitment fees amounting to UGX.2.9Bn as at 30th June 2021. It also reduces the period between commissioning, commercialization and payback which may have implications on the electricity tariff structure. \nI further noted Key Non-conformities by the EPC Contractor which included; 11kV switchgears installation, Units 1 to 6 ring gate leakage oil sump control box, severe damages on the various 400kV cables, damaged conic sealing surfaces, repair of the oil water separator unit, prolonged spillway operation, Outgoing Line Yard \u2013 cracks in the Control Building and absence of a Floating Boom. \n73 \nThere is a risk that the non-conformities will result into damages, malfunction of equipment, unreliable plant components, and significant impact on working life duration and high operation and maintenance costs, as well as, negative environmental impact. This is likely to further affect the timely and successful commissioning of the Karuma", "metadata": {"headings": [{"headings_0": {"content": "3.7.5. Delayed Commissioning of Karuma HPP", "page": 85, "level": 4}}, {"headings_1": {"content": "this amount would significantly affect the Company\u2019s cash flows.", "page": 85, "level": 2}}, [{"headings_0": {"content": "3.7.5. Delayed Commissioning of Karuma HPP", "page": 85, "level": 4}}, {"headings_1": {"content": "this amount would significantly affect the Company\u2019s cash flows.", "page": 85, "level": 2}}], [{"headings_0": {"content": "3.7.5. Delayed Commissioning of Karuma HPP", "page": 85, "level": 4}}, {"headings_1": {"content": "this amount would significantly affect the Company\u2019s cash flows.", "page": 85, "level": 2}}], [{"headings_0": {"content": "3.7.5. Delayed Commissioning of Karuma HPP", "page": 85, "level": 4}}, {"headings_1": {"content": "this amount would significantly affect the Company\u2019s cash flows.", "page": 85, "level": 2}}], [{"headings_0": {"content": "3.7.5. Delayed Commissioning of Karuma HPP", "page": 85, "level": 4}}, {"headings_1": {"content": "this amount would significantly affect the Company\u2019s cash flows.", "page": 85, "level": 2}}], [{"headings_0": {"content": "3.7.5. Delayed Commissioning of Karuma HPP", "page": 85, "level": 4}}, {"headings_1": {"content": "this amount would significantly affect the Company\u2019s cash flows.", "page": 85, "level": 2}}]], "page": 85, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Dam.", "metadata": {"headings": [{"headings_0": {"content": "Dam.", "page": 86, "level": 2}}, {"headings_1": {"content": "3.7.5. Delayed Commissioning of Karuma HPP", "page": 85, "level": 4}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I advised the Accounting Officer to ensure that the rectification of pending works under the Karuma Dam is expedited to enable project completion and commissioning without further delay.", "metadata": {"headings": [{"headings_0": {"content": "Dam.", "page": 86, "level": 2}}, {"headings_1": {"content": "3.7.5. Delayed Commissioning of Karuma HPP", "page": 85, "level": 4}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.7.6.", "metadata": {"headings": [{"headings_0": {"content": "3.7.6.", "page": 86, "level": 2}}, {"headings_1": {"content": "Dam.", "page": 86, "level": 2}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Bottlenecks in the Compensation of Project Affected Persons(PAPs) under Transmission Line Projects \nThe Uganda Electricity Transmission Company Ltd (UETCL) is mandated to augment", "metadata": {"headings": [{"headings_0": {"content": "3.7.6.", "page": 86, "level": 2}}, {"headings_1": {"content": "Dam.", "page": 86, "level": 2}}, [{"headings_0": {"content": "3.7.6.", "page": 86, "level": 2}}, {"headings_1": {"content": "Dam.", "page": 86, "level": 2}}]], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "government\u2019s efforts of increasing electricity coverage and expanding the national", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s efforts of increasing electricity coverage and expanding the national", "page": 86, "level": 2}}, {"headings_1": {"content": "3.7.6.", "page": 86, "level": 2}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "power transmission line network. The Sustainable Development Goals (SDGs); Seven (7) and Nine (9) both aim at increased electricity access by 2030.The electricity transmission sector has been affected by delayed construction and energizing of transmission lines. The delay has contributed to the low electricity consumption rates in the country of 215 KWh per capita per year, which is below the Sub-Saharan Africa\u2019s average of 552Kwh per capita per year. The delayed construction has further more resulted into low uptake of borrowed funds, leading to increased costs, such as commitment fees paid. \nThe delays in undertaking the construction of the transmission lines have been majorly attributed to inadequacies in the compensation process of the Project Affected Persons", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s efforts of increasing electricity coverage and expanding the national", "page": 86, "level": 2}}, {"headings_1": {"content": "3.7.6.", "page": 86, "level": 2}}, [{"headings_0": {"content": "government\u2019s efforts of increasing electricity coverage and expanding the national", "page": 86, "level": 2}}, {"headings_1": {"content": "3.7.6.", "page": 86, "level": 2}}]], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "(PAPs), thus leading to challenges faced in \u201cAcquisition of the Right of Way\u201d (ROW).", "metadata": {"headings": [{"headings_0": {"content": "(PAPs), thus leading to challenges faced in \u201cAcquisition of the Right of Way\u201d (ROW).", "page": 86, "level": 2}}, {"headings_1": {"content": "government\u2019s efforts of increasing electricity coverage and expanding the national", "page": 86, "level": 2}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "This has in turn led to delayed implementation of a number of projects in the Energy Sector. A review of the compensation process under UETCL revealed the following irregularities;", "metadata": {"headings": [{"headings_0": {"content": "(PAPs), thus leading to challenges faced in \u201cAcquisition of the Right of Way\u201d (ROW).", "page": 86, "level": 2}}, {"headings_1": {"content": "government\u2019s efforts of increasing electricity coverage and expanding the national", "page": 86, "level": 2}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "i)", "metadata": {"headings": [{"headings_0": {"content": "i)", "page": 86, "level": 3}}, {"headings_1": {"content": "(PAPs), thus leading to challenges faced in \u201cAcquisition of the Right of Way\u201d (ROW).", "page": 86, "level": 2}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The budgeting, disbursement, and absorption of compensation funds were not properly managed which resulted into over budgeting to the tune of UGX.111.3Bn on GERP and Mputa projects.", "metadata": {"headings": [{"headings_0": {"content": "i)", "page": 86, "level": 3}}, {"headings_1": {"content": "(PAPs), thus leading to challenges faced in \u201cAcquisition of the Right of Way\u201d (ROW).", "page": 86, "level": 2}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ii)", "metadata": {"headings": [{"headings_0": {"content": "ii)", "page": 86, "level": 3}}, {"headings_1": {"content": "i)", "page": 86, "level": 3}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The valuation process was marred with a number of irregularities, which included the use of un-updated district compensation rates; and unverified legal interests in the land; which resulted into unnecessary revaluations and ligation.", "metadata": {"headings": [{"headings_0": {"content": "ii)", "page": 86, "level": 3}}, {"headings_1": {"content": "i)", "page": 86, "level": 3}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii)", "metadata": {"headings": [{"headings_0": {"content": "iii)", "page": 86, "level": 3}}, {"headings_1": {"content": "ii)", "page": 86, "level": 3}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "About 56% of the PAPs for GERP and Mputa projects were not properly identified, and this resulted into a mismatch between the number of PAPs appearing on the Payment files, Survey reports and Valuation Reports.", "metadata": {"headings": [{"headings_0": {"content": "iii)", "page": 86, "level": 3}}, {"headings_1": {"content": "ii)", "page": 86, "level": 3}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iv)", "metadata": {"headings": [{"headings_0": {"content": "iv)", "page": 86, "level": 3}}, {"headings_1": {"content": "iii)", "page": 86, "level": 3}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Of the released compensation amount of UGX.21.5Bn for both GERP and Mputa Projects, only UGX.5.86Bn was paid to PAPs, thus resulting into unspent funds to the tune of UGX.15.64Bn. This mostly affected the GERP Project which alone had UGX.13.17Bn not utilized, while Mputa had only UGX.1.66Bn.", "metadata": {"headings": [{"headings_0": {"content": "iv)", "page": 86, "level": 3}}, {"headings_1": {"content": "iii)", "page": 86, "level": 3}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "v)", "metadata": {"headings": [{"headings_0": {"content": "v)", "page": 86, "level": 3}}, {"headings_1": {"content": "iv)", "page": 86, "level": 3}}], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "There were significant delays in compensation of PAPs. 1,109 PAPs (52.2%) for Mputa and 821 (35%) for the GERP Transmission Line remained unpaid by the time of concluding the audit (November, 2021). Relatedly, Compensations in kind also delayed whereby out of 149 PAPs identified, only 93 were resettled, leaving 56 PAPs not resettled. \n74 \nvi) There were inadequacies in the construction of the resettlement houses which included; irregular payments to contractors, delayed progress of works, discrepancies in drawing specifications and BOQs, poor materials used for construction, and a number of defects which were not rectified. \nTimely compensations of project affected persons (PAPs) and acquisition of the right of way for electricity transmission lines would enable increased access to electricity by the citizens as envisaged in the sustainable development goals; 7 and 9. This would have a multiplier effect on industrialization which is critical for creation of employment and ultimately poverty reduction in the country. \nI advised management to streamline its RAP processes, including proper identification of PAPs, clear valuation processes, proper budgeting and release of funds, timely submission of PAP documentation and proper supervision of RAP activities.", "metadata": {"headings": [{"headings_0": {"content": "v)", "page": 86, "level": 3}}, {"headings_1": {"content": "iv)", "page": 86, "level": 3}}, [{"headings_0": {"content": "v)", "page": 86, "level": 3}}, {"headings_1": {"content": "iv)", "page": 86, "level": 3}}], [{"headings_0": {"content": "v)", "page": 86, "level": 3}}, {"headings_1": {"content": "iv)", "page": 86, "level": 3}}], [{"headings_0": {"content": "v)", "page": 86, "level": 3}}, {"headings_1": {"content": "iv)", "page": 86, "level": 3}}], [{"headings_0": {"content": "v)", "page": 86, "level": 3}}, {"headings_1": {"content": "iv)", "page": 86, "level": 3}}]], "page": 86, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.8. GENDER AND SOCIAL DEVELOPMENT SECTOR", "metadata": {"headings": [{"headings_0": {"content": "3.8. GENDER AND SOCIAL DEVELOPMENT SECTOR", "page": 87, "level": 4}}, {"headings_1": {"content": "v)", "page": 86, "level": 3}}], "page": 87, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "3.8.1. Labour Externalization Inadequacies", "metadata": {"headings": [{"headings_0": {"content": "3.8.1. Labour Externalization Inadequacies", "page": 87, "level": 2}}, {"headings_1": {"content": "3.8. GENDER AND SOCIAL DEVELOPMENT SECTOR", "page": 87, "level": 4}}], "page": 87, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Labour externalization is a process whereby government undertakes to regulate the export of labour to foreign countries. This role is under the mandate of the Ministry of Gender, Labour and Social Development (MoGLSD). This activity involves the signing of Bi-lateral Migrant Agreements (BLMA) with destination countries. I noted that the country has only 3 BLMAs with destination countries namely; Saudi Arabia, the Hashemite Kingdom of Jordan and the United Arab Emirates. However, a review of the ministry records indicated that the country was exporting labour to more than 3 countries, such as; Kuwait, Oman, Qatar, Turkey, Afghanistan, Iraq and Somalia, among others. \nI noted that the Ministry had no mechanism in place to monitor the implementation of the BLMAs. Furthermore, pre-externalization checks on the working conditions, safety and health perspectives of the importing labour organizations had not been undertaken. I observed that 246 female migrant workers returned between June and December 2019 without completing their contract period of two years due to human abuse related challenges, according to the Uganda Association of External Recruitment Agencies reception Centre report on Returnee Migrant workers. \nFurthermore, 548 external labour cases were registered, out of which, 48 (9%) cases remained unresolved at year end. \nAccordingly, the gender equality, labour and human rights of over 103,935 Ugandan workers who have migrated to various countries to provide labour, from July 2016 to June 2021, may not be guaranteed without duly signed BLMAs. \nI advised the Accounting Officer to expedite the finalization of bilateral migrant agreements with all the destination countries as this would provide clear international protocols for protection of migrant workers. In addition, the Ministry should liaise with Ugandan Missions in the destination countries and register all the Ugandan migrants for ease of follow up. \n75", "metadata": {"headings": [{"headings_0": {"content": "3.8.1. Labour Externalization Inadequacies", "page": 87, "level": 2}}, {"headings_1": {"content": "3.8. GENDER AND SOCIAL DEVELOPMENT SECTOR", "page": 87, "level": 4}}, [{"headings_0": {"content": "3.8.1. Labour Externalization Inadequacies", "page": 87, "level": 2}}, {"headings_1": {"content": "3.8. GENDER AND SOCIAL DEVELOPMENT SECTOR", "page": 87, "level": 4}}], [{"headings_0": {"content": "3.8.1. Labour Externalization Inadequacies", "page": 87, "level": 2}}, {"headings_1": {"content": "3.8. GENDER AND SOCIAL DEVELOPMENT SECTOR", "page": 87, "level": 4}}], [{"headings_0": {"content": "3.8.1. Labour Externalization Inadequacies", "page": 87, "level": 2}}, {"headings_1": {"content": "3.8. GENDER AND SOCIAL DEVELOPMENT SECTOR", "page": 87, "level": 4}}], [{"headings_0": {"content": "3.8.1. Labour Externalization Inadequacies", "page": 87, "level": 2}}, {"headings_1": {"content": "3.8. GENDER AND SOCIAL DEVELOPMENT SECTOR", "page": 87, "level": 4}}], [{"headings_0": {"content": "3.8.1. Labour Externalization Inadequacies", "page": 87, "level": 2}}, {"headings_1": {"content": "3.8. GENDER AND SOCIAL DEVELOPMENT SECTOR", "page": 87, "level": 4}}]], "page": 87, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.8.2. Implementation of the Uganda Women Entrepreneurship Programme", "metadata": {"headings": [{"headings_0": {"content": "3.8.2. Implementation of the Uganda Women Entrepreneurship Programme", "page": 88, "level": 4}}, {"headings_1": {"content": "3.8.1. Labour Externalization Inadequacies", "page": 87, "level": 2}}], "page": 88, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The Uganda Women Entrepreneurship Programme (UWEP) is an initiative of the Government for empowering women to improve their income levels and their contribution to economic development; by improving their access to financial services and equipping them with skills for enterprise growth, value addition and marketing of their products and services. The Programme has disbursed UGX.107 billion to 11,256 women groups, covering approximately 135,000 women, over the five-year period from financial year 2015/16 to 2019/20. \nI carried out a Value for Money audit to assess the extent to which the Programme achieved its intended objectives, and noted a number of key improvement areas as follows;", "metadata": {"headings": [{"headings_0": {"content": "3.8.2. Implementation of the Uganda Women Entrepreneurship Programme", "page": 88, "level": 4}}, {"headings_1": {"content": "3.8.1. Labour Externalization Inadequacies", "page": 87, "level": 2}}, [{"headings_0": {"content": "3.8.2. Implementation of the Uganda Women Entrepreneurship Programme", "page": 88, "level": 4}}, {"headings_1": {"content": "3.8.1. Labour Externalization Inadequacies", "page": 87, "level": 2}}]], "page": 88, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "i)", "metadata": {"headings": [{"headings_0": {"content": "i)", "page": 88, "level": 2}}, {"headings_1": {"content": "3.8.2. Implementation of the Uganda Women Entrepreneurship Programme", "page": 88, "level": 4}}], "page": 88, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I noted that only 4,185 women had benefited from the Programme under the capacity and skills development component, which translates into 42% of the desired target (10,000 women) according to the UWEP Programme document.", "metadata": {"headings": [{"headings_0": {"content": "i)", "page": 88, "level": 2}}, {"headings_1": {"content": "3.8.2. Implementation of the Uganda Women Entrepreneurship Programme", "page": 88, "level": 4}}], "page": 88, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ii)", "metadata": {"headings": [{"headings_0": {"content": "ii)", "page": 88, "level": 2}}, {"headings_1": {"content": "i)", "page": 88, "level": 2}}], "page": 88, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "There were delays in disbursement of funds to the women groups. In some cases, the delays were more than 12 months from time of approval of the applications to receipt of the funds which affected the performance and success of enterprises, specifically those in the agricultural sector, which depend on the rainy seasons for planting.", "metadata": {"headings": [{"headings_0": {"content": "ii)", "page": 88, "level": 2}}, {"headings_1": {"content": "i)", "page": 88, "level": 2}}], "page": 88, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii)", "metadata": {"headings": [{"headings_0": {"content": "iii)", "page": 88, "level": 2}}, {"headings_1": {"content": "ii)", "page": 88, "level": 2}}], "page": 88, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Despite the UGX.16Bn sitting on the recovery account with Bank of Uganda from the loan repayments over the five years, only UGX.963 million (6%) of the amount had been revolved. This denied the qualifying women groups timely access to funds, which were otherwise available for disbursement. \niv) The Ministry of Gender, Labor and Social Development through the UWEP Technical Support Unit did not effectively plan and coordinate implementation of the objectives of facilitating women to access markets for their product, as well as promoting access to appropriate technologies which were not allocated funds in the budgets for the entire 5-year period. Consequently, these objectives were not fully achieved. \nv) There was underfunding of monitoring and supervision activities at the local government level which affected the frequency of monitoring of beneficiary women groups. The programme gaps at enterprise level could not be adequately identified and corrected on time. At the National level, the Technical Support Unit (TSU) undertook only 13 (43%) of the planned 30 monitoring and supervision visits to the regions throughout the five-year period. This resulted in delayed identification of performance gaps and timely remedial actions. \nI advised the Accounting Officer, prioritize the capacity and skills development component of the Programme and ensure women groups are given funds after attaining the requisite skills in management of the approved enterprises. In addition, the Ministry and Local Authorities should iron out all the bottlenecks in the application approval process to ensure timely revolving of the funds to women groups. \n76 \n3.9. LAND SECTOR \n3.9.1. Management of Government Land Matters \nThe Uganda Land Commission is mandated to manage public land acquired by government both abroad and locally. I noted that the Commission does not have an inventory for all government land and properties that are either occupied by tenants, vacant, acquired under compensation (but not yet re-distributed to the bona fide occupants), or acquired and owned by other government institutions and missions abroad. This inadequacy has contributed to government losing land to fraudsters, squatters and also inadequate revenue collections from the untimely collection of the property premiums and leases.", "metadata": {"headings": [{"headings_0": {"content": "iii)", "page": 88, "level": 2}}, {"headings_1": {"content": "ii)", "page": 88, "level": 2}}, [{"headings_0": {"content": "iii)", "page": 88, "level": 2}}, {"headings_1": {"content": "ii)", "page": 88, "level": 2}}], [{"headings_0": {"content": "iii)", "page": 88, "level": 2}}, {"headings_1": {"content": "ii)", "page": 88, "level": 2}}], [{"headings_0": {"content": "iii)", "page": 88, "level": 2}}, {"headings_1": {"content": "ii)", "page": 88, "level": 2}}], [{"headings_0": {"content": "iii)", "page": 88, "level": 2}}, {"headings_1": {"content": "ii)", "page": 88, "level": 2}}], [{"headings_0": {"content": "iii)", "page": 88, "level": 2}}, {"headings_1": {"content": "ii)", "page": 88, "level": 2}}], [{"headings_0": {"content": "iii)", "page": 88, "level": 2}}, {"headings_1": {"content": "ii)", "page": 88, "level": 2}}]], "page": 88, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "I further noted an increase of UGX. 118.Bn (81.5%) in land compensation payables during the year, of which UGX 105.5Bn related to new compensations for land, while UGX.12.5Bn related to revaluations of land that had been previously fully compensated or had an outstanding payment. Furthermore, UGX.8.93Bn (15%) was paid to eight (8) persons out of the eight four (84) ranchers who had not been paid in the previous years. The delay to pay other ranch claimants may result into litigation and court awards that would further increase the domestic arrears. As at 30th June, 2021, the outstanding claim from ranchers was UGX.61.5Bn, and compensations to other claimants stood at UGX.188.0Bn, thus bringing total outstanding compensations in the Ministry of Lands alone to UGX.249.5Bn. \nSimilarly, the current landlord claims under the Uganda Land Fund, at the Uganda Land Commission, stand at UGX 194.7Bn. These also increased by UGX.7.2Bn during the current year. However, this amount is not supported by complete and appropriate documentation. The claims have been outstanding for a while due to the limited budget allocation to the Commission and the delay to fully operationalize the Land Fund which has remained operating as a budget support line in the Commission\u2019s appropriated budget. \nI advised government to fully operationalize the Land Fund under the Commission and consider decentralizing all government land compensation payment claims to the Fund for proper management of government compensation processes, including mobilization of funds. \n3.10. EDUCATION SECTOR", "metadata": {"headings": [{"headings_0": {"content": "iii)", "page": 88, "level": 2}}, {"headings_1": {"content": "ii)", "page": 88, "level": 2}}, [{"headings_0": {"content": "iii)", "page": 88, "level": 2}}, {"headings_1": {"content": "ii)", "page": 88, "level": 2}}], [{"headings_0": {"content": "iii)", "page": 88, "level": 2}}, {"headings_1": {"content": "ii)", "page": 88, "level": 2}}]], "page": 89, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.10.1. Management of Bilateral Scholarships", "metadata": {"headings": [{"headings_0": {"content": "3.10.1. Management of Bilateral Scholarships", "page": 89, "level": 2}}, {"headings_1": {"content": "iii)", "page": 88, "level": 2}}], "page": 89, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Section 42(1) of the Higher Education Students Financing Act provides that all scholarships offered by the Government of Uganda (GOU), including bilateral scholarships, existing immediately before the commencement of this Act shall vest in the", "metadata": {"headings": [{"headings_0": {"content": "3.10.1. Management of Bilateral Scholarships", "page": 89, "level": 2}}, {"headings_1": {"content": "iii)", "page": 88, "level": 2}}], "page": 89, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Board.", "metadata": {"headings": [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}, {"headings_1": {"content": "3.10.1. Management of Bilateral Scholarships", "page": 89, "level": 2}}], "page": 89, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Subsection (2) further provides that the central scholarship committee of the Ministry of education and Sports existing immediately before the commencement of this Act shall cease to exist on such a date as the Minister may by Statutory Instrument publish in the gazette. \n77 \nOver the years, Uganda has received scholarships through various schemes from several Countries. The various types of awards include offers through bilateral cooperation, offers through multilateral cooperation and direct offers to individuals through Embassies of awarding Governments, Institutions and Agencies. \nScholarships awarded to Ugandans through Embassies of awarding Government are in most cases received on an annual basis, most of them routed through the Ministry of Foreign Affairs. The major and regular donors are; United Kingdom, India, Egypt, China, Cuba, Turkey, Algeria, New Zealand and Hungary, among others. \nA review was undertaken with the objective of establishing the effectiveness in management of Bi-lateral scholarships, identifying the challenges and providing recommendations for improvement. During the analysis, a number of aspects were considered including; the extent of awareness of the scholarship programmes by Ugandans, absorption of Bilateral Scholarships, and the transparency and effectiveness of the award process. The following matters anomalies were identified;", "metadata": {"headings": [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}, {"headings_1": {"content": "3.10.1. Management of Bilateral Scholarships", "page": 89, "level": 2}}, [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}, {"headings_1": {"content": "3.10.1. Management of Bilateral Scholarships", "page": 89, "level": 2}}], [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}, {"headings_1": {"content": "3.10.1. Management of Bilateral Scholarships", "page": 89, "level": 2}}], [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}, {"headings_1": {"content": "3.10.1. Management of Bilateral Scholarships", "page": 89, "level": 2}}], [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}, {"headings_1": {"content": "3.10.1. Management of Bilateral Scholarships", "page": 89, "level": 2}}]], "page": 89, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Management of scholarships at the Ministry of Education and Sports is not supported by a Scholarship Policy, thus the country lacks policy direction in regard to sourcing, accepting, allocation and monitoring of scholarships.", "metadata": {"headings": [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}, {"headings_1": {"content": "3.10.1. Management of Bilateral Scholarships", "page": 89, "level": 2}}], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}, {"headings_1": {"content": "3.10.1. Management of Bilateral Scholarships", "page": 89, "level": 2}}, [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}, {"headings_1": {"content": "3.10.1. Management of Bilateral Scholarships", "page": 89, "level": 2}}]], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Ministry of Education and Sports still holds the mandate of managing Government scholarships contrary to Section 42(1) of the", "metadata": {"headings": [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}, {"headings_1": {"content": "3.10.1. Management of Bilateral Scholarships", "page": 89, "level": 2}}], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "metadata": {"headings": [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}, {"headings_1": {"content": "Board.", "page": 89, "level": 2}}], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "mandate. \n", "metadata": {"headings": [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}, {"headings_1": {"content": "Board.", "page": 89, "level": 2}}, [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}, {"headings_1": {"content": "Board.", "page": 89, "level": 2}}]], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Information on Scholarship offered at the different Missions and other Government organizations was not readily available at the Secretariat.", "metadata": {"headings": [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}, {"headings_1": {"content": "Board.", "page": 89, "level": 2}}], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}, {"headings_1": {"content": "Board.", "page": 89, "level": 2}}], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Low uptake of scholarships was noted whereby out of a total of 280 scholarships offered to government in the previous three years, only 162 were filled resulting into an under absorption of 118 (42%) scholarships.", "metadata": {"headings": [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}, {"headings_1": {"content": "Board.", "page": 89, "level": 2}}], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "The above outlined weaknesses have resulted into the process of accessing information on scholarships not being properly streamlined and consequently leading to low utilization/absorption of the scholarships available to the Country. \nI advised the Ministry of Education and Sports to ensure that the administration of scholarships in the country is streamlined for efficient and effective management. \n3.10.2. Management of Research Grants by Public Universities in Uganda \nOwing to the different challenges faced by public Universities in the management of research grants I undertook a value for money audit and independently assessed the management of research grants by Public Universities in 4 out of the 9 Public Universities in Uganda, these included; Makerere University, Mbarara University of Science and Technology (MUST), Kyambogo University and Busitema University. I noted the following;", "metadata": {"headings": [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}, {"headings_1": {"content": "Board.", "page": 89, "level": 2}}, [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}, {"headings_1": {"content": "Board.", "page": 89, "level": 2}}], [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}, {"headings_1": {"content": "Board.", "page": 89, "level": 2}}], [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}, {"headings_1": {"content": "Board.", "page": 89, "level": 2}}]], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "i)", "metadata": {"headings": [{"headings_0": {"content": "i)", "page": 90, "level": 2}}, {"headings_1": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "There is no framework to ensure collective planning, coordination and follow-up of research efforts for the different Public Universities to ensure equitable allocation of resources, efficient utilization of academic staff, and that research results contribute to National development. \n78", "metadata": {"headings": [{"headings_0": {"content": "i)", "page": 90, "level": 2}}, {"headings_1": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}, [{"headings_0": {"content": "i)", "page": 90, "level": 2}}, {"headings_1": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}]], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ii)", "metadata": {"headings": [{"headings_0": {"content": "ii)", "page": 91, "level": 2}}, {"headings_1": {"content": "i)", "page": 90, "level": 2}}], "page": 91, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I noted that key research and grant management policies/guidelines were missing at a number of Universities to guide on the efficient and effective management of research activities. Furthermore, the country lacks national regulations and guidelines for research and innovation activities including; sourcing of external grants, development and uptake of technologies and, management and commercialization of intellectual properties.", "metadata": {"headings": [{"headings_0": {"content": "ii)", "page": 91, "level": 2}}, {"headings_1": {"content": "i)", "page": 90, "level": 2}}], "page": 91, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii)", "metadata": {"headings": [{"headings_0": {"content": "iii)", "page": 91, "level": 2}}, {"headings_1": {"content": "ii)", "page": 91, "level": 2}}], "page": 91, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I noted inadequate administration structures for management of university grants, for example, out of the 4 Universities, only MUST had a grants office with dedicated staff to support grant activities. Busitema and Kyambogo universities did not have grants administrators at college/faculty level, while at Makerere and Mbarara only the college of Health Sciences and the faculty of medicine, respectively, had grant administrators to undertake the tasks.", "metadata": {"headings": [{"headings_0": {"content": "iii)", "page": 91, "level": 2}}, {"headings_1": {"content": "ii)", "page": 91, "level": 2}}], "page": 91, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iv)", "metadata": {"headings": [{"headings_0": {"content": "iv)", "page": 91, "level": 2}}, {"headings_1": {"content": "iii)", "page": 91, "level": 2}}], "page": 91, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I noted that the country does not have a clear research agenda to guide planning, implementation and policy matters regarding research in the Country. Some Universities lacked research agenda. For example, Mbarara and Busitema Universities did not have an approved research agenda. \nv) I noted that resource mobilization initiatives for public universities were inadequate. Out of the 4 universities, only MUK had a consolidated Research Innovation Fund (RIF) for research funds from government the other universities have not explored this initiative. All the universities have not raised any resources internally into a separate fund for research. This was attributed to government policy of remitting all internally generated revenue into the consolidated fund.", "metadata": {"headings": [{"headings_0": {"content": "iv)", "page": 91, "level": 2}}, {"headings_1": {"content": "iii)", "page": 91, "level": 2}}, [{"headings_0": {"content": "iv)", "page": 91, "level": 2}}, {"headings_1": {"content": "iii)", "page": 91, "level": 2}}]], "page": 91, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "vi)", "metadata": {"headings": [{"headings_0": {"content": "vi)", "page": 91, "level": 2}}, {"headings_1": {"content": "iv)", "page": 91, "level": 2}}], "page": 91, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I noted monitoring and evaluation of research projects was inadequate in all the four Universities. M&E was not carried out by the university management on external research grants for the period 2017/18-2019/20. I further noted that even where M&E was undertaken by donors, recommendations were not fully implemented by the Universities. \nvii) I noted significant delays in completion of research projects. For example, 450 (88%) out of 512 Government funded Grants from MUK, Kyambogo and Busitema, were not completed in time during the period under review. Similarly, 218 (62.3%) out of 350 Donor funded Grants from the 4 universities were not completed in time. \nI advised government through its various entities to consider establishing a National research agenda which should be supported by a comprehensive research management framework streamlined throughout the entities. In addition, Government should consider establishing a research fund at each public university in which both government and donor research funds could be collected and effectively managed. \n79", "metadata": {"headings": [{"headings_0": {"content": "vi)", "page": 91, "level": 2}}, {"headings_1": {"content": "iv)", "page": 91, "level": 2}}, [{"headings_0": {"content": "vi)", "page": 91, "level": 2}}, {"headings_1": {"content": "iv)", "page": 91, "level": 2}}], [{"headings_0": {"content": "vi)", "page": 91, "level": 2}}, {"headings_1": {"content": "iv)", "page": 91, "level": 2}}], [{"headings_0": {"content": "vi)", "page": 91, "level": 2}}, {"headings_1": {"content": "iv)", "page": 91, "level": 2}}]], "page": 91, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.11. WATER & ENVIRONMENT SECTOR", "metadata": {"headings": [{"headings_0": {"content": "3.11. WATER & ENVIRONMENT SECTOR", "page": 92, "level": 2}}, {"headings_1": {"content": "vi)", "page": 91, "level": 2}}], "page": 92, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "3.11.1.", "metadata": {"headings": [{"headings_0": {"content": "3.11.1.", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11. WATER & ENVIRONMENT SECTOR", "page": 92, "level": 2}}], "page": 92, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Afforestation and Restoration of Selected Central Forest Reserves (CFRS) by the National Forest Authority (NFA) \nThe National Forestry Authority (NFA) was established under section 52 of the National Forestry and Tree Planting Act, 2003 (NFTPA) with an objective of managing the Central", "metadata": {"headings": [{"headings_0": {"content": "3.11.1.", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11. WATER & ENVIRONMENT SECTOR", "page": 92, "level": 2}}, [{"headings_0": {"content": "3.11.1.", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11. WATER & ENVIRONMENT SECTOR", "page": 92, "level": 2}}]], "page": 92, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "metadata": {"headings": [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11.1.", "page": 92, "level": 2}}], "page": 92, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "9% (1,956,664ha) in 2015, with a slight increase of up to 12.3% (2,025,192ha) in 2017. The forest cover loss over the years from 1990 to the last biomass study in 2017 was estimated at 58.9%. Similarly, the CFR forest cover under NFA\u2019s jurisdiction alone dropped from 62.5% (791,240ha) of the NFA forest cover to 45.8% (579,257ha) in the same period. This trend was contrary to Sustainable Development Goal 15 which required governments to ensure the restoration of forests and increase forest cover in line with obligations under international agreements by 2020. \nI carried a value for money audit to evaluate the effectiveness of the measures put in place by the NFA towards the restoration and establishment of new plantations in the central forest reserves, between the period of 2016 and 2020, and noted the following; \ni) Although management achieved 11,173ha (78%) of their planned outputs (14,277ha) for both restoration planting and establishment of new tree plantations, this only contributed a total of only 0.88% to the NFA forest cover (1,265,742ha) over the four-year period. This dismal performance was attributed to a number of inadequacies in the Planning; Budgeting; Land management; Monitoring and Inspections; and Collaboration management, resulting into the failure by NFA to meet its desired targets towards increasing the national forest cover. \nii) A number of stakeholders in the forest sector, with different projects across MDAs supporting forestry restoration activities, were not adequately coordinated under a single mandate. In addition, there are; inconsistencies in the national, sector and NFA strategic plans, there is a lack of specific outputs per stakeholder in the plan together with matching funding for the activities met to achieve the planned outputs. These inadequacies in coordination and planning at NFA, the Forest sector and national level have contributed to the limited National forest coverage of 12.3% and NFA forest cover of 45.8%.", "metadata": {"headings": [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11.1.", "page": 92, "level": 2}}, [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11.1.", "page": 92, "level": 2}}], [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11.1.", "page": 92, "level": 2}}], [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11.1.", "page": 92, "level": 2}}]], "page": 92, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii) I that out of the expected 16 monitoring reports in the four-year period ending 30 th June, 2020, only 4 (25%) were prepared in the entire four-year period. In addition, NFA budgeted to receive UGX.320m for monitoring in the four years under review, but only UGX.91.8million (29%) was released, and the entity spent UGX 88.8million over the period on monitoring activity. Furthermore, there were limitations in discussing and implementing monitoring report recommendations, and as a result, there were instances in which management did not demarcate the area as recommended by the M&E report before restoring the forest. This led to destruction of the newly restored forests by encroachers. \nI established that seventeen (17) MOUs were signed with different government agencies, out of the planned twenty (20), representing an 85% performance. Although these collaborations contributed to the restoration and establishment of new plantations, there were inadequacies in providing the planned quantity of seedlings. In addition, twenty (20) out twenty-eight (28) Collaborative Forest management (CFM) agreements were signed with forest edge communities. \n80 \nI advised the Accounting Officer to improve on the Planning, Budgeting, Coordination and Collaborations, Monitoring aspects, and prioritization of fixed resources required in the restoration and establishment of forest cover in the country. \n3.12. WORKS SECTOR", "metadata": {"headings": [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11.1.", "page": 92, "level": 2}}, [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11.1.", "page": 92, "level": 2}}], [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11.1.", "page": 92, "level": 2}}], [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11.1.", "page": 92, "level": 2}}], [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}, {"headings_1": {"content": "3.11.1.", "page": 92, "level": 2}}]], "page": 92, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.12.1. Uganda National Roads Authority", "metadata": {"headings": [{"headings_0": {"content": "3.12.1. Uganda National Roads Authority", "page": 93, "level": 4}}, {"headings_1": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "a)", "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 93, "level": 2}}, {"headings_1": {"content": "3.12.1. Uganda National Roads Authority", "page": 93, "level": 4}}], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Loss of funds in interest on delayed payment of contractors \nThe Authority incurred wasteful expenditure to a tune of UGX.17Bn in form of interest and penalties due to delayed settlement of invoices from contractors. This was a loss to Government. The Accounting Officer explained that interest costs arise due to inadequate funding for the road development and maintenance projects that UNRA is managing. I advised the Accounting Officer to enhance the Authority cash flow management by rationalizing available resources, especially reduction of advances", "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 93, "level": 2}}, {"headings_1": {"content": "3.12.1. Uganda National Roads Authority", "page": 93, "level": 4}}, [{"headings_0": {"content": "a)", "page": 93, "level": 2}}, {"headings_1": {"content": "3.12.1. Uganda National Roads Authority", "page": 93, "level": 4}}]], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "payments to settle outstanding claims and to improve the Authority\u2019s budgeting process", "metadata": {"headings": [{"headings_0": {"content": "payments to settle outstanding claims and to improve the Authority\u2019s budgeting process", "page": 93, "level": 2}}, {"headings_1": {"content": "a)", "page": 93, "level": 2}}], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "and liaison with relevant authorities such Parliament and Ministry of Finance for adequate financial resource allocation.", "metadata": {"headings": [{"headings_0": {"content": "payments to settle outstanding claims and to improve the Authority\u2019s budgeting process", "page": 93, "level": 2}}, {"headings_1": {"content": "a)", "page": 93, "level": 2}}], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "b)", "metadata": {"headings": [{"headings_0": {"content": "b)", "page": 93, "level": 2}}, {"headings_1": {"content": "payments to settle outstanding claims and to improve the Authority\u2019s budgeting process", "page": 93, "level": 2}}], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Delayed road projects and accumulation of commitment fees", "metadata": {"headings": [{"headings_0": {"content": "b)", "page": 93, "level": 2}}, {"headings_1": {"content": "payments to settle outstanding claims and to improve the Authority\u2019s budgeting process", "page": 93, "level": 2}}], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "By 30 th June 2021, 35 road projects under UNRA with a total contract value of USD.398,427,063.99 and UGX.149,739,813,845 had been delayed. These 35 projects were to be completed during the year were behind schedule as per their work programme still on-going by the close of the year. The delays which ranged from 64 days (about two months) to 1,072 days (about two months three years) days were majorly attributed to: inadequate mobilization by some contractors, abnormal rains, delayed acquisition of Right of Way and the effects of COVID-19 that resulted into nationwide lockdown. I computed commitment fees on only two projects (Busega-Mpigi- UGX.7,1140,345,245) and RSSPV (UGX.3,079,241,588) and observed an accumulation of total commitment fees amounting to UGX.10,219,586,833 in only one year alone. \nThe Accounting Officer explained that the delay to complete the projects was due to a number of factors that included; inadequate mobilization by some contractors, abnormal rains, delayed acquisition of Right of Way and the effects of COVID-19 that resulted into nationwide lockdown. I advised the Accounting Officer to always ensure that projects are completed within the agreed timelines.", "metadata": {"headings": [{"headings_0": {"content": "b)", "page": 93, "level": 2}}, {"headings_1": {"content": "payments to settle outstanding claims and to improve the Authority\u2019s budgeting process", "page": 93, "level": 2}}, [{"headings_0": {"content": "b)", "page": 93, "level": 2}}, {"headings_1": {"content": "payments to settle outstanding claims and to improve the Authority\u2019s budgeting process", "page": 93, "level": 2}}]], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "c)", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 93, "level": 2}}, {"headings_1": {"content": "b)", "page": 93, "level": 2}}], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Delayed compensation for Project Affected Persons and Acquisition of Right of Way for Road Projects (Projects- Kampala Jinja Expressway, Hoima Wanseko)", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 93, "level": 2}}, {"headings_1": {"content": "b)", "page": 93, "level": 2}}], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "I observed delays in compensation of Project Affected Persons and hence Acquisition of the Right of Way. The majority of Project Affected Persons are compensated beyond the stipulated six-month period after approval of the Valuation Reports by the Chief Government Valuer. For the KJE Project, the construction works are planned to commence in January 2022. However, 21% of the approved compensation amount worth UGX.92,571,144,970 has not yet been paid, with less than 6 months to the scheduled commencement date which is likely to impede timely handover of the project corridor and timely commencement of works. In addition, compensation for properties within volume 5 comprising Kasokoso area had not yet been assessed. \n81 \nThe Accounting Officer explained that a number of issues caused the delays for compensations, such as; lack of proper ownership documents, for example; sales agreements, letters of administration, ownership disputes especially for untitled interests like Kibanja or customary land, absentee landlords, and; rejection of compensation awards by PAPs that lead to review of the complaint to ascertain validity. I advised the Accounting Officer to consider using escrow accounts with district local governments for the absentee landlords and PAPs where funds may be deposited so as to aid fast land acquisition.", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 93, "level": 2}}, {"headings_1": {"content": "b)", "page": 93, "level": 2}}, [{"headings_0": {"content": "c)", "page": 93, "level": 2}}, {"headings_1": {"content": "b)", "page": 93, "level": 2}}], [{"headings_0": {"content": "c)", "page": 93, "level": 2}}, {"headings_1": {"content": "b)", "page": 93, "level": 2}}]], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.12.2. Ministry of Works and Transport", "metadata": {"headings": [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}, {"headings_1": {"content": "c)", "page": 93, "level": 2}}], "page": 94, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "a) Failure to maintain district road equipment", "metadata": {"headings": [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}, {"headings_1": {"content": "c)", "page": 93, "level": 2}}], "page": 94, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The inspection of the Ministry\u2019s Regional Mechanical Workshops during August and September 2021 revealed that 21 units of district road equipment which are key in opening and maintaining district roads were left unused in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. This means that the districts that own the said equipment could not maintain their roads and deliver such critical service to the country as planned. In addition, the cost of repair may escalate as other parts also become faulty when the equipment is grounded for a long time. \nThe Accounting Officer explained that the amount budgeted and received to maintain road equipment represents 30% of the total funds required for equipment maintenance. I advised the Accounting Officer to liaise with the responsible authorities to obtain the necessary funding for the full maintenance of the equipment so that the equipment operates and serves the Districts. \nb) Delayed acquisition of land for the Right of Way for the Standard Gauge Railway project (Ministry of Works and Transport) \nThe SGR project was to acquire 5,200 acres of land free of encumbrances at an estimated cost of UGX 534.6 bn for the Right of Way (ROW) for the construction of the Kampala \u2013 Malaba SGR route by October 2016. However, by September 2021 only 1,296 acres (25%) had been acquired at a cost of UGX 95.3 bn. Additionally, the project had not obtained titles for the acquired land. There are risks of subsequent compensation for the land already paid for and failure to acquire all the land needed for the full realization of the project. \nThe Accounting Officer explained that currently, land acquisition is one of the core activities of the project. He further explained that the releases however have been going down in comparison to the annual budgets. I advised the Accounting Officer to obtain and transfer land titles to Government for the land paid for and expedite the acquisition of all the land needed for the project. \n82", "metadata": {"headings": [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}, {"headings_1": {"content": "c)", "page": 93, "level": 2}}, [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}, {"headings_1": {"content": "c)", "page": 93, "level": 2}}], [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}, {"headings_1": {"content": "c)", "page": 93, "level": 2}}], [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}, {"headings_1": {"content": "c)", "page": 93, "level": 2}}], [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}, {"headings_1": {"content": "c)", "page": 93, "level": 2}}], [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}, {"headings_1": {"content": "c)", "page": 93, "level": 2}}]], "page": 94, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.12.3. Uganda Railways Corporation", "metadata": {"headings": [{"headings_0": {"content": "3.12.3. Uganda Railways Corporation", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "a) Procurement, supply, delivery, training and commissioning of four (4) used locomotives", "metadata": {"headings": [{"headings_0": {"content": "3.12.3. Uganda Railways Corporation", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "URC contracted M/S GRP Leasing Africa for the supply, delivery, training and commissioning of four (4) used locomotives under procurement reference; URC/SUPLS/2020-11/0001 at UGX.41,323,768,935. However, I noted that the bidder did not comply with some requirements within the bid document which were supposed to be the basis of evaluation. Despite the non-compliance, the bid was evaluated without following the evaluation criteria for Technical stage contrary to the regulations. Non-compliance with the evaluation criteria may have led to delivery of unsuitable locomotives at an inflated cost. Important to note was that the locomotives could not turn at the existing turning points in the country. Therefore, the Corporation will incur un-planned costs of providing turning points for the locomotives.", "metadata": {"headings": [{"headings_0": {"content": "3.12.3. Uganda Railways Corporation", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The Accounting Officer further explained that the limiting turning curvature for the 98 class locomotives is 26 degrees whereas the existing railway triangle had some sections with sharper curvature of less than 26 degrees presumably because the existing triangle design considered the existing locomotive fleet prior to purchase of the new locomotives with different design specifications to safely change direction at the triangle. The physical constraints of the triangle including 2 bridges over Nakivubo channel, high voltage electricity transmission line pylon and the Kampala Flyover Project Right of Way have limited any possible improvements in the triangle alignment to relax the limiting curvature. I advised the Accounting Officer to always ensure that Evaluation Committees", "metadata": {"headings": [{"headings_0": {"content": "3.12.3. Uganda Railways Corporation", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "check for bids\u2019 responsiveness to the criteria set in the bid documents and recommend", "metadata": {"headings": [{"headings_0": {"content": "check for bids\u2019 responsiveness to the criteria set in the bid documents and recommend", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.3. Uganda Railways Corporation", "page": 95, "level": 2}}], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "only fully responsive bids for award of contracts. \nb) Lack of Land titles - UGX 91,832,636,500 \nI noted that Uganda Railways Corporation land worth UGX.91,832,636,500 lacked land", "metadata": {"headings": [{"headings_0": {"content": "check for bids\u2019 responsiveness to the criteria set in the bid documents and recommend", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.3. Uganda Railways Corporation", "page": 95, "level": 2}}, [{"headings_0": {"content": "check for bids\u2019 responsiveness to the criteria set in the bid documents and recommend", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.3. Uganda Railways Corporation", "page": 95, "level": 2}}], [{"headings_0": {"content": "check for bids\u2019 responsiveness to the criteria set in the bid documents and recommend", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.3. Uganda Railways Corporation", "page": 95, "level": 2}}]], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "titles as evidence of URC\u2019s rights to own and use the property. Management\u2019s efforts to", "metadata": {"headings": [{"headings_0": {"content": "titles as evidence of URC\u2019s rights to own and use the property. Management\u2019s efforts to", "page": 95, "level": 2}}, {"headings_1": {"content": "check for bids\u2019 responsiveness to the criteria set in the bid documents and recommend", "page": 95, "level": 2}}], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "secure the land titles appear remote. Lack of land titles led to the Corporation\u2019s land to have been heavily encroached upon and grabbed as was observed during field inspection. \nThe Accounting Officer explained that Management was pursuing the titling of land in various locations. I advised the Accounting Officer to expedite the completion of Management interventions and processing of titles for all URC land.", "metadata": {"headings": [{"headings_0": {"content": "titles as evidence of URC\u2019s rights to own and use the property. Management\u2019s efforts to", "page": 95, "level": 2}}, {"headings_1": {"content": "check for bids\u2019 responsiveness to the criteria set in the bid documents and recommend", "page": 95, "level": 2}}, [{"headings_0": {"content": "titles as evidence of URC\u2019s rights to own and use the property. Management\u2019s efforts to", "page": 95, "level": 2}}, {"headings_1": {"content": "check for bids\u2019 responsiveness to the criteria set in the bid documents and recommend", "page": 95, "level": 2}}]], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.12.4. Uganda Civil Aviation Authority", "metadata": {"headings": [{"headings_0": {"content": "3.12.4. Uganda Civil Aviation Authority", "page": 95, "level": 4}}, {"headings_1": {"content": "titles as evidence of URC\u2019s rights to own and use the property. Management\u2019s efforts to", "page": 95, "level": 2}}], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "a) Delayed revision of the Financing Agreement for the Exim Bank loan for Upgrading and Expansion of the Entebbe International Airport (EIA) Phase I Project \nUCAA entered into an agreement with China Communications Construction Company (CCCC) on 8 th October 2014 for the upgrading and expansion of the EIA Phase I. To obtain funding for this project, the Government of Uganda (GoU) represented by Ministry of Finance Planning and Economic Development (MoFPED) entered into a 20", "metadata": {"headings": [{"headings_0": {"content": "3.12.4. Uganda Civil Aviation Authority", "page": 95, "level": 4}}, {"headings_1": {"content": "titles as evidence of URC\u2019s rights to own and use the property. Management\u2019s efforts to", "page": 95, "level": 2}}, [{"headings_0": {"content": "3.12.4. Uganda Civil Aviation Authority", "page": 95, "level": 4}}, {"headings_1": {"content": "titles as evidence of URC\u2019s rights to own and use the property. Management\u2019s efforts to", "page": 95, "level": 2}}]], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "years\u2019 concessional loan agreement not exceeding Japanese Yuan One Billion, two", "metadata": {"headings": [{"headings_0": {"content": "years\u2019 concessional loan agreement not exceeding Japanese Yuan One Billion, two", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.4. Uganda Civil Aviation Authority", "page": 95, "level": 4}}], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "hundred and sixty million (\u00a5 1,260,000,000), equivalent to USD Two Hundred Million ($200,000,000) with the Export-Import (EXIM) Bank of China on 31 st March 2015. \n83 \nSubsequently, MoFPED entered into an on-lending agreement with the UCAA which transferred the following loan obligations to the Authority: - \na) Semi-annual loan repayment within 13 years after the grace period of 7 years at an interest rate of 2% p.a on the principal amount drawn for the actual number of days elapsed from a 360-day year.", "metadata": {"headings": [{"headings_0": {"content": "years\u2019 concessional loan agreement not exceeding Japanese Yuan One Billion, two", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.4. Uganda Civil Aviation Authority", "page": 95, "level": 4}}, [{"headings_0": {"content": "years\u2019 concessional loan agreement not exceeding Japanese Yuan One Billion, two", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.4. Uganda Civil Aviation Authority", "page": 95, "level": 4}}], [{"headings_0": {"content": "years\u2019 concessional loan agreement not exceeding Japanese Yuan One Billion, two", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.4. Uganda Civil Aviation Authority", "page": 95, "level": 4}}], [{"headings_0": {"content": "years\u2019 concessional loan agreement not exceeding Japanese Yuan One Billion, two", "page": 95, "level": 2}}, {"headings_1": {"content": "3.12.4. Uganda Civil Aviation Authority", "page": 95, "level": 4}}]], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "b)", "metadata": {"headings": [{"headings_0": {"content": "b)", "page": 96, "level": 2}}, {"headings_1": {"content": "years\u2019 concessional loan agreement not exceeding Japanese Yuan One Billion, two", "page": 95, "level": 2}}], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Payment of a management fee on the aggregate amount of the facility equal to \u00a5 3,150,000 (USD 500,000) in one lump sum within 30 days after the effective date of the agreement with EXIM Bank but not later than the first disbursement. \nc) Semi-annual payment of commitment fees calculated at 0.25% per annum during the loan availability period. \nOther terms of the agreements relating to the loan included: \na) The Repayment Reserve account shall be used to maintain the minimum amount of balance as a debt service reserve required by the lender. \nb) Banking of Revenue collections on Escrow Accounts, and ensuring that withdrawals are based on approvals of the lender.", "metadata": {"headings": [{"headings_0": {"content": "b)", "page": 96, "level": 2}}, {"headings_1": {"content": "years\u2019 concessional loan agreement not exceeding Japanese Yuan One Billion, two", "page": 95, "level": 2}}, [{"headings_0": {"content": "b)", "page": 96, "level": 2}}, {"headings_1": {"content": "years\u2019 concessional loan agreement not exceeding Japanese Yuan One Billion, two", "page": 95, "level": 2}}], [{"headings_0": {"content": "b)", "page": 96, "level": 2}}, {"headings_1": {"content": "years\u2019 concessional loan agreement not exceeding Japanese Yuan One Billion, two", "page": 95, "level": 2}}], [{"headings_0": {"content": "b)", "page": 96, "level": 2}}, {"headings_1": {"content": "years\u2019 concessional loan agreement not exceeding Japanese Yuan One Billion, two", "page": 95, "level": 2}}]], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "c)", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 96, "level": 2}}, {"headings_1": {"content": "b)", "page": 96, "level": 2}}], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Budgeting and Approval of Annual budgets by the lender for funds on Escrow", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 96, "level": 2}}, {"headings_1": {"content": "b)", "page": 96, "level": 2}}], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Accounts.", "metadata": {"headings": [{"headings_0": {"content": "Accounts.", "page": 96, "level": 2}}, {"headings_1": {"content": "c)", "page": 96, "level": 2}}], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "d)", "metadata": {"headings": [{"headings_0": {"content": "d)", "page": 96, "level": 2}}, {"headings_1": {"content": "Accounts.", "page": 96, "level": 2}}], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Paying semi-annually to the lender a commitment fee calculated at the rate set forth in concessional loan agreement (which is 0.25%) on the undrawn and un-cancelled balance of the facility. \nBecause UCAA was not prepared to meet the terms and conditions of the loan agreement, several meetings were held with the MoFPED and the MoWT and a", "metadata": {"headings": [{"headings_0": {"content": "d)", "page": 96, "level": 2}}, {"headings_1": {"content": "Accounts.", "page": 96, "level": 2}}, [{"headings_0": {"content": "d)", "page": 96, "level": 2}}, {"headings_1": {"content": "Accounts.", "page": 96, "level": 2}}]], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "resolution was made to have a Ugandan team headed by Uganda\u2019s Ambassador to", "metadata": {"headings": [{"headings_0": {"content": "resolution was made to have a Ugandan team headed by Uganda\u2019s Ambassador to", "page": 96, "level": 2}}, {"headings_1": {"content": "d)", "page": 96, "level": 2}}], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "China, to engage Exim bank for a renegotiation of the loan terms and conditions. At the time, the Exim Bank had halted payments to the Contractor. \nThe Accounting officer explained that as per the Attorney Generals guidance dated 5th November 2021, in his opinion none of the clauses in the agreement require amendment. \nI advised the Accounting Officer to engage the relevant authorities on the clarity of the consequences of non-compliance with the terms and conditions that directly affect", "metadata": {"headings": [{"headings_0": {"content": "resolution was made to have a Ugandan team headed by Uganda\u2019s Ambassador to", "page": 96, "level": 2}}, {"headings_1": {"content": "d)", "page": 96, "level": 2}}, [{"headings_0": {"content": "resolution was made to have a Ugandan team headed by Uganda\u2019s Ambassador to", "page": 96, "level": 2}}, {"headings_1": {"content": "d)", "page": 96, "level": 2}}], [{"headings_0": {"content": "resolution was made to have a Ugandan team headed by Uganda\u2019s Ambassador to", "page": 96, "level": 2}}, {"headings_1": {"content": "d)", "page": 96, "level": 2}}]], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UCAA\u2019s operations, and on the possibility of transferring the loan liability from UCAA\u2019s", "metadata": {"headings": [{"headings_0": {"content": "UCAA\u2019s operations, and on the possibility of transferring the loan liability from UCAA\u2019s", "page": 96, "level": 2}}, {"headings_1": {"content": "resolution was made to have a Ugandan team headed by Uganda\u2019s Ambassador to", "page": 96, "level": 2}}], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "books to MoFPED.", "metadata": {"headings": [{"headings_0": {"content": "UCAA\u2019s operations, and on the possibility of transferring the loan liability from UCAA\u2019s", "page": 96, "level": 2}}, {"headings_1": {"content": "resolution was made to have a Ugandan team headed by Uganda\u2019s Ambassador to", "page": 96, "level": 2}}], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "b) Ratio analysis and financial performance of Uganda Civil Aviation Authority \nThe Authority made a loss for the year under review amounting to UGX 29,321,645,000. On review of the operating margin, I observed that the costs before considering interest and taxes exceeded revenue for the year. I also observed that due to the loss incurred, the Authority generated a negative return on assets of 5%. Further, the Authority could not cover interest accrued on its long-term loans in view of its earnings. Along with the lack of potential to cover loan interest, the Authority had a significant long term liabilities portfolio on its balance sheet, which majorly comprised of the loan from Exim of China to finance the upgrading and expansion of Entebbe International Airport. \n84", "metadata": {"headings": [{"headings_0": {"content": "UCAA\u2019s operations, and on the possibility of transferring the loan liability from UCAA\u2019s", "page": 96, "level": 2}}, {"headings_1": {"content": "resolution was made to have a Ugandan team headed by Uganda\u2019s Ambassador to", "page": 96, "level": 2}}, [{"headings_0": {"content": "UCAA\u2019s operations, and on the possibility of transferring the loan liability from UCAA\u2019s", "page": 96, "level": 2}}, {"headings_1": {"content": "resolution was made to have a Ugandan team headed by Uganda\u2019s Ambassador to", "page": 96, "level": 2}}]], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The Authority\u2019s loss and the ratios computed are an indication that Uganda Civil Aviation", "metadata": {"headings": [{"headings_0": {"content": "The Authority\u2019s loss and the ratios computed are an indication that Uganda Civil Aviation", "page": 97, "level": 2}}, {"headings_1": {"content": "UCAA\u2019s operations, and on the possibility of transferring the loan liability from UCAA\u2019s", "page": 96, "level": 2}}], "page": 97, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Authority did not perform well in terms of profitability and ability to sustain provision of services without further Government intervention for funding and Management strategies to improve revenue generation. The Accounting Officer explained that the performance results during the period were severely impacted by the COVID-19 situation that affected the airport operations of the Authority. \nI advised the Accounting officer to ensure that strategies are devised to improve the revenue generating potential of the Authority, while putting in place cost cutting mechanisms. I also advised the Accounting Officer to engage Government on further financing including clearance of the debt held by Government agencies, to be able to cover the current operating costs as they devise strategies to improve the earning potential of the Authority. \n3.13. HEALTH SECTOR", "metadata": {"headings": [{"headings_0": {"content": "The Authority\u2019s loss and the ratios computed are an indication that Uganda Civil Aviation", "page": 97, "level": 2}}, {"headings_1": {"content": "UCAA\u2019s operations, and on the possibility of transferring the loan liability from UCAA\u2019s", "page": 96, "level": 2}}, [{"headings_0": {"content": "The Authority\u2019s loss and the ratios computed are an indication that Uganda Civil Aviation", "page": 97, "level": 2}}, {"headings_1": {"content": "UCAA\u2019s operations, and on the possibility of transferring the loan liability from UCAA\u2019s", "page": 96, "level": 2}}], [{"headings_0": {"content": "The Authority\u2019s loss and the ratios computed are an indication that Uganda Civil Aviation", "page": 97, "level": 2}}, {"headings_1": {"content": "UCAA\u2019s operations, and on the possibility of transferring the loan liability from UCAA\u2019s", "page": 96, "level": 2}}]], "page": 97, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.13.1. Mulago National Referral Hospital", "metadata": {"headings": [{"headings_0": {"content": "3.13.1. Mulago National Referral Hospital", "page": 97, "level": 4}}, {"headings_1": {"content": "The Authority\u2019s loss and the ratios computed are an indication that Uganda Civil Aviation", "page": 97, "level": 2}}], "page": 97, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "a)", "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 97, "level": 2}}, {"headings_1": {"content": "3.13.1. Mulago National Referral Hospital", "page": 97, "level": 4}}], "page": 97, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Status of key medical equipment", "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 97, "level": 2}}, {"headings_1": {"content": "3.13.1. Mulago National Referral Hospital", "page": 97, "level": 4}}], "page": 97, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "I carried out an assessment of key medical equipment in the hospital. The assessment focused on the functionality and availability of medical equipment in seven key hospital departments, that is; CSSD, radiology, nuclear medicine, ICU, Laundry, clinical laboratories and accidents and emergencies. I noted that some vital medical equipment was in poor working condition, while others were fully not functional and required replacement. The equipment included: autoclaves in the central sterile service department; patient monitors in the accident and emergency surgical unit; blood coagulation machine in the clinical laboratory unit; ICU beds in the intensive care unit, and CT machine in the Radiology department. \nManagement attributed the poor state of medical equipment in the Hospital to the limited funding provided under the capital development budget of the Hospitals. Absence of such essential medical equipment presents a daunting task for the medical workers in the effective execution of their duties. The efficiency of the medical workers is compromised. \nI advised the Accounting Officer to liaise with the MoFPED and development partners to ensure that the funding gaps are covered to have the essential medical equipment provided to the hospital units.", "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 97, "level": 2}}, {"headings_1": {"content": "3.13.1. Mulago National Referral Hospital", "page": 97, "level": 4}}, [{"headings_0": {"content": "a)", "page": 97, "level": 2}}, {"headings_1": {"content": "3.13.1. Mulago National Referral Hospital", "page": 97, "level": 4}}], [{"headings_0": {"content": "a)", "page": 97, "level": 2}}, {"headings_1": {"content": "3.13.1. Mulago National Referral Hospital", "page": 97, "level": 4}}]], "page": 97, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "b)", "metadata": {"headings": [{"headings_0": {"content": "b)", "page": 97, "level": 2}}, {"headings_1": {"content": "a)", "page": 97, "level": 2}}], "page": 97, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Delayed Construction of 150 housing units \nI observed delays in the construction 150 housing units at Mulago Hospital. The contract was awarded on 20 th June 2020 at UGX.30,228,600,856 for a duration of thirty-six (36) months. One year and half down the road, the contractor had not yet completed the foundation of the first block out of the three blocks expected. \n85 \nThe Accounting Officer indicated that the UGX. 4bn cap on the hospital capital expenditure budget creates challenges in undertaking high value capital projects since the absence of funding leads to delays in achievement of project milestones leading to project cost overruns. The Accounting Officer further explained that they have received funds in this Financial Year Budget to pay the contractor and it is expected that by the end of June 2022, the progress of construction shall be at a desirable level. \nI advised the Accounting Officer to follow up with contractor to ensure that the construction of the above staff houses is expedited.", "metadata": {"headings": [{"headings_0": {"content": "b)", "page": 97, "level": 2}}, {"headings_1": {"content": "a)", "page": 97, "level": 2}}, [{"headings_0": {"content": "b)", "page": 97, "level": 2}}, {"headings_1": {"content": "a)", "page": 97, "level": 2}}], [{"headings_0": {"content": "b)", "page": 97, "level": 2}}, {"headings_1": {"content": "a)", "page": 97, "level": 2}}], [{"headings_0": {"content": "b)", "page": 97, "level": 2}}, {"headings_1": {"content": "a)", "page": 97, "level": 2}}], [{"headings_0": {"content": "b)", "page": 97, "level": 2}}, {"headings_1": {"content": "a)", "page": 97, "level": 2}}]], "page": 97, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.13.2. National Drug Authority a) Delayed Construction of the Laboratory Tower", "metadata": {"headings": [{"headings_0": {"content": "3.13.2. National Drug Authority a) Delayed Construction of the Laboratory Tower", "page": 98, "level": 4}}, {"headings_1": {"content": "b)", "page": 97, "level": 2}}], "page": 98, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "NDA is undertaking a Laboratory Tower Construction project at a total contract sum of UGX. 35,849,057,474. The start for the works was 11 th October 2019 and the original completion date was 11 th October 2021. The completion was revised to 07 th March 2022 because of delays. By the time of inspection, UGX 11,847,043,442 had been paid to the contractors. The implementation of the contract was not sufficiently managed leading to delayed works. \nI also noted that changes were made to the original building plans to cater for the adjustments to the outdoor and building basement parking and though the Contract Management Team and the Authority (NDA) had approved the adjustments and works had commenced by the time of audit in August 2021, the amended building plans had not yet been approved by the Metropolitan Physical Planning Authority. Implementation of unapproved building plans poses a risk of loss of the NDA funds in case the responsible Authority (Metropolitan Authority /KCCA) rejects the plans and directs demolition of the works. \nThe Accounting Officer explained that the delays in the completion of works were due to the COVID-19 lockdown that took two phases in 2020 and 2021 which interrupted staff movement, manufacturing of inputs globally and transportation. The Accounting Officer also explained that the consultant submitted the revised drawings on 3rd August 2020 and no response had come through despite numerous follow-ups including that of 15th April 2021. Management promised to continue reminding KCCA to approve the submitted adjusted plans. \nI advised the Accounting Officer to liaise with the contractors to scale up project works to ensure that the project is completed within reasonable timelines. I advised the Accounting Officer to follow up with the Physical Planning Authority/KCCA to ensure that the building plans are approved as soon as possible. \n3.14. SCIENCE, TECHNOLOGY AND INNOVATION SECTOR", "metadata": {"headings": [{"headings_0": {"content": "3.13.2. National Drug Authority a) Delayed Construction of the Laboratory Tower", "page": 98, "level": 4}}, {"headings_1": {"content": "b)", "page": 97, "level": 2}}, [{"headings_0": {"content": "3.13.2. National Drug Authority a) Delayed Construction of the Laboratory Tower", "page": 98, "level": 4}}, {"headings_1": {"content": "b)", "page": 97, "level": 2}}], [{"headings_0": {"content": "3.13.2. National Drug Authority a) Delayed Construction of the Laboratory Tower", "page": 98, "level": 4}}, {"headings_1": {"content": "b)", "page": 97, "level": 2}}], [{"headings_0": {"content": "3.13.2. National Drug Authority a) Delayed Construction of the Laboratory Tower", "page": 98, "level": 4}}, {"headings_1": {"content": "b)", "page": 97, "level": 2}}], [{"headings_0": {"content": "3.13.2. National Drug Authority a) Delayed Construction of the Laboratory Tower", "page": 98, "level": 4}}, {"headings_1": {"content": "b)", "page": 97, "level": 2}}]], "page": 98, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.14.1.", "metadata": {"headings": [{"headings_0": {"content": "3.14.1.", "page": 98, "level": 2}}, {"headings_1": {"content": "3.13.2. National Drug Authority a) Delayed Construction of the Laboratory Tower", "page": 98, "level": 4}}], "page": 98, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Closure of the Ministry of Science, Technology and Innovation \nThe GoU established the Ministry of Science Technology and Innovation in 2016, and it started its operations in 2017/2018 as Vote 023, with a mandate to oversee the overall contribution of the Science Technology and Innovation Sector towards attaining key objectives focused on mainstreaming Science, Technology, and Innovation in the development process of Uganda. \n86 \nAt the time of the transfer, the Ministry had the following subventions and independent projects in pursuit of its objectives;", "metadata": {"headings": [{"headings_0": {"content": "3.14.1.", "page": 98, "level": 2}}, {"headings_1": {"content": "3.13.2. National Drug Authority a) Delayed Construction of the Laboratory Tower", "page": 98, "level": 4}}, [{"headings_0": {"content": "3.14.1.", "page": 98, "level": 2}}, {"headings_1": {"content": "3.13.2. National Drug Authority a) Delayed Construction of the Laboratory Tower", "page": 98, "level": 4}}], [{"headings_0": {"content": "3.14.1.", "page": 98, "level": 2}}, {"headings_1": {"content": "3.13.2. National Drug Authority a) Delayed Construction of the Laboratory Tower", "page": 98, "level": 4}}], [{"headings_0": {"content": "3.14.1.", "page": 98, "level": 2}}, {"headings_1": {"content": "3.13.2. National Drug Authority a) Delayed Construction of the Laboratory Tower", "page": 98, "level": 4}}]], "page": 98, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "i)", "metadata": {"headings": [{"headings_0": {"content": "i)", "page": 99, "level": 3}}, {"headings_1": {"content": "3.14.1.", "page": 98, "level": 2}}], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Uganda National Council for Science and Technology (UNCST);", "metadata": {"headings": [{"headings_0": {"content": "i)", "page": 99, "level": 3}}, {"headings_1": {"content": "3.14.1.", "page": 98, "level": 2}}], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ii)", "metadata": {"headings": [{"headings_0": {"content": "ii)", "page": 99, "level": 3}}, {"headings_1": {"content": "i)", "page": 99, "level": 3}}], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The Presidential Initiative on Banana Industrial Development (PIBID); and iii) Kiira Motors Corporation (KMC).", "metadata": {"headings": [{"headings_0": {"content": "ii)", "page": 99, "level": 3}}, {"headings_1": {"content": "i)", "page": 99, "level": 3}}], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iv)", "metadata": {"headings": [{"headings_0": {"content": "iv)", "page": 99, "level": 3}}, {"headings_1": {"content": "ii)", "page": 99, "level": 3}}], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Uganda Industrial Research Institute (Vote 110), an agency under the ST&I Sector and self-accounting.", "metadata": {"headings": [{"headings_0": {"content": "iv)", "page": 99, "level": 3}}, {"headings_1": {"content": "ii)", "page": 99, "level": 3}}], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "v)", "metadata": {"headings": [{"headings_0": {"content": "v)", "page": 99, "level": 3}}, {"headings_1": {"content": "iv)", "page": 99, "level": 3}}], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The commercialisation of sericulture Technologies and Innovations(TRIDI) \nvi) Presidential Scientific initiative on Epidemics (PRESIDE) is an umbrella organisation for multiple scientific research organisations. \nThe Ministry was later abolished effective 1st July 2021, and its operations were transferred to the President's Office. The Ministry's closure may slow down the developments in the above entities during re-organisation. \nI noted that there were also no transition plans for the merger and continuity of operations of the subventions. Lack of transition arrangements could delay research projects, loss of assets and critical human resources.", "metadata": {"headings": [{"headings_0": {"content": "v)", "page": 99, "level": 3}}, {"headings_1": {"content": "iv)", "page": 99, "level": 3}}, [{"headings_0": {"content": "v)", "page": 99, "level": 3}}, {"headings_1": {"content": "iv)", "page": 99, "level": 3}}], [{"headings_0": {"content": "v)", "page": 99, "level": 3}}, {"headings_1": {"content": "iv)", "page": 99, "level": 3}}]], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.14.2.", "metadata": {"headings": [{"headings_0": {"content": "3.14.2.", "page": 99, "level": 2}}, {"headings_1": {"content": "v)", "page": 99, "level": 3}}], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Un-deployed Staff upon the abolition of the Ministry \nThe Ministry had a structure with a total staff establishment of 154 positions, of which 136 positions had been filled and had a recruitment plan for another fifteen (15) staff of different cadres. \nAs a result of the closure of the Ministry, the staff were rendered redundant and had not received their emoluments by the end of November 2021. In addition, 48 common cadre staff had been transferred back to the Ministry of Public Service, as the technical and support staff employed by the Ministry await their fate. \nI noted that some staff were living under uncertainty, which may lead to redundancy escalation and high costs to the Government. \nManagement explained that the Ministry of Public Service is reviewing the structure, and once it is approved, a validation exercise will be undertaken to determine those who fit in. Those that will not be absorbed will be handled in line with the public service standing orders.", "metadata": {"headings": [{"headings_0": {"content": "3.14.2.", "page": 99, "level": 2}}, {"headings_1": {"content": "v)", "page": 99, "level": 3}}, [{"headings_0": {"content": "3.14.2.", "page": 99, "level": 2}}, {"headings_1": {"content": "v)", "page": 99, "level": 3}}], [{"headings_0": {"content": "3.14.2.", "page": 99, "level": 2}}, {"headings_1": {"content": "v)", "page": 99, "level": 3}}], [{"headings_0": {"content": "3.14.2.", "page": 99, "level": 2}}, {"headings_1": {"content": "v)", "page": 99, "level": 3}}], [{"headings_0": {"content": "3.14.2.", "page": 99, "level": 2}}, {"headings_1": {"content": "v)", "page": 99, "level": 3}}]], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.14.3.", "metadata": {"headings": [{"headings_0": {"content": "3.14.3.", "page": 99, "level": 2}}, {"headings_1": {"content": "3.14.2.", "page": 99, "level": 2}}], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Progress on the COVID-19 Vaccine, Diagnostics and Treatment Projects \nThe Ministry of Science, Technology and Innovation (MOSTI) was appropriated supplementary funding of UGX.31.033Bn, which was meant to support 23 selected projects of scientists and innovators engaged in CoVID-I9 scientific research, including the procurement of specialised machinery and equipment, development of vaccines, drug diagnostics and other operational costs. The funds were divided into the purchase of Equipment (UGX.15.787Bn) and Operational Costs (UGX.15.787Bn). \nAs of 30th June 2021, the Ministry had received 86.5% of the Operational funds and", "metadata": {"headings": [{"headings_0": {"content": "3.14.3.", "page": 99, "level": 2}}, {"headings_1": {"content": "3.14.2.", "page": 99, "level": 2}}, [{"headings_0": {"content": "3.14.3.", "page": 99, "level": 2}}, {"headings_1": {"content": "3.14.2.", "page": 99, "level": 2}}], [{"headings_0": {"content": "3.14.3.", "page": 99, "level": 2}}, {"headings_1": {"content": "3.14.2.", "page": 99, "level": 2}}]], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "100% of the Equipment Funds.", "metadata": {"headings": [{"headings_0": {"content": "100% of the Equipment Funds.", "page": 99, "level": 2}}, {"headings_1": {"content": "3.14.3.", "page": 99, "level": 2}}], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "87 \nOf the 23 projects, five were for Diagnostics, four for the development of Vaccines, nine for the development of treatments, and five for material support to existing projects. \nOf the 23 projects initially selected and funded, 19 progressed while others stalled. Their progress was slowed down by the merger of the Ministry without transition plans and subsequent delays in funding. \nThese delays affect the overall intention of the emergency initiative of averting the adverse effects of COVID-19 on the population. \n3.15. TRADE SECTOR", "metadata": {"headings": [{"headings_0": {"content": "100% of the Equipment Funds.", "page": 99, "level": 2}}, {"headings_1": {"content": "3.14.3.", "page": 99, "level": 2}}, [{"headings_0": {"content": "100% of the Equipment Funds.", "page": 99, "level": 2}}, {"headings_1": {"content": "3.14.3.", "page": 99, "level": 2}}], [{"headings_0": {"content": "100% of the Equipment Funds.", "page": 99, "level": 2}}, {"headings_1": {"content": "3.14.3.", "page": 99, "level": 2}}], [{"headings_0": {"content": "100% of the Equipment Funds.", "page": 99, "level": 2}}, {"headings_1": {"content": "3.14.3.", "page": 99, "level": 2}}]], "page": 99, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.15.1.", "metadata": {"headings": [{"headings_0": {"content": "3.15.1.", "page": 100, "level": 2}}, {"headings_1": {"content": "100% of the Equipment Funds.", "page": 99, "level": 2}}], "page": 100, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Under Absorption of funds by UDC \nUDC received UGX 263.47Bn, from the Government of Uganda, of which only UGX 119.29Bn, (45.3%), was spent by the entity during the year resulting in an unspent balance of UGX. 144.18Bn, (46%) \nOut of the total funds received, UGX.126.2Bn was for Covid-19related interventions, and only UGX.55.9Bn (44.3%) was spent. \nThis may be partly attributed to the release of funds before completion of feasibility studies, the release of funds tagged to specific projects in disregard of UDC project appraisals and the un-timely release of funds, among others. \nUnder-absorption undermines the intention of Government funding for import substitution and export promotion strategies spearheaded by the Corporation and averting the effects of Covid-19.", "metadata": {"headings": [{"headings_0": {"content": "3.15.1.", "page": 100, "level": 2}}, {"headings_1": {"content": "100% of the Equipment Funds.", "page": 99, "level": 2}}, [{"headings_0": {"content": "3.15.1.", "page": 100, "level": 2}}, {"headings_1": {"content": "100% of the Equipment Funds.", "page": 99, "level": 2}}], [{"headings_0": {"content": "3.15.1.", "page": 100, "level": 2}}, {"headings_1": {"content": "100% of the Equipment Funds.", "page": 99, "level": 2}}], [{"headings_0": {"content": "3.15.1.", "page": 100, "level": 2}}, {"headings_1": {"content": "100% of the Equipment Funds.", "page": 99, "level": 2}}], [{"headings_0": {"content": "3.15.1.", "page": 100, "level": 2}}, {"headings_1": {"content": "100% of the Equipment Funds.", "page": 99, "level": 2}}]], "page": 100, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.15.2.", "metadata": {"headings": [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}, {"headings_1": {"content": "3.15.1.", "page": 100, "level": 2}}], "page": 100, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Extent of Implementation of Planned Development Projects by UDC: \nI noted that out of the 17 development project activities planned to be implemented over the year, 15 were funded under the Covid-19 supplementary budget. Two development projects, namely: Soroti Fruit Factory and Feasibility studies & Business Plans, were funded under the normal budget. \nA review of the extent of implementation revealed that; \n", "metadata": {"headings": [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}, {"headings_1": {"content": "3.15.1.", "page": 100, "level": 2}}, [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}, {"headings_1": {"content": "3.15.1.", "page": 100, "level": 2}}], [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}, {"headings_1": {"content": "3.15.1.", "page": 100, "level": 2}}], [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}, {"headings_1": {"content": "3.15.1.", "page": 100, "level": 2}}]], "page": 100, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Only (3) three development projects were fully implemented, i.e., shareholder's loan to Atiak Sugar Factory; Acquisition of shares in Mabale Tea Factory; and Acquisition of shares in Bukoona Agro Processors Limited.\n- Five (5) development projects were partially implemented.\n- Eleven (11) projects were not implemented at all.", "metadata": {"headings": [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}, {"headings_1": {"content": "3.15.1.", "page": 100, "level": 2}}], "page": 100, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "This was attributed to the conditional release of funds tied to specified development projects and inadequate institutional capacity to appraise and implement investment projects. \nUnder-absorption undermines government effort in attaining its goals. \n88", "metadata": {"headings": [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}, {"headings_1": {"content": "3.15.1.", "page": 100, "level": 2}}, [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}, {"headings_1": {"content": "3.15.1.", "page": 100, "level": 2}}], [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}, {"headings_1": {"content": "3.15.1.", "page": 100, "level": 2}}]], "page": 100, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.15.3.", "metadata": {"headings": [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.2.", "page": 100, "level": 2}}], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UNBS Inadequate Capacity in Testing and Enforcing Commodity Standards \nSection 3(1) of the UNBS Act spells out the functions of the Bureau which, among others, include providing for the testing of locally manufactured or imported commodities with a view to determining whether the commodities conform to the standard specification as well as making arrangements or provide facilities for the examination, testing or analysis of commodities and any material or substance from which or with which and how they may be manufactured, produced, processed or treated. However, I noted; \n", "metadata": {"headings": [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.2.", "page": 100, "level": 2}}, [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.2.", "page": 100, "level": 2}}], [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.2.", "page": 100, "level": 2}}]], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UNBS released 633 consignments due to the absence of standards to test these commodities for conformity.", "metadata": {"headings": [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.2.", "page": 100, "level": 2}}], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The Bureau also released 366 consignments without testing product standards due to lack of capacity, which may lead to sub-standard products on the market.", "metadata": {"headings": [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.2.", "page": 100, "level": 2}}], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.2.", "page": 100, "level": 2}}, [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.2.", "page": 100, "level": 2}}]], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Bureau had staff presence at only 27 out of the 170 border entry points. This was attributed to understaffing at the Bureau.", "metadata": {"headings": [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.2.", "page": 100, "level": 2}}], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Although management explained that it had since developed the capacity to test the majority of commodities but it lacked some product standards. \n3.16. TOURISM SECTOR", "metadata": {"headings": [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.2.", "page": 100, "level": 2}}, [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.2.", "page": 100, "level": 2}}]], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.16.1.", "metadata": {"headings": [{"headings_0": {"content": "3.16.1.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.3.", "page": 101, "level": 2}}], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Decreasing Tourism Revenue due to Covid-19 \nOver the last two years, the tourism sector has been greatly hit by the unprecedented effects of the Covid-19 pandemic that has greatly affected all sectors of the economy, including the tourism sector. \nI observed a significant fall in tourism revenue collections for all of the entities in the Sector whose revenue is entirely dependent on tourism. This was attributed to the countrywide restrictions on the movement of persons, including tourists, due to the Covid-19 lockdown. As a result, tourist visitor numbers reduced from 255,711 to 103,812 (40.6%) \nThe reduction in revenue collection has been significant and has directly affected the implementation of the planned activities across the Sector.", "metadata": {"headings": [{"headings_0": {"content": "3.16.1.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.3.", "page": 101, "level": 2}}, [{"headings_0": {"content": "3.16.1.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.3.", "page": 101, "level": 2}}], [{"headings_0": {"content": "3.16.1.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.3.", "page": 101, "level": 2}}], [{"headings_0": {"content": "3.16.1.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.15.3.", "page": 101, "level": 2}}]], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.16.2.", "metadata": {"headings": [{"headings_0": {"content": "3.16.2.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.16.1.", "page": 101, "level": 2}}], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Invasive species removal in the Wildlife Conservation Areas in Uganda \nI noted that most of the Protected Areas in Uganda are currently undergoing ecosystem changes as rangeland infestation by invasive and exotic plant species limits the grazing land. These plant species include; Dichrostachys cinerea, Lantana camara, Parthenium hysterophorus, Opuntia vulgaris, Imperata cylindrica, Maeruade cumbens, Caesalepina decaputala, Acacia hockii, Tecoma Stan, Senna siamea and Thevetia peruviana. \n89 \nDuring my inspection of Queen Elizabeth, Lake Mburo Park, Murchison Falls, and Kidepo Valley National Parks, I noted that these plant species continue to cover large expanses of grazing land despite the Uganda Wildlife Authority's effort to eliminate them. This is reducing the populations of specific grazers such as hippos, buffalos, zebras, topis, and Uganda kobs. \nThis is attributed to climate change and inadequate funding to remove invasive species from the national parks.", "metadata": {"headings": [{"headings_0": {"content": "3.16.2.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.16.1.", "page": 101, "level": 2}}, [{"headings_0": {"content": "3.16.2.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.16.1.", "page": 101, "level": 2}}], [{"headings_0": {"content": "3.16.2.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.16.1.", "page": 101, "level": 2}}], [{"headings_0": {"content": "3.16.2.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.16.1.", "page": 101, "level": 2}}], [{"headings_0": {"content": "3.16.2.", "page": 101, "level": 2}}, {"headings_1": {"content": "3.16.1.", "page": 101, "level": 2}}]], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.16.3.", "metadata": {"headings": [{"headings_0": {"content": "3.16.3.", "page": 102, "level": 2}}, {"headings_1": {"content": "3.16.2.", "page": 101, "level": 2}}], "page": 102, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Merger of entities within the Sector \nOn 22nd February 2021, Cabinet under minute No. 43 (CT 2021), a decision to merge Uganda Wildlife Authority with Uganda Wildlife Conservation Education Centre was undertaken. However, there were no transitional arrangements and plans to facilitate a smooth merger by the time of the audit. \nDelays in mergers create uncertainties among staff, reduce sector performance and subsequently lead to misappropriation of entity assets by disgruntled staff.", "metadata": {"headings": [{"headings_0": {"content": "3.16.3.", "page": 102, "level": 2}}, {"headings_1": {"content": "3.16.2.", "page": 101, "level": 2}}, [{"headings_0": {"content": "3.16.3.", "page": 102, "level": 2}}, {"headings_1": {"content": "3.16.2.", "page": 101, "level": 2}}], [{"headings_0": {"content": "3.16.3.", "page": 102, "level": 2}}, {"headings_1": {"content": "3.16.2.", "page": 101, "level": 2}}]], "page": 102, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.17.", "metadata": {"headings": [{"headings_0": {"content": "3.17.", "page": 102, "level": 2}}, {"headings_1": {"content": "3.16.3.", "page": 102, "level": 2}}], "page": 102, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "HIGHLIGHTS FROM THE AUDIT OF LOWER LOCAL GOVERNMENTS FOR THE PERIOD", "metadata": {"headings": [{"headings_0": {"content": "3.17.", "page": 102, "level": 2}}, {"headings_1": {"content": "3.16.3.", "page": 102, "level": 2}}], "page": 102, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2019/2020", "metadata": {"headings": [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}, {"headings_1": {"content": "3.17.", "page": 102, "level": 2}}], "page": 102, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I undertook an audit of a total of 2,048 Lower Local Governments (Sub-counties, Town Councils and Divisions), covering two financial years 2018/2019 (762 LLGs) and 2019/2020 (1,286 LLGs). \nI noted the following cross cutting issues; \n3.17.1. Under staffing \nI noted that 217 LLGs in FY 2018/2019 and 175 in FY 2019/2020 had significant staffing gaps averaging 48% and 60% shortages respectively. Details are in the table 26 below. \nTable 26 : Understaffing in Lower Local Government", "metadata": {"headings": [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}, {"headings_1": {"content": "3.17.", "page": 102, "level": 2}}, [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}, {"headings_1": {"content": "3.17.", "page": 102, "level": 2}}], [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}, {"headings_1": {"content": "3.17.", "page": 102, "level": 2}}], [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}, {"headings_1": {"content": "3.17.", "page": 102, "level": 2}}]], "page": 102, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Financial Year", "Approved", "Filled up", "Shortage", "Percentage shortage"], ["", "positions", null, null, null], ["2018/2019", "3,847", "2,008", "1,842", "48%"], ["2019/2020 6,797 2,713 3,823 60%", null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}, {"headings_1": {"content": "3.17.", "page": 102, "level": 2}}], "page": 102, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "Source: OAG analysis \nUnderstaffing overstretches the available staff beyond their capacity, creates jobrelated stress to the fewer staff and negatively affects the level of public service delivery to the community. \nThe Accounting Officers explained that staffing at LLG level is a responsibility of the respective Districts and Municipal Councils. \nI advised the Accounting Officers to follow up on the matter with the relevant authorities and ensure that most of the vacancies are filled. \n90", "metadata": {"headings": [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}, {"headings_1": {"content": "3.17.", "page": 102, "level": 2}}, [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}, {"headings_1": {"content": "3.17.", "page": 102, "level": 2}}], [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}, {"headings_1": {"content": "3.17.", "page": 102, "level": 2}}], [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}, {"headings_1": {"content": "3.17.", "page": 102, "level": 2}}], [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}, {"headings_1": {"content": "3.17.", "page": 102, "level": 2}}]], "page": 102, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.17.2.", "metadata": {"headings": [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}, {"headings_1": {"content": "2019/2020", "page": 102, "level": 2}}], "page": 103, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Budget implementation in sample LLGs for FY 2018/2019 and 2019/2020 \nI sampled 627 LLGs for FY 2018/19 and 250 LLGs for FY 2019/20 to assess the implementation of the budget and noted the following significant audit findings: \n3.17.2.1. Performance of Central Government Grants \nThe LLGs sampled budgeted to receive UGX.146,160,919,043 for FY 2018/2019 and 2019/2010 (revised) as Central Government Grants). However, UGX.134,095,135,622(92%) was received resulting into a shortfall of UGX.12,065,783,421(8%) majorly attributed to budget cuts as shown in the table below. \nThis affected service delivery in Lower Local Governments Table 27 : Performance of Central Government Grant", "metadata": {"headings": [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}, {"headings_1": {"content": "2019/2020", "page": 102, "level": 2}}, [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}, {"headings_1": {"content": "2019/2020", "page": 102, "level": 2}}], [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}, {"headings_1": {"content": "2019/2020", "page": 102, "level": 2}}], [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}, {"headings_1": {"content": "2019/2020", "page": 102, "level": 2}}], [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}, {"headings_1": {"content": "2019/2020", "page": 102, "level": 2}}]], "page": 103, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Financial Year", "Revised Budget", "Actual Receipts", "Variance", "Percentage"], ["", null, null, null, "Perfomance"], ["2018/2019", "92,214,094,491", "87,717,635,886", "4,496,458,605", "95%"], ["2019/2020 53,946,824,552 46,377,499,736 7,569,324,816 86%", null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}, {"headings_1": {"content": "2019/2020", "page": 102, "level": 2}}], "page": 103, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Financial Year", "Approved", "Filled up", "Shortage", "Percentage shortage"], "type": "table"}}, {"content": "Source: Financial Statements \nI advised the Accounting Officer to always engage the PS/ST through their respective higher local governments to ensure that all revenue is availed to the entity as planned.", "metadata": {"headings": [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}, {"headings_1": {"content": "2019/2020", "page": 102, "level": 2}}, [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}, {"headings_1": {"content": "2019/2020", "page": 102, "level": 2}}]], "page": 103, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.17.2.2. Local Revenue Performance", "metadata": {"headings": [{"headings_0": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}, {"headings_1": {"content": "3.17.2.", "page": 103, "level": 2}}], "page": 103, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The LLGs sampled had approved budgeted total local revenue for the 2 financial years amounting to UGX.91,399,324,016 (revised) out of which UGX.74,615,525,633(82%) was collected resulting into a shortfall of UGX.16,783,798,383(18%), as shown in the table below: \nTable 28 : Performance of Local Revenue \nFinancial Year Revised Budget Actual Receipts \nVariance Percentage Perfomance \n2018/2019 68,424,052,397 57,321,631,217 11,102,421,180 84% 2019/2020 22,975,271,619 17,293,894,416 5,681,377,203 75% \nSource: OAG analysis \nThe Accounting Officers mainly attributed the underperformance of local revenue in the financial year 2019/2020 to the Covid19 lock down which affected several of their major sources of local revenue. \nI advised the Accounting Officer to always ensure that local revenue is collected as budgeted. \n91", "metadata": {"headings": [{"headings_0": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}, {"headings_1": {"content": "3.17.2.", "page": 103, "level": 2}}, [{"headings_0": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}, {"headings_1": {"content": "3.17.2.", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}, {"headings_1": {"content": "3.17.2.", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}, {"headings_1": {"content": "3.17.2.", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}, {"headings_1": {"content": "3.17.2.", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}, {"headings_1": {"content": "3.17.2.", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}, {"headings_1": {"content": "3.17.2.", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}, {"headings_1": {"content": "3.17.2.", "page": 103, "level": 2}}]], "page": 103, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.17.3. Quality of Financial Statements", "metadata": {"headings": [{"headings_0": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}], "page": 104, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "In my previous year\u2019s reports, I noted that there was still a problem with the presentation of financial statements in the Lower Local Governments. In the financial years under review, I noted that there was an improvement in the quality of financial statements with only 37 (6%) LLGs out of 627 and 22 (9%) out of 250 LLGs in financial years 2018/2019 and 2019/2020 respectively having qualified audit opinions. \nI however noted the following matters; UGX 202, 282,811 was improperly accounted for in FY 2018/2019 and UGX 80,259,257 remained Un accounted for in FY 2019/2020. \nThe most common shortcomings were; Inconsistences in the amounts in the financial statement, Errors in Financial Statements, Incomplete financial statements and notes, wrong presentation of figures in financial statement, failure to prepare financial statements and unsupported figures in the financial statements. \nPreparation of financial statements is a stewardship role in which accountability for application of resources entrusted to Accounting Officers is reported to the stakeholders. Failure to present financial statements properly impairs interpretation and analysis of entity performances. \nThe Accounting Officers attributed this to staff changes that were made in the middle of the financial year, difficulty in acquiring books of accounts from district stores and lack of training. I advised the Accounting Officers to liaise with responsible authorities to ensure that the staffing gaps are addressed and the necessary trainings undertaken.", "metadata": {"headings": [{"headings_0": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}, [{"headings_0": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.2.2. Local Revenue Performance", "page": 103, "level": 2}}]], "page": 104, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.17.4. Land Management in Local Governments", "metadata": {"headings": [{"headings_0": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}], "page": 104, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I noted that 331 (53%) Lower Local Governments out of the 627 in FY 2018/19 and 188 (75%) Lower Local Governments out of 250 in FY 2019/20 sampled respectively had land management challenges such as: \n", "metadata": {"headings": [{"headings_0": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}, [{"headings_0": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}]], "page": 104, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- 41 LLGs in FY 2018/19 and 24 LLGs in FY 2019/20 respectively lacked land titles, including where their headquarters are located.\n- 41 LLGs in FY 2018/19 and 24 LLGs in FY 2019/20 respectively lacked Area Lands Committees or the committees were non-functional.\n- In the circumstances, there is risk of persons trespassing, disputes and litigation.", "metadata": {"headings": [{"headings_0": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}], "page": 104, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Majority of Accounting Officers explained that it was the responsibility of the Districts or Municipal Councils to obtain these land titles. A number of other Accounting Officers cited insufficient funding as a cause for failure to have fully functional land committees \nGovernment should consider taking deliberate steps to fund the survey and titling of all government land at the Local Governments. I also advised the Accounting Officers to constitute the Area land Committees. \n92", "metadata": {"headings": [{"headings_0": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}, [{"headings_0": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}], [{"headings_0": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}, {"headings_1": {"content": "3.17.3. Quality of Financial Statements", "page": 104, "level": 4}}]], "page": 104, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "3.17.5.", "metadata": {"headings": [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}, {"headings_1": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}], "page": 105, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Lack of Urban Physical Planning Committees \nI noted that 32 Town Councils in the two financial years had no Urban Physical Planning Committees in place or the Committees were not fully functional. \nConsequently, physical developments undertaken within the physical planning areas may not have been well determined and managed by the respective LLGs. This was mainly attributed to lack of sufficient funds to operationalize the physical planning committees. \nI advised Government to engage the relevant stakeholders to nominate members and ensure that the committees are fully instituted and are functional. \n93 \nPART 4: INFORMATION SYSTEMS, ENGINEERING, VALUE FOR MONEY AND SPECIAL", "metadata": {"headings": [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}, {"headings_1": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}, [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}, {"headings_1": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}], [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}, {"headings_1": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}], [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}, {"headings_1": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}], [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}, {"headings_1": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}], [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}, {"headings_1": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}]], "page": 105, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "AUDITS", "metadata": {"headings": [{"headings_0": {"content": "AUDITS", "page": 106, "level": 2}}, {"headings_1": {"content": "3.17.5.", "page": 105, "level": 2}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "During the financial year 2020/2021, I undertook three Information Systems audits, three Engineering audits covering 90 projects, eight Value for money audits. In addition, I undertook special and forensic audits which are reported on separately. \nBelow is a summary of the key findings I noted in each category, the details of which are included in individual reports issued separately.", "metadata": {"headings": [{"headings_0": {"content": "AUDITS", "page": 106, "level": 2}}, {"headings_1": {"content": "3.17.5.", "page": 105, "level": 2}}, [{"headings_0": {"content": "AUDITS", "page": 106, "level": 2}}, {"headings_1": {"content": "3.17.5.", "page": 105, "level": 2}}]], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "4.0.", "metadata": {"headings": [{"headings_0": {"content": "4.0.", "page": 106, "level": 3}}, {"headings_1": {"content": "AUDITS", "page": 106, "level": 2}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "metadata": {"headings": [{"headings_0": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}, {"headings_1": {"content": "4.0.", "page": 106, "level": 3}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "4.1. Value for Money Audit and Assessment of Urban Infrastructure projects implemented by 22 Municipal Councils under the USMID-AF Program for projects started in the Financial year 2018/2019", "metadata": {"headings": [{"headings_0": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}, {"headings_1": {"content": "4.0.", "page": 106, "level": 3}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "For the financial year 2020/21 a total of 14 infrastructure projects procured in 2018/2019 under the World Bank funded Uganda Support to Municipal Infrastructure Development-Additional Financing (USMID-AF) Program implemented by 22 Municipal Councils namely Arua, Gulu, Kitgum, Lira, Apac, Soroti, Moroto, Mbale, Tororo, Busia, Kamuli, Jinja, Lugazi, Entebbe, Hoima, Mubende, Fort Portal, Kasese, Mbarara, Ntungamo, Kabale and Masaka were audited and assessment of the performance of these projects across the 22 municipalities carried out including a selected sample of non-USMID i.e. Uganda Road Fund (URF) funded projects, and Schools Facilities Grant (SFG)/Transitional Development Grant (TDG)/Discretional Development Equalisation Grant (DDEG) funded projects implemented in the participating municipalities. \nThe total contract value of the projects assessed was UGX 192,742,021,942. Below is a summary of the Key findings I noted, the details of which are included in the consolidated audit report for the 22 Municipal Councils and the 22 Individual reports issued separately; \n", "metadata": {"headings": [{"headings_0": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}, {"headings_1": {"content": "4.0.", "page": 106, "level": 3}}, [{"headings_0": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}, {"headings_1": {"content": "4.0.", "page": 106, "level": 3}}], [{"headings_0": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}, {"headings_1": {"content": "4.0.", "page": 106, "level": 3}}]], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Overpayments and irregular expenditure on USMID and Non USMID projects were noted during the audit. This comprised of overpayments of UGX. 214,862,488 and UGX 459,323,494 on USMID projects and Non-USMID projects respectively. The audit assessment also revealed various questionable expenditures, irregular payments, and potential financial losses attributable to different contractual irregularities totaling to UGX. 817,571,137 on the USMID funded projects in Arua, Jinja and Mbale", "metadata": {"headings": [{"headings_0": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}, {"headings_1": {"content": "4.0.", "page": 106, "level": 3}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Municipalities.", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- All the municipalities had completed their projects by the time of the audit and the entire infrastructure in the municipalities was in use with the exception of Entebbe whose project was phased. Although the projects were finally completed there were delays in completion of the projects within the stipulated contract timelines.", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- During physical inspection of the municipalities of Mbale, Moroto and Lira, major defects were noted such as missing draining/emptying pipe on the", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "94 \nsoaking tank (leads to poor drainage), Clogged manholes and missing manhole covers, potholes on roads and poor drainage leading to ponding.", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}, [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}]], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- All the participating municipalities implemented environmental protection measures with the exception of Arua Municipality. Further, all the participating municipalities implemented social/safety measures except Soroti and Tororo Municipalities.", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}, [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}]], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Inadequate allocation of funds in the budget for operation and maintenance of USMID infrastructure was noted in the municipalities except for the municipalities of Lira, Hoima, Fort Portal, Masaka and Gulu.", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "I advised the Accounting officers of the Municipal Councils to ensure that;", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- All amounts overpaid are recovered by the respective municipalities.\n- Contractors have updated work programs and delays in delivery of projects within stipulated contract timelines should be penalized by invoking liquidated damages clauses\n- Inspections are carried out during the DLP as some defects can only surface while the structure is in use and report on the progress of the structure during the period and have all the identified major defects rectified.\n- All municipalities should plan, budget and implement operation and maintenance activities to avoid early deterioration of the facilities.", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, {"headings_1": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Conclusion", "metadata": {"headings": [{"headings_0": {"content": "Conclusion", "page": 107, "level": 2}}, {"headings_1": {"content": "Municipalities.", "page": 106, "level": 2}}], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Owing to the challenges faced by the Municipal Councils during the delivery of USMID- AF Urban infrastructure as highlighted in this report, audit observed that these challenges notable improvements have been noted in planning, cost control enforcement of internal controls for certification, supervision and monitoring, and general contract management for the USMID Infrastructure projects, however these gains have not been translated to the Non USMID projects as URF, SFG,DDEG accordingly the Town Clerks must ensure that Non USMID projects are equally effectively monitored and supervised to ensure delivery of the works within the planned cost, quality and time requirements", "metadata": {"headings": [{"headings_0": {"content": "Conclusion", "page": 107, "level": 2}}, {"headings_1": {"content": "Municipalities.", "page": 106, "level": 2}}], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "4.2.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Value for Money audit and assessment of Infrastructure projects implemented by 60 Local Governments under the UgIFT Program for Construction of Seed Schools and Health Facilities in the Education and Health Sectors \nFor the financial year 2020/21 a total of 109 infrastructure projects implemented by 60 Local Governments involving the construction of seed schools and Health centre IIs under the World Bank funded Uganda Inter-Governmental Fiscal Transfer (UgIFT) Programme for Results was audited and assessment of the performance of these projects across the 60 Local Governments municipalities carried out for the Education Sector and Health Sector. \n95 \nUnder the UgIFT programme, the World Bank committed the total of US$500m over the period FY 2018/19 to FY 2023/24 to support decentralized services in Education, Health, Water and Environment, and Agriculture (micro-scale irrigation) as well as support I \nnterventions in Refugee host communities, With this financial support, Government committed to construct Seed Secondary Schools and Upgrade Health Centre IIs to IIIs in Sub-Counties, extend rural water to underserved communities including the newly constructed seed Secondary Schools and Health Centre IIIs, and also provide Small Scale Irrigation equipment to farmers to enhance their productivity. \nThe scope of the audit and assessment covered 53 seed secondary schools\u2019 construction projects with an overall total contract sum of UGX 111,860,803,846 and 57 health centre construction projects with an overall total contract sum of UGX 33,743,610,012. \nBelow is a summary of the Key findings noted, the details of which are included in the consolidated audit report for the 60 Local Governments and the 60 Individual reports issued separately; \n", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}, [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}]], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- In assessing the adequacy of the design process for the buildings, evidence of needs assessment, presence of geotechnical investigations report, design report, drawings and specifications were considered as key requirements, it was observed that detailed design reports were not availed to all local governments by the Ministry of Education.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Overpayments and irregular expenditure amounting to UGX 3,153,351,606 was noted during payment for construction works in some of the seed schools. Furthermore, UGX 3,588,640,939 were made without providing the breakdown of work items being certified.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- During physical inspection of the Seed school infrastructure works, the participating LGs with exception of 3 LGs had defects such as honeycombing in concrete, absence of anti-sag rods, cracks in the ceilings, absence of expansion joint in the ICT blocks, exposed steel reinforcement, inadequate painting in the roof structures.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "The observed defects, if not addressed, will result in increased maintenance costs for the local governments.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- In assessing the adequacy of the design process for the buildings, evidence of needs assessment, presence of geotechnical investigations report, design report, drawings and specifications were considered as key requirements. It was observed that 39 local governments did not carry out needs assessment, geotechnical investigations, produce design reports in addition work specifications were also omitted.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}, [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}]], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Overpayments and irregular expenditure totalling to UGX 920,905,442 were noted during payment for construction works of the Health Centre IIs in LGs and municipalities. Furthermore, UGX 209,175,652 were made without providing the breakdown of work items being certified.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "96", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 107, "level": 2}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "construction of HCs revealed that out of the 56 local governments, only the 4 local governments had evidence that the contractors mobilized all required equipment. Further, only 13 local governments had evidence that the contractors mobilized all required equipment under the construction of seed schools. \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}, [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}]], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Review of land ownership revealed that 7 local governments did not avail any evidence of acquisition or ownership of the land on which the Seed schools and health centres were constructed.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "I advised the Accounting officers of the Local Governments to ensure that; \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}, [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}]], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Prior to implementation of any infrastructural projects of similar nature; all due design procedures such as needs assessment, geotechnical investigations are undertaken and documented by the local governments to facilitate adequate designs.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Overpayments in respect of quantities certified in excess of the actual works executed worth UGX. 3,153,351,606 in the Education Sector and UGX. 920,905,442 in the Health Sector should be recovered. In addition, the technical officers should review the other items that were not part of the audit sample and have additional checks in the certification process to minimise the errors in quantification.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Investigate the basis of payment of the questionable amounts totalling to UGX.3,588,640,939 in the Education Sector and UGX.209,175,652 in the Health Sector and take appropriate action.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- Enforce the requirement for contractors to fully mobilize adequate equipment to undertake the works. In addition, any demobilization during contract implementation should be with the written approval of the project manager/supervisor.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- All the defects/omissions observed should be corrected. Furthermore, additional inspection of the contractor\u2019s works should be undertaken and any defects identified remedied immediately.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}, [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}]], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Fast track the process of obtaining formal ownership of the land on which the infrastructure is being constructed. Going forward, Accounting Officers should ensure that projects of similar nature are constructed on land that is formally owned by the respective local government.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, {"headings_1": {"content": "4.2.", "page": 107, "level": 3}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Conclusion", "metadata": {"headings": [{"headings_0": {"content": "Conclusion", "page": 109, "level": 2}}, {"headings_1": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Owing to the challenges faced by the various local governments during the delivery of UgIFT infrastructure projects in the education and health sectors as highlighted in this report, audit observed that these challenges are a result of gaps/weaknesses in the planning and costing of works, enforcement of internal controls for certification, supervision and monitoring, and general contract management. \n97 \nAccordingly, the relevant stakeholders should enhance the capacities of the local governments through involvement of local governments in the planning for future projects of similar nature, organizing tailor made trainings for technical staff, review of the staff structure in the engineering department and ensure that it is adequate and appropriately staffed. The relevant ministries should develop standardized guidelines for costing of civil works and strengthen the monitoring and supervision role in local governments.", "metadata": {"headings": [{"headings_0": {"content": "Conclusion", "page": 109, "level": 2}}, {"headings_1": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, [{"headings_0": {"content": "Conclusion", "page": 109, "level": 2}}, {"headings_1": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], [{"headings_0": {"content": "Conclusion", "page": 109, "level": 2}}, {"headings_1": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}]], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "4.3.", "metadata": {"headings": [{"headings_0": {"content": "4.3.", "page": 110, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 109, "level": 2}}], "page": 110, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Engineering Audit of Selected Road and Building Projects in Kampala Capital City Authority (KCCA) \nFor the financial year 2020/21, a total of 24 public works projects (Road upgrade/rehabilitation, signalization of road junctions, and building projects) with a total contract sum/value of UGX.333.72tn were implemented by KCCA. A sample of Eight (8) projects (road, signalization and building projects) with a contract value of UGX. 276.92tn. were selected for audit. This sample represents 82.98% of the value of the 24 projects. \nEight (8) of the KCCA projects were sampled for audit comprising of three (3) road projects funded by the World Bank under the Second Kampala Institutional and Infrastructure Development Project (KIIDP 2) and five (5) projects funded by the Government of Uganda (GoU). The five projects funded by GoU comprised of three (3) road upgrading/ rehabilitation projects and two (2) building projects, the following key observations were noted on these projects", "metadata": {"headings": [{"headings_0": {"content": "4.3.", "page": 110, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 109, "level": 2}}, [{"headings_0": {"content": "4.3.", "page": 110, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 109, "level": 2}}], [{"headings_0": {"content": "4.3.", "page": 110, "level": 3}}, {"headings_1": {"content": "Conclusion", "page": 109, "level": 2}}]], "page": 110, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "i.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 110, "level": 2}}, {"headings_1": {"content": "4.3.", "page": 110, "level": 3}}], "page": 110, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Delayed relocation of existing services", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 110, "level": 2}}, {"headings_1": {"content": "4.3.", "page": 110, "level": 3}}], "page": 110, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Delayed relocation of existing utilities for water and power for the three KIIDP road projects of Kulambira ring road 4.82Km, spur to Najjera road 0.7Km, Nakawa Ntinda road 2.8Km, Kabuusu \u2013Bunamwaya \u2013 Lweza road 8.06Km and Lukuli road 7.71Km resulted in significant delays in execution of road works by up to 17 months. The Accounting Officer explained that public utility services by Statutory Undertakers (UMEME, NITA, UG POLICE, NWSC and UTL) in particular Kampala City are so complex that even the owners/operators do not know the exact location of their infrastructure, In addition, obtaining of shut-down permits from UMEME was always delayed as UMEME had to fit request within their planned shutdown programme. \nI advised the Accounting Officer to ensure that relocation of services is implemented in time, and works executed as per the approved work programme.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 110, "level": 2}}, {"headings_1": {"content": "4.3.", "page": 110, "level": 3}}, [{"headings_0": {"content": "i.", "page": 110, "level": 2}}, {"headings_1": {"content": "4.3.", "page": 110, "level": 3}}]], "page": 110, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ii.", "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}, {"headings_1": {"content": "i.", "page": 110, "level": 2}}], "page": 110, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Unjustified and overpayments amounting to UGX 1.355Bn \nIt was noted that on some of the projects, payments equivalent to UGX.1.355Bn had been made for quantities of works in excess of those executed, not backed up by the necessary payment supporting documentation or contrary to the contract conditions as follows; \n98 \nTable 29 : Unjustified Payments and Overpayments", "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}, {"headings_1": {"content": "i.", "page": 110, "level": 2}}, [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}, {"headings_1": {"content": "i.", "page": 110, "level": 2}}], [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}, {"headings_1": {"content": "i.", "page": 110, "level": 2}}], [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}, {"headings_1": {"content": "i.", "page": 110, "level": 2}}]], "page": 110, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["S/No", "Project Name", "Payment (UGX)", "Remarks"], ["1", "Upgrading to Paved Standards of", "80,849,062", "Payment of Unverified"], ["", "Kulambiro Ring Road (4.82km)", null, "NITA Relocations"], [null, "including Spur to Najjera Road 503,716,979.38 Unaccounted for Payments", null, null], [null, "(0.7km), Reconstruction and of for relocation of", null, null], [null, "Dualling of Nakawa Ntinda Road services", null, null], [null, "(2.8km) (Including Signalization of", "215,992,827.81", "Payments for quantities of"], [null, "Four Junctions) and Reconstruction", null, "works in excess of those"], [null, "and Widening of Acacia Avenue", null, "executed"], [null, "(1.45km) (including Signalization of", null, null], [null, "Six Junctions) \u2013 Lot 1", null, null], ["2 Upgrading to paved standard of Kabuusu \u2013Bunamwaya \u2013 Lweza road (8.06Km) \u2013 Lot 2 56,860,150 Irregular Payment for Costs due to Extension of Time 348,214,079.83 Payments for quantities of works in excess of those executed", null, null, null], ["3 Upgrading of Cecila Road (1.3Km) 14,074,910 Payments for quantities of works in excess of those executed", null, null, null], ["4", "Construction of Kitintale Market \u2013", "119,717,000", "Payments for quantities of"], ["", "Phase I", null, "steel reinforcement in"], [null, "", null, "excess of those in the bar"], [null, null, null, "bending schedule"], ["5 Reconstruction of Ntinda II Road 16,213,200 Payments for quantities of works in excess of those executed", null, null, null], ["TOTAL", null, "1,355,638,209", ""], ["", null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}, {"headings_1": {"content": "i.", "page": 110, "level": 2}}], "page": 111, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "I advised the Accounting Officer to ensure that the amounts certified and paid in excess of the quantities executed, unaccounted for payments and irregular/unjustified payments are recovered from the contractors prior to concluding the contracts.", "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}, {"headings_1": {"content": "i.", "page": 110, "level": 2}}], "page": 111, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 111, "level": 2}}, {"headings_1": {"content": "ii.", "page": 110, "level": 2}}], "page": 111, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Delayed Land Acquisitions for the KIIDP Road projects", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 111, "level": 2}}, {"headings_1": {"content": "ii.", "page": 110, "level": 2}}], "page": 111, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "There was delayed acquisition of land by the Authority for the two KIIDP road projects of Kulambiro ring road 4.82 Km, Spur to Najjera road 0.7 Km, Nakawa Ntinda road 2.8 km and Acacia Avenue 1.45 Km under Lot 1, and Kabuusu \u2013 Bunamwaya \u2013 Lweza road 8.06Km for Lot 2 resulting in delays of more than 12 months significantly affected the progress and timely completion of the works on these projects. The Accounting Officer explained that it has always been the plan of KCCA to expedite land expropriation in time and issue commencement orders for sites that are free of any encumbrances, however the delayed land acquisition was caused by absentee land lords, and unwillingness by some PAPs to accept the Chief government Valuers value of compensation. \nI advised the Accounting Officer that for future projects, the entity should ensure that contractors are issued with commencement orders when the site for construction is fully accessible. \n99", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 111, "level": 2}}, {"headings_1": {"content": "ii.", "page": 110, "level": 2}}, [{"headings_0": {"content": "iii.", "page": 111, "level": 2}}, {"headings_1": {"content": "ii.", "page": 110, "level": 2}}], [{"headings_0": {"content": "iii.", "page": 111, "level": 2}}, {"headings_1": {"content": "ii.", "page": 110, "level": 2}}]], "page": 111, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iv.", "metadata": {"headings": [{"headings_0": {"content": "iv.", "page": 112, "level": 2}}, {"headings_1": {"content": "iii.", "page": 111, "level": 2}}], "page": 112, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Failure to undertake Ground Investigations for Building Projects \nDetailed ground investigations to inform the foundation designs were not undertaken during the design of Kitintatle Market and the Maternity ward at Kiswa Health Center. Such omissions can lead to inadequate designs which may compromise the safety of the buildings during usage. The Accounting Officer explained that for the Kitintale Market and Kiswa Health Center Projects, no funds were availed for geotechnical investigations \nI advised the Accounting Officer to ensure that detailed ground investigations are undertaken to ensure that the constructed buildings can safely be put to usage when completed and going forward, the Accounting Officer should ensure that for projects of similar nature, detailed ground investigations are undertaken during the design phase.", "metadata": {"headings": [{"headings_0": {"content": "iv.", "page": 112, "level": 2}}, {"headings_1": {"content": "iii.", "page": 111, "level": 2}}, [{"headings_0": {"content": "iv.", "page": 112, "level": 2}}, {"headings_1": {"content": "iii.", "page": 111, "level": 2}}], [{"headings_0": {"content": "iv.", "page": 112, "level": 2}}, {"headings_1": {"content": "iii.", "page": 111, "level": 2}}]], "page": 112, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "5.0. INFORMATION SYSTEMS AUDITS", "metadata": {"headings": [{"headings_0": {"content": "5.0. INFORMATION SYSTEMS AUDITS", "page": 112, "level": 2}}, {"headings_1": {"content": "iv.", "page": 112, "level": 2}}], "page": 112, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "In accordance with Sections 13 and 22 of the National Audit Act (NAA) 2008, I am mandated to audit all the government investments and carry out special audit engagements that include information technology (IT) Audits. Accordingly, I planned and executed my audits following ISSAI 200: Fundamental Principles of Public-Sector Auditing and INTOSAI 5100 guidance. \nI conducted three (2) audits namely; Information Systems Audit of Civil Aviation Authority; the Academic Information Management System (AIMS) and Uganda National Land Information System (Ug-NLIS). Below are redacted version of my key findings.", "metadata": {"headings": [{"headings_0": {"content": "5.0. INFORMATION SYSTEMS AUDITS", "page": 112, "level": 2}}, {"headings_1": {"content": "iv.", "page": 112, "level": 2}}, [{"headings_0": {"content": "5.0. INFORMATION SYSTEMS AUDITS", "page": 112, "level": 2}}, {"headings_1": {"content": "iv.", "page": 112, "level": 2}}]], "page": 112, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "5.1. Information Systems Audit of Civil Aviation Authority", "metadata": {"headings": [{"headings_0": {"content": "5.1. Information Systems Audit of Civil Aviation Authority", "page": 112, "level": 4}}, {"headings_1": {"content": "5.0. INFORMATION SYSTEMS AUDITS", "page": 112, "level": 2}}], "page": 112, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "i. Disintegrated Systems/Manual Interfaces \nThe entity has twelve independent IT systems which are not integrated to share information. As such, information sharing was purely manual despite being explicitly provided for in the respective system requirements and contracts. This increases the risk of human errors and abuse during data extraction and re- entry. This was attributed to lack of integrated planning for IT interventions. \nFailure to automate sharing of information between systems compromises the data integrity, creates opportunities for fraudulent falsification of records. In addition, maintaining multiple systems increases maintenance costs and increases man hours because of manual extraction and entry of data which would otherwise be used for other productive activities. \nI advised management to comprehensively plan for IT projects. In the meantime, management may explore interfacing the systems as they plan to implement an Enterprise Resource System to ensure that various departments share data seamlessly. \n100", "metadata": {"headings": [{"headings_0": {"content": "5.1. Information Systems Audit of Civil Aviation Authority", "page": 112, "level": 4}}, {"headings_1": {"content": "5.0. INFORMATION SYSTEMS AUDITS", "page": 112, "level": 2}}, [{"headings_0": {"content": "5.1. Information Systems Audit of Civil Aviation Authority", "page": 112, "level": 4}}, {"headings_1": {"content": "5.0. INFORMATION SYSTEMS AUDITS", "page": 112, "level": 2}}], [{"headings_0": {"content": "5.1. Information Systems Audit of Civil Aviation Authority", "page": 112, "level": 4}}, {"headings_1": {"content": "5.0. INFORMATION SYSTEMS AUDITS", "page": 112, "level": 2}}], [{"headings_0": {"content": "5.1. Information Systems Audit of Civil Aviation Authority", "page": 112, "level": 4}}, {"headings_1": {"content": "5.0. INFORMATION SYSTEMS AUDITS", "page": 112, "level": 2}}], [{"headings_0": {"content": "5.1. Information Systems Audit of Civil Aviation Authority", "page": 112, "level": 4}}, {"headings_1": {"content": "5.0. INFORMATION SYSTEMS AUDITS", "page": 112, "level": 2}}]], "page": 112, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ii.", "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 113, "level": 3}}, {"headings_1": {"content": "5.1. Information Systems Audit of Civil Aviation Authority", "page": 112, "level": 4}}], "page": 113, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Lack of Integrated Revenue Systems at CAA", "metadata": {"headings": [{"headings_0": {"content": "Lack of Integrated Revenue Systems at CAA", "page": 113, "level": 2}}, {"headings_1": {"content": "ii.", "page": 113, "level": 3}}], "page": 113, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Despite a big shift to digitalisation and the Authority spending UGX.1.13Bn in acquiring a Passenger Tracking System with the aim of ascertaining the number and identity of passengers on a given flight, two years later, the system was not being used consistently and by-passed from time to time. As a result, the Authority has no independent mechanism to ascertain the number of passengers on each flight, but entirely depends on manual submissions from airlines to bill for revenues. There is a risk of under declaration of passengers which can lead to revenue loss. In addition, the system produces incomplete information. \nUnder the circumstances, there is a risk that the amounts disclosed in the financial statements were not accurate and the system does not provide reliable information. \nI advised management to explore possibilities of enforcing the use of the system. \niii. Failure to capitalise Information System Intangible Assets in the Financial", "metadata": {"headings": [{"headings_0": {"content": "Lack of Integrated Revenue Systems at CAA", "page": 113, "level": 2}}, {"headings_1": {"content": "ii.", "page": 113, "level": 3}}, [{"headings_0": {"content": "Lack of Integrated Revenue Systems at CAA", "page": 113, "level": 2}}, {"headings_1": {"content": "ii.", "page": 113, "level": 3}}], [{"headings_0": {"content": "Lack of Integrated Revenue Systems at CAA", "page": 113, "level": 2}}, {"headings_1": {"content": "ii.", "page": 113, "level": 3}}], [{"headings_0": {"content": "Lack of Integrated Revenue Systems at CAA", "page": 113, "level": 2}}, {"headings_1": {"content": "ii.", "page": 113, "level": 3}}]], "page": 113, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Statements", "metadata": {"headings": [{"headings_0": {"content": "Statements", "page": 113, "level": 2}}, {"headings_1": {"content": "Lack of Integrated Revenue Systems at CAA", "page": 113, "level": 2}}], "page": 113, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Despite spending UGX.4.723Bn on system development, Civil Aviation Authority (CAA) has not capitalised intangible assets. These include licenses, software, operating systems, subscriptions. \nAs a result, the assets value is understated in financial statements. \nManagement explained that they have engaged a consultant to carry out verification of all UCAA Assets; ICT Assets inclusive. \nI advised management to ensure that such assets are properly recorded and disclosed in the financial statements.", "metadata": {"headings": [{"headings_0": {"content": "Statements", "page": 113, "level": 2}}, {"headings_1": {"content": "Lack of Integrated Revenue Systems at CAA", "page": 113, "level": 2}}, [{"headings_0": {"content": "Statements", "page": 113, "level": 2}}, {"headings_1": {"content": "Lack of Integrated Revenue Systems at CAA", "page": 113, "level": 2}}], [{"headings_0": {"content": "Statements", "page": 113, "level": 2}}, {"headings_1": {"content": "Lack of Integrated Revenue Systems at CAA", "page": 113, "level": 2}}], [{"headings_0": {"content": "Statements", "page": 113, "level": 2}}, {"headings_1": {"content": "Lack of Integrated Revenue Systems at CAA", "page": 113, "level": 2}}]], "page": 113, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iv.", "metadata": {"headings": [{"headings_0": {"content": "iv.", "page": 113, "level": 3}}, {"headings_1": {"content": "Statements", "page": 113, "level": 2}}], "page": 113, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Failure to implement Cargo Handling IT Systems \nOne of the major revenue streams of CAA is cargo handling fees levied on the airline operators. Although CAA contracted two companies through concession agreements where 5% is charged on cash exports, 10% on general handling and 10% on standard charge related to aircraft and passenger handling. The Authority does not have an independent system to track and reconcile the revenue collected before charging the percentage as per the concession agreements. The information is not shared in real-time due to lack of appropriate IT systems and they rely on information provided by the contractors. \nThis situation poses a risk of loss of revenue as a result of under-declaration of income from cargo handling operations by the handling companies. \nManagement explained that they have initiated procurement for extension of the Point of Sale (POS) system to new concessionaires. The Specifications include provision for interface with the existing Cargo Management systems. \n101 \nI advised management to expedite the procurement and installation of the system. Meanwhile, CAA should engage the contractors to gain read-only access to the systems and extract accurate information for monitoring and reconciliation.", "metadata": {"headings": [{"headings_0": {"content": "iv.", "page": 113, "level": 3}}, {"headings_1": {"content": "Statements", "page": 113, "level": 2}}, [{"headings_0": {"content": "iv.", "page": 113, "level": 3}}, {"headings_1": {"content": "Statements", "page": 113, "level": 2}}], [{"headings_0": {"content": "iv.", "page": 113, "level": 3}}, {"headings_1": {"content": "Statements", "page": 113, "level": 2}}], [{"headings_0": {"content": "iv.", "page": 113, "level": 3}}, {"headings_1": {"content": "Statements", "page": 113, "level": 2}}], [{"headings_0": {"content": "iv.", "page": 113, "level": 3}}, {"headings_1": {"content": "Statements", "page": 113, "level": 2}}], [{"headings_0": {"content": "iv.", "page": 113, "level": 3}}, {"headings_1": {"content": "Statements", "page": 113, "level": 2}}]], "page": 113, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "v.", "metadata": {"headings": [{"headings_0": {"content": "v.", "page": 114, "level": 3}}, {"headings_1": {"content": "iv.", "page": 113, "level": 3}}], "page": 114, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Tenants/Concessionaires without Point of Sale (POS) machines \nThe Point of Sale (POS) system is being used to track sales of airport tenants to inform the rental charges, which are a percentage of the sales. However, it was noted that after ten years of implementation, only 7 out of the 18 concessioners have POS terminals installed which creates a risk of revenue loss. I also noted that even for those using the POS system, were using them selectively, hence under-declaration of sales. \nIn addition, there is a risk that tax-free goods are being sold to non-passengers compounding revenue losses. This results into loss of revenue both to CAA and", "metadata": {"headings": [{"headings_0": {"content": "v.", "page": 114, "level": 3}}, {"headings_1": {"content": "iv.", "page": 113, "level": 3}}, [{"headings_0": {"content": "v.", "page": 114, "level": 3}}, {"headings_1": {"content": "iv.", "page": 113, "level": 3}}], [{"headings_0": {"content": "v.", "page": 114, "level": 3}}, {"headings_1": {"content": "iv.", "page": 113, "level": 3}}]], "page": 114, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "URA.", "metadata": {"headings": [{"headings_0": {"content": "URA.", "page": 114, "level": 2}}, {"headings_1": {"content": "v.", "page": 114, "level": 3}}], "page": 114, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Management explained that they had 14 concessionaire locations at the deployment of the POS system in 2013. In addition, CAA will deploy a new system to cover the new locations and the procurement has been initiated. \nI advised management to fast-track the procurement and deployment of the new system. \n5.2. Information Systems Audit of the Academic Management Information System", "metadata": {"headings": [{"headings_0": {"content": "URA.", "page": 114, "level": 2}}, {"headings_1": {"content": "v.", "page": 114, "level": 3}}, [{"headings_0": {"content": "URA.", "page": 114, "level": 2}}, {"headings_1": {"content": "v.", "page": 114, "level": 3}}], [{"headings_0": {"content": "URA.", "page": 114, "level": 2}}, {"headings_1": {"content": "v.", "page": 114, "level": 3}}]], "page": 114, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "(AIMS)", "metadata": {"headings": [{"headings_0": {"content": "(AIMS)", "page": 114, "level": 2}}, {"headings_1": {"content": "URA.", "page": 114, "level": 2}}], "page": 114, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "i.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 114, "level": 3}}, {"headings_1": {"content": "(AIMS)", "page": 114, "level": 2}}], "page": 114, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Contested Ownership of the AIMS (Source Code) \nThe Ministry of ICT and National Guidance through its rationalization policy of promoting locally developed information systems agreed with Kyambogo University (KYU) to enhance its E-Kampus for sharing with other Public Universities and Self Accounting Tertiary Institutions (PUSATIs). Subsequently the user requirements were reviewed, functionalities improved and the system was rebranded to AIMS. \nA review of the framework contract between The Ministry of ICT and National Guidance and the supplier (Zeenode Uganda Limited) states that; the purchaser (MoICT&NG) acknowledges and agrees that the supplier and/or its licensors own all intellectual property rights in the services and the documentation. It was brought to my attention during my review that there is a disagreement of ownership of the source code and the parties are in court. \nI await the outcome of the court decision. \n102", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 114, "level": 3}}, {"headings_1": {"content": "(AIMS)", "page": 114, "level": 2}}, [{"headings_0": {"content": "i.", "page": 114, "level": 3}}, {"headings_1": {"content": "(AIMS)", "page": 114, "level": 2}}], [{"headings_0": {"content": "i.", "page": 114, "level": 3}}, {"headings_1": {"content": "(AIMS)", "page": 114, "level": 2}}], [{"headings_0": {"content": "i.", "page": 114, "level": 3}}, {"headings_1": {"content": "(AIMS)", "page": 114, "level": 2}}], [{"headings_0": {"content": "i.", "page": 114, "level": 3}}, {"headings_1": {"content": "(AIMS)", "page": 114, "level": 2}}]], "page": 114, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ii.", "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 115, "level": 3}}, {"headings_1": {"content": "i.", "page": 114, "level": 3}}], "page": 115, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Unclear Ownership of the system \nThe Ministry of ICT & NG undertook the enhancement and deployment at the Public Universities and Self Accounting Tertiary Institutions (PUSATIs) of the E- Kampus into the AIMS under the innovation fund at a cost of UGX 2.1 Bn. Subsequently, the Ministry of ICT & NG procured technical support and maintenance services of the same system. \nHowever, I noted that the \u201cvendor\u201d (Zeenode) was charging UGX. 30,000 per student for use of the system. \nThis casts doubt on the ownership of the system. I further noted that the system was switched off for two weeks December 2020 over non-payment of service and maintenance fees. \nAs earlier noted, the case is before Court. I await Court\u2019s decision.", "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 115, "level": 3}}, {"headings_1": {"content": "i.", "page": 114, "level": 3}}, [{"headings_0": {"content": "ii.", "page": 115, "level": 3}}, {"headings_1": {"content": "i.", "page": 114, "level": 3}}], [{"headings_0": {"content": "ii.", "page": 115, "level": 3}}, {"headings_1": {"content": "i.", "page": 114, "level": 3}}], [{"headings_0": {"content": "ii.", "page": 115, "level": 3}}, {"headings_1": {"content": "i.", "page": 114, "level": 3}}], [{"headings_0": {"content": "ii.", "page": 115, "level": 3}}, {"headings_1": {"content": "i.", "page": 114, "level": 3}}]], "page": 115, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 115, "level": 3}}, {"headings_1": {"content": "ii.", "page": 115, "level": 3}}], "page": 115, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "No right to audit provided in the contract \nThe contract between Ministry of ICT & NG and the supplier did not include any \"right to audit by third party\" clause. As a result, during the execution of the audit, I was denied access to key components of the Information system and I cannot provide assurance on their adequacy. \nManagement explained that it will consider including the clause on Right to Audit software, systems, data, in Contracts in collaboration with MoFPED and PPDA. \nI advised management to engage all stakeholders to make a provision for providing audit assurance in the contract.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 115, "level": 3}}, {"headings_1": {"content": "ii.", "page": 115, "level": 3}}, [{"headings_0": {"content": "iii.", "page": 115, "level": 3}}, {"headings_1": {"content": "ii.", "page": 115, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 115, "level": 3}}, {"headings_1": {"content": "ii.", "page": 115, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 115, "level": 3}}, {"headings_1": {"content": "ii.", "page": 115, "level": 3}}]], "page": 115, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iv.", "metadata": {"headings": [{"headings_0": {"content": "iv.", "page": 115, "level": 3}}, {"headings_1": {"content": "iii.", "page": 115, "level": 3}}], "page": 115, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Failure to update the Source Code held in Escrow \nThe contract between Ministry of ICT & NG and the supplier provides that any additions and inventions added by the purchaser and those that are unique to the purchaser will be documented and copyrighted to the purchaser upon installation and development. \nI noted, however, that even though the AIMS has been in continuous development for the last three years, there is no evidence that the original source code held in Escrow has been updated and neither was copyrighting of all changes to the AIMS after the contract signing. \nManagement acknowledged the omission and stated that the source code was not periodically updated. The Ministry committed to ensure continuous periodic updates to all source code held in Escrow. \nI advised management to keep the code updated in real time.", "metadata": {"headings": [{"headings_0": {"content": "iv.", "page": 115, "level": 3}}, {"headings_1": {"content": "iii.", "page": 115, "level": 3}}, [{"headings_0": {"content": "iv.", "page": 115, "level": 3}}, {"headings_1": {"content": "iii.", "page": 115, "level": 3}}], [{"headings_0": {"content": "iv.", "page": 115, "level": 3}}, {"headings_1": {"content": "iii.", "page": 115, "level": 3}}], [{"headings_0": {"content": "iv.", "page": 115, "level": 3}}, {"headings_1": {"content": "iii.", "page": 115, "level": 3}}], [{"headings_0": {"content": "iv.", "page": 115, "level": 3}}, {"headings_1": {"content": "iii.", "page": 115, "level": 3}}]], "page": 115, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "v.", "metadata": {"headings": [{"headings_0": {"content": "v.", "page": 115, "level": 3}}, {"headings_1": {"content": "iv.", "page": 115, "level": 3}}], "page": 115, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Data Ownership of the AIMS", "metadata": {"headings": [{"headings_0": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}, {"headings_1": {"content": "v.", "page": 115, "level": 3}}], "page": 115, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "A review of the AIMS operations revealed that there is no clear data owner of the universities' data. The system vendor; \n103", "metadata": {"headings": [{"headings_0": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}, {"headings_1": {"content": "v.", "page": 115, "level": 3}}, [{"headings_0": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}, {"headings_1": {"content": "v.", "page": 115, "level": 3}}]], "page": 115, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Has unlimited access to the application that is used to process the PUSATI information.\n- Has control over the AIMS database and operating system environment\n- Has the only Administrator privileges on the AIMS for all the PUSATIs.\n- Issues access rights to the AIMS system users.", "metadata": {"headings": [{"headings_0": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}, {"headings_1": {"content": "v.", "page": 115, "level": 3}}], "page": 116, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nThis presents a conflict of interest as well as data integrity risk when the system developer has continuous access to the production environment. \nManagement explained that Clause 19 (ii) of the Framework contract specifies that each PUSATI shall own its individual data and processes that they run on the System. The Ministry shall ensure that remedial action is taken as per recommendation as part of the new Policy under development. \nI advised management to consider remedial action that would limit the risk of unlimited access and manipulation to both privileged and critical information of the PUSATIs", "metadata": {"headings": [{"headings_0": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}, {"headings_1": {"content": "v.", "page": 115, "level": 3}}, [{"headings_0": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}, {"headings_1": {"content": "v.", "page": 115, "level": 3}}], [{"headings_0": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}, {"headings_1": {"content": "v.", "page": 115, "level": 3}}], [{"headings_0": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}, {"headings_1": {"content": "v.", "page": 115, "level": 3}}]], "page": 116, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "vi.", "metadata": {"headings": [{"headings_0": {"content": "vi.", "page": 116, "level": 3}}, {"headings_1": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}], "page": 116, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "No data protection after contract termination \nI noted that in the framework contract signed between the MoICT & NG and the supplier, there is no provision for how the PUSATI data is to be handled at the end of the contract. Without such a provision, the PUSATIs have no way to require the third party to return institutional data or otherwise dispose of such data in a way that does not jeopardise the information security and reputation of the institutions or their affiliated institutions. \nManagement committed to address the matter as part of the Policy on System development for Government. \nI advised management to devise means of ensuring that the data will be safely returned or destroyed in order to avoid the associated risks.", "metadata": {"headings": [{"headings_0": {"content": "vi.", "page": 116, "level": 3}}, {"headings_1": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}, [{"headings_0": {"content": "vi.", "page": 116, "level": 3}}, {"headings_1": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}], [{"headings_0": {"content": "vi.", "page": 116, "level": 3}}, {"headings_1": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}], [{"headings_0": {"content": "vi.", "page": 116, "level": 3}}, {"headings_1": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}]], "page": 116, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "vii.", "metadata": {"headings": [{"headings_0": {"content": "vii.", "page": 116, "level": 3}}, {"headings_1": {"content": "vi.", "page": 116, "level": 3}}], "page": 116, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Deviation from the Contract terms by ZUL \nAlthough the Framework Contract between MoICT and the suppler stipulates that the supplier shall ensure uninterrupted and error-free services, on 12th December 2020, the supplier without consequence, denied services to all PUSATIs for a period of two weeks citing alleged non-payment by MoICT & NG. This led to loss of revenue, critical time and information loss thus delaying decision making. \nManagement promised to engage the vendor and ensure future contracts guard against such occurrences. \nI advised management to engage the Attorney General and devise means of protecting data as they wait for the disposal of the court case. \n104 \nviii. Sustainability of the AIMS \nThe maintenance contract with the supplier expired in December 2020 and MoICT&NG had to pay the vendor an additional UGX.1Bn to guarantee continued support and maintenance until the 30th June 2021. It was proposed that beyond that period, PUSATIs would meet their own costs at UGX.30,000 per student per year, but there was no agreement or MOU with the system provider to ensure compliance by the PUSATIs. There is a risk of non-continued use of the system despite such investments by government. \nI advised management to ensure that all foreseeable costs of the system are analysed and evaluate sustainability of the project. In future, GoU should aim at outright acquisition or ownership and development of any public information system to avoid escalation of costs and ensure sustainability.", "metadata": {"headings": [{"headings_0": {"content": "vii.", "page": 116, "level": 3}}, {"headings_1": {"content": "vi.", "page": 116, "level": 3}}, [{"headings_0": {"content": "vii.", "page": 116, "level": 3}}, {"headings_1": {"content": "vi.", "page": 116, "level": 3}}], [{"headings_0": {"content": "vii.", "page": 116, "level": 3}}, {"headings_1": {"content": "vi.", "page": 116, "level": 3}}], [{"headings_0": {"content": "vii.", "page": 116, "level": 3}}, {"headings_1": {"content": "vi.", "page": 116, "level": 3}}], [{"headings_0": {"content": "vii.", "page": 116, "level": 3}}, {"headings_1": {"content": "vi.", "page": 116, "level": 3}}], [{"headings_0": {"content": "vii.", "page": 116, "level": 3}}, {"headings_1": {"content": "vi.", "page": 116, "level": 3}}], [{"headings_0": {"content": "vii.", "page": 116, "level": 3}}, {"headings_1": {"content": "vi.", "page": 116, "level": 3}}], [{"headings_0": {"content": "vii.", "page": 116, "level": 3}}, {"headings_1": {"content": "vi.", "page": 116, "level": 3}}]], "page": 116, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ix.", "metadata": {"headings": [{"headings_0": {"content": "ix.", "page": 117, "level": 3}}, {"headings_1": {"content": "vii.", "page": 116, "level": 3}}], "page": 117, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Lack of Change Management Procedures", "metadata": {"headings": [{"headings_0": {"content": "Lack of Change Management Procedures", "page": 117, "level": 2}}, {"headings_1": {"content": "ix.", "page": 117, "level": 3}}], "page": 117, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "According to Section A.12.1.2 of the ISO/IEC 27001:2013, Changes to the organisation, business processes, information processing, facilities and systems that affect information security shall be controlled. I established that no change management policies were in place at either MoICT&NG or the universities in regard to the AIMS and as such, Change Requests from users and other changes deemed fit by the supplier were implemented on the live environment without any documented authorisation from either MoICT or PUSATIs management. \nI advised management to integrate change management policies/procedures in project design and implementation. \n5.3. Information Systems Audit of Uganda National Land Information System (Ug-", "metadata": {"headings": [{"headings_0": {"content": "Lack of Change Management Procedures", "page": 117, "level": 2}}, {"headings_1": {"content": "ix.", "page": 117, "level": 3}}, [{"headings_0": {"content": "Lack of Change Management Procedures", "page": 117, "level": 2}}, {"headings_1": {"content": "ix.", "page": 117, "level": 3}}], [{"headings_0": {"content": "Lack of Change Management Procedures", "page": 117, "level": 2}}, {"headings_1": {"content": "ix.", "page": 117, "level": 3}}]], "page": 117, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "NLIS)", "metadata": {"headings": [{"headings_0": {"content": "NLIS)", "page": 117, "level": 2}}, {"headings_1": {"content": "Lack of Change Management Procedures", "page": 117, "level": 2}}], "page": 117, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The Government of Uganda sought assistance from the World Bank to make reforms in the Lands Sector through the Competitiveness and Enterprise Development Project (CEDP). The Modernizing of the land administration activity was implemented through a project named the \"Design, Supply, Installation and", "metadata": {"headings": [{"headings_0": {"content": "NLIS)", "page": 117, "level": 2}}, {"headings_1": {"content": "Lack of Change Management Procedures", "page": 117, "level": 2}}], "page": 117, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Implementation of the National Land Information System Infrastructure", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], "page": 117, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "(DeSINLISI) by the Ministry of Lands Housing and Urban Development (MLHUD). The main objective of the DeSINLISI) project was to establish a National Land Information System Infrastructure for the entire country to foster efficiency and transparency in land transactions processing as well as uphold the land tenure security. \nI undertook an audit of the system with the aim of assessing it effectiveness in supporting the land registration process to achieve intended objectives. \nBelow are the key findings: i. Land Registration Process \nI reviewed the land registration process and noted the following gaps that have led to poor service delivery: \n105 \n", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}, [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}]], "page": 117, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Despite investing substantial amounts of money in the land system, the land registration processes are largely still manual and no transactions take place without a manual file.", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The system encourages rampant use of agents; sometimes, titles change hands four times before getting to the registrar.", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}, [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}]], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Currently, changes on land titles are effected using manual typewriters, which are prone to error and waste time due to a requirement of scanning out to capture the manual changes.", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- There is no mechanism of communication to clients whose titles are ready; I noted that there are a number of duplicate copies of titles that have not been picked by clients, some as far back as 1997.", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The system does not provide for functionality to perform electronic printing and sealing of land titles as a security feature in the certificate of titles.", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "The above gaps have led to unjustified delays in processing of land transactions, frustrating the public. \nI advised management to automate the land registration process; enhance system functionality to enable registered proprietors to create accounts to eliminate land agents (brokers) and an SMS alert system for the public to keep track of submitted applications. \nii. Subdivision of plots \nThe workflow process is so lengthy as it has seventeen levels of approval with duplicated roles. District physical planners as key technical players were left out of the system workflow process. The system workflow process is not flexible to allow queries at different approval levels without cancellation of the transaction. In addition, the applications involving surveys are submitted physically at the Zonal office, despite the investment in the surveyor's portal to aid the process. \nThe public frustration has led to unethical ways of quickening the process, thus creating fertile ground for corruption. \nManagement explained that it will enhance the land system functionality and workflow process to improve service delivery. \nI advised management to consider a review of the subdivision and workflow process to create efficiency.", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}, [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}], [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, {"headings_1": {"content": "NLIS)", "page": 117, "level": 2}}]], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 118, "level": 3}}, {"headings_1": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Failure to Operationalise the Approved IT Staff Structure", "metadata": {"headings": [{"headings_0": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}, {"headings_1": {"content": "iii.", "page": 118, "level": 3}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "I noted that Ug-NLIS structure has not been operationalized with all senior positions still vacant despite the criticality of system to the country. Notably, system is largely supported by temporary short term contract staff who have not been recruited into main stream public service but continue to perform critical system roles such as database administration. \n106 \nThe use of temporary staff to oversee and support critical IT system exposes the entire investment to high risk. Management explained that they have made submission to the Public Service Commission (PSC). \nI advised management to follow up with the PSC to expedite the process.", "metadata": {"headings": [{"headings_0": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}, {"headings_1": {"content": "iii.", "page": 118, "level": 3}}, [{"headings_0": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}, {"headings_1": {"content": "iii.", "page": 118, "level": 3}}], [{"headings_0": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}, {"headings_1": {"content": "iii.", "page": 118, "level": 3}}], [{"headings_0": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}, {"headings_1": {"content": "iii.", "page": 118, "level": 3}}]], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iv.", "metadata": {"headings": [{"headings_0": {"content": "iv.", "page": 119, "level": 3}}, {"headings_1": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}], "page": 119, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Failure by Uganda Lands Commission (ULC) to Utilise the UG-NLIS \nI reviewed the Land information system and noted that Uganda Land Commission (ULC) does not utilize the Ug-NLIS to process land transactions (leases of public land). I noted that lease transactions were manually processed outside the system. \nIt should be noted that ULC was involved in the development of system and user requirements and acceptance of Ug-NLIS as a solution that meets the Commission\u2019s business needs. Further, I noted that ULC acquired another system which duplicates the functionality of the Ug-NLIS at a cost of UGX.500 million. \nThe investment by ULC in a duplicate land registration system is deemed a wasteful expenditure. Management informed me that the Commission has commenced processing of public leases using the Ug-NLIS. \nI have advised Management to ensure that all public leases processed outside the Ug-NLIS should be captured into the system as a backlog. \nv. Overlapping Land Parcels \nThere are a number of parcels in the system whose geo-referenced coordinates were erroneously captured which created distortions in the cadastral data of the", "metadata": {"headings": [{"headings_0": {"content": "iv.", "page": 119, "level": 3}}, {"headings_1": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}, [{"headings_0": {"content": "iv.", "page": 119, "level": 3}}, {"headings_1": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}], [{"headings_0": {"content": "iv.", "page": 119, "level": 3}}, {"headings_1": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}], [{"headings_0": {"content": "iv.", "page": 119, "level": 3}}, {"headings_1": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}], [{"headings_0": {"content": "iv.", "page": 119, "level": 3}}, {"headings_1": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}], [{"headings_0": {"content": "iv.", "page": 119, "level": 3}}, {"headings_1": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}], [{"headings_0": {"content": "iv.", "page": 119, "level": 3}}, {"headings_1": {"content": "Failure to Operationalise the Approved IT Staff Structure", "page": 118, "level": 2}}]], "page": 119, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Ug-NLIS.", "metadata": {"headings": [{"headings_0": {"content": "Ug-NLIS.", "page": 119, "level": 2}}, {"headings_1": {"content": "iv.", "page": 119, "level": 3}}], "page": 119, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The errors manifest where parcels on the system stretch beyond the boundaries and overreach neighbouring parcels such as road reserves, protected areas and neighbouring plots. Where overlaps exist, the system may create delays in processing of deed plans or titles. \nManagement informed me that it has prioritised cadastral data cleaning. \nI advised Management to institute mechanisms to ensure quality control of survey data from surveyors and input validation. \n107 \n6.0. SPECIAL VERIFICATIONS \nIn accordance with Sections 13 and 22 of the National Audit Act, 2008, I undertook two special verifications in the telecom sector, and below is a summary of my findings;", "metadata": {"headings": [{"headings_0": {"content": "Ug-NLIS.", "page": 119, "level": 2}}, {"headings_1": {"content": "iv.", "page": 119, "level": 3}}, [{"headings_0": {"content": "Ug-NLIS.", "page": 119, "level": 2}}, {"headings_1": {"content": "iv.", "page": 119, "level": 3}}], [{"headings_0": {"content": "Ug-NLIS.", "page": 119, "level": 2}}, {"headings_1": {"content": "iv.", "page": 119, "level": 3}}], [{"headings_0": {"content": "Ug-NLIS.", "page": 119, "level": 2}}, {"headings_1": {"content": "iv.", "page": 119, "level": 3}}], [{"headings_0": {"content": "Ug-NLIS.", "page": 119, "level": 2}}, {"headings_1": {"content": "iv.", "page": 119, "level": 3}}], [{"headings_0": {"content": "Ug-NLIS.", "page": 119, "level": 2}}, {"headings_1": {"content": "iv.", "page": 119, "level": 3}}]], "page": 119, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "6.1.", "metadata": {"headings": [{"headings_0": {"content": "6.1.", "page": 120, "level": 2}}, {"headings_1": {"content": "Ug-NLIS.", "page": 119, "level": 2}}], "page": 120, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Verification of Assets and Liabilities for Uganda Telecom (In-Administration) \nIn accordance with Section 13(2) and 22 of the National Audit Act 2008, I undertook a special audit, for verification of liabilities of UTL comprising preferred taxes, UCC liability, UCECPS, administration costs, creditor payments and TDB Loan and assets on a request by the Minister of Finance, Planning and Economic Development. \nBelow are the findings of the verification;", "metadata": {"headings": [{"headings_0": {"content": "6.1.", "page": 120, "level": 2}}, {"headings_1": {"content": "Ug-NLIS.", "page": 119, "level": 2}}, [{"headings_0": {"content": "6.1.", "page": 120, "level": 2}}, {"headings_1": {"content": "Ug-NLIS.", "page": 119, "level": 2}}], [{"headings_0": {"content": "6.1.", "page": 120, "level": 2}}, {"headings_1": {"content": "Ug-NLIS.", "page": 119, "level": 2}}]], "page": 120, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "i.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}], "page": 120, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Verification of Trade Development Bank Loan \nOut of the claimed USD.16.51 Million by Trade Development Bank, the verified and approved outstanding loan amounted to USD.9.31 Million The balance of USD.7.24 Million which relates to default interest charged during the period from 22 nd May 2017 to 31 st May 2021 when UTL was under administration, could not be verified, as it appears to be contrary to the Ugandan Insolvency Act 2011 and the attendant regulations, which provide that interest payable in respect of any period after the commencement of a liquidation and/or insolvency shall be suspended. \nGovernment was advised to seek the opinion of the Attorney General, before the amount relating to default interest is allowed. \nii. Verification of Other Creditors \nI verified claims from the creditors as at 30 th June 2021 totalling to UGX. 302.74Bn as summarised in the table 30 below; \nTable 30 : Creditors Verified", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}, [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}]], "page": 120, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN", "Item", "Amount - UGX"], ["1", "Consolidated Tax Liability (PAYE, Local Exercise,", "9,786,780,845"], ["", "Withholding Tax, Value Added Tax)", null], ["2 UCC liability 62,469,304,749", null, null], ["3", "UCECPS liability", "2,353,904,321"], ["4 Verified Creditors Liability (Pre & Post Administration period) 63,079,412,417", null, null], ["5", "Un remitted NSSF Deductions", "15, 462, 575,874"], ["6 UTL Pension Liability for former UPTC employees 165,048,246,917", null, null], ["", "Total", "302,737,649,249"]], "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}], "page": 120, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "I noted that creditors worth UGX. 28.74Bn were not verified due to insufficient information and creditors totalling to 336.3Bn were subject to court proceedings and therefore not verified. \n108 \nThe Government should explore ways of settling the above liabilities to avoid litigation and associated costs. \niii. Verification of Non-Current Assets \nThe current estimated value of UTL Non-Current Assets is UGX.184Bn which was computed based on independent valuers reports of M/s Bageine and Company (September 2017) and Elite Realty Limited (June 2018). Adjustments were made for depreciation and disposals since the valuation date to arrive at the current estimated value. There is need for re-valuation by the Chief Government Valuer to ascertain the current market values.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}, [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}]], "page": 120, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "In addition, UTL has a 9.13% shareholding in a company (i.e. WIOCC) which was valued between USD.146.2 \u2013 181.2 million, by an independent valuer commissioned by WIOCC in December 2020. The Administrator further informed me of an ongoing offer by an equity investor into WIOCC, who has valued the company at USD.171 million by the time of my verification. This would imply that the UTL shareholding of 9.13% in WIOCC, could be valued at USD.15.61 Million (i.e. approximately UGX.55.45Bn exchanged at UGX.3,551.71 for one USD), as of 30th June, 2021. This would significantly increase the value of total assets of UTL. \nThere are disputes on ownership of 11 Properties worth UGX.57.5Bn between Uganda Telecom Limited (UTL), POSTA (U) Ltd, Uganda Broadcasting Corporation (UBC), and other entities. \nGovernment should consider resolving the disputes before liquidating the company. iv. Verification of Receivables \nReceivables totalling to UGX.113.65Bn were presented for verification. Due to time limitations and sensitivity of the matter, I could not verify receivables, however the process of verification had commenced under the administrator. I await the outcome of the verification exercise.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}, [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, {"headings_1": {"content": "6.1.", "page": 120, "level": 2}}]], "page": 121, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "6.2.", "metadata": {"headings": [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}, {"headings_1": {"content": "i.", "page": 120, "level": 3}}], "page": 121, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Verification of Terminal Benefits/Pension of former Employees UPTC in Respect of Civil Appeal No. 230 Of 2013 And No.10 Of 2014 Of The Court Of Appeal Of Uganda \nI undertook a country wide verification exercise of 1,837 former employees/ claimants of the defunct Uganda Posts and Telecommunications Corporation (UPTC) in accordance with the orders of the Court of Appeal in respect to Civil Appeal No. 230 of 2013 and No. 10 of 2014. \nBelow are my findings; \nThe claims presented for verification in the actuarial report as at 30 th June 2020 and are summarized in the Table 31 below; \n109 \nTable 31 : Summary of claims presented for Verification", "metadata": {"headings": [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}, {"headings_1": {"content": "i.", "page": 120, "level": 3}}, [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}, {"headings_1": {"content": "i.", "page": 120, "level": 3}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}, {"headings_1": {"content": "i.", "page": 120, "level": 3}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}, {"headings_1": {"content": "i.", "page": 120, "level": 3}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}, {"headings_1": {"content": "i.", "page": 120, "level": 3}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}, {"headings_1": {"content": "i.", "page": 120, "level": 3}}]], "page": 121, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["S/N", "Entity", "Total No. of Claimants", "Claim Amounts as at 30 th June"], ["", null, null, "2020 - UGX"], ["1", "UTL", "1,065", "200,444,057,531"], ["2 UPL 348 35,249,791,537", null, null, null], ["3", "PBUL", "8", "135,780,242"], ["4 UCC 11 691,361,961", null, null, null], ["5", "UPTC", "71", "9,638,276,645"], ["Total 1,503 246,159,267,916", null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}, {"headings_1": {"content": "i.", "page": 120, "level": 3}}], "page": 122, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "I verified the claims presented and summarized the findings per entity as presented below; \ni. Verified Claims \u2013 UGX.213,026,888,318 \nThe total verified amount of UGX.213,026,888,318 is payable to 1,254 claimants under UTL (in-Administration), Uganda Posts Limited (UPL) and the defunct UPTC as summarised in the Table 35 below;", "metadata": {"headings": [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}, {"headings_1": {"content": "i.", "page": 120, "level": 3}}, [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}, {"headings_1": {"content": "i.", "page": 120, "level": 3}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}, {"headings_1": {"content": "i.", "page": 120, "level": 3}}]], "page": 122, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Table 32 : Summary of Verified claims payable", "metadata": {"headings": [{"headings_0": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}, {"headings_1": {"content": "6.2.", "page": 121, "level": 2}}], "page": 122, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["S/N Entity Total No. of Claimants Total claimants verified Total Amount Verified Payable as at June 2021- UGX", null, null, null, null], ["1", "UTL", "1,065", "882", "165,048,246,917"], ["2 UPL 348 337 43,233,738,001", null, null, null, null], ["3", "UPTC", "71", "35", "4,744,903,400"], ["Total 1,484 1,254 213,026,888,318", null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}, {"headings_1": {"content": "6.2.", "page": 121, "level": 2}}], "page": 122, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "I advised the Government to make the necessary budgetary provisions to cater for settlement of the above claims. \nii. Fully Settled Claims \nAlthough the Actuarial report from the Privatisation Unit under the Ministry of Finance, Planning and Economic Development (MoFPED) submitted included claims from former employees of Uganda Communications Commission (UCC) and Post Bank Uganda Limited (PBUL) respectively, from the verification carried out I verified that these entities had duly settled the claims of 21 beneficiaries totalling to UGX.1,124,966,993. \nThis verification gave assurance that the Government had fulfilled its obligation to the respective beneficiaries, thereby eliminating any risk of possible double payment of claims in this regard. \n110", "metadata": {"headings": [{"headings_0": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}, {"headings_1": {"content": "6.2.", "page": 121, "level": 2}}, [{"headings_0": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}, {"headings_1": {"content": "6.2.", "page": 121, "level": 2}}], [{"headings_0": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}, {"headings_1": {"content": "6.2.", "page": 121, "level": 2}}], [{"headings_0": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}, {"headings_1": {"content": "6.2.", "page": 121, "level": 2}}], [{"headings_0": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}, {"headings_1": {"content": "6.2.", "page": 121, "level": 2}}]], "page": 122, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 123, "level": 3}}, {"headings_1": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}], "page": 123, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Conflict between the legal representative and the beneficiaries \nDuring the audit, I obtained information relating to the fact that a section of the claimants had a disagreement with their legal advocate, allegedly from failure to remit funds received from UTL and UPL to all the claimants. UTL in Administration and UPL transferred a total of UGX.4,184,469,245 to the lawyer as part payment of their obligations. \nI advised the Ministry of Finance, Planning and Economic Development (MoFPED) and the Attorney General to take note of the conflict and ensure that the dispute is resolved before funds are disbursed to benefit the rightful claimants.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 123, "level": 3}}, {"headings_1": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}, [{"headings_0": {"content": "iii.", "page": 123, "level": 3}}, {"headings_1": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 123, "level": 3}}, {"headings_1": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}]], "page": 123, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "metadata": {"headings": [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], "page": 123, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "7.1. Value for Money Audit on the Management of Government Investments by Uganda Development Corporation \nThe Government of Uganda has committed over UGX.223.9Bn in various investment projects under Uganda Development Corporation (UDC) over the years 2016/17 to 2019/20. These investments which are highlighted as government priorities from National Development Plan (NDP I), through to NDP III, are meant to promote social and economic development and contribute to poverty eradication by increasing national and regional economic growth and development. \nThe objective of the value for money audit was to assess the effectiveness of UDC processes in the management of Government Investments through planning, implementation and monitoring of such investments. \nI sampled eight (8) investment projects worth UGX. 191.5 Bn as of 30 th June, 2020 including; Soroti Fruit factory, Kigezi Highland Tea factory, Kayonza Tea factory, Mabale tea factory, Luwero Fruits factory, Moroto Cement factory, Isingiro Fruit factory and Atiak Sugar Factory. \nThe following were the key findings; i. Project Planning \nI noted that only one out of the eight selected projects was dully subjected to the planning process representing 12.5%. The objective of the planning process is to justify investment of government funds in identified projects. As a result of ineffective planning, two projects failed to take off while there was a change of scope, cost and implementation strategy for the other five investment projects. \n111 \nUDC management should ensure that all Investment projects follow the due planning and identification processes as documented in the investment guide. This will increase on the success rate for those projects that are properly planned, identified and appraised. \nii. Project Implementation \nAudit noted that UDC had not been able to have five investment projects operating at full capacity as expected representing 37.5% of the eight sampled projects. The projects faced different challenges as summarised in the table 33 below; \nTable 33 : Challenges of Project Implementation", "metadata": {"headings": [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}, [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}]], "page": 123, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["S/N", "Project Name", "Amount Invested as at 30 th June", "Challenge"], ["", null, "2020 (UGX in Bn)", null], ["01", "Soroti Fruit factory", "23.76", "Additional machinery was"], ["", null, null, "procured to cater for the user"], [null, null, null, "needs not identified at planning"], [null, null, null, "stage"], ["02 Kigezi Highland 14.03 Additional funds to support raw material uptake leading to project cost-overruns", null, null, null], ["03", "Mabale Tea Factory", "16.6", "Change of user needs during"], ["", null, null, "implementation"], ["04 Kayonza tea factory 14.06 Project performance is satisfactory however, the objective of the investment decision on the part of Government is yet to be realised.", null, null, null], ["05", "Atiak Sugar factory", "88.8", "Inadequate inputs to match the"], ["", null, null, "factory capacity"], ["Total 157.25", null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], "page": 124, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "Management should improve implementation processes by ensuring that guidelines are in place, and that sufficient staffing is deployed. Additionally, the institution should lobby for a \u2018Fund-based\u2019 financing approach of the institution, instead of \u2018projectised\u2019 financing where funds are sent to UDC already tagged to an investment project to be funded. This will allow flexibility during implementation of investment projects. \n112 \niii. Monitoring and Evaluation \nI noted that the oversight role in all the eight sampled investment projects had not been fully undertaken and thus, the projects were not operating at full capacity as expected. This was greatly attributed to weak governance structures and non-existing/inadequate Boards in those investment projects supported as partnership ventures. This ultimately caused delays in decision making, financing and signing of contractual agreements. \nUDC management should improve the monitoring and oversight role in the government investments by ensuring that the monitoring frameworks are established and followed- up at both management and Board levels. \nOverall Conclusion", "metadata": {"headings": [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}, [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}]], "page": 124, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Government has invested over UGX.200Bn in various sectors of the economy with the objective of boosting value addition mainly in the agricultural sector. There has been a noted increase in both tea and sugar production. It should however be noted that the levels of outputs and other expected benefits are not commensurate with the investments due to challenges of budgeting and planning, lack of feasibility studies and criteria for allocation of funding, inadequate contractual arrangements to clarify roles and targets and limited oversight and monitoring of investments. There is a risk of failure to achieve the intended objectives. There is still potential for improvement by ensuring UDC staffing levels are increased to undertake the above-mentioned tasks. It is also necessary to enhance autonomy for UDC by providing capitalisation instead of project related financing, so that management is flexible in allocation and re-allocate resources where they are urgently required at the time.", "metadata": {"headings": [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, {"headings_1": {"content": "iii.", "page": 123, "level": 3}}], "page": 125, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "7.2.", "metadata": {"headings": [{"headings_0": {"content": "7.2.", "page": 125, "level": 2}}, {"headings_1": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}], "page": 125, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "A Value for Money Draft Audit Report on The Afforestation and Restoration of Selected Central Forest Reserves (CFRs) by the National Forestry Authority (NFA) \nThe National Forestry Authority (NFA) was established under section 52 of the National Forestry and Tree Planting Act, 2003 (NFTPA). The objective of NFA is to manage the Central Forest reserves, expand and promote partnership arrangements, ensure equitable supply of forest and non-forest products and services and enhance organisational sustainability.", "metadata": {"headings": [{"headings_0": {"content": "7.2.", "page": 125, "level": 2}}, {"headings_1": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, [{"headings_0": {"content": "7.2.", "page": 125, "level": 2}}, {"headings_1": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}]], "page": 125, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The country\u2019s forest cover is managed by different stakeholders comprising; Uganda", "metadata": {"headings": [{"headings_0": {"content": "The country\u2019s forest cover is managed by different stakeholders comprising; Uganda", "page": 125, "level": 2}}, {"headings_1": {"content": "7.2.", "page": 125, "level": 2}}], "page": 125, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Wildlife Authority, National Forestry Authority and Privately owned forest plantations. \nThe forest cover loss over the years from 1990 to the last biomass study in 2017 is estimated at 58.9%. Similarly, the CFR forest cover under NFA dropped from 62.5% (791,240ha) of the NFA forest cover to 45.8% (579,257ha) in the same period. This trend was contrary to Sustainable Development Goal 15 which required governments to ensure the restoration of forests and increase forest cover in line with obligations under international agreements by 2020. \nThe overall objective of this audit was to evaluate the effectiveness of the measures put in place by the NFA towards the restoration and establishment of new plantations in the central forest reserves, between the period of 2016 and 2020. \n113 \nThe following are the key findings from the study;", "metadata": {"headings": [{"headings_0": {"content": "The country\u2019s forest cover is managed by different stakeholders comprising; Uganda", "page": 125, "level": 2}}, {"headings_1": {"content": "7.2.", "page": 125, "level": 2}}, [{"headings_0": {"content": "The country\u2019s forest cover is managed by different stakeholders comprising; Uganda", "page": 125, "level": 2}}, {"headings_1": {"content": "7.2.", "page": 125, "level": 2}}], [{"headings_0": {"content": "The country\u2019s forest cover is managed by different stakeholders comprising; Uganda", "page": 125, "level": 2}}, {"headings_1": {"content": "7.2.", "page": 125, "level": 2}}], [{"headings_0": {"content": "The country\u2019s forest cover is managed by different stakeholders comprising; Uganda", "page": 125, "level": 2}}, {"headings_1": {"content": "7.2.", "page": 125, "level": 2}}], [{"headings_0": {"content": "The country\u2019s forest cover is managed by different stakeholders comprising; Uganda", "page": 125, "level": 2}}, {"headings_1": {"content": "7.2.", "page": 125, "level": 2}}]], "page": 125, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "i.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 126, "level": 3}}, {"headings_1": {"content": "The country\u2019s forest cover is managed by different stakeholders comprising; Uganda", "page": 125, "level": 2}}], "page": 126, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Restoration and establishment of new plantations \nAudit noted that management achieved 11,173ha (78%) of their planned outputs (14,277ha) for both restoration planting and establishing new tree plantations, which contributed to only 0.88% of the national forest cover (1,265,742ha) over the four-year period. \nConsidering the current rate of forest restoration, it will require 75.8 years for NFA to restore the national forest cover to 62.5% of was it was in the year 1990.Similarly, even if NFA was to meet its targets of 14,277ha in the four-year period, it would still take 59.3 years to restore the CFRs to the 1990 forest cover in Uganda. \nThe non-achievement of targets to restore forest cover was caused by inadequacies in the planning and budgeting process; land management; monitoring and inspections; and collaboration with institutional stakeholders.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 126, "level": 3}}, {"headings_1": {"content": "The country\u2019s forest cover is managed by different stakeholders comprising; Uganda", "page": 125, "level": 2}}, [{"headings_0": {"content": "i.", "page": 126, "level": 3}}, {"headings_1": {"content": "The country\u2019s forest cover is managed by different stakeholders comprising; Uganda", "page": 125, "level": 2}}], [{"headings_0": {"content": "i.", "page": 126, "level": 3}}, {"headings_1": {"content": "The country\u2019s forest cover is managed by different stakeholders comprising; Uganda", "page": 125, "level": 2}}], [{"headings_0": {"content": "i.", "page": 126, "level": 3}}, {"headings_1": {"content": "The country\u2019s forest cover is managed by different stakeholders comprising; Uganda", "page": 125, "level": 2}}]], "page": 126, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ii.", "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 126, "level": 3}}, {"headings_1": {"content": "i.", "page": 126, "level": 3}}], "page": 126, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Coordination and planning in the Forest Sector \nI noted weaknesses in coordination in the regulation of activities/projects under a single mandate that impact of national forest cover. There are inconsistencies and inadequacies in mainstreaming initiatives to increase forest cover across government and private sector which has led to limited national forest coverage of 12.4% and NFA forest cover of 45.8%.", "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 126, "level": 3}}, {"headings_1": {"content": "i.", "page": 126, "level": 3}}, [{"headings_0": {"content": "ii.", "page": 126, "level": 3}}, {"headings_1": {"content": "i.", "page": 126, "level": 3}}]], "page": 126, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], "page": 126, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Monitoring and Evaluation, and inspections. \nIt was observed that out of the expected 16 monitoring reports in the four-year period ending 30th June, 2020, only 4 (25%) were prepared in the entire four-year period. In addition, NFA budgeted to receive UGX.320m for monitoring in the four years under review, however, it received UGX.91.8million (29%) of which UGX 88.8million was spent. There was limited uptake of monitoring and evaluation recommendations which led to led to destruction of the newly restored forests by encroachers. \niv. NFA collaborations \nIt was established that seventeen (17) MOUs were signed with different government agencies, out of the planned twenty (20), representing an 85% performance. Although these collaborations contributed to the restoration and establishment of new plantations, there were inadequacies in providing the planned quantity of seedings. \nIn addition, twenty (20) Collaborative Forest management (CFM) agreements were signed with forest edge communities, out of the planned twenty-eight (28) over the last three years. There were inadequacies of; staffing, limited sensitization and coordination between the CFM stakeholders. As a result, communities were sighted to be involved in encroachment of newly restored forests in some instances. \n114 \nKey Recommendations \nThe National Forestry Authority should; \n", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}, [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}]], "page": 126, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Engage all relevant stakeholders to ensure sustainable coordination and comprehensive planning initiatives to enhance mainstreaming efforts to increase forest cover in the country.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], "page": 127, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], "page": 127, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Improve on its collaboration and sensitization efforts with all stakeholders to protect all forest land and undertake a process of titling all gazetted forest reserves and national forests to curb illegal encroachment. The National Land Information System (NLIS) should include control measures to prevent illegal titling of gazetted forest land.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], "page": 127, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- Continue engaging the relevant Government authorities to fast-track the revision and approval of the NFA organizational structure, to enhance the institutional capacity to manage national forests.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], "page": 127, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nOverall Conclusion \nWhereas the National Forestry Authority has undertaken specific interventions aimed at increasing forest cover through restoration and establishing new plantations; inadequate coordination, planning, monitoring, collaboration with communities have led to a limited increase in the NFA forest cover over the years. In some instances, increased encroachment, land encumbrances through issuance of title over the NFA land, limited community sensitization and involvement, inadequate prioritization of restoration and new forest establishment have contributed to the dismal 45.8% forest cover under NFA and national cover of 12.3%. \nIt is hoped that despite the increased population that is exerting pressure on the rather limited national forest cover, the lessons learnt and recommendations will be applied to fulfil the objectives of the NFA, forest sector and country.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}, [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, {"headings_1": {"content": "ii.", "page": 126, "level": 3}}]], "page": 127, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "7.3.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 127, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "A Value for Money Audit on the Implementation of the Uganda Women Entrepreneurship Programme by the Ministry of Gender, Labour and Social Development (MGLSD) \nI undertook a Value for Money to assess the extent to which the Programme achieved its intended objectives. \nThe Uganda Women Entrepreneurship Programme (UWEP) is an initiative of the Government of Uganda that is aimed at empowering women to improve their income levels and their contribution to economic development; by improving their access to financial services and equipping them with skills for enterprise growth, value addition and marketing of their products and services. \nThe Programme has disbursed UGX.107 Bn to 11,256 women groups, benefitting over 135,000 women, over the five-year period (2015/16 to 2019/20) in the first Phase. The \n115 \nprogramme through its revolving fund recovered over UGX.16 billion from the loans disbursed to the women which funds were available for financing new women groups. \nDespite the achievements registered, the audit identified the following areas that need to be addressed by the Ministry;", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}, [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}]], "page": 127, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that 4,185 women had benefited from the Programme under the capacity and skills development component, which translates into 42% of the desired target (10,000 women) according to the UWEP Programme document.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- There were delays in disbursement of funds to the women groups. In some cases, the delays were more than 12 months from time of approval of the applications to receipt of the funds which affected the performance and success of enterprises, specifically those in the agricultural sector, which depend on the rainy seasons for planting. The delays impact on agricultural yields.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}, [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}]], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted budget cuts for women groups at the MGLSD level (TSU) with some groups receiving less than budgeted funds to implement their enterprises; however, at the Local Government level, explanations for the budget revisions were not effectively communicated to the groups; which hindered implementation of activities of women groups.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Funds to the tune of UGX 16 Bn remained idle on the recovery account in Bank of Uganda over the five years. Only 6% (UGX 963 million) of the amount had been re- disbursed; which denied the other qualifying women groups access to funds.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The MGLSD through the UWEP Technical Support Unit did not effectively plan for and coordinate implementation of the activities to facilitate women groups to access markets for their products. In addition, access to appropriate technologies were not catered for in the project design and budgets for the entire 5-year period. The intended objective of the funds disbursed may not be fully realised.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- There was underfunding of monitoring and supervision activities at the Local Government level which affected the frequency of monitoring of beneficiary women groups. The programme gaps at enterprise level could not be adequately identified and corrected on time.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- At the National level, the Technical Support Unit (TSU) undertook only 13 (43%) of the planned 30 monitoring and supervision visits to the regions throughout the five- year period. This resulted in delayed identification of performance gaps and timely remedial actions.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nKey Recommendations \nI advised management to do the following; \n", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}, [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}]], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Prioritize the capacity and skills development component of the Programme through increased sensitization to ensure that women groups receive the required skills to", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "116 \neffectively implement selected enterprises. In addition, consider reviewing the funding programme requirements to make training a prerequisite for all groups venturing into value addition enterprises for the first time.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}, [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}]], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The programme implementation guidelines should be reviewed to reduce on the time taken between approval and disbursement to improve timely access to funding to the groups. All budgetary cuts should be communicated to beneficiary women groups in time.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 129, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}, [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}]], "page": 129, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The MGLSD should ensure that the funds recovered are revolved in a timely manner to benefit the intended women groups, and ensure sustainability of the Programme.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 129, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The MGLSD should liaise with MoFPED to mobilise funds to cater for value addition, and monitoring and evaluation activities within the programme.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], "page": 129, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nOverall Concluion \nUWEP exceeded its target in attracting 100,000 women beneficiaries over the five year period and managed to put in place implementation guidelines and training of beneficiaries and implementing partners. \nHowever, utilization of funds from the programme\u2019 revolving fund and equipping beneficiaries with value addition and skills for enterprise growth was found to be", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}, [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, {"headings_1": {"content": "iii.", "page": 126, "level": 3}}]], "page": 129, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "metadata": {"headings": [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}, {"headings_1": {"content": "7.3.", "page": 127, "level": 2}}], "page": 129, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The overall prospects of the programme are promising if the challenges of rationalization of the programme funding; delayed funding of beneficiaries; limited focus on skills and capacity development; inadequate coordination of partnering institutions; are addressed. \n7.4. A Value for Money Audit Report on the Management of Research Grants by Public Universities in Uganda \nResearch is any type of systematic investigation, testing and evaluation whose objective is to discover new facts or information and increase the stock of knowledge. It generates new knowledge, which is critical for sustained economic growth and social transformation of Nations. \nAccording to Section 24(2)(a) of the Universities and other Tertiary Institutions Act, 2001 (as amended), a Public University has a function of provision of higher education, promotion of research and advancement of learning. Research is a costly activity and often relies on grants to supplement the existing financial resources. Research grants enable the research community within the Universities to thrive in knowledge sharing and to use research towards solving community-based problems. \nOwing to the different challenges in the management of research grants at public universities which is characterised by poor rankings of the universities at continental and world level, and less innovation products from the public universities, the Office of the \n117 \nAuditor General undertook an independent assessment of the management of research grants by Public Universities. \nThe overall audit objective was to assess the adequacy of management of research grants in achieving grant management objectives in Public Universities in Uganda. The audit adopted a case study approach whereby 4 out of the 9 Public Universities in Uganda were considered as cases for the study, these included; Makerere University, Mbarara University of Science and Technology (MUST), Kyambogo University and Busitema University. Below is a summary of key findings and recommendations, the details are found in the subsequent part of the report; \nKey Findings", "metadata": {"headings": [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}, {"headings_1": {"content": "7.3.", "page": 127, "level": 2}}, [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}, {"headings_1": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}, {"headings_1": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}, {"headings_1": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}, {"headings_1": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}, {"headings_1": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}, {"headings_1": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}, {"headings_1": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}, {"headings_1": {"content": "7.3.", "page": 127, "level": 2}}]], "page": 129, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "i.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 130, "level": 3}}, {"headings_1": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Institutional framework for coordination of research grants activities", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 130, "level": 3}}, {"headings_1": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- It was noted that all the Public Universities through their respective Councils determine the research policies, research management structures and research direction of the respective Universities. There is no framework to ensure collective planning, coordination and follow-up of research efforts for the different Public Universities to ensure equitable allocation of resources, efficient utilization of academic staff, and that research results contribute to National development.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 130, "level": 3}}, {"headings_1": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 130, "level": 3}}, {"headings_1": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- It was also established that key research and grant management policies/guidelines were missing at a number of Universities to guide on the efficient and effective management of research activities. Only MUST and Busitema had a grants management policy/manual to guide their grants management processes. Furthermore, the country lacks national regulations and guidelines for research and innovation activities including; sourcing of external grants, development and uptake of technologies and, management and commercialization of intellectual properties.\n- Furthermore, the research committees for MUK, MUST and Kyambogo which are responsible for strategic planning and research direction focused more on graduate", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 130, "level": 3}}, {"headings_1": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "students\u2019 research with limited emphasis on university grants research.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- It was also noted that out of the 4 Universities, only MUST had a grants office under the DRGT with dedicated staff to support grant activities. It was further noted that Busitema and Kyambogo did not have grants administrators at college/faculty level while at MUK and MUST only the college of Health Sciences and the faculty of medicine respectively had grant administrators to undertake the tasks.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The most funded area of the research agenda for MUK was health and health systems which accounted for over 50% of the funding with other areas of research getting smaller contributions. In addition, no operational processes were in place to ensure that external grants sourced by MUK & KYU staff are in line with the university\u2019s research agenda. MUST and Busitema University did not have an approved research agenda at University level. Furthermore, the country does not have a clear research agenda to guide planning, implementation and policy making.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n118 \nii. Resource Mobilization Initiatives", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}, [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}]], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- It was found that MUK, KYU and Busitema have established processes to centrally award competitive research grants from internally generated funds or Government support as initiatives to promote research and innovation in public universities. These processes have in turn enabled staff to seek external grants through proposal writing. The processes however have challenges. MUST on the other hand has not established such processes.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the 4 universities, only MUK had a consolidated Research Innovation Fund (RIF) for research funds from government. Through continuous lobbying by MUK, government allocated UGX.30bn to the fund; the other universities have not explored this initiative. All the universities have not raised any resources internally into a separate fund for research. This was attributed to government policy of remitting all internally generated revenue into the consolidated fund and therefore appropriating funds through the annual budget process.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}, [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}]], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- It was noted that for all the 348 grants sampled from the four (4) universities, overheads/indirect costs were not deducted from the funds spent contrary to percentage requirements in the research and grant policies of the universities.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "iii. Monitoring and Evaluation", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- In all the four Universities, M&E was not carried out by the university management on external research grants for the period 2017/18-2019/20. 193 out of 348 (55.5%) sampled external grants were however monitored by the donors. For internal grants, only 222 grants under MUK RIF were monitored.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- It was noted that even where M&E was undertaken by donors, recommendations were not fully implemented by the Universities.\n- 450 out of 512 Government funded Grants from MUK, Kyambogo and Busitema, representing 87.9% were not completed in time during the period under review. Similarly, 218 out of 350 (62.3%) Donor funded Grants from the 4 universities were not completed in time.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Key Recommendations \n", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}, [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}]], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Ministry of Education and Sports should institute a committee with full representation from all public universities and supported with relevant legislation to collectively undertake strategic planning for university research in line with the National Development Plan and ensure adequate coordination between universities, follow-up of research activities, equitable allocation of resources and efficient utilization of academic staff on research.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The NCHE should introduce a standard legal framework for evaluation of management of research activities in the universities. The Universities should then take the responsibility for mainstreaming the instituted framework into their management system. Regular audits of planned university research activities vis a vis expected outputs should be undertaken.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "119", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The public universities should prioritize development of key research and grant management policies to guide the related processes. Benchmarking with leading universities in the region and at the continental level can be used to ease the process and ensure up-to-date policies with the changing environment.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Government and related institutions should fast track the development of policies, strategies and guidelines to promote research, technology development and, uptake and management & commercialization of Intellectual Properties (IPs) as provided for in the NDP III.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}, [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}]], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The public universities should have different Senate/Management committees for the different roles of governing graduate programs and students on one hand and research and innovations activities including grants management on the other hand. This would ensure adequate focus on strategic planning for research, management and follow-up of research activities at the university for timely achievement of university research objectives.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The public universities should engage with MoPS, MoFPED and MoES for support to fill the key staffing gaps for grants management and ensure that the necessary key roles such as grants administration and M&E are undertaken.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Government through the Ministry of Finance, Planning and Economic Development should prioritise funding/grants for research in public universities to enable focus on research which is in line with university research agendas and national priorities.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Government and related institutions should fast track the development of the national research agenda to guide planning, implementation and policy making as provided for in the NDP III.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, {"headings_1": {"content": "i.", "page": 130, "level": 3}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, {"headings_1": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "implementation of recommendations on project or grant monitoring and Evaluation for improvement in the management of research grants in the University. \nOverall Audit Conclusion", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, {"headings_1": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, [{"headings_0": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, {"headings_1": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}]], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Despite the challenges noted in the management of Research Grants, Public Universities have, achieved some notable research outputs through research grants with outstanding innovations which included; production of an electric automobile, crop protection systems, farming systems for generating biofuel, improved water treatment, low cost MakaPads for the girl child, production of energy, and secure fertilizers all at Makerere University. Mbarara University of Science and Technology (MUST) has also been able to produce traditional health care products at its Pharm-Biotechnology and traditional medicine centre, while Kyambogo produced an improved low-cost baby incubator and an online Academic Information Management System (AIMS), which is used by all public universities in the country. \nThere are still bottlenecks in management of Research Grants in Public Universities which have affected achievement of the university research objectives. These included; gaps in \n120 \nthe Institutional Framework for coordination of research grants, inadequate resource mobilization initiatives, inadequate implementation of research projects, lack of monitoring and evaluation framework, and absence of a joint organ to oversee and regulate research initiatives in public universities in the country. \nIt is hoped that when the recommendations in this report are implemented; the universities will effectively manage research grants, thus attaining the objectives of their research agendas.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, {"headings_1": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, [{"headings_0": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, {"headings_1": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, {"headings_1": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, {"headings_1": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, {"headings_1": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}]], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "7.5.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], "page": 133, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Value for Money Audit on The Management Of MATIP-1 Markets by Municipalities \nThe Government of Uganda through MATIP-1 redeveloped and reconstructed seven (7) markets at a cost of USD.64.5 million to create a conducive trade environment and increase revenue collections for the municipalities. The seven (7) markets that were redeveloped were; Mpanga market, Hoima Central market, Mbale Central market, Jinja Central market, Gulu Central market, Wandegeya market and Lira central market. \nThis study assessed whether the municipalities had ensured that the redeveloped markets created a conducive trade environment and increased revenue collections for the municipalities. \nThe redevelopment of the seven (7) markets resulted in an increase in the number of vendors trading in these markets from 14,826 vendors in 2015 to 19,481 Vendors in 2021 which is a growth of 31%. In addition, market management structures comprising of staff of the Municipalities as well as vendor associations were established in all the markets and supported the Municipalities in their role of managing the markets through mobilizing vendors to participate in market activities such as trainings in running small scale businesses, market cleaning, and sensitizations in market security, trade order and hygiene. \nDespite these achievements, the study noted areas that require attention if the management of these markets is to improve; \n", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}]], "page": 133, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The study revealed that the annual revenue budgets or targets of all the seven (7) markets were consistently below their revenue potential by 38%. Whereas the revenue potential for the markets was UGX.32.8Bn over the 6 years reviewed, the markets only budgeted to collect UGX.12.5Bn over the period. This was attributed to lack of a management information systems and the manner in which the municipalities develop the revenue budgets based on prior year collections instead of using actual market occupancy. Unrealistically low budgets imply that the revenue performance is likely to be below the market potential.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], "page": 133, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], "page": 133, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the budget of UGX.12.5Bn by these markets for the six-year period, only UGX.7.9Bn was collected representing a performance of 54%. This was due to lack of automated revenue management system, leaseholders who were not paying monthly market rents, unoccupied stalls and lockups, irregular subletting, and the failure to terminate tenancy of rent defaulters. Under collection of revenues has affected the", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], "page": 133, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "121 \nability of these markets to meet their obligations which has resulted into accumulation of arrears totalling to UGX.1.41Bn in the seven (7) markets.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}]], "page": 133, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Four (4) markets of Mbale, Gulu, Lira and Jinja were overcrowded with the vendor- occupancy exceeding the markets\u2019 design capacity by 36% due to over allocation of market spaces, illegal traders and sub-lettees, inadequate enforcement by the municipality and design deficiencies such as poor lighting in some sections, and lack of accessibility. The overcrowding has caused congestion in the markets.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}]], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The majority of vendors all the seven (7) markets were not trading in the established zones due to insufficient space in zones, allocation of spaces to traders outside their designated zones, rejection of the stalls by vendors, and weak enforcement of zoning. This has resulted in a disorganised market environment which continues to present challenges for customers and traders.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- All the seven (7) markets had failed to maintain adequate sanitation within the markets due to overcrowding of the markets, weaknesses in the supervision of the cleaning staff and cleaning contracts, insufficient number of garbage trucks, skips, bins, garbage banks and landfills. The poor sanitation makes the markets unsightly for the customers and poses health risks for both the traders and customers such as food contamination and air pollution.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The market infrastructure was not well maintained for all the markets. There were cases of leaking roofs, walls with old peeling paint, cracked floors, non-functioning toilets, failed water pumps, un-serviced generators and firefighting equipment, and non-functioning CCTV security equipment. Inadequate maintenance of the market infrastructure was attributed to failure to prioritize this activity by the municipalities, and failure to set aside maintenance funds as recommended in the market maintenance guidelines. Failure to maintain infrastructure has resulted in accelerated deterioration of the newly constructed markets.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nIn order to address the gaps identified, the municipalities should roll out automated revenue management systems in all the markets, enforce terms of tenancy agreements in relation to sub-letting, invoicing and payment of rent, modify the market structures to allow for better lighting and improved access. The municipalities should also address the issue of illegal occupants, and develop guidelines to regulate sub-letting. \nThe municipalities should review the current markets layout to address the challenges of zoning, and overcrowding. In addition, there is need to enhance supervision of market cleaning and prioritise the maintenance of the market structures.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, {"headings_1": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}]], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "7.6.", "metadata": {"headings": [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}, {"headings_1": {"content": "7.5.", "page": 133, "level": 2}}], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Prevention and Response to Incidents of Fire by Uganda Police Force. \nDirectorate of Fire Prevention and Emergency Rescue Services (DFPERS) is one of the directorates in the Uganda Police Force. Its major role is to enhance capacity for prevention of emergencies and delivery of rescue services in order to deliver on its functions of fire prevention, fire suppression and emergence rescue. The directorate operates eleven (11) fire stations in Kampala Metropolitan Area and thirty-four (34) others stations across the country. \n122 \nThis study assessed the extent to which DFPERS has put in place measures to prevent and respond to fire outbreaks. The Directorate of Fire and Rescue services has made notable achievements over its nine years of existence as illustrated below; \nFollowing the creation of DFPERS in 2012 the number of fire stations in the country has increased by thirty-one (31) which has improved access to fire services. In addition, coordination with stakeholders in preventing and responding to fire by DFPERS has improved and a total of 4,131 have been responded to in the last four years thus saving lives and property. Despite the achievements registered, the audit identified the following areas that need to be addressed. \n", "metadata": {"headings": [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}, {"headings_1": {"content": "7.5.", "page": 133, "level": 2}}, [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}, {"headings_1": {"content": "7.5.", "page": 133, "level": 2}}], [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}, {"headings_1": {"content": "7.5.", "page": 133, "level": 2}}], [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}, {"headings_1": {"content": "7.5.", "page": 133, "level": 2}}], [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}, {"headings_1": {"content": "7.5.", "page": 133, "level": 2}}], [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}, {"headings_1": {"content": "7.5.", "page": 133, "level": 2}}]], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Directorate of Fire and Rescue Services (DFPERS) undertakes activities aimed at preventing the outbreak of fire and incidents that require emergency response. The study observed that the Directorate faced challenges in preventing the occurrence of fire. These include;", "metadata": {"headings": [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}, {"headings_1": {"content": "7.5.", "page": 133, "level": 2}}], "page": 135, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf076 DFPERS did not have fire and safety Act, regulations, and policies to aid the operations of the directorate in prevention. Because of this the Directorate was unable to effectively carry out risk assessment, sensitization of the public, inspection of buildings by DFPERS staff, and carry out post incident investigations as indicated below. \n\uf076 DFPERS has not undertaken any comprehensive assessment of risks relating to occurrence of fire incidents in order to develop appropriate prevention and response measures/strategies to control fire outbreaks which has affected the", "metadata": {"headings": [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}, {"headings_1": {"content": "7.5.", "page": 133, "level": 2}}, [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}, {"headings_1": {"content": "7.5.", "page": 133, "level": 2}}]], "page": 135, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "metadata": {"headings": [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, {"headings_1": {"content": "7.6.", "page": 134, "level": 2}}], "page": 135, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf076 DFPERS undertook only 873 (29%) out of the planned 3,020 sensitisations in the past four (4) years. This has continued to expose buildings and their occupants to fire outbreaks and limited the capacity of citizens to prevent the occurrence of such incidents. \n\uf076 DFPERS undertook only 527 (17%) out of the planned 3,080 inspections in the past four (4) years. This affects the level of compliance to fire standards which increases the probability of fire outbreaks which can lead to loss of life and damage to property. \nThe study also noted the following weaknesses on the side of the Fire department: \n", "metadata": {"headings": [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, {"headings_1": {"content": "7.6.", "page": 134, "level": 2}}, [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, {"headings_1": {"content": "7.6.", "page": 134, "level": 2}}], [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, {"headings_1": {"content": "7.6.", "page": 134, "level": 2}}], [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, {"headings_1": {"content": "7.6.", "page": 134, "level": 2}}]], "page": 135, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- DFPERS did not undertake post incident investigations to ascertain the cause, extent of damage or loss from the fires and lessons for prevention of re-occurrence of similar incidents on the 3,179 incidents of fire reported during the past three years due to lack of equipment and trained investigators and coordination with other government investigative bodies. This has resulted into non-conclusion of investigations hence continued public dissatisfaction on the way Uganda Police Force handles fire investigations.", "metadata": {"headings": [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, {"headings_1": {"content": "7.6.", "page": 134, "level": 2}}], "page": 135, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "123 \n", "metadata": {"headings": [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, {"headings_1": {"content": "7.6.", "page": 134, "level": 2}}, [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, {"headings_1": {"content": "7.6.", "page": 134, "level": 2}}]], "page": 135, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- In addition to fire prevention, DFPERS responds to fire outbreaks to minimize the impact of fire on people\u2019s lives and property. The Directorate faced challenges in responding to fire outbreaks due to limited number of fire stations, inadequate staff, lack of enough equipment and non-automation of operations to respond to fires as indicated below;", "metadata": {"headings": [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, {"headings_1": {"content": "7.6.", "page": 134, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, {"headings_1": {"content": "7.6.", "page": 134, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- DFPERS is currently operating forty-five (45) fire stations in thirty-eight (38) districts to respond to cases of fire outbreaks across the country which is only 27% coverage of the total number of districts in the country due to the high cost of opening and", "metadata": {"headings": [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, {"headings_1": {"content": "7.6.", "page": 134, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "to incidents of fire across the country. \n", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}]], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- DFPERS currently has 599 fire staff against an approved establishment of 1,081 staff representing staffing levels of 55% implying that the current fireman to population ratio in Uganda is 1:75,000 compared to the recommended international ratio of 1:2,000. The existing staff were also not well trained and lacked adequate accommodation.", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The equipment at the fire stations were inadequate in terms of quantity and functionality (not well maintained) to support effective response in the event of fire incidents. DFPERS had only 78 out of 232 equipment required to handle fire incidents representing 34% level of required equipment capacity. In addition, it was noted that firemen lacked adequate PPEs for use during fire response.", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The fire stations inspected were not automated and information was recorded in manual books there were also no computers and communication systems which affected the efficiency and coherence of DFPERS response in the event of fire outbreak.\n- DFPERS coordinates with some stakeholders such as Local Governments, NWSC, DGAL, CIID, Hospital emergency units, Civil Aviation Authority and Uganda Red Cross Society however this coordination is informal and characterized by slow decision making which affects response time.", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Key Recommendations \nI advised DFPER to engage the Ministry of internal Affairs to develop a comprehensive fire and safety Act, policy and guidelines in consultation with key stakeholders to streamline risk assessment, sensitisation, inspection and post incident investigations. In addition, DFPERS should enhance coordination mechanisms with internal and external players to support its operations particularly post incident investigations. \nDFPERS should prioritize increasing coverage of fire stations to at least 50% of the districts and develop strategies to ensure the population fire man ratio of 1:75,000 is matched to internationally recommended ratio of 1: 2,000. In addition, UPF should undertake an assessment of the current accommodation needs with a view of developing strategies to address the current inadequacies in accommodation. UPF should prioritise the acquisition of equipment, PPEs and automation of the current communication and record management systems to ensure that there is an effective \n124 \nresponse to fire incidents enhance on the operational efficiency during responses to incidents of fire outbreaks", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, {"headings_1": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}]], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "7.7.", "metadata": {"headings": [{"headings_0": {"content": "7.7.", "page": 137, "level": 2}}, {"headings_1": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Value for Money Audit on the Performance of the Performance of the Agriculture Cluster Development Project \nGovernment has implemented the Agriculture Cluster Development Project (ACDP) with an overall objective of raising on-farm productivity, production and marketable volumes of selected agricultural commodities (Maize, Beans, Cassava, Rice, and Coffee) in twelve (12) clusters in fifty-seven (57) districts across the country. The project is funded through IDA Credit worth UGX.540Bn and farmer contribution of UGX.352.8Bn and implemented through the e-voucher management system. \nThe intervention has resulted into distribution of 60,124 tonnes of beans, maize, and rice and 49,871 bags of cassava planting materials to 245,510 farmers/beneficiaries by the agro-dealers between 2018/2019 and 2020/2021. The intervention has also resulted into increased the marketable volumes from 11.94MT to 33.28MT in the past three years. \nDespite the achievements registered, the study identified areas that need to be addressed. The following key observations were noted;", "metadata": {"headings": [{"headings_0": {"content": "7.7.", "page": 137, "level": 2}}, {"headings_1": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, [{"headings_0": {"content": "7.7.", "page": 137, "level": 2}}, {"headings_1": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], [{"headings_0": {"content": "7.7.", "page": 137, "level": 2}}, {"headings_1": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], [{"headings_0": {"content": "7.7.", "page": 137, "level": 2}}, {"headings_1": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}]], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "approvals from cabinet and parliament (20 months) and delayed fulfilment of the project effectiveness conditions (26 months) which led to late implementation of project activities and service delivery. \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}, [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}]], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Despite the project achieving more than 70% in five (5) districts in training of Local Government Staff and farmers on system use and financial literacy, the project did not perform satisfactorily in twenty-three (23) districts where twenty-seven (27) trainings had been planned. As a consequence, a number of farmers were unable to transition from the first cropping cycle to the third cropping cycle.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the targeted 450,000 farmers, 204,490 (46%) farmers did not access inputs through the e-voucher system. With only one year left to the end of the project, the project may not achieve its intended objective.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The inputs that were distributed to the farmers were not verified by UNBS because of absence of a streamlined quality control process. As a result, farmers reported cases where seeds did not germinate and fertilizers that \u201cjust hardened the soils\u201d were distributed by the Agro-dealers. This has compromised the process of ensuring farmers get the best quality inputs since the department is limited in capacity to undertake this activity.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The project did not achieve the intended targets in the three areas below in the three years of implementation.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "125", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "o Only 207 Area Commodity Cooperative Enterprises (ACCEs) (69%) and 155 Rural Producer Organisations (RPOs) (5%) have been supported with value addition facilities out of the targeted 300 ACCEs and 3000 RPOs in the six-year project life span. \no \nOut of 1,835 farmers in the cooperatives that received matching grants for the value addition facilities, only 585 farmers (31.9%) were enrolled on the e-voucher system which made it difficult for the project to reach its targeted 450,000 farmers. \no The project had planned to rehabilitate a total of 2,827.7km planned road chokes however, only 228.1km (8%) had been rehabilitated representing 8% of the overall performance of the community access roads. \nGovernment should ensure that for future projects of a similar nature; The necessary loan documentation is submitted by the implementing entities and loan appraisal unit at MoFPED to the approving authorities in time, trainings activities are undertaken in a timely manner, farmers are mobilized into village savings and lending associations to increase access to funding and reviewing the e-voucher subsidy rates in order to make them more affordable to farmers. The role of other partner participating agencies (in this case UNBS) regarding quality is clearly defined in future project designs. \nIn addition, MAAIF should ensure that evaluation of business proposals for funding of ACCEs and RPOs are done in a timely manner for the farmer groups to access funds. MAAIF should also enhance supervision in the rollout districts so that works on the road chocks are completed in the remaining project life span. \n7.8. Follow up on the Value for Money Audit on the Compensation of Project Affected Persons under the Refinery Project by the Ministry of Energy and Mineral Development \nThe follow-up on the 2017 VFM audit on Compensation of Project Affected Persons (PAPs) under the Refinery Project by the Ministry of Energy and Mineral Development found that MEMD had made efforts to implement the Auditor General\u2019s recommendations made at the time, resulting in improved RAP implementation. \nOut of the 21 key audit recommendations made in the report of 2017, 12 (57%) were fully implemented and 4 (19%) were partially implemented. The status of implementation of 5 (24%) of the recommendations can only be verified in future projects through audit of subsequent RAPs. \nSpecifically, after the 2017 audit, MEMD had registered the following progress in RAP", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}, [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, {"headings_1": {"content": "7.7.", "page": 137, "level": 2}}]], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Implementation:", "metadata": {"headings": [{"headings_0": {"content": "Implementation:", "page": 138, "level": 2}}, {"headings_1": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Implementation:", "page": 138, "level": 2}}, {"headings_1": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- All PAPs houses had been occupied by the respective owners;\n- Electricity had been connected to all PAP houses;\n- Four boreholes were constructed for use by the PAPs and the Host Community;", "metadata": {"headings": [{"headings_0": {"content": "Implementation:", "page": 138, "level": 2}}, {"headings_1": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}, {"headings_1": {"content": "Implementation:", "page": 138, "level": 2}}], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "motorable;", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}, {"headings_1": {"content": "Implementation:", "page": 138, "level": 2}}], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Construction of the places of worship and a Police Post had been completed and the structures handed over to the respective authorities;\n- Construction of the community centre and market stalls was on-going.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}, {"headings_1": {"content": "Implementation:", "page": 138, "level": 2}}], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "126", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}, {"headings_1": {"content": "Implementation:", "page": 138, "level": 2}}], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- MEMD had acquired land titles for the land occupied by the PAPs and was processing the transfer of the individual land titles into the names of the PAPs.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}, {"headings_1": {"content": "Implementation:", "page": 138, "level": 2}}], "page": 139, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nSome outstanding issues noted included the following: A few pending compensation payments mostly due to failure to trace the PAPs; failure by the contractor to remedy most defects identified during the 2017 audit; reports of conflicts owing to changing social dynamics as people adapt to living in congregated settlements; and long distance from the resettlement area to the boreholes. Finally, the PAPs also reported that MEMD and other responsible players rarely conduct visits to sensitise or update them on progress of pending outputs or to explain delays. \nFurther recommendations were then made with the aim of addressing the outstanding issues noted.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}, {"headings_1": {"content": "Implementation:", "page": 138, "level": 2}}, [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}, {"headings_1": {"content": "Implementation:", "page": 138, "level": 2}}], [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}, {"headings_1": {"content": "Implementation:", "page": 138, "level": 2}}]], "page": 139, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "7.9.", "metadata": {"headings": [{"headings_0": {"content": "7.9.", "page": 139, "level": 2}}, {"headings_1": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}], "page": 139, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "VFM Audit on the Implementation of the Uganda Reproductive Maternal and Child Health Services Improvement Project (URMCHSIP) \nURMCHSIP is a USD 180 million project fully donor funded and was approved in August 2016 and is expected to close in December 2022. The target group comprises women of childbearing age, adolescents, and children under-five in all the one-hundred and thrty five (135) districts in Uganda. The Project Development Objectives (PDOs) are to: (a) to scale up reproductive, maternal, newborn, child and adolescent health (RMNCAH) services in the whole country; (b) scale-up birth and death registration (BDR) services; and (c) to strengthen disease outbreak preparedness and response. \nThe audit covered twelve (12) Districts benefiting from this project in the three financial years of 2017/18, 2018/19 and 2019/20. Below are the key findings of the study;", "metadata": {"headings": [{"headings_0": {"content": "7.9.", "page": 139, "level": 2}}, {"headings_1": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}, [{"headings_0": {"content": "7.9.", "page": 139, "level": 2}}, {"headings_1": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}], [{"headings_0": {"content": "7.9.", "page": 139, "level": 2}}, {"headings_1": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}]], "page": 139, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "i.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 139, "level": 3}}, {"headings_1": {"content": "7.9.", "page": 139, "level": 2}}], "page": 139, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Status of Implementation of the Project \nIt was noted that out of the 22 project performance indicators considered, 13 (i.e. 60%) achieved their target for the FY 2019/20. The remaining 9 indicators (i.e. 40%) were below their 2019/20 target. Amongst the 9 are two indicators: the number of health facilities constructed and equipped, which are not reflecting any progress due to delays in implementation.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 139, "level": 3}}, {"headings_1": {"content": "7.9.", "page": 139, "level": 2}}], "page": 139, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ii.", "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 139, "level": 3}}, {"headings_1": {"content": "i.", "page": 139, "level": 3}}], "page": 139, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The Results-Based Financing (RBF) Program \nSince January 2019 to date, the URMCHSIP has rolled out the RBF program to 1,316 health facilities in one-hundred and thirty-five (135) districts across the country in three phases. However, review of timing of RBF payments made by the Ministry of Health-to- health facilities revealed delayed payments ranging from 83 to 154 days after the prescribed deadline. Consequently, timely implementation of Performance Improvement Plan (PIP) activities at these facilities was adversely impacted. The delayed payments were partly attributed to the delayed verification of health facility outputs by the District Health Management Teams (DHMTs) which was further constrained by the reliance on manual processes. \n127", "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 139, "level": 3}}, {"headings_1": {"content": "i.", "page": 139, "level": 3}}, [{"headings_0": {"content": "ii.", "page": 139, "level": 3}}, {"headings_1": {"content": "i.", "page": 139, "level": 3}}]], "page": 139, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 140, "level": 3}}, {"headings_1": {"content": "ii.", "page": 139, "level": 3}}], "page": 140, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Procurement of Essential RMNCAH Medicines and Supplies", "metadata": {"headings": [{"headings_0": {"content": "Procurement of Essential RMNCAH Medicines and Supplies", "page": 140, "level": 2}}, {"headings_1": {"content": "iii.", "page": 140, "level": 3}}], "page": 140, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "The project intended to support the Ministry of Health (MoH), through National Medical Stores (NMS), to procure and distribute essential Reproductive, maternal, newborn, child and adolescent health (RMNCAH) commodities. However, there have been several delays in the procurement of these commodities under the project, leaving health facilities partly incapable of handling certain complications arising during delivery. This was partly attributed to failure by the MoH to retender certain procurements, there being no bidder that initially met the requirements.", "metadata": {"headings": [{"headings_0": {"content": "Procurement of Essential RMNCAH Medicines and Supplies", "page": 140, "level": 2}}, {"headings_1": {"content": "iii.", "page": 140, "level": 3}}], "page": 140, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iv.", "metadata": {"headings": [{"headings_0": {"content": "iv.", "page": 140, "level": 3}}, {"headings_1": {"content": "Procurement of Essential RMNCAH Medicines and Supplies", "page": 140, "level": 2}}], "page": 140, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Birth and Death Notifications in Health Facilities", "metadata": {"headings": [{"headings_0": {"content": "Birth and Death Notifications in Health Facilities", "page": 140, "level": 2}}, {"headings_1": {"content": "iv.", "page": 140, "level": 3}}], "page": 140, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "There were delays in implementation of various activities by National Identification and Registration Authority (NIRA) especially (i) scaling up the electronic vital records system", "metadata": {"headings": [{"headings_0": {"content": "Birth and Death Notifications in Health Facilities", "page": 140, "level": 2}}, {"headings_1": {"content": "iv.", "page": 140, "level": 3}}], "page": 140, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "for birth registration through the supply of laptops, MiFi\u2019s and internet data bundles to", "metadata": {"headings": [{"headings_0": {"content": "for birth registration through the supply of laptops, MiFi\u2019s and internet data bundles to", "page": 140, "level": 2}}, {"headings_1": {"content": "Birth and Death Notifications in Health Facilities", "page": 140, "level": 2}}], "page": 140, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "285 HC IVs and High-volume Health centre IIIs. As a result, the project has made minimal improvement in capacity of these facilities to conduct birth and death notifications.", "metadata": {"headings": [{"headings_0": {"content": "for birth registration through the supply of laptops, MiFi\u2019s and internet data bundles to", "page": 140, "level": 2}}, {"headings_1": {"content": "Birth and Death Notifications in Health Facilities", "page": 140, "level": 2}}], "page": 140, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "v.", "metadata": {"headings": [{"headings_0": {"content": "v.", "page": 140, "level": 3}}, {"headings_1": {"content": "for birth registration through the supply of laptops, MiFi\u2019s and internet data bundles to", "page": 140, "level": 2}}], "page": 140, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Monitoring and Evaluation of Project Activities \nThe monitoring and evaluation (M&E) function was found to be inadequate and this was partly attributed to the fact that there were no annual M&E work plans and the M&E specialist was only recruited in December 2019, two and a half years after the project had commenced. \nOverall Audit Conclusion", "metadata": {"headings": [{"headings_0": {"content": "v.", "page": 140, "level": 3}}, {"headings_1": {"content": "for birth registration through the supply of laptops, MiFi\u2019s and internet data bundles to", "page": 140, "level": 2}}, [{"headings_0": {"content": "v.", "page": 140, "level": 3}}, {"headings_1": {"content": "for birth registration through the supply of laptops, MiFi\u2019s and internet data bundles to", "page": 140, "level": 2}}]], "page": 140, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The MoH is advised to continue working closely with the National Identification and Registration Authority, the District Local Governments, National Medical Stores, and the World Bank to address any capacity gaps and implementation delays that are derailing project performance. The MoH is also advised to liaise with MoFPED and other key stakeholders to guarantee the continuity of the interventions set up under this project especially the RBF Program, the increased supply of key RMNCAH medicines and supplies, the recruitment of health workers trained under URMCHSIP, so as maintain the gains made in the Health sector as a result of this project. \n128", "metadata": {"headings": [{"headings_0": {"content": "v.", "page": 140, "level": 3}}, {"headings_1": {"content": "for birth registration through the supply of laptops, MiFi\u2019s and internet data bundles to", "page": 140, "level": 2}}, [{"headings_0": {"content": "v.", "page": 140, "level": 3}}, {"headings_1": {"content": "for birth registration through the supply of laptops, MiFi\u2019s and internet data bundles to", "page": 140, "level": 2}}]], "page": 140, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "ANNEXURES", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 141, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "ANNEXURE I: SUMMARY OF ENTITY FINDINGS AND OPINIONS FOR MDAs, COMMISSIONS, STATUTORY CORPORATIONS AND STATE ENTERPRISES AND PROJECTS", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 141, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Sn SECTOR AND ENTITY SUMMARY OF KEY FINDINGS", null, null], ["", "AGRICULTURE SECTOR", ""], ["1\\. Agriculture Cluster Development Project (ACDP). 2020/21 Opinion Unqualified \uf0b7 Delays in the implementation of some project activities were noted such as provision of E-Vouchers subsidies to beneficiaries in the 12 clusters, only a total of 208,827 of beneficiaries used E-Voucher out of the targeted 400,000 and only 18 road chokes have been worked on in the 7 pilot districts against the targeted 90. \uf0b7 The project budgeted to receive UGX 361.7Bn from development partners but only received UGX 254.8Bn, representing a performance of 70% of the budget. Similarly, the project budgeted to receive UGX 4Bn as GOU counterpart funding but only received UGX 2.6Bn (66%) resulting in a shortfall of UGX 1.4Bn which is 34% of the budget. \uf0b7 Out the releases of funds of UGX 254.8Bn, the project remained with unspent balance of UGX 99.1Bn representing an absorption level of 61%. \uf0b7 I sampled 12 outputs with a total of 25 activities worth UGX.324.1Bn representing 90% of the total budget and noted that 8 outputs with 17 activities worth UGX 53.7Bn were not quantified to enable measurement of performance. Furthermore, of the 4 outputs with a total of (8) quantified activities worth UGX 80.14Bn assessed; 1 output with 1 activity representing 25% was fully implemented while 3 outputs with a total of 7 activities representing 75% were partially implemented. \uf0b7 The budget for the financial year 2020/21 was approved on 13th August 2020 (2 months into the financial year). \uf0b7 Project funds to the tune of UGX 3.5Bn were disbursed significantly late to the districts. \uf0b7 National Project Steering Committee (NPSC) held only one meeting as opposed to two recommended in a year. \uf0b7 Procurements for rehabilitation of identified and approved road chokes/work in the last 29 roll-out districts had not commenced by the time of audit despite MAAIF budgeting for the activity at UGX 90Bn. \uf0b7 Shortcomings were observed with the E-Voucher Management Agency which included, frequent breakdown of the system, lesser enrolment of beneficiaries ie 64% of the target, only 44% of the project beneficiaries were trained in Financial Literacy and Input use, the system was at 78% of its functional requirement, system installation, configuration, optimisation and commissioning reports have not been submitted. \uf0b7 MAAIF budgeted UGX.104.9Bn to provide Electronic Voucher subsidies to 293,500 beneficiaries in 12 project clusters but only managed 118,933 (41%) beneficiaries. \uf0b7 Farmers still had challenges in transacting using the system, managing farmer savings and use of inputs via the system. During the financial years 2019/2020 and 2020/2021, 52,089 transactions were made by users who had never logged onto the system and were accessing inputs manually. Relatedly, 2,873 user IDs initiated 7,878 payment requests", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 141, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": [["Sn SECTOR AND ENTITY SUMMARY OF KEY FINDINGS", null, null], ["", "AGRICULTURE SECTOR", ""], ["1\\. Agriculture Cluster Development Project (ACDP). 2020/21 Opinion Unqualified \uf0b7 Delays in the implementation of some project activities were noted such as provision of E-Vouchers subsidies to beneficiaries in the 12 clusters, only a total of 208,827 of beneficiaries used E-Voucher out of the targeted 400,000 and only 18 road chokes have been worked on in the 7 pilot districts against the targeted 90. \uf0b7 The project budgeted to receive UGX 361.7Bn from development partners but only received UGX 254.8Bn, representing a performance of 70% of the budget. Similarly, the project budgeted to receive UGX 4Bn as GOU counterpart funding but only received UGX 2.6Bn (66%) resulting in a shortfall of UGX 1.4Bn which is 34% of the budget. \uf0b7 Out the releases of funds of UGX 254.8Bn, the project remained with unspent balance of UGX 99.1Bn representing an absorption level of 61%. \uf0b7 I sampled 12 outputs with a total of 25 activities worth UGX.324.1Bn representing 90% of the total budget and noted that 8 outputs with 17 activities worth UGX 53.7Bn were not quantified to enable measurement of performance. Furthermore, of the 4 outputs with a total of (8) quantified activities worth UGX 80.14Bn assessed; 1 output with 1 activity representing 25% was fully implemented while 3 outputs with a total of 7 activities representing 75% were partially implemented. \uf0b7 The budget for the financial year 2020/21 was approved on 13th August 2020 (2 months into the financial year). \uf0b7 Project funds to the tune of UGX 3.5Bn were disbursed significantly late to the districts. \uf0b7 National Project Steering Committee (NPSC) held only one meeting as opposed to two recommended in a year. \uf0b7 Procurements for rehabilitation of identified and approved road chokes/work in the last 29 roll-out districts had not commenced by the time of audit despite MAAIF budgeting for the activity at UGX 90Bn. \uf0b7 Shortcomings were observed with the E-Voucher Management Agency which included, frequent breakdown of the system, lesser enrolment of beneficiaries ie 64% of the target, only 44% of the project beneficiaries were trained in Financial Literacy and Input use, the system was at 78% of its functional requirement, system installation, configuration, optimisation and commissioning reports have not been submitted. \uf0b7 MAAIF budgeted UGX.104.9Bn to provide Electronic Voucher subsidies to 293,500 beneficiaries in 12 project clusters but only managed 118,933 (41%) beneficiaries. \uf0b7 Farmers still had challenges in transacting using the system, managing farmer savings and use of inputs via the system. During the financial years 2019/2020 and 2020/2021, 52,089 transactions were made by users who had never logged onto the system and were accessing inputs manually. Relatedly, 2,873 user IDs initiated 7,878 payment requests", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 141, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "129", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 141, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", null, null], ["2", "Agriculture Value Chain Development Programme (AVCP).", "\uf0b7 Out of the planned twelve (12) strategic targets/goals to be achieved by financial year 2020/2021; four (4) had been fully achieved, seven (7) were partially achieved while one (1) was not achieved at all."], [null, "2020/21 Opinion", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 142, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", null, null], ["2", "Agriculture Value Chain Development Programme (AVCP).", "\uf0b7 Out of the planned twelve (12) strategic targets/goals to be achieved by financial year 2020/2021; four (4) had been fully achieved, seven (7) were partially achieved while one (1) was not achieved at all."], [null, "2020/21 Opinion", null], [null, "Unqualified", ""], [null, null, "activities were fully quantified. Further, out of the 14 outputs that were"], [null, null, "fully quantified, I observed that; 0ne (01) output with four (04) activities"], [null, null, "and expenditure worth UGX.0.547Bn was fully implemented; ten (10)"], [null, null, "outputs with forty-two (42) activities worth UGX.10.1Bn were partially"], [null, null, "implemented i.e. out of the 42 activities, 17 activities (40%) were fully"], [null, null, "implemented, 16 activities (39%) were partially implemented while 9"], [null, null, "activities (21%) remained unimplemented. Three (03) outputs with four"], [null, null, "(04) activities were not implemented at all."], [null, null, "\uf0b7 Assessment of achievement of services from implemented outputs"], [null, null, "revealed that 60 artificial inseminations (AI) Kits were purchased at"], [null, null, "UGX.0.26Bn and delivered to NAGRC in June; however, management had"], [null, null, "not yet distributed them to beneficiary AIs by November 2021 implying"], [null, null, "that the equipment was not in use for more than five months."], [null, null, "\uf0b7 Relatedly, the project undertook the Purchase and Installation of Ultra-"], [null, null, "High Performance Liquid Chromatography (UHPLC) for analysis of various"], [null, null, "chemical food and environmental residues and related substances at"], [null, null, "UGX.0.39Bn which was delivered in June 2021 but was not functional by"], [null, null, "November due to incomplete components."], [null, null, "\uf0b7 There was no Steering committee sitting during the year to facilitate and"], [null, null, "ensure adherence to relevant strategies established by Government"], [null, null, "during project implementation."], ["3 Coordinating Office for Control of Trypanosomiasis in Uganda. 2020/21 Opinion Unqualified \uf0b7 The entity had an approved strategic plan, however the plan had not been certified by NPA contrary to Regulation 26 (1) of the NPA (development of plans). \uf0b7 All budgeted Donor revenue of UGX.0.783Bn for the financial year 2020/2021, was dully received representing performance of 100% of the target. \uf0b7 There was a shortfall in releases amounting to UGX.0.172Bn representing 4.1% of the budget. Furthermore, the entity remained with unspent balance of UGX.0.00037Bn representing an absorption level of 99.9%. \uf0b7 The entity received off-budget financing to a tune of UGX.0.783bn which was not appropriated as part of the entity budget contrary to the law. \uf0b7 4 outputs with 8 activities and expenditure worth UGX.0.324Bn were fully quantified while 5 outputs with 34 activities worth UGX.4.41Bn were", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 142, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "130", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 142, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["insufficiently quantified. Of the 4 outputs with all 8 quantified activities worth UGX.0.324Bn assessed; 3 outputs with 4 activities worth UGX.0.19Bn were fully implemented, while 1 output with 4 activities worth UGX.0.134 was partially implemented. \uf0b7 All 4 quarterly performance reports were submitted after the quarterly deadline and I did not obtain evidence to confirm that the Accounting Officer prepared monitoring plans and reports. \uf0b7 Out of the approved staff number of 37 employees, 19 (51%) have been filled leaving a 18 (49%) vacant among which are key posts of Deputy Director, Accountant, Medical Officer, Entomology Officer, M&E Officer etc. \uf0b7 Contrary to the COCTU Human Resource Manual that requires operation of a medical insurance scheme to benefit all its employees, the entity has not operationalized any Staff Medical Insurance Policy for its staff.", null, null], ["4", "Cotton Development Organization. 2020/21", "\uf0b7 The entity cotton sub sector strategic plan had been prepared and approved; however, it was not certified by NPA to evidence its alignment to the NDP-III."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 143, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None"], "type": "table"}}, {"content": "131", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 143, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "targets."], [null, "\uf0b7 Analysis of the domestic arrears showed an increase of 198% from"], [null, "UGX.7,925,963 in the prior year to UGX.23,659,951 in the year under"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 144, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": [["", "targets."], [null, "\uf0b7 Analysis of the domestic arrears showed an increase of 198% from"], [null, "UGX.7,925,963 in the prior year to UGX.23,659,951 in the year under"], [null, "review."], [null, "\uf0b7 CDO staff structure had thirty seven (37) positions dully filled leaving a"], [null, "staff vacancy of ten (10) positions (21%). The positions that have"], [null, "remained vacant over the years include key positions of two (2)"], [null, "Agronomy officers, a classifier and a Personnel & Administration Officer."], [null, "\uf0b7 Withholding tax to the tune of UGX.83,142,447 from payments worth"], [null, "UGX.839,194,850 was not recovered for onward remittance to URA"], [null, "contrary to section 120(1) and 120(4) of the Income tax Act."], ["5 National Agricultural Research Organization 2020/21 Opinion Unqualified \uf0b7 The entity\u2019s draft strategic plan had been aligned to the NDP-III at the time of audit and was awaiting certification from NPA due to delayed approval of the Programme Implementation Action Plans (PIAPs). \uf0b7 The entity budgeted to collect NTR of UGX.4.625Bn but collected UGX.3.053Bn representing a performance of 66% of the target. \uf0b7 There was a shortfall in GoU releases amounting to UGX.11.216Bn representing 10.1%. Further, the entity remained with unspent balance of UGX.0.085Bn representing an absorption level of 99.9%. \uf0b7 The entity received off-budget financing directly from development partners to a tune of UGX.49.77Bn out of which only UGX.38.19Bn was declared to the PSST and disclosed in the entity ministerial policy statement without a supplementary appropriation for the balance of UGX.11.58Bn. \uf0b7 I sampled 8 outputs with 35 activities and expenditure of UGX.99.59Bn and noted that 7 outputs with 18 activities and expenditure worth UGX.45.070Bn were fully quantified while 1 output with 17 activities and expenditure worth UGX.54.52Bn was insufficiently quantified, of which 5 activities (29%) were quantified while 12 activities (71%) were not clearly quantified to enable measurement of performance. Further, I observed that out of the seven (7) outputs that were fully quantified, two (2) outputs with five (5) activities and expenditure worth UGX.5.186Bn were fully implemented while Five (5) outputs with thirteen (13) activities worth UGX.39.884Bn were partially implemented i.e. four (4) activities were fully implemented, eight (8) activities were partially implemented, while one (1) activity remained unimplemented. \uf0b7 Submission of performance reports for all the quarters was made after the deadline dates. \uf0b7 Fourteen (14) slow progressing competitive grant scheme (CGS) projects initiated in 2018/19 with funding of UGX.1.158Bn during the financial year 2020/2021 were still on-going despite expected completion date of June 2021. \uf0b7 Civil works and Supplies Projects worth UGX.32,051,565,938 undertaken during the financial year were not yet handed over for use. Further, inspections of NARO facilities at institutes revealed poor road networks, broken down silos at the feed mill, non-functional water pump and abandoned works. \uf0b7 There was failure to achieve the intended service delivery for the additional Civil Works at Rwebitaba ZARDI that costed UGX.418,584,880. This was due to lack of equipment in the laboratory. \uf0b7 Review of 9 sample procurements worth UGX.27,606,866,233 revealed an", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 144, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": "132", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 144, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["average delay of 45 days in the procurement process due to late release of funds by MoFPED. \uf0b7 The entity received Covid 19 supplementary budget of UGX.0.0134Bn for settlement of arrears which was all spent by the entity representing an absorption level of 100%. It was noted that this was inadequate for settlement of domestic arrears brought forward from the previous year 2019/20 given leaving a deficit of UGX1.69Bn (98%). \uf0b7 Domestic arrears increased from UGX.1.72Bn in the previous year to UGX.2.875Bn in the year under review, an increase of 67%. The arrears remained unsettled at the close of the year. Further, NARO did not budget for domestic arrears amounting to UGX.1.687Bn during the year as a paltry provision of only UGX.0.033Bn was budgeted to settle arrears of UGX.1.72Bn. \uf0b7 A review of NARO\u2019s land portfolio revealed that the entity had surveyed 31 pieces of land with total coverage of 4097.20364 Hectares, however it was noted that 8 pieces (3172.937 Hectares) were titled, 20 pieces of land (706.75454 Hectares) were at deed plan stage and 3 pieces of land (217.5121 Hectares) were still at survey report stage. Further, 17 parcels of land located in NaFIRRI-Jinja, Bulindi-Kibaale district, NaLIRRI- Tororo, Namayingo, Nyakyesasa, Ngetta- Kitgum and Rwebitaba-Fort-portal still had cases of encroachement by both private and public developers. \uf0b7 A review of the NARO staff establishment revealed that out of the approved staff number of 995 employees, 851 positions have been filled leaving a staffing gap of 144 (14.5%) staff which indicates a further reduction in staff by about 2.5% compared to the previous financial year.", null, null], ["6", "National Animal Genetics and Data Bank (NAGRIC) 2020/21", "\uf0b7 The entity strategic plan had been aligned to the NDP-III at the time of audit but it was still in draft form awaiting certification from NPA before approval."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 145, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None"], "type": "table"}}, {"content": "133", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 145, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "expenditure of UGX.0.54Bn. By 30th June 2021, prior year LCs worth"], [null, "UGX.10.875Bn were still outstanding."], [null, "\uf0b7 12 project sites whose contracts total to UGX.20.055Bn out of which"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 146, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": [["", "expenditure of UGX.0.54Bn. By 30th June 2021, prior year LCs worth"], [null, "UGX.10.875Bn were still outstanding."], [null, "\uf0b7 12 project sites whose contracts total to UGX.20.055Bn out of which"], [null, "UGX.6.327Bn had been paid were abandoned while 8 delayed and"], [null, "remained incomplete by 30th June 2021."], [null, "\uf0b7 34 contracts for construction of structures, procurement of land and"], [null, "delivery of supplies worth UGX.34.4Bn out of which UGX.11.451Bn was"], [null, "paid had not started. Out of the 34 contracts, 3 service providers who"], [null, "had been fully paid a sum of UGX.7.45Bn had not delivered."], [null, "\uf0b7 640 acres of planted pasture/ fodder in Kasolwe ranch had dried up"], [null, "adversely affecting the quality and quantity of feeds for the animals."], [null, "\uf0b7 Domestic arrears increased by UGX.0.918Bn from UGX. 0.336Bn in the"], [null, "previous year to UGX.1.254Bn in the year under review. The arrears"], [null, "remained unsettled at the close of the year."], [null, "\uf0b7 Out of 12 ranches managed by NAGRC & DB, 6 had been encroached on"], [null, "while some of the NAGRC & DB land had no land titles in the names of"], [null, "NAGRIC 7DB."], [null, "\uf0b7 NAGRC & DB had an approved staff structure of 189 positions with only"], [null, "105 (56%) filled leaving 84 (44%) vacant and 17 positions were filled"], [null, "beyond the approved structure. Further, general support staff structure of"], [null, "128 positions had 310 staff resulting in an over staffing of 142 (185%)."], ["7 National Oil Palm Project 2020/21 Opinion Unqualified \uf0b7 Out of seven (7) strategic targets to be achieved by 30th June 2021, none had been fully achieved, two (2) were partially achieved while five (5) were not achieved at all. \uf0b7 The Project budgeted to receive IFAD funds to a tune of UGX.39.87bn, out of which UGX.25.584bn was available representing a performance of 64% of the budget. Further, there was a shortfall in GoU releases amounting to UGX.0.035Bn representing 0.46% of the budgeted UGX.7.597Bn. \uf0b7 Out of the total available funding of UGX.35.528Bn during the financial year, UGX.28.415Bn was spent by the entity resulting in an unspent balance of UGX.7.113Bn representing an absorption level of 80%. \uf0b7 I sampled Six (6) outputs with a total of eighty one (81) activities and expenditure of UGX.21.6231Bn and noted that all six (6) outputs with 81 activities were fully quantified to enable assessment of performance. Further, assessment of the implementation of all Six (6) outputs revealed that; all six (6) outputs with eighty one (81) activities were partially implemented i.e. out of the eighty one (81) activities, thirty two (32) activities (40%) were fully implemented; thirty (30) activities (37.5%) were partially implemented, while nineteen (19) activities (12.5%) remained unimplemented. \uf0b7 Two (2) contracts worth UGX.12.397Bn in relation to construction of landing sites were cancelled due to delayed implementation of projects beyond 12 months from the initial intended completion date. \uf0b7 I noted delayed titling of 883.92 hectares of the acquired nucleus estate Land exposing it to risks of encroachment by individuals. \uf0b7 Review of four (4) sample procurements worth UGX.1.47Bn revealed an average delay of 140 days in the procurement process majorly as a result of delayed approval process by IFAD, contracts committee and Solicitor General.", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 146, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": "134", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 146, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["8", "Strengthening National Seed Certification Service Project (SNSCS).", "\uf0b7 Out of the planned six (6) strategic targets/goals to be achieved, none was either fully or partially achieved and one target was not even quantified to enable assessment."], [null, "2019/2020 Opinion Unqualified", null], ["9 Strengthening National Seed Certification Service Project (SNSCS). 2020/21 Opinion Unqualified \uf0b7 Out of the planned six (6) strategic targets/goals to be achieved by 30th June 2021, one (1) target was fully achieved, three (3) targets had been partially achieved and two (2) were not achieved at all. \uf0b7 The Project budgeted to receive UGX.1.184bn out of which UGX.1.049bn was received resulting into a shortfall of UGX.0.135bn, which is 11% of the budget. Further, out of the total warrants of UGX.1.049Bn received during the financial year, only UGX.0.199Bn was spent by the entity resulting in an unspent balance of UGX.0.85Bn representing absorption level of 19%. \uf0b7 I sampled five (5) outputs with 15 activities worth UGX.0.199Bn and noted that three (3) outputs with a total of seven (7) activities and expenditure worth UGX.0.199Bn were fully quantified; Two (2) outputs with a total of eight (8) activities were not quantified at all. Further, of the three quantified outputs assessed, one (1) output with 3 activities worth UGX.199, 045,000 was partially implemented. Out of the 3 activities, one (1) activity was partially implemented, while two (2) activities remained unimplemented. Two (2) outputs with four (4) activities worth NIL expenditure were not implemented. \uf0b7 AGRA amended the disbursement of Grant due to low absorption and decided to de-obligate US$.571,167 being the total un-disbursed funds for the project thus necessity to restructure the budget and milestone delivery plan to fit within US$.323, 450 that had been disbursed. \uf0b7 Contrary to the grant guidelines, unspent or un-committed grant funds remained on the project bank account and were not invested in highly liquid investments to earn income. \uf0b7 A number of project milestones had not been achieved by the end of the financial year exposing the Grant to a risk of failure to achieve its objectives.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 147, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None"], "type": "table"}}, {"content": "135", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 147, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["10", "The Uganda Multi-Sectoral Food Security and Nutrition Project.", "\uf0b7 Out of the planned fourteen (14) strategic targets/goals to be achieved by financial year 2020/2021; ten (10) (71%) had been fully achieved while four (4) (29%) were partially achieved."], [null, "2020/21 Opinion Unqualified", null], ["11 The Regional Pastoral Livelihoods Resilience Project. 2020/21 Opinion Unqualified \uf0b7 Out of the planned fourteen (14) strategic targets/goals to be achieved by financial year 2020/2021; six (6) had been fully achieved, five (5) were partially achieved while three (3) were not achieved at all. \uf0b7 There was a shortfall in releases from the donor of UGX.13.788Bn which is 30% of the budget. The project budgeted to receive UGX.0.3Bn GOU funding all of which was availed. Further, the entity remained with unspent balance of UGX.15.172Bn representing an absorption level of 54%. \uf0b7 I reviewed all the eleven (11) outputs with a total of twenty six (26) activities and expenditure of UGX.17.71Bn and noted all were fully quantified. Further, assessment of the level of implementation for the 11 outputs revealed that five (5) outputs with nine (9) activities and expenditure worth UGX.0.765Bn were fully implemented while the six (6) outputs with seventeen (17) activities worth UGX.16.945Bn were partially implemented i.e. out of the seventeen (17) activities, the entity fully implemented seven (7) activities (41%); five (5) activities (29%) were partially implemented, while five (5) activities (29%) remained unimplemented. \uf0b7 Assessment of achievement of services from implemented outputs revealed that although the Livestock marketing Information System is in place, it lacks up to date information for the beneficiaries implying that it", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 148, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None"], "type": "table"}}, {"content": "136", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 148, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["may not be regularly used. \uf0b7 Contract works for the valley dams which are the critical infrastructure for the long term sustainability of the project are past the completion time and works are still significantly behind schedule despite contractors having been paid substantial percentages of the contract sums \uf0b7 Shortcomings were noted on reliability of the market information data system designed to track information such as prices, tradeable volumes, diseases concerning livestock for use by famers such as failure to input market information data into the system since October 2019, lack of a designated system administrator that is responsible for managing and updating the system at the Ministry and lack of a system manual that provides standard guideline for the system use. \uf0b7 There was no Steering committee sitting during the year to facilitate and to ensure adherence to relevant strategies established by Government during project implementation.", null, null], ["12", "Dairy Development Authority.", "\uf0b7 DDA\u2019s dairy strategic plan had been prepared, approved and certified by NPA to evidence its alignment to the NDP-III."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 149, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None"], "type": "table"}}, {"content": [["may not be regularly used. \uf0b7 Contract works for the valley dams which are the critical infrastructure for the long term sustainability of the project are past the completion time and works are still significantly behind schedule despite contractors having been paid substantial percentages of the contract sums \uf0b7 Shortcomings were noted on reliability of the market information data system designed to track information such as prices, tradeable volumes, diseases concerning livestock for use by famers such as failure to input market information data into the system since October 2019, lack of a designated system administrator that is responsible for managing and updating the system at the Ministry and lack of a system manual that provides standard guideline for the system use. \uf0b7 There was no Steering committee sitting during the year to facilitate and to ensure adherence to relevant strategies established by Government during project implementation.", null, null], ["12", "Dairy Development Authority.", "\uf0b7 DDA\u2019s dairy strategic plan had been prepared, approved and certified by NPA to evidence its alignment to the NDP-III."], [null, "2020/21 Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 DDA directly received off-budget financing to a tune of UGX.0.63Bn from"], [null, null, "Fleming fund country grant II but it was never declared to the PSST and"], [null, null, "as such not appropriated to the entity by parliament."], [null, null, "\uf0b7 I sampled 4 outputs for review with a total of twenty four (24) activities"], [null, null, "and expenditure of UGX.3.8Bn and noted that One (01) output with four"], [null, null, "(04) activities and expenditure worth UGX1.1Bn was insufficiently"], [null, null, "quantified, that is, one (01) activity (25%) was quantified while three"], [null, null, "(03) activities (75%) were not clearly quantified to enable assessment of"], [null, null, "performance. Three (03) outputs with a total of twenty (20) activities and"], [null, null, "expenditure worth UGX.2.7Bn were not quantified at all. Further, I"], [null, null, "assessed the implementation of one activity that was quantified and"], [null, null, "noted that the Rehabilitation of Kyegegwa and Katakwi Milk Collection"], [null, null, "Centres(MCCs) was partially implemented."], [null, null, "\uf0b7 Submission of performance reports for the four quarters was made after"], [null, null, "the deadline dates and there was no evidence to confirm that the"], [null, null, "Accounting Officer prepared Monitoring Plans and reports which affect"], [null, null, "timely tracking and evaluation of performance."], [null, null, "\uf0b7 Analysis of the domestic arrears showed new arrears incurred during the"], [null, null, "year under review to the tune of UGX.0.178Bn. Further, I noted that"], [null, null, "there was no budget provision for settlement of these arrears in the year"], [null, null, "under review."], [null, null, "\uf0b7 I noted that the entity lost fixed assets through theft which included"], [null, null, "fifteen (15) desktop computers, two (02) laptop computers, a projector, a"], [null, null, "router, and cameras but they were not disclosed in the financial"], [null, null, "statements."], [null, null, "\uf0b7 The Authority has failed to collect CESS revenue compensation from"], [null, null, "MoFPED contrary to the presidential directive requiring the same."], [null, null, "\uf0b7 DDA is understaffed by seventy seven (77) posts out of one hundred and"], [null, null, "forty (140) posts which is 55% understaffing. The unfilled posts include"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 149, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None"], "type": "table"}}, {"content": "137", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 149, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "key positions like Head of internal audit, Director Finance and"], [null, "Administration, Planner, Regional managers, Principal Dairy Development"], [null, "Officers and Dairy inspectors. Some posts have remained vacant since"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 150, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": [["", "key positions like Head of internal audit, Director Finance and"], [null, "Administration, Planner, Regional managers, Principal Dairy Development"], [null, "Officers and Dairy inspectors. Some posts have remained vacant since"], [null, "2003."], ["13 National Agricultural Advisory Services (NAADS). 2020/21 Opinion Unqualified \uf0b7 The entity had prepared the strategic plan; but there was no approval and certification of the same by NPA to evidence alignment to the NDP- III at the time of audit. \uf0b7 Out of the budgeted NTR of UGX.3.587Bn, the Authority collected only UGX.0.12Bn, representing a performance of 3.3% of the target. There was 100% performance in GoU releases amounting to UGX. 243.9Bn. Further, NAADS remained with unspent balance of UGX.0.06Bn representing an absorption level of 99.9%. \uf0b7 I sampled four (04) outputs with a total of twenty five (25) activities and expenditure of 184.4Bn and noted that two (02) outputs with a total of three (03) activities and expenditure worth UGX.43.19Bn were fully quantified while two (02) outputs with a total of twenty two (22) activities and expenditure worth UGX.141.19Bn were insufficiently quantified i.e. out of the twenty two (22) activities, fourteen (14) activities (64%) were quantified while the balance of eight (08) activities (36%) were not clearly quantified. Further, assessment of the implementation of the two (2) outputs that were fully quantified with a total of three (03) activities revealed that none was fully implemented. \uf0b7 Assessment of one partially implemented output revealed that out of 3,010,000 hand hoes, only 2,500,000 hand hoes were procured and distributed to the Northern parts of the country instead of the planned vulnerable rural small holder farming households across the country. \uf0b7 Submission of performance reports for all quarters was made after the deadline dates. Furthermore, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports. \uf0b7 NAADS incurred huge LC charges to a tune of UGX.1.053Bn as a result of opened LCs worth UGX.71.25Bn for contracts that failed to deliver within the year. Further, I noted LCs worth UGX.23.13Bn that failed to perform for a period of more than two (2) financial years with one of UGX.2.071Bn for milk coolers outstanding for more than 4 years. \uf0b7 Review of the Kasese industrial park Agri-LED intervention worth UGX.3.9Bn revealed allocation of land to a bus company contrary to the set objectives and delayed payment of NWSC to connect piped water. \uf0b7 Review of the sugarcane production project implementation with investments of UGX.85Bn revealed shortcomings i.e.lack of feasibility assessment, lack of accruing benefits to the beneficiaries, weaknesses in the MoU signed with beneficiaries, limited information on members of the cooperatives, delays in contract completions, pending liquidated damages, and stalled activities. \uf0b7 I noted failure to enter into MOU\u2019s with beneficiaries of milk coolers contrary to the selection criteria of the standing orders of procedure for operation wealth creation. \uf0b7 There was lack of clearly identified beneficiaries from the start in the transportation and distribution of hoes intervention, lack of MOU\u2019s with delegated DLGs on distribution modalities and nugatory storage costs. \uf0b7 Review of the tractor strategic intervention revealed lack of assessment of potential beneficiaries and non-adherence to the terms of the MoU thus risks of beneficiaries without the capacity to manage the tractor for", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 150, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": "138", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 150, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["farming practice or as an enterprise. \uf0b7 NAADS had a Covid 19 arrears supplementary budget of UGX.17.84Bn all of which was warranted and absorbed. Further, review of utilisation revealed failure to settle long outstanding payables, appropriation in excess of requirement and diversion of Covid 19 relief funds worth UGX.10.032Bn from the settlement of domestic arrears to settlement of current year bills without seeking and obtaining the necessary approvals \uf0b7 A trend analysis of the domestic arrears showed an increase of UGX.7.085Bn (53.6%) from UGX.13.23Bn in the previous year to UGX.20.31Bn that remained unsettled at close of the year with arrears of UGX.0.162Bn relating to previous financial years. \uf0b7 Funds worth UGX.2.15Bn were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals \uf0b7 I noted long outstanding receivables of UGX.2.38Bn relating to cash balances and accountabilities that remained at the DLG at the time of restructuring thus casting doubt on their recoverability. \uf0b7 Review of the procurement function revealed shortcomings such as delayed supplies and unjustified extensions and non execution of performance security. \uf0b7 I noted that NAADS has an approved staff structure of 56 positions out of which 53 (94.6%) positions are filled. Key among the vacant posts is Manager Finance and Administration and Zonal Agricultural Development Officer. Further, I noted temporary appointments of six (6) staff for the sugarcane field based team for 30 months contrary to the recommended 12 months as stipulated in the regulations.", null, null, null], ["14", "Ministry of Agriculture, Animal, Industry and Fisheries (MAAIF). 2020/21", null, "\uf0b7 I noted that the Ministry had prepared the Agro-Industrialization (AGI) Programme as a strategic plan for 2020/21-2024/25 that is aligned to the NDP-III and according to the certificate of compliance for the FY 2020/21"], [null, null, null, "annual budget, the overall Agro-industrialization programme budget was"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 151, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None", "None"], "type": "table"}}, {"content": [["farming practice or as an enterprise. \uf0b7 NAADS had a Covid 19 arrears supplementary budget of UGX.17.84Bn all of which was warranted and absorbed. Further, review of utilisation revealed failure to settle long outstanding payables, appropriation in excess of requirement and diversion of Covid 19 relief funds worth UGX.10.032Bn from the settlement of domestic arrears to settlement of current year bills without seeking and obtaining the necessary approvals \uf0b7 A trend analysis of the domestic arrears showed an increase of UGX.7.085Bn (53.6%) from UGX.13.23Bn in the previous year to UGX.20.31Bn that remained unsettled at close of the year with arrears of UGX.0.162Bn relating to previous financial years. \uf0b7 Funds worth UGX.2.15Bn were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals \uf0b7 I noted long outstanding receivables of UGX.2.38Bn relating to cash balances and accountabilities that remained at the DLG at the time of restructuring thus casting doubt on their recoverability. \uf0b7 Review of the procurement function revealed shortcomings such as delayed supplies and unjustified extensions and non execution of performance security. \uf0b7 I noted that NAADS has an approved staff structure of 56 positions out of which 53 (94.6%) positions are filled. Key among the vacant posts is Manager Finance and Administration and Zonal Agricultural Development Officer. Further, I noted temporary appointments of six (6) staff for the sugarcane field based team for 30 months contrary to the recommended 12 months as stipulated in the regulations.", null, null, null], ["14", "Ministry of Agriculture, Animal, Industry and Fisheries (MAAIF). 2020/21", null, "\uf0b7 I noted that the Ministry had prepared the Agro-Industrialization (AGI) Programme as a strategic plan for 2020/21-2024/25 that is aligned to the NDP-III and according to the certificate of compliance for the FY 2020/21"], [null, null, null, "annual budget, the overall Agro-industrialization programme budget was"], [null, "Opinion Unqualified", null, "scored at 63.5% compliance to the NDP-III."], [null, null, null, "\uf0b7 There was a shortfall in NTR collections amounting to UGX.6.82bn representing 76% and a shortfall in GOU releases amounting to"], [null, null, null, "UGX.24.1Bn representing 14%. Further, out of the total warrants of"], [null, null, null, "UGX.151.2Bn received, UGX.146.95Bn was spent by the entity resulting in an unspent balance of UGX.4.24Bn representing absorption of 97%."], [null, "", "", "\uf0b7 The Ministry received off-budget financing to a tune of UGX.1.78Bn that"], [null, "", "", "was not appropriated as part of the entity budget contrary to the law."], [null, "", "", "\uf0b7 I sampled sixty-five (65) outputs with a total of one hundred and sixty-"], [null, "", "", "seven (167) activities and expenditure of UGX.98.2Bn for assessment. I"], [null, "", "", "noted that; sixty-one (61) outputs with a total of one hundred and sixty"], [null, "", "", "(160) activities and expenditure worth UGX.89.6Bn were fully quantified"], [null, "", "", "while four (4) outputs with a total of seven (7) activities and expenditure"], [null, "", "", "worth UGX.8.6Bn were not quantified at all to enable assessment of"], [null, "", "", "performance. Further, I assessed all the quantified 61 outputs and noted"], [null, "", "", "that; 34 outputs with a total of 75 activities worth UGX.39.1Bn were fully"], [null, "", "", "implemented and 27 outputs with a total of 85 activities worth"], [null, "", "", "UGX.50.5Bn were partially implemented i.e. out of the 85 activities, the"], [null, "", "", "Ministry fully implemented 39 activities (46%), partially implemented 44"], [null, "", "", "activities (52%) while 2 activities (2%) remained unimplemented."], [null, "", "", "\uf0b7 I noted failure of timely interventions to combat the foot and mouth"], [null, "", "", "disease (FMD) outbreak as a result of challenges faced in the"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 151, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None", "None"], "type": "table"}}, {"content": "139", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 151, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "procurement of vaccines despite the availability of funds. The Ministry"], [null, "faced challenges as only 500,000 doses were delivered out of the"], [null, "procured 700,000 doses from the prior year and these came 4 months"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 152, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": [["", "procurement of vaccines despite the availability of funds. The Ministry"], [null, "faced challenges as only 500,000 doses were delivered out of the"], [null, "procured 700,000 doses from the prior year and these came 4 months"], [null, "after expected delivery. Further, none of the procured 2,311,000 doses"], [null, "procured in May 2020 were delivered within the contract period despite"], [null, "the emergency situation and by the time of audit, the contract had not"], [null, "fully performed with 611,000 doses outstanding."], [null, "\uf0b7 Shortcomings were noted in the management of the Ministry Public"], [null, "Investment Plan (PIP) Projects in regard to compliance with the"], [null, "Development Committee Guidelines 2016 and the budget execution"], [null, "circular 2020/2021. I noted incomplete approvals for Projects, non-"], [null, "adherence of Projects with appraisal Guidelines, ongoing projects after"], [null, "expiry of project duration and irregular and excessive spending on"], [null, "recurrent Items"], [null, "\uf0b7 Domestic arrears decreased by 14% from UGX.12.96Bn in the prior year"], [null, "to UGX.11.13Bn in the year under review. Further, a paltry UGX.2.42Bn"], [null, "budget provision was provided for settlement of domestic arrears in the"], [null, "current year budget."], [null, "\uf0b7 All documents pertaining to Contingency fund activities and transfers to"], [null, "agricultural institutions during the year worth UGX 11.95Bn were"], [null, "submitted to the IGG for investigations and I was unable to confirm"], [null, "whether the amount involved was applied to the intended purpose."], [null, "\uf0b7 Management did not undertake monthly wage and pension performance"], [null, "analysis to reconcile the payroll generated through the IPPS with the"], [null, "payment information from the IFMS as required resulting into delays in"], [null, "granting clearance to recruit, inefficient wage and pension payroll"], [null, "management, accumulated arrears and non-absorption of pension and"], [null, "gratuity budget."], [null, "\uf0b7 Out of 919 approved staffing positions, only 595 had been filled and the"], [null, "rest of the positions (324) were vacant representing 35% staffing gap."], [null, "Among the vacant were key positions such as directors, commissioners,"], [null, "assistant commissioners and principals in core directorates and noticed"], [null, "management\u2019s failure to undertake timely recruitments despite availability"], [null, "of funds."], ["15 Uganda Coffee Development Authority (UCDA). 2020/21 Opinion Unqualified \uf0b7 The entity had prepared the coffee strategy; but there was no approval and certification of the strategic plan by NPA to evidence alignment to the NDP-III at the time of audit. \uf0b7 Out of the budgeted NTR of UGX.27.5Bn, the Authority collected only UGX.20.1Bn, representing a performance of 73% of the target. \uf0b7 There was a shortfall in GoU releases amounting to UGX.5.8Bn representing 3.1% of the budgeted UGX.186.3Bn. Further, the entity remained with unspent balance of UGX.9.391Bn representing an absorption level of 94.8%. \uf0b7 The Authority received off-budget financing worth UGX.443M which was never declared to the PSST and as such no supplementary appropriation was issued as guided by the PSST. \uf0b7 I sampled eight (08) outputs with a total of sixty two (62) activities and expenditure of UGX.150.6Bn and noted that one (01) output with a total of four (04) activities and expenditure worth UGX.2.1Bn was fully quantified; three (03) outputs with a total of fifty four (54) activities and expenditure worth UGX.67.1Bn were insufficiently quantified i.e. out of the fifty four (54) activities, forty nine (49) activities (91%) were quantified while the balance of five (05) activities (9%) were not clearly", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 152, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": "140 \nquantified and four (04) outputs with a total of four (04) activities and expenditure worth UGX.81.3Bn were not quantified at all. Further, assessment of the implementation of the one (01) output that was fully quantified with a total of four (04) activities revealed that it was partially implemented i.e. out of the four (4) activities, the entity fully implemented three (03) activities (75%) while one (1) activity (25%) remained unimplemented.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 152, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Submission of performance reports for three quarters was made after the deadline dates. Furthermore, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Review of the distribution lists (form Bs) attached to the accountabilities for coffee seedlings supplied revealed that deliveries to a tune of UGX.0.213Bn were made either out of season or towards season end thus rendering the survival of the inputs nearly impossible.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Fertilizers worth UGX.2.25Bn distributed to the cooperatives were unacknowledged by the intended coffee farmers. The form F3\u2019s where the actual farmers who received the fertilisers were supposed to have acknowledged had not yet been received and verified by management and neither had the cooperatives returned the empty fertiliser bags and filled in form F4\u2019s.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- 65,445 and 1880 bags of fertilisers for the western and Elgon region respectively had not yet been distributed at the time of inspection in September 2021 contrary to section 7 (a) of the fertiliser distribution guidelines that required application of fertilisers to only be done in the rainy season.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Field inspection of the procured fertilizers and materials to support the establishment of CWDR nurseries revealed several anomalies i.e. bad warehousing storage (stacked high on the floor, instead of pallets), lack of aeration and non-adherence to first in first out (FIFO) policy. Further, the nurseries for CWDR had not been setup and materials were simply kept in stores by the beneficiaries and some had started using the implements such as hoes, pangas, wheel burrows; mother gardens were poorly maintained and no labels of the lines had been added to the mother gardens.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UCDA had a Covid 19 arrears supplementary budget of UGX.73Bn all of which was warranted and absorbed 100%. Review of utilisation revealed doubtful payments, duplicated arrears on verified list and witting down of invoice amounts without supplier consent which exposes the entity to litigation", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Domestic arrears showed a movement in arrears from UGX.120,383,249,500 in the previous year to UGX.23,036,904,150 by the close of the financial year 2019/20, representing a decrease of 80.8%. Out of this, amount UGX.16,699,179,350 was incurred during the year under review.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A total of UGX.80,373,239,334 (43.1% of the approved budget) was provided for settlement of domestic arrears, however, arrears worth UGX.125,407,367,170 were paid resulting in settlement of prior year domestic arrears worth UGX.45,034,127,836.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Review of the procurement function revealed several shortcomings such as delays in the procurement process with an average delay period of 2 and a half months, failure to deliver within contractual timelines, un- deducted liquidated damages, inconsistent liquidated damages clauses and deviation from Ministry of Works specifications for vehicle", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "141", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", null, null], ["16", "Uganda Seeds Limited. 2019/20", "\uf0b7 A receivable of UGX.1,147,910,181 (17% of the total assets) could not be supported as there was no evidence to confirm the accuracy, existence and completeness of the reported balance."], [null, "Opinion Qualified", null], ["JUSTICE, LAW AND ORDER SECTOR", null, null], ["1", "Directorate of Government Analytical Laboratory (DGAL).", "\uf0b7 Out the total receipts for the financial year of UGX.24.684Bn, only UGX.15.630Bn was spent by the entity resulting in an unspent balance of UGX.9.054Bn representing an absorption level of 63.3%."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 154, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "142", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 154, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "their contract obligations."], [null, "\uf0b7 In the financial year 2019/2020, DGAL procured digital forensic tools for"], [null, "use to recover data on mobile phones at an estimated cost of USD.82,000"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 155, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None"], "type": "table"}}, {"content": [["", "their contract obligations."], [null, "\uf0b7 In the financial year 2019/2020, DGAL procured digital forensic tools for"], [null, "use to recover data on mobile phones at an estimated cost of USD.82,000"], [null, "(equivalent to UGX.290,232,000). In the period since acquisition, the"], [null, "entity has only used the forensic tools and equipment to process and"], [null, "analyse just one (1) case raising the possibility that the equipment is"], [null, "under-utilised."], [null, "\uf0b7 Nine (9) staff positions for a Commissioner, Government Analysts and"], [null, "drivers in the Directorate were cleared by the Ministry of Public Service"], [null, "for recruitment, and the directorate received funding amounting to"], [null, "UGX.0.032Bn for the purpose. The recruitment process had not been"], [null, "finalised at the year end and the funds were returned to the consolidated"], [null, "fund."], [null, "\uf0b7"], ["2 Justice Law and Order Sector JLOS-SWAP. 2019/20 Opinion Unqualified \uf0b7 I noted that out of the budgeted revenue of UGX. 121,683,362,209 for the financial year 2019/2020 only UGX. 104,870,934,098 (86%) was released, resulting in a shortfall of UGX. 16,812,428,111 (14%) on the overall. The largest shortfall of UGX. 10,304,157,202 (8.4%) was in respect to the Development Partners funding, \uf0b7 A review of the JLOS SWAP disbursement of funds to implementing entities and the respective actual expenditure revealed that only UGX. 81,391,358,207 was spent out of the availed UGX.104,870,934,098, resulting in an unspent balance of UGX.31,080,004,792. The unspent balance excludes the JLOS House Project balance of UGX. 18,592,439,794, which commenced in the subsequent financial year 2020/21. \uf0b7 I reviewed all the 43 activities under the JLOS Secretariat with a budget of UGX.23.561Bn, out of which UGX.18.027Bn was released, resulting in a shortfall of UGX.5.534Bn, which is 23.5% of the budget \uf0b7 I further noted from the analysis of the annual performance report that some critical activities for which funds had been released had not been implemented. \uf0b7 Out of the 43 activities with a total budget of UGX.23.561Bn, I reviewed the extent of quantification of outputs and activities and noted that a total of three (3) activities and releases worth UGX.4.076Bn were not quantified at all to enable assessment of performance. A total of forty (40) activities and releases worth UGX.13.951Bn were fully quantified. That is, all the forty (40) activities (100%) were clearly quantified to enable assessment of performance. \uf0b7 I assessed the implementation of all the Forty (40) JLOS SWAP activities worth UGX.13.951Bn that were fully quantified and noted that Fourteen (14) activities worth UGX.12.507Bn were fully implemented. The entity implemented all the Fourteen (14) activities (100%) within the JLOS SWAP consolidated strategic outputs. Four (4) activities worth UGX.0.665Bn were partially implemented. All the Four (4) activities within the JLOS SWAP consolidated strategic outputs were not achieved 100%. Twenty-two (22) activities worth UGX0.779Bn were not implemented at all. \uf0b7 I observed that UGX.656,905,350 advanced to various beneficiaries by four implementing agencies to execute sector activities during the COVID- 19 lockdown period, i.e. between November 2019 and June 2020, lacked the necessary supporting documents such as payment vouchers, activity reports and receipts at the time of audit (November 2020) and were", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 155, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None"], "type": "table"}}, {"content": "143", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 155, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["submitted during the month of January 2021, implying that the funds had not been accounted for by 30th June 2020. \uf0b7 I noted from the review of financial statements that management did not disclose the outstanding balances as at 30th June 2019. Consequently, no provision was made to cater for domestic arrears in the financial year 2019/2020 budget. But I noted that UGX.9,145,799 was spent to settle outstanding bills in respect of conference facilities for JLOS and the supply and delivery of law reference books", null, null, null], ["3", "Office of the Director of Public Prosecutions. 2020/21 Opinion Unqualified", null, "\uf0b7 During the years under review, 666,620 cases were brought forward from the previous years, and 99,232 cases were registered during the year, giving a cumulative sum of 765,492 cases recorded. Of these cumulative"], [null, null, null, "cases, only 40,466 (5%) were cleared during the year. \uf0b7 Over the five years only 253,596 cases representing (33%) have been"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 156, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None", "None"], "type": "table"}}, {"content": [["submitted during the month of January 2021, implying that the funds had not been accounted for by 30th June 2020. \uf0b7 I noted from the review of financial statements that management did not disclose the outstanding balances as at 30th June 2019. Consequently, no provision was made to cater for domestic arrears in the financial year 2019/2020 budget. But I noted that UGX.9,145,799 was spent to settle outstanding bills in respect of conference facilities for JLOS and the supply and delivery of law reference books", null, null, null], ["3", "Office of the Director of Public Prosecutions. 2020/21 Opinion Unqualified", null, "\uf0b7 During the years under review, 666,620 cases were brought forward from the previous years, and 99,232 cases were registered during the year, giving a cumulative sum of 765,492 cases recorded. Of these cumulative"], [null, null, null, "cases, only 40,466 (5%) were cleared during the year. \uf0b7 Over the five years only 253,596 cases representing (33%) have been"], [null, null, null, "concluded through conviction, acquittal, withdrawal, dismissal and closed files. \uf0b7 ODPP continues to incur substantial annual maintenance costs of"], [null, "", "", "UGX.2,808,000,000 in spite of the low coverage of the system (only 41"], [null, "", "", "stations out of the planned 138) and some system components like the complaint handling and processing component are not fully operational."], [null, "", null, null], ["4 Uganda Human Rights Commission 2020/21 Opinion Unqualified \uf0b7 I noted that the Commission did not have an approved strategic plan that was aligned to NDP III by the time of audit. The draft plan prepared by the entity had not been certified by NPA. \uf0b7 The Commission collected over 100% of its NTR target for the year over and above the target. The Commission absorbed only 86.8% of the funds that were released by government. \uf0b7 The Commission received off-budget financing directly from development partners to a tune of UGX.2.187Bn, which was not declared to Treasury and, therefore, not appropriated to the entity by Parliament. \uf0b7 Management did not quantify 2 outputs with 6 activities and expenditure worth UGX 0.12Bn. \uf0b7 Out of (11) outputs that were fully quantified with 22 activities, 3 activities worth UGX.0.44Bn were fully implemented, 18 activities worth UGX.15.54Bn were partially implemented. 1 output with 1 activity worth UGX.0.17Bn was not implemented at all. \uf0b7 \uf0b7 The Commission neither prepared annual budget monitoring plans nor submitted quarterly budget monitoring reports. The Commission also failed to submit all its quarterly budget performance reports in time. \uf0b7 The UHRC had tribunal case backlog of 1,756 cases at the beginning of the financial year 2020/2021, and 71 additional cases were registered during the year, resulting in a total of 1,827 outstanding cases. Out of the 1,827 cases, only 326 (17.8%) were investigated and disposed of. The", null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 156, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None", "None"], "type": "table"}}, {"content": "144", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 156, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["un-cleared complaints at the tribunal level stood at 1,501 at the year-end, translating into underperformance of 82.2%. \uf0b7 Timeline errors continue to occur due to the limited interface between IPPS and IFMS in payroll processing. A review of the payroll register and IFMS payment file revealed that UGX.5.706 Bn was paid as per payroll register; while IFMS indicates that UGX.6.124Bn was paid, resulting in an overpayment of UGX. 0.417Bn.", null, null], ["5", "Uganda Law Reform Commission. 2020/21", "\uf0b7 I noted that the Commission did not have an approved strategic plan that was aligned to NDP III by the time of audit. The draft plan prepared by the entity had not been certified by NPA. \uf0b7 The Commission collected only 100% of its NTR target for the year which was commendable. The Commission also absorbed only 92.4% of the"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 157, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": [["un-cleared complaints at the tribunal level stood at 1,501 at the year-end, translating into underperformance of 82.2%. \uf0b7 Timeline errors continue to occur due to the limited interface between IPPS and IFMS in payroll processing. A review of the payroll register and IFMS payment file revealed that UGX.5.706 Bn was paid as per payroll register; while IFMS indicates that UGX.6.124Bn was paid, resulting in an overpayment of UGX. 0.417Bn.", null, null], ["5", "Uganda Law Reform Commission. 2020/21", "\uf0b7 I noted that the Commission did not have an approved strategic plan that was aligned to NDP III by the time of audit. The draft plan prepared by the entity had not been certified by NPA. \uf0b7 The Commission collected only 100% of its NTR target for the year which was commendable. The Commission also absorbed only 92.4% of the"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 Out of the 8 outputs assessed with 37 activities and expenditure of"], [null, null, "UGX.7.74Bn, 6 outputs with worth UGX.4.53Bn were fully quantified."], [null, null, "\uf0b7 I assessed the implementation of 6 outputs with 24 activities that were"], [null, null, "fully quantified and noted that 1 output with 3 activities and expenditure"], [null, null, "worth UGX 3.43Bn was fully implemented while 5 outputs with 21"], [null, null, "activities worth UGX.1.1Bn were partially implemented. Out of the 21"], [null, null, "activities, the entity fully implemented 9 activities, 4 activities were"], [null, null, "partially implemented, while 8 activities remained unimplemented."], [null, null, "\uf0b7 The Commission neither prepared annual budget monitoring plans nor"], [null, null, "submitted quarterly budget monitoring reports. The Commission also"], [null, null, "failed to submit all its quarterly budget performance reports in time."], [null, null, "\uf0b7 ULRC did not have any domestic arrears brought forward from the"], [null, null, "previous year; however, the entity recorded payables worth"], [null, null, "UGX.124,626,384 under court awards and compensations in the year"], [null, null, "under audit."], ["6 Judicial Service Commission 2020/21 Opinion Unqualified \uf0b7 I noted that the Commission submitted a draft strategic plan to NPA for approval. \uf0b7 The Commission budgeted for NTR of UGX.4.5bn for the financial year 2020/21, however only UGX. 788,000 was collected representing performance of 0.02% of the target. The Commission absorbed 95.7% of the funds that were released. \uf0b7 Out of the fifteen (15) outputs sampled, ten (10) were fully quantified, while one (1) was insufficiently quantified and two (2) were not quantified at all. \uf0b7 Out of the ten (10) outputs assessed, five (5) were fully implemented while five (5) were partially implemented. \uf0b7 The Commission neither prepared annual budget monitoring plans nor submitted quarterly budget monitoring reports. The Commission also failed to submit all its quarterly budget performance reports in time. \uf0b7 Out of the approved 143 staff positions, ninety-seven (97) positions were filled while forty-seven (47) positions were vacant. \uf0b7 The commission did not remit to URA PAYE of UGX.138,219,093.", null, null], ["7", "Ministry of Justice and Constitutional Affairs. 2020/21", "\uf0b7 At the time of audit, the entity strategic plan had not yet been submitted to NPA; management was awaiting the completion of revising"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 157, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "145", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 157, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Opinion", "the Governance and Security Programme. \uf0b7 The entity budgeted to collect NTR of UGX.0.112Bn but collected UGX.0.233Bn representing a performance of 208% of the target."], [null, "Unqualified", null], ["8 The Directorate of Citizenship and Immigration Control. 2020/21 Opinion Unqualified \uf0b7 The DCIC prepared a strategic plan for 2020-2025 that was approved by the National Planning Authority on 22nd November 2021. However, following the issuance of a Certificate of Approval, management had not approved the plan for implementation. \uf0b7 \uf0b7 Out of the total receipts for the financial year of UGX.104.9Bn, only UGX.103.9Bn was spent by the entity resulting in an unspent balance of UGX.1.0Bn representing an absorption level of 99%. \uf0b7 I sampled seventeen (17) outputs with a total of one hundred seventeen (117) activities and expenditure of UGX.101.8Bn for assessment and noted that eleven (11) outputs with expenditure worth UGX.26.95Bn were fully quantified. Five (5) outputs with worth UGX.74.09Bn were insufficiently quantified, and One (1) output with expenditure worth UGX.0.13Bn was not quantified at all \uf0b7 I noted that a sum of UGX.1.02Bn was released to DCIC to settle Domestic Arrears to a supplier under Covid-19 related funding. \uf0b7 An assessment of service delivery revealed that DCIC takes an average of 7.7 days to process a passport and a further 7.3 days from the date of printing to issue the passport to the citizens. I further observed that although the Directorate has several regional offices for processing of passports, 97% of the applications for passports and 92% of the issuances are done at the Central Office in Kampala. \uf0b7 A trend analysis of the Directorate domestic arrears over the past three", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 158, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "146", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 158, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["years showed a decreasing trend from UGX.4.19Bn in 2018/2019 to UGX.0.32Bn in 2020/2021. \uf0b7 A review of the approved budget estimates for the year revealed that only UGX.1,015,473,085 (11.4%) was budgeted and released to settle domestic arrears amounting to UGX.8,898,668,915, implying insufficient budgeting for domestic arrears. \uf0b7 The Directorate procured an e-visa and permit management system during the financial year. I observed a number of contract conditions, including final user acceptance testing, completion of the setup of the system workflow, training of end-users, and integration of the system to other government systems in NIRA, CAA, URSB, and URA had not yet to be achieved. \uf0b7 The Directorate procured a consultant for the configuration, installation and maintenance of an Integrated System for archived records and the maintenance of the electronic data management system. I observed delays in contract execution and that the entity did not have a Service Level Agreement to guide the support and maintenance of the system.", null, null], ["9", "The Court of Judicature (The Judiciary).", "\uf0b7 The Judiciary prepared a strategic plan and had it approved by NPA at the time of audit."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 159, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": [["years showed a decreasing trend from UGX.4.19Bn in 2018/2019 to UGX.0.32Bn in 2020/2021. \uf0b7 A review of the approved budget estimates for the year revealed that only UGX.1,015,473,085 (11.4%) was budgeted and released to settle domestic arrears amounting to UGX.8,898,668,915, implying insufficient budgeting for domestic arrears. \uf0b7 The Directorate procured an e-visa and permit management system during the financial year. I observed a number of contract conditions, including final user acceptance testing, completion of the setup of the system workflow, training of end-users, and integration of the system to other government systems in NIRA, CAA, URSB, and URA had not yet to be achieved. \uf0b7 The Directorate procured a consultant for the configuration, installation and maintenance of an Integrated System for archived records and the maintenance of the electronic data management system. I observed delays in contract execution and that the entity did not have a Service Level Agreement to guide the support and maintenance of the system.", null, null], ["9", "The Court of Judicature (The Judiciary).", "\uf0b7 The Judiciary prepared a strategic plan and had it approved by NPA at the time of audit."], [null, "2020/21 Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 Thirteen (13) outputs with a total of sixty-seven (67) activities were"], [null, null, "quantified, while seven (7) outputs with a total of twenty-seven (27)"], [null, null, "activities were insufficiently quantified, and six (6) outputs with a total of"], [null, null, "forty-five (45) activities were not quantified at all. Further, of the thirteen"], [null, null, "(13) quantified outputs/activities assessed, five (5) outputs with fourteen"], [null, null, "(14) activities were fully implemented; eight (8) outputs with fifty-three"], [null, null, "activities were partially implemented."], [null, null, "\uf0b7 Submission of all performance reports for all the quarters was made after"], [null, null, "the deadline dates."], [null, null, "\uf0b7 I noted the accumulation of case backlog due to delayed"], [null, null, "operationalisation of gazetted courts and a limited number of judicial"], [null, null, "officer\u2019s compared to the workload."], [null, null, "\uf0b7 Judiciary had a COVID 19 arrears supplementary budget of UGX.8.66Bn,"], [null, null, "all of which was warranted and spent representing 100% of the budget"], [null, null, "absorption."], [null, null, "\uf0b7 I noted an increase in receivables from UGX 661,164,656(2019/2020) to"], [null, null, "UGX 3,268,317,882 (2020/2021). This was partly due to UGX."], [null, null, "1,652,842,084 that was advanced to courts to undertake election"], [null, null, "petitions and remained unaccounted for at the end of the financial year"], [null, null, "under audit. Furthermore, the other receivables of UGX.320,947,170"], [null, null, "carried forward from previous years remained outstanding with no"], [null, null, "recoveries made."], [null, null, "\uf0b7 I noted that management accrued new domestic arrears totalling UGX."], [null, null, "4,171,245,048 during the financial year 2020/2021 compared to UGX."], [null, null, "2,641,109,446 new arrears accrued in 2019/2020, registering an"], [null, null, "increment of new arrears of UGX. 1,530,135,602 thus representing a"], [null, null, "58% growth rate."], [null, null, "\uf0b7 Judiciary did not budget for domestic arrears amounting to UGX.3.543Bn,"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 159, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "147", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 159, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "which remained outstanding in the FY 2019/20."], [null, "\uf0b7 I noted inconsistencies in statistics reported on both pending and cases"], [null, "handled by the Judiciary during the period."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 160, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None"], "type": "table"}}, {"content": [["", "which remained outstanding in the FY 2019/20."], [null, "\uf0b7 I noted inconsistencies in statistics reported on both pending and cases"], [null, "handled by the Judiciary during the period."], [null, "\uf0b7 I noted delays in the implementation of The Electronic Court Case"], [null, "Management Information System (ECCMIS); an overall average delay of"], [null, "3 months since the Go-live had been scheduled on 7th June 2021. But, as"], [null, "of 11th October 2021, this has not yet been done. Data migration of the"], [null, "Phase 1 stations from CCAS into the new integrated ECCMIS has not"], [null, "been performed; the project was still at the design and development"], [null, "stage at the time of audit; the Change management training is still"], [null, "ongoing as of 6th October 2021, yet the training had been scheduled for"], [null, "23rd October 2020, some planned activities were not implemented, like"], [null, "the migration of data for phase 1 entities from the court case"], [null, "administration system (CCAS) to ECCMIS."], ["10 The Uganda Prisons Service. 2020/21 Opinion Unqualified \uf0b7 The UPS prepared a strategic plan for the period 2020-2025 and was approved by the National Planning Authority on the 23rd of July 2021. \uf0b7 Out of the total receipts for the financial year of UGX.310.8Bn, only UGX.306.5Bn was spent by the entity resulting in an unspent balance of UGX.4.4Bn representing an absorption level of 98.6%. \uf0b7 I sampled fourteen (14) outputs with a total of eighty seven (87) activities and expenditure of UGX.316.2Bn for assessment and noted that ten (10) outputs with a total of fifty-seven (57) activities and expenditure worth UGX.293.82Bn were fully quantified and four (4) outputs with a total of thirty (30) activities and expenditure worth UGX 22.36Bn were insufficiently quantified \uf0b7 I noted that of the 57 quantified activities worth UGX293.82Bn assessed; 35 activities representing 61% were fully implemented, 20 activities representing 35% were partially implemented, while 2 activities representing 4% were not implemented. \uf0b7 I noted that a sum of UGX. 40,6Bn was released to UPS for the settlement of Domestic Arrears to suppliers under Covid-19 related funding with all funds spent for settlement of arrears. \uf0b7 A trend analysis of the Service\u2019s domestic arrears over the past three years showed a decreasing trend from UGX.65.97Bn in 2018/2019 to UGX.62.345Bn in 2020/2021. \uf0b7 I noted that UPS was only allocated UGX.40.6Bn (67.4%) for settlement of domestic arrears worth UGX.60.2Bn and paid for arrears worth UGX.54.8Bn with the additional funds worth UGX.14.2Bn diverted from planned activities to pay for the arrears \uf0b7 An assessment of service delivery revealed cases of overcrowding in prison cells with the congestion levels increasing from 291.5% in 2017/18 to 321.1% in 2020/2021. This compromises the welfare of the inmates and may result in a number of health risks such as the quick spread of diseases and compromising on sanitation. The existing congestion has proved a challenge for the prisons\u2019 service when implementing Standard Operating Procedures (SOPs) to reduce the spread of COVID-19. It has also posed a challenge in separating different categories of offenders to break the cyclic chain of crime and violence. \uf0b7 I noted that a total of 33 (12.7%) prisons stations are still using the bucket system of sanitation which may turn cells into a breeding centre for diseases, resulting in the violation of the prisoners\u2019 rights \uf0b7 I noted cases of over stay of prisoners on remand with the prisoners\u2019", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 160, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None"], "type": "table"}}, {"content": "148", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 160, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["length of stay on remand increasing from 10.5 to 18.8 months for capital offenders and from 2.6 months to 3.8 months for petty offenders from 2016/17 to 2020/2021 respectively. For example out of the 32,409 prisoners on remand, a total of 13,933 prisoners had overstayed on remand \uf0b7 I observed challenges of staff accommodation which currently stands at a deficit of 7,217 (65.1%) housing units with staff staying in temporary houses/shelters/not accommodated \uf0b7 The Service also faced challenges of under staffing where out of an approved organisation structure comprising of 49,470 staff, only 12,860 (26%) posts were filled, leaving a balance of 36,610 (74%) posts vacant. This leads to high staff prisoner ratio and causes fatigue among the few staff \uf0b7 I noted that sixty-seven (67) of the prison stations did not have buses to enable safe and secure transportation of prisoners to court which resulted into delayed delivery of prisoners to courts, transportation of high-risk inmates on open trucks, and prisoners and staff walking long distances to attend court. \uf0b7 I noted delays in completion of the Prisoners Management Information System (PMIS) which has delayed the enjoyment of anticipated benefits from the system. \uf0b7 I observed challenges in land management including encroachments, land disputes and encumbrances. Out of 158 pieces of land of different sizes in the different parts of the country, only 52 pieces were surveyed and titled, 17 pieces were surveyed but still not yet titled, while 89 pieces were not yet surveyed. Furthermore, the UPS did not have land surveying equipment", null, null], ["11", "The Law Development Centre.", "\uf0b7 LDC had prepared the Strategic Plan aligned to NDP III and approved by NPA."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 161, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "149", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 161, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 The entity submitted all performance reports after the deadline."], [null, null, "\uf0b7 LDC had outstanding commitments brought forward totaling UGX."], [null, null, "2,697,202,827 as at 30th June 2020. During the year under review, UGX."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 162, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": [["", null, "\uf0b7 The entity submitted all performance reports after the deadline."], [null, null, "\uf0b7 LDC had outstanding commitments brought forward totaling UGX."], [null, null, "2,697,202,827 as at 30th June 2020. During the year under review, UGX."], [null, null, "1,490,351,141 was paid, and UGX. 786,304,467 was accumulated,"], [null, null, "leaving an outstanding of UGX. 1,993,156,153 as at 30th June 2021."], ["12 The Uganda Registration Services Bureau \u2013 Liquidation. 2020/21 Opinion Unqualified \uf0b7 The entity had a court appropriation of UGX.1.162Bn for the financial year 2020/2021 and an appropriation by court brought forward from the previous year 2019/2020 of UGX.0.640Bn totaling up to UGX.1.802Bn receipts. \uf0b7 Out of the total funds available for expenditure of UGX.1.802Bn, UGX.1.277Bn was spent by the bureau resulting in an unspent balance of UGX.0.525, representing an absorption level of 70.9%. \uf0b7 I reviewed all the outputs and noted that the outputs were all adequately quantified. \uf0b7 Out of the six (6) outputs assessed, one (1) was fully implemented, while five (5) were partially implemented. Five (5) outputs with twenty-four (24) activities worth UGX1.061Bn were partially implemented. \uf0b7 URSB did not prepare performance reports for liquidation. \uf0b7 I observed that the bureau had receivables carried forward from the previous financial years amounting to UGX.6.243Bn that remained outstanding at the end of the financial year under audit.", null, null], ["13", "The Uganda Registration", "\uf0b7 The URSB strategic plan was prepared and approved by NPA."], ["", "Services Bureau - Operations. 2020/21 Opinion", null], [null, "Unqualified", ""], [null, "", ""], [null, null, "\uf0b7 Out of the seven (7) outputs sampled, five (5) were fully quantified, while"], [null, null, "one (1) was insufficiently quantified and one (1) was not quantified at all."], [null, null, "\uf0b7 Out of the five (5) outputs assessed, two (2) were fully implemented"], [null, null, "while three (3) were partially implemented."], [null, null, "\uf0b7 Submission of all the quarterly performance reports was made after the"], [null, null, "deadline date. Also, inconsistencies were noted in the annual"], [null, null, "performance report and the system-generated reports. For example,"], [null, null, "management reported four (4) and two (2) patents to have been granted"], [null, null, "in the financial years of June 2020 and June 2021, respectively. Yet the"], [null, null, "system report analysis showed that no patent had been granted in the"], [null, null, "last two financial years."], [null, null, "\uf0b7 Despite a positive increase in the number of searches on the system,"], [null, null, "there was a significant decline in the performance of industrial designs"], [null, null, "registered, Local Trademarks renewed, Patents granted, and foreign"], [null, null, "trademarks registered"], [null, null, "\uf0b7 I analysed the number of applications received and eventually registered"], [null, null, "for the Utility model, patents and industrial designs and noted a"], [null, null, "significant difference in the number of applications that materialised to"], [null, null, "actual registrations. For instance, three (3) out of nineteen (19) Utility"], [null, null, "model applications were granted, two (2) out of the fifteen (15) Patent"], [null, null, "applications were granted, seventeen (17) out of the seventy-six (76)"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 162, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "150", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 162, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "were granted."], [null, "\uf0b7 I noted a decline in performance for activities planned under Civil"], [null, "Registration; the number of churches registered declined by 38.8%."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 163, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None"], "type": "table"}}, {"content": [["", "were granted."], [null, "\uf0b7 I noted a decline in performance for activities planned under Civil"], [null, "Registration; the number of churches registered declined by 38.8%."], [null, "Similarly, the number of Marriage returns FBOs, and Districts registered a"], [null, "decline in the performance of 17.56%."], [null, "\uf0b7 I noted shortcomings in the performance of the National Marriage"], [null, "registration system such as; NMRS could not internally generate reports;"], [null, "few staff are trained, incomplete information on certificates generated"], [null, "through the system, the system does not allow bulky payments, resulting"], [null, "in multiple bank charges to the customer, other systems of the Bureau"], [null, "like on base are not integrated with NMRS."], [null, "\uf0b7 URSB received COVID 19 arrears supplementary budget of"], [null, "UGX.0.0318Bn, all of which was spent representing 100% of the budget"], [null, "absorption."], [null, "\uf0b7 The Bureau had UGX.4.516Bn in domestic arrears, but it budgeted and"], [null, "was warranted UGX.0.032Bn, leaving a balance of UGX.4.484Bn"], [null, "unbudgeted. URSB effected payments totaling UGX.1.216Bnresulting in"], [null, "excess of UGX.1.184Bn above the approved budget. Domestic arrears"], [null, "increased by UGX.3.055Bn (68%) from UGX.1.466Bn to UGX.4.516Bn as"], [null, "at June 2021. The arrears remained unsettled at the close of the year."], [null, "\uf0b7 I reviewed the business registration system and noted the absence of an"], [null, "inbuilt mechanism to track and trace the movement and clearance of"], [null, "queries raised regarding name reservations and applications. The entity"], [null, "still has some processes that use manual backup. There were delays in"], [null, "the development of the Quality Management system ISO 9001(QMS)"], ["14 The Ministry of Internal Affairs. 2020/21 Opinion Unqualified \uf0b7 The Ministry of Internal Affairs prepared a strategic plan for 2020-2025. However, it had not been approved by the National Planning Authority at the time of audit. \uf0b7 Out of the total receipts for the financial year of UGX.51.5Bn, only UGX.50.8Bn was spent by the entity resulting in an unspent balance of UGX.0.7Bn representing an absorption level of 99%. \uf0b7 I sampled forty-one (41) outputs with a total of one hundred and ninety- seven (197) activities and expenditure of UGX.37.7Bn for assessment and noted that fifty-nine (59) activities with expenditure worth UGX.11.30Bn were fully quantified. one hundred thirty-seven (137) activities with worth UGX.26.1Bn were insufficiently quantified, and one (1) activity with expenditure worth UGX.0.24Bn was not quantified at all \uf0b7 An assessment of service delivery revealed that in the financial year 2020/2021, the Ministry extended support to 299 victims of human trafficking, which is only 45% of the total victims of human trafficking as reported by the Uganda Police Force. An assessment of the Monitoring of NGOs revealed that although the Ministry had registered 2,249 NGOs, the Ministry could only carry out offsite inspections of just 145 NGOs or 1% of all registered NGOs. \uf0b7 A trend analysis of the Ministry domestic arrears over the past three years showed an increasing trend from UGX.0.078Bn in 2018/2019 to UGX.1.45Bn in 2020/2021. \uf0b7 The Ministry paid for repair services worth UGX.13,237,877 without being certified by the responsible technical officer to confirm receipt of the services. The Ministry also procured stores worth UGX.88,444,071, which were not recorded in the Ministry\u2019s stores records. \uf0b7 I noted that procurements worth UGX.88,844,071 were not recorded in", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 163, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None"], "type": "table"}}, {"content": "151", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 163, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["the stores\u2019 ledgers nor witnessed by internal audit, making it difficult to verify the deliveries. \uf0b7 The Ministry of Internal Affairs has an approved structure of 224 positions, out of which 105 are filled, resulting in a shortfall of 119 (representing 47%)., including critical positions such as Commissioner Compliance, Assistant Commissioner Compliance, Senior Internal Auditor, Commissioner and Assistant Commissioner for the Social Integration department were vacant.", null, null], ["15", "Uganda Police Force. 2020/21", "\uf0b7 Uganda Police Force prepared a strategic plan for the period 2020-2025. However, the plan had not yet been approved by the National Planning Authority at the time of audit ."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 164, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "152", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 164, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "surveyed nor titled."], ["16 National Identification and Registration Authority (NIRA). 2020/21 Opinion Unqualified \uf0b7 NIRA prepared a strategic plan for the period 2020-2025, which was approved by the National Planning Authority. However, the plan is yet to be approved by the Board of the Authority for implementation. \uf0b7 NIRA budgeted to collect NTR of UGX.15.0Bn during the year. However, by the end of the year, NIRA had collected a total of UGX.3.66Bn. \uf0b7 Out of the total GoU receipts for the financial year of UGX.55.2Bn, only UGX.53.3Bn was spent by the entity resulting in an unspent balance of UGX.1.7Bn representing an absorption level of 97%. As a result, I noted that of the twenty-four (24) fully quantified activities worth UGX.70.6Bn assessed; 10 activities representing 42% were fully implemented, 12 activities representing 50% were partially implemented, while 2 activities representing 8% were not implemented at all. \uf0b7 I assessed the extent of service delivery and noted that only 11% of the planned 1,712,880 citizens were registered during the year, while only 30% of the planned 2,000,000 National IDs were issued. \uf0b7 I assessed the progress on registration of births and deaths and observed that NIRA registered 90% of the planned 960,000 births and only 1.3% of the 960,000 deaths. \uf0b7 A review of the progress of registering citizens indicated that as of December 2021, 29,713,029 applications, or 69% of all Ugandans, had applied to NIRA for registration. Of these, only 25,557,448 or 86% of the applicants had been registered, and only 16,258,521 (63.6%) have been issued with National Identity cards. \uf0b7 Only 16.3 million cards out of the over 19 million national identity cards so far printed have been claimed, leaving over 2.7 million cards unissued or unclaimed. \uf0b7 At the time of audit (December 2021), the Authority had over 4.3 million applications yet to be processed. Of these, 3.2 million applications were still being processed, while 1.1 million applications have been rejected. \uf0b7 NIRA plans to register at least 28,000 aliens annually and issue them with the relevant identification cards. From 2015 to date, the entity has only received 16 applications for alien IDs, and no Alien ID has been issued. \uf0b7 A reviewed the outcome of the initiative to register learners (or school going children within their schools) undertaken in 2017/2018 to determine whether all registered learners had been issued with NINs. I noted that records of over 1.8 million (or 19%) learners\u2019 who registered during that exercise had been rejected and thus not processed for issuance of NINs and Identification Cards. \uf0b7 NIRA failed to procure over 4,500,000 million IDs from the Uganda Security Printing Company as the Joint Venture Agreement required. As a result, the entity has recognised a contingent liability of UGX.33.5Bn.", null, null], ["17", "Amnesty Commission 2020/21", "\uf0b7 The entity budgeted to receive UGX.4.016Bn, out of which UGX.3.868Bn was warranted, resulting in a shortfall of UGX.0.147Bn, which is 3.7% of the budget."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 165, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": [["", null, "surveyed nor titled."], ["16 National Identification and Registration Authority (NIRA). 2020/21 Opinion Unqualified \uf0b7 NIRA prepared a strategic plan for the period 2020-2025, which was approved by the National Planning Authority. However, the plan is yet to be approved by the Board of the Authority for implementation. \uf0b7 NIRA budgeted to collect NTR of UGX.15.0Bn during the year. However, by the end of the year, NIRA had collected a total of UGX.3.66Bn. \uf0b7 Out of the total GoU receipts for the financial year of UGX.55.2Bn, only UGX.53.3Bn was spent by the entity resulting in an unspent balance of UGX.1.7Bn representing an absorption level of 97%. As a result, I noted that of the twenty-four (24) fully quantified activities worth UGX.70.6Bn assessed; 10 activities representing 42% were fully implemented, 12 activities representing 50% were partially implemented, while 2 activities representing 8% were not implemented at all. \uf0b7 I assessed the extent of service delivery and noted that only 11% of the planned 1,712,880 citizens were registered during the year, while only 30% of the planned 2,000,000 National IDs were issued. \uf0b7 I assessed the progress on registration of births and deaths and observed that NIRA registered 90% of the planned 960,000 births and only 1.3% of the 960,000 deaths. \uf0b7 A review of the progress of registering citizens indicated that as of December 2021, 29,713,029 applications, or 69% of all Ugandans, had applied to NIRA for registration. Of these, only 25,557,448 or 86% of the applicants had been registered, and only 16,258,521 (63.6%) have been issued with National Identity cards. \uf0b7 Only 16.3 million cards out of the over 19 million national identity cards so far printed have been claimed, leaving over 2.7 million cards unissued or unclaimed. \uf0b7 At the time of audit (December 2021), the Authority had over 4.3 million applications yet to be processed. Of these, 3.2 million applications were still being processed, while 1.1 million applications have been rejected. \uf0b7 NIRA plans to register at least 28,000 aliens annually and issue them with the relevant identification cards. From 2015 to date, the entity has only received 16 applications for alien IDs, and no Alien ID has been issued. \uf0b7 A reviewed the outcome of the initiative to register learners (or school going children within their schools) undertaken in 2017/2018 to determine whether all registered learners had been issued with NINs. I noted that records of over 1.8 million (or 19%) learners\u2019 who registered during that exercise had been rejected and thus not processed for issuance of NINs and Identification Cards. \uf0b7 NIRA failed to procure over 4,500,000 million IDs from the Uganda Security Printing Company as the Joint Venture Agreement required. As a result, the entity has recognised a contingent liability of UGX.33.5Bn.", null, null], ["17", "Amnesty Commission 2020/21", "\uf0b7 The entity budgeted to receive UGX.4.016Bn, out of which UGX.3.868Bn was warranted, resulting in a shortfall of UGX.0.147Bn, which is 3.7% of the budget."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 165, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "153", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 165, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SECURITY SECTOR", null, null], ["1", "NEC AGRO SMSC LTD 2019/2020 Opinion", "\uf0b7 Accounts receivables increased by 229% from UGX.3.080bn in the financial year 2018/19 to UGX.7.062bn in financial year 2019/20. Outstanding debtors represent idle resources which could be used in the implementation of planned activities."], [null, "Unqualified", null], ["2 NEC AGRO SMSC LTD 2020/2021 Opinion Unqualified \uf0b7 Receivables increased by 23.2% from UGX.6,671,059,244 in the F/Y 2019/20 to UGX.8,219,802,915 in the F/Y 2020/21 and a number of debtors had been outstanding since financial year 2018/19 to-date. \uf0b7 NEC AGRO SMC LTD has an operating margin of 8.5% which is below the desirable 15%. This implies that the subsidiary has a lower proportion of revenues covering expenses rather than profits or income. \uf0b7 The Corporation had a current ratio of 11.4 for the year under review which was way above the desirable ratio of 1.5. I further noted that the current ratio for the year increased by 322% from a ratio of 2.7 recorded in the previous year.", null, null], ["3", "(NEC) Farm Katonga Limited. 2019/2020", "\uf0b7 The Corporation had an operating margin of 2.1%, which is below 50% which implies that the Corporation is having a lower proportion of revenues covering expenses rather than profits or income."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 166, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "154", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 166, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "meet future contingencies or investments in growth."], [null, null, "\uf0b7 The return on assets for the Corporation increased by 0.01% from 0.55%"], [null, null, "recorded in the previous year, the return was still very low. This implies"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 167, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": [["", "", "meet future contingencies or investments in growth."], [null, null, "\uf0b7 The return on assets for the Corporation increased by 0.01% from 0.55%"], [null, null, "recorded in the previous year, the return was still very low. This implies"], [null, null, "that the Corporation is not making enough income from the use of its"], [null, null, "assets."], [null, null, "\uf0b7 The Corporation had a current ratio of 389 for the year under review"], [null, null, "which was far above the desirable range of 1.5 \u2013 2.0. It reduced by 59%"], [null, null, "from a ratio of 938 realized in the previous year."], ["4 (NEC) Farm Katonga Limited, 2020/2021 Opinion Unqualified \uf0b7 The Corporation has an operating margin of 1.2%, which is below the 50% compared to 2.1% realized in the previous year 2019/20 representing a reduction of 43% which implies that the Corporation is having a lower proportion of revenues covering expenses rather than profits or income. \uf0b7 The Corporation made profits of UGX.32,789,541 after tax in the year under review up from profits of UGX.30,230,727 realized in the previous year representing a rise in profits of 8.5%. However the Corporation had negative retained earnings of UGX.1,441,914,445 as at the end of the financial year which may affect the entity\u2019s ability to meet future contingencies or investments in growth. \uf0b7 The corporation posted a return on assets of only 0.4% down from 0.56% posted in the previous year, representing a reduction in ROA of 28.6%. This implies that the Corporation is not making enough income from the use of its assets. \uf0b7 The Corporation had a current ratio of 2,123 for the year under review which was far above the desirable range of 1.5 \u2013 2.0. The very high current ratio implies that the Corporation is not efficiently using its current assets or its short-term financing facilities. \uf0b7 A loan advances worth UGX.808,940,140 was extended to NEC AGRO SMC LTD on 10/03/2021 after committing to pay back the short term loan in 4 weeks. It was however observed that at the time of writing this report in December 2021, the loan advance had not been repaid. \uf0b7 It was established that NEC was involved in land disputes with various encroachers at NEC Farm Katonga which may result into loss of land if not promptly handled.", null, null], ["5", "NEC Headquarter 2019/2020 Opinion Unqualified", "\uf0b7 The Corporation had outstanding debtors amounting to UGX.1,796,916,916 some of which have been outstanding for a number of years. Continued reflection of the debtors\u2019 amount in the financial statements when their recovery seems to be remote misleads users of the accounts."], [null, "", null], ["6 NEC Headquarters 2020/2021 Opinion Qualified \uf0b7 I observed that NEC Pharmaceutical investment reduced to UGX.1,118,877,451 from UGX.2,460,326,736 by the end of the financial year 2020/2021 because machinery and furniture valued at UGX.1,341,449,285 was to be disposed of. The Ministry of Works expert put the value of the machinery and furniture to be disposed of at UGX.413,720,000 implying that value for sale was overstated by UGX.927,729,285. \uf0b7 In the FY 2017, NEC was allocated road construction and maintenance", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 167, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "155", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 167, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["equipment from Ministry of Works and Transport as one way of enhancing its competitiveness in the market. I however noted that the depreciation charge related to the road construction and maintenance equipment was not disclosed in the statement of profit and loss and other comprehensive income contrary to the existing financial reporting standards. \uf0b7 Debtors worth UGX.757,989,660 were reported among which are sundry debtors and prepayments worth UGX.142,254,800 which have been outstanding for a period of more than one year. \uf0b7 Payable amounting to UGX.10,010,447 have remained outstanding for over ten years. \uf0b7 In 2005, Iran Agro Industries was given a lease for 17 square miles of land at NEC Farm Katonga. The initial 5-year lease elapsed without fulfilment of the lease obligations by Iran Agro Industries and the lease was terminated but the land titles were not repossessed by NEC. \uf0b7 It was observed that there was no Annual General Meeting held in the last five years and the entity\u2019s draft strategic plan had not been reviewed by NPA to align to NDP III for onward approval by the Board of Directors.", null, null], ["7", "NEC Luwero Industries Limited, 2019/2020 Opinion Unqualified", "\uf0b7 The Corporation had outstanding trade debtors amounting to UGX.791,065,997 at the close of the financial year 2019/2020 some of which have been outstanding for over the past three financial years. Uncollected debtors represent an idle resource that would be put to use by the entity to enhance its operations."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 168, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "156", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 168, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "financed by debt. In comparison with the previous year, the debt ratio"], [null, null, "was 6.6% indicating a reduction of 1.3% in the debt over the one year"], [null, null, "period."], ["8 National Enterprise Corporation (NEC) Luwero Industries Limited. 2020/21 Opinion Unqualified \uf0b7 The entity had outstanding trade debtors amounting to UGX.491,697,278 at the close of the financial year 2020/2021, some of which have been outstanding for over the past three financial years. Uncollected debtors represent an idle resource that would be put to use by the entity to enhance its operations. \uf0b7 The Corporation had outstanding trade creditors amounting to UGX.744,085,592 some of which have been outstanding for over three financial years. Failure to settle creditors for such long periods could lead to expensive litigation costs for the entity and impact on the going concern as the creditors may cease doing business with the entity. \uf0b7 The Corporation had negative retained earnings of UGX.15,552,895,876 as at the end of the financial year. This may affect the entity\u2019s ability to meet future contingencies or investments in growth. \uf0b7 The corporation posted a return on assets of only 10% down from 12.5% posted in the previous year, representing a reduction in ROA of 20%. This implies that the Corporation is not making enough income from the use of its assets. \uf0b7 The Corporation had a current ratio of 11.9 for the year under review which was above the desirable ratio of 1.5. A very high current ratio implies that the Corporation is not efficiently using its current assets or its short-term financing facilities. \uf0b7 The Corporation had a debt ratio of 2.1% as at the end of the financial year under review implying that majority of Corporation assets are financed by debt.", null, null], ["9", "NEC UZIMA. 2019/2020 Opinion Unqualified", "\uf0b7 I noted that management procured major factory materials worth UGX.1,645,898,731 without adhering to neither the existing procurement processes nor applying for accreditation of an alternative system specifying existence of unique circumstances that could have prevented adherence to the requirements of PPDA Act."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 169, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "157", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 169, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["10 NATIONAL ENTERPRISE UZIMA LTD, 2020/2021 Opinion Unqualified \uf0b7 Payables increased from UGX.1,042,752,671 in the F/Y 18/19 to UGX.1,744,963,543 in 19/20 and further to UGX.2,052,449,538 in the year under review. The increasing trend of payables could result into an uncontrollable level of payables which greatly affects the credit worthiness of the entity. \uf0b7 The Corporation had negative retained earnings of UGX.88,435,269 as at the end of the financial year. This may affect the entity\u2019s ability to meet future contingencies or investments in growth. \uf0b7 The Corporation had a current ratio of 2.3 for the year under review which is above the desirable ratio of 1.5. The high current ratio implies that the Corporation is not efficiently using its current assets or its short term financing facilities. \uf0b7 The Corporation had a debt ratio of 53.5% as at the end of the financial year under review which is considered undesirable. This implies that the company does not have enough funds to meet its current debt obligations and may find it hard to pay a return on Government investment.", null, null], ["11", "NEC Construction Works and Engineering Limited, 2019/2020", "\uf0b7 NEC Works Ltd had outstanding trade debtors of UGX.10,074,717,689 as at the close of the financial year 2019/2020. Outstanding debtors represent an idle asset that would be put to use by the entity to enhance its operations."], [null, "Opinion Unqualified", null], ["12 National Enterprise Corporation - Construction, Works and Engineering Ltd 2020/21 \uf0b7 NEC Works Ltd had outstanding trade debtors of UGX.2,961,747,233 as at the close of the financial year 2020/2021 some of which have been outstanding for more than one year. I was not availed any recovery plans", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 170, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "158", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 170, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Unqualified nor any initiatives taken by management to recover the debts. \uf0b7 The Corporation had an operating margin of 11%, which is below 15% compared to 9% realized in the previous year 2019/20 representing an increase of 22%. This implies that the Corporation is having a lower proportion of revenues covering expenses rather than profits or income. \uf0b7 The Corporation had a current ratio of 1.4 for the year under review which was below the desirable ratio of 1.5. The low current ratio implies that the Corporation has limited ability to meet short-term obligations without raising external capital. \uf0b7 The Corporation had a debt ratio of 69% as at the end of the financial year under review implying that majority of Corporation assets are financed by debt.", null, null], ["13", "Uganda Air Cargo Corporation 2019/2020", "\uf0b7 The Corporation had outstanding debtors of UGX.8,174,344,548 as at 30th June, 2020. UGX.8,159,631,016 representing 99.8% of the debtors reported has been outstanding for a period of more than 5 years. The uncollected debtors constitute more than 65% of the total current assets."], [null, "Opinion Unqualified", null], ["14 Uganda Air Cargo Corporation, 2020/2021 Opinion Unqualified \uf0b7 MoFPED released UGX.46,048,485,223 through MoDVA for capitalisation of UACC but MoDVA transferred UGX.42,511,285,223 leaving a balance of UGX.3,537,200,000. It was observed that UACC with the approval of the Board of Directors agreed to reallocate UGX.28,647,537,490 to fund new priorities other than those for which the funds were appropriated. \uf0b7 A review of the ten (10) year Strategic Business and Investment Plan 2016 to 2027 revealed that out of the planned seven (7) targets/goals, one (1) had been fully achieved, three (3) were partially achieved while", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 171, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "159", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 171, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["three (3) were not achieved at all. \uf0b7 Management created an additional position of \u201cPrincipal Director\u201d to oversee the Directorates of Flight operations and Maintenance which is not in the established structure and is contrary to The Civil Aviation Regulations 2014, section 13. \uf0b7 UACC is a statutory corporation that is supposed to undertake procurements in accordance with PPDA Law and its Regulations. I observed that procurements are normally undertaken as and when the aircrafts breakdown and as such did not follow the formal procurement procedures. \uf0b7 UACC signed a contract on 20th April, 2021 with National Enterprise Corporation (NEC) for construction of the UACC HQ offices for a sum of UGX.1.097Bn and the expected project completion date was 19th October, 2021. I observed that unsecured advances of UGX.1.04Bn (95%) of the contract sum had been paid to NEC by closure of the financial year 30th June 2021. Audit inspection carried out on 18th October, 2021 observed that construction works were behind schedule. \uf0b7 UACC to-date does not have an operating Aircraft to do business since most of them had been grounded or not operational under different circumstances. \uf0b7 The Corporation had negative retained earnings/revenue reserves of UGX.24.03Bn as at the end of the financial year. This may affect the entity\u2019s ability to meet future contingencies or investments in growth.", null, null], ["15", "State House. 2020/21", "\uf0b7 There was a shortfall in NTR collections amounting to UGX.0.573.4bn representing 64%."], [null, "Opinion Unqualified", null], ["16 Office of the President Opinion Unqualified \uf0b7 The entity had prepared a draft strategic plan which was submitted to align the plan to NDP III upon which the certificate of compliance will be issued. \uf0b7 Out of the budgeted revenue of UGX.525,000,000 for the year 2020/21; UGX.423,827,920 was collected representing performance of 80% of the target. \uf0b7 Out of the total warrants for the financial year of UGX.202,499,917,566,", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 172, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "160", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 172, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["UGX.201,682,707,928 was spent by the entity resulting in an unspent balance of UGX.817,209,638 representing absorption level of 99.6%. \uf0b7 I assessed the implementation of all the 19 out puts that were fully quantified with a total of 100 activities worth UGX.92.2 bn. and noted the following: \uf0b7 Twelve (12) outputs with a total of seventy eight (78) activities worth UGX.62.1bn were fully implemented. \uf0b7 Four (4) outputs with a total of fifteen (15) activities worth UGX.16.0bn were partially implemented. \uf0b7 Three (3) outputs with a total of seven (7) activities worth UGX.14.7bn were not implemented at all. \uf0b7 \uf0b7 Out of the planned 27 strategic targets/goals, 23 targets had been fully achieved while 4 were not achieved at all. \uf0b7 Out of the budgeted revenue of UGX.0.52bn for the year 2019/20; only UGX.0.20bn was collected representing performance of only 3.8% of the target. \uf0b7 Out of the total receipts for the financial year of UGX.2.17bn, UGX.2.11bn was spent by the entity resulting in an unspent balance of UGX.5.633bn representing an absorption level of 97.4%. \uf0b7 I assessed a sampled of 19 outputs with a total of 175 activities and actual expenditure of UGX.94Bn which were fully quantified by management. I observed that; 11 outputs with a total of 69 activities worth UGX.77.2Bn were fully implemented. 2 outputs with a total of 21 activities worth UGX.18.5Bn were partially implemented. \uf0b7 I examined supplementary funding received by the Office for COVID 19 interventions and observed anomalies which included under absorption of the funds, failure to quantify activities implemented, inappropriate procurement methods and funds not accounted for. Specifically for management of quarantine centres, I observed that items were procured at varying prices and they were not taken on charge. \uf0b7 Arrears totalling to UGX 30,549,780,185 remained unsettled at close of the year. Further, UGX.28,431,892,310 was provided for settlement of domestic arrears yet domestic arrears brought forward from the prior year were UGX.58,981,672,495. \uf0b7 Shortcomings were observed in the Ministry\u2019s fleet management which included incomplete recording of motor vehicles in the assets register, failure to use motor vehicle logbooks, lack of motor vehicle annual inspections, lack of adequate vehicles for allocation to RDCs, gaps in drivers\u2019 competences and failure to implement board of survey recommendations for disposal of motor vehicles.", null, null], ["17", "Ministry of Defence and Veteran Affairs. 2020/21", "\uf0b7 Out of the budgeted revenue of UGX.1.735Bn for the year 2020/21; UGX.1.018Bn was collected representing performance of 59% of the target. \uf0b7 Out of the total warrants for the financial year of UGX.5.316Tn, UGX.5.315Tn was spent by the entity resulting in an unspent balance of"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 173, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": [["UGX.201,682,707,928 was spent by the entity resulting in an unspent balance of UGX.817,209,638 representing absorption level of 99.6%. \uf0b7 I assessed the implementation of all the 19 out puts that were fully quantified with a total of 100 activities worth UGX.92.2 bn. and noted the following: \uf0b7 Twelve (12) outputs with a total of seventy eight (78) activities worth UGX.62.1bn were fully implemented. \uf0b7 Four (4) outputs with a total of fifteen (15) activities worth UGX.16.0bn were partially implemented. \uf0b7 Three (3) outputs with a total of seven (7) activities worth UGX.14.7bn were not implemented at all. \uf0b7 \uf0b7 Out of the planned 27 strategic targets/goals, 23 targets had been fully achieved while 4 were not achieved at all. \uf0b7 Out of the budgeted revenue of UGX.0.52bn for the year 2019/20; only UGX.0.20bn was collected representing performance of only 3.8% of the target. \uf0b7 Out of the total receipts for the financial year of UGX.2.17bn, UGX.2.11bn was spent by the entity resulting in an unspent balance of UGX.5.633bn representing an absorption level of 97.4%. \uf0b7 I assessed a sampled of 19 outputs with a total of 175 activities and actual expenditure of UGX.94Bn which were fully quantified by management. I observed that; 11 outputs with a total of 69 activities worth UGX.77.2Bn were fully implemented. 2 outputs with a total of 21 activities worth UGX.18.5Bn were partially implemented. \uf0b7 I examined supplementary funding received by the Office for COVID 19 interventions and observed anomalies which included under absorption of the funds, failure to quantify activities implemented, inappropriate procurement methods and funds not accounted for. Specifically for management of quarantine centres, I observed that items were procured at varying prices and they were not taken on charge. \uf0b7 Arrears totalling to UGX 30,549,780,185 remained unsettled at close of the year. Further, UGX.28,431,892,310 was provided for settlement of domestic arrears yet domestic arrears brought forward from the prior year were UGX.58,981,672,495. \uf0b7 Shortcomings were observed in the Ministry\u2019s fleet management which included incomplete recording of motor vehicles in the assets register, failure to use motor vehicle logbooks, lack of motor vehicle annual inspections, lack of adequate vehicles for allocation to RDCs, gaps in drivers\u2019 competences and failure to implement board of survey recommendations for disposal of motor vehicles.", null, null], ["17", "Ministry of Defence and Veteran Affairs. 2020/21", "\uf0b7 Out of the budgeted revenue of UGX.1.735Bn for the year 2020/21; UGX.1.018Bn was collected representing performance of 59% of the target. \uf0b7 Out of the total warrants for the financial year of UGX.5.316Tn, UGX.5.315Tn was spent by the entity resulting in an unspent balance of"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 173, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "161 \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 173, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A budgetary allocation on Court awards and compensations of UGX.279.12M was received during the year against the outstanding claim of UGX.3.537BN resulting into a shortfall of 99.92%.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Domestic arrears over the past three years have shown a declining trend with arrears reducing by UGX.284.868Bn from 2019 to 2021.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that trade creditors totalling to UGX.364.821Bn remained unsettled at close of the year with arrears totalling to UGX.194.297Bn relating to previous financial year(s).", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that UGX.19.711Bn paid to settle domestic arrears was diverted from the current budget.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- I observed that Batuma Ivan Mbabazi was paid UGX.1.085Bn out of UGX.3.056Bn in respect of compensation for Kibanja land situated in Kihumuro village without proof of ownership. I noted the compensation value of crops worth UGX.1.885Bn paid did not provide details of crops planted and the land coverage.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that a number of illegal activities were being carried out on UPDF 36 Sq Miles land in Kaweweta to include: Illegal acquisition and fencing of military land by veterans; Illegal leasehold registration; Land encroachment; Charcoal burning; Cattle grazing and construction of dams.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that UGX.47BN out of the contract sum of UGX.104.77BN had been paid in relation to the construction of UPDF National Referral Hospital at Lower Mbuya. I observed during my inspections that the no single structure was complete, agreed time frame had elapsed and the site looked abandoned.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted during my inspection that Kaweweta Recruit Training School construction project site had been abandoned and observed the following: Abandoned water supply project; pending works on phase 2 and phase 3 projects; un finished works on road opening of the security road; pending works on tarmacking of 3kms internal road network; Abandoned dormitory blocks for female trainees and aqua-privy toilets; abandoned construction of 2 range grounds and lack of adequate accommodation.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted an urgent need to repair the white house building at URDCC which was found to have a leaking roof in the mess and accommodation rooms.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that the UPDF Legal Training Centre which was started in 2014 funded by Netherlands Government had stalled and looked abandoned.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that out of the required 5.6km concrete perimeter wall fence for land forces headquarter Bombo, only 525 meters had been covered leaving 4.6kms outstanding to complete the perimeter wall.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that Land forces operation centre Bombo had been abandoned since September 2021 and the project had stalled at 75%. The pending works on the project included painting, electrical and water connections and finishing works on the toilets.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I inspected the General Military Hospital- Bombo (GMHB) and observed the following: a need for a centralised system of resource allocation at the hospital; Inadequate medical supplies; Underutilization of hospital equipment; Crowded hospital premises; Old hospital equipment and Parked staff bus.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- I observed that the Marine Pier at Ntokolo Landing site Magamaga was", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n162", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "affected with water levels on Lake Victoria dropping back to normal"], [null, null, "hence making it difficult for the marine boats to fully utilise the docking"], [null, null, "area due to shallow waters. I noted that only half of the docking area"], [null, null, "was utilised contrary to the original plan."], [null, null, "\uf0b7 I inspected Magamaga cantonment and observed the following issues:"], [null, null, "lack of sufficient storage space, land encroachments\u2019, inadequate water"], [null, null, "supply, poor road network, insufficient lighting system at the store"], [null, null, "premises, accommodation challenges, need to expand Health centre II to"], [null, null, "Health centre III and inadequate toilets at the store premises."], [null, null, "\uf0b7 I observed inadequate Fuel supply for Air Force training as Air Force is"], [null, null, "not allocated fuel for operations. but the same fuel allocation for training"], [null, null, "is used for other operations and yet the trainers have specific"], [null, null, "performance contracts."], [null, null, "\uf0b7 I noted that while there are reserve tanks in Nakasongola and Jinja that"], [null, null, "were constructed in past regimes, these have never been utilised"], [null, null, "subjecting management to buying Jet fuel from dealers at the open"], [null, null, "market pump prices and exorbitant prices."], [null, null, "\uf0b7 I inspected Special Forces Command (SFC) and observed creation of 206"], [null, null, "brigade SFC without sufficient funding. I noted lack of office furniture,"], [null, null, "storage space and CCTV cameras."], ["PUBLIC SECTOR MANAGEMENT SECTOR", null, null], ["1.", "The New Vision printing and Publishing company Limited 2020/21", "\uf0b7 Because the company\u2019s market capitalisation of UGX 23,715 million was significantly lower than the carrying amount of the company\u2019s net assets of UGX 65,039 million as at 30thJune 2021. In accordance with IAS 36"], [null, null, "Impairment of Assets, this impairment indicator triggered impairment"], [null, "Opinion", "testing of the non-current assets of the company. The recoverable cost of UGX 57,866 estimated to be the fair value of the company. \uf0b7 NVPPCL incurred costs relating to a one-off discretionary retirement"], [null, "Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 175, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "163", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 175, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "the following;"], [null, null, "\uf0b7 Absence of a defined information security management system"], [null, null, "\uf0b7 Absence of a cybersecurity incident response team"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 176, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": [["", null, "the following;"], [null, null, "\uf0b7 Absence of a defined information security management system"], [null, null, "\uf0b7 Absence of a cybersecurity incident response team"], [null, null, "\uf0b7 Inadequate security awareness"], [null, null, "\uf0b7 Vulnerability assessments not performed"], [null, null, "\uf0b7 Absence of data classification"], [null, null, "\uf0b7 Inadequate ICT vendor management"], ["2\\. Markets and Agricultural Trade Improvement Project (MATIP) II 2020/21 Opinion Unqualified \uf0b7 There was a shortfall in releases from GOU sources of UGX.0.23Bn and donors of UGX.19.763Bn. Furthermore, the project failed to absorb UGX.0.271Bn. \uf0b7 I reviewed 4 out-puts with a total of 16 activities worth UGX.57.7Bn representing 100% of the total expenditure and noted that two (2) outputs with six (6) activities worth UGX.38.6Bn were fully quantified. I further observed two (2) out-puts with ten (10) activities worth UGX.19.1Bn were insufficiently quantified. All the two (2) outputs that were fully quantified were partially implemented. \uf0b7 I observed that there was delayed completion of works on some of the markets and value addition facilities. Two (2) markets were completed by June 2021 however they had not been commissioned and operationalized by September 2021 thus affecting service delivery. \uf0b7 I observed that except for Entebbe market all the other markets lacked a revenue management information system to facilitate revenue management. This was also the case for the seven (7) MATIP 1 markets. I further observed that the allocation guidelines favor leaseholders who pay very little in terms of ground rent to the Municipalities. This affects revenue mobilization and impairs self-reliance and sustainability of these markets. \uf0b7 The beneficiary Municipalities have failed to put in place a market maintenance fund which would facilitate routine maintenance of the completed structures. This was also the case for the MATIP 1 markets. In addition, all the markets redeveloped under MATIP 1 and 2 are not insured against risks such as; fire outbreaks, electrical failures and unforeseen disasters.", null, null], ["3.", "Ministry of Public Service 2020/21", "\uf0b7 The Ministry\u2019s five (5) year strategic plan was certified by NPA, confirming that it is aligned to the NDP III. \uf0b7 The Ministry collected only 57.7% of its NTR target for the year and had a shortfall in government funding of UGX.9.7Bn, which is 32.4% of the"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 The Ministry had off-budget financing of UGX.0.529Bn, which was never"], [null, null, "declared to the PSST for re-voting."], [null, null, "\uf0b7 Out of the thirty-five (35) outputs assessed, eight (8) were fully"], [null, null, "quantified, while five (5) were insufficiently quantified to facilitate"], [null, null, "performance measurement. The balance of two (2) outputs were not"], [null, null, "included in the Ministerial Policy Statement submitted to Parliament."], [null, null, "\uf0b7 Out of the eight (8) outputs that were fully quantified, seven (7) outputs"], [null, null, "were partially implemented, while one (1) output was not implemented at"], [null, null, "all as a result of the disruptions caused by restrictions imposed due to"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 176, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "164", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 176, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Covid-19."], [null, "\uf0b7 The Ministry delayed submitting all its quarterly performance reports to"], [null, "MoFPED, and similarly, I did not find evidence to confirm that monitoring"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 177, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": [["", "Covid-19."], [null, "\uf0b7 The Ministry delayed submitting all its quarterly performance reports to"], [null, "MoFPED, and similarly, I did not find evidence to confirm that monitoring"], [null, "plans and reports were prepared."], [null, "\uf0b7 I observed that a number of government entities had not been filling"], [null, "positions of persons who had been granted leave without pay, which"], [null, "resulted in manpower gaps in these entities affecting their efficiency in"], [null, "delivering services to the citizens."], [null, "\uf0b7 The Ministry failed to utilise up to UGX.6.5Bn of the total salary budget of"], [null, "UGX.17.9Bn provided by MoFPED over the past four (4) years."], [null, "\uf0b7 The Ministry had outstanding domestic arrears of UGX 0.86Bn by the end"], [null, "of the financial year."], [null, "\uf0b7 The Ministry had not put in place adequate guidance regarding the"], [null, "number of boards on which a civil servant is allowed to serve at any one"], [null, "time. This resulted in some civil servants serving on more than three (3)"], [null, "boards, which affects the time they allocate to their substantive jobs."], [null, "\uf0b7 I noted some challenges in the management of recruitments into the"], [null, "service, such as; irregular employment of staff by Accounting Officers and"], [null, "the absence of a policy for the recruitment and selection of temporary"], [null, "staff."], [null, "\uf0b7 I noted irregularities in the management of leave without pay for civil"], [null, "servants, which included; absence of a complete register of all civil"], [null, "servants who were away on leave without pay and irregular grant of"], [null, "leave without pay."], [null, "\uf0b7 I noted irregularities in overseas training for civil servants, such as the"], [null, "absence of a register of all civil servants who were away on training and"], [null, "some Officers who went abroad for training programmes offered by the"], [null, "different local universities in Uganda."], ["3\\. Local Government Finance Commission 2020/21 Opinion Unqualified \uf0b7 I noted that the Commission did not have an approved strategic plan that was aligned to NDP III by the time of audit. The draft plan prepared by the entity had not been certified by NPA. \uf0b7 The Commission collected only 0.03% of its NTR target for the year and had a shortfall in government funding of 0.04Bn which is 0.75% of the budget. The Commission absorbed all the funds that were released. \uf0b7 Out of the five (5) out-puts assessed, one (1) output with 0.115 Bn was fully quantified, while four (4) outputs with 4.01Bn were insufficiently quantified. The one (1) output that was fully quantified was partially implemented. \uf0b7 The Commission neither prepared annual budget monitoring plans nor submitted quarterly budget monitoring reports. The Commission also failed to submit all its quarterly budget performance reports in time. \uf0b7 The Commission failed to coordinate the automation of revenue management systems. There are currently four (4) revenue management systems used by various Local Governments which are implemented in a disjointed and uncoordinated manner. This has resulted in duplication of activities associated with running these systems thus affecting service delivery. \uf0b7 The Commission received UGX.182,000,000 as budget support to undertake physical decentralization and service delivery. However only UGX.31,241,000 was absorbed by the Commission which significantly", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 177, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "165", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 177, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["affected service delivery. \uf0b7 I noted that by 30th June 2021 the Commission had accumulated domestic arrears of UGX.101,473,991.", null, null], ["4.", "City Wide Inclusive Sanitation (CWIS) 2020/21", "\uf0b7 I observed that the program work plans and budgets were not sent to parliament for formal approval through the KCCA Ministerial Policy Statements \uf0b7 The project budgeted to receive donor financing of USD 1.2M for the year under review; however, only USD 1M was received during the year. Also,"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 178, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": [["affected service delivery. \uf0b7 I noted that by 30th June 2021 the Commission had accumulated domestic arrears of UGX.101,473,991.", null, null], ["4.", "City Wide Inclusive Sanitation (CWIS) 2020/21", "\uf0b7 I observed that the program work plans and budgets were not sent to parliament for formal approval through the KCCA Ministerial Policy Statements \uf0b7 The project budgeted to receive donor financing of USD 1.2M for the year under review; however, only USD 1M was received during the year. Also,"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 The project under absorbed funds totaling USD 1,329,522, which is 62%"], [null, null, "of the funds that were available to the project for implementation of"], [null, null, "activities"], [null, null, "\uf0b7 Out of the sixty-seven (67) activities assessed, forty-seven activities"], [null, null, "worth USD 609,563 were fully quantified, while twenty (20) activities"], [null, null, "worth USD 199,314 were insufficiently quantified. Out of the forty-seven"], [null, null, "(47) activities that were quantified, twenty (20) 43% activities worth USD"], [null, null, "502,564 were fully implemented, seventeen (17) 36% activities worth"], [null, null, "USD 99,664 were partially implemented, while ten (10) 21% activities"], [null, null, "worth USD 7,335 were never implemented at all."], [null, null, "\uf0b7 The project accumulated arrears amounting to USD 583,742 during the"], [null, null, "year under review."], [null, null, "\uf0b7 The project's progress towards achieving project targets or outcomes was"], [null, null, "found unsatisfactory in some areas. The performance in some cases was"], [null, null, "below 50%, while in other areas, no activities had been implemented."], [null, null, "This affects service delivery."], [null, null, "\uf0b7 The project irregularly recruited providers that KCCA or NEMA had not"], [null, null, "licensed."], ["5 Development Response to Displacement Impacts Project 2020/21 Opinion Unqualified \uf0b7 The Project budgeted to receive UGX.233Bn out of which UGX.185Bn was received representing 79% of the budget leaving a balance of UGX.48.1Bn as unreleased. All the funds that were released were absorbed. \uf0b7 All the four (4) outputs with a total of thirteen (13) activities worth UGX.185Bn were fully quantified to enable assessment of performance. Out of this two (2) out puts with six (6) activities worth UGX.9.86Bn were fully implemented while the balance of two (2) out puts with seven (&) activities worth UGX.175Bn were partially implemented. \uf0b7 I noted that the project did not utilise grant funds totalling to UGX UGX.9.6Bn. \uf0b7 The project had not achieved its thre e(3) year targets in four (4) areas with performance in some cases being as low as 0% in some areas.", null, null], ["6", "National Planning Authority 2020/21", "\uf0b7 The Authority prepared a new five (5) year strategic plan which was certified as aligned to NDP III."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 178, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "166", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 178, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "appropriated to the entity by Parliament. These funds were received"], [null, null, "directly from development partners for undertaking activities not"], [null, null, "budgeted for."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 179, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": [["", null, "appropriated to the entity by Parliament. These funds were received"], [null, null, "directly from development partners for undertaking activities not"], [null, null, "budgeted for."], [null, null, "\uf0b7 I noted that out of the 12 out-puts sampled for review, 6 (50%) were"], [null, null, "fully quantified, 5 (41%) were insufficiently quantified and 1 (9%) was"], [null, null, "not quantified at all making it impossible to measure performance. Out of"], [null, null, "the 6 out puts that were fully quantified, none was fully implemented, 4"], [null, null, "(66%) were partially implemented while 2 (34%) were not implemented."], [null, null, "\uf0b7 All the quarterly budget performance reports were submitted late by the"], [null, null, "Authority."], [null, null, "\uf0b7 I noted cases of delays in approval of MDA and LG strategic plans. In"], [null, null, "addition to this seventy three (73) entities had not submitted their"], [null, null, "strategic plans for review and certification by the Authority."], [null, null, "\uf0b7 The Authority had not undertaken capacity building of planners at both"], [null, null, "local and national level which affected the capacity of the planners to"], [null, null, "implement, monitor and report on the performance of the budgets in"], [null, null, "their respective entities."], [null, null, "\uf0b7 I observed shortcomings in government\u2019s readiness to implement the"], [null, null, "new programme approach to planning and budgeting which included;"], [null, null, "non-alignment of the accounting and oversight processes to the new"], [null, null, "programme planning framework, non-alignment to the statistical and data"], [null, null, "collection systems to the new programme planning framework and non-"], [null, null, "functional programme working groups among others."], [null, null, "\uf0b7 I also noted that the Authority had not realigned the development"], [null, null, "planning regulations from the sector approach to planning and budgeting"], [null, null, "to the new programme approach of planning and budgeting."], ["7 Public Service Commission 2020/21 Opinion Unqualified \uf0b7 Although the Commission had come up with a strategic plan aligned to NDP III, this plan had not been approved and certified by NPA as required by the planning regulations. \uf0b7 The Commission did collect NTR for the year despite having an NTR budget of UGX.2.7Bn. The Commission received 99% of its budget from Treasury and absorbed all the funds. \uf0b7 Out of the thirteen out-puts assessed, two (2) outputs worth 0.88Bn were fully quantified, six (6) worth 6.72Bn were partially quantified while five (5) outputs worth 1.87Bn were not quantified at all. The two (2) out-puts that were quantified were all partially implemented. \uf0b7 All the quarterly performance reports were submitted late by the Commission and there were no budget monitoring reports prepared by the Accounting Officer. \uf0b7 The Commission does not participate in the recruitment of foreign service officers in Uganda\u2019s missions and embassies abroad. \uf0b7 The Commission had outstanding domestic arrears amounting to UGX.48.768,099. \uf0b7 The Commission did not deduct PAYE from gratuity payments amounting to UGX.1Bn for its Commission members.", null, null], ["8", "Office of The Prime Minister 2020/21", "\uf0b7 I noted that OPM strategic plan had not been approved by NPA as aligned to NDP III."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 179, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "167", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 179, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "government releases. OPM had unspent balances of UGX.2.5Bn, which"], [null, "were returned to the consolidated fund."], [null, "\uf0b7 OPM received off-budget financing amounting to UGX.53.452Bn, which"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 180, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": [["", "government releases. OPM had unspent balances of UGX.2.5Bn, which"], [null, "were returned to the consolidated fund."], [null, "\uf0b7 OPM received off-budget financing amounting to UGX.53.452Bn, which"], [null, "Parliament never appropriated."], [null, "\uf0b7 I noted that out of the thirty-two (32) outputs sampled for review,"], [null, "twenty-nine (29) (91%) were fully quantified, one (1) (3%) was partially"], [null, "quantified, and 2 (6%) were not quantified at all which made it"], [null, "impossible to measure performance. Out of the twenty-nine (29) outputs"], [null, "that were fully quantified, four (4) outputs (14%) were fully"], [null, "implemented, while twenty-five (25) outputs (86%) were partially"], [null, "implemented."], [null, "\uf0b7 OPM did not prepare and submit annual budget monitoring plans and"], [null, "reports while submission of all the quarterly performance reports were"], [null, "delayed."], [null, "\uf0b7 I observed service delivery challenges such as delayed completion of"], [null, "works, failure to fund micro-projects and non-functional District Disaster"], [null, "Management Committees."], [null, "\uf0b7 I noted that OPM received UGX.0.25Bn as part of the COVID-19 relief"], [null, "interventions budget. These funds were all absorbed and used for the"], [null, "intended purpose."], [null, "\uf0b7 I noted delayed resettlement of encroachers in the Apaa game reserve"], [null, "land."], [null, "\uf0b7 OPM did not have a complete database of all entitled beneficiaries and"], [null, "those paid since 2008 under the Akasiimo gratuity scheme."], ["9 Northern Uganda Social Action Fund (NUSAF 3) 2020/21 Opinion Unqualified \uf0b7 This was the last year of implementation of the NUSAF 3 Project. An independent impact evaluation undertaken by Makerere University Business School highlighted achievements by the project, which included; increased income for beneficiary households, improved resilience and vulnerability to shocks, improved household welfare and progress out of poverty, improved savings and investments, increased production and income earnings and increased household food security and consumption for a number of beneficiaries. \uf0b7 uring FY2020/2021, the project budgeted to receive UGX.38.7Bn, which was all received. Similarly, the project absorbed all this money representing 100% performance. \uf0b7 All the three (3) outputs with nine (9) activities worth UGX.38.8Bn sampled for verification were fully quantified. Out of these, two (2) outputs with five (5) activities worth UGX.26.72Bn were fully implemented while one (1) output with four (4) activities worth UGX.12.08Bn was partially implemented. \uf0b7 The project advanced funds for the construction of coffee shops in Arua, Gulu, Lira, Mbale and Tororo. At the time of audit, works were not complete in Lira, Arua and Gulu. The coffee shop in Mbale was not fully operational. \uf0b7 During my inspection, I noted that the beneficiary communities and districts were having sustainability challenges in maintaining project investments three (3) months after the closure of the project. These included poor maintenance of roads, low savings by farmers, among others. \uf0b7 Ownership of two (2) project vehicles had not reverted to government three (3) months after the closure of the project.", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 180, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "168", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 180, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["10", "Project for The Restoration of Livelihoods in the Northern Region (PRELNOR)", "\uf0b7 The project had a shortfall of UGX.26Bn, which is 52% and UGX.3.27Bn, which is 67% of the budget in external and government funding, respectively. The project absorbed UGX.25.65Bn, which is 88% of all the funds that were released."], [null, "2020/21 Opinion Unqualified", null], ["11 Ministry of Local Government 2020/21 Opinion Unqualified \uf0b7 The Ministry\u2019s strategic plan (2020/2021 to 2025/2026) had not been certified by NPA to confirm that it was well aligned to NDP III at the time of the audit. \uf0b7 There was a shortfall in NTR collection of up to 89.9% of the target, while government receipts were less than anticipated by UGX.3.64Bn. The Ministry had unspent balances of UGX.3.94Bn by year-end. \uf0b7 I noted that out of the thirty-nine (39) outputs sampled for review, fifteen (15) (38%) were fully quantified, twenty (20) (51%) were insufficiently quantified, and four (4) (10%) were not quantified at all. Out of the fifteen (15) outputs that were fully quantified, one (1) output was fully implemented, while fourteen (14) outputs were partially implemented. \uf0b7 All the quarterly performance reports were submitted after the deadline for submission. \uf0b7 2,127 motorcycles and 77,831 bicycles worth UGX.18.9Bn and UGX.24.6Bn respectively had not yet been delivered by the time of audit in November 2021, although they were due for delivery in September 2021. \uf0b7 The Ministry delayed disbursing funds for budget support to Local Governments. UGX.22.1Bn to various Local Governments was disbursed in the last two weeks of June 2021. \uf0b7 The Ministry delayed disbursing start-up costs of UGX.6.79Bn to 125 Local Governments. Most of the funds were transferred the last two weeks of June and, in some cases, as late as 29th June 2021. \uf0b7 The Ministry received UGX.2.86Bn for settlement of domestic arrears as part of the COVID 19 interventions, which was all absorbed and used to settle domestic arrears. \uf0b7 The Ministry had outstanding domestic arrears of UGX.33Bn as at June 2021.", null, null], ["12", "Kampala Capital City Authority (KCCA).", "\uf0b7 I noted that the Authority\u2019s strategic plan had not been certified by NPA by the time of audit, contrary to the Planning Regulations."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 181, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "169", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 181, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "UGX.18.97Bn, which Parliament never appropriated."], [null, null, "\uf0b7 I noted that out of the thirty-nine (39) outputs sampled for review, two"], [null, null, "(2) outputs (5%) were fully quantified, two (2) outputs (5%) were"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 182, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": [["", null, "UGX.18.97Bn, which Parliament never appropriated."], [null, null, "\uf0b7 I noted that out of the thirty-nine (39) outputs sampled for review, two"], [null, null, "(2) outputs (5%) were fully quantified, two (2) outputs (5%) were"], [null, null, "partially quantified, and thirty-five (35) outputs (90%) were not"], [null, null, "quantified at all which made it impossible to measure performance. The"], [null, null, "two (2) outputs that were fully quantified were all fully implemented."], [null, null, "\uf0b7 All performance reports were submitted after the deadline."], [null, null, "\uf0b7 I noted that the Authority had not developed regulations to guide the"], [null, null, "collection of outdoor advertising fees, which hindered the collection of"], [null, null, "NTR. I further noted that the Authority did not undertake regular updates"], [null, null, "of the valuation rolls."], [null, null, "\uf0b7 The Authority has an unserviceable long-term liability of"], [null, null, "UGX.42,570,448,999 in addition to accumulated domestic arrears of"], [null, null, "UGX.62,477,592,377 as at 30th June 2021."], [null, null, "\uf0b7 The Authority did not remit statutory deductions to URA and NSSF"], [null, null, "amounting to UGX.1.86Bn."], [null, null, "\uf0b7 The Authority incurred avoidable expenditure of UGX.7.8Bn as interest"], [null, null, "due to delayed site handover for civil works constructions."], [null, null, "\uf0b7 noted that the Authority had not adopted the Computerized Government"], [null, null, "Financial Management Information Systems (GFMIS) for management of"], [null, null, "its inventories as required by the Treasury Instructions."], ["13 Kampala Institutional and Infrastructure Development Project (KIIDP). 2020/21 Opinion Unqualified \uf0b7 The Project budgeted to receive UGX.8.7Bn from GOU out of which UGX.1.9Bn was released representing 21.8% of the budget leaving a balance of UGX.6.8Bn as unreleased. Similarly, the project budgeted to receive UGX.139.7Bn from World Bank however only UGX.125.2Bn (90%) was availed. \uf0b7 UGX.49.9Bn remained un-utilized at the end of the financial year. \uf0b7 Out of the four (4) outputs reviewed, only one (1) output (25%) was fully quantified. Three (3) outputs were not quantified at all. I observed that management did not prepare performance reports that show the status of implementation of planned outputs. \uf0b7 I noted that there was slow progress of works, delayed relocation of utilities and delayed land aquistion which resulted in delayed service delivery. \uf0b7 I also noted that UGX.1,323,171,260 that was garnished had not yet been refunded by Government through KCCA. \uf0b7 I noted that ownership of one hundred forty-seven (147) pieces of land on which project roads and drainages had been constructed had not yet been transferred to KCCA.", null, null], ["1.", "PUBLIC ADMINISTRATION SECTOR", "\uf0b7 \uf0b7 Out of the planned 10 strategic targets/goals, 4 targets were fully achieved, 5 targets were partially achieved and 1 was not achieved at all. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.544Bn representing 1.66% performance. \uf0b7 I sampled 4 outputs with a total of 8 activities and actual expenditure of UGX.5.376Bn and observed that 3 outputs with a total of 7 activities and expenditure worth UGX.5.31Bn were fully quantified while 1 output with 1 activity and expenditure worth UGX 0.06Bn was not quantified. I further"], [null, "Uganda Embassy in Abu Dhabi. 2019/20 Opinion \uf0b7 Out of the planned 10 strategic targets/goals, 4 targets were fully achieved, 5 targets were partially achieved and 1 was not achieved at all. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.544Bn representing 1.66% performance.", null], [null, "Unqualified \uf0b7 I sampled 4 outputs with a total of 8 activities and actual expenditure of UGX.5.376Bn and observed that 3 outputs with a total of 7 activities and expenditure worth UGX.5.31Bn were fully quantified while 1 output with 1 activity and expenditure worth UGX 0.06Bn was not quantified. I further", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 182, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "170", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 182, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["observed that none of the outputs were fully implemented. \uf0b7 The Mission did not prepare and submit the annual monitoring plans to MoFPED and NPA contrary to the requirement of paragraph 58 of the Budget Execution Circular for 2019/2020. I also noted that the Mission submitted performance reports for Q1, Q2, Q3 and Q4 after the elapse of the deadline given for submission of the reports. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.58,817,501 out of which UGX.37,898,755 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX. 20,918,746 not remitted. \uf0b7 The Mission paid 73,400.00 AED (equivalent to UGX.73,326,600) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission paid medical refunds to its staff amounting to 8,540.9 AED (equivalent to UGX.8,531,460) contrary to Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 The Mission has an approved staff structure of 4 staff positions out of which 3 (75%) were filled leaving 1 (25%) vacant.", null, null], ["2.", "Uganda Embassy in Abuja, 2019/20", "\uf0b7 Out of the planned 9 strategic targets/goals, no target was fully achieved, 4 targets were partially achieved and 5 targets were not achieved at all."], [null, "Opinion Qualified", null], ["3\\. Uganda Embassy in Algeria 2019/20 Opinion Unqualified \uf0b7 All the planned 7 strategic targets/goals in the Mission charter were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.078Bn representing 0.5% performance. \uf0b7 Out of the total receipts for the financial year of UGX.4.16Bn, UGX.3.81Bn", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 183, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "171", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 183, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["was spent by the entity resulting in an unspent balance of UGX.0.35Bn representing an absorption level of 91.5%. \uf0b7 I sampled 5 outputs with a total of 16 activities and actual expenditure of UGX.3.89Bn and observed that 1 output with a total of 6 activities and expenditure worth UGX.1.14Bn was fully quantified, 2 outputs with a total of 8 activities and expenditure worth UGX.2.47Bn were insufficiently quantified while 2 outputs with 2 activities and expenditure worth UGX.0.28Bn were not quantified at all. \uf0b7 Out of 6 activities planned, only 2 were fully implemented (33%) while 1 activity was partially implemented (17%) and 3 activities were actually not implemented (50%). \uf0b7 Funds to the tune of \u00a3 890 (UGX.3,739,406) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The entity did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 A review of the cumulative performance reports revealed the subsequent quarterly performance reports did not include activities implemented in the previous quarter(s) and therefore, the cumulative activities reported in the fourth quarter performance report does not include all activities implemented in the first, second and third quarters. \uf0b7 The Mission paid Euros.45,314 (equivalent to UGX.190,390,396) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission had a fixed assets register detailing all of the Mission\u2019s assets but lacked some of the information such as date of purchase, estimated useful life, maintenance costs and the expected date of disposal making it incomplete. I further observed that a number of the entity\u2019s assets were old and due for boarding off but this had not been done.", null, null], ["4.", "Uganda Embassy in Ankara 2019/20", "\uf0b7 Out of the planned 10 strategic targets/goals in the Mission charter, seven (7) targets had been fully achieved, two (2) were partially achieved, while one (1) was not achieved."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 184, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "172", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 184, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "management of the Embassy procured office equipment, ICT equipment"], [null, null, "and furniture and fittings worth UGX.129,698,987 resulting into a"], [null, null, "diversion of UGX.39,698,987. Furthermore, the additions in the Statement"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 185, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was spent by the entity resulting in an unspent balance of UGX.0.35Bn representing an absorption level of 91.5%. \uf0b7 I sampled 5 outputs with a total of 16 activities and actual expenditure of UGX.3.89Bn and observed that 1 output with a total of 6 activities and expenditure worth UGX.1.14Bn was fully quantified, 2 outputs with a total of 8 activities and expenditure worth UGX.2.47Bn were insufficiently quantified while 2 outputs with 2 activities and expenditure worth UGX.0.28Bn were not quantified at all. \uf0b7 Out of 6 activities planned, only 2 were fully implemented (33%) while 1 activity was partially implemented (17%) and 3 activities were actually not implemented (50%). \uf0b7 Funds to the tune of \u00a3 890 (UGX.3,739,406) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The entity did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 A review of the cumulative performance reports revealed the subsequent quarterly performance reports did not include activities implemented in the previous quarter(s) and therefore, the cumulative activities reported in the fourth quarter performance report does not include all activities implemented in the first, second and third quarters. \uf0b7 The Mission paid Euros.45,314 (equivalent to UGX.190,390,396) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission had a fixed assets register detailing all of the Mission\u2019s assets but lacked some of the information such as date of purchase, estimated useful life, maintenance costs and the expected date of disposal making it incomplete. I further observed that a number of the entity\u2019s assets were old and due for boarding off but this had not been done.", "None", "None"], "type": "table"}}, {"content": [["", "", "management of the Embassy procured office equipment, ICT equipment"], [null, null, "and furniture and fittings worth UGX.129,698,987 resulting into a"], [null, null, "diversion of UGX.39,698,987. Furthermore, the additions in the Statement"], [null, null, "of Stores and Other Assets (physical assets) as at the end of the financial"], [null, null, "year 2019/2020 was UGX.129,698,987 but the payment file revealed that"], [null, null, "only office equipment, ICT equipment and furniture and fittings worth"], [null, null, "UGX.85,138,153 were procured implying that this statement is overstated"], [null, null, "by UGX.44,560,834."], [null, null, "\uf0b7 The Embassy made upfront payments for rent of USD.74,850 (equivalent"], [null, null, "to UGX.279,215,200) beyond the financial year but did not disclose the"], [null, null, "prepayments in the Statement of Financial Position for the year."], [null, null, "\uf0b7 The Mission paid USD.35,000 (equivalent to UGX.130,725,000) in respect"], [null, null, "of education allowances direct to its officials instead of their respective"], [null, null, "educational institutions or schools contrary to Section (E - e) Paragraphs"], [null, null, "19 and 20 of the Public Service Standing Orders 2010."], [null, null, "\uf0b7 The Embassy spent USD.53,627 (equivalent to UGX.200,296,400) on"], [null, null, "refunds for medical expenses to its officers contrary to Section M (m-a)"], [null, null, "(14) of the Public Service Standing Orders, 2010."], [null, null, "\uf0b7 The Mission has an approved staff structure of 8 staff positions out of"], [null, null, "which, 5 (63%) were filled leaving 3 (37%) vacant."], ["5", "Uganda Embassy in China, Beijing 2019/20 Opinion Qualified \uf0b7 Out of the planned 8 strategic targets/goals in the Mission charter, three (3) targets had been fully achieved, three (3) were partially achieved, while two (2) was not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.4.17Bn representing 0.05% performance. \uf0b7 Out of the total receipts for the financial year of UGX.5.031Bn, UGX.4.276Bn was spent by the entity resulting in an unspent balance of UGX.0.755Bn representing an absorption level of 84.99%. \uf0b7 The Embassy received off-budget financing from the Contingency Fund as a relief fund for students locked down in Wuhan to a tune of UGX.227,318,724 which was not appropriated by Parliament. \uf0b7 I sampled 5 outputs with a total of 20 activities and actual expenditure of UGX.4.28Bn and observed that 1 output with a total of 20 activities and expenditure worth UGX.4.23Bn was fully quantified while 2 outputs with a total of 2 activities and expenditure worth UGX.0.05Bn were not quantified. I further noted that for the quantified outputs, 3 outputs with 20 activities worth UGX.4.23Bn were partially implemented, 9 (45%) activities were fully implemented, 2 (10%) activities partially implemented and 9 (45%) activities remained unimplemented \uf0b7 Funds to the tune of UGX.20,000,000 were irregularly diverted from purchase of specialized machinery and equipment for which they were budgeted to purchase of curtains without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. \uf0b7 I noted 20 cases of activities that were not reported that were disclosed in quarter 2 and quarter 3 reports but not disclosed the cumulative 4th", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 185, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was spent by the entity resulting in an unspent balance of UGX.0.35Bn representing an absorption level of 91.5%. \uf0b7 I sampled 5 outputs with a total of 16 activities and actual expenditure of UGX.3.89Bn and observed that 1 output with a total of 6 activities and expenditure worth UGX.1.14Bn was fully quantified, 2 outputs with a total of 8 activities and expenditure worth UGX.2.47Bn were insufficiently quantified while 2 outputs with 2 activities and expenditure worth UGX.0.28Bn were not quantified at all. \uf0b7 Out of 6 activities planned, only 2 were fully implemented (33%) while 1 activity was partially implemented (17%) and 3 activities were actually not implemented (50%). \uf0b7 Funds to the tune of \u00a3 890 (UGX.3,739,406) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The entity did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 A review of the cumulative performance reports revealed the subsequent quarterly performance reports did not include activities implemented in the previous quarter(s) and therefore, the cumulative activities reported in the fourth quarter performance report does not include all activities implemented in the first, second and third quarters. \uf0b7 The Mission paid Euros.45,314 (equivalent to UGX.190,390,396) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission had a fixed assets register detailing all of the Mission\u2019s assets but lacked some of the information such as date of purchase, estimated useful life, maintenance costs and the expected date of disposal making it incomplete. I further observed that a number of the entity\u2019s assets were old and due for boarding off but this had not been done.", "None", "None"], "type": "table"}}, {"content": "173", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 185, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["quarter performance report of the Mission. \uf0b7 The Mission had outstanding commitments to a tune of UGX.7,720,207 from the previous year but no budget was provided for settlement of domestic arrears in the current budget but the arrears were paid. \uf0b7 For procurements, I observed that the Mission had one member for an Evaluation Committee and there was lack involvement of the Contracts Committee in the procurement processes. \uf0b7 I observed that the fixed assets register maintained by the entity was not updated and not maintained in the format prescribed in the Treasury Instructions. \uf0b7 The Embassy spent RMB.154,898 (equivalent to UGX.81,538,197) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Expenditure amounting to RMB.118,327 (equivalent to UGX.62,287,491) was incurred on staff telephone bills out of which RMB.78,885 (equivalent to UGX.41,524,994) representing 2/3 of the amount should have been recovered from staff but the recovery was not effected contrary to Section H (h-e) (12) of the Public service Standing Orders, 2010.", null, null], ["6.", "Uganda Embassy in Berlin 2019/20 Opinion", "\uf0b7 The cashbook closing balance revealed an amount of Eur.8,442.77 (equivalent to UGX.35,283,771) while the bank statement closing balance revealed Eur.53,180.48 (222,250,267) resulting into un-reconciled difference of Eur.44,737.71 (equivalent to UGX.186,966,496)."], [null, "Qualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 186, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was spent by the entity resulting in an unspent balance of UGX.0.35Bn representing an absorption level of 91.5%. \uf0b7 I sampled 5 outputs with a total of 16 activities and actual expenditure of UGX.3.89Bn and observed that 1 output with a total of 6 activities and expenditure worth UGX.1.14Bn was fully quantified, 2 outputs with a total of 8 activities and expenditure worth UGX.2.47Bn were insufficiently quantified while 2 outputs with 2 activities and expenditure worth UGX.0.28Bn were not quantified at all. \uf0b7 Out of 6 activities planned, only 2 were fully implemented (33%) while 1 activity was partially implemented (17%) and 3 activities were actually not implemented (50%). \uf0b7 Funds to the tune of \u00a3 890 (UGX.3,739,406) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The entity did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 A review of the cumulative performance reports revealed the subsequent quarterly performance reports did not include activities implemented in the previous quarter(s) and therefore, the cumulative activities reported in the fourth quarter performance report does not include all activities implemented in the first, second and third quarters. \uf0b7 The Mission paid Euros.45,314 (equivalent to UGX.190,390,396) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission had a fixed assets register detailing all of the Mission\u2019s assets but lacked some of the information such as date of purchase, estimated useful life, maintenance costs and the expected date of disposal making it incomplete. I further observed that a number of the entity\u2019s assets were old and due for boarding off but this had not been done.", "None", "None"], "type": "table"}}, {"content": "174", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 186, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], [null, null, "Germany was under lock down (March to June, 2020). I could not"], [null, null, "establish the genuineness of the expenditure."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 187, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", null, "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], [null, null, "Germany was under lock down (March to June, 2020). I could not"], [null, null, "establish the genuineness of the expenditure."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 187, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", null, "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], [null, null, "Germany was under lock down (March to June, 2020). I could not"], [null, null, "establish the genuineness of the expenditure."], [null, null, "\uf0b7 The Embassy has an approved staff structure of 8 positions out of which"], [null, null, "5 (62.5%) were filled leaving 3 (37.5%) vacant."], ["7\\. Uganda Embassy in Brussels 2019/20 Opinion Unqualified \uf0b7 Out of the planned 10 strategic targets/goals in the Mission charter, two (2) targets had been fully achieved while eight (8) were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.445Bn representing 7.9% performance. \uf0b7 I sampled 4 outputs with a total of 11 activities and actual expenditure of UGX.10.359Bn and observed that all the 4 outputs with a total of 11 activities and expenditure worth UGX.10.359Bn were fully quantified. I further observed that 1 output with 1 activity worth UGX.4.993Bn was fully implemented while 3 outputs with 10 activities worth UGX.5.336Bn were partially implemented. \uf0b7 Funds to the tune of USD.1,949.02 (equivalent to UGX.7,990,982) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The entity submitted performance reports for Q1, Q2, Q3 and Q4 but there was no evidence for submission before elapse of the deadline. I noted cases of material inaccuracies and inconsistencies in the annual cumulative performance reports. \uf0b7 The Embassy paid Euro.21,086.69 (equivalent to UGX.88,711,704) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 \uf0b7 The Embassy spent Embassy spent Euro.16,297.47 (equivalent to UGX.68,563,456) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Euro.15,364.80 (equivalent to UGX.64,639,713) was incurred on the payments for telephone bills out of which Euro.10,243.20 (UGX.43,093,142), equivalent to (2/3) should have been recovered from the respective staff during the period but the recovery was not effected contrary to Section H (h-e) (12) of the Public service Standing Orders, 2010. \uf0b7 The Embassy has an approved staff structure of 8 positions out of which 6 (75%) were filled leaving 2 (25%) vacant.", null, null], ["8.", "Uganda Embassy in Bujumbura 2019/20", "\uf0b7 Out of the planned 9 strategic targets/goals in the Mission charter, three (3) targets had been fully achieved, three (3) were partially achieved while three (3) were not achieved."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 187, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "175", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 187, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 I sampled 6 outputs with a total of 23 activities and actual expenditure of"], [null, "UGX.4.140Bn and observed that 4 outputs with a total of 21 activities and"], [null, "expenditure worth UGX.3.440Bn were fully quantified while 2 outputs"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 188, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", "\uf0b7 I sampled 6 outputs with a total of 23 activities and actual expenditure of"], [null, "UGX.4.140Bn and observed that 4 outputs with a total of 21 activities and"], [null, "expenditure worth UGX.3.440Bn were fully quantified while 2 outputs"], [null, "with a total of 2 activities and expenditure worth UGX.0.7Bn were"], [null, "insufficiently quantified. I further observed that all 4 outputs with 21"], [null, "activities were partially implemented."], [null, "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "MoFPED and NPA and also did not prepare and submit quarterly"], [null, "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, "\uf0b7 The entity submitted performance reports for Q1, Q2, Q3 and Q4 but"], [null, "there was no evidence for submission before elapse of the deadline."], [null, "\uf0b7 The Mission had total collections including balance brought forward from"], [null, "previous year of UGX.59,804,444 out of which UGX.17,626,729 had been"], [null, "transferred to the Treasury for onward transfer to the Consolidated Fund"], [null, "leaving a balance UGX.42,177,715 not remitted"], [null, "\uf0b7 The Embassy paid USD.16,000 (equivalent to UGX.59,685,280) in respect"], [null, "of education allowances direct to its officials instead of their respective"], [null, "education institutions or schools contrary to Section (E - e) Paragraphs 19"], [null, "and 20 of the Public Service Standing Orders, 2010."], [null, "\uf0b7 BIF.452,224,651 (equivalent to UGX.863,334,000) was withdrawn from"], [null, "the Mission\u2019s expenditure account as cash imprest but was not"], [null, "adequately accounted for."], [null, "\uf0b7 The Embassy maintains an asset register which is not in the format"], [null, "prescribed in the Treasury Instructions and has a number of assets that"], [null, "are unserviceable and need to be disposed of."], ["9\\. Uganda Embassy in Cairo, 2019/20 Opinion Unqualified \uf0b7 All the seven (7) targets/goals of the Mission Charter were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.999Bn representing 4.45% performance. \uf0b7 Out of the total receipts for the financial year of UGX.5.564Bn, UGX.4.952Bn was spent by the entity resulting in an unspent balance of UGX.0.612Bn representing an absorption level of 89%. \uf0b7 4 outputs with 14 activities and expenditure worth UGX.3.176Bn were not quantified to enable assessment of performance. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The entity submitted performance reports for Q1, Q2, Q3 and Q4 but there was no evidence for submission before elapse of the deadline. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.238,031,600 out of which UGX.183,216,635 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.54,814,965 not remitted. \uf0b7 UGX.90,391,294 was disclosed as unspent balances for the period 2018/19 but note 17, cash and cash equivalents indicates that the prior year closing balance was UGX.75,022,891. The variance amounting to UGX.15,368,403 was not explained. \uf0b7 EGP.1,015,780.00 (equivalent to UGX.229,058,390) was drawn as imprest", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 188, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "176", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 188, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["and spent on activities such as advances, transport and per diems which are not small incidental expenditures contrary to Instruction 17.22 of the Treasury Instructions 2017. \uf0b7 The Embassy paid USD.27,419.00 (equivalent to UGX.101,998,680) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 The Embassy spent Egyptian pounds.255,613 (equivalent to UGX.57,640,732) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010.", null, null, null], ["10", "Uganda High Commission in Canberra. 2019/20 Opinion Qualified", null, "\uf0b7 The High Commission made upfront payments for rent of AUD.43,096.67 (equivalent to UGX.109,469,851) beyond the financial year but did not disclose the same as prepayments in the Statement of Financial Position"], [null, null, null, "for the year. \uf0b7 The High Commission did not provide strategic performance reports and"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 189, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["and spent on activities such as advances, transport and per diems which are not small incidental expenditures contrary to Instruction 17.22 of the Treasury Instructions 2017. \uf0b7 The Embassy paid USD.27,419.00 (equivalent to UGX.101,998,680) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 The Embassy spent Egyptian pounds.255,613 (equivalent to UGX.57,640,732) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010.", null, null, null], ["10", "Uganda High Commission in Canberra. 2019/20 Opinion Qualified", null, "\uf0b7 The High Commission made upfront payments for rent of AUD.43,096.67 (equivalent to UGX.109,469,851) beyond the financial year but did not disclose the same as prepayments in the Statement of Financial Position"], [null, null, null, "for the year. \uf0b7 The High Commission did not provide strategic performance reports and"], [null, null, null, "therefore, I could not undertake an assessment of the achievements of the Mission charter targets/goals."], [null, "", "", "\uf0b7 There was a shortfall in NTR collections amounting to UGX.1.00Bn"], [null, "", "", "representing 0.05% performance."], [null, "", "", "\uf0b7 I sampled 3 outputs with a total of 9 activities and actual expenditure of"], [null, "", "", "UGX.4.84Bn and observed that the activities were not quantified. I was"], [null, "", "", "therefore unable to undertake assessment of the performance of the High"], [null, "", "", "Commission."], [null, "", "", "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "", "", "MoFPED and NPA and also did not prepare and submit quarterly"], [null, "", "", "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, "", "", "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, "", "", "\uf0b7 The entity submitted performance reports for Q1, Q2 and Q3 after the"], [null, "", "", "deadline given for submission. I noted cases of material inaccuracies and"], [null, "", "", "inconsistencies in the level of performance reported."], [null, "", "", "\uf0b7 Assets to the tune of AUD.25,060 (equivalent to UGX.63,654,906) were"], [null, "", "", "procured during the year which were not disclosed in the summary"], [null, "", "", "statement of stores and other assets (physical assets) at the end of the"], [null, "", "", "year."], [null, "", "", "\uf0b7 The High Commission had total collections including balance brought"], [null, "", "", "forward from previous year of UGX.59,002,072. At the closure of the"], [null, "", "", "period, no funds had been transferred to the Treasury for onward"], [null, "", "", "transfer to the Consolidated Fund thus implying UGX.59,002,072 was not"], [null, "", "", "remitted"], [null, "", "", "\uf0b7 The Embassy paid AUD.77,726 (equivalent to UGX.197,430,593) in"], [null, "", "", "respect of education allowances direct to its officials instead of their"], [null, "", "", "respective education institutions or schools contrary to Section (E - e)"], [null, "", "", "Paragraphs 19 and 20 of the Public Service Standing Orders, 2010."], [null, "", "", "\uf0b7 The Embassy spent AUD.77,726 (equivalent to UGX.197,430,593) on"], [null, "", "", "refunds for medical expenses to its officers contrary to the requirements"], [null, "", "", "of Section M (m-a) (14) of the Public Service Standing Orders, 2010."], [null, "", "", "\uf0b7 AUD.28,722 (equivalent to UGX.72,956,752) out of which AUD.19,148"], [null, "", "", "(equivalent to UGX.48,637,835) representing 2/3 of the amount should"], [null, "", "", "have been recovered from the respective staff was incurred on the"], [null, "", "", "payments for telephone bills during the period. The recovery was not"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 189, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "177", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 189, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, null, "effected."], [null, null, null, "\uf0b7 AUD.44,725.21 (equivalent to UGX.113,605973) was withdrawn from the"], [null, null, null, "High Commission\u2019s local expenditure account as cash imprest but was not"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 190, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", null, null, "effected."], [null, null, null, "\uf0b7 AUD.44,725.21 (equivalent to UGX.113,605973) was withdrawn from the"], [null, null, null, "High Commission\u2019s local expenditure account as cash imprest but was not"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 190, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", null, null, "effected."], [null, null, null, "\uf0b7 AUD.44,725.21 (equivalent to UGX.113,605973) was withdrawn from the"], [null, null, null, "High Commission\u2019s local expenditure account as cash imprest but was not"], [null, null, null, "adequately accounted for."], [null, null, null, "\uf0b7 Out of an approved staff structure of 7 staff positions for the Mission, six"], [null, null, null, "(86%) were filled leaving one (14%) vacant."], ["11\\. Uganda High Commission in Dar es Salaam. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 30 strategic targets/goals in the Mission charter, eight(8) outputs/targets had been fully achieved, twelve (12) were partially achieved, while ten (10) were not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.3.12Bn representing 0.01% performance. \uf0b7 I sampled 5 outputs with a total of 18 activities and actual expenditure of UGX.5.277Bn and observed that 1 output with 1 activity and expenditure worth UGX.0.173 was fully quantified, 1 output with 4 activities and expenditure worth UGX.0.674Bn was partially quantified at 50% quantification while 3 outputs with 13 activities and expenditure worth UGX.4.43Bn were not quantified. I further observed that 1 output with 1 activity and expenditure worth UGX.0.173Bn was partially implemented. \uf0b7 The entity submitted performance reports for Q1, Q2, Q3 and Q4 but there was no evidence for submission before elapse of the deadline. \uf0b7 Prepayments amounting to TSHS.1,130,500 (equivalent to UGX.1,818,975) were made to various suppliers for services but were not disclosed in the financial statements thereby understating the assets in the Statement of Financial Position and overstating expenditure in the Statement of Financial Performance. \uf0b7 The Embassy owns land in Dodoma on which the proposed Chancery building and official residence are to be constructed but the value of this land was not disclosed in the financial statements contrary to GOU accounting policy \u2018disclosure of land under non-produced assets. \uf0b7 The Embassy paid UGX.74,506,600 in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 The Embassy spent UGX.61,871,014 on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 UGX.15,954,192 out of which UGX.10,636,129 representing 2/3 of the amount should have been recovered from the respective staff was incurred on the payments for telephone bills during the period. The recovery was not effected. \uf0b7 Out of an approved staff structure of 7 staff positions for the Mission, 5 (71%) were filled leaving 2 (29%) vacant.", null, null, null], ["12.", "Uganda High Commission in Doha. 2019/20", null, "\uf0b7 Prepayments amounting to QR.424,000 (equivalent to UGX.431,046,880) were made to various suppliers for services but were not disclosed in the financial statements thereby understating the assets in the Statement of"], [null, null, null, "Financial Position and overstating expenditure in the Statement of"], [null, "Opinion Qualified", null, "Financial Performance."], [null, null, null, "\uf0b7 There was a shortfall in NTR collections amounting to UGX.1.547Bn representing 1.45% performance."], [null, "", "", "\uf0b7 Out of the total receipts for the financial year of UGX.3.293Bn,"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 190, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "178", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 190, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "UGX.2.64Bn was spent by the entity resulting in an unspent balance of"], [null, "UGX.0.653Bn representing an absorption level of 80.2%."], [null, "\uf0b7 I sampled 5 outputs with a total of 7 activities and actual expenditure of"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 191, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", "UGX.2.64Bn was spent by the entity resulting in an unspent balance of"], [null, "UGX.0.653Bn representing an absorption level of 80.2%."], [null, "\uf0b7 I sampled 5 outputs with a total of 7 activities and actual expenditure of"], [null, "UGX.2.64Bn and observed that 2 outputs of the 5 outputs with a total of"], [null, "2 activities and expenditure worth UGX.0.06Bn were not quantified. I"], [null, "further observed that 1 output out of the 3 outputs with 2 activities worth"], [null, "UGX.2.02Bn was fully implemented 2 outputs with 3 activities worth"], [null, "UGX.0.56Bn were partially implemented."], [null, "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "MoFPED and NPA and also did not prepare and submit quarterly"], [null, "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, "\uf0b7 The Embassy submitted performance reports for Q1, Q2, Q3 and Q4 after"], [null, "the deadline given for submission of the reports."], [null, "\uf0b7 The Embassy spent QR.11,481 (equivalent to UGX.11,671,814) on"], [null, "refunds for medical expenses to its officers contrary to the requirements"], [null, "of Section M (m-a) (14) of the Public Service Standing Orders, 2010."], [null, "\uf0b7 QR.43,652 (equivalent to UGX.44,377,496) out of which (2/3) amounting"], [null, "to QR.29,101 (equivalent to UGX.29,584,659) should have been"], [null, "recovered from the respective staff was incurred on the payments for"], [null, "telephone bills during the period. The recovery was not effected."], [null, "\uf0b7 I noted that all the three (3) sampled procurements were undertaken"], [null, "using direct procurement method but no justification was given and no"], [null, "contract manager was appointed to oversee these procurements."], [null, "\uf0b7 Out of an approved staff structure of 7 staff positions for the Mission, 9"], [null, "(60%) were filled leaving 6 (40%) vacant."], ["13 Uganda High Commission in Geneva. 2019/20 Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.3.045Bn representing 3% performance. \uf0b7 I sampled 3 outputs with a total of 7 activities and actual expenditure of UGX.7.66Bn and observed that all the 3 outputs were fully quantified and were partially implemented. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Embassy submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.345,130,819. At the closure of the period, UGX.146,139,671 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.198,991,148 not remitted. \uf0b7 UGX.27,296,608 was spent on procurements outside the approved procurement plan for the financial year 2019/2020 while procurements worth UGX.294,979,327 were acquired using the wrong procurement methods. \uf0b7 The fixed assets register maintained by the entity was not updated as it lacks details of exact month of purchase (only the year was mentioned), maintenance cost and estimated useful life of the asset. \uf0b7 The Embassy paid UGX.39,320,000 in respect of education allowances", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 191, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "179", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 191, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 CHF.12,623 (equivalent to UGX.49,602,836) out of which CHF.8,415 (equivalent to UGX.33,068,557) equivalent to 2/3 should have been recovered from the respective staff was incurred on the payments for telephone bills during the period. The recovery was not effected. \uf0b7 Out of an approved staff structure of 7 staff positions for the Mission, six (86%) were filled leaving one (14%) vacant.", null, null], ["14", "Uganda Consulate in Guangzhou, China 2019/20", "\uf0b7 Out of the planned 8 strategic targets/goals in the Mission charter, six (6) outputs/targets had been fully achieved while two (2) were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.037Bn representing 2.54% performance."], [null, "Opinion Unqualified", null], ["15\\. Uganda Embassy in South Sudan. 2019/20 \uf0b7 Prepayments amounting to UGX.399,145,310 were made to various suppliers for services but were not disclosed in the financial statements", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 192, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "180", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 192, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Qualified thereby understating the assets in the Statement of Financial Position and overstating expenditure in the Statement of Financial Performance. \uf0b7 Out of the planned 7 strategic targets/goals in the Mission charter, 2 outputs/targets had been fully achieved while 5 were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.56Bn representing 17.3% performance. \uf0b7 Out of the total receipts for the financial year of UGX.7.624Bn, UGX.9.11Bn was spent by the entity resulting into an over absorption of UGX.1.48Bn representing an absorption level of 119%. \uf0b7 I sampled 5 outputs with a total of 30 activities and actual expenditure of UGX.7.07Bn and observed that 4 outputs with a total of 18 activities and expenditure worth UGX.6.69Bn were fully quantified while 1 output with a total of 12 activities and expenditure worth UGX.0.39Bn was insufficiently quantified. For the 5 fully quantified outputs, 2 outputs with 2 activities worth UGX.2.55Bn were fully implemented while 3 outputs with 28 activities worth UGX.4.09Bn were partially implemented. \uf0b7 Funds to the tune of USD.17,382.29 (equivalent to UGX.64,841,678) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The entity submitted performance reports for Q1, Q2 and Q3 after the deadline given for submission. I noted some cases of material inaccuracies and inconsistencies in the level of performance reported. \uf0b7 UGX.328,779,539 reported as cash in transit has been in the books of the Embassy for more than three financial years and the funds have never been credited to the Consolidated Fund. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.884,552,695out of which UGX.180,503,771 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.704,048,924 not remitted. \uf0b7 The Embassy paid USD.25,000.00 (equivalent to UGX.93,258,250) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 USD.1,613.00 (equivalent to UGX.6,017,022) out of which USD.1,076.00 (equivalent to UGX.4,013,835) representing 2/3 of the amount should have been recovered from the respective staff was incurred on the payments for telephone bills during the period. The recovery was not effected. \uf0b7 Out of an approved staff structure of 6 staff positions for the Mission, 5 (83%) were filled leaving 1(17%) vacant.", null, null], ["16.", "Uganda Embassy in Khartoum.", "\uf0b7 Out of the planned 10 strategic targets/goals in the Mission charter, 5 outputs/targets had been fully achieved while 3 were partially achieved."], [null, "2019/20", null], [null, "Opinion", ""]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 193, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "181", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 193, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Unqualified", "UGX.4.169Bn and observed that 2 outputs with a total of 6 activities and expenditure worth UGX.0.95Bn were fully quantified, 1 output with a total"], [null, null, "of 4 activities and expenditure worth UGX.3.11Bn was insufficiently"], [null, null, "quantified while 1 output with 1 activity and expenditure worth UGX.0.11"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 194, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", "Unqualified", "UGX.4.169Bn and observed that 2 outputs with a total of 6 activities and expenditure worth UGX.0.95Bn were fully quantified, 1 output with a total"], [null, null, "of 4 activities and expenditure worth UGX.3.11Bn was insufficiently"], [null, null, "quantified while 1 output with 1 activity and expenditure worth UGX.0.11"], [null, null, "was totally not quantified. I further observed that no output was fully"], [null, null, "implemented while 3 outputs with 10 activities worth UGX.4.09Bn were"], [null, null, "partially implemented."], [null, null, "\uf0b7 Funds to the tune of USD.4,393.04 (equivalent to UGX.15,595,150) were"], [null, null, "irregularly diverted from the activities on which they were budgeted and"], [null, null, "spent on other activities without seeking and obtaining the necessary"], [null, null, "approvals."], [null, null, "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, null, "MoFPED and NPA and also did not prepare and submit quarterly"], [null, null, "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, null, "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, null, "\uf0b7 The entity submitted performance reports for Q1, Q2 and Q3 after the"], [null, null, "deadline given for submission."], [null, null, "\uf0b7 The Embassy paid USD.17,500.00 (equivalent to UGX.64,925,000) in"], [null, null, "respect of education allowances direct to its officials instead of their"], [null, null, "respective education institutions or schools contrary to Section (E - e)"], [null, null, "Paragraphs 19 and 20 of the Public Service Standing Orders, 2010."], [null, null, "\uf0b7 The Embassy spent USD.3,702.42 (equivalent to UGX.13,702,656.42) on"], [null, null, "refunds for medical expenses to its officer\u2019s contrary to the requirements"], [null, null, "of Section M (m-a) (14) of the Public Service Standing Orders, 2010."], [null, null, "\uf0b7 USD.7,979.94 (equivalent to UGX.29,605,577) out of which USD.5,319.96"], [null, null, "(equivalent to UGX.19,737,051) representing 2/3 of the amount should"], [null, null, "have been recovered from the respective staff was incurred on the"], [null, null, "payments for telephone bills during the period. The recovery was not"], [null, null, "affected."], [null, null, "\uf0b7 Out of an approved staff structure of 5 staff positions for the Mission, 4"], [null, null, "(80%) were filled leaving 1 (20%) vacant."], ["17 Uganda Embassy in Kigali. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 10 strategic targets/goals in the Mission charter, 2 outputs/targets had been fully achieved, 2 were partially achieved while 6 were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.3.07Bn representing 2.3% performance. \uf0b7 I sampled 4 outputs with a total of 13 activities and actual expenditure of UGX.3.325Bn and observed that all the 4 outputs were not quantified. Therefore, I was unable to undertake assessment of the performance of the Mission. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The entity submitted performance reports for Q1, Q2 and Q3 after the deadline given for submission. I noted that the cumulative activities reported in the fourth quarter performance report did not include all activities implemented in the first, second and third quarters. \uf0b7 I noted that the assets register maintained was not in the format prescribed in the Treasury Instructions and lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 194, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "182", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 194, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["useful life. \uf0b7 Out of an approved staff structure of 5 staff positions for the Mission, two (2) (40%) were filled leaving 3 (60%) vacant.", null, null], ["18", "Uganda Embassy in Kinshasa. 2019/20", "\uf0b7 UGX.241,949,940 was reported as the variance between the approved budget/warrants and the actual expenditure instead of UGX.3,564,587. The source of UGX.241,949,940 could not be established. \uf0b7 The statement of revenue collected in the financial statements in comparison with statement of performance and the NTR estimates for the"], [null, "Opinion Qualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 195, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "183", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 195, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "(85.7%) were filled leaving 3 (14.3%) vacant."], ["19 Uganda High Commission in Kuala Lumpur. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 10 (ten) strategic targets/goals in the Mission charter, one (1) target had been fully achieved, three (3) were partially achieved, while six (6) were not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.068Bn representing 1% performance. \uf0b7 I sampled 3 outputs with a total of 13 activities and actual expenditure of UGX.3.57Bn and observed that 2 outputs with a total of 9 activities and expenditure worth UGX.0.87Bn were fully quantified while 1 output with a total of 4 activities and expenditure worth UGX.2.6Bn was insufficiently quantified. Of the fully quantified outputs, 1 output with 5 activities worth UGX.0.21Bn was fully implemented while 1 output with 4 activities worth UGX.0.66Bn was partially implemented. \uf0b7 Funds to the tune of MYR.11,209 (equivalent to UGX.9,763,039) were irregularly diverted from purchase of specialized machinery and equipment for which they were budgeted to purchase of curtains without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q2 and Q3 after the deadline given for submission of the reports. \uf0b7 The Embassy paid MYR.136,000 (equivalent to UGX.118,456,000) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 The Mission has an approved staff structure of five (5) staff positions out of which, two (2) (40%) were filled leaving three (3) (60%) vacant. \uf0b7 Management of the Embassy paid salary and FSA advances to staff to the tune of MYR.185,950 (equivalent to UGX.160,995,510) which exceeded three (3) months gross pay and no authority was sought from Secretary to the Treasury. This is contrary to the Public Service Standing Orders, 2010.", null, null], ["20", "Uganda High Commission in London. 2019/20 Opinion Unqualified", "\uf0b7 Out of the planned 9 (nine) strategic targets/goals in the Mission charter, four (4) targets had been fully achieved, three (3) were partially"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 196, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", null, "(85.7%) were filled leaving 3 (14.3%) vacant."], ["19 Uganda High Commission in Kuala Lumpur. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 10 (ten) strategic targets/goals in the Mission charter, one (1) target had been fully achieved, three (3) were partially achieved, while six (6) were not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.068Bn representing 1% performance. \uf0b7 I sampled 3 outputs with a total of 13 activities and actual expenditure of UGX.3.57Bn and observed that 2 outputs with a total of 9 activities and expenditure worth UGX.0.87Bn were fully quantified while 1 output with a total of 4 activities and expenditure worth UGX.2.6Bn was insufficiently quantified. Of the fully quantified outputs, 1 output with 5 activities worth UGX.0.21Bn was fully implemented while 1 output with 4 activities worth UGX.0.66Bn was partially implemented. \uf0b7 Funds to the tune of MYR.11,209 (equivalent to UGX.9,763,039) were irregularly diverted from purchase of specialized machinery and equipment for which they were budgeted to purchase of curtains without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q2 and Q3 after the deadline given for submission of the reports. \uf0b7 The Embassy paid MYR.136,000 (equivalent to UGX.118,456,000) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 The Mission has an approved staff structure of five (5) staff positions out of which, two (2) (40%) were filled leaving three (3) (60%) vacant. \uf0b7 Management of the Embassy paid salary and FSA advances to staff to the tune of MYR.185,950 (equivalent to UGX.160,995,510) which exceeded three (3) months gross pay and no authority was sought from Secretary to the Treasury. This is contrary to the Public Service Standing Orders, 2010.", null, null], ["20", "Uganda High Commission in London. 2019/20 Opinion Unqualified", "\uf0b7 Out of the planned 9 (nine) strategic targets/goals in the Mission charter, four (4) targets had been fully achieved, three (3) were partially"], [null, null, "achieved, while two (2) were not achieved."], [null, null, "\uf0b7 There was a shortfall in NTR collections amounting to UGX.1.604Bn"], [null, null, "representing 31% performance."], [null, null, "\uf0b7 I sampled 4 outputs with a total of 7 activities and actual expenditure of UGX.7.32Bn and observed that all the 4 outputs with 7 activities and"], [null, null, "expenditure worth UGX.7.32Bn were not quantified to enable assessment"], [null, null, "of performance."], [null, null, "\uf0b7 Funds to the tune of GBP.2,598.56 (equivalent to UGX.11,756,583) were"], [null, null, "irregularly diverted from purchase of specialized machinery and"], [null, null, "equipment for which they were budgeted to purchase of curtains without"], [null, null, "seeking and obtaining the necessary approvals."], [null, null, "\uf0b7 Entities are supposed to report actual performance of the quarter as well"], [null, null, "as the cumulative activities of the previous quarter(s). I observed that"], [null, null, "cumulative performance reports did not include activities implemented in"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 196, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "184", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 196, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "the previous quarter(s)."], [null, "\uf0b7 The Mission had total collections including balance brought forward from"], [null, "previous year of UGX.1,606,177,645 out of which UGX.706,072,607 had"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 197, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", "the previous quarter(s)."], [null, "\uf0b7 The Mission had total collections including balance brought forward from"], [null, "previous year of UGX.1,606,177,645 out of which UGX.706,072,607 had"], [null, "been transferred to the Treasury for onward transfer to the Consolidated"], [null, "Fund leaving a balance UGX.900,105,038 not remitted."], [null, "\uf0b7 Payables increased from UGX.130,550,604 in the previous year to"], [null, "UGX.161,515,890 in the year under review, an increase of 24%. The"], [null, "arrears remained unsettled at the close of the year."], [null, "\uf0b7 Management has accumulated receivable advances to the tune of"], [null, "UGX.105,435,937 of which UGX.79,896,783 (76%) relates to the prior"], [null, "year and remains unrecovered."], [null, "\uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end"], [null, "of the financial year 2019/2020 revealed that additions during the year"], [null, "relating to non-residential buildings were disclosed as UGX.465,161,335,"], [null, "however, the Embassy procured items amounting to GBP.107,661"], [null, "(equivalent to UGX.494,777,699) implying that items worth"], [null, "UGX.29,616,364 were not disclosed in this statement thus understating"], [null, "the Statement of Stores and Other Assets (physical assets)."], [null, "\uf0b7 The Embassy had a capital expenditure budget of UGX.275,000,000 but"], [null, "items worth UGX.494,777,699 were procured resulting into an over"], [null, "expenditure of UGX.224,777,699."], [null, "\uf0b7 The Embassy paid GBP.28,187.49 (equivalent UGX.129,541,258) in"], [null, "respect of education allowances direct to its officials instead of their"], [null, "respective education institutions or schools contrary to Section (E - e)"], [null, "Paragraphs 19 and 20 of the Public Service Standing Orders, 2010."], [null, "\uf0b7 The Embassy spent GBP.14,300.09 (equivalent to UGX.65,718,929) on"], [null, "refunds for medical expenses to its officers contrary to the requirements"], [null, "of Section M (m-a) (14) of the Public Service Standing Orders, 2010."], [null, "\uf0b7 The Mission has an approved staff structure of eight (8) staff positions"], [null, "out of which, 5 (63%) were filled leaving 3 (37%) vacant."], ["21\\. Uganda Embassy in Mogadishu. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 5 strategic targets/goals in the Mission charter, all the 5 were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.3.14Bn representing 0% performance. \uf0b7 Out of the total receipts of UGX.3.78Bn, UGX.2.87Bn was spent by the entity resulting in an unspent balance of UGX.0.91Bn representing an absorption level of 76%. \uf0b7 I sampled 3 outputs with a total of 6 activities and actual expenditure of UGX.2.87Bn and observed that all the 3 outputs with a total of 6 activities and expenditure worth UGX.2.87Bn were not quantified at all. I was therefore unable to assess the implementation of outputs/activities of the Mission. \uf0b7 Funds to the tune of UGX.16,835,000 were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, Q2, Q3 and Q4 after", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 197, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "185", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 197, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["the deadline given for submission. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.850,244,773 out of which UGX.7,829 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.850,236,944 not remitted. \uf0b7 USD.1,020,250 (equivalent to UGX.3,800,767,933) was withdrawn as petty cash during the year out of which USD.340,250.00 (equivalent to UGX.1,267,543,533) was withdrawn in the last quarter of the financial year (March, April, May and June), the period affected by COVID 19 lockdown which appears irregular. \uf0b7 The Embassy paid UGX.83,250,000 in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010.", null, null], ["22.", "Uganda Consulate in", "\uf0b7 Out of the planned 6 strategic targets/goals in the Mission charter, 2"], ["", "Mombasa. 2019/20", "outputs/targets had been fully achieved while 4 were partially achieved."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 198, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": [["the deadline given for submission. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.850,244,773 out of which UGX.7,829 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.850,236,944 not remitted. \uf0b7 USD.1,020,250 (equivalent to UGX.3,800,767,933) was withdrawn as petty cash during the year out of which USD.340,250.00 (equivalent to UGX.1,267,543,533) was withdrawn in the last quarter of the financial year (March, April, May and June), the period affected by COVID 19 lockdown which appears irregular. \uf0b7 The Embassy paid UGX.83,250,000 in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010.", null, null], ["22.", "Uganda Consulate in", "\uf0b7 Out of the planned 6 strategic targets/goals in the Mission charter, 2"], ["", "Mombasa. 2019/20", "outputs/targets had been fully achieved while 4 were partially achieved."], [null, null, "\uf0b7 There was a shortfall in NTR collections amounting to UGX.2.089Bn representing 0.01% performance. \uf0b7 Out of the total receipts for the financial year of UGX.1.996Bn,"], [null, "", "UGX.1.883Bn was spent by the entity resulting in an under expenditure of"], [null, "", "UGX.0.113Bn representing an absorption level of 94.34%."], [null, "", "\uf0b7 UGX.12,562,792 was received as off-budget financing for a symposium"], [null, "", "held in the financial year under review but the funds were not disclosed"], [null, "", "in the financial statements."], [null, "", "\uf0b7 I sampled 3 outputs with a total of 4 activities and actual expenditure of"], [null, "", "UGX.1.883Bn and observed that 1 output with a total of 2 activities and"], [null, "", "expenditure worth UGX.0.73Bn was fully quantified while 2 outputs with a"], [null, "", "total of 2 activities and expenditure worth UGX.1.15Bn were insufficiently"], [null, "", "quantified. The quantified output with all its activities with its activities"], [null, "", "and expenditure worth UGX.0.73Bn was partially implemented."], [null, "", "\uf0b7 Funds to the tune of UGX.5,205,620 were charged wrongly on other"], [null, "", "expenditure item codes without obtaining the necessary approvals."], [null, "", "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "", "MoFPED and NPA and also did not prepare and submit quarterly"], [null, "", "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, "", "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, "", "\uf0b7 Entities are supposed to report actual performance of the quarter as well"], [null, "", "as the cumulative activities of the previous quarter(s). I observed that"], [null, "", "cumulative performance reports did not include activities implemented in"], [null, "", "the previous quarter(s)."], [null, "", "\uf0b7 The Embassy paid UGX.44,763,960 in respect of education allowances"], [null, "", "direct to its officials instead of their respective education institutions or"], [null, "", "schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public"], [null, "", "Service Standing Orders, 2010."], [null, "", "\uf0b7 A number of the Consulate\u2019s assets were old and due for boarding off but"], [null, "", "were still at the Consulate resulting into loss of value and high"], [null, "", "maintenance costs."], ["23\\. Uganda Embassy in Moscow. 2019/20 \uf0b7 Out of the planned 24 (twenty-four) strategic targets/goals in the Mission charter, thirteen (13) targets had been fully achieved, eight (8) were partially achieved, while three (3) were not achieved.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 198, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "186", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 198, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", null, null], ["24.", "Uganda High Commission in Nairobi.", "\uf0b7 Out of the planned 10 (ten) strategic targets/goals in the Mission charter, 2 (two) were partially achieved while eight (8) were not achieved."], [null, "2019/20", null], [null, "Opinion Unqualified", ""], [null, null, "was spent by the entity resulting in an unspent balance of UGX.1.17Bn"], [null, null, "representing an absorption level of 76.3%."], [null, null, "\uf0b7 I sampled 4 outputs with a total of 7 activities and actual expenditure of"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 199, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "187", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 199, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "UGX.3.77Bn and observed that all the 4 outputs with a total of 7 activities"], [null, "and expenditure worth UGX.3.77Bn were fully quantified but were"], [null, "partially implemented."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 200, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None"], "type": "table"}}, {"content": [["", "UGX.3.77Bn and observed that all the 4 outputs with a total of 7 activities"], [null, "and expenditure worth UGX.3.77Bn were fully quantified but were"], [null, "partially implemented."], [null, "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "MoFPED and NPA and also did not prepare and submit quarterly"], [null, "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, "\uf0b7 The Mission submitted performance reports for all quarters after the"], [null, "deadline given for submission. I also observed that cumulative"], [null, "performance reports revealed that the subsequent quarterly performance"], [null, "reports did not include activities implemented in the previous quarter(s)."], [null, "\uf0b7 Accumulated arrears of revenue to the tune of UGX.181,948,023 most of"], [null, "which related to the prior year remained uncollected."], [null, "\uf0b7 The Embassy paid a sum of USD.46,950 (equivalent to UGX.174,513,150)"], [null, "to Toyota Kenya Limited for the acquisition of a Land Cruiser Prado but"], [null, "the procurement was undertaken by the High Commissioner instead of"], [null, "the Accounting Officer which resulted into usurping the powers of the"], [null, "Accounting Officer, over committing the Mission, non-compliance with"], [null, "Government ban on acquisition of motor vehicles, un-planned"], [null, "procurement, use of inappropriate procurement method and failure to"], [null, "involve the Contracts Committee."], [null, "\uf0b7 The Embassy paid KES.3,360,000 (equivalent to UGX.117,633,600) in"], [null, "respect of education allowances direct to its officials instead of their"], [null, "respective education institutions or schools contrary to Section (E - e)"], [null, "Paragraphs 19 and 20 of the Public Service Standing Orders, 2010."], [null, "\uf0b7 The Embassy spent KES.620,485 (equivalent to UGX.21,723,180)on"], [null, "refunds for medical expenses to its officers contrary to the requirements"], [null, "of Section M (m-a) (14) of the Public Service Standing Orders, 2010."], [null, "\uf0b7 The Mission did not have a fixed assets register in the format prescribed"], [null, "in the Treasury Instructions and therefore additions and disposals to the"], [null, "assets could not be verified. I further observed that a number of the"], [null, "entity\u2019s assets were old and due for boarding off exposing the assets to"], [null, "loss of value and high maintenance costs."], [null, "\uf0b7 The Mission has an approved staff structure of seven (7) staff positions"], [null, "out of which 5 (71.4%) were filled leaving 2 (28.5%) vacant."], ["25\\. Uganda Embassy in New Delhi. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 6 (six) strategic targets/goals in the Mission charter, 1 (one) was fully achieved while 2 (two) were partially achieved while three (3) were not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.62Bn representing 0.0015% performance. \uf0b7 Out of the total receipts for the financial year of UGX.4.554Bn, UGX.3.732Bn was spent by the entity resulting in an unspent balance of UGX.0.822Bn representing an absorption level of 81.9%. \uf0b7 I sampled 3 outputs with a total of 6 activities and actual expenditure of UGX.3.732Bn and observed that all the 3 outputs were fully quantified and none was fully implemented. \uf0b7 Funds to the tune of INR.42,262 (equivalent to UGX.2,062,385) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 200, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None"], "type": "table"}}, {"content": "188", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 200, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["MoFPED and NPA and contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 Cumulative performance reports did not include activities implemented in the previous quarter(s). \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.524,440,586 out of which UGX.160,671,521 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.1,284,723,792 not remitted. \uf0b7 INR.38,324.24 (equivalent to UGX.1,839,564) out of which 2/3 of the amount should have been recovered from the respective staff was incurred on the payments for telephone bills during the period. The recovery was not effected. \uf0b7 Salary advances to the tune of USD. 98,406.39 (equivalent to UGX.369,023,963) were paid to staff during the year which exceeded three (3) months gross contrary to the Public Service Standing Orders. \uf0b7 The Embassy spent INR.549,516.00 (equivalent to UGX.26,376,775) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010.", null, null], ["26.", "The Uganda Embassy in New York.", "\uf0b7 The Embassy had a capital expenditure budget of UGX.0 but items worth UGX.665,143,450 resulting into an over expenditure of UGX.665,143,450."], [null, "2019/20 Opinion Qualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 201, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": "189", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 201, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, null, "\uf0b7 The Embassy spent UGX.145,667,183 on refunds for medical expenses to"], [null, null, null, "its officers contrary to the requirements of Section M (m-a) (14) of the"], [null, null, null, "Public Service Standing Orders, 2010."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 202, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None", "None"], "type": "table"}}, {"content": [["", null, null, "\uf0b7 The Embassy spent UGX.145,667,183 on refunds for medical expenses to"], [null, null, null, "its officers contrary to the requirements of Section M (m-a) (14) of the"], [null, null, null, "Public Service Standing Orders, 2010."], [null, null, null, "\uf0b7 The Mission prepared an approved procurement plan for the financial"], [null, null, null, "year 2019/2020 but procurement reports and procurement files were not"], [null, null, null, "availed for audit."], [null, null, null, "\uf0b7 The Mission has an approved staff structure of 9 staff positions out of"], [null, null, null, "which 8 (88%) were filled leaving 01 (12%) vacant."], ["27\\. Uganda High Commission in Ottawa. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 8 (eight) strategic targets/goals in the Mission charter, four (4) were fully achieved while 2 (two) were partially achieved while two (2) were not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.077Bn representing 0.62% performance. \uf0b7 I sampled 3 outputs with a total of 8 activities and actual expenditure of UGX.5.63Bn and observed that all the 3 outputs were fully quantified but none was fully implemented. \uf0b7 Funds to the tune of CAD.3,301.3 (equivalent to UGX.9,586,521) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit the annual monitoring plans to MoFPED and NPA contrary Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.2,585,956,931 out of which UGX.39,588,787 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.2,546,368,144 not remitted. \uf0b7 The Mission paid CAD.35,000.00 (equivalent to UGX.101,605,000)in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Embassy spent CAD.114,255 (equivalent to UGX.331,693,168) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010.", null, null, null], ["28.", "Uganda Embassy in Paris. 2019/20 Opinion Unqualified", null, "\uf0b7 The Mission made upfront payments for rent of EUR.50,183 (equivalent to UGX.209,723,288) beyond the financial year but did not disclose the"], [null, null, null, "same as prepayments in the Statement of Financial Position for the year. \uf0b7 Funds to the tune of UGX.40,504,892 were irregularly diverted from the"], [null, null, null, "activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals."], [null, "", "", "\uf0b7 There was a shortfall in NTR collections amounting to UGX.2.61Bn"], [null, "", "", "representing 0.4% performance."], [null, "", "", "\uf0b7 Out of the total receipts for the financial year of UGX.9.59Bn, UGX.5.56Bn"], [null, "", "", "was spent by the entity resulting in an unspent balance of UGX.4.03Bn"], [null, "", "", "representing an absorption level of 58%."], [null, "", "", "\uf0b7 I sampled 4 outputs with a total of 19 activities and actual expenditure of"], [null, "", "", "UGX.5.56Bn and observed that 1 output (25%) with a total of 7 activities"], [null, "", "", "and expenditure worth UGX.1.61Bn was insufficiently quantified while 3"], [null, "", "", "outputs (75%) with a total of 12 activities and expenditure worth UGX"], [null, "", "", "3.95Bn were not quantified at all. I was therefore unable to undertake"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 202, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None", "None"], "type": "table"}}, {"content": "190", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 202, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "assessment of implementation of outputs by the Mission."], [null, "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "MoFPED and NPA and also did not prepare and submit quarterly"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 203, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None"], "type": "table"}}, {"content": [["", "assessment of implementation of outputs by the Mission."], [null, "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "MoFPED and NPA and also did not prepare and submit quarterly"], [null, "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, "\uf0b7 The Mission submitted performance reports for Q1, Q2, Q3 and Q4 after"], [null, "the deadline given for submission. Furthermore, entities are supposed to"], [null, "report actual performance of the quarter as well as the cumulative"], [null, "activities of the previous quarter(s) but the Mission quarterly performance"], [null, "reports did not include activities implemented in the previous quarter(s)."], [null, "\uf0b7 The Embassy paid EUROS.30,691 (equivalent to UGX.128,071,701) in"], [null, "respect of education allowances direct to its officials instead of their"], [null, "respective education institutions or schools contrary to Section (E - e)"], [null, "Paragraphs 19 and 20 of the Public Service Standing Orders, 2010."], [null, "\uf0b7 The Embassy spent EUROS.7,933 (equivalent to UGX.33,101,972) on"], [null, "refunds for medical expenses to its officers contrary to the requirements"], [null, "of Section M (m-a) (14) of the Public Service Standing Orders, 2010."], [null, "\uf0b7 UGX.3.75BN was released for renovation and modification of Uganda"], [null, "Chancery Building in Paris but the procurement was undertaken using the"], [null, "restricted bidding instead of open domestic bidding without proper"], [null, "justification. Furthermore, the implementation of the contract had not"], [null, "commenced by the end of the financial and the contactor is said to have"], [null, "had difficulty in obtaining a bank guarantee from banks because the"], [null, "Mission is a foreign entity which could pose challenges in contract"], [null, "performance."], [null, "\uf0b7 The Mission has an approved staff structure of 7 staff positions out of"], [null, "which positions, 6 (86%) were filled leaving 1 (14%) vacant."], [null, "\uf0b7 EUR.43,541.63 (equivalent to UGX.181,969,420) was paid from the"], [null, "Mission\u2019s imprest account to cater for official activities but EUR.15,851"], [null, "(equivalent to UGX.66,244,024) was spent on activities such as,"], [null, "allowances, purchase of computer and household items which cannot be"], [null, "categorised under imprest making it irregular."], ["29\\. Uganda Embassy in Pretoria. 2019/2020 Opinion Unqualified \uf0b7 Out of the planned 8 (eight) strategic targets/goals in the Mission charter, two (2) were fully achieved while 4 (four) were partially achieved while two (2) were not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.49Bn representing 5% performance. \uf0b7 I sampled 4 outputs with a total of 8 activities and actual expenditure of UGX.3.62Bn and observed that three (3) outputs with a total of seven (7) activities and expenditure worth UGX.3.54Bn were fully quantified while one (1) output with one (1) activity and expenditure worth UGX.0.08Bn was not quantified. Of the quantified outputs, one (1) output with three (3) activities worth UGX.0.38Bn was fully implemented while two (2) outputs with four (4) activities worth UGX.3.16Bn were partially implemented. \uf0b7 Funds to the tune of RAND.35,774.08 (equivalent to UGX.7,697,509) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The entity submitted performance reports for Q1, Q2, Q3, and Q4, however they were submitted after the deadline. I also observed that cumulative performance reports did not include activities implemented in", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 203, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None"], "type": "table"}}, {"content": "191", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 203, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["the previous quarter(s) \uf0b7 The Embassy paid USD.18,000.009 (equivalent to UGX.66,785,973) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 The Embassy spent 162,579.25 RAND (equivalent to UGX.34,982,177) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 The Mission has an approved staff structure of 6 staff positions out of which, 5 (83%) were filled leaving 1 (17%) vacant.", null, null], ["30.", "Uganda Embassy in Riyadh 2019/2020", "\uf0b7 There was a shortfall in NTR collections amounting to UGX.2.088Bn representing 0.5% performance. \uf0b7 I sampled 3 outputs with a total of 13 activities and actual expenditure of UGX.4.156Bn and observed that all the 3 outputs were fully quantified. I"], [null, "Opinion Unqualified", null], ["31\\. Uganda Embassy in Rome 2019/20 Opinion Unqualified \uf0b7 Out of the planned 8 (eight) strategic targets/goals in the Mission charter, two (2) targets had been fully achieved and six (6) were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.503Bn representing 4.2% performance. \uf0b7 Of the total receipts for the financial year of UGX.5.564Bn, UGX.4.952Bn was spent by the entity resulting in an unspent balance of UGX.0.612Bn representing an absorption level of 89%. \uf0b7 I sampled 4 outputs with a total of 8 activities and actual expenditure of UGX.3.62Bn and observed that 3 outputs with a total of 7 activities and expenditure worth UGX.3.54Bn were fully quantified while 1 output with 1 activity and expenditure worth UGX.0.08Bn was not quantified. Of the quantified outputs, 1) output with 3) activities worth UGX.0.38Bn was fully implemented while 2 outputs with 4 activities worth UGX.3.16Bn", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 204, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": "192", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 204, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["were partially implemented. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.1,702,152,606 out of which UGX.67,884,170 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.1,634,268,436 not remitted. \uf0b7 The Mission reported cash in transit of UGX.32,102,340 which relates to over 10 years ago which may be difficult for the Mission to trace or recover. \uf0b7 The Statement of Contingent Liabilities in the financial statements for the year ended 30th June, 2020, indicated an opening balance of UGX.1,141,003,975.79 instead of UGX.542,522,152.97 resulting into an overstatement of UGX.598,481,822.82. \uf0b7 During the year 2019/2020, management of the Mission was availed a supplementary funding of UGX.433,360,086 to cater for settlement of four (4) court cases but the Mission still remained with outstanding liabilities for settlement of court cases amounting to UGX.542,522,152 at the end of the year. \uf0b7 The Embassy spent Euros.8,430.75 (equivalent to UGX.35,422,471) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 The Embassy has an approved staff structure of 6 staff positions out of which 5 (83%) were filled leaving 1 (15%) vacant.", null, null], ["32.", "Uganda Embassy in Tokyo", "\uf0b7 Out of the planned 17 (seventeen) strategic targets/goals in the Mission"], ["", "2019/20", "charter, nine (9) were fully achieved, 4 (four) were partially achieved while four (4) were not achieved at all. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.451Bn"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 205, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": "193", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 205, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 JPY.2,591,132 (equivalent to UGX.89,938,192) out of which 2/3 of the"], [null, null, "amount should have been recovered from the respective staff was"], [null, null, "incurred on the payments for telephone bills during the period. The"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 206, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": [["", null, "\uf0b7 JPY.2,591,132 (equivalent to UGX.89,938,192) out of which 2/3 of the"], [null, null, "amount should have been recovered from the respective staff was"], [null, null, "incurred on the payments for telephone bills during the period. The"], [null, null, "recovery was not effected."], [null, null, "\uf0b7 The fixed assets register maintained by the entity was not in the format"], [null, null, "prescribed in the Treasury Instructions and lacked details of: cost of"], [null, null, "some items, maintenance cost, estimated useful life, among others and"], [null, null, "assets which had already been disposed were still in the assets register."], ["33\\. Uganda Embassy in Washington. 2019/20 Opinion Unqualified \uf0b7 Funds to the tune of UGX.184,722,054 were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 Out of the planned 31 strategic targets/goals in the Mission charter, 13 were fully achieved while 18 were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.3.64Bn representing 0.7% performance. \uf0b7 Out of the total receipts for the financial year of UGX.8,039,710,935, UGX.7,707,884,006 was spent by the entity resulting in an unspent balance of UGX.331,826,929 representing an absorption level of 96%. \uf0b7 I sampled 6 outputs with a total of 17 activities and actual expenditure of UGX.7.67Bn and observed that all 6 outputs were not quantified. I was therefore unable to undertake assessment of performance. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 Performance reports for Q1, Q2 and Q3 were submitted after the deadline given for submission. \uf0b7 The Mission paid USD.27,500 (equivalent to UGX.103,134,075) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Embassy spent USD.21,764.99 (equivalent to UGX.81,625,894.95) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 USD.18,000 (equivalent to UGX.69,552,175) was paid to Embassy staff as Covid relief allowance during the financial year 2019/2020 in the last month of the financial year. This allowance is not provided for in the Public Service Standing Orders and neither was it budgeted for during the year. \uf0b7 JPY.2,591,132 (equivalent to UGX.89,938,192) out of which 2/3 of the amount should have been recovered from the respective staff was incurred on the payments for telephone bills during the period. The recovery was not effected. \uf0b7 The fixed assets register maintained by the entity was not in the format prescribed in the Treasury Instructions and lacked details of: cost of some items, maintenance cost, estimated useful life, among others and assets which had already been disposed were still in the assets register.", null, null], ["34.", "Uganda Embassy in Teheranc. 2019/2020", "\uf0b7 Out of the planned 11 (eleven) strategic targets/goals in the Mission charter, one (1) were fully achieved while 10 (ten) were partially"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 206, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": "194", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 206, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "achieved."], [null, "Opinion", "\uf0b7 There was a shortfall in NTR collections amounting to UGX.1.57Bn representing 0.1% performance. \uf0b7 I sampled 7 outputs with a total of 12 activities and actual expenditure of"], [null, "Unqualified", null], ["35\\. Uganda Embassy in Addis Ababa. 2019/2020 Opinion Unqualified \uf0b7 Out of the planned 7 strategic targets/goals, no target was fully achieved, 5 targets were fully achieved and 2 targets were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.85Bn representing 11% performance. \uf0b7 Out of the total receipts for the financial year of UGX.4.16Bn, UGX.3.81Bn was spent by the entity resulting in an unspent balance of UGX.0.35Bn representing an absorption level of 91.5%. \uf0b7 I sampled 5 outputs with a total of 9 activities and actual expenditure of UGX.3.76Bn and observed that 3 outputs with a total of 7 activities and expenditure worth UGX.3.76Bn were fully quantified while 2 outputs with a total of 2 activities were not quantified. I further observed that 2 outputs with 5 activities worth UGX.3.22Bn were fully implemented while 1 output with 2 activities worth UGX.0.674Bn was partially implemented. \uf0b7 Funds to the tune of Birr.304,045.69 (equivalent to UGX.23,958,820) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 A review of the 4 quarterly performance reports revealed that the supplementary release of UGX.0.653Bn was not captured at all making the reports inaccurate. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.707,901,392 out of which UGX.236,256,209 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.471,645,183 not remitted. \uf0b7 USD.48,129.83 and BIRR.94,144.96 (equivalent to UGX.183,940,336)", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 207, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": "195", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 207, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["was withdrawn from the Mission\u2019s local expenditure account as cash imprest but was not adequately accounted for. \uf0b7 The Mission paid USD.44,000.00 (equivalent to UGX.165,000,000) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission paid medical refunds to its staff amounting to Birr.298,287.38 (equivalent to UGX.582,793,607) contrary to Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 The Mission maintains an assets register that is not in the format prescribed by the Treasury Instructions.", null, null], ["36.", "Uganda Embassy in Copenhagen. 2019/2020", "\uf0b7 A sum of UGX.300,000,000 was approved by Parliament as supplementary budget for the Embassy for the financial year 2019/2020 out of which UGX.270,000,000 was subsequently released during the"], [null, null, "year. This amount was not accurately disclosed in the \u201cCommentary on"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 208, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": [["was withdrawn from the Mission\u2019s local expenditure account as cash imprest but was not adequately accounted for. \uf0b7 The Mission paid USD.44,000.00 (equivalent to UGX.165,000,000) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission paid medical refunds to its staff amounting to Birr.298,287.38 (equivalent to UGX.582,793,607) contrary to Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 The Mission maintains an assets register that is not in the format prescribed by the Treasury Instructions.", null, null], ["36.", "Uganda Embassy in Copenhagen. 2019/2020", "\uf0b7 A sum of UGX.300,000,000 was approved by Parliament as supplementary budget for the Embassy for the financial year 2019/2020 out of which UGX.270,000,000 was subsequently released during the"], [null, null, "year. This amount was not accurately disclosed in the \u201cCommentary on"], [null, "Opinion Qualified", "the Financial Statements by the Head of Accounts\u201d."], [null, null, "\uf0b7 Receivables from security deposits reduced by UGX.53,375,046 from UGX.313,145,225 in the previous year to UGX.259,770,179 as at the end"], [null, null, "of the year 2019/2020. I was not availed with supporting records to"], [null, null, "confirm the movement."], [null, null, "\uf0b7 VAT claims increased from UGX.45,636,374 in the previous year to"], [null, null, "UGX.70,11,405 in the current year. I was not provided with a ledger"], [null, null, "showing the specific VAT claims, the VAT supplier numbers, and"], [null, null, "documents to support the claims for refunds from the tax authority"], [null, null, "among others."], [null, null, "\uf0b7 Monthly and end-of-year bank reconciliations were not carried out. In"], [null, null, "addition, a list of bank accounts operated by the Embassy during the year"], [null, null, "was not disclosed by the Head of Accounts in his commentary on the"], [null, null, "Financial Statements."], [null, null, "\uf0b7 The Embassy\u2019s approved budget for Non-Tax Revenue was"], [null, null, "UGX.1,570,000,000. I observed that the Non-Tax Revenue budget was"], [null, null, "not reflected in the Statements of Appropriation."], [null, null, "\uf0b7 The Mission paid advances to various suppliers amounting to"], [null, null, "DKK.861,578.82 (equivalent to UGX.479,037,824). Whereas the Financial"], [null, null, "Reporting Guide, 2018 requires that prepayments are reported separately"], [null, null, "in the Statement of Cash Flows \u2013 as net advances paid and in the"], [null, null, "Statement of Financial Position as receivables, I noted that these"], [null, null, "prepayments were missing in both statements."], [null, null, "\uf0b7 The Embassy lost a court case and subsequently a sum of"], [null, null, "UGX.27,965,384 (DKK.49,878.51) was awarded and paid in the year"], [null, null, "2019/2020. I noted that the Memorandum Statement of Outstanding"], [null, null, "Commitments did not disclose the details regarding this case and there"], [null, null, "was no evidence that the funds for settlement of this court case had been"], [null, null, "budgeted for during the year."], [null, null, "\uf0b7 Funds amounting to DKK.399,793.77 (equivalent to UGX.225,083,893)"], [null, null, "were irregularly diverted from the activities on which they were budgeted"], [null, null, "and spent on other activities for which money had not been appropriated"], [null, null, "without seeking and obtaining the necessary approval."], [null, null, "\uf0b7 Payments made to the tune of DKK.109,193.75 (equivalent to"], [null, null, "UGX.61,221,660) lacked adequate supporting documents. Consequently,"], [null, null, "I could not confirm that the amounts paid were commensurate to the"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 208, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": "196 \nworks or supplies made by the different payees. \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 208, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Embassy had planned to refurbish the official residence and UGX.300,000,000 was released by the Ministry of Finance Planning and Economic Development (MoFPED) through a supplementary budget for the purpose. However, the refurbishment did not take place and UGX.190,000,000 was returned to the consolidated fund as required by Section 17(2) of the PFMA 2015 while UGX.110,000,000 was diverted.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Payments to the tune of DKK.171,063.61 (equivalent to UGX.95,910,234) had contradicting supporting documentation attached, payments were unbudgeted for or were incurred for activities which are not the responsibility of the Embassy.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Salary payments to locally recruited staff at the Mission to the tune of DKK.141,940.00 (equivalent to UGX.79,581,500) were made to two staff but no contract appointment letters were availed to justify them.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- Out of the budgeted NTR of UGX.1,570,000,000 for the financial year 2019/2020 only UGX.33,780,671 was collected representing performance of 2.15% of the target. The entity did not remit the collected amounts to the consolidated fund by the 31st July following the closure of the financial year contrary to the requirements of the PFMA.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the total receipts for the financial year of UGX.5.642Bn, UGX.5.152Bn was spent by the Mission resulting in an unspent balance of UGX.0.490Bn representing an absorption level of 91.3%. The unspent balance at the end of the financial year was not returned to the consolidated fund account by the 31st July 2020 contrary to the law.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the 5 outputs with a total of 9 activities and expenditure of UGX.5.152Bn, 2 outputs with a total of 2 activities and expenditure worth UGX.0.467bn were fully quantified, 2 outputs with a total of 5 activities and expenditure worth UGX.4.828Bn were insufficiently quantified while 1 output with a total of 2 activities and expenditure worth UGX.0.372Bn was not quantified at all. Of the quantified outputs, 1 output with 1 activity worth UGX.0.167bn was fully implemented while 1 output with 1 activity worth UGX.0.300bn was partially implemented.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. In addition, performance reports for Q1, Q2, Q3 and Q4 were submitted after the deadline for submission.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that the Head of Mission and the Accounting Officer were absent from the station from March 2020 to June 2020, a period that is critical for preparation and finalisation of the Embassy financial statements. The two officers were under lock-down restrictions in Uganda due to onset of the Covid-19 pandemic. In addition the Finance Attach\u00e9 was not in office for most of the financial year. This negatively impacted on the operations of the Mission during that period.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- During the month of June 2020, a sum of DKK.152,700 (equivalent to UGX.85,970,100) was paid to Embassy staff for claims for trips that had been undertaken in January and February 2020. I observed that the payments were not adequately supported to justify that the trips were undertaken.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- An officer of the Embassy was paid Foreign Service Allowance for the months of November and December amounting to DKK.23,375.85 (equivalent to UGX.13,160,604) and education allowance amounting to", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "197", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "DKK.37,500 (equivalent to UGX.21,112,500) while on interdiction."], [null, "Payment of employment benefits to staff on interdiction may be unlawful."], [null, "\uf0b7 The Embassy continued to pay rent for the Finance Attach\u00e9\u2019s residence"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 210, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", "DKK.37,500 (equivalent to UGX.21,112,500) while on interdiction."], [null, "Payment of employment benefits to staff on interdiction may be unlawful."], [null, "\uf0b7 The Embassy continued to pay rent for the Finance Attach\u00e9\u2019s residence"], [null, "from April 2020 to September 2020 amounting to DKK.133,800.00"], [null, "(equivalent to UGX.75,329,400), a period during which the residence was"], [null, "not occupied."], [null, "\uf0b7 The Embassy procured 64 items for use at the Chancery and Embassy"], [null, "staff residences involving a sum of DKK.433,707.00 (equivalent to"], [null, "UGX.244,177,283). The procurements were undertaken without"], [null, "adherence to the procurement procedures and were not adequately"], [null, "accounted for."], [null, "\uf0b7 Contrary to the provisions in the law, expenditure amounting to"], [null, "DKK.1,181,215.74 (equivalent to UGX.665,024,462) was irregularly"], [null, "incurred by the Embassy during the month of July out of the expired"], [null, "appropriation and before the first quarter release for the financial year"], [null, "2020/2021 was received."], [null, "\uf0b7 Prepayments amounting to DKK.566,960.83 (equivalent to"], [null, "UGX.319,198,947) were made to nine (9) suppliers for services including"], [null, "fuel, insurance, water, electricity and heating. The funds were paid"], [null, "before the services were received by the Embassy."], [null, "\uf0b7 Cash amounting to DKK.37,000 (equivalent to UGX.20,831,000) was"], [null, "irregularly withdrawn from the Mission\u2019s corporate bank account by Amb."], [null, "Elly Kamahungye Kafeero to pay for accounting work done by a non-"], [null, "member of staff living outside Copenhagen. The funds were re-deposited"], [null, "on the Embassy account on 12th June 2020 by Amb. Elly Kamahungye"], [null, "Kafeero after three months because the reasons for which the funds were"], [null, "withdrawn had been suspended. I found it unusual for an amount of"], [null, "money to be set aside for an activity without confirming the total cost of"], [null, "the activity or following procurement procedures to identify a supplier."], [null, "\uf0b7 During the year 2019/2020, the Finance Committee was comprised of the"], [null, "Head of Mission (chairperson), Deputy Head of Mission, Accounting"], [null, "Officer, Finance Attach\u00e9, Head of Chancery (Third Secretary) and the"], [null, "Administrative Attach\u00e9. I observed that the Committee did not perform its"], [null, "roles of reviewing and approving the budgets and work-plans, monitoring"], [null, "implementation of the annual work-plans and procurement plans,"], [null, "monitoring implementation of internal controls over financial"], [null, "management and ensuring that there is compliance with applicable laws"], [null, "and regulations."], ["37\\. Ministry of Foreign Affairs (MOFA). 2020/21 Opinion Unqualified \uf0b7 The Ministry has an approved strategic plan for FY 2020/21- 2024/25. NPA had issued a Certificate of Compliance (CoC) to the Ministry, and Ministry Top Management had approved the plan. It is now aligned to the NDPIII. \uf0b7 The Ministry collected only 5.7% of its NTR target for the year and had a shortfall in government funding of UGX.19.886Bn which is 30.9% of the budget. The Ministry absorbed 92.3% of the funds that were released. \uf0b7 Out of the thirty-two (32) outputs sampled, ten (10) were fully quantified, seventeen (17) were insufficiently quantified and five (5) were not quantified. \uf0b7 Out of the ten (10) outputs assessed, seven (7) were fully implemented while three (3) were partially implemented. \uf0b7 The Ministry prepared and submitted the annual budget implementation plans and reports as required but failed to accurately report and submit", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 210, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "198", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 210, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["its quarterly budget performance reports in time. \uf0b7 Analysis of the Ministry\u2019s domestic arrears over the past four years showed an increase by 34.2% from 2016/17 to 2020/21. \uf0b7 The Ministry had domestic arrears worth UGX.37,436,592,723 from the prior financial year but only budgeted for UGX.6,356,885,823 (17%) in the financial year under review, thus under budgeting. \uf0b7 The approved staff establishment of Ministry of Foreign Affairs revealed that out of the approved 362 staff positions, 344 positions representing 95% were filled while 18 positions representing 5% were vacant.", null, null], ["38", "Ministry of East African Community Affairs 2020/21", "\uf0b7 I noted that the Ministry only had a draft strategic plan. NPA had not issued a Certificate of Compliance (CoC) to prompt to management of the Ministry approve the strategic plan. \uf0b7 The Ministry budgeted for NTR of UGX.699,000,000 for the financial year 2020/21, however only UGX.12,100,000 was collected representing"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 211, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "DKK.37,500 (equivalent to UGX.21,112,500) while on interdiction."], "type": "table"}}, {"content": [["its quarterly budget performance reports in time. \uf0b7 Analysis of the Ministry\u2019s domestic arrears over the past four years showed an increase by 34.2% from 2016/17 to 2020/21. \uf0b7 The Ministry had domestic arrears worth UGX.37,436,592,723 from the prior financial year but only budgeted for UGX.6,356,885,823 (17%) in the financial year under review, thus under budgeting. \uf0b7 The approved staff establishment of Ministry of Foreign Affairs revealed that out of the approved 362 staff positions, 344 positions representing 95% were filled while 18 positions representing 5% were vacant.", null, null], ["38", "Ministry of East African Community Affairs 2020/21", "\uf0b7 I noted that the Ministry only had a draft strategic plan. NPA had not issued a Certificate of Compliance (CoC) to prompt to management of the Ministry approve the strategic plan. \uf0b7 The Ministry budgeted for NTR of UGX.699,000,000 for the financial year 2020/21, however only UGX.12,100,000 was collected representing"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 Out of the fourteen (14) outputs sampled, twelve (12) were fully"], [null, null, "quantified, while two (2) were insufficiently quantified."], [null, null, "\uf0b7 Out of the twelve (12) outputs assessed, eight (8) were fully"], [null, null, "implemented while four (4) were partially implemented."], [null, null, "\uf0b7 The Ministry neither prepared annual budget monitoring plans nor"], [null, null, "submitted quarterly budget monitoring reports. The Ministry also failed to"], [null, null, "submit all its quarterly budget performance reports in time."], [null, null, "\uf0b7 Analysis of the Ministry\u2019s domestic arrears over the past four years"], [null, null, "showed a downward trend from 2017 to 2021. As at the close of the"], [null, null, "financial year a sum of UGX.13,002,369,510 was outstanding."], [null, null, "\uf0b7 Out of the approved one hundred three (103) staff positions, seventy two"], [null, null, "(72) positions representing 70% were filled while thirty one (31) positions"], [null, null, "representing 30% were vacant."], [null, null, ""], ["39 The Independent Electoral Commission. 2020/21 Opinion Unqualified \uf0b7 The Commission had not finalised the preparation of the strategic plan for the period 2021-2025. \uf0b7 The entity budgeted to collect NTR of UGX.4.483Bn during the year under review. Out of this, UGX.31.1Bn was collected, representing a performance of 694% of the target. \uf0b7 Out of the total warrants of UGX.671.61Bn received during the financial year, UGX.649.15Bn was spent by the entity resulting in an unspent balance of UGX.21.906Bn representing absorption level of 96.1%. \uf0b7 Out of the 9 outputs with a total of 40 activities and expenditure of UGX.671.61Bn assessed, 4 outputs with a total of 10 activities and expenditure worth UGX.51.838Bn was fully quantified, 3 outputs with a total of 16 activities and expenditure worth UGX.499.639Bn were insufficiently quantified while 2 outputs with a total of 14 activities and expenditure worth UGX.97.675Bn were not quantified at all. \uf0b7 Of the 4 out puts that were fully quantified with a total of ten (10) activities worth UGX.51.8Bn, 3 outputs with a total of 9 activities worth UGX.50.9Bn were fully implemented, while 1 output with 1 activity worth UGX.0.846Bn was partially implemented.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 211, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "DKK.37,500 (equivalent to UGX.21,112,500) while on interdiction."], "type": "table"}}, {"content": "199", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 211, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 An assessment to establish if there has been service delivery from a sample of outputs that were implemented revealed that purchase of motor vehicles and other transport equipment was undertaken but not fully used for the purpose while the Commission continues to pay rent after fully acquiring warehousing space. \uf0b7 I noted inconsistencies in the reported performance where all vehicles were reported as received which was not true while reported balances in the financial statements were inconsistent with those reported in the performance reports. \uf0b7 I noted that funds to the tune of UGX.4,023,217,397 were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 I noted that the Commission has been accumulating arrears in past three years and during the year 2020/2021, UGX.6.959Bn in arrears remained outstanding. \uf0b7 The Commission has in the past won cases and was awarded costs to the tune of UGX.336,880,920 but management has not collected these receivables. \uf0b7 The Commission procured Biometric Voter Verification Kit and services for the 2021 general election at a cost of UGX.82,894,881,252 and I observed that available kits were not considered while the services were not fully delivered. \uf0b7 The Commission entered into two contract agreements with a company to supply 10 double cabin pick-up vehicles at a cost of UGX.1,564,563,350 and 40 double cabin pick-up vehicles at UGX.7,013,387,920 for nomination of the Presidential candidates but by the time of audit, whereas the Commission had paid the full amount, only 32 double cabin vehicles out of the total 50 vehicles procured had been delivered leaving a balance of 18 vehicles. \uf0b7 The Commission procured for printing of ballot papers for 2021 general elections at a total cost of UGX.83.855Bn. 248 out of expected 448 pallets were delivered but the Commission had assembled vehicles to carry the entire load which rendered the vehicles redundant and this caused a loss to the Commission in form of hire fees, fuel and allowances. \uf0b7 The Commission was required to vacate their current premises by 30th June, 2021 and was subsequently compensated with UGX.22.14Bn by the Uganda National Roads Authority which was transferred to the consolidated fund as non-tax revenue. As a result of the continued delay to implement this critical activity of finding a new home, the Commission is already incurring losses on property acquired and is also likely to cause government to incur litigation costs through UNRA\u2019s failure to completely hand over the construction sites for roads to the contractor. \uf0b7 The Commission contracted two law firms for provision of legal services for Presidential petition at a cost of UGX.3,748,550,000 which had been budgeted at UGX.800Million resulting into payment of UGX.2,948,550,000 over and above the budget. Even though the planning for the elections started 3 years back, the procurement was treated as an emergency and there was no basis for the fees charged or detail of how the Commission came up with the market price for the service.", null, null], ["", "WORKS AND TRANSPORT SECTOR", ""], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 212, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "200", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 212, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", null, null], ["2", "Report on Verification SGS Automotive Uganda Limited For", "\uf0b7 I was unable to obtain all documents relating to the procurement for my review. From the available records however, it was noted that there were significant delays in the procurement process arising from administrative"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 213, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "201", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 213, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Setting Up of Vehicle", "reviews and court processes. It is also important to note that the High"], [null, "Inspection Facilities Under the Contract for Provision of Mandatory Motor Vehicle Inspection", "Court had made a ruling in favour of award of the contract to SGS. \uf0b7 There were delays in formulation of the statutory instrument covering revision of chargeable rates, negatively impacting on compliance by the vehicle owning public."], [null, "Services (MVIS). Dec 2021", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 214, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None", "None"], "type": "table"}}, {"content": [["", "Setting Up of Vehicle", "reviews and court processes. It is also important to note that the High"], [null, "Inspection Facilities Under the Contract for Provision of Mandatory Motor Vehicle Inspection", "Court had made a ruling in favour of award of the contract to SGS. \uf0b7 There were delays in formulation of the statutory instrument covering revision of chargeable rates, negatively impacting on compliance by the vehicle owning public."], [null, "Services (MVIS). Dec 2021", null], ["3 Uganda Road Fund. Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 URF did not forecast the NTR to be collected during the year. However, the Fund collected a total of UGX7,078,800 during the year. \uf0b7 Out of the total warrants of UGX. 506.507bn received during the financial year, UGX. 506.296 Bn was spent by the entity resulting in an unspent balance of UGX. 0.211Bn representing an absorption level of 99.96%. The unspent funds were swept back to the consolidated fund as required by the PFMA \uf0b7 The Authority did not implement some of its planned activities during the year. Examples include: Production of quarterly reports on the status and functionality of District Road Committees; Recruitment and substantive appointment of staff and; Review and calibration of the funds allocation formula. \uf0b7 The Fund did not collect the funds provided for under section 21 of the URF Act 2008 which mandates the Fund on recommendation by the URF Board to charge road user charges which include fuel levies, international transit fees from vehicles entering the country, road license fees, axle load fees, and bridge and road toll fees. \uf0b7 I noted that the fund allocation formula was last reviewed by the Secretariat in 2019. In addition, during the year, the formula was not reviewed to provide for current situations such as budget cuts and Covid- 19 pandemic effects which led to disproportionate transfers to designated agencies. \uf0b7 Procurements worth UGX 642,234,236 had delays ranging between 1 and 93 working days. For example; the contract for provision of Motor Vehicle maintenance services under framework contract was delayed by 93 days and the contract for supply, delivery and installation of I-pads for URF Board members was delayed by 15 days. \uf0b7 There were inadequate monitoring Designated Agencies. Out of the 203 designated agencies supposed to be monitored, only twenty-seven (27) Agencies representing 13.3% of the total designated agencies and sub", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 214, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None", "None"], "type": "table"}}, {"content": "202", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 214, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["agencies were monitored during the year. \uf0b7 Whereas URF had central stores under the charge and control of the Administrative Officer, the entity did not have a proper stores management system that is recommended in the Treasury Instructions.", null, null], ["4", "Uganda National Roads Authority. 2020/21 Opinion", "\uf0b7 A total of UGX 124,367,095,163 representing 21.58% of the spent funds for the sampled planned outputs was diverted from the budgeted projects to other projects contrary to the above provision. There was no evidence that the reallocations/diversions of such magnitude were authorized either by Parliament or the relevant funders."], [null, "Qualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 215, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None", "None"], "type": "table"}}, {"content": "203", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 215, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "agreed resettlement houses was initially scheduled to be completed by"], [null, "December 2020, no contractor had been procured for this purpose by the"], [null, "time of the audit in September 2021, implying a delay of over 9 months."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 216, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None"], "type": "table"}}, {"content": [["", "agreed resettlement houses was initially scheduled to be completed by"], [null, "December 2020, no contractor had been procured for this purpose by the"], [null, "time of the audit in September 2021, implying a delay of over 9 months."], [null, "\uf0b7 Significant delays in subdivision, demarcation and transfer of titles for"], [null, "fully acquired plots were observed on the Kampala-Jinja Expressway and"], [null, "Hoima-Wanseko Road projects."], [null, "\uf0b7 The Authority had an outstanding balance of UGX 215,059,225,419 in"], [null, "terms of payables at the year end. This figure increased by UGX"], [null, "73,885,957,262 (52.3%) from the previous year\u2019s amount of UGX"], [null, "141,173,268,157. It was observed that the bulk of this amount is"], [null, "comprised of unpaid certificates to contractors which yield interest due to"], [null, "delayed payments."], [null, "\uf0b7 Authority made payments amounting to UGX 17,078,565,465 as a result"], [null, "of penalties for the court cases and interest on delayed payments of"], [null, "advances and IPCs invoices from various projects. This is a loss to"], [null, "Government."], [null, "\uf0b7 The value of the Authority\u2019s infrastructure assets at the end of the"], [null, "financial year was disclosed as UGX10,417,198,881,566. However,"], [null, "contrary to the policy requirement to revalue the assets every three"], [null, "years, I was not availed with any valuation report for the infrastructure"], [null, "assets to confirm that the assets had ever been valued."], [null, "\uf0b7 35 road projects with a total contract value of USD.398,427,063.99 and"], [null, "UGX. 149,739,813,845 that were to be completed during the year were"], [null, "still on \u2013 going by the close of the year."], [null, "\uf0b7 Three civil cases with claims totaling to UGX6.991bn were brought"], [null, "against UNRA due to its failure to return residue land titles to the"], [null, "registered proprietors."], ["5 Uganda Civil Aviation Authority. 2020/21 Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 UCAA budgeted to collect internal revenue of UGX 293bn during the year under review. Out of this, only UGX 114.991bn was collected, representing a performance of 39.2% of the target. \uf0b7 UCAA absorbed all its revenue collected, and accrued expenditure in unpaid bills that is. its actual expenditure was more than the revenue. \uf0b7 The Authority did not implement some of its planned activities during the year. Examples include: Capital projects for Regional Airports, KOICA Counterpart funding, and procurement of a fleet management system, updating the master plan and constructing the ground surface car park. \uf0b7 There was an increase in trade and other receivables of UGX. 12,279,645,000 (equivalent to 25%) from UGX. 48,854,526,000 to UGX.61,134,171,000. The delayed collection of the receivables may lead to bad debts. \uf0b7 Management reported an increase in trade payables of UGX 21,763,762,000 (equivalent to 47.9%) from UGX 45,470,736,000 to UGX 67,234,498,000. \uf0b7 The Authority had accumulated receivables of up to UGX 96,569,511,580 in the FY 2019/20 due from Government Agencies. In the year under review, there was no follow up of this debt to the Government agencies, and no amounts were cleared. \uf0b7 The Authority made a loss for the year under review amounting to UGX 29,321,645,000. Because of the loss, the Authority did not have capacity", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 216, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None"], "type": "table"}}, {"content": "204", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 216, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["to cover any potential interest accruing on its long term loans in view of its earnings. Along with the lack of potential to cover loan interest, the Authority had a significant long term liabilities portfolio on its balance sheet, which majorly comprised of the loan from Exim Bank of China. \uf0b7 Prime Media\u2019s contract ended with a debt of UGX 1,131,017,128 which was unpaid for the year before the expiry of the contract. \uf0b7 UCAA has multiple systems operating in different departments which are tailored for the operations in the respective departments. A review of these systems revealed that some were not functional, not interfaced with other complementary system(s) and/or some of their modules were not working. Further, the IT Point of Sale System bought for tracking of revenue from concessionaire shops was out of date. \uf0b7 The Exim Bank loan terms to UCAA were renegotiated and this was to be formalized into an addendum agreement, to ensure that they are manageable. However, the addendum to the contract terms had still not been made by the time of this audit.", null, null], ["6", "Uganda National Airlines Company Ltd (UNACL). 2020/21 Opinion Qualified", "\uf0b7 UGX 8,716,398,000 was disclosed as the value of the inventories in the statement of financial position. However there was no evidence that Management carried out end of year stock taking to get actual values of inventories. In addition, there were no stores ledgers for engineering stores, and although the general stores had manual ledgers, the ledgers were not capturing Goods Received Note reference numbers (GRN)"], [null, null, "against the receipts in the ledgers as a reference of the goods received."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 217, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None", "None"], "type": "table"}}, {"content": [["to cover any potential interest accruing on its long term loans in view of its earnings. Along with the lack of potential to cover loan interest, the Authority had a significant long term liabilities portfolio on its balance sheet, which majorly comprised of the loan from Exim Bank of China. \uf0b7 Prime Media\u2019s contract ended with a debt of UGX 1,131,017,128 which was unpaid for the year before the expiry of the contract. \uf0b7 UCAA has multiple systems operating in different departments which are tailored for the operations in the respective departments. A review of these systems revealed that some were not functional, not interfaced with other complementary system(s) and/or some of their modules were not working. Further, the IT Point of Sale System bought for tracking of revenue from concessionaire shops was out of date. \uf0b7 The Exim Bank loan terms to UCAA were renegotiated and this was to be formalized into an addendum agreement, to ensure that they are manageable. However, the addendum to the contract terms had still not been made by the time of this audit.", null, null], ["6", "Uganda National Airlines Company Ltd (UNACL). 2020/21 Opinion Qualified", "\uf0b7 UGX 8,716,398,000 was disclosed as the value of the inventories in the statement of financial position. However there was no evidence that Management carried out end of year stock taking to get actual values of inventories. In addition, there were no stores ledgers for engineering stores, and although the general stores had manual ledgers, the ledgers were not capturing Goods Received Note reference numbers (GRN)"], [null, null, "against the receipts in the ledgers as a reference of the goods received."], [null, null, "\uf0b7 I noted that the entity did not have a strategic / business plan aligned to"], [null, null, "NDPIII."], [null, null, "\uf0b7 UNACL budgeted to collect internal revenue of UGX 304.6bn during the"], [null, null, "year under review. Out of this, only UGX 48.6bn was collected,"], [null, null, "representing a performance of 16% of the target."], [null, null, "\uf0b7 The Company did not implement some of its planned activities during the"], [null, null, "year. Examples include: Procurement of spare parts for the Airbus fleet;"], [null, null, "supporting 32 pilots for A330-800 neo type training, and; supporting 60"], [null, null, "pilots in simulator training."], [null, null, "\uf0b7 The company had payables totaling UGX.47,032,043,000. All the"], [null, null, "outstanding invoices were payable to UCAA. Out of the amount, payables"], [null, null, "totaling UGX 16,065,309,363 had been due for more than 6 months."], [null, null, "\uf0b7 UGX 1,127,484,315 as the value of Property Plant and Equipment In the"], [null, null, "statement of financial position and the corresponding note (Note 12) as"], [null, null, "at the close of the financial year. However, it was noted that assets were"], [null, null, "not engraved to give them an identification number for easy of"], [null, null, "identification. It was also noted that the assets could not be traced in the"], [null, null, "assets\u2019 register due to lack of identification numbers."], [null, null, "\uf0b7 I carried out financial analysis of UNACL financial performance and"], [null, null, "observed that the Company had made losses for the year 2019/2020 and"], [null, null, "2020/2021 amounting to UGX102.442bn and UGX164.573bn respectively."], [null, null, "On review of the operating margin, I observed that the costs before"], [null, null, "considering interest and taxes exceeded company revenues for the two"], [null, null, "years. I also observed that due to the losses incurred, the Company"], [null, null, "generated negative return on assets of 12.2% for the year 2019/2020"], [null, null, "and 13.1% for the year 2020/2021. The Company\u2019s revenue is still far"], [null, null, "below its assets."], [null, null, "\uf0b7 UACL implemented twenty-five (25) procurements outside the approved"], [null, null, "procurement plan for the FY 2020/2021. The procurements were made in"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 217, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None", "None"], "type": "table"}}, {"content": "205 \ndifferent currencies amounting to (for each currency); Euro 1150,854.06, Kenya Shillings 61,879.2, USD 65,441.36, Tanzania Shillings 7,752,600 and UGX 346,738,939. \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 217, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A purchase Order was made for the supply of inflight equipment at a price of USD 25,694.46 (VAT Exclusive) without the approval of the Contracts Committee.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Two companies submitted bids for specialized motorized equipment used in ground handling of aircraft. The companies failed the preliminary stage (compliance), however, the Evaluation Committee did not cancel the evaluation process. The contract manager was not appointed and the delivery was not witnessed.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- USD 8,620.7 vide payment voucher No PV07/21/072 was paid to DAS Air as rent for the month of April 2021. Further to the above a review of invoices revealed that DAS Air had billed Uganda Airlines a total of USD 43,103.5 for unpaid ground rent. However, Uganda Airlines had not made any tenancy agreement with the DAS air, and there was no handover report from Uganda Airlines to DAS Air.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UGX 103,532,800 (USD 28,000) was paid to the supplier vide payment voucher No. PV09/20/025 dated 4/9/2020. The vehicle was purchased through direct procurement without proper justification.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Uganda National Airlines Limited made a contract agreement with M/s Ninesun Manufacturing Limited for supply of inflight service equipment for airbus at a contract amount of USD 319,226.86. The items were said to have been delivered to DAS Air. I was not provided with evidence that the items were actually delivered, witnessed for quality and quantity and handed over to DAS Air stores.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UNACL concluded the procurement of a contractor for the provision of an Enterprise Resource Planning (ERP) software solution at a contract sum of USD 1,066,910 (VAT Exclusive) as well as the provision of an integrated Passenger Service System at a contract sum of USD 1,234,441 (VAT Exclusive). The procurements were conducted and finalized without seeking the necessary approvals from NITA-U.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The company issued a purchase order on 27/01/2021 to M/s Stelia Aerospace for Supply of critical spare parts for business class seats for A330-800 NEO at a price of USD 146,230.72. I was however not provided with the contract for the supply.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- From the 20 procurements sampled, I noted that neither was there Accounting Officer\u2019s appointments of contract managers nor were there contract management files. The procurements were made in different currencies amounting to (for each currency); Euro 212,050.67, Kenya Shillings 12,253,905.74, USD 109,803,962.54 and UGX 347,242,879.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Company did not have a Board approved staff structure and establishment to assess staff recruitment needs and staffing status, and did not have approved staff salary grades. This affected proper planning and budgeting for staff costs. As a consequence, the Company incurred excess expenditure of UGX 4,919,238,464 (USD 1,333,008) on salaries and staff expenses.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- There has been delayed conclusion of suspension cases. On 21st of April 2021, some HoDs were suspended for a period of 3 months (effective 29th April, 2021) to enable the appointed committee to investigate and report on stated allegations. Review of the staff files revealed that there were no committee resolutions on the cases and as a result Management extended the suspension on 20th August 2021 for another 3 months.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n206", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Since the affected staff remained on the same terms of contract, the"], [null, "officers appointed to act in their positions receive extra pay implying"], [null, "double payment for the same position. As a consequence, the company"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 219, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", "Since the affected staff remained on the same terms of contract, the"], [null, "officers appointed to act in their positions receive extra pay implying"], [null, "double payment for the same position. As a consequence, the company"], [null, "has lost a total of UGX 2,319,017,267 in a seven months\u2019 period (May to"], [null, "November 2021)."], ["7 Uganda Railways Corporation. 2020/21 Opinion Qualified \uf0b7 The Corporation had Non-current assets worth UGX.3,525,540,249,000 as at 30th June 2021. However, this figure included a total of UGX.6,012,000,000 in respect of Kabalega ferry (UGX.5,760,000,000) and Barbus ferry (UGX.252,000,000) which sunk under water twenty five years and sixteen years respectively. Since the ferries have been out of use under water for a long time without retrieval and cannot be disposed of while under water, it cannot be determined whether they still hold the value indicated to the Corporation. \uf0b7 The Corporation had GoU equipment loans amounting to UGX.22,067,482,000 at the beginning and end of the year under review. Out of this loan amount, loans totalling UGX.16,511,595,000 (other than the Spanish Government loan) were not supported and did not show any movement over the last four (4) years. \uf0b7 Interest arising from loans that was yet to be cleared by URC amounted to UGX.9,511,880,000. However, this balance has been outstanding over several years without any movement. The status quo still remained the same by the close of the year under review. This interest payable was not supported by any original documentation. \uf0b7 Trade and Other Payables increased from UGX.17,937,602,000 at the beginning of the year to UGX.21,513,931,000 at the close of the year. Out of the amount, trade and other payables worth UGX.9,753,781,407 lacked supporting documents such as LPOs, contracts, inward invoices, claims and demand notes. \uf0b7 The Corporation had Trade and Other Receivables of UGX.75,637,890,000 as at 30th June 2021. The figure includes UGX.69,516,000,000 due from Government in respect of the Nsambya land. This amount has remained un-paid to URC for too long despite Government having disposed of the land to the public long ago implying that the Corporation may never be compensated for its land. \uf0b7 URC budgeted to collect internal revenue of UGX 120.49 during the year under review. Out of this, only UGX 54.6bn was collected, representing a performance of 45.3% of the target. \uf0b7 The Corporation did not implement some of its planned activities during the year. Examples include: Sleeper reconditioning; Kampala Station not fencing; Tororo Station Roof Repairs and; Rehabilitation of Steel Mill Jinja siding. \uf0b7 The Corporation made losses for the past two years; UGX 37,783,152,000 (2020/2021) and UGX 66,151,318,000 (2019/2020). The Corporation\u2019s losses and the ratios computed are an indication that Uganda Railways Corporation is not performing well in terms of profitability and ability to sustain provision of services without further Government intervention for funding and Management strategies to improve revenue generation. \uf0b7 Management did not assess impairment of assets despite existence of impairment indicators. For instance, rental properties were being charged below market value. \uf0b7 Uganda Railways Corporation land worth UGX.91,832,636,500 lacked land titles as evidence of URC\u2019s rights to own and use the property. Management\u2019s efforts to secure the land titles appear remote. Lack of", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 219, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "207", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 219, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["land titles has led to heavy encroachment and grabbing of the Corporation\u2019s land. \uf0b7 URC procured four (4) used locomotives at UGX.41,323,768,935. I noted that the bidder did not comply with some requirements within the bid document which were supposed to be the basis of evaluation. Despite the non-compliance at the preliminary stage, the bid was evaluated at the Technical stage without following procurement regulations. \uf0b7 Government signed an agreement with Mango Tree (U) Ltd for the rehabilitation and upgrade of the Pamba ferry. However, the vessel was still grounded after a year of signing the agreement. \uf0b7 An officer of URC irregularly signed to transfer land measuring 4.452 hectares in Lira (under FRV 220 Folio 13). The land was subdivided into plots 41-63, 52-62, 42-50 and the titles were being processed. \uf0b7 Jinja Municipal took part of URC land in Jinja (6.3 acres) and gave it out to 58 developers, without consultation with the Corporation.", null, null], ["8", "Busega-Mpigi Road Project (Uganda National Roads Authority) 2020 Opinion Unqualified", "\uf0b7 I observed slow progress in Construction works and accumulation of loan charges. As of June 30th 2020, the contractor had only achieved physical progress of 0.13% against 12.77% planned cumulative progress. The total time lapse since commencement of the construction works was 7 months constituting 24.26% of the total contract duration yet only 0.13% construction work had been achieved. Slow progress in Construction works has led to continued accumulation of both Commitment and"], [null, null, "Service Charges that amounted to UGX 2,921,803,802 and UGX"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 220, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": [["land titles has led to heavy encroachment and grabbing of the Corporation\u2019s land. \uf0b7 URC procured four (4) used locomotives at UGX.41,323,768,935. I noted that the bidder did not comply with some requirements within the bid document which were supposed to be the basis of evaluation. Despite the non-compliance at the preliminary stage, the bid was evaluated at the Technical stage without following procurement regulations. \uf0b7 Government signed an agreement with Mango Tree (U) Ltd for the rehabilitation and upgrade of the Pamba ferry. However, the vessel was still grounded after a year of signing the agreement. \uf0b7 An officer of URC irregularly signed to transfer land measuring 4.452 hectares in Lira (under FRV 220 Folio 13). The land was subdivided into plots 41-63, 52-62, 42-50 and the titles were being processed. \uf0b7 Jinja Municipal took part of URC land in Jinja (6.3 acres) and gave it out to 58 developers, without consultation with the Corporation.", null, null], ["8", "Busega-Mpigi Road Project (Uganda National Roads Authority) 2020 Opinion Unqualified", "\uf0b7 I observed slow progress in Construction works and accumulation of loan charges. As of June 30th 2020, the contractor had only achieved physical progress of 0.13% against 12.77% planned cumulative progress. The total time lapse since commencement of the construction works was 7 months constituting 24.26% of the total contract duration yet only 0.13% construction work had been achieved. Slow progress in Construction works has led to continued accumulation of both Commitment and"], [null, null, "Service Charges that amounted to UGX 2,921,803,802 and UGX"], [null, null, "5,802,593,707 respectively as at the reporting date."], [null, null, "\uf0b7 UNRA reallocated GOU counterpart funding to other projects for the year"], [null, null, "ended 30th June, 2020. A total of UGX 320,077,550 was reallocated from"], [null, null, "the project to other projects. The reallocations delay project progress."], ["9 Busega-Mpigi Road Project (Uganda National Roads Authority). 2021 Opinion Unqualified \uf0b7 I observed slow progress in Construction works and accumulation of loan charges. As of June 30th 2021, the contractor had only achieved 3.42% against 29.18% planned cumulative progress. The total time lapse since commencement of the construction works was 19 months constituting 64.01% of the total contract duration yet only 3.42% construction work had been achieved. Slow progress in Construction works has led to continued accumulation of both Commitment and Service Charges that amounted to UGX 3,224,867,623 and UGX 7,140,345,245 respectively as at the reporting date. \uf0b7 I observed failure to procure Prefabricated Pipe Culvert Units to the project which is delaying project progress. The contractor could not progress through pipe culvert installation due to lack the culverts. \uf0b7 There were delays in payments to the contractor that are likely to lead to interest charges. I observed that on 2nd June 2021, the contractor issued IPC No. 3 amounting to UGX 8,303,000,336 which was unpaid by 30th June, 2021 and interest on the late payment was due to commence on 28th July 2021. \uf0b7 I observed delayed possession of site and land take over by the contractor. By 30th June, 2021, land acquisition was at 54.8% or 14.605 km of the main expressway where access to and possession was granted. It is to be noted that 100% access to and possession should have been formally handed over after 18 months (that is; 22nd May 2021) from commencement. \uf0b7 UNRA reallocated GOU counterpart funding to other projects for the year ended 30th June, 2020. A total of UGX 1,956,237,995 was reallocated", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 220, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": "208", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 220, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["from the project to other projects. The reallocations delay project progress.", null, null], ["10", "Kapchorwa-Suam Road Project (Uganda National Roads Authority) 2021 Opinion Unqualified", "\uf0b7 I observed delayed access and possession of site by the contractor. The last section of the road (from km 48+000 to km 073+000) was granted to the contractor on the 14th of June 2021 which is after 888 days. Further, additional land acquisition is still under progress from Km33+000 to Km73+000. Civil works from Km 46 to Km 58 have been put on hold pending additional land take especially for slope protection. It was also noted that new structures were being erected in the road reserve at"], [null, null, "Km17+692 and KM5+430."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 221, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": [["from the project to other projects. The reallocations delay project progress.", null, null], ["10", "Kapchorwa-Suam Road Project (Uganda National Roads Authority) 2021 Opinion Unqualified", "\uf0b7 I observed delayed access and possession of site by the contractor. The last section of the road (from km 48+000 to km 073+000) was granted to the contractor on the 14th of June 2021 which is after 888 days. Further, additional land acquisition is still under progress from Km33+000 to Km73+000. Civil works from Km 46 to Km 58 have been put on hold pending additional land take especially for slope protection. It was also noted that new structures were being erected in the road reserve at"], [null, null, "Km17+692 and KM5+430."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 221, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": [["from the project to other projects. The reallocations delay project progress.", null, null], ["10", "Kapchorwa-Suam Road Project (Uganda National Roads Authority) 2021 Opinion Unqualified", "\uf0b7 I observed delayed access and possession of site by the contractor. The last section of the road (from km 48+000 to km 073+000) was granted to the contractor on the 14th of June 2021 which is after 888 days. Further, additional land acquisition is still under progress from Km33+000 to Km73+000. Civil works from Km 46 to Km 58 have been put on hold pending additional land take especially for slope protection. It was also noted that new structures were being erected in the road reserve at"], [null, null, "Km17+692 and KM5+430."], [null, null, "\uf0b7 I observed delays in execution of Project civil works. UNRA engaged M/S"], [null, null, "China State Construction Engineering Corporation Ltd on the 7th May"], [null, null, "2018 to upgrade Kapchorwa-Suam road for a period of 36 months, with"], [null, null, "effect from 1st October 2018. There was an extension of time of 4.5"], [null, null, "months up to 15th February 2022. Based on the extension of time, the"], [null, null, "time lapse as at 30th June 2021 was 33 months that is 81.40 %."], [null, null, "However the reported cumulative physical progress for civil works was"], [null, null, "43.14% with no active works from Km 55 to km 73."], ["11 Road Sector Support Project 4 \u2013 Kigumba-Masindi- Hoima-Kabwoya Road (2021) (Uganda National Roads Authority). 2021 Opinion Unqualified \uf0b7 I observed delayed completion of civil works on Upgrading of Bulima \u2013 Kabwoya Road (Lot2).The project commencement date was 1st December 2015, and the initial completion date was after 30 months on 31st May 2018. Successive revisions of completion dates extended the construction period by a further 22 months with the last revised completion date being 27th March 2021. A certificate of substantial completion was issued in January 2021, and the contractor allowed 12 months as the Defects Liability Period, expiring on 27th January 2022. The snag list included two main items; the construction of Hoima Town Roads and a way bridge. \uf0b7 I observed delayed completion of civil works on Upgrading of Kigumba \u2013 Bulima Road (Lot1). The construction period was for 30 months (after commencement in March 2018), elapsing on 31st August 2020. When the Audit Team visited the site in September 2021, (42 months after commencement), the attained level of completion was approximately 95%. However, the new proposed completion date of 31st August had passed and no new completion date had been communicated. \uf0b7 There were delays in payment of lot1 supervision fees. By the time of my audit, the Lot 1 Supervising Engineer\u2019s unpaid invoices had accumulated to Euros 661,605 for the foreign component of the contract and UGX 1.38bn for the local component. The delays are likely to impact on the Engineer\u2019s ability to perform the contractual obligations and in turn impact on the progress of the construction works.", null, null], ["12", "Albertine Regional Sustainable Development Project (ARSDP) (Uganda National Roads Authority). 2021 Opinion Unqualified", "\uf0b7 I observed delayed implementation of civil works (Upgrading of Kyenjojo- Kabwoya Raod \u2013 100km). The duration of the contract was 36 months (from 5th April 2016 to 4tth April 2019) excluding the Defects Liability Period. There were two extensions of time; the first one for 818 days i.e from 4th April 2019 up to 30th June 2021 and the second one for four months from 1st July 2021 to 31st October 2021. The right of way for the last section, Km 0 to Km 30 was handed over to the contractor on the 14th September 2018. However, as per the monthly report No. 63 for the"], [null, null, "month of June 2021, the progress of works was reported as 94.83%"], [null, null, "against planned of 96.27%. In addition to this, the contractor was"], [null, null, "supposed to substantially complete and hand over 30% of works within"], [null, null, "180 days of the commencement date. However, as at 30th June 2021"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 221, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": "209", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 221, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "(1,912 days) no section of the road was handed over and UNRA."], [null, "\uf0b7 There were significant defects on the road works. I observed failure of"], [null, "road shoulders, lined drain and a speed hump at KM88+678. It was also"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 222, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": [["", "(1,912 days) no section of the road was handed over and UNRA."], [null, "\uf0b7 There were significant defects on the road works. I observed failure of"], [null, "road shoulders, lined drain and a speed hump at KM88+678. It was also"], [null, "observed that the contractor continued to construct line drains on steep"], [null, "slopes without scour checks."], [null, "\uf0b7 I also observed poor quality works on some sections of the road"], [null, "construction. For example: poor visibility on the right-hand side of river"], [null, "Nguse bridge and also inadequate protection between the end of stone"], [null, "pitching and the stream at the bridge; noticeable bleeding at Km 52+511,"], [null, "failed line drain at Km71+200 RHS and damaged guard rail at km72+921"], [null, "RHS; maintenance of the completed sections was poor with overgrown"], [null, "grass and silted drainages especially from Km 51 to Km 100, and;"], [null, "pedestrian walkways were not provided for in the design of Kagadi town"], [null, "roads which were under construction at time of the audit."], [null, "\uf0b7 I noted lack of adherence to the insurance contract. The ICEA Workman\u2019s"], [null, "Compensation Policy No 110-A2506044-18 covering the period 18th"], [null, "January 2021 to 17th February 2022 indicated that the number of staff"], [null, "insured are 181 only with neither the names nor the number of staff"], [null, "under each category/designation indicated but the monthly progress"], [null, "reports, the PAYE and NSSF returns for the period under review indicated"], [null, "that the contractor has over 400 staff. Further, the contract required that"], [null, "the insurances are in the joint names of the parties that is; UNRA and the"], [null, "contractor. However, the UAP Old Mutual contractor\u2019s All Risk Policy No"], [null, "0000461578 and the ICEA Motor Commercial Policy No. 080-A2-105193-"], [null, "17 indicate that the insured was only the contractor."], [null, "\uf0b7 Work Permits for all the foreign consultant\u2019s and contractor\u2019s staff were"], [null, "not provided for review. In the absence of the work permits for the"], [null, "foreign staff, the implication is that the expatriate staff are working"], [null, "irregularly in Uganda irregularly and this may lead to deportation, which"], [null, "will in turn affect the progress of work."], ["13 Road Sector Support Project 5 (Upgrading of Rukungiri- Kihihi-Ishasha/Kanungu and Bumbobi-Lwakhakha Roads (Uganda National Roads Authority). 2020. Opinion Unqualified \uf0b7 I observed significant delays in Project implementation. During the FY 2019/20, Project disbursements from ADF amounted to UA 6,679,508.53. From the signed loan amount of UA 70,000,000, only UA 24,672,103.72 representing 35% of the signed loan amount had been cumulatively disbursed through direct payments for Project expenditures as at 30th June 2020. However, 91% of the original project implementation time had elapsed as at 30th June 2020. Civil works for the upgrade of Bumbobi-Lwakhakha 44.5km road had attained 84% physical progress as at 30th June 2020 versus time progress and planned physical progress of 91%. The financial progress stood at 83% against plan of 92% as at 30th June 2020. For the upgrade of Rukungiri-Kihihi-Ishasha/Kanungu (78.5km), 19.24% cumulative physical progress had been achieved as at 30th June 2020 although 33.4% was planned to be completed. \uf0b7 During the FY 2019/20, UGX 3,033,479,790 (28%) of GOU counterpart project funds were re-allocated to other Projects. Re-allocation of Project funds to other projects invalidates the approved plan for implementation of RSSP-V activities. \uf0b7 UGX 267,083,716 was paid as interest on delayed payments. Such costs are un-necessary and represent unbudgeted expenditures which affect funds ear-marked for implementation of planned Project activities. \uf0b7 UGX 226,500,820 had been paid to Government agencies (votes) including sub-counties and town councils during the FY 2019/20. These payments constitute revenue received for purpose of Government and", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 222, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": "210", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 222, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["should have been paid directly to the Uganda Consolidated Fund. \uf0b7 Financing charges were accumulating due to low utilization of the loan funds. Total charges of UGX 3,912,848,969 accrued on the disbursed and undisbursed loan balances during the FY 2019/2020. This is comprised of UGX 3,079,241,588 (79%) being charges on the undisbursed loan balances during the year and UGX 833,607,381 (21%) being charges on the disbursed loan amounts.", null, null], ["14", "Road Sector Support Project 5 (Upgrading of Rukungiri- Kihihi-Ishasha/Kanungu and Bumbobi-Lwakhakha Roads (Uganda National Roads Authority). 2021 Opinion Unqualified", "\uf0b7 I observed significant delays in Project implementation. During the FY 2020/21, Project disbursements from ADF amounted to UA 10,235,407.97 resulting into cumulative disbursements of UA 34,907,511.69 (representing 49.9% of the signed amount of UA 70,000,000). Whereas the upgrading of Bumbobi-Lwakhakha (Lot2) 44.5km road had been substantially completed and the road was handed over to UNRA by the Contractor on 21st December 2020, the upgrading of Rukungiri-Kihihi- Ishasha/Kanungu (Lot1) 78.5km stretch had attained cumulative physical progress of only 42.6% completion rate against planned progress of 55.1% as at 30th June 2021. As at 30th June 2021, only 18 months"], [null, null, "(19.6%) time were left to the end of the extended Project"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 223, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": [["should have been paid directly to the Uganda Consolidated Fund. \uf0b7 Financing charges were accumulating due to low utilization of the loan funds. Total charges of UGX 3,912,848,969 accrued on the disbursed and undisbursed loan balances during the FY 2019/2020. This is comprised of UGX 3,079,241,588 (79%) being charges on the undisbursed loan balances during the year and UGX 833,607,381 (21%) being charges on the disbursed loan amounts.", null, null], ["14", "Road Sector Support Project 5 (Upgrading of Rukungiri- Kihihi-Ishasha/Kanungu and Bumbobi-Lwakhakha Roads (Uganda National Roads Authority). 2021 Opinion Unqualified", "\uf0b7 I observed significant delays in Project implementation. During the FY 2020/21, Project disbursements from ADF amounted to UA 10,235,407.97 resulting into cumulative disbursements of UA 34,907,511.69 (representing 49.9% of the signed amount of UA 70,000,000). Whereas the upgrading of Bumbobi-Lwakhakha (Lot2) 44.5km road had been substantially completed and the road was handed over to UNRA by the Contractor on 21st December 2020, the upgrading of Rukungiri-Kihihi- Ishasha/Kanungu (Lot1) 78.5km stretch had attained cumulative physical progress of only 42.6% completion rate against planned progress of 55.1% as at 30th June 2021. As at 30th June 2021, only 18 months"], [null, null, "(19.6%) time were left to the end of the extended Project"], [null, null, "implementation time of 31st December 2022. It is unlikely that UNRA will"], [null, null, "complete the 57.4% works outstanding (planned) for the upgrade of"], [null, null, "Rukungiri-Kihihi-Ishasha/Kanungu road in the agreed timelines."], [null, null, "\uf0b7 During the FY 2019/20, UGX 3,822,002,388 (36%) of GOU counterpart"], [null, null, "project funds were re-allocated to other Projects. Re-allocation of Project"], [null, null, "funds to other projects invalidates the approved plan for implementation"], [null, null, "of RSSP-V activities."], [null, null, "\uf0b7 UGX 150,255,638 was paid as interest on delayed payments. Such costs"], [null, null, "are un-necessary and represent unbudgeted expenditures which affect"], [null, null, "funds ear-marked for implementation of planned Project activities."], [null, null, "\uf0b7 Financing charges were accumulating due to low utilization of the loan"], [null, null, "funds. UGX 3,770,851,261 was accrued on the disbursed and undisbursed"], [null, null, "loan balances with ADF during the FY 2020/2021. This is comprised of"], [null, null, "UGX 2,620,478,974 (69%) being charges on the undisbursed loan"], [null, null, "balances during the year and UGX 1,150,372,287 (31%) being charges"], [null, null, "on the disbursed loan amounts. For the last two financial years (FY"], [null, null, "2019/20 and 2020/21), total charges of UGX 7,683,700,230 had accrued"], [null, null, "on the loan balances with ADF. This is comprised of UGX 5,699,720,562"], [null, null, "(74%) being charges on the undisbursed loan balances and UGX"], [null, null, "1,983,979,668 (26%) being charges on the disbursed loan balances."], ["15 Upgrading of Tirinyi-Pallisa- Kumi and Pallisa-Kamonkoli Road project (Uganda National Roads Authority). 2020 \uf0b7 The Authority was made to pay interest as a result of delay to pay the contractor\u2019s approved interim payment certificates (IPCs). The contractor invoked clause 14.7 and 14.8 of GCC and charged interest of UGX 373,044,074.47 for IPCs 1-6. Another interest amount of UGX 166,845,192 was paid for IPCs 11,12,13,14. The total interest paid for the delayed settlement of the IPCs amounted to UGX 539,889,266. These interest payments could have been higher if the dollar amounts had not been negotiated downwards by USD 108,262.29 due to disagreements in computations. \uf0b7 During the FY 2019/20, UGX 892,920,000 of Project funds were re- allocated to other Projects. Re-allocation of Project funds to other projects overrides established budgeting procedures. \uf0b7 There were delays in recruitment of the Project consultant. In the period 15th March 2018 to 26th April 2021, there was no Project consultant procured to carry out supervisory roles for upgrading the Tirinyi-Kumi-", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 223, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": "211", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 223, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Pallisa-Kamonkoli Road Project. In this period, the Directorate of Roads and Bridges Development of UNRA stepped in to carry out design review and supervisory roles in addition to their other activities. Recruitment of the Consultant, AECO (Abuljebain Engineering Consulting Office) delayed until 15th March 2021 and they commenced work on 26th April 2021 four months when the project physical progress was already at 92.51% and in time progress was 37.3 months (103.6%) to completion. The Consultant\u2019s first report was in the month of May 2021. \uf0b7 I observed delays in payment of Project Affected Persons. As of 30th June 2021 payment of PAPs was still incomplete with a total of 156 PAPs not yet paid. Tirinyi Pallisa Kumi (Lot 1) had 100 PAPs for land measuring 80.06 acres while Pallisa Kamonkoli road (Lot 2) had 56 PAPs not paid for 27.318 acres of land (by May 2021)", null, null], ["16", "Upgrading of Tirinyi-Pallisa- Kumi and Pallisa-Kamonkoli Road project (Uganda National Roads Authority).", "\uf0b7 There were overpayments to the contractor in interim payment certificates numbers 25 and 26 amounting to UGX 8,613,048,720 (USD 2,556,164.89). These payments were meant for supervisors who had not been recruited."], [null, "2021", null], ["17 North Eastern Road- Corridor Asset Management Project (Uganda National Roads Authority) 2020/21 \uf0b7 The Project did not have an annual work plan and budget prepared for implementation of its activities. Also, quantification of Project outputs was not done for the financial year audited. \uf0b7 I observed delays in Project implementation. From the signed loan", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 224, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "212", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 224, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", null, null], ["18", "Masaka-Bukakata Road project (2021) (Uganda National Roads Authority)", "\uf0b7 Project funds to the tune of UGX 262,339,751 were reallocated from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals."], [null, "2020/21", null], ["LANDS SECTOR", null, null], ["1", "National Physical Planning Board 2020/21", "\uf0b7 Out of the budgeted revenue of UGX.6.0 Bn, UGX.5.29 Bn was realised, resulting in a shortfall of UGX 0.710 Bn, which is 12% of the budget, Out of the total receipts for the financial year of UGX 5.29, Bn, UGX 2.945 Bn was spent representing an absorption level of 56%."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 225, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "213", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 225, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "were not quantified at all."], [null, null, "\uf0b7 One (01) output with one (01) activity and expenditure worth UGX 0.452"], [null, null, "Bn was fully implemented., two (2) outputs with two (02) activities worth"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 226, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "were not quantified at all."], [null, null, "\uf0b7 One (01) output with one (01) activity and expenditure worth UGX 0.452"], [null, null, "Bn was fully implemented., two (2) outputs with two (02) activities worth"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 226, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "were not quantified at all."], [null, null, "\uf0b7 One (01) output with one (01) activity and expenditure worth UGX 0.452"], [null, null, "Bn was fully implemented., two (2) outputs with two (02) activities worth"], [null, null, "UGX.0.308 Bn were not implemented."], [null, null, "\uf0b7 I noted that out of the approved staff structure of thirty five (35)"], [null, null, "positions, no position was substantively filled. The Board had only three"], [null, null, "(3) staff on secondment and twenty six (26) on assignment of duties."], [null, null, "\uf0b7"], ["2 Ministry of Lands, Housing and Urban Development 2020/21 Opinion Unqualified \uf0b7 Out of the budgeted NTR of UGX.5.500Bn for the financial year 2019/2020 only UGX.5.480Bn was realized, representing a performance of 99.6 % above the target. \uf0b7 The Ministry budgeted for UGX.74.32Bn in Government receipts, out of which UGX.71.13Bn was warranted, resulting in a shortfall of UGX.3.19Bn which is 4.29% of the budget. \uf0b7 Out of the total receipts of UGX.71.12Bn, UGX.69.13Bn was spent resulting into an unspent balance of UGX.1.99Bn representing an absorption level of 97.2%. The balance unspent was subsequently swept back to the consolidated fund at the end of the financial year. \uf0b7 I sampled 34 outputs with a total of 175 activities and expenditure of UGX 57.908Bn and noted that 15 outputs with a total of 67 activities and expenditure of UGX.12.45Bn were fully quantified. Fifteen (15) outputs with a total of 92 activities and expenditure worth UGX.42.35Bn were insufficiently quantified. Four (4) outputs with a total of 16 activities and expenditure worth UGX.3.11Bn were not quantified. \uf0b7 I assessed the implementation of 15 fully quantified outputs with a sample of 67 activities worth UGX.12.45Bn and noted that three (3) outputs with a total of three (3) activities worth UGX.0.456 Bn were fully implemented. Twelve (12) outputs with a total of sixty-four (64) activities worth UGX.11.99Bn were partially implemented. \uf0b7 I noted that the Ministry\u2019s Payables amount increased by UGX.105,145,022,390 from UGX.144,329,975,873 in the previous year to UGX.249,474,998,263 in the current year. In addition, UGX.11,593,918,200 of the new compensations related to private persons that had been included among the ranchers to be compensated, but lacked ranch title number, area of land lost and other details recorded in the domestic arrears schedule. \uf0b7 I noted a recognized NTR amount of UGX.1.7billion relating to proceeds from the sale of government pool housed had no proper documentation. \uf0b7 I noted that Parliament approved a payment of UGX.3,802,500,000, as compensation for Ndeeba Land but the payment was halted by an interim court order. \uf0b7 I noted that the Ministry compensated the claimant of land at Block 237 plots 29,48,56,59 and 67 at Mutungo for a sum of UGX.26.4 Bn which had earlier been purchased by Uganda Land Commission which partly paid UGX 2.4Bn. The two entities have not agreed on the ownership of the land.", null, null], ["3", "Uganda Support to Municipal Infrastructure Development, Additional Financing (USMID-AF/II)", "\uf0b7 To-date, the program has made available USD 140,331,745 (UGX.514,740,787,823), out of which only USD.44,938,686 (UGX.477,249,316,165) had been made available to the LGs, leading to a"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 226, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "214", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 226, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Project. 2020/21", "funds availability to LG level of 32%. \uf0b7 Out of the budgeted disbursements/receipts of UGX.454,866,200,300 in the financial year, only UGX.301,529,104,089 (66.3%) was available to the project, leading to a shortfall of UGX. 153,337,096,211(33.7%)."], [null, "Opinion Unqualified", null], ["4 Albertine Region Sustainable Development Project (ARSDP) \u2013 MoLHUD 2020/21 Opinion Unqualified \uf0b7 Out of the budgeted IDA disbursement of UGX.19,514,012,776 for the year 2020/2021, only UGX.10,094,659,078 (52%) was realized leading to a shortfall of UGX.9,419,353,698 (48%). Revenue shortfall limits the implementation of planned activities which could affect the achievement of the project objectives. \uf0b7 Review of the Q4 Progress report revealed that many sub-projects worth USD 27.5million handed over to the Ministry of Lands, Housing and Urban Development for construction, will not be implemented due to lack of funding, yet, costs have already been incurred since all the sub- projects have been designed and Environment and Social Impact Assessment done. \uf0b7 The civil works for construction of three markets, namely: Biiso Market in Buliisa District, Kabaale Market in Hoima District and Buhuka Market in Kikuube District costed at UGX.9,963,228,048 were not complete despite the extension of the completion date to 31st August 2021, thus delaying service delivery to citizens.", null, null], ["5", "Competitiveness and Enterprise Development Project (CEDP) Component", "\uf0b7 It was noted that out of the UGX.12.73Bn budget allocated for the project activities during the fiscal year 2020/2021, UGX.11.86 Bn (93%) was spent, leaving a balance of UGX.0.87Bn."], [null, "1- Land Administration (IDA CREDIT AGREEMENT CR 52690-UG) PROJECT ID P130471. 2020/21 Opinion", null], [null, "Unqualified", null], [null, "", null], ["6 Uganda Land Commission. 2020/21 Opinion Qualified \uf0b7 Out of the approved budget of UGX. 71,868,574,709, only UGX. 65,793,286,529was warranted/released resulting into a budget shortfall of UGX.6,075,288,180 representing 91.5%. \uf0b7 Out of the total warrants of UGX.65.79Bn received during the financial year. UGX.64.94Bn was spent by the entity resulting in an unspent balance of UGX.0.85Bn representing an absorption level of 98.71%. \uf0b7 Out of the twenty-one (21) outputs with a total of sixty-one (61) activities and expenditure of UGX.64.86Bn sampled, Two (2) outputs with a total of Six (6) activities and expenditure worth UGX.0.71Bn were fully quantified, Eight (8) outputs with a total of thirty (30) activities and expenditure worth UGX.32.35Bn, was insufficiently quantified. Eleven (11) outputs with a total of twenty-five (25) activities and expenditure worth UGX", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 227, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "215", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 227, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["31.8Bn were not quantified at all. \uf0b7 Out of the two (2) fully quantified outputs, Two (2) outputs with six (6) activities worth UGX.0.71Bn were partially implemented. Out of the six (6) activities, the entity fully implemented one (1) activity; Four (4) activities were partially implemented, while one (1) activity remained unimplemented. \uf0b7 The balances for; payables of UGX 169,490,014,824 , Non-produced assets of UGX 212,279,181,177, and that of revenue receivables of UGX 24,760,000 as at 30th June, 2021, Could not be confirmed due to absence of adequate supporting documentation and reliable data by the commission. \uf0b7 A sum of UGX.1,237,717,474 was paid for outstanding arrears that related to the prior year, but were not recognized in the prior year financial statements as payables. In addition, withholding tax of UGX.22,020,000 was not deducted and paid to URA. \uf0b7 I noted that the court garnished the Commission\u2019s bank Account with a balance of UGX.244,184,480 leading to the delay to clear the outstanding obligations to third parties. \uf0b7 It was noted that the entity obtained a supplementary of UGX 10.62Bn was received by the entity but was not requisitioned by management. There were unsupported payments of domestic arrears amounting to UGX 14.4 Bn. Payments worth UGX 6.7Bn were paid to unverified arrears. \uf0b7 In addition, payables to Church of Uganda amounting to UGX 15Bn, and Receivables amounting to UGX 3.966 Bn relating to the overpayment to Kampala archdiocese in the prior year were not recognised. In addition, outstanding arrears of UGX 1.2Bn related to prior year but paid during the year have not been recognised in the current year. \uf0b7 The Commission does not have a land inventory and database for all government land and properties under its jurisdiction that are either occupied by tenants, vacant, acquired under compensation (but not yet re-distributed to the bona fide occupants), or acquired and owned by other government institutions and missions abroad. As such tracking of lease payments and revenue arrears related to ground rent and premium could not be supported.", null, null], ["", "ACCOUNTABILITY SECTOR", "\uf0b7"], ["1\\. Uganda Communication Employees Contributory Pension Scheme. 2019/20 Opinion Qualified \uf0b7 Reported in the Statement of Net Assets Available for Benefits are payables and accruals of UGX.2,679,752,000, of which UGX.2,022,412,000 and UGX.442,330,000 are administrative and actuarial fees respectively. However, these were not adequately supported to confirm existence. \uf0b7 Eleven (11) properties disclosed as part of the non-core assets were still not valued and therefore not included in the value of Non-current assets of the Scheme. \uf0b7 A review and comparison made between the audited financial statements for the period ending 30th June, 2019 and the financial statements for the period ending 30th June, 2020 revealed inconsistencies in the account balances of reserves. \uf0b7 Receivables were not supported with any documentation and schedule to confirm the amounts and authenticity. \uf0b7 The reported cash and cash equivalents is misstated.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 228, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["31.8Bn were not quantified at all. \uf0b7 Out of the two (2) fully quantified outputs, Two (2) outputs with six (6) activities worth UGX.0.71Bn were partially implemented. Out of the six (6) activities, the entity fully implemented one (1) activity; Four (4) activities were partially implemented, while one (1) activity remained unimplemented. \uf0b7 The balances for; payables of UGX 169,490,014,824 , Non-produced assets of UGX 212,279,181,177, and that of revenue receivables of UGX 24,760,000 as at 30th June, 2021, Could not be confirmed due to absence of adequate supporting documentation and reliable data by the commission. \uf0b7 A sum of UGX.1,237,717,474 was paid for outstanding arrears that related to the prior year, but were not recognized in the prior year financial statements as payables. In addition, withholding tax of UGX.22,020,000 was not deducted and paid to URA. \uf0b7 I noted that the court garnished the Commission\u2019s bank Account with a balance of UGX.244,184,480 leading to the delay to clear the outstanding obligations to third parties. \uf0b7 It was noted that the entity obtained a supplementary of UGX 10.62Bn was received by the entity but was not requisitioned by management. There were unsupported payments of domestic arrears amounting to UGX 14.4 Bn. Payments worth UGX 6.7Bn were paid to unverified arrears. \uf0b7 In addition, payables to Church of Uganda amounting to UGX 15Bn, and Receivables amounting to UGX 3.966 Bn relating to the overpayment to Kampala archdiocese in the prior year were not recognised. In addition, outstanding arrears of UGX 1.2Bn related to prior year but paid during the year have not been recognised in the current year. \uf0b7 The Commission does not have a land inventory and database for all government land and properties under its jurisdiction that are either occupied by tenants, vacant, acquired under compensation (but not yet re-distributed to the bona fide occupants), or acquired and owned by other government institutions and missions abroad. As such tracking of lease payments and revenue arrears related to ground rent and premium could not be supported.", null, null], ["", "ACCOUNTABILITY SECTOR", "\uf0b7"], ["1\\. Uganda Communication Employees Contributory Pension Scheme. 2019/20 Opinion Qualified \uf0b7 Reported in the Statement of Net Assets Available for Benefits are payables and accruals of UGX.2,679,752,000, of which UGX.2,022,412,000 and UGX.442,330,000 are administrative and actuarial fees respectively. However, these were not adequately supported to confirm existence. \uf0b7 Eleven (11) properties disclosed as part of the non-core assets were still not valued and therefore not included in the value of Non-current assets of the Scheme. \uf0b7 A review and comparison made between the audited financial statements for the period ending 30th June, 2019 and the financial statements for the period ending 30th June, 2020 revealed inconsistencies in the account balances of reserves. \uf0b7 Receivables were not supported with any documentation and schedule to confirm the amounts and authenticity. \uf0b7 The reported cash and cash equivalents is misstated.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 228, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "216", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 228, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 The Scheme recognized a retrenchment penalty worth UGX.11,320,160,000 as a receivable from UTL yet this amount had been written off. \uf0b7 I noted that out of the budgeted revenue of UGX.12,447,003,444 for the year 2019/2020, only UGX.2,264,969,444 was realised representing a performance of only 18.2% of the target. \uf0b7 I established that funds totaling to UGX.88,575,000 were never budgeted for, and no authority was sought from the Founder to use the current year\u2019s appropriated funds to meet this expenditure. \uf0b7 Diversion of members\u2019 contribution (DC) to pay defined benefits (DB) liabilities: UGX.4,550,343,000. \uf0b7 I noted that, whereas PAYE to a tune of UGX.35,427,298 was withheld from employees as required during the year, it was not remitted to URA in the timelines prescribed by the Income Tax Act.", null, null], ["2", "Uganda Bureau of Statistics (UBOS). 2020/21", "\uf0b7 I noted a number of issues in the implementation of the approved budget such: under absorption of funds; partial or non-implementation of activities, non-quantification of activities, under performance of the NTR and government releases. \uf0b7 There was delayed Implementation of a number of Projects such as:"], [null, "Opinion Unqualified", null], ["3 URA Corporate 2020/21 Opinion Unqualified \uf0b7 URA operated at least six operations bank accounts in commercial banks with an annual turnover of over UGX.1.1 Tn, in contravention of Section 33 (5), (6) and (7) of the Public Finance Management Act 2015. The action overrides the Government financial management controls and distorts the monetary policy. \uf0b7 UGX.9.6Bn was advanced to staff through their bank accounts to purchase goods, services, and other activities without following regulations. The practice is irregular and also exposes Government funds to a risk loss through misuse. \uf0b7 UGX.1.16Bn paid through mobile money to various suppliers for the provision of services were not adequately supported with accountability documents as required; as a result, I could not ascertain whether the funds were utilised correctly for the intended activities. \uf0b7 Management made cash withdrawals amounting to UGX.5.2Bn during the year, contrary to Section 11 of PFMA 2015, as well as Section 7 of the URA Cash Policy that sets the maximum insurable cash limit to UGX.20Mn. The practice has been recurring and exposes government funds to a risk of misuse of cash and loss.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 229, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "217", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 229, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 The Authority awarded multi-year contracts to the tune of UGX.18.7Bn without evidence of approval of these multi-year commitments by the Parliament. This was contrary to Section 23(1) of the PFMA 2015. \uf0b7 Planned procurements worth UGX.25.1Bn were not implemented by 30th June 2021. This adversely affects the realisation of critical government programs. Management explained that the delays were due to various reasons, some of which are beyond their control. \uf0b7 During the financial year 2020/21, the collaborating institutions under the Tax Registration and Expansion Programme (TREP) registered only 167,211 taxpayers against a target of 436,869 taxpayers representing a 38.27% registration success and a shortfall of 61.7%. In revenue terms, although TREP had a revenue target of UGX.124.58 Bn in FY 2020/21, it had only collected UGX.49.93Bn by 30th June 2021, representing a 40% performance rate. The paltry performance was attributed to COVID-19 effects, riots and the political environment, that hindered field activities. \uf0b7 The Ministry of Local Government had planned to implement activities worth UGX.4.4Bn under TREP activities but only implemented activities worth UGX.3.3Bn, leaving un-implemented activities worth UGX.1.1Bn despite receiving all funding. As a result, the e-LogRev objective of simplifying and strengthening the local revenue collection systems for Local Governments may not be achieved in time.", null, null], ["4", "URA Revenue Collection Account 2020/21", "\uf0b7 The Authority had a total revenue collection target of UGX.22.039Tn for the financial year 2020/21, and collected total gross revenue of UGX.19.649Tn, representing 89% hence a shortfall of UGX.2.39Tn"], [null, null, "(11%). Under collection of revenue affects cash flow performance of"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 230, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["\uf0b7 The Authority awarded multi-year contracts to the tune of UGX.18.7Bn without evidence of approval of these multi-year commitments by the Parliament. This was contrary to Section 23(1) of the PFMA 2015. \uf0b7 Planned procurements worth UGX.25.1Bn were not implemented by 30th June 2021. This adversely affects the realisation of critical government programs. Management explained that the delays were due to various reasons, some of which are beyond their control. \uf0b7 During the financial year 2020/21, the collaborating institutions under the Tax Registration and Expansion Programme (TREP) registered only 167,211 taxpayers against a target of 436,869 taxpayers representing a 38.27% registration success and a shortfall of 61.7%. In revenue terms, although TREP had a revenue target of UGX.124.58 Bn in FY 2020/21, it had only collected UGX.49.93Bn by 30th June 2021, representing a 40% performance rate. The paltry performance was attributed to COVID-19 effects, riots and the political environment, that hindered field activities. \uf0b7 The Ministry of Local Government had planned to implement activities worth UGX.4.4Bn under TREP activities but only implemented activities worth UGX.3.3Bn, leaving un-implemented activities worth UGX.1.1Bn despite receiving all funding. As a result, the e-LogRev objective of simplifying and strengthening the local revenue collection systems for Local Governments may not be achieved in time.", null, null], ["4", "URA Revenue Collection Account 2020/21", "\uf0b7 The Authority had a total revenue collection target of UGX.22.039Tn for the financial year 2020/21, and collected total gross revenue of UGX.19.649Tn, representing 89% hence a shortfall of UGX.2.39Tn"], [null, null, "(11%). Under collection of revenue affects cash flow performance of"], [null, "Opinion Unqualified", "Government and realisation of the planned service delivery targets. Management attributed the performance to the adverse impact of COVID-"], [null, null, "19 pandemic."], [null, null, "\uf0b7 I reviewed the statement of comparison of target and actual revenue"], [null, null, "collection by the tax head and noted that revenues from different sources"], [null, null, "worth UGX.86.979Bn were not budgeted for, despite collecting significant"], [null, null, "incomes on these tax heads for the past two years leading to under-"], [null, null, "budgeting. Lack of budget provisions of the tax heads conceals revenue"], [null, null, "potential, distorts revenue projections and may lead to un-appropriate"], [null, null, "performance assessments and related bonuses."], [null, null, "\uf0b7 Uganda Tax/GDP ratio remained low at 12.5% in 2020/21, compared to"], [null, null, "other countries in the region and globally. This performance was similar"], [null, null, "to last year's performance. This implies that tax bases have not widened"], [null, null, "or deepened enough to tax all potential sources."], [null, null, "\uf0b7 There was an increase in total Tax Arrears from UGX.3.009Tn in 2019/20"], [null, null, "to UGX.4.519Tn in the financial year 2020/21 representing a total"], [null, null, "increase of UGX.1.492Tn or percentage increase in total Tax Arrears of"], [null, null, "50%. The Increase denies Government the required resources to deliver"], [null, null, "more services."], [null, null, "\uf0b7 The contract between the Government of Uganda (GoU) and a private"], [null, null, "company had since expired even though the Company had continued to"], [null, null, "manufacture motor vehicle registration numbers for taxpayers. Expired"], [null, null, "contracts expose the Government to the risk of loss of revenue without a"], [null, null, "remedy."], [null, null, "\uf0b7 I noted that government had continued to engage only two private"], [null, null, "companies, making them monopolies in providing motor vehicle"], [null, null, "registration number plates for more than eight (8) years without opening"], [null, null, "it up for competition. The Monopoly exposes the taxpayer to high prices"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 230, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "218", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 230, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "for the services."], [null, null, "\uf0b7 URA received a sum of UGX.279.509Bn through Bank of Uganda from"], [null, null, "Government Ministries, Departments and Agencies and Local"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 231, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "for the services."], [null, null, "\uf0b7 URA received a sum of UGX.279.509Bn through Bank of Uganda from"], [null, null, "Government Ministries, Departments and Agencies and Local"], [null, null, "Governments. The amount was not reconciled and receipted due to the"], [null, null, "inability to identify the tax head and the lack of IFMS and BoU Systems"], [null, null, "interface with URA systems. Collection of Revenue without receipting and"], [null, null, "charging the correct tax heads results into misstatement of revenue"], [null, null, "collected per tax head."], ["5 Uganda Retirement Benefits Regulatory Authority. 2020/21 Opinion Unqualified \uf0b7 The entity budgeted to receive UGX.12.35Bn in the FY 2021/21. However, only UGX.11.25Bn was available for spending resulting into a shortfall of UGX.1.1Bn, which is 9% of the budget; this affected implementation of planned activities. \uf0b7 Assessment of implementation of planned outputs revealed that Nine (9) outputs with a total of forty (40) activities worth UGX.2.89Bn were partially implemented. Out of the forty (40) activities, the entity implemented twenty-eight (28) activities (70%), while twelve (12) activities (30%) remained unimplemented. In addition, planned procurements totaling UGX.309Mn were also not implemented. \uf0b7 Out of the approved staffing level of 61, the Authority has only 36 positions filled (59%), leaving a staffing gap of 25 positions (41%). Included in the unfilled positions are key positions of Director Finance and Accounting, Director Human Resource and Administration and the Director Research and Strategy. This affects the entity\u2019s capacity to effectively deliver its mandate.", null, null], ["6", "Bank of Uganda 2020", "\uf0b7 Uncertainties brought by Covid-19 could potentially led to delays by Government to refund/repay amounts due to the Bank. \uf0b7 Audit noted that the Government capital account included in the loans, advances and drawdowns to Government increased by UGX 1,087,811"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 The assessment of the possible outcome of the appeal (Crane Bank - Civil"], [null, null, "Appeal No. 252 of 201) and the amount of any resulting potential"], [null, null, "obligations, if any, involves significant judgement by the directors."], [null, null, "\uf0b7 I noted that, as at June 30, 2020, the core capital of the Bank was below"], [null, null, "the minimum required capital by UGX.453,331 million (2019:"], [null, null, "UGX.671,712 million)"], ["7 Housing Finance Bank Limited 2020 Opinion Unqualified \uf0b7 I noted that Management has estimated impairment provisions for loans and advances to customers collectively for homogenous loan portfolios using statistical methods on the basis of risk parameters using historical data taking into account forward looking information on expected macroeconomic conditions including considerations made for possible effects from the COVID-19 pandemic. \uf0b7 As at 31 December 2020, a total of 1184 customers with loans worth UGX. 159.8 billion had applied and been granted loan restructures of different forms. However, as at 31 December 2020, only 331 customers with loans worth UGX. 58.0 billion were still under repayment moratoriums with the rest having reverted to periodic repayments schedules following the initial restructures. \uf0b7 The COVID-19 pandemic containment measures increased economic uncertainty amongst the borrowers, prompting many to prematurely repay their loans during and after the lockdowns. These redemptions", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 231, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "219", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 231, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["involving as many as 901 customers affected the growth rate of the loan book by over UGX. 37.0 billion. \uf0b7 I noted that there was a disruption in the periodic repayments by the Bank\u2019s borrowing customers at the peak of the pandemic containment measures.", null, null], ["8", "Post Bank Uganda Limited. 2020", "\uf0b7 COVID-19 effects and corresponding bank measures impacted PBU loan portfolio in different ways including reduction in cash flows from loan"], [null, null, "repayments as a result of granting moratoriums, increase in customers"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 232, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["involving as many as 901 customers affected the growth rate of the loan book by over UGX. 37.0 billion. \uf0b7 I noted that there was a disruption in the periodic repayments by the Bank\u2019s borrowing customers at the peak of the pandemic containment measures.", null, null], ["8", "Post Bank Uganda Limited. 2020", "\uf0b7 COVID-19 effects and corresponding bank measures impacted PBU loan portfolio in different ways including reduction in cash flows from loan"], [null, null, "repayments as a result of granting moratoriums, increase in customers"], [null, "Opinion Unqualified", "demanding for Interest rate reduction, shrink in credit demand for some sectors and drop in disbursements due to cautious lending coupled with"], [null, null, "increase in default rates for some sectors."], ["9 Contigencies\u2019 Fund. 2020/21 Opinion Unqualified \uf0b7 Section 26(i) of the PFMA 2015 (as amended) provides that a Contingencies Fund shall every financial year be replenished with an amount equivalent to 0.5% of the appropriated annual budget of Government of the previous financial year. The approved budget for the previous financial year (FY2019/20) was UGX.40.49Trillion, which would have translated into UGX.202.43Bn funding for the Contingencies\u2019 Fund in the year under review. I noted however, that Parliament only appropriated UGX.62Bn to the Contingencies fund, causing a deficit of UGX.140.3Bn. Underfunding of the Contingencies Fund distorts implementation of the approved budget for the current year as evidenced by budget cuts and reallocations to fund supplementary budgets relating to natural disasters and emergencies that occurred during the year. \uf0b7 Audit of the withdrawals made off the Contingencies Fund revealed that a total of UGX.62,070,000,000 was transferred to the Fund bank account held at Bank of Uganda. The funds were consequently transferred to entity bank accounts and expensed off the IFMS, which makes it difficult to follow up and track to confirm the adherence to the approved budget guidelines and also confirm accuracy of the reports generated. Spending off the IFMS also exposes the funds to the risk of misuse due to lack of transparency.", null, null], ["10", "Financial Intelligence Authority. 2020/21", "\uf0b7 The Financial Intelligence Authority lacked an approved strategic plan aligned to the NDP III. Under the circumstances, there is a risk that activities implemented during the financial year 2020/2021 were not"], [null, null, "aligned to the NDP-III, which negatively affects the achievement of NDP-"], [null, "Opinion", "III objectives. I advised the Accounting Officer to follow up on the approval of the strategic plan urgently. \uf0b7 A review of the staffing structure for FIA revealed that out of the total"], [null, "Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 232, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "220", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 232, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["11 Insurance Training College (ITC). 2020/21 Opinion Unqualified \uf0b7 Section 63 of the Insurance Act requires the Insurance Training levy to be reconciled with Insurers within 60 days after the end of the calendar year. I however noted that a total of UGX.4.9Bn was collected based on basis of computed returns submitted by the Insurers and Health Member Organisations (HMO\u2019s), with no evidence of reconciliation of Training Levy returns, contrary to requirements under the Act. As a result, the returns may be understated to reduce remittances, which may lead to revenue loss.", null, null], ["12", "National Population Council.", "\uf0b7 Out of the ten (10) sampled outputs that NPC planned to implement"], ["", "Opinion", "during the period under review, five (5) outputs representing 50% of the planned sampled outputs were fully implemented, four (4) Outputs representing 40% were partially implemented, and one (1) Output"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 233, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["11 Insurance Training College (ITC). 2020/21 Opinion Unqualified \uf0b7 Section 63 of the Insurance Act requires the Insurance Training levy to be reconciled with Insurers within 60 days after the end of the calendar year. I however noted that a total of UGX.4.9Bn was collected based on basis of computed returns submitted by the Insurers and Health Member Organisations (HMO\u2019s), with no evidence of reconciliation of Training Levy returns, contrary to requirements under the Act. As a result, the returns may be understated to reduce remittances, which may lead to revenue loss.", null, null], ["12", "National Population Council.", "\uf0b7 Out of the ten (10) sampled outputs that NPC planned to implement"], ["", "Opinion", "during the period under review, five (5) outputs representing 50% of the planned sampled outputs were fully implemented, four (4) Outputs representing 40% were partially implemented, and one (1) Output"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 233, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["11 Insurance Training College (ITC). 2020/21 Opinion Unqualified \uf0b7 Section 63 of the Insurance Act requires the Insurance Training levy to be reconciled with Insurers within 60 days after the end of the calendar year. I however noted that a total of UGX.4.9Bn was collected based on basis of computed returns submitted by the Insurers and Health Member Organisations (HMO\u2019s), with no evidence of reconciliation of Training Levy returns, contrary to requirements under the Act. As a result, the returns may be understated to reduce remittances, which may lead to revenue loss.", null, null], ["12", "National Population Council.", "\uf0b7 Out of the ten (10) sampled outputs that NPC planned to implement"], ["", "Opinion", "during the period under review, five (5) outputs representing 50% of the planned sampled outputs were fully implemented, four (4) Outputs representing 40% were partially implemented, and one (1) Output"], [null, "Unqualified", "representing 10% was not implemented during the period under review."], [null, null, "\uf0b7 Gratuity payments totalling UGX.940Mn were not subjected to PAYE and"], [null, null, "the 5% NSSF employee deductions. I further noted that NPC did not"], [null, null, "provide for the 10% employer contribution for the staff resulting from the"], [null, null, "gratuity payment. This denied URA the much-needed revenue and the"], [null, null, "staff were disadvantaged due to failure to contribute to NSSF."], ["13 Tax Appeals Tribunal. 2020/21 Opinion Unqualified \uf0b7 Arising out of a supreme court decision, all tax disputes in Uganda must first commence in the Tax appeal Tribunal before they move to any other court. A review of the cases filed at the Tribunal, in the last three years, revealed that there was an increase of cases filed from 40 in 2017 to 176 in 2020. In spite of the increase in cases, there has been no increase in the number of members of the Tribunal which has necessitated that the members of the Tribunal sit every day not withstanding their regular involvement in the administrative aspects of the Tribunal. The current structure of the remuneration of the members indicates that each member will be paid a sitting allowance and a retainer. This has resulted into the Tribunal spending the bulk of its money on the payment of allowances to the Tribunal members. \uf0b7 During the reviews, I noted that there were instances in which a Tribunal member is an active partner of a Firm that has a case before the Tribunal. Whereas the said Tribunal Member does not form part of the panel of the committee adjudicating the disputes, this presents a potential conflict of interest for the members of the committee who work with him and have to decide the matters involving his Firm for which he is an active partner. \uf0b7 I noted that the approved organisation structure for the Tribunal, did not have a provision for internal audit function and indeed, this role has not been assigned to any staff. This is contravention with the PFMA 2015, and it also denies the Tribunal an early warning mechanism in cases of errors of omission or commission.", null, null], ["14", "Uganda Microfinance Regulatory Authority (UMRA) 2020/21", "\uf0b7 It was noted that, contrary to Section 17 of the PFMA 2015, the Authority had unspent funds totalling UGX.4.93Mn at the year-end that were never returned to Treasury. It should also be noted that the same was done in the preceding year where UGX.204Mn was never returned. Failure to"], [null, null, "return unspent funds contravenes Section 17 of the Public Finance and"], [null, "Opinion Unqualified", "Management Act 2015, and exposes the funds to a risk of diversion since they are spent in the subsequent financial year without appropriation by"], [null, null, "parliament."], [null, null, "\uf0b7 Section 11.2.4 of the Treasury Instructions 2017, requires the Head of"], [null, null, "Finance to ensure that commitments are not approved unless sufficient"], [null, null, "funds are available in the commitment item. However, in disregard to the"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 233, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "221", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 233, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "above provision, commitments to a tune of UGX.321Mn remained unpaid"], [null, "at the close of the year under review."], [null, "\uf0b7 Comparison of licensees per category (Moneyl enders and non-deposit"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 234, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None"], "type": "table"}}, {"content": [["", "above provision, commitments to a tune of UGX.321Mn remained unpaid"], [null, "at the close of the year under review."], [null, "\uf0b7 Comparison of licensees per category (Moneyl enders and non-deposit"], [null, "taking institutions) between the previous year 2019/2020 and those that"], [null, "renewed their licenses in the year under review 2020/2021 revealed that"], [null, "a total of 365 licensees had not submitted applications for renewal. In"], [null, "light of the occurrence, there is a risk that the licensees in issue could"], [null, "have operated for the whole year without having paid the requisite fees,"], [null, "which would lead to a loss in government revenue to a tune of"], [null, "UGX.200Mn."], [null, "\uf0b7 Section 36(1)(a & b) of the Tier 4 Microfinance Institutions Act and"], [null, "Moneylenders Act, 2016 states that a SACCO shall not carry on the"], [null, "business of financial services unless it is a registered society; and licensed"], [null, "under the Act. Audit noted that only 15 SACCOs were issued with"], [null, "operating licenses by Uganda Microfinance Regulatory Authority."], [null, "However, data obtained from Microfinance Support Centre (MSC)"], [null, "indicated that over 6,150 EMYOOGA SACCOs were by March, 2021 in"], [null, "operation without acquiring operating licenses."], [null, "\uf0b7 Audit of the Authority\u2019s payroll and other expenses revealed that during"], [null, "the financial year ended 30th June 2021, Pay as You Earn (PAYE) tax"], [null, "amounting to UGX.290Mn in respect of deductions from employees was"], [null, "never remitted to the Uganda Revenue Authority."], ["15 The Departed Asians Property Custodian Board (DAPCB). 2020/21 Opinion Unqualified \uf0b7 I noted that MDAs and LGs are still experiencing challenges in implementing the budgets approved by parliament and policy guidance\u2019s issued by PS/ST, which has continued to affect the performance and credibility of the budget negatively. \uf0b7 I reviewed the NTR estimates, revenue sources and rates charged for the financial year 2020/2021 and noted that the entity budgeted to collect NTR of UGX.2,572,820,000 during the year under review. Out of this, only UGX.1,410,970,500 was collected, representing a performance of 55% of the target, resulting into a shortfall of UGX.1,161,849,500. \uf0b7 The entity budgeted to receive UGX.2.572Bn during the period, out of which UGX.1.383Bn was warranted, resulting into a shortfall of UGX.1.189Bn which is 46.23% of the budget. \uf0b7 I observed that in cases where outputs were not quantified, management reported performance in generic ways such as tenants sensitised to pay rent, court attended etc, without specifying the number/quantities achieved. \uf0b7 All five (5) outputs with a total of thirteen (13) activities worth UGX.1.383Bn were partially implemented. \uf0b7 I noted that in a twist of events, the Board refunded the sum of UGX.0.860Bn that had been deposited in respect of the property, citing the fact that the property had been donated to the tenant, but this was not supported by a Board resolution. \uf0b7 I observed that according to a disclosure in note 19 of the accounts, receivables have increased from UGX.3.35Bn last year to UGX.8.21Bn this year. Of this amount, UGX.3,73Bn relates to uncollected rent from prior years and UGX.4.60Bn relates to unpaid proceeds from property sales. \uf0b7 I reviewed the portfolio of DAPCB court cases and noted that there was a continuous rise) in the number of court cases against the Board arising from disputes of properties. The cases rose by 18, making a total of 120, as at the end of the year.", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 234, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None"], "type": "table"}}, {"content": "222", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 234, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that the entity does not have a comprehensive asset register to date. The copy of the compendium/register availed to me for audit was still under verification by management and as such management could not vouch for its completeness. \uf0b7 I reviewed the compendium of assets presented for audit by management and noted that nearly all properties therein were not yet valued, and yet the Board of valuers has now been in place for nearly three financial years.", null, null], ["16", "The Danida (Upgrade) Project Under the Inspectorate of Government.", "\uf0b7 I noted that MDAs and LGs are still experiencing challenges in implementing the budgets approved by parliament and policy guidance's issued by PS/ST, which has continued to affect the performance and credibility of the budget negatively."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 235, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["\uf0b7 I noted that the entity does not have a comprehensive asset register to date. The copy of the compendium/register availed to me for audit was still under verification by management and as such management could not vouch for its completeness. \uf0b7 I reviewed the compendium of assets presented for audit by management and noted that nearly all properties therein were not yet valued, and yet the Board of valuers has now been in place for nearly three financial years.", null, null], ["16", "The Danida (Upgrade) Project Under the Inspectorate of Government.", "\uf0b7 I noted that MDAs and LGs are still experiencing challenges in implementing the budgets approved by parliament and policy guidance's issued by PS/ST, which has continued to affect the performance and credibility of the budget negatively."], [null, "2020/21 Opinion Unqualified", null], ["17 The Inspectorate of Government (IG). 2020/21 Opinion Unqualified \uf0b7 I noted that MDAs and LGs are still experiencing challenges in implementing the budgets approved by parliament and policy guidance\u2019s issued by PS/ST, which has continued to affect the performance and credibility of the budget negatively. \uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity budgeted to collect NTR of UGX.1,201,509,223 during the year under review. Out of this, a total of UGX.1,875,073,520 was collected, representing a performance of 156% of the target with an excess collection of UGX.673,564,297. \uf0b7 The entity budgeted to receive UGX.53.4Bn from GoU sources; however, only UGX.49.45Bn was released, resulting into a shortfall of UGX.3.95Bn, which is 7.4% of the budget. \uf0b7 Out of the total warrants for the financial year of UGX.49,446,960,793, UGX.45,655,225,893 was spent by the entity, leaving a balance of UGX.3,791,734,900 unutilised by the vote. \uf0b7 I noted that the approved work programme for the construction of headquarter building indicated planned progress of 32% compared to the actual work progress of 11.9%.", null, null], ["18", "The Northern Uganda Social Action Fund Project Under the Inspectorate of", "\uf0b7 The project had an approved budget of UGX.2,235,166,397 for the FY 2020/21. I noted that a total of UGX.2,235,166,397 was received for the period representing 100% of the appropriated amount."], [null, "Government (IG). 2020/21 Opinion", null], [null, "Unqualified", null], [null, "", null], ["19 Ministry of Finance Planning and Economic Development (MoFPED). 2020/21 \uf0b7 Analysis of domestic arrears showed an increase of UGX.139Bn from UGX.129Bn in the financial year 2019/20 to UGX.269Bn in the financial year 20/21 representing a jump of 108%. Overall, tax expenditure by government for private firms continues to account for the biggest portion of the arrears (at 78%) despite the write off of the tax arrears in the", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 235, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "223", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 235, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Unqualified previous financial year. I also noted that arrears relating to unsettled obligations to international organizations stood at UGX.49.49Bn with some dating as far back as financial year 2014/15. \uf0b7 GoU, through MOFPED, offered additional incentives of USD Cents 5/KWH to companies in the Cotton, Textile and Apparels (CTA) industry. During the financial year ended 30th June 2021, a total of UGX.3.36Bn was paid/refunded to two manufacturers while UGX.5.41Bn remained outstanding as at year end; However, I noted that; i) the concession was not time-bound, which exposes government to perpetual expenditure without value analysis. ii) none of the beneficiaries had furnished the Ministry with the required insurance bond despite the continued access to the benefit. iii) there was no evidence of publicizing the concession for the benefit of all eligible firms/persons. In this regard, the concession is only being enjoyed by two firms which creates competitive disadvantages to the other players in the industry. iv) there was no mechanism in place to monitor compliance with the set targets despite having reached the first milestone. v) the memorandum of understanding signed did not provide for reporting obligations for the beneficiaries. There was thus no justification for the continued incentive vi) all refunds effected so far are made from supplementary budgets implying none sustainability of the incentive. Indeed a total of UGX.5.41Bn remains outstanding as at 30th June 2021. \uf0b7 In line with the above, it is apparent that the subsidy is being implemented with irregularities. Government is exposed to continued expenditure without due regard to achievement of the intended objectives. \uf0b7 The Uganda Agriculture Insurance Scheme (UAIS) is a Public Private Partnership between GoU and the Private Sector represented by the Uganda Insurers Association and insurance companies under the agro- Consortium. The purpose of the scheme is to hedge Ugandan farmers against natural calamities beyond their control. However, review of implementation revealed that there was lack of a mutual agreement on Marketing of the scheme to the potential beneficiaries and a number of conditions in the MoU are not yet fulfilled. This has limited its access to potential beneficiaries and also raised transparency concerns in regard to how the current beneficiaries were identified. \uf0b7 The PPP Act 2015 provides that there is to be established a Project Development Fund to support public private partnerships initiatives. However, six years later, there is no evidence of operationalization of the Fund by the Minister. Failure to establish the fund may be a contributory factor to the slow uptake and limited feasibility studies of the Public Private Partnerships.", null, null], ["20", "PPDA Tribunal. 2020/21", "\uf0b7 I noted that the Tribunal was operating a strategic plan that is not aligned to the NDP III period. The Tribunal\u2019s planning period is 2017-"], [null, null, "2022 implying that activities implemented during the financial year"], [null, "Opinion", "2020/2021 may not have been aligned to the NDP-III, which negatively affects the achievement of NDP-III objectives."], [null, "Unqualified", null], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 236, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "224", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 236, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["21 Uganda Investment Authority. 2020/21 Opinion Unqualified \uf0b7 The Authority received off-budget financing to a tune of UGX.50.43Bn, which was not transferred to the consolidated fund as required by law. These funds were received directly from development partners to the EPC contractor for the Development of infrastructure at Kampala Industrial and Business Park, Namanve. Off-budget financing distorts planning, may result into duplication of activities and is contrary to the Public finance Management Act 2015. \uf0b7 The approved budget estimates for the Authority for the financial year 2020/2021 indicated that only UGX.22Mn out of UGX.2.411Bn was budgeted towards the settlement of domestic arrears. The arrears balance of UGX.2.389Bn was therefore not budgeted for settlement. Failure to provide resources for the accumulated arrears increases outstanding obligations. \uf0b7 The Authority continued to accumulate domestic arrears with a total of UGX.1.768Bn incurred in the financial year under review, without clearing outstanding arrears from the previous financial year 2019/2020 of UGX.2.411Bn. The total accumulated domestic arrears stood at UGX.4.18Bn at 30th June 2021. This is an indicator of non adherence with the commitment control system of government. \uf0b7 During inspections countrywide, I observed that the industrial parks lack or had inadequate infrastructures like roads, solid waste and sewage management systems, power supply, street lights etc. The Parks have been characterized by encroachment, farming and cattle grazing, degradation of nearby swamps, unallocated land, idle land allocated to unserious investors and misunderstandings between investors and park management staff. Most roads are impassable and with inadequate lighting which exposes the parks to thefts and insecurity. I observed that some factories in the parks have set up their own infrastructure which may not be sustainable, and to the desired standards. This may negatively affect the usage and utilization of the parks. \uf0b7 The Authority lacks regulations required under Section 38(1) of the Investment Code Act to operationalize the statute. This may hinder the smooth implementation of the Act which is meant to create an investment enabling environment. \uf0b7 Although the Authority has 124 approved positions, only 78 (i.e. 62.9%) are filled, leaving 46 (37.1%) vacant positions. Among the vacant positions include 24 unfilled positions that are from the core Directorate of Investment which is the backbone of UIA. Understaffing undermines service delivery.", null, null], ["22", "Treasury Operations. 2020/21", "\uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity had not budgeted to collect NTR during the year under review."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 237, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["21 Uganda Investment Authority. 2020/21 Opinion Unqualified \uf0b7 The Authority received off-budget financing to a tune of UGX.50.43Bn, which was not transferred to the consolidated fund as required by law. These funds were received directly from development partners to the EPC contractor for the Development of infrastructure at Kampala Industrial and Business Park, Namanve. Off-budget financing distorts planning, may result into duplication of activities and is contrary to the Public finance Management Act 2015. \uf0b7 The approved budget estimates for the Authority for the financial year 2020/2021 indicated that only UGX.22Mn out of UGX.2.411Bn was budgeted towards the settlement of domestic arrears. The arrears balance of UGX.2.389Bn was therefore not budgeted for settlement. Failure to provide resources for the accumulated arrears increases outstanding obligations. \uf0b7 The Authority continued to accumulate domestic arrears with a total of UGX.1.768Bn incurred in the financial year under review, without clearing outstanding arrears from the previous financial year 2019/2020 of UGX.2.411Bn. The total accumulated domestic arrears stood at UGX.4.18Bn at 30th June 2021. This is an indicator of non adherence with the commitment control system of government. \uf0b7 During inspections countrywide, I observed that the industrial parks lack or had inadequate infrastructures like roads, solid waste and sewage management systems, power supply, street lights etc. The Parks have been characterized by encroachment, farming and cattle grazing, degradation of nearby swamps, unallocated land, idle land allocated to unserious investors and misunderstandings between investors and park management staff. Most roads are impassable and with inadequate lighting which exposes the parks to thefts and insecurity. I observed that some factories in the parks have set up their own infrastructure which may not be sustainable, and to the desired standards. This may negatively affect the usage and utilization of the parks. \uf0b7 The Authority lacks regulations required under Section 38(1) of the Investment Code Act to operationalize the statute. This may hinder the smooth implementation of the Act which is meant to create an investment enabling environment. \uf0b7 Although the Authority has 124 approved positions, only 78 (i.e. 62.9%) are filled, leaving 46 (37.1%) vacant positions. Among the vacant positions include 24 unfilled positions that are from the core Directorate of Investment which is the backbone of UIA. Understaffing undermines service delivery.", null, null], ["22", "Treasury Operations. 2020/21", "\uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity had not budgeted to collect NTR during the year under review."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 237, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "225", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 237, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "government to private enterprises for which no recovery has been"], [null, null, "effected since 2013."], [null, null, "\uf0b7 Included in cash and cash equivalents is UGX.15.62Bn which was a"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 238, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "government to private enterprises for which no recovery has been"], [null, null, "effected since 2013."], [null, null, "\uf0b7 Included in cash and cash equivalents is UGX.15.62Bn which was a"], [null, null, "USAID grant for enhancing Livelihoods and Infrastructure of Northern"], [null, null, "Uganda under a project. The funds have remained utilized for more than"], [null, null, "two years and risk being refunded to the donor yet it was a grant."], [null, null, "\uf0b7 I noted that there is no clear method of identifying which claimants are"], [null, null, "considered for negotiations even in the instance of where the said"], [null, null, "claimants have mandamus orders."], [null, null, "\uf0b7 I have noted that over the years, budgets for mandamus payments are"], [null, null, "included in the original budget as notional amounts despite having a"], [null, null, "figure for outstanding payments at the beginning of the year, including"], [null, null, "those for which settlement plans have been drawn as per the signed"], [null, null, "MoUs and court variation orders with beneficiaries."], [null, null, "\uf0b7 Audit observed that, UGX.3.32Tn which was advanced by the Bank of"], [null, null, "Uganda to settle matured obligations relating to treasury bills and bonds"], [null, null, "(principal and interest) had not been refunded as at 30th June 2021"], [null, null, "contrary to the requirements under Section 36 of the PFMA."], [null, null, "\uf0b7 A review of the company files in which the GOU holds shares revealed"], [null, null, "that some companies were dormant, with no activities being undertaken"], [null, null, "on the said files. There was no evidence that the said companies were"], [null, null, "filing the mandatory annual returns, minutes of the Annual General"], [null, null, "Meetings or any information to indicate the activity of the companies."], [null, null, "\uf0b7 Audit established through a review of records at Uganda Registration"], [null, null, "Services Bureau that Government owns a number of investments that are"], [null, null, "not reported/ recognised in the financial statements of Treasury"], [null, null, "Operations."], [null, null, "\uf0b7 It was established that the Minister provided authorisations to nineteen"], [null, null, "(19) Public Institutions to borrow funds from financial institutions totalling"], [null, null, "to UGX.60.042Bn, but there was no evidence of any monitoring being"], [null, null, "undertaken by the Ministry to ensure adherence to the loan terms and"], [null, null, "conditions."], ["23 Insurance Regulatory Authority. 2020/21 Opinion Unqualified \uf0b7 Out of the budgeted NTR of UGX.26.874Bn, only UGX.19.818Bn was collected and a shortfall of UGX.7.056Bn, representing a performance of 73.7% of the target. Shortfalls in NTR collections affect the implementation of planned activities. \uf0b7 I noted that a number of planned procurements were not executed worth UGX.5.61Bn. Non implementation of all procurements leads to failure to attain the intended objectives during the financial year. \uf0b7 There were noted delays in the phase one construction of an ultra- modern 11 storeyed office building for Insurance Regulatory Authority located at plot 6, Lumumba Avenue, which was awarded to a contractor at an amended contract price of UGX.32.662Bn. By the time of reporting, although a total cumulative payment of UGX.29.943Bn (91%) had been made to the contractor, the project was at 80% completion and 46 months behind schedule.", null, null], ["24", "National Lottery & Gaming Board. Opinion", "\uf0b7 I noted that a number of Gaming houses had not filed the required quarterly returns contrary to the Lotteries and Gaming regulations. There was no evidence that the Board had conducted enforcement activities to ensure compliance by the operators."], [null, "Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 238, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "226", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 238, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "not making returns and having operational gaps going undetected which"], [null, null, "affects the revenue collections of Uganda Revenue Authority and exposes"], [null, null, "the Ugandan public to risk of unprofessional operators."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 239, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "not making returns and having operational gaps going undetected which"], [null, null, "affects the revenue collections of Uganda Revenue Authority and exposes"], [null, null, "the Ugandan public to risk of unprofessional operators."], [null, null, "\uf0b7 The Ministry of Finance, Planning and Economic Development on behalf"], [null, null, "of Lotteries and Gaming Regulatory Board awarded a UGX.10.833Bn"], [null, null, "contract to a foreign company to provide consultancy services for"], [null, null, "development of a National Central Electronic Monitoring system. The"], [null, null, "contract period was for 2 (two) years effective 23rd June, 2020. I noted"], [null, null, "that, two years later, the procurement has not been made. There is no"], [null, null, "provision for implementation of the system even in the current budget"], [null, null, "2021/22. The failure to procure the system, denies the Board the"], [null, null, "associated benefits like monitoring and revenue tracking. Beside this may"], [null, null, "result into litigation on grounds of breach of contract and expose"], [null, null, "Government to loss of funds in compensation."], [null, null, "\uf0b7 During the year under review, although the Board licensed 17 casinos,"], [null, null, "there was no evidence that the Board advertised the applications for the"], [null, null, "said casinos to invite the views of the public as is required by regulations."], [null, null, "Failure to publish the notices poses a risk of granting licenses to"], [null, null, "operators with some conflicts among the public and as such may result"], [null, null, "into litigation."], ["25 Public Procurment And Disposal of Public (PPDA) 2020/21 Opinion Unqualified \uf0b7 I noted at the time of the audit that out of the planned Four (4) strategic targets/goals, No targets had been fully achieved, while three (3) were partially achieved, and one (1) target had not been achieved at al \uf0b7 I noted that out of the budgeted revenue of UGX.28.4Bn for the year 2020/21, UGX.21.3Bn was realised representing a performance of only 75% of the target. \uf0b7 Out of the 5 outputs assessed, No output was fully implemented; 5 outputs representing 100% were partially implemented, while no output was not implemented at all. \uf0b7 I noted that although the budget for Domestic arrears was UGX.42,407,000, funds amounting to UGX.432,579,009 were spent on domestic arrears for the FY 2020/21, implying an over expenditure of UGX.390,172,009 on this item. \uf0b7 Out of the total receipts for the financial year of UGX.18.698Bn, UGX.18.59Bn was spent by the Authority, resulting into an unspent balance of UGX.0.108Bn representing an absorption level of 99%. \uf0b7 The audit reviewed the performance of the above project and noted that much as most of the key planned activities had been implemented, there were few that were still pending. \uf0b7 I observed that the entity has a staff establishment of 140 positions, out of which only 116 were filled, leaving 24 positions vacant, representing 17% of the workforce of the entity. In addition, seven staff exited the Authority during the year, due to various reasons.", null, null], ["26", "Bank of Uganda.", "\uf0b7 No significant findings."], ["", "2020/21", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["27 Capital Markets Authority. 2019/20 Opinion \uf0b7 No significant findings.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 239, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "227", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 239, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Unqualified", null, null], ["28", "Deposit Protection Fund (\"The Fund\") 2020/21 Opinion Unqualified", "\uf0b7 I noted that although effective 1st July 2020, DPF was exempt from withholding tax, Bank of Uganda erroneously deducted withholding tax (WHT) on the Fund\u2019s interest income on matured government securities during the period amounting to UGX.10.4Bn. However, directors have decided to make full provision against the WHT receivable based on the historical experience and expected future outcome of the claim from URA"], [null, null, "on a conservative basis, and this is in accordance with the requirement of"], [null, null, "IAS 36: Impairment of Assets."], ["29 Pride Microfinance Limited (MDI) 2020 Opinion Unqualified \uf0b7 No significant findings.", null, null], ["30", "Project for Financial Inclusion In Rural Areas (PROFIRA)", "\uf0b7 I noted that, as reported in my report for the year ended 30th June 2020, Government of Uganda has not yet honored its obligation of UGX.5.6Bn as co-funding for the Project."], [null, "Opinion Unqualified", null], ["31 The Resource Enhancement and Accountability Programme (REAP) 2020/21 Opinion Unqualified \uf0b7 No significant findings.", null, null], ["32", "Uganda Development Bank", "\uf0b7 No significant findings."], ["", "Limited (UDBL). 2020", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["33\\. Microfinance Support Centre Limted (MCSC) 2020 Opinion Unqualified \uf0b7 I noted that unresolved receipts in payables balance amounting to UGX. UGX.581 Million", null, null], ["", "INFORMATION COMMUNICATION SECTOR", ""], [null, null, ""], ["1\\. Ministry of ICT and National Guidance Opinion Unqualified \uf0b7 The entity budgeted to receive UGX.46.401Bn from Treasury; out of this amount, UGX.43.586 Bn was warranted, resulting into a shortfall of UGX.2.81Bn which was 6% of the budget. Of the released amount, the Ministry absorbed UGX.42Bn, resulting into an unspent balance of UGX.1.6Bn representing an absorption level of 96%. Unspent balances imply un implemented activities and which in turn hampers proper service", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 240, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "228", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 240, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["delivery. \uf0b7 Contrary to Regulation 18 (1) of the PPDA (Contracts) Regulations, 2014, the Ministry issued call off orders to two firms in three separate procurements of office furniture worth UGX.144.8Mn under a framework contract where the items and prices on the call off orders were different from what was agreed on in the signed framework contract. This erodes the benefits of framework contracts and may cause a loss to Government.", null, null], ["2", "Uganda Communications Commission. Opinion Unqualified", "\uf0b7 Assessment of the Commission\u2019s performance of Non Tax Revenue (NTR) revealed that out of the budgeted NTR of UGX.156.59Bn, a total of UGX.454.61 was collected, representing an increase of UGX.298Bn (190% of the target). Management attributed the overperformance to payment of the National Telecom Operator (NTO) license by two telecom"], [null, null, "companies which had not been budgeted for. The Accounting Officer was"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 241, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["delivery. \uf0b7 Contrary to Regulation 18 (1) of the PPDA (Contracts) Regulations, 2014, the Ministry issued call off orders to two firms in three separate procurements of office furniture worth UGX.144.8Mn under a framework contract where the items and prices on the call off orders were different from what was agreed on in the signed framework contract. This erodes the benefits of framework contracts and may cause a loss to Government.", null, null], ["2", "Uganda Communications Commission. Opinion Unqualified", "\uf0b7 Assessment of the Commission\u2019s performance of Non Tax Revenue (NTR) revealed that out of the budgeted NTR of UGX.156.59Bn, a total of UGX.454.61 was collected, representing an increase of UGX.298Bn (190% of the target). Management attributed the overperformance to payment of the National Telecom Operator (NTO) license by two telecom"], [null, null, "companies which had not been budgeted for. The Accounting Officer was"], [null, null, "advised to always conduct comprehensive research on all potential"], [null, null, "revenue sources for proper budgeting of NTR."], [null, null, "\uf0b7 Out of the total receipts for the financial year of UGX.454.61Bn, only"], [null, null, "UGX.451.98Bn was spent by the entity resulting into an unspent balance"], [null, null, "of UGX.2.63Bn representing an absorption level of 99.5%. I commended"], [null, null, "the Accounting Officer for absorbing most of the funds availed despite the"], [null, null, "challenges during the year."], [null, null, "\uf0b7 I noted that several procurements to the tune of UGX.4.51Bn were not"], [null, null, "implemented as of 30th June 2021. As a result, implementation of critical"], [null, null, "Commission programs was delayed. Management attributed the delays in"], [null, null, "these procurements to the COVID-19 pandemic that paralysed the entire"], [null, null, "procurement process."], [null, null, "\uf0b7 The Commission discontinued issuing invoices to Uganda Telecom Ltd,"], [null, null, "Posta Uganda and Uganda Broadcasting Corporation due to tax"], [null, null, "implications where, the Commission has to pay VAT to URA on every"], [null, null, "invoice raised, whether funds are received or not. As a result, UCC ledger"], [null, null, "balances of UGX.85.1Bn differed from the reported receivables of"], [null, null, "UGX.13.1Bn, by a total of UGX.72.0Bn. Furthermore, I noted that the"], [null, null, "reported receivables by UCC from the same entities differed from the"], [null, null, "reported payables to UCC by the same entities. The Accounting Officer"], [null, null, "was advised to engage management of the affected entities with a view"], [null, null, "of reconciling to the correct receivable figures."], [null, null, "\uf0b7 The Commission did not charge the 2% gross annual levy on the licensed"], [null, null, "Television and FM radio operators and no licensed Television and FM"], [null, null, "radio operator had submitted Audited financial statements to the"], [null, null, "Commission for assessment. This denied the Commission the revenue to"], [null, null, "implement development programs."], [null, null, "\uf0b7 The Commission lacks a Tribunal with the jurisdiction to hear and"], [null, null, "determine all matters relating to communications services arising from"], [null, null, "decisions made by the Commission or the Minister, contrary to Section"], [null, null, "60(1 & 2) and 64(1) of the Uganda Communications Act, 2013. The"], [null, null, "accounting officer explained that the responsibility to appoint the tribunal"], [null, null, "resides with the President on the recommendation of the Judicial Service"], [null, null, "Commission. I advised management and the Board of Directors to liaise"], [null, null, "with the relevant authorities with the view of constituting the"], [null, null, "Communications Tribunal."], ["3 Rural Communications Infrastructure Program, Phase 5 \u2013 Uganda Project, IDA LOAN NO.5635-UG \uf0b7 I noted that MDAs and LGs are still experiencing challenges in implementing the budgets approved by parliament and policy guidance\u2019s issued by PS/ST, which has continued to affect the performance and", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 241, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "229", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 241, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["2020/21 Opinion Unqualified credibility of the budget negatively. \uf0b7 I noted that RCIP was lagging behind in some activities that would not be completed at the project end. \uf0b7 I noted that all four components did not fully absorb the available funds. Out of the UGX.104.88Bn that was released to RCIP, the Project only utilised UGX.76.52Bn, thus failing to absorb funds to a tune of UGX.28.36Bn representing 27% of the released funds. \uf0b7 It was noted that RCIP set clear performance targets and indicators for some activities to facilitate performance measurement. \uf0b7 I noted that a total of USD.702,415 has so far been paid to the contractor for supply, installation and commissioning of the e-government procurement system, of which a total of USD.198,645 was paid during the year under audit. \uf0b7 Government lost USD.208,156 for receiving quality assurance services for a system that had already been discontinued by Government", null, null], ["4", "National Information Technology Authority \u2013 Uganda (NITA-U) 2020/21 Opinion Unqualified", "\uf0b7 Analysis of domestic arrears over the past three years has shown a steep upward trend over the period with a 123% growth. The outstanding amount currently is UGX.6Bn. Further analysis revealed that most of the arrears relate to costs of expanding the national backbone infrastructure. The domestic arrears at hand now account for 14% of the annual GoU budget of the Authority. Such a trend is not only unsustainable but may lead to erosion of the credit worthiness of the Authority and may attract"], [null, null, "interest and penalties."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 242, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["2020/21 Opinion Unqualified credibility of the budget negatively. \uf0b7 I noted that RCIP was lagging behind in some activities that would not be completed at the project end. \uf0b7 I noted that all four components did not fully absorb the available funds. Out of the UGX.104.88Bn that was released to RCIP, the Project only utilised UGX.76.52Bn, thus failing to absorb funds to a tune of UGX.28.36Bn representing 27% of the released funds. \uf0b7 It was noted that RCIP set clear performance targets and indicators for some activities to facilitate performance measurement. \uf0b7 I noted that a total of USD.702,415 has so far been paid to the contractor for supply, installation and commissioning of the e-government procurement system, of which a total of USD.198,645 was paid during the year under audit. \uf0b7 Government lost USD.208,156 for receiving quality assurance services for a system that had already been discontinued by Government", null, null], ["4", "National Information Technology Authority \u2013 Uganda (NITA-U) 2020/21 Opinion Unqualified", "\uf0b7 Analysis of domestic arrears over the past three years has shown a steep upward trend over the period with a 123% growth. The outstanding amount currently is UGX.6Bn. Further analysis revealed that most of the arrears relate to costs of expanding the national backbone infrastructure. The domestic arrears at hand now account for 14% of the annual GoU budget of the Authority. Such a trend is not only unsustainable but may lead to erosion of the credit worthiness of the Authority and may attract"], [null, null, "interest and penalties."], [null, null, "\uf0b7 Included in the Statement of Financial Position is a receivable of"], [null, null, "UGX.14.9Bn arising from the 1% levy on Telecoms due from Uganda"], [null, null, "Communications Commission (UCC) dating as far back as financial year"], [null, null, "2016/17, whose recoverability is doubtful following a policy directive from"], [null, null, "the Ministry of Information, Communication and National Guidance to the"], [null, null, "effect that NITA-U should stop recognizing its share of 1% levy on"], [null, null, "Telecoms."], [null, null, "\uf0b7 UGX.1,532,979,432 reflected as non-produced assets in the Statement of"], [null, null, "Financial Position relates to land leased to NITA-U by Uganda Investment"], [null, null, "Authority. The same land has been leased to a private company without"], [null, null, "the knowledge of NITA-U. Although NITA-U filed a case against UIA in"], [null, null, "the High Court seeking a permanent injunction restraining UIA, the case"], [null, null, "was dismissed noting that the matter could only be determined under"], [null, null, "land law. By the time of audit, a developer to whom UIA leased the"], [null, null, "property had taken possession of the land and started undertaking"], [null, null, "developments on it."], ["5 Uganda Broadcasting Corporation (UBC). 2020/21 Opinion Unqualified \uf0b7 Although the entity budgeted to receive UGX.45.83Bn only UGX.15.39Bn was collected and spent, resulting into a shortfall of UGX.30.43Bn which is 66.4% of the budget. The budget for the financial year 2020/2021 was developed on the assumption that UBC would receive the UGX.34.6 Billion approved by Parliament; however, the Corporation did not receive the funds as planned. This is an indication of unrealistic budgeting by the Corporation well aware of the effects of the Covid-19 pandemic \uf0b7 Comparison of the trade receivables balances for current year and prior year indicates that the receivables decreased by 28% from UGX.30.79Bn to UGX.22Bn. An ageing analysis revealed that receivables worth UGX.13.549Bn from 228 clients were at least 7 years old without any movements in their ledger accounts, thus casting doubt as to their existence and recoverability.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 242, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "230", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 242, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 The Corporation has outstanding NSSF amounting to UGX.46.38Bn as at 30th June 2021. As a result, the Corporation and the Managing Director have been sued for non-payment and imposition of interest and fines by the NSSF due to non-remittance is now likely. This is wasteful as it could have been avoided if remittances had been made in a timely manner.", null, null], ["6", "Uganda Post Limited.", "\uf0b7 I noted that despite this being the final year of the Strategic plan and"], ["", "2020/21", "collecting on average, over 86% of the budget, most objectives were not"], [null, "Opinion", "achieved, with some attaining between 21% and 39% of implementation. The key strategic objectives that were not met include Building a strong financial base to meet operational and project development budget,"], [null, "Unqualified", "Attracting, deploying, developing and retaining a productive and motivated Human Resource, Strengthening the ICT unit to raise efficiency"], [null, null, "and competitiveness of UPL products and Rationalizing existing business"], [null, "", "lines and diversifying into low hanging opportunities to improve profitability."], [null, "", null], ["7 Uganda Communication Employees Contributory Pension Scheme (UCECPS) 2020/21 Opinion Qualified \uf0b7 I noted unsurpported payables amounting to UGX.2,679,752,000. \uf0b7 I noted that eleven (11) properties disclosed as part of the non-core assets were not valued and therefore not included in the value of Non- current assets of the Scheme. \uf0b7 A review and comparison made between the audited financial statements for the period ending 30th June, 2019 and the financial statements for the period ending 30th June, 2020 revealed inconsistencies in the account balances of reserves. \uf0b7 Unsupported and un-reconciled receivables from Uganda Telecom LimiteD (UTL - IN ADMINISTRATION) \uf0b7 I noted that the cash flow statement was misstated. \uf0b7 I noted that out of the budgeted revenue of UGX.12,447,003,444 for the year 2019/2020, only UGX.2,264,969,444 was realised representing a performance of only 18.2% of the target which implied that the Scheme had a deficit of 81.8%. \uf0b7 I noted unbudgeted expenditure totaling to UGX.88,575,000 \uf0b7 I noted diversion of members\u2019 contribution (dc) to pay Defined Benefits", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 243, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "231", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 243, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["(DB) liabilities amounting to UGX.4,550,343,000 \uf0b7", null, null], ["8", "Agricultural Credit Facility (ACF) 2020/21", "\uf0b7 No significant findings."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 244, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["(DB) liabilities amounting to UGX.4,550,343,000 \uf0b7", null, null], ["8", "Agricultural Credit Facility (ACF) 2020/21", "\uf0b7 No significant findings."], [null, null, ""], ["TRADE SECTOR \uf0b7", null, null], ["1", "Quality Infrastructure and Standards Programme (QUISP). 2017/2018", "\uf0b7 I observed that a sum of UGX. 80,034,014 and USD. 14,040 was paid to various officers and companies. However, contrary to the guidelines, the expenditure vouchers together with the supporting documents were not availed for audit verification. \uf0b7 Payments amounting to UGX.28,798,048 were paid to officers to enable them carryout various QUISP activities. However, some of the"], [null, "Opinion Qualified", null], [null, "", ""], [null, null, "373,603,894 as at end of the financial year. According to a letter from"], [null, null, "the Embassy of Sweden to the Permanent Secretary Ministry of Trade,"], [null, null, "Industry and Cooperatives dated 27th April, 2017 activities to a tune of"], [null, null, "UGX. 147,264,493 were authorized to be charged on the QUISP"], [null, null, "Programme. The entity spent a sum of UGX. 147,468,378 leaving"], [null, null, "outstanding commitments of UGX. 226,135,516 as indicated in the"], [null, null, "schedule of outstanding commitments."], [null, null, "\uf0b7 I reviewed the Programme bank statements and noted that as at 31st"], [null, null, "March 2021, UGX. 10,426,029 and USD. 1,973.43 was still on account."], [null, null, "Failure to spend funds resulted in partial and non-implementation of"], [null, null, "planned activities."], [null, null, "\uf0b7 I observed that a sum of UGX. 4,038,651 was deducted from two (2)"], [null, null, "service providers in respect of 6% withholding tax for onward remittance"], [null, null, "to Uganda Revenue Authority"], [null, null, "\uf0b7 The project procured 79 assets over the Programme life time. In March"], [null, null, "2021, I carried out an inspection of the assets procured under the"], [null, null, "Programme and noted that 12 were functional, 2 (vehicles) were under"], [null, null, "repair, 16 were old and beyond repair, 12 were non-functional while 37"], [null, null, "were not availed for verification. I could not assess the status of the 37"], [null, null, "assets that were not availed."], ["2 Uganda Export Promotions Board 2020/21 Opinion Unqualified \uf0b7 The entity budgeted to receive UGX.5.813Bn. However, UGX.3.759Bn was warranted, resulting into a shortfall of UGX.2.054Bn, which is 35.4% of the budget. This affected implementation of planned activities. \uf0b7 It was observed that the term of office for the previous Board expired on 5th October 2019, and no replacement Board had been appointed by the time of issuance of my report. This is likely to affect the strategic direction of the entity. For example, I noted that at the time of the audit (June 2021), the entity\u2019s strategic plan was in draft form and was not approved due to the lack of a Board. \uf0b7 I noted that contracts worth UGX.192Mn were awarded to bidders who", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 244, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "232", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 244, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["did not submit the required documents to evidence the eligibility and administrative compliance as required by regulations and bid documents at the preliminary stage.", null, null], ["3", "Uganda Freezones Authority (UFZA) 2020/21", "\uf0b7 Contrary to Section 15 of the Public Finance Management Act 2015, the Authority overspent to the tune of UGX.635Mn on recruitment and personnel costs in excess of what was approved by the Board. \uf0b7 The entity budgeted to collect NTR amounting to UGX.2.101Bn but was only able to collect UGX.0.06Bn resulting into a shortfall of UGX.2.04Bn,"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 245, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["did not submit the required documents to evidence the eligibility and administrative compliance as required by regulations and bid documents at the preliminary stage.", null, null], ["3", "Uganda Freezones Authority (UFZA) 2020/21", "\uf0b7 Contrary to Section 15 of the Public Finance Management Act 2015, the Authority overspent to the tune of UGX.635Mn on recruitment and personnel costs in excess of what was approved by the Board. \uf0b7 The entity budgeted to collect NTR amounting to UGX.2.101Bn but was only able to collect UGX.0.06Bn resulting into a shortfall of UGX.2.04Bn,"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 The development work on 5 acres of land at Entebbe International Airport"], [null, null, "commenced in September 2020 and works worth UGX.4.146Bn (27%)"], [null, null, "had been certified as completed as at 30th June 2021. However, the"], [null, null, "Authority had affected 89% advance payment to NEC as at 29th June"], [null, null, "2021, amounting to UGX.15.34Bn and all the advance guarantees staked"], [null, null, "had expired."], [null, null, "\uf0b7 Although the Authority has taken possession of 109 acres of land at"], [null, null, "Buwaya purchased at UGX.7.6Bn and 5 acres of land at Entebbe"], [null, null, "International Airport purchased at UGX.850Mn, it still lacks land titles to"], [null, null, "confirm legal ownership."], ["4 Uganda Warehouse Receipt System Authority (UWRSA) 2020/21 Opinion Unqualified \uf0b7 The Uganda Warehouse Receipt System Authority had an approved budget of UGX.8,904,499,400 for the year. A review of the entity\u2019s receipts, cashbook and bank statement for the period ending 30th June 2021 revealed that UGX.8,035,212,980 was received under the normal budget appropriation \uf0b7 Whereas the overall Government National Development Plan (NDP II1) 2020/2021-2024/2025 was commissioned in the year under review, UWRSA had no approved strategic plan for the period under review \uf0b7 I noted that the entity did not budget for any tax revenue despite collecting 84 million. Failure to budget for NTR conceals the entity\u2019s potential collect revenue and also complicates assessment of performance since there is no benchmark. \uf0b7 I noted that out of the budgeted revenue of UGX. 8.899Bn from the Central Government for 2020/2021, and only UGX. 8.035Bn was received, representing a performance of only 90 % of the release. \uf0b7 The entity had a cash balance brought forward of UGX.134,172,095 from FY 2019/2020 and received UGX.8,035,212,980 making total cash available for spending in FY 20/21 of UGX.8,169,385,075. Out of the total cash available to spend, only UGX.3,730,897,866 was actually spent by the entity, representing an absorption level of 46%. This resulted into a balance of UGX.4,438,487,209 (54%) as unspent funds. \uf0b7 I compared the consolidated procurement plan, monthly procurement reports and procurement files availed and established that a number of procurements worth UGX.2,621,000,000 were not completed as of 30th June 2021. \uf0b7 Failure to implement planned activities despite availability of funds. \uf0b7 I noted that the Board sat only once during the year under review on 16th September 2020. I also noted that the Chairperson of the meeting did not sign the minutes for the meeting. \uf0b7 I noted that the Board had not developed some governance policies, manuals and other documents that would help in the smooth running of", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 245, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "233", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 245, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["the Authority. \uf0b7 The Authority received from the Treasury UGX.13,237,853,910 for the last three financial years to deliver its mandate; however, no tangible results are indicating that it is effective. \uf0b7 I established that procurements worth UGX.62,390,000 were implemented during the year, and yet they were not in the Authority\u2019s consolidated procurement plan.", null, null, null], ["5", "Competitiveness and Enterprise Development Project (CEDP) Component 2-5 IDA Credit Agreement", null, "\uf0b7 Competitiveness Enterprise Development Project (CEDP) approved budget for the Financial Year 2020/2021 was UGX.24.18Bn Comprising: UGX.23.5Bn IDA funding and UGX.742.3Mn GoU contributions. Expenditure was UGX.17.4Bn, yielding a 72% budget performance."], [null, "CR 52690-UG PROJECT ID P130471. 2020/21", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 246, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None", "None"], "type": "table"}}, {"content": [["the Authority. \uf0b7 The Authority received from the Treasury UGX.13,237,853,910 for the last three financial years to deliver its mandate; however, no tangible results are indicating that it is effective. \uf0b7 I established that procurements worth UGX.62,390,000 were implemented during the year, and yet they were not in the Authority\u2019s consolidated procurement plan.", null, null, null], ["5", "Competitiveness and Enterprise Development Project (CEDP) Component 2-5 IDA Credit Agreement", null, "\uf0b7 Competitiveness Enterprise Development Project (CEDP) approved budget for the Financial Year 2020/2021 was UGX.24.18Bn Comprising: UGX.23.5Bn IDA funding and UGX.742.3Mn GoU contributions. Expenditure was UGX.17.4Bn, yielding a 72% budget performance."], [null, "CR 52690-UG PROJECT ID P130471. 2020/21", null, null], [null, "Opinion Unqualified", null, ""], [null, null, null, "completed by 25th April 2019, and several extensions were entered into"], [null, null, null, "up to 30th June 2021. By the time of my field inspection, construction"], [null, null, null, "was still ongoing."], ["6 Great Lakes Trade Facilitation Project (GLTFP). 2020/21 Opinion Unqualified \uf0b7 I noted that the project management had failed to achieve its objectives by the initial project closure date of 31st December 2020. \uf0b7 As at 30th June 2021, a total of UGX.6.862Bn representing 62% was available for spending as indicated in the Statement of Financial performance leaving a budget deficit of UGX.4.106Bn representing 38%. \uf0b7 Audit noted that out of UGX.6.862Bn total funds available for use during the year, the project managed to utilize UGX.4.423Bn in the implementation of various project activities, leaving an unspent balance of UGX.2.439Bn (25% of the available funding).", null, null, null], ["7", "Ministry of Trade, Industry and Cooperatives 2020/21", null, "\uf0b7 I reviewed the approved revenue estimates for the financial year 2020/2021 and noted that the Ministry budgeted to receive Revenue of UGX.233.147Bn during the year under review. The entity received"], [null, null, null, "UGX.230.417Bn as releases from the consolidated fund representing the"], [null, "Opinion Unqualified", null, "overall performance of 98%."], [null, null, null, "\uf0b7 The Ministry budgeted to collect UGX.0.072Bn but realised UGX.0.053Bn, hence a shortfall of UGX.0.019Bn representing 25.4% of the budget."], [null, "", "", "\uf0b7 Out of UGX.230.417Bn released for various activities, UGX.229.123Bn was"], [null, "", "", "spent by the entity resulting into an unspent balance of UGX.1.294Bn"], [null, "", "", "representing an absorption level of 99%."], [null, "", "", "\uf0b7 Analysis of the vote performance revealed that a number of programs"], [null, "", "", "remained outstanding at the year-end, leaving a total unspent balance of"], [null, "", "", "UGX.2.0726Bn."], [null, "", "", "\uf0b7 The entity charged different expenditure codes for several expenditure"], [null, "", "", "items from those stipulated in the chart of accounts. This resulted in"], [null, "", "", "mischarging of expenditures worth UGX.81,083,608."], [null, "", "", "\uf0b7 Analysis of domestic arrears over the past three years has shown an"], [null, "", "", "upward trend in arrears from UGX.10.4Bn in 2018/19 to UGX.19.4Bn in"], [null, "", "", "2020/21."], [null, "", "", "\uf0b7 I observed that the Ministry had not paid verified domestic arrears worth"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 246, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None", "None"], "type": "table"}}, {"content": "234", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 246, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "UGX.16.743Bn."], [null, "\uf0b7 I noted that the Ministry accrued domestic arrears worth UGX.242Mn"], [null, "during the financial year."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 247, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None"], "type": "table"}}, {"content": [["", "UGX.16.743Bn."], [null, "\uf0b7 I noted that the Ministry accrued domestic arrears worth UGX.242Mn"], [null, "during the financial year."], [null, "\uf0b7 I noted that a total of UGX.159,543,267 paid to service providers and"], [null, "advances to various staff was not adequately supported with"], [null, "accountabilities and supporting documents such as requisitions, receipts,"], [null, "activity reports, minutes of meetings."], [null, "\uf0b7 Payments amounting to UGX.73Mn were advanced to personal accounts"], [null, "of staff to make onward payments to suppliers for services like office"], [null, "internet, hotels, workshop related expenditure, among others."], [null, "\uf0b7 I noted that as of 30th June 2021, several compensations claim worth"], [null, "UGX.165Bn by some Cooperative Societies had not been verified. There"], [null, "was also no evidence that verification teams had been constituted to"], [null, "undertake the verification exercise."], [null, "\uf0b7 Examination of records revealed that for some Cooperatives, the amounts"], [null, "to be paid as compensation for war losses were in excess of the amounts"], [null, "originally claimed by the Cooperatives."], [null, "\uf0b7 I noted that payments amounting to UGX.14Bn were made to persons"], [null, "and law firms other than the beneficiary Cooperative Societies."], [null, "\uf0b7 review of the procurement processes revealed that, for eight (8)"], [null, "procurements valued at UGX.282,626,237, the estimated market prices"], [null, "approved by the Accounting Officer on Form 5, were the same as those"], [null, "quoted by the best-evaluated bidder and subsequently awarded. I"], [null, "observed that the evaluation committee and Contracts committees did"], [null, "not detect the questionable coincidence."], [null, "\uf0b7 The ministry acquired a lease on an already existing lease for land and"], [null, "subsequent loss of funds."], ["8 Uganda National Bureau of Standards. 2020/21 Opinion Unqualified \uf0b7 The Beareau was unable to activate the use of the Digital Tracking System (DTS) to enforce conformity to standards of selected items and claim the associated fees due to absence of an enabling regulation to operationalise the Service. As a result, the Buereau was unable to claim for a total of UGX.13Bn charged on goods and services for conformity stamps issued by the provider towards conformity enforcement. There is a risk of misuse of the amounts involced by the private provider. \uf0b7 The Bureau released 366 consignments without testing due to lack of capacity and another 633 consignments released due to the absence of standards to test these commodities for conformity. Lack of capacity may lead to the release of sub-standard products to the market. \uf0b7 I noted that out of the approved staff structure of 666 positions, the Bureau had only filled 439, leaving a staffing gap of 227 (34 %). As a result, there was staff presence at only 27 out of the 170 border entry points. There is a risk of sub-standard goods entering the country through border points where the Bureau staffs are not present. \uf0b7 It was noted that procurements to the tune of UGX.2.735Bn were not completed as of 30th June 2021. This was attributed to several reasons, including failure to attract competitive bidders for some procruements, delayed submission of clear specifications, especially for specialised equipment, late submissions/ initiations of procurement requisitions by the users, as well as delayed deliveries due to COVID-19 especially for specialised Equipment. Un implemented activities imply that the provision of critical government programs and associated services were delayed.", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 247, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None"], "type": "table"}}, {"content": "235", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 247, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["9", "Uganda Development Corporation (UDC). 2020/21", "\uf0b7 Out of the total funds received of UGX.137.27Bn only UGX.63.39Bn was spent by the entity during the year, resulting into an unspent balance of UGX.73.88Bn representing an absorption level of only 46%. I noted that"], [null, null, "out of the 17 development project activities planned to be implemented"], [null, "Opinion Unqualified", "during the period under review, only (3) three development projects were fully implemented, while Five (5) development projects were partially"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 248, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["9", "Uganda Development Corporation (UDC). 2020/21", "\uf0b7 Out of the total funds received of UGX.137.27Bn only UGX.63.39Bn was spent by the entity during the year, resulting into an unspent balance of UGX.73.88Bn representing an absorption level of only 46%. I noted that"], [null, null, "out of the 17 development project activities planned to be implemented"], [null, "Opinion Unqualified", "during the period under review, only (3) three development projects were fully implemented, while Five (5) development projects were partially"], [null, null, "implemented, Eleven (11) projects were not implemented at all. Failure to"], [null, "", "fully absorb funds by the Corporation, leads to non-achievement of"], [null, null, "development objectives."], [null, null, "\uf0b7 The UDC Act 2016 requires capitalisation of UDC to the tune of"], [null, null, "UGX.500Bn. The same Act also established an Industrial and Economic"], [null, null, "Development Fund which was to be run by the UDC. However, 5 years"], [null, null, "later, the company has never been capitalised to that tune; currently the"], [null, null, "capitalisation grants have accumulated to UGX.311Bn and the Industrial"], [null, null, "and Economic Development Fund has never been operationalized. The"], [null, null, "current funding model, is such that capitalisation grants over the years"], [null, null, "come assigned to specific projects which nullifies the investment appraisal"], [null, null, "process of UDC. This has the disadvantage of earmarking funds for"], [null, null, "investments that are not ready or even viable leading to the low"], [null, null, "absorption noted above."], [null, null, "\uf0b7 An amount of UGX.30.46Bn was invested in various companies by UDC"], [null, null, "during the year without valuation. Shareholding in these companies had"], [null, null, "not been secured by the time of reporting. There is a risk of loss of value."], [null, null, "\uf0b7 Although the UDC Act 2016 provides that the Corporation will take over"], [null, null, "the interest of government in seven entities specified in schedule 2 and to"], [null, null, "manage, promote and facilitate the interest of the government in those"], [null, null, "entities, 5 years later, this had not been done except for Nile Hotel"], [null, null, "Limited. The other entities include: Amber House Limited, Embassy"], [null, null, "House, Development House, Munyonyo Commonwealth Resort, Phoenix"], [null, null, "Logistics and Tri-Star Apparels Limited. There is a risk of loss of strategic"], [null, null, "direction and government may not be aware whether the national"], [null, null, "objectives of import substitution, employment and industrialization are"], [null, null, "being met by these entities."], ["10 Uganda Investment Authority. 2020/21 Opinion Unqualified \uf0b7 The Authority received off-budget financing to a tune of UGX.50.43Bn, which was not transferred to the consolidated fund as required by law. These funds were received directly from development partners to the EPC contractor for the Development of infrastructure at Kampala Industrial and Business Park, Namanve. Off-budget financing distorts planning, may result into duplication of activities and is contrary to the Public finance Management Act 2015. \uf0b7 The approved budget estimates for the Authority for the financial year 2020/2021 indicated that only UGX.22Mn out of UGX.2.411Bn was budgeted towards the settlement of domestic arrears. The arrears balance of UGX.2.389Bn was therefore not budgeted for settlement. Failure to provide resources for the accumulated arrears increases outstanding obligations. \uf0b7 The Authority continued to accumulate domestic arrears with a total of UGX.1.768Bn incurred in the financial year under review, without clearing outstanding arrears from the previous financial year 2019/2020 of UGX.2.411Bn. The total accumulated domestic arrears stood at UGX.4.18Bn at 30th June 2021. This is an indicator of non adherence with the commitment control system of government. \uf0b7 During inspections countrywide, I observed that the industrial parks lack or had inadequate infrastructures like roads, solid waste and sewage", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 248, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "236", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 248, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["management systems, power supply, street lights etc. The Parks have been characterized by encroachment, farming and cattle grazing, degradation of nearby swamps, unallocated land, idle land allocated to unserious investors and misunderstandings between investors and park management staff. Most roads are impassable and with inadequate lighting which exposes the parks to thefts and insecurity. I observed that some factories in the parks have set up their own infrastructure which may not be sustainable, and to the desired standards. This may negatively affect the usage and utilization of the parks. \uf0b7 The Authority lacks regulations required under Section 38(1) of the Investment Code Act to operationalize the statute. This may hinder the smooth implementation of the Act which is meant to create an investment enabling environment. \uf0b7 Although the Authority has 124 approved positions, only 78 (i.e. 62.9%) are filled, leaving 46 (37.1%) vacant positions. Among the vacant positions include 24 unfilled positions that are from the core Directorate of Investment which is the backbone of UIA. Understaffing undermines service delivery.", null, null], ["", "TOURISM SECTOR", "\uf0b7"], ["1 Uganda Hotel and Tourism Training Institute (UHTII) 2020/21 Opinion Unqualified \uf0b7 Management failed to collect tuition fees and accumulated receivables to the tune of UGX.460Mn by close of the financial year, with some debts dating as far back as 2014. I observed that some students who had not cleared fees had completed their studies, graduated and even obtained their certificates rendering such receivables uncollectible. \uf0b7 I noted that the entity had prepared a new strategic plan, but had no proof of certification and approval of its plan by NPA. Management explained that the exercise was interrupted by Covid-19 Lock down and closure of schools. \uf0b7 Out of 175 approved posts for the Institute, only 127 were filled, resulting into a staffing gap of forty-eight (48) positions. Furthermore, seven (7) positions were filled by staff in an acting capacity including the Position of the Principal. Staffing gaps limit the Institute\u2019s ability to effectively deliver the intended services.", null, null], ["2", "Uganda Hotel and Tourism Training Institute. 2019/20", "\uf0b7 I noted that the budget is not aligned to the specific outputs and therefore, I could not analyze the outputs achieved and planned in line with the approved budget."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 249, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "237", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 249, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "Stock cards and Goods Received Notes."], ["3 Uganda Wildlife Education Conservation Centre (UWEC). 2019/20 Opinion Unqualified \uf0b7 Out of the 29 quantified outputs/activities assessed, 20 outputs/activities representing 69% were fully implemented; 4 outputs/activities representing 14% were partially implemented while 5 outputs/activities representing 17% were not implemented at all. \uf0b7 I noted that out of the budgeted NTR of UGX.5,360,000,000; only UGX.3,737,222,734 was collected representing performance of only 70% of the target. \uf0b7 I noted that the construction of the floating restaurant stalled. To date, the project is still at the first-floor stage and has since not been opened to the public. \uf0b7 A review of UWEC records revealed that UGX.6.6million was spent for resurveying the land on which the Centre is located. However, by the time of audit, the title had not been transferred to the Centre\u2019s names.", null, null], ["4", "Uganda Wildlife Research and Training Institute (UWRTI).", "\uf0b7 I observed that out of the budgeted NTR of UGX.435,000,000, only UGX.328,287,026 was collected representing a performance of 75% of the target."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 250, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "Stock cards and Goods Received Notes."], ["3 Uganda Wildlife Education Conservation Centre (UWEC). 2019/20 Opinion Unqualified \uf0b7 Out of the 29 quantified outputs/activities assessed, 20 outputs/activities representing 69% were fully implemented; 4 outputs/activities representing 14% were partially implemented while 5 outputs/activities representing 17% were not implemented at all. \uf0b7 I noted that out of the budgeted NTR of UGX.5,360,000,000; only UGX.3,737,222,734 was collected representing performance of only 70% of the target. \uf0b7 I noted that the construction of the floating restaurant stalled. To date, the project is still at the first-floor stage and has since not been opened to the public. \uf0b7 A review of UWEC records revealed that UGX.6.6million was spent for resurveying the land on which the Centre is located. However, by the time of audit, the title had not been transferred to the Centre\u2019s names.", null, null], ["4", "Uganda Wildlife Research and Training Institute (UWRTI).", "\uf0b7 I observed that out of the budgeted NTR of UGX.435,000,000, only UGX.328,287,026 was collected representing a performance of 75% of the target."], [null, "2019/20 Opinion", null], [null, "Unqualified", ""], [null, null, "procure particular items or pay other staff members yet the funds in"], [null, null, "question, could have been paid directly to the intended final beneficiaries."], [null, null, "\uf0b7 A review of the staffing structures for the UWRTI revealed that, out of"], [null, null, "the total approved structure of 46 staff, only 23 (50%) positions were"], [null, null, "filled while 23 (50%) positions had not yet been filled."], [null, null, "\uf0b7 I noted that several direct procurements amounting to UGX.122,943,179"], [null, null, "were made by the entity without justification for use of the direct"], [null, null, "procurement method."], [null, null, "\uf0b7 I observed that the Governing Council is not fully constituted, since a"], [null, null, "representative of the Academic Board has not been nominated."], ["5 The Handicraft and Souvenir Development Project (HSDP) in Uganda for the year ended 31 st Dec 2020. Opinion Unqualified \uf0b7 I noted that cumulatively a total of USD.940,460.00 had been disbursed to the Project by 31st December 2020, out of which USD.430,916.94 had been utilized, leaving a closing balance of USD.509,543.06 as at 31st December 2020. \uf0b7 It was also noted that no activity had been fully implemented/completed as of the time of this audit as they all remained either partially achieved or not achieved at all.", null, null], ["6", "Nile Hotel 2020/21 Opinion Unqualified", "\uf0b7 I noted that out of the budgeted revenue of UGX.2.041Bn from Concession fees and Investment income from fixed deposits, only UGX.1.191Bn was received, representing a performance of only 58% of the target. Failure to realise all budgeted revenue affects the implementation of planned activities. This was attributed to the effects of"], [null, null, "the COVID19 pandemic on the Tourism sector."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity is not in possession and is not aware of the exact"], [null, null, "whereabouts of the land title to the land on which Serena Hotel Kampala,"], [null, null, "is seated. The land is located on Plot 16-20 Nile avenue measuring 19.3"], [null, null, "acres. The land is listed as part of the assets in the concession agreement"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 250, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "238", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 250, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "that was signed between the Government of Uganda and TPS Uganda"], [null, null, "Limited and was leased by ULC and Nile Hotel International Ltd (NHIL) in"], [null, null, "1995."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 251, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "that was signed between the Government of Uganda and TPS Uganda"], [null, null, "Limited and was leased by ULC and Nile Hotel International Ltd (NHIL) in"], [null, null, "1995."], ["7 Uganda Wildlife Authority. 2020/21 Opinion Unqualified \uf0b7 This being the first year of implementation of the NDP-III, the entity was expected to prepare a strategic plan aligned to NDP III and ensure that the plan was approved. \uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity budgeted to collect NTR of UGX.82.Bn (Exclusive of UGX.30Bn prior-year surplus approved for re-investment during the year under review). \uf0b7 The entity budgeted to receive UGX.6.24Bn from donors, however, UGX.5.74Bn was realized, resulting into a shortfall of UGX.501Mn (8%) of the budget. \uf0b7 The entity budgeted to receive UGX.0.72Bn, out of which UGX.0.762Bn was received, resulting into an excess receipt of UGX.0.042Bn, representing 5.8% of the budget \uf0b7 I noted that Management re-assessed its revenue performance and requested the Board to approve a contingency plan to limit the expenditure of the Authority to only UGX.72.595Bn in line with the reduced revenue collections to finance only priority activities in the original approved budget of UGX.119.469Bn for FY 2020-2021. \uf0b7 I noted that the Authority prepared and submitted all the quarterly reports to the line ministry. However, there were delays in submission of Q1, Q2 & Q4 performance reports due to the effect of the covid-19 pandemic. \uf0b7 I noted decreasing Tourism Revenues due to Covid-19 Effect. \uf0b7 It was observed that the Authority has a total outstanding receivables balance of UGX.3.303Bn in the statement of financial position, of which UGX.2.244Bn are unpaid overdue fees from concessionaires that have been outstanding for more than a year. \uf0b7 It was noted that the entity has outstanding payables of UGX.71.655Bn in the statement of financial position of which UGX.8.422Bn are accrued staff gratuity that becomes due at the end of each staff\u2019s four year contract. \uf0b7 UWA had only disbursed UGX.642,455,690 in respect of revenue sharing for the surrounding communities in Lake Mburo National Park, leaving a balance of UGX.9,697,730,137 un-disbursed. \uf0b7 The Accountabilities of the disbursed grants have not yet been availed by the beneficiary communities through to the district local governments by the time of audit on 3rd November 2021. \uf0b7 I noted that whereas the Human Resource unit is critical in managing staff-related affairs, it is only situated at the headquarters and comprises five (5) staff. \uf0b7 Non-integration of gorilla booking system to the accounting system. \uf0b7 It was noted that most of the Protected Areas in Uganda are currently undergoing ecosystem changes as rangeland infestation by invasive and exotic plant species.", null, null], ["8", "Wildlife Research and Training Institute 2020/21", "\uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity budgeted to collect NTR of UGX.0.495Bn during the year under review. Out of this,"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 251, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "239", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 251, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "only UGX.0.200Bn was collected, representing a performance of 40.6% of"], [null, "Opinion Unqualified", "the target. \uf0b7 The entity budgeted to receive UGX.3.931Bn during the period, out of"], [null, null, "which UGX.2.531Bn was warranted, resulting into a shortfall of"], [null, null, "UGX.1.4Bn, which is 36% of the budget."], [null, null, "\uf0b7 A review of the staffing structure for UWRTI revealed that out of the total"], [null, null, "approved structure of 47 staff, only 23 (49%) positions were filled and 24"], [null, null, "positions (51%) had not yet been filled."], [null, null, "\uf0b7 A review of the procurement files revealed that the Institute awarded"], [null, null, "contracts to various providers totalling UGX.519Mn without carrying out"], [null, null, "market assessments/surveys."], ["9 Uganda Wildlife Education Conservation Centre. 2020/21 Opinion Unqualified \uf0b7 I noted that UWEC is one of the entities affected by the Government rationalisation policy on mergers anticipated to be concluded in 2023. By the time of reporting, discussions on transitional arrangements were ongoing. However, I was not provided with the transitional plans for a smooth merger. Delayed decision making leads to costly mergers and uncertainity amonst the stakeholders. \uf0b7 Five (5) procurements with a total value of UGX.3.239Bn were not implemented as planned due to insufficient release of funds from GOU and the adverse effects of the covid-19 pandemic resulting into delayed service delivery. \uf0b7 Although some electronic equipment and motor vehicles at cost of UGX.331Mn had been fully depreciated as per the previous financial year, they were still in use. Under the circumstances, the benefits accruing from them are not matched with their usage/expenditure. Management explained that the revaluation of assets had started, but COVID \u2013 19 effects hindered the process.", null, null], ["10", "Ministry of Tourism, Wildlife and Antiquities. 2020/21. Opinion Unqualified", "\uf0b7 The entity budgeted to receive UGX.27.408Bn out of which UGX.22.934Bn was warranted, resulting into a shortfall of UGX.4.474Bn which is 16.3% of the budget. This affected implementation of planned activities. I further noted that the Ministry did not seek a revision of its budget and work plan, as provided for by Section 17 (3) of the PFMA 2015, following the revenue shortfall."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 252, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "240", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 252, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 Attention is drawn to Note 19 of the financial statements in which"], [null, null, "management made a provision to reduce the receivable amount from"], [null, null, "UGX.13Bn to UGX.3.2Bn given the preliminary findings by a company"], [null, null, "engaged to assess recoverability of the funds."], ["11 Uganda Tourism Board. 2020/21 Opinion Unqualified \uf0b7 Contrary to Section 45 (3) of the Public Finance and Management Act, 2015, the Board failed to implement procurements worth UGX.2.79Bn which had been indicated in their procurement plan. Unimplemented procurements signify unimplemented activities and therefore delayed service delivery. \uf0b7 Contrary to Section 26 (4) of the PPDA 2003, procurements for stationery worth UGX.1.67Bn were concluded without carrying out market assessments. As a result, I could not establish how the estimated unit cost for these procurements was arrived at, thus implying that the procurements may have been awarded at exorbitant costs. \uf0b7 A review of the Board's establishment structure revealed that 38 posts out of the approved 85 remained vacant during the year, indicating a 45% understaffing level. Most notable among the vacant positions are key staffs like the Director Marketing, Director Quality Assurance, Director Finance and planning, and Manager Human Resource. Inadequate staffing levels not only deprive the entity of the skills required to enhance service delivery but also frustrates segregation of duty.", null, null], ["", "WATER AND ENVIRONMENT SECTOR", "\uf0b7"], [null, null, ""], ["1 Kampala Sanitation Program (KSP) Closure 2020/21 Opinion Unqualified \uf0b7 Contingent Liabilities \uf0b7 A contractor\u2019s global claim of Euros 25,043,073 arising from the contractual obligation of extension of time and causation of delays in project completion which was approved; \uf0b7 A compensation claim of UGX220 Million which is now before the Land Division of the High Court Civil suit No.109 of 2019 and thus the outcome of the compensation claim will be determined by court; \uf0b7 A compensation of UGX1.15 Billion which is now before the Land Division of the High Court HCCS NO. 518 of 2016 and thus the outcome of the compensation claim will be determined by court.", null, null], ["2.", "National Forestry Authority 2020/21", "\uf0b7 The Authority prepared and had its strategic plan for the period 2020/2021 to 2024/2025 approved by the Board, however there was no certification from NPA."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 253, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "241", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 253, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "was not implemented at all."], [null, null, "\uf0b7 I noted a significant receivables balance of UGX 8,268,255,693 at close of"], [null, null, "the financial year which impacts the liquidity capacity of the Authority."], [null, null, "\uf0b7 There were irregularities in forest land utilization with four (4) unlicensed"], [null, null, "Central Forest Reserves (one in Kajansi and three in Lutoboka) and 24"], [null, null, "non-complying developers in CFRs."], [null, null, "\uf0b7 I noted irregularities in forest land utilization, inactive private tree"], [null, null, "planters in CFRs, non-operationalisation of the Tree Fund, Out-dated"], [null, null, "Forest Reserve Management Plans and major encroachment on CFRs."], ["3 Uganda National Meteorological Authority (UNMA). 2020/21 Opinion Unqualified \uf0b7 The Authority collected NTR of UGX 317,259,177 out of the estimated UGX 1,259,080,696 representing a performance of 25.2%. \uf0b7 Out of the budgeted revenue of UGX 26,675,604,875, only UGX 19,025,934,156 was realized representing performance level of 71.3% of the target. Out of UGX 19,025,934,156 warranted, UGX 17,970,307,440 was absorbed by the authority leaving unspent balance of UGX 1,295,279,000 representing 94.5% absorption level. \uf0b7 The Authority received off-budget financing of UGX. 668,042,740 \uf0b7 Five (5) outputs with a total of twenty-eight (28) activities and expenditure worth UGX 5,094,648,000 were fully quantified, while Three (3) outputs with a total of thirty-seven (37) activities and expenditure worth UGX 2,682,683,000 were insufficiently quantified. \uf0b7 Of the 5 outputs with 28 fully quantified activities, 7 activities (25%) were fully implemented, 10 activities (35.7%) were partially implemented, while 11 activities (39.3%) remained unimplemented. \uf0b7 There was delayed completion of the Radars in Mwizi-Rwampara and Lira due to the restrictions of Covid 19 lockdown. \uf0b7 The average functionality of all the weather stations is at 89% instead of the desired 100% resulting from the non-functional meteorological equipment.", null, null], ["4", "Investment plan preparation grant for the strategic plan for climate resilience.", "\uf0b7 Two out of the three (3) sub objectives of the Project, were fully achieved while the third objective of building capacity of both national and subnational stakeholders in the management of climate change disasters was partially achieved."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 254, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "242", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 254, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "were not remitted to the Uganda Revenue Authority."], ["5 Integrated Water Management and Development Project- NWSC 2020/21 Opinion Unqualified \uf0b7 No material findings to report.", null, null], ["6", "National Water and Sewerage Corporation- Kampala Water Lake Victoria Water and Sanitation (KW-LV WATSAN", "\uf0b7 I noted that NWSC delayed to pay the Contractor and as a result, the contractor claimed for interest of Euros 141,968 approximately UGX.610 Million. I also noted changes in the scope of the contract which resulted into a contract variation of Euros 612,000 (approximately UGX 1.4 Billion)."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 255, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "were not remitted to the Uganda Revenue Authority."], ["5 Integrated Water Management and Development Project- NWSC 2020/21 Opinion Unqualified \uf0b7 No material findings to report.", null, null], ["6", "National Water and Sewerage Corporation- Kampala Water Lake Victoria Water and Sanitation (KW-LV WATSAN", "\uf0b7 I noted that NWSC delayed to pay the Contractor and as a result, the contractor claimed for interest of Euros 141,968 approximately UGX.610 Million. I also noted changes in the scope of the contract which resulted into a contract variation of Euros 612,000 (approximately UGX 1.4 Billion)."], [null, "I) PROJECT 2020/21", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["7 NATIONAL ENVIRONMENT MANAGEMENT AUTHORITY Opinion Unqualified \uf0b7 The Authority collected NTR of UGX.8,084,594,955 (50.2%) against the estimated UGX.16,088,769,336 as projected by Ministry of MOFPED. However, there were no NTR estimates indicated in the statement of appropriation. \uf0b7 Out of the budgeted GoU revenue of UGX.25,555,655,669 by the Authority, only UGX 18,809,799,829 was warranted representing performance of 73.6% of the target. \uf0b7 I noted that out of the UGX.18,809,799,829 released to the Authority, only UGX.18,494,875,926 was spent representing an absorption level of 98.3%. Subsequently, the unspent funds amounting to UGX.314,923,903 were swept back to the Consolidated Fund. \uf0b7 The Authority received off-budget funding to the tune of UGX.1,963,413,072 and USD 2,805,651,484 which were not appropriated as required by the law. \uf0b7 9 (69%) of the 13 activities (against which UGX 9,707,487,720 was released) were fully implemented and 4 (31%) of the activities were partially implemented. \uf0b7 Contrary to the directive from the Ministry of Finance, during the financial year a total of UGX 441,857,268 was deposited directly into the National Environment Fund (NEF) account as NTR and this amount was not remitted to the consolidated fund. \uf0b7 The Authority does not have any legal provision to regulate the work of the Environment Police. In addition, the funds to facilitate the work of the force were not budgeted for in the annual work plan and budget. Financial records indicate that only UGX.21,280,000 was spent on the force during the year. \uf0b7 I noted that all the wetlands in Uganda are not gazetted, contrary to Section 2 of the National Environment Act 2019, although they are indicated on the maps. In addition, contrary to Instrument 2 of the Nation Environment Act, 2019 (Commencement) that empowers the Authority to enforce wetland gazetting, the Authority went ahead to collect NTR from wetland user permits amounting to UGX 8,800,000", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 255, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "243", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 255, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["during the financial year 2020/21.", null, null], ["8", "Strategic Towns Water Supply and Sanitation Project. 2020/21", "\uf0b7 Out of the total budget of UGX 40 Bn for the financial year, only UGX 19.24 Bn was received representing a performance level of 48%. Out of the amount received, UGX.18.88 Bn was spent during the year representing an absorption level of 98.13%."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 256, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["during the financial year 2020/21.", null, null], ["8", "Strategic Towns Water Supply and Sanitation Project. 2020/21", "\uf0b7 Out of the total budget of UGX 40 Bn for the financial year, only UGX 19.24 Bn was received representing a performance level of 48%. Out of the amount received, UGX.18.88 Bn was spent during the year representing an absorption level of 98.13%."], [null, "Opinion Unqualified", null], ["9 Irrigation for Climate Resilience Project 2020/21 Opinion Unqualified \uf0b7 Out of the budgeted revenue of USD 13,641,026, only USD 6,305,937 (46.2%) was realized representing performance level of 46.2% of the target. Out of USD 6,305,917, disbursed, there was no absorption by the project as at close of the financial year. \uf0b7 Twenty-two (22) outputs with a total of thirty three (33) activities and budget of USD 13,641,026 were fully quantified as required. Out of 22 outputs with a total of 33 activities, only 1 activity (3%) was fully achieved, 27 (82%) were partially achieved and 5 activities (15%) were not implemented at all.", null, null], ["10", "Enhancing Resilience of Communities to Climate Change (EURECCCA)", "\uf0b7 At the end of the initial project completion date of 30th April 2021, all the four project components had been partially achieved and thus, the project completion date was extended to 30th April 2022."], [null, "2020/21 Opinion Unqualified", null], [null, "", ""], [null, null, "quantified to enable assessment of performance and enhance"], [null, null, "accountability. Out of the 42 planned activities 19 (45.2%) were fully"], [null, null, "implemented, 22 (52.4%) were partially implemented and 1(2.4%) was"], [null, null, "not implemented at all."], ["11 Nyabyeya Forestry College (NFC) Opinion Unqualified \uf0b7 The College does not have an approved strategic plan for the period 2021-202 and lacks an enabling law that stipulates its mandate. There is a risk that activities implemented during the financial year 2020/2021 were not aligned to the NDP-III, which negatively affects the achievement of the National Development objectives \uf0b7 Out of the total receipts of UGX 2,753,839,117 for the financial year, UGX 2,911,962,444 was spent resulting into an over expenditure of UGX 158,123,327 representing an absorption level of 106%. The over absorption of funds was due to the opening balances for civil works executed even during the Covid-19 lockdown. \uf0b7 I noted a decline in students\u2019 enrolment from 431 students in 2016/17 to 256 students in 2020/21. Continued fall in enrolment may result in the College\u2019s failure to achieve its mandate of producing technical human resource in forestry and related natural resources through training.", null, null], ["12", "Farm Income Enhancement and Forestry Conservation Project Phase II (FIEFOC", "\uf0b7 The Project has not fully achieved the three project subcomponents of Agriculture Infrastructure Development, Agribusiness Development and"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 256, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "244", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 256, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "II).", "Integrated Natural resources Management which had been set to be"], [null, "2020/21", "achieved by 30/06/2021."], [null, null, "\uf0b7 The project had an approved annual budget of UGX 111,249,503,000 out"], [null, "Opinion", "of which UGX 63,414,586,000 (57%) was received leading to a shortfall of UGX 47,834,917,000. \uf0b7 Out of the total funds received of UGX 63,414,586,000, a total of UGX"], [null, "Unqualified", null], ["13 Integrated Water Management and Development Project (IWMDP) 2020/21 Opinion Unqualified \uf0b7 Out of the approved budget of UGX 70,327,857,900, UGX.52,949,933,856 (75.3%) was availed for spending leading to a shortfall of UGX.17,377,924,044. Out of the total funds available for the financial year of UGX.52,949,933,856, UGX.20,830,393,625 was spent representing an absorption level of only 39.3%. \uf0b7 Fifteen (15) outputs with a total of twenty-seven (27) activities and expenditure worth UGX.14,957,387,000 were fully quantified, while one (1) outputs with one (1) activity was inadequately quantified. \uf0b7 Of the 15 outputs with 27 fully quantified activities, 2 out puts (13%) were fully implemented, 6 out puts (40%) were partially implemented while 7 out puts (47%) were not implemented. \uf0b7 Review of the project appraisal document, the monitoring and results framework analysis report of October 2021 together with annual progress reports revealed that the rate of achievement of project targets is slow as a result of procurement delays.", null, null], ["14", "Northern Uganda Resilience Initiative Project 2020/21", "\uf0b7 Out of the total rolled over funds of UGX.1,520,434,217 from the previous financial year, the project spent UGX.1,055,516,512 (69%) leaving an unspent balance of UGX.464,917,705 (31%). \uf0b7 Out of the 17 planned activities for the financial year 2020/2021, only 2 activities were quantified as required leaving 15 activities unquantified."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 257, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "245", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 257, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["15 Third National Communication (TNC) 2020/21 Opinion Unqualified \uf0b7 Out of an approved budget of USD.173,474, USD.83,000 was disbursed representing a performance level of 47.8% of the target. \uf0b7 Out of the total available funds for the year of US$ 92,304.34, the project spent US$ 60,493.32 representing an absorption level of 65.6%. As a result some activities were not implemented. \uf0b7 All the 16 outputs with a total budget of USD.173,474 and actual expenditure of 60,555.97 were not quantified at all.", null, null], ["16", "Water Supply and Sanitation on Refugee Hosting Communities in", "\uf0b7 Out of the Project budget of UGX. 20,868,100,000, a sum of UGX 9,204,079,893 was disbursed by the donor, representing a performance level of 44.1% of the target."], [null, "Northern Uganda Funded By (Kfw) Project KfW 2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 258, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["15 Third National Communication (TNC) 2020/21 Opinion Unqualified \uf0b7 Out of an approved budget of USD.173,474, USD.83,000 was disbursed representing a performance level of 47.8% of the target. \uf0b7 Out of the total available funds for the year of US$ 92,304.34, the project spent US$ 60,493.32 representing an absorption level of 65.6%. As a result some activities were not implemented. \uf0b7 All the 16 outputs with a total budget of USD.173,474 and actual expenditure of 60,555.97 were not quantified at all.", null, null], ["16", "Water Supply and Sanitation on Refugee Hosting Communities in", "\uf0b7 Out of the Project budget of UGX. 20,868,100,000, a sum of UGX 9,204,079,893 was disbursed by the donor, representing a performance level of 44.1% of the target."], [null, "Northern Uganda Funded By (Kfw) Project KfW 2020/21 Opinion Unqualified", null], ["17 Uganda National Redd - Plus Support Project Opinion Unqualified \uf0b7 The project had 2 sub components which had not been fully achieved. \uf0b7 The project had an approved revenue budget of USD.644,500 for the year under review but only USD.250,000 (38.8%) was disbursed. \uf0b7 Out of the total funds available for spending of USD.475,919.18, only USD.249,763.51 (52.18%) was spent leaving an unspent balance of $ 226,155.67 (48.82%). As a result certain activities were not implemented. \uf0b7 All the 10 outputs comprising 57 activities with a total budget of USD.2,210,799 were properly quantified. \uf0b7 The draft progress report was not detailed to enable assessment of implementation of activities against planned.", null, null], ["18", "Ministry of Water, and Environment (MoWE) 2020/21", "\uf0b7 I noted that the entity had not prepared a specific strategic plan as required by the NDP III and was instead utilizing an Investment plan (2030). \uf0b7 I noted that out of the estimated NTR collection of UGX 8.97 billion, only UGX1.39 Bn was realized, representing a performance of 15.5%."], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 Out of the total receipts for the financial year of 452.01 Bn, a sum of"], [null, null, "UGX. 453.24 Bn was spent by the entity resulting in an unspent balance"], [null, null, "of UGX 5.58 Bn, representing an absorption level of 98.7%."], [null, null, "\uf0b7 As a result of the under absorption, I noted that of the 72 quantified"], [null, null, "activities worth UGX.388.26Bn assessed; 15 activities representing 27.3%"], [null, null, "were fully implemented, 38 activities representing 69.1% were partially"], [null, null, "implemented,2 activities representing 3.6% were not implemented .I"], [null, null, "further noted that there was delayed submission of performance reports."], [null, null, "\uf0b7 The Ministry incurred penal interest of UGX.103,632,504 (USD.32,218)"], [null, null, "arising from delayed payment to the contractor."], [null, null, "\uf0b7 I noted that the Ministry\u2019s Payables amount significantly increased from"], [null, null, "UGX.64.3 billion in the previous year to UGX.114.5 billion in the current"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 258, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "246", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 258, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "year due to the increasing number of multi-year projects in the ministry."], [null, null, "\uf0b7 I noted that the Ministry\u2019s Receivables amount significantly increased"], [null, null, "from UGX.1.3 million in the previous year to UGX.22.4 billion in the"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 259, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "year due to the increasing number of multi-year projects in the ministry."], [null, null, "\uf0b7 I noted that the Ministry\u2019s Receivables amount significantly increased"], [null, null, "from UGX.1.3 million in the previous year to UGX.22.4 billion in the"], [null, null, "current year. This was attributed to prepayments made to contractors"], [null, null, "(UGX.19.3 billion) and the outstanding letters of credit (UGX.3.1 billion)"], [null, null, "for on-going projects in the Ministry."], [null, null, "\uf0b7 From my audit and field inspection of facilities, regional centres and"], [null, null, "Umbrella Organisations, I observed several weaknesses in service delivery"], [null, null, "such as; untitled land for piped water systems and schemes; delayed"], [null, null, "execution of works; outstanding revenue arrears; unmetered water"], [null, null, "schemes, Lack and faulty bulk meters; among others."], ["19 Support to Priority Irrigation Investments in Uganda Grant 2020/21 Opinion Unqualified \uf0b7 All the budgeted revenue from Government of USD.949,422.62 was realised representing a performance of 100% of the target. \uf0b7 Out of the donar funds of USD.949,422.62 received, only USD 117,475.04 was absorbed by the project representing an absorption level of 12.4%. The Under absorption was attributed to Covid-19 effects. \uf0b7 All the Six (6) outputs with a total of six (6) activities and expenditure of USD.117,475.04 were fully quantified. \uf0b7 Four (4) out of six (6) outputs had not been achieved despite the fact that the initial Project completion period had been 30thJune 2020. This was later extended to 30/06/2021 and another extension to 31/3/2022.", null, null], ["20", "The Adapting to Climate Change In Lake Victoria", "\uf0b7 Out of the budgeted revenue of USD.249,377, only USD.194,645.56 was received representing performance level of 78% of the target."], [null, "Basin. 2020/21 Opinion", null], [null, "Unqualified", ""], [null, null, "were fully achieved, 2 activities (18.2%) were partially achieved and 4"], [null, null, "activities (36.3%) were not implemented at all."], ["21 South Western Cluster Water and Sanitation Project \u2013 NWSC 2020/21 Opinion Unqualified \uf0b7 No material issues to report on", null, null], ["22", "National Water and Sewerage Corporation (NWSC) 2020/21 Opinion Unqualified", "\uf0b7 The financial statements under Note 28 include a Financial Asset in form of Trade Receivables. Management has estimated the fair value of the net financial asset receivable to be UGX 133.7 billion as at 30th June 2021 of which, the net amount of receivables UGX38.2bn is owed from"], [null, null, "the government and its MDA (Ministries; Departments and Agencies). \uf0b7 I noted that NWSC leased vehicles, offices and land under operating lease"], [null, null, "contracts whose terms were more than twelve (12) months, which were classified as; Right of Use asset amortization (UGX 87.8m) Right of Use"], [null, null, "Lease Assets (UGX 12.4bn) and Obligations due to Right of Use Leased"], [null, null, "Assets (UGX 8.4bn). Liabilities were not amortised annually using"], [null, null, "effective interest method in order to arrive at the amortised costs for"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 259, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "247", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 259, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "profit and loss recognition although the necessary disclosures were made"], [null, null, "in the financial statements."], [null, null, "\uf0b7 I noted that freehold land (UGX. 176.5bn) and leasehold land (UGX. 4bn)"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 260, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "profit and loss recognition although the necessary disclosures were made"], [null, null, "in the financial statements."], [null, null, "\uf0b7 I noted that freehold land (UGX. 176.5bn) and leasehold land (UGX. 4bn)"], [null, null, "included some land that had expired lease periods, some titles were not"], [null, null, "yet transferred in the names of NWSC, and Katosi, which is a long term"], [null, null, "investment constructed on a short term leased land of ten (10) years."], [null, null, "\uf0b7 Some on-going water projects were significantly delayed by litigations"], [null, null, "and substantial amounts that are required to compensate the interested"], [null, null, "parties in note 24 of the financial statements."], ["23 Multinational Lakes Edward and Albert Integrated Fisheries and Water Resources Management Project (LEAF) II 2020/21 Opinion Unqualified \uf0b7 A total of six (6) strategic outputs (50%) were fully achieved, while 6 outputs were partially achieved and still on-going (50%). \uf0b7 Out of the approved budgeted revenue of USD 1,887,374, USD 603,588.93 was released representing performance of 32% of the target. \uf0b7 The project had a total available balance of USD 2,767,452.2, out of which USD 2,754,945.85 (99.5%) was spent leading to an unspent balance of only USD 12,506.35. \uf0b7 All the 10 planned outputs with 39 activities and a total budget of USD 3,119,412.9 were properly quantified to enable measurement of performance. \uf0b7 Out of the 39 planned activities under the 3 Project components, 19 (48.7%) were fully implemented, 10 (25.6 %) were partially implemented and 10 (25.6%) were not implemented at all. \uf0b7 I noted delays in construction of infrastructure projects resulting from the effects of the Covid pandemic and effects of the rising water level of Lakes Albert and Edward and inadequate GoU funding. The projects affected included the construction of the surveillance station, Kitebere Landing Site, Mbegu landing site, fish processing facility at Dei Landing site, and supply of a fisheries research vessel.", null, null], ["", "ENERGY SECTOR", "\uf0b7"], ["1 Electricity Regulatory Authority (ERA) 2020/21 Opinion Unqualified \uf0b7 I noted that out of the budgeted revenue of UGX 28.57Bn, a sum of UGX. 27.70Bn was realized representing a performance of 98%. \uf0b7 Out of the revenue realized of UGX. 27.70Bn for the financial year, UGX 24.55Bn was spent on recurrent expenditure and UGX.2.25Bn on capital expenditure, resulting into an unspent balance of UGX.0.9Bn, representing absorption level of 97%. \uf0b7 Out of the forty-six (46) key activities, sixteen (16) (35%) activities had been fully achieved, and thirty (30) (65%) were partially achieved. \uf0b7 Included in the receivables figure of UGX.7,566,003,960, under Note 7 of the Financial Statements is a sum of UGX.724, 185,509, relating to license fees and permit fees which have been outstanding for more than 90 days instead of the recommended 14 days. \uf0b7 I noted that the target of reduction of the end user tariff was not achieved across customers\u2019 categories, with a weighted average of UGX.485.7 per Kwh. The end user off \u2013peak tariff for extra- large industrial customers was achieved at UGX.223.7. \uf0b7 I noted that out of the total staff establishment of 92 positions, only 67 (73%) positions had been filled leaving a balance of 25 (27%) positions vacant.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 260, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "248", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 260, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted Non-compliance to Quality-of-Service Standards (QoS) by Distribution Licensees, with an average of 45% compliance. Non- compliance with QoS denies customers quality and reliable electricity supply.", null, null], ["2", "Energy for Rural Transformation III PSFU Project (ERT III). 2020/21", "\uf0b7 Out of the total Receipts for the financial year of USD. 636,993, only USD.382,224 was spent by the Project resulting in an unspent balance of USD. 254,769 representing absorption level of 60% for the year. As a result, activities such as training of certified wiremen was partially implemented."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 261, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["\uf0b7 I noted Non-compliance to Quality-of-Service Standards (QoS) by Distribution Licensees, with an average of 45% compliance. Non- compliance with QoS denies customers quality and reliable electricity supply.", null, null], ["2", "Energy for Rural Transformation III PSFU Project (ERT III). 2020/21", "\uf0b7 Out of the total Receipts for the financial year of USD. 636,993, only USD.382,224 was spent by the Project resulting in an unspent balance of USD. 254,769 representing absorption level of 60% for the year. As a result, activities such as training of certified wiremen was partially implemented."], [null, "Opinion Unqualified", null], ["3 Uganda Rural Electricity Access Project (UREAP). 2020/21 Opinion Unqualified \uf0b7 Out of the Budget of UGX.157.4Bn, only UGX.106Bn was disbursed representing a shortfall of 51,339,828,177, which is 32.6% of the Budget. I further noted that out of the total receipts for the financial year of UGX. 106.1Bn, UGX.105.5Bn was utilized on installation of Medium Voltage Networks and Last Mile consumer connections, leaving an unutilized balance of UGX.564,461,546 representing an absorption level of 99.5%. \uf0b7 As 30th June 2021, the Bank had disbursed USD.44.83Million and Euros 5.89Million against the Loan credit facility of USD.100 Million and Grant of Euros 11.205 Million representing 45% and 53%, respectively. \uf0b7 I noted delays in construction works under procurement of plants, design, supply and installation of medium voltage networks and last mile consumer connections. Notably, under Lots 6, Medium Voltage stringing, and Low Voltage (LV) stringing had not yet commenced. Under Lot 7 Medium Voltage Pole erection was at 31% and stringing at 47%. \uf0b7 Out of 1,686 Project Affected Persons (PAPs), with an approved compensation amount of UGX.1,240,502,500, only 1,209 PAPs have been paid an amount of UGX.863,758,500, leaving an outstanding amount of UGX.376,744,000 relating to 477 PAPs.", null, null], ["4", "Lira-Gulu-Agago 132KV transmission project 2020/21 Opinion", "\uf0b7 Out of the total Receipts for the financial Year of USD. 2,304,191, only USD.519,117 was utilized by the Project, resulting in an unspent balance of USD.1,785,074, representing an absorption rate of only 22.5%. As a result, activities such as compensation of Project Affected Persons and supervision of EPC works were not implemented."], [null, "Unqualified", null], ["5 Energy for Rural Transformation III (ERT III) \u2013REA Project. 2020/21 Opinion Unqualified \uf0b7 Out of the total receipts for the financial year of UGX.139.5Bn, only UGX.98.3Bn was utilized on installation of Medium Voltage Networks and Last Mile consumer connections, leaving an unutilized balance of UGX 41.2Bn representing an absorption level of 70%. As a result, activities such as Grid extensions, Line connections and Grid Intensification schemes under various Lines were partially implemented. \uf0b7 Out of the total credit amount of USD.116.1 Million, only USD.73.7 Million", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 261, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "249", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 261, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["had been disbursed by the Bank under ERT- REA representing 64% of the Total credit. \uf0b7 The overall Implementation of the Grid extension and associated connections is behind schedule especially under Lines 20-21 which are at 17% and 2% respectively. Progress of work under Grid Intensification, UMEME Batch 1 and 2 were at 55% and 20% respectively. \uf0b7 Out of 34,535 Project Affected Persons (PAPs), with an approved compensation amount of UGX. 22.6Bn, only 22,180 PAPs have been compensated with an amount of UGX.14.2Bn, leaving an outstanding amount of 8.3Bn relating to 12,355 PAPs.", null, null], ["6", "Hoima Kafu Transmission Line Project - Kafu Interconnection Project. 2020/21", "\uf0b7 Out of the total receipts for the financial year, of USD.1,903,946, only USD.41,960 was spent by the Project, resulting in an unspent balance of USD.1,861,986, representing absorption level of only 2.2%. As a result, activities such as compensation of Project Affected Persons were not implemented."], [null, "Opinion Unqualified", null], ["7 Kampala Metropolitan Transmission System Improvement Project. 2020/21 Opinion Unqualified \uf0b7 Out of the total receipts for the financial year of USD.9,259,009 for the financial year, only USD.2,465,150 was spent by the Project, leaving an unspent balance of USD.6,793,859, representing absorption of rate of 26.6%. As a result, I noted that Key activities such as consulting Services for Procurement of the EPC contractor was not implemented, while compensation of projected affected persons was partially implemented. \uf0b7 I noted that out of 130 PAPs, 109 (83%) were compensated. Disclosures made were 120 (91%), agreements obtained from disclosures were 117 (89%), and PAPs not yet compensated were 22 (16.7%).", null, null], ["8", "Petroleum Authority of Uganda (PAU). 2020/21", "\uf0b7 I noted that the Authority budgeted to receive UGX.63.61Bn out of which only UGX.52 Bn was warranted, resulting in a shortfall of UGX11.6Bn, which is 18% of the budget."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 262, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "250", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 262, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "sector. These include; the air quality standards, noise and vibration and"], [null, null, "the chemicals management standards."], ["9 Grid Expansion and Reinforcement Project (GERP)-UETCL. 2020/21 Opinion Unqualified \uf0b7 Out of the total Receipts for the financial year of USD.35,395,297, only USD.6,139,307 was spent by the project leaving an unspent balance of USD.29,255,991, representing absorption of rate of 17.3%. As a result, activities such as construction of Transmission Lines and compensation of Project affected Persons were partially implemented. \uf0b7 Out of the total amount of IDA credit for the Project of USD.100,000,000 only USD.29,457,000(29.4%) was disbursed, and out of USD.27.3M GoU counterpart funding, 7,945,423 (28.9%) was disbursed by the end of the financial Year. \uf0b7 Out of the annual target of 59% progress, under Lot 1; -Construction of 132kv Double Circuit Transmission Lines, only 39% was achieved. Out of a target of 47% progress under Lot 2- construction of Substations, only 20% was achieved. \uf0b7 I noted that out of 2,340 identified PAPs under Gulu-Nebbi-Arua Section, only 1,719 (73%) had been compensated. Out of 994 PAPs under Kole- Gulu Section 985 (99%) were compensated, leaving a total of 630 PAPs not compensated by the time of audit. In addition to the 3,334 PAPs with a total cash resettlement of USD. 1,463,955.41, USD.1,241,137 was paid to 2,704 PAPs resulting into an outstanding obligation of USD.222,818 relating to 630 PAPs", null, null], ["10", "Islamic Development Bank (IDB) III Grid Rural Electrification Project.", "\uf0b7 Out of the total Loan credit of USD.70,730,000 Million by the Islamic Development Bank, USD 69,764,722.91 was disbursed representing a performance of 99% of the total Loan facility."], [null, "2020/21 Opinion Unqualified", null], ["11 Uganda Petroleum Fund (UPF). Opinion Unqualified \uf0b7 I noted that for the year under review, the balance in the Petroleum Fund increased from UGX.87.79Bn as at 30th June 2020 to UGX. 228.79Bn as at 30th June 2021. However, there was no appropriation of UGX. UGX.87.79Bn by during the Financial Year 2020/21 to the Consolidated Fund and/or the Petroleum Revenue Investment Reserve for budget support and investment activities, respectively.", null, null], ["12", "Uganda Electricity Generation Company Limited (UEGCL)", "\uf0b7 Out of the budgeted revenue of UGX.173,191,277,000, for the year 2020/21, UGX.169,743,586,000 was realized representing performance of 98% of the target."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 263, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "251", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 263, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, null, "for Karuma Hydro Power Plant was outstanding as at 30th June, 2021."], [null, null, null, "\uf0b7 There has been delayed commissioning of Karuma Dam, whose"], [null, null, null, "completion date was extended to 15th June 2022, resulting in a delay of"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 264, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None", "None"], "type": "table"}}, {"content": [["", null, null, "for Karuma Hydro Power Plant was outstanding as at 30th June, 2021."], [null, null, null, "\uf0b7 There has been delayed commissioning of Karuma Dam, whose"], [null, null, null, "completion date was extended to 15th June 2022, resulting in a delay of"], [null, null, null, "3 years and 6 months from the initial planned completion date."], [null, null, null, "\uf0b7 Instances of non-conformances (NC) were noted in relation to electrical,"], [null, null, null, "mechanical and civil works components that required rectification before"], [null, null, null, "commissioning of the Karuma Dam."], [null, null, null, "\uf0b7 There has been continuous extension of the Isimba Dam Defects Liability"], [null, null, null, "Period (DLP), due to the various snags and defects that were detected"], [null, null, null, "after the Dam\\`s commissioning on March 2019."], [null, null, null, "\uf0b7 I noted delayed commencement of the Construction of Muzizi Hydro"], [null, null, null, "Power Project whose credit facility agreement with Agence Francaise De"], [null, null, null, "Development (AFD) and KFW was signed on 9th December 2016 and"], [null, null, null, "25th November, 2016, respectively, to finance the construction of Muzizi"], [null, null, null, "Hydro Power Project with expected completion date of December 2023."], [null, null, null, "\uf0b7 I noted delayed Compensation of Project Affected Persons (PAPs) for"], [null, null, null, "Muzizi HPP whereby a total of UGX.1,769,227,282 (36.41%) of the total"], [null, null, null, "compensation value UGX.4,858,711,140 has been paid to PAPs."], [null, null, null, "\uf0b7 I also note a failure to undertake remedial works on the plants being"], [null, null, null, "handled under the concession between GOU and ESKOM with less than"], [null, null, null, "50% of the remedial works that have been carried out currently, with a"], [null, null, null, "few months to end of the concession."], ["13 Strengthening the Management of Oil and Gas Programme (SMOGP) 2020/21 Opinion Unqualified \uf0b7 Out of the total receipts for the financial year of USD 790,580.38, only USD. 239,221.92 was spent by the Programme resulting in an unspent balance of USD 551,358.46, representing an absorption level of 30.2%. Under absorption of released funds results in non-implementation of planned activities. \uf0b7 I noted that the Planned Programme activities such as Development of Reservoir Modelling and Simulation, Review of the Tax Laws and the Model Production Sharing Agreement Training course for Component Managers and Program Secretariat among others were not implemented. There is a risk of failure to achieve intended Programme objectives and service delivery due to delayed implementation of activities.", null, null, null], ["14 15", "Mutundwe-Entebbe 132kv Double Circuit Transimssion Line Project - UETCL- June", null, "\uf0b7 I noted delays in transfer of titles, caused by the slow land titling process. Out of the expected 463 land titles, UETCL received 264, and 70 were handed over to the RAP Consultant."], [null, "2020", null, null], [null, "Opinion", null, ""], [null, "Unqualified", null, ""], [null, null, null, "consultant such as inclusion of forest reserves and wetlands as part of"], [null, null, null, "compensation to private individuals anddivergent surcey and valuation report for the same property."], [null, "", "", "\uf0b7 Out of the total receipts for the financial year of UGX. 64.97Bn, a sum of UGX 63.38Bn was spent by the entity resulting in an unspent balance of UGX 1.52Bn representing absorption level of 97.6 %. \uf0b7 I noted un-reconciled receivables amount of UGX.70.1Bn resulting from the withheld funds by UMEME from the Escrow Account in regard to unpaid government electricity bills by MDAs."], [null, "", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 264, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None", "None"], "type": "table"}}, {"content": "252", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 264, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Unqualified \uf0b7 I noted power evacuation liability of UGX.15.29Bn, payable to UETCL. This was due to power losses attributed to absence of transmission lines to evacuate electricity from PA Technical, Siti 1 and Arpe Power Plants, as a result of wheeling power over a lower capacity and weaker distribution lines operated by UEDCL. \uf0b7 The long outstanding receivable resulting from payment of former UEB pension costs of UGX.38.6Bn by UEDCL which has never been paid back to the Company by MoFPED. \uf0b7 Failed to meet its targeted annual connection 37,293 of customers whereby only 6,309 (16.9%) connections were made. \uf0b7 I noted that in the FY 2020/21, the approved energy loss target by the Electricity Regulatory Authority was at 20.1%. I however noted from the Grid Energy Reports submitted to ERA, that the Company was unable to meet its target energy losses and most of its service territories registered an average of 32.7% power losses. \uf0b7 I noted non -compliance by the WENRECO to the terms of the Operation and Maintenance Agreement, such as provision of semi-annual reports on status of the assets, safe storage of UEDCL connection materials, participation in the physical network inspection, submission of asset modifications register among others. \uf0b7 The 62,944 poles leased to UMEME by UEDCL were damaged and required replacement which was not done contrary to the provisions of the Lease Agreement.", null, null], ["16", "Uganda National Oil Company 2020/21", "\uf0b7 Out of the total receipts for the financial year of UGX.34.4bn only UGX 26.6bn was spent by the company, resulting in an unspent balance of UGX 7.8bn. This represents an absorption level of 77.3%."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 265, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["Unqualified \uf0b7 I noted power evacuation liability of UGX.15.29Bn, payable to UETCL. This was due to power losses attributed to absence of transmission lines to evacuate electricity from PA Technical, Siti 1 and Arpe Power Plants, as a result of wheeling power over a lower capacity and weaker distribution lines operated by UEDCL. \uf0b7 The long outstanding receivable resulting from payment of former UEB pension costs of UGX.38.6Bn by UEDCL which has never been paid back to the Company by MoFPED. \uf0b7 Failed to meet its targeted annual connection 37,293 of customers whereby only 6,309 (16.9%) connections were made. \uf0b7 I noted that in the FY 2020/21, the approved energy loss target by the Electricity Regulatory Authority was at 20.1%. I however noted from the Grid Energy Reports submitted to ERA, that the Company was unable to meet its target energy losses and most of its service territories registered an average of 32.7% power losses. \uf0b7 I noted non -compliance by the WENRECO to the terms of the Operation and Maintenance Agreement, such as provision of semi-annual reports on status of the assets, safe storage of UEDCL connection materials, participation in the physical network inspection, submission of asset modifications register among others. \uf0b7 The 62,944 poles leased to UMEME by UEDCL were damaged and required replacement which was not done contrary to the provisions of the Lease Agreement.", null, null], ["16", "Uganda National Oil Company 2020/21", "\uf0b7 Out of the total receipts for the financial year of UGX.34.4bn only UGX 26.6bn was spent by the company, resulting in an unspent balance of UGX 7.8bn. This represents an absorption level of 77.3%."], [null, "Opinion Unqualified", null], ["17 Uganda Refinery Holding Company Ltd 2020/21 Opinion Unqualified \uf0b7 Out of a total of UGX 2.9bn received during the financial year, UGX.2.9bn was spent by the Company. This represents an absorption level of 100%. \uf0b7 I noted delays in the development of the Kabaale Industrial Park. As at 30th June 2021, implementation of infrastructure such as roads, power supply, water supply and Information Communication Technology connection had not yet commenced. \uf0b7 I noted delays in the implementation of the Refinery Project. As at 30th June 2021, the refinery investor had not met the targets for some Project milestones. Preliminary activities such as the Front End Engineering Design were at 97%, Environmental Social Impact Assessment Study at 70%, and procurement for the consultancy services for the Resettlement Action Plan was on-going.", null, null], ["18", "Uganda Electricity Transmission Company Limited (UETCL) 2020/21", "\uf0b7 I noted that UETCL developed and approved a Corporate Business Plan without certification from the National Planning Authority. There is a risk that activities implemented during the financial year 2020/2021 were not aligned to the NDP-III, which negatively affects the achievement of NDP- III objectives."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 265, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "253", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 265, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "of UGX 86Bn. Domestic energy sales were 9.5 % below budget. Both"], [null, "sales to Rwanda and DRC 29% below the budget, and no sales were"], [null, "made to South Sudan despite the anticipated revenue of UGX.824 million."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 266, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None"], "type": "table"}}, {"content": [["", "of UGX 86Bn. Domestic energy sales were 9.5 % below budget. Both"], [null, "sales to Rwanda and DRC 29% below the budget, and no sales were"], [null, "made to South Sudan despite the anticipated revenue of UGX.824 million."], [null, "\uf0b7 UETCL budgeted to receive from Government, UGX.108.823Bn for"], [null, "capacity charges and deemed energy costs. However, only UGX 36.4Bn"], [null, "was released resulting in a shortfall of UGX 72.423Bn, which is 66% of"], [null, "the budget."], [null, "\uf0b7 I sampled 40 critical activities implemented under 7 sampled departments"], [null, "under UETCL and noted that 17(43%) tasks had been fully implemented,"], [null, "13 (32%) were partially implemented, while 10 (25%) were not"], [null, "implemented at all."], [null, "\uf0b7 A provision for bad and doubtful debts amounting to UGX 161.4bn was"], [null, "made under Trade and other receivables in the financial statements. This"], [null, "was an increment of 25% from the financial year 2019/20. The provision"], [null, "relates to customers with unpaid balances in contravention of the terms"], [null, "and conditions of the power sales agreement. I further noted that 74.7%"], [null, "of the provisions were attributable to only one Company."], [null, "\uf0b7 Analysis of the trade and other payables revealed an increment of 18.7Bn"], [null, "from UGX.740.8Bn in 2019/20. Included in these payables were amounts"], [null, "of UGX.71.2Bn and USD.4.7 million which have been outstanding for over"], [null, "10 years."], [null, "\uf0b7 M/s UMEME and M/s UEDCL withheld UETCL revenue of UGX 64Bn and"], [null, "10.31Bn, respectively on account of evacuation losses and non-payment"], [null, "of electricity bills by Government MDAs. Withholding revenue constrains"], [null, "UETCL\u2019s ability to pay electricity generators."], [null, "\uf0b7 The land titling process was not satisfactory on most of UETCL Projects."], [null, "UETCL takes an average of 3 years to conclude the titling process in"], [null, "contravention of the 6 months period warranted which exposes the"], [null, "company to a risk of litigation and potential encroachment."], [null, "\uf0b7 UETCL incurred deemed energy costs of UGX 87.7Bn on thirteen (13)"], [null, "PPAs, save for me HPP were directly financed through the tariff system,"], [null, "hence impacting on the electricity price to the final consumer."], [null, "\uf0b7 I noted that UETCL incurred about UGX 494,150,000 in replacing"], [null, "vandalized tower equipment during the year under review. I further noted"], [null, "that the company incurred UGX. 1.6Bn in replacement costs on assorted"], [null, "transmission line items vandalized between 2017 and 2021."], [null, "\uf0b7 I noted delays in concluding the procurement process for a sample of"], [null, "procurements with a total contract sum of UGX.17.8Bn with"], [null, "procurements lasting an average of 3 years and some cases going up to 5"], [null, "years. Prolonged procurement processes deny timely achievement of"], [null, "intended project objectives."], ["19 National Pipeline Company 2020/21 Opinion Unqualified \uf0b7 Out of the total receipts for the financial year of UGX.3.71Bn, UGX.3.71Bn was utilized. This represents an absorption level of 100%. \uf0b7 I noted that the Company failed to maintain National Strategic Reserves. In the period under review, the Consortium failed to meet the required National Strategic Reserve levels of 12 million litres per month. Failure to restock petroleum reserves exposes the Country to supply shocks and a risk of inflated prices in the event of disruptions in the petroleum supplies chain. \uf0b7 I noted that as at 30th June 2021, the consortium had not developed the facilities to enable lake transport to the Jinja Storage Tanks. The construction of an oil jetty and connecting pipeline to Jinja Storage Tanks", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 266, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None"], "type": "table"}}, {"content": "254", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 266, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["had not commenced. \uf0b7 I noted delays in implementation of Kampala Storage Terminal (KST). As at 30th June 2021, Preliminary activities such as the Power Reticulation Proposal and Environment Social Impact Assessment for the terminal were undertaken However, Construction activities under the Project had not commenced.", null, null], ["20", "Rural Electrification Agency 2020/21 Opinion", "\uf0b7 Out of the budgeted government receipts for the financial year of UGX.155.23Bn, a sum of UGX. 149.26Bn was spent by the entity resulting in an unspent balance of UGX.5.97Bn, representing an absorption level of 96%."], [null, "Unqualified", null], ["21 Uganda Energy Credit Capitalisation Company Limited 2020/21 Opinion Unqualified \uf0b7 No material issue reported. \uf0b7", null, null], ["22", "Grid Expansion and Reinforcement Project \u2013 MEMD", "\uf0b7 Out of the total receipts for the financial year of USD.1,698,907.88, only USD.1,030,144.30 was spent resulting into an unspent balance of USD.654,938.58, representing an absorption level of only 60.6%."], [null, "2020/21 Opinion Unqualified", null], ["23 The Fuel Marking and Quality Monitoring Program, Ministry of Energy and Mineral Development \uf0b7 Out of the total receipts for the financial year of UGX.9.62Bn, a sum of UGX. 8.71Bn was spent representing 91% absorption level by the program. As a result activities such as Stakeholders\u2019 awareness", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 267, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "255", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 267, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["2020/21 Opinion Unqualified workshops and Training on petroleum standard development were partially implemented. \uf0b7 \uf0b7 I noted non-compliance by fuel stations with the Standard that covers the siting, design and construction of service stations, installation and operation of equipment in service stations for handling, storage and dispensing of petroleum products and their derivatives. \uf0b7 I noted that the Program does not have in place a comprehensive system of monitoring and testing the quality of lubricants and engine oils based on the standards. This poses a risk to motorists who may purchase poor quality engine oils and lubricants.", null, null, null], ["24", "The Ministry of Energy and Mineral Development (MEMD) 2020/21 Opinion Unqualified", null, "\uf0b7 I noted in the year under review, that the entity did not have an approved sector development plan (strategic plan) 2020/21. The Accounting Officer explained that a strategic Plan was prepared and is aligned to the NDP III, a however the approval of management delayed"], [null, null, null, "due to management transition \uf0b7 The Ministry budgeted to collect NTR of UGX.19.9Bn during the year"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 268, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None", "None"], "type": "table"}}, {"content": [["2020/21 Opinion Unqualified workshops and Training on petroleum standard development were partially implemented. \uf0b7 \uf0b7 I noted non-compliance by fuel stations with the Standard that covers the siting, design and construction of service stations, installation and operation of equipment in service stations for handling, storage and dispensing of petroleum products and their derivatives. \uf0b7 I noted that the Program does not have in place a comprehensive system of monitoring and testing the quality of lubricants and engine oils based on the standards. This poses a risk to motorists who may purchase poor quality engine oils and lubricants.", null, null, null], ["24", "The Ministry of Energy and Mineral Development (MEMD) 2020/21 Opinion Unqualified", null, "\uf0b7 I noted in the year under review, that the entity did not have an approved sector development plan (strategic plan) 2020/21. The Accounting Officer explained that a strategic Plan was prepared and is aligned to the NDP III, a however the approval of management delayed"], [null, null, null, "due to management transition \uf0b7 The Ministry budgeted to collect NTR of UGX.19.9Bn during the year"], [null, null, null, "under review. Out of this, only UGX. 13Bn was realized, representing a performance of 65.3% of the target. This was attributed to COVID"], [null, null, null, "Pandemic that greatly affected businesses in the Country to extent that"], [null, null, null, "some companies wrote requested for either a reduction or waiving off their rent arrears."], [null, "", "", "\uf0b7 Out of the total warrants for the financial year of UGX.342.3Bn, a sum of"], [null, "", "", "UGX.336.9Bn was spent by the entity resulting in an unspent balance of"], [null, "", "", "UGX.5.4Bn representing an absorption level of 98%. As a result, I noted"], [null, "", "", "that of the 148 quantified activities worth UGX.99.3Bn assessed; 16"], [null, "", "", "activities representing 10.8% were fully implemented, 125 activities"], [null, "", "", "representing 84.5% were partially implemented, while 7 activities"], [null, "", "", "representing 4.7% were not implemented."], [null, "", "", "\uf0b7 A trend analysis of the domestic arrears reported in Note 24 to the"], [null, "", "", "financial statements showed movement of domestic arrears from"], [null, "", "", "UGX.18.29Bn in the previous year to UGX.17.13Bn in the year under"], [null, "", "", "review, a decrease of 7%. This unsustainable trend poses risks of"], [null, "", "", "litigation and related costs inform of interest penalty."], [null, "", "", "\uf0b7 The Ministry received UGX.1.39Bn into the Mineral Royalties Sharing Fund"], [null, "", "", "account during the period, in addition to the closing amount of"], [null, "", "", "UGX.442.07Mn from the previous period. However, only UGX.1.39Bn was"], [null, "", "", "paid leaving an outstanding balance of UGX.433.82Mn which has been"], [null, "", "", "correctly disclosed as payables as at year end."], [null, "", "", "\uf0b7 The receivables amount of UGX.14,287,738,002 in the statement of"], [null, "", "", "financial position and under Note 19, to the financial statements includes"], [null, "", "", "an amount UGX.4,494,005,610 receivables (UGX 4,288,550,000 and"], [null, "", "", "UGX.205,455,610 relating to annual mineral rent/royalties and sale of"], [null, "", "", "goods and services, respectively) which has been outstanding for over"], [null, "", "", "four years."], [null, "", "", "\uf0b7 The RAP implementation and land acquisition for the Karuma Reservoir"], [null, "", "", "Area project. The contract has been extended several times with the new"], [null, "", "", "completion date set for 23rd June 2022. I established that a RAP survey"], [null, "", "", "and valuation report was submitted by the Consultant on 31st April 2021,"], [null, "", "", "but, as at 30th June 2021, compensation of the PAPs had not yet"], [null, "", "", "commenced."], [null, "", "", "\uf0b7 A review of the Department of Geological Survey and Mines staff"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 268, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None", "None"], "type": "table"}}, {"content": "256", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 268, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "establishment revealed that out of 127 approved positions, only 85"], [null, null, "positions were filled leaving 42 positions vacant representing a staffing"], [null, null, "gap of 33%."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 269, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "establishment revealed that out of 127 approved positions, only 85"], [null, null, "positions were filled leaving 42 positions vacant representing a staffing"], [null, null, "gap of 33%."], ["25 Kilembe Mines Ltd (KML) 2020/21 Opinion Unqualified \uf0b7 The entity budgeted to receive UGX.3.574Bn out of which, UGX.857Mn was realised, resulting in a shortfall of UGX.2.717Bn which is 76% of the budget. As a result activities such as dewatering the Copper Mines and revamping of Hima Lime Works, were not been implemented. \uf0b7 \uf0b7 I noted that a number of assets had been damaged / impaired due to waters that broke the banks of River Nyamwamba on 7th and 10th of May, 2020. However, no formal estimate of the recoverable amount has been conducted. This may result into an overstatement of the total assets and understatement of operating loss. \uf0b7 I noted that the Company had an outstanding receivable of UGX.1.26Bn as at 30th June 2021, 54% of the amount relates to unpain rent from Tibet Hima Mining Co. Ltd. Delayed recovery of outstanding revenues affects the Company\u2019s liquidity position. \uf0b7 I noted that the Company had outstanding payables of UGX.2.28Bn. The amount increased from UGX.0.966 to UGX.2.286Bn resulting into an increase of UGX.1.321Bn (137%) as at 30th June 2021. \uf0b7 I noted delayed divesture of Kilembe Mines. Three (3) years have elapsed without an investor/operator being identified to take over Kilembe Mines operations, following the termination of the Tibet Hima Concession Agreement. \uf0b7 Emergency Funding of UGX 4.375bn was required to rehabilitate the damaged Company infrastructure following flooding of rivers Nyamambwa and Mubuku in May and August 2020. However, the requested funds were not availed. \uf0b7 Mubuku Hydro-Power Plant was designed to generate 5MW. I however noted that the plant was only generating 2MW from Unit 1. Units 2 to 4 were out of service for a number of years. \uf0b7 Review of the Annual Performance Report, 2021 revealed that the Company had a number of long outstanding court cases, relating to encroachment of Land belonging to the company. Three cases had been outstanding for over 7 years, three other cases for 5 but less than 7 years and six cases for less than 5 years.", null, null], ["26", "Uganda Electricty Generation Company Limited Capacity Building Program-Norwegian Grant", "\uf0b7 Out of UGX.6,475,227,265 received for project activities UGX.5,285,679,281 was utilized representing 82% absorption. The under absorption was attributed to postponement of commissioning of Karuma Hydro power plant."], [null, "Uga-16/0010 Initial Support to UEGCL \u2013 2019 2020/21", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], ["27 Atomic Energy Council 2020/21 Opinion \uf0b7 Out of the total receipts for the financial year of UGX. 13.98bn, UGX. 9.96bn was spent by the entity resulting in an unspent balance of UGX 4bn representing an absorption level of 71.2%. As a result, Six (6) outputs with thirty nine (39) activities worth UGX. 4.2Bn were partially", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 269, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "257", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 269, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Unqualified implemented. \uf0b7 I noted that the Council lacked of Radiation Protection and Safety Laboratories. There were no Laboratories in place for testing radioactivity levels in food stuffs, construction materials and other consumable products that contain natural radionuclides. This puts the lives of the community at risk. \uf0b7 I noted that the Council lacked adequate specialized inspection equipment required for various practices and activities that involved management of radiation sources. \uf0b7 Out of Staff the Council Establishment of 90 positions, only 49 positions filled leaving 21 positions vacant, representing a staff shortfall of 30%. This affects the efficient and effective execution of the Council mandate.", null, null], ["28", "Energy for Rural Transformation Project (ERT III)-PCU 2020/21", "\uf0b7 Out of the total available funds for the financial year of USD 6,346,771.03, only USD 5,585,830.71 was spent by the Project, resulting in an unspent balance of USD. 760,940.32, representing absorption level of 88%. \uf0b7 I noted low disbursements of loan funds over the Project Life. Out of the ERT III Project loan amount of USD 143.2 Million, only USD 94.5 Million"], [null, "Opinion Unqualified", null], ["29 Opuyo- Moroto 132kv Transmission Line Project - (UETCL) 2019 Opinion Unqualified \uf0b7 I noted that despite the project nearing completion, out of 1,300 PAPs, only 1,222 had been compensated leaving a balance of 78 (6%) by 30th June 2019. There is a risk that the outstanding compensation of PAPs may further delay project implementation. \uf0b7 I noted that despite the loan last disbursement date being 28th February 2021, only 21% of the total funds were disbursed to both UETCL and REA by 30th June 2019", null, null], ["30", "Opuyo- Moroto 132kv Transmission Line Project - (UETCL) 2020 Opinion Unqualified", "\uf0b7 I noted under Note 9.13 that the project payables increased from USD.1,169,371 (2019) to USD. 2,290,568 (2020) due to non payments of service providers at the end of the financial year for the services"], [null, null, "provided."], [null, null, ""], ["31 The 132kv Mirama-Kabale Transmission Line and Distribution Project-2019 Opinion Unqualified \uf0b7 No significant matters to report on.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 270, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "258", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 270, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["32", "The 132kv Mirama-Kabale Transmission Line And Distribution Project-2020", "\uf0b7 No significant matters to report on."], [null, null, ""], [null, null, ""], ["33 Energy for Rural Transformation III Implemented by Uganda Energy Credit Capitalization Company Limited (ERT III- UECCCL) Opinion Unqualified \uf0b7 No material issue reported.", null, null], ["34", "Energy for Rural Transformation III BOU Project (ERT III).", "\uf0b7 No material findings to report on"], [null, null, ""], ["EDUCATION SECTOR", null, null], ["1", "African Centre for Agro ecology and Livelihood Systems (ACALISE) Project \u2013 UMU", "\uf0b7 I noted in the statement of income and expenditure that out of budgeted total revenue of USD 1,807,602 for the financial year 2020/2021, only USD 610,980 (33.8%) was realized leading to a budget shortfall of USD 1,196,622."], [null, "2020/21 Opinion Unqualified", null], ["2 Soroti University. 2020/21 Opinion Unqualified \uf0b7 I noted that the University did not indicate NTR estimates in its statement of Appropriation. How out of the budgeted NTR of UGX.706,000,000 for the financial year 2020/2021, UGX.195,985,600 was collected representing a performance of 28% of the target. \uf0b7 The entity budgeted to receive UGX.20.229Bn out of which UGX.19.621Bn was warranted, resulting into a shortfall of UGX.0.608 Bn which is 3% of the budget. \uf0b7 I noted the University received off-budget financing to the tune of UGX.36,710,266 which was not transferred to the consolidated fund as required by the law. \uf0b7 Out of the total receipts (warrants) for the financial year of UGX.19.621Bn, UGX.17.484Bn was spent by the entity resulting into an under absorption of UGX.2.137Bn representing an absorption level of 89%. \uf0b7 Ten (10) outputs with a total of ninety-nine (99) activities and", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 271, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "259", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 271, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["expenditure worth UGX 10.251Bn were fully quantified while one (1) output with a total of four (4) activities and expenditure worth UGX 1.898Bn was not quantified to enable assessment of performance as there was no output that was insufficiently quantified. \uf0b7 Out of the ten (10) out puts that were fully quantified, one (1) output with a total of 6 (six) activities worth UGX.0.051Bn was fully implemented while 9(nine) outputs with a total of ninety-three (93) activities worth UGX.10.201Bn were partially implemented. \uf0b7 The University closed the financial year with an accumulated payable totaling to UGX.2,604,379,429 of which UGX.559,049,780 had been outstanding for more than one year. \uf0b7 The University paid a contractor UGX.996,389,960 in respect of outstanding debt that included UGX.188,055,690 relating to accrued interest charged by the contractor as a result of delayed payments. The interest expenditure was nugatory", null, null], ["3", "Busitema University.", "\uf0b7 Out of the budgeted Non tax revenue of UGX.6,517,061,618 for the year"], ["", "2020/21", "2020/21, only UGX.4,904,767,921 was collected representing a"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 272, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["expenditure worth UGX 10.251Bn were fully quantified while one (1) output with a total of four (4) activities and expenditure worth UGX 1.898Bn was not quantified to enable assessment of performance as there was no output that was insufficiently quantified. \uf0b7 Out of the ten (10) out puts that were fully quantified, one (1) output with a total of 6 (six) activities worth UGX.0.051Bn was fully implemented while 9(nine) outputs with a total of ninety-three (93) activities worth UGX.10.201Bn were partially implemented. \uf0b7 The University closed the financial year with an accumulated payable totaling to UGX.2,604,379,429 of which UGX.559,049,780 had been outstanding for more than one year. \uf0b7 The University paid a contractor UGX.996,389,960 in respect of outstanding debt that included UGX.188,055,690 relating to accrued interest charged by the contractor as a result of delayed payments. The interest expenditure was nugatory", null, null], ["3", "Busitema University.", "\uf0b7 Out of the budgeted Non tax revenue of UGX.6,517,061,618 for the year"], ["", "2020/21", "2020/21, only UGX.4,904,767,921 was collected representing a"], [null, "Opinion Unqualified", "performance of only 75% of the target."], [null, null, "\uf0b7 There was a shortfall in releases amounting to UGX4.63Bn which is 9% of the budget. Furthermore, the entity remained with unspent balance of"], [null, null, "UGX.1.60Bn representing an absorption level of 97%."], [null, null, "\uf0b7 The University received off-budget financing to the tune of"], [null, null, "UGX.1,462,363,950 which was not transferred to the consolidated fund as"], [null, null, "required by the law. These funds were received directly from"], [null, null, "development partners for undertaking activities which were not budgeted"], [null, null, "for."], [null, null, "\uf0b7 Nine (9) outputs with 73 activities worth UGX.33.34Bn were insufficiently"], [null, null, "quantified. That is out of the Seventy-three (73) activities, twelve (12)"], [null, null, "activities (16%) were not clearly quantified. Two (2) outputs with a total"], [null, null, "of eight (8) activities worth UGX.8.52Bn were fully implemented while"], [null, null, "two (2) outputs with a total of fifteen (15) activities worth UGX3.46Bn"], [null, null, "were partially implemented."], [null, null, "\uf0b7 I noted that the University closed the financial year with outstanding"], [null, null, "payables to the tune of UGX.1,504,842,864 of which UGX.1,421,201,933"], [null, null, "related to unpaid enhanced salaries for administrative and support staff"], [null, null, "that accrued in the financial year 2016/17."], ["4 Gulu University. 2020/21 Opinion Unqualified \uf0b7 I noted that the University\u2019s strategic plan was not certified by NPA and no feedback had been received by the time of concluding the audit. This was attributed to delays in the review and certification process by NPA. \uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity budgeted to collect NTR of UGX.12.75Bn during the year under review. Out of this, UGX.4.18Bn was collected, representing a performance of 32.8% of the target. The entity budgeted to receive UGX. 58.88Bn from treasury, out of which UGX.57.90Bn was warranted, resulting into a shortfall of UGX.0.98Bn which is 1.7% of the budget. \uf0b7 Out of the total warrants of UGX 58.11Bn received during the financial year, UGX. 57.90bn was spent by the entity resulting in an unspent balance of UGX 0.21Bn, representing an absorption level of 99.6%. The unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account as required by the PFMA.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 272, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "260", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 272, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 The University received off-budget financing to the tune of UGX.6,255,990,597 which was not declared to Treasury and, therefore, not appropriated to the entity by Parliament. These funds were received directly from development partners for undertaking activities not budgeted for. \uf0b7 I reviewed the extent of quantification of outputs and activities for a sample of the ten (10) outputs with a total of twenty (20) activities and expenditure of UGX.45.556Bn and noted that seven (7) outputs with a total of twelve (12) activities and expenditure worth 43.284bn were fully quantified while three (3) outputs with a total of eight (8) activities and expenditure worth UGX. 2.871bn were not quantified at all. \uf0b7 I assessed the implementation of seven (7) out puts that were fully quantified with a total of twelve (12) activities worth UGX.43.282Bn and noted that three (3) outputs with a total of six (6) activities worth UGX.37.054Bn were fully implemented. Two (2) outputs with a total of four (4) activities worth UGX,5.706Bn were partially implemented while two (2) outputs with a total of two (2) activities worth UGX. 0.522Bn were not implemented. \uf0b7 The University had outstanding domestic arrears of UGX.5,681,315,557 dating as far back as financial year 2015/16. There is a risk that the University could face litigation from the suppliers and other beneficiaries. \uf0b7 Gulu University is involved in several court cases and some of the cases remained pending at the financial year end. The cases are mostly between the University and its former staff, students and suppliers. The cases arose mainly from unlawful termination, breach of contracts, unfair treatment, land issues, Arrears/failure to pay suppliers. \uf0b7 Gulu University awarded a contract for the supply and installation of Network Equipment to the Faculty of Agriculture, Biometric Equipment for Staff attendance, Laptops and Desktops for Vice Chancellor, Director ICT and Director Planning & Development at a contract price of UGX.181,794,897 on the 25th June, 2021. However, as at the time of concluding the audit, installation was not undertaken. \uf0b7 Gulu University signed a contract for the construction of the Business and Development Centre on the 19th June, 2019 for a contract price of UGX.30,122,043,772. The construction start date was 1st August, 2019 and the expected completion date of 30th July, 2023. I noted that only UGX.2.1Bn out of UGX.6.0Bn was paid as advance for mobilization and this led to the temporary stoppage of works by the contractor which led to slow progress of the building works. At the time of concluding the audit, no major works were undergoing. \uf0b7 I noted that the following University pieces of land were not titled; forest land measuring 28 hectares, Pajengo Latoro; Agago and Agora Pader land. There is a risk that the land in question could be lost to unscrupulous individuals. \uf0b7 Out of the 1,606 approved positions in Gulu University; only 441 (27%) posts were filled, leaving 1,165 (73%) positions vacant.", null, null], ["5", "The Higher Education Students' Financing Board (HESFB)", "\uf0b7 I noted that the University\u2019s strategic plan was not certified by NPA and no feedback had been received by the time of concluding the audit. This was attributed to delays in the review and certification process by NPA."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 273, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "261 \ntarget. The entity budgeted to receive UGX. 58.88Bn from treasury, out of which UGX.57.90Bn was warranted, resulting into a shortfall of UGX.0.98Bn which is 1.7% of the budget.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 273, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the total warrants of UGX 58.11Bn received during the financial year, UGX. 57.90bn was spent by the entity resulting in an unspent balance of UGX 0.21Bn, representing an absorption level of 99.6%. The unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account as required by the PFMA.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The University received off-budget financing to the tune of UGX.6,255,990,597 which was not declared to Treasury and, therefore, not appropriated to the entity by Parliament. These funds were received directly from development partners for undertaking activities not budgeted for.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I reviewed the extent of quantification of outputs and activities for a sample of the ten (10) outputs with a total of twenty (20) activities and expenditure of UGX.45.556Bn and noted that seven (7) outputs with a total of twelve (12) activities and expenditure worth 43.284bn were fully quantified while three (3) outputs with a total of eight (8) activities and expenditure worth UGX. 2.871bn were not quantified at all.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I assessed the implementation of seven (7) out puts that were fully quantified with a total of twelve (12) activities worth UGX.43.282Bn and noted that three (3) outputs with a total of six (6) activities worth UGX.37.054Bn were fully implemented. Two (2) outputs with a total of four (4) activities worth UGX,5.706Bn were partially implemented while two (2) outputs with a total of two (2) activities worth UGX. 0.522Bn were not implemented.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The University had outstanding domestic arrears of UGX.5,681,315,557 dating as far back as financial year 2015/16. There is a risk that the University could face litigation from the suppliers and other beneficiaries.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Gulu University is involved in several court cases and some of the cases remained pending at the financial year end. The cases are mostly between the University and its former staff, students and suppliers. The cases arose mainly from unlawful termination, breach of contracts, unfair treatment, land issues, Arrears/failure to pay suppliers.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Gulu University awarded a contract for the supply and installation of Network Equipment to the Faculty of Agriculture, Biometric Equipment for Staff attendance, Laptops and Desktops for Vice Chancellor, Director ICT and Director Planning & Development at a contract price of UGX.181,794,897 on the 25th June, 2021. However, as at the time of concluding the audit, installation was not undertaken.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Gulu University signed a contract for the construction of the Business and Development Centre on the 19th June, 2019 for a contract price of UGX.30,122,043,772. The construction start date was 1st August, 2019 and the expected completion date of 30th July, 2023. I noted that only UGX.2.1Bn out of UGX.6.0Bn was paid as advance for mobilization and this led to the temporary stoppage of works by the contractor which led to slow progress of the building works. At the time of concluding the audit, no major works were undergoing.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the following University pieces of land were not titled; forest land measuring 28 hectares, Pajengo Latoro; Agago and Agora Pader land. There is a risk that the land in question could be lost to unscrupulous individuals.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- Out of the 1,606 approved positions in Gulu University; only 441 (27%)", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n262", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "posts were filled, leaving 1,165 (73%) positions vacant."], ["6 Kabale University. 2020/21 Opinion Unqualified \uf0b7 I noted that the University prepared a strategic plan aligned to NDP III and the plan was approved by NPA and a certificate of approval issued. \uf0b7 Out of budgeted NTR collections of UGX.7.6 Bn, only UGX. 5.26Bn was realized, representing a performance of 74.6 % of the target. \uf0b7 There was a shortfall in government releases amounting to UGX.0.03Bn representing 0.08% of the budget. \uf0b7 Out of the total receipts for the financial year of UGX.40.95 Bn a sum of UGX. 40.5 Bn was spent by the entity resulting in an unspent balance of UGX 0.45Bn representing an absorption level of 99%. \uf0b7 I sampled 5 outputs of a total of Nine (9) outputs and expenditure worth 37.22.Bn and noted that two (2) outputs with a total of three (3) activities was fully quantified; three (3) outputs with thirteen (13) activities were partially quantified while two (2) activities were not implemented. \uf0b7 The university accumulated receivables totalling to UGX.3,114,950,156 as at 30/6/2021. Under collection of billed revenue cripples, the University\u2019s ability to meet its financial obligations and impacts negatively on service delivery. \uf0b7 I noted the University had outstanding payables of UGX.1,872,390,164 as at 30/6/2021. The failure to clear payables by the closure of the financial year may attract litigation resulting into wasteful expenditure in form of legal fees.", null, null], ["7", "Lira University. 2020/21 Opinion", "\uf0b7 The entity submitted its final copy of the strategic plan to National Planning Authority (NPA) for alignment and certification however, no feedback had been received by the entity at the time of audit (September 2021)."], [null, "Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 275, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "263", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 275, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "quantified with a total of six (6) activities worth UGX.5.3Bn and noted"], [null, null, "that two (2) outputs with two (2) activities worth UGX.0.3Bn were fully"], [null, null, "implemented while three (3) outputs with four (4) activities worth"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 276, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "posts were filled, leaving 1,165 (73%) positions vacant."], "type": "table"}}, {"content": [["", null, "quantified with a total of six (6) activities worth UGX.5.3Bn and noted"], [null, null, "that two (2) outputs with two (2) activities worth UGX.0.3Bn were fully"], [null, null, "implemented while three (3) outputs with four (4) activities worth"], [null, null, "UGX.5Bn were partially implemented."], [null, null, "\uf0b7 During the year, the University incurred nugatory expenditure totalling to"], [null, null, "UGX.25,752,041 being interest and penalties paid resulting from"], [null, null, "management\u2019s failure to deduct and remit NSSF deductions for the period"], [null, null, "August 2016 to June 2020."], [null, null, "\uf0b7 I noted that Lira University signed a tenancy agreement with the Law"], [null, null, "Development Centre letting out the first floor of the faculty of Education"], [null, null, "to LDC at a consideration of UGX.15,300,000 per month inclusive of taxes"], [null, null, "implying that the University is making a monthly financial loss of"], [null, null, "UGX.2,754,000 in form of VAT payable to URA. As a result, the university"], [null, null, "did not remit VAT totalling to UGX. UGX.33,048,000 being VAT payable"], [null, null, "on rental income to URA on the annual rental income of UGX.183,600,000"], [null, null, "(UGX.15,300,000 for 12 months) received by the University."], [null, null, "\uf0b7 I noted a delayed construction of the Administration Block following a"], [null, null, "contract award of UGX.16,664,107,531 to the construction contractor."], [null, null, "Despite the expiry of the contract duration of the three years to 11th"], [null, null, "September 2021, the construction works had not been completed, and"], [null, null, "the progress of works was estimated at 32% level. However, the"], [null, null, "supervising contractor had been paid 92% on his contract of"], [null, null, "UGX.749,885,000 ending 4th February 2022."], ["8 MAK Holdings. 2020/21 Opinion Unqualified \uf0b7 I noted that the Company management budgeted to receive and generate revenue of UGX.1,892,600,000 however, only UGX.809,760,761 (43%) was realized reflecting an underperformance of UGX.1,082,839,239 which is 57% of the expected revenue for the year. \uf0b7 The Makerere University Guest house had accumulated creditors to the tune of UGX.620,024,827 from UGX.405,138,535 in the financial year ended 30th June, 2020 representing a 53% increase in liabilities. Some of the outstanding liabilities include statutory payments worth UGX.240,026,071 \uf0b7 I noted an increase in receivables of UGX.299,307,621 from UGX.271,978,943 reported in the prior year.", null, null], ["9", "Mapronano World Bank Project. 2020/21 Opinion", "\uf0b7 I noted that out of the released USD 1,995,561, only USD 1,357,190 was spent by the Project resulting into unspent balance of USD 638,371 representing an under absorption level of 31.98%. The unspent balance at the end of the financial year was subsequently carried forward to the next financial year."], [null, "Unqualified", null], ["10 MaRCCI World bank Project. 2020/21 Opinion Unqualified \uf0b7 I assessed the implementation of the eight (8) out puts with 42 activities that were fully quantified worth US$ $907,282.93, and noted that one (1) output with two (2) activities worth US$ 27,600 was fully implemented while seven (7) outputs with a total of forty (40) activities worth US$ 879,681.93 were partially/not-implemented. The project management implemented sixteen (16) activities fully, eighteen (18) activities partially and six (6) activities were not implemented.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 276, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "posts were filled, leaving 1,165 (73%) positions vacant."], "type": "table"}}, {"content": "264", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 276, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that the project did not pay staff salaries to the tune of USD 13,596 (approximately UGX.50,305,2000. In addition, PAYE withheld from staff deductions for the months of October and November, 2020 totaling to USD. 11,764 (approximately UGX.43,526,800) was not remitted to Uganda Revenue Authority as per regulations.", null, null], ["11", "Management Training and Advisory Centre (MTAC).", "\uf0b7 The MTAC had not prepared the required 5-year strategic plan that is in line with the NDPIII"], [null, "2020/21 Opinion Unqualified", null], ["12 Makerere University. 2020/21 Opinion Unqualified \uf0b7 I noted that the University did not have the strategic plan annualized to indicate which outputs are expected for each year of implementation of the plan covering the period of 2021/21-2024/25. I also noted that whereas the University had prepared and submitted its strategic plan to NPA for approval, it had not yet been approved at the time of audit in October 2021. \uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2021/2021 and noted that the University budgeted to collect NTR of UGX.95.84Bn during the year under review. Out of this, only UGX.58.29Bn was collected, representing a performance of 60.82% of the target. I further noted that the University budgeted to receive UGX.363.74Bn out of which UGX.359.86Bn was warranted, resulting in a shortfall of UGX.3.88Bn which is 1.1% of the budget. Revenue shortfalls affect implementation of the planned activities. \uf0b7 Out of the total warrants of UGX.359.86Bn received during the financial year, UGX.357.04Bn was spent by the entity resulting in an unspent balance of UGX.2.82Bn representing an absorption level of 99.2%. The unspent funds were swept back to the consolidated fund as required by PFMA. \uf0b7 I noted that the University received off-budget financing to the tune of UGX.237,398,885,878 which was not declared to Treasury and, therefore, not appropriated to the entity by Parliament. These funds were received directly from both development partners and other stakeholders for undertaking activities not budgeted for. \uf0b7 I reviewed the extent of quantification of outputs and activities for a", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 277, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "posts were filled, leaving 1,165 (73%) positions vacant."], "type": "table"}}, {"content": "265 \nsample of ten (10) outputs with a total of forty two (42) activities and expenditure of UGX.356.85Bn and noted that two (2) outputs with a total of seven (7) activities and expenditure worth UGX.265.85Bn were fully quantified. Two (2) outputs with a total of twenty-five (25) activities and expenditure worth UGX.30.11Bn were insufficiently quantified while six (6) outputs with a total of ten (10) activities and expenditure worth UGX.60.89Bn were not quantified at all. I observed that in cases where outputs were either partially or not quantified, management reported performance in generic ways. \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 277, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I assessed implementation of two (2) out puts that were fully quantified with a sample of seven (7) activities worth UGX.265.85Bn and noted that one (1) output with a total of three (3) activities worth UGX 4.06Bn was fully implemented while one (1) output with a total of four (4) activities worth UGX.261.78Bn were partially implemented.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- During the financial year under review, the University lost its main administration building and other assets therein to a fire that gutted the main administration Block on the 20th day of September 2020. The fire caused substantial damage to the main building whose value was estimated at UGX.15,434,782,500 by the Chief Government Valuer.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The Statement of reported losses of Public moneys, stores and other assets during the year showed the reported losses of assets/property of total estimated value of UGX.16,457,577,500.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The University had a receivables balance of UGX.25,527,015,916 as at 30/6/2021 broken down as accrued income of UGX.23,372,851,776 and a prepayment of UGX.2,154,164,140 to UMEME for electricity bulk purchase. The accumulation of receivables may lead to under performance of the university on its planned activities.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The University has an outstanding pension liability of UGX.18,920,219,207, inclusive of interest as reported in the Statement of Financial Position for the year ended 30th June 2021 resulting from accumulation of In-House Retirement Benefits since 2010. Delayed payment of retirement benefits may result in nugatory expenditure if the retirees decide to take the University to court.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Statement of Financial Position showed accumulation of domestic arrears of UGX.7,819,385,752 as at 30th June 2021. I noted that majority of these arrears were from the prior years. There is a risk that the University could face litigation from the suppliers and other beneficiaries.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the main University installations/buildings such as the Senate, the Library, School of Women and Gender Studies and others are not comprehensibly insured. In case of a catastrophe, the University is at risk of huge financial obligations to the tenants.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that there are non-qualifying persons occupying the University buildings. These were identified to be former University staff (retirees), unknown persons and Uganda Police Officers whose services were transferred from Makerere University.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that water bills for the year under review were neither read nor submitted to the finance department for deductions. I noted that staff salaries were arbitrarily deducted to clear their water consumption without following one\u2019s monthly water consumption.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The University owns various pieces of land totalling to 102 Acres in prime locations around Kampala including Makerere, Mulago and Makindye. Inspection of the land revealed that the land is heavily encroached upon and a number of cases have been in court for more than five (5) years.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n266", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", null, null], ["13", "Muni University. 2020/21 Opinion Unqualified", "\uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that Muni University budgeted to collect NTR of UGX.1.18bn during the year under review. Out of this, only UGX.0.34bn was collected, representing a performance of 29% of the target."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 279, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "267", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 279, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "Latrine and Store have deteriorated and in dire need of renovation."], [null, null, "\uf0b7 The University\u2019s land in BidiBidi measuring about 439.58 acres valued at"], [null, null, "UGX.439,580,000 did not have a land title."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 280, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": [["", null, "Latrine and Store have deteriorated and in dire need of renovation."], [null, null, "\uf0b7 The University\u2019s land in BidiBidi measuring about 439.58 acres valued at"], [null, null, "UGX.439,580,000 did not have a land title."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 280, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": [["", null, "Latrine and Store have deteriorated and in dire need of renovation."], [null, null, "\uf0b7 The University\u2019s land in BidiBidi measuring about 439.58 acres valued at"], [null, null, "UGX.439,580,000 did not have a land title."], [null, null, "\uf0b7 Muni University entered into a contract for the Completion of the"], [null, null, "Construction of Health Science Laboratory Building at a contract price of"], [null, null, "UGX.9,393,202,823 inclusive of taxes. However, works were significantly"], [null, null, "behind schedule at an estimated 36% completion. There is a risk that the"], [null, null, "Project may not be completed within the projected time frame."], ["14 Mbarara University of Science & Technology. 2020/21 Opinion Unqualified \uf0b7 I noted that the University had NTR estimates of UGX.12.43Bn out of which UGX.9.28Bn was collected representing 75% of the budget. \uf0b7 I noted that out of the total receipts for the financial year of UGX.55.4Bn, only UGX.51.4Bn was spent by the entity resulting in an unspent balance of UGX.4Bn representing an absorption level of 92.9%. \uf0b7 I noted that the University received off-budget financing to the tune of UGX.9.2Bn which was not transferred to the consolidated fund as required by the law. \uf0b7 I noted that nine (9) outputs with a total of twenty-two (22) activities and expenditure worth 42.9Bn were fully quantified. That is, 99% of the activities within these out-puts were clearly quantified to enable assessment of performance. \uf0b7 I noted that one (1) output with a total of three (3) activities and expenditure worth UGX 0.47Bn was insufficiently quantified. That is, the two (2) activities of the three sampled (67%) of the output was not clearly quantified to enable assessment of performance. \uf0b7 I noted that one (1) output with one activity worth UGX.0.05Bn was fully implemented, while eight (8) outputs with a total of twenty-one (21) activities worth UGX.42.9Bn were partially implemented. Out of the twenty-one (21) activities, the entity fully implemented nine (9) activities (43%), 9 (43%) activities were partially implemented and three (3) activities (14%) remained unimplemented \uf0b7 I noted that the University accumulated receivables totalling to UGX.4,222,012,678 as at 30th June 2021, an increase of UGX.1,427,267,366 (51%) in the outstanding receivables of UGX.2,794,745,312 of the prior year ended 30th June 2020. \uf0b7 I noted that the leasehold land on Plot No. 6, lower circular Road, Mbarara expired on 31st March 2017 and has not been renewed four (4) years after its expiry. \uf0b7 I noted that MUST owns six (6) tourist camping sites (bandas) adjacent to Bwindi forest, in Kanungu district on approximately 2 acres of land which was leased to a service provider for a period of 10 years effective 12/04/2020 at contract sum of UGX.480,000,000 (UGX.48,000,000 annually). However, the service provider did not pay the first instalment of UGX.48,000,000 which was due on 12th April 2021, citing challenges of Covid-19 pandemic.", null, null], ["15", "National Council of Sports. 2020/21", "\uf0b7 Out of the budgeted NTR of UGX.1,185,394,990 for the financial year 2020/2021, UGX.515,782,750 was collected representing a performance of 44% of the target."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 280, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "268", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 280, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 Out of the total receipts for the financial year of UGX.22.165 Bn,"], [null, "UGX.22.160 Bn was spent by the entity resulting into an under absorption"], [null, "of UGX.0.006 Bn representing an absorption level of 99.97%."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 281, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None"], "type": "table"}}, {"content": [["", "\uf0b7 Out of the total receipts for the financial year of UGX.22.165 Bn,"], [null, "UGX.22.160 Bn was spent by the entity resulting into an under absorption"], [null, "of UGX.0.006 Bn representing an absorption level of 99.97%."], [null, "\uf0b7 Out of the eleven (11) outputs with a total of seventy-six (76) activities"], [null, "and expenditure of UGX.22.059 Bn taken for assessment, six (6) outputs"], [null, "with a total of thirteen (13) activities and expenditure worth UGX.18.708"], [null, "Bn were fully quantified."], [null, "\uf0b7 I assessed the implementation of six (6) out puts that were fully"], [null, "quantified with a total of thirteen (13) activities worth UGX.18.708Bn and"], [null, "noted that five (5) outputs with a total of twelve (12) activities worth"], [null, "UGX.18.708Bn were partially implemented. Out of the twelve (12)"], [null, "activities, the entity fully implemented five (5) activities (42%); partially"], [null, "implemented three (3) activities (25%) and four (4) activities (33%)"], [null, "remained unimplemented."], [null, "\uf0b7 A review of the strategic plan, budgets and other records revealed that"], [null, "Council does not have a policy in place for promoting sports. There was"], [null, "no evidence availed by management to show that there is any framework"], [null, "of relationship with Local authorities to provide sports facilities."], [null, "\uf0b7 Whereas Council approved funds transfer of UGX.1,431,284,198 to"], [null, "various Associations, there was no evidence to show that Council"], [null, "approved budgets of the individual Associations as required by NCS"], [null, "Regulations. I further noted that the approved funds transfers lacked a"], [null, "schedule supporting the allocation break down."], [null, "\uf0b7 Out of the 51 registered Associations, 49 submitted information about"], [null, "their other sources of funding. The remaining 2 Associations did not"], [null, "submit the required information for the period under review."], [null, "\uf0b7 I noted that some Associations did not deduct and remit WHT totalling to"], [null, "UGX.21,636,694 to the Uganda Revenue Authority."], ["16 Uganda Management Institute (UMI). 2020/21 Opinion Unqualified \uf0b7 I noted that the Institute budgeted to collect NTR of UGX.25.68Bn during the year under review. Out of this, only UGX.9.11Bn was collected, representing a performance of 35.5% of the target. In addition, the Institute budgeted to receive UGX.36.33Bn however, UGX.33.89Bn was availed, resulting in a deficit of UGX.2.44 Bn which is 6.7% of the budget. \uf0b7 Out of the total warrants of UGX.33.88Bn received during the financial year. UGX.29.25Bn was spent by the entity resulting in an unspent balance of UGX.4.63Bn, thus an absorption level of 86.33%. The unspent funds were swept back to the consolidated fund as required by the PFMA. I further noted that the entity did not seek a revision of its budget and work plan as provided for by section 17 (3) of the PFMA 2015. \uf0b7 I noted that the University received off-budget financing to the tune of UGX.185,595,654 which was not declared to treasury and, therefore, not appropriated to the entity by Parliament. These funds were received directly from development partners for undertaking activities not budgeted for. \uf0b7 I reviewed the extent of quantification of outputs and activities for a sample of twelve (12) outputs with a total of sixty-eight (68) activities and expenditure of UGX.35.32Bn and noted that all the twelve (12) outputs with a total of sixty-eight (68) activities and expenditure worth UGX 35.32Bn were not quantified at all. That is, all the sixty-eight (68) activities (100%) within these outputs were not clearly quantified to enable assessment of performance. \uf0b7 I noted that PAYE tax totaling to UGX.589,262,089 was not deducted", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 281, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None"], "type": "table"}}, {"content": "269", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 281, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["from staff gratuity payments on the basis of exemption from PAYE under the Pensions Act However, I noted that the gratuity of staff under contract terms is not regulated by the Pensions Act. \uf0b7 I noted that UMI did not transfer to the Consolidated Fund unspent balances of UGX. 555,953247 on ABSA Project Account at the end of the financial year as advised by the Accountant General.", null, null], ["17", "Uganda National Examinations Board (UNEB).", "\uf0b7 Out of the budgeted NTR of UGX.56.7Bn for the financial year 2020/2021, UGX.55.5 Bn was collected representing a performance of 97.9% of the target."], [null, "2020/21 Opinion Unqualified", null], ["18 BTVET SUPPORT PROJECT 2020/21 Opinion Unqualified \uf0b7 There were no reportable issues.", null, null], ["19", "Petroleum Geoscience Collaboration Programme (ENPE II PROJECT) 2020/21 Opinion", "\uf0b7 Makerere University main Building was gutted down by fire where vital documents got lost in the inferno. Consequently, payment vouchers and supporting documents in support of payments totaling to UGX.368,361,770 which is 65% of the total expenditure were not presented for examination. I was not able to confirm the authenticity of the expenditure."], [null, "Qualified", null], ["20 Makerere Institute of Social Research Beyond Criminal Justice Project Centre File 107453-001 for the Period 1 st January 2013 to 31 st December 2013 \uf0b7 No material issues to report on", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 282, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "270", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 282, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Unqualified", null, null], ["21", "Makerere Institute of Social", "\uf0b7 No material issues to report on"], ["", "Research Beyond Criminal Justice Project Centre File", null], [null, "107453-001 For The Period", null], [null, "1 st January 2014 to 31 st", null], [null, "December 2014", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["22 Makerere Institute Of Social Research Beyond Criminal Justice Project Centre File 107453-001 For The Period 1st January 2015 To 31st December 2015 Opinion Unqualified \uf0b7 No material issues to report on", null, null], ["23", "Makerere Institute of Social Research Beyond Criminal Justice Project Centre File", "\uf0b7 No material issues to report on"], [null, null, ""], ["24 MAKERERE INSTITUTE OF SOCIAL RESEARCH- HARRY FRANK GUGGENHEIM FOUNDATION GRANT FOR THE PERIOD 1st JANUARY 2014 TO 31ST DECEMBER 2014 Opinion Unqualified \uf0b7 No material issues to report on", null, null], ["25", "MAKERERE INSTITUTE OF SOCIAL RESEARCH- HARRY FRANK GUGGENHEIM", "\uf0b7 No material issues to report on"], [null, null, ""], ["26 MAKERERE INSTITUTE OF SOCIAL RESEARCH- HARRY FRANK GUGGENHEIM FOUNDATION GRANT FOR THE PERIOD 1 st JANUARY 2016 TO 31ST DECEMBER \uf0b7 No material issues to report on", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 283, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "271", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 283, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["2016 Opinion Unqualified", null, null], ["27", "Makerere Institute Of Social Research Internally Generated Funds For The Period 1st July 2012 To", "\uf0b7 No material issues to report on"], [null, null, "\uf0b7"], ["28 Makerere Institute of Social Research Internally Generated Funds for The Period 1st July 2013 To 30th June 2014 Opinion Unqualified \uf0b7 No material issues to report on \uf0b7", null, null], ["29", "Makerere Institute of Social Research Internally Generated Funds for The Period 1st July 2014 to 30th", "\uf0b7 No material issues to report on"], [null, null, "\uf0b7"], ["30 Makerere Institute of Social Research Internally Generated Funds for The Period 1st July 2015 to 30th June 2016 Opinion Unqualified \uf0b7 No material issues to report on \uf0b7", null, null], ["31", "Makerere Institute of Social Research- Norhed Project \u201cBuilding and Reflecting on Interdisciplinary Phd-", "\uf0b7 No material issues to report on"], [null, null, "\uf0b7"], ["32 Makerere Institute of Social Research- Norhed Project \u201cBuilding and Reflecting on Interdisciplinary Phd- \uf0b7 No material issues to report on \uf0b7", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 284, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "272", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 284, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Studies for Higher Education Transformation\u201d Grant Number: Uga- 13/0023 For the Period 1st January 2015 to 31st December 2015 Opinion Unqualified", null, null], ["33", "Makerere Institute of Social Research- Norhed Project \u201cBuilding and Reflecting On", "\uf0b7 No material issues to report on"], [null, null, ""], ["34 Makerere Institute of Social Research- Think Tank Initiative Phase 2 Institutional Support Centre File: 107906-001 For The Period 1st January 2014 To 31st December 2014 Opinion Unqualified \uf0b7 No material issues to report on \uf0b7", null, null], ["35", "Makerere Institute of Social Research- Think Tank Initiative Phase 2 Institutional Support Centre", "\uf0b7 No material issues to report on"], [null, null, ""], ["36 Makerere Institute of Social Research- Think Tank Initiative Phase 2 Institutional Support Centre File: 107906-001 For the Period 1st January 2016 to 31st December 2016 Opinion Unqualified \uf0b7 No material issues to report on", null, null], ["37", "Makerere Institute of Social Research- Carnegie", "\uf0b7 No material issues to report on"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 285, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "273", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 285, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Corporation Grant Number B 8741.Ro1 for the Period", "\uf0b7"], [null, "1st January 2014 to 31st", null], [null, "December 2014", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["38 Makerere Institute of Social Research Carnegie Corporation Grant Number B 8741.R01 for the Period 1 st January 2015 to 31 st December 2015 Opinion Unqualified \uf0b7 No material issues to report on \uf0b7", null, null], ["39", "Makerere Institute of Social Research-Carnegie Corporation Grant Number B 8741.Ro1 For the Period", "\uf0b7 No material issues to report on"], [null, null, "\uf0b7"], ["40 Kyambogo University Enable Report June 2020 Opinion Unqualified \uf0b7 No material issues to report on \uf0b7", null, null], ["41", "KYU University ENABLE Project Report Dec 2020 Opinion", "\uf0b7 No material issues to report on"], [null, null, "\uf0b7"], ["42 KYU NORHED-MVP Project Report June 2020 Opinion Unqualified \uf0b7 No material issues to report on \uf0b7", null, null], ["43", "KYU NORHED-MVP Project Report Dec 2020 Opinion", "\uf0b7 No material issues to report on"], [null, null, "\uf0b7"], ["44 Uganda Petroleum Institute Kigumba 2020/21 Opinion Unqualified \uf0b7 I noted that the Institute submitted its strategic plan for the period 2021- 2025 to NPA for review and approval but at the time of audit the certificate of approval had not been received. \uf0b7 Out of the budgeted NTR of UGX.0.67Bn for the year 2020/2021only UGX.0.073Bn was collected, representing a performance of 9% of the target. Similarly, the Institute budgeted to receive UGX.8.5bn from GOU", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 286, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "274", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 286, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["of which UGX.6.65bn was warranted, resulting in a shortfall of UGX. 1.85bn representing 21% of the budget. \uf0b7 I noted that the Institute spent all the funds that was available amounting to UGX.6.92bn representing 100% performance. \uf0b7 I noted that Seven (7) outputs with fifteen (15) activities and expenditure worth UGX.4Bn were fully quantified. That is, 100% of the activities within these out-puts were clearly quantified to enable assessment of performance. I further noted that Twelve (12) outputs with Twenty two (22) activities and expenditure worth UGX.2.49Bn was not quantified to enable assessment of performance. \uf0b7 Out of the Seven (7) quantified outputs three (3) outputs with seven (7) activities and expenditure worth UGX 4.39Bn were fully implemented while two (2) outputs with four (4) activities worth UGX.0.25Bn were partially implemented as two (2) outputs with four (4) activities worth UGX0.33Bn were not implemented. That is none of the four (4) activities was implemented at all. \uf0b7 The Institute had accumulated domestic arrears totalling to UGX. UGX.1.03Bn by the closure of the financial year under review (2020/2021) thereby being expressed to risk of litigation. \uf0b7 The Institute had outstanding receivables totalling to UGX.0.055Bn by the closure of the financial year under review. \uf0b7 Construction of Female hostel block, 2 Lecture halls, Library and an information Centre and Health Centre had delayed by 20months from the initial completion date of 27th March, 2020. \uf0b7 Out of the 103 approved staff established of the Institute, only 84 posts had been filled leaving 19 (18%) positions vacancies. I further noted that in spite of the vacant positions, the Institute had recruited an additional Forty-six (46) staff on contract terms outside the approved structure.", null, null], ["45", "Tb Preventive Therapy for Hiv-Infected Alcohol Users in Uganda: An Evaluation of Safety, Tolerability and Adherence (ADEPTT)", "\uf0b7 I noted that the closing balance of USD 12,178.00 was different from the balance brought forward as at 1st September 2017 of USD 9,615.58 creating a difference of USD 2,562.42. The difference could not be explained by management and was therefore disclosed in the Fund accountability statement as unaccounted for funds."], [null, "Project 2018 Opinion", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 287, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": [["of which UGX.6.65bn was warranted, resulting in a shortfall of UGX. 1.85bn representing 21% of the budget. \uf0b7 I noted that the Institute spent all the funds that was available amounting to UGX.6.92bn representing 100% performance. \uf0b7 I noted that Seven (7) outputs with fifteen (15) activities and expenditure worth UGX.4Bn were fully quantified. That is, 100% of the activities within these out-puts were clearly quantified to enable assessment of performance. I further noted that Twelve (12) outputs with Twenty two (22) activities and expenditure worth UGX.2.49Bn was not quantified to enable assessment of performance. \uf0b7 Out of the Seven (7) quantified outputs three (3) outputs with seven (7) activities and expenditure worth UGX 4.39Bn were fully implemented while two (2) outputs with four (4) activities worth UGX.0.25Bn were partially implemented as two (2) outputs with four (4) activities worth UGX0.33Bn were not implemented. That is none of the four (4) activities was implemented at all. \uf0b7 The Institute had accumulated domestic arrears totalling to UGX. UGX.1.03Bn by the closure of the financial year under review (2020/2021) thereby being expressed to risk of litigation. \uf0b7 The Institute had outstanding receivables totalling to UGX.0.055Bn by the closure of the financial year under review. \uf0b7 Construction of Female hostel block, 2 Lecture halls, Library and an information Centre and Health Centre had delayed by 20months from the initial completion date of 27th March, 2020. \uf0b7 Out of the 103 approved staff established of the Institute, only 84 posts had been filled leaving 19 (18%) positions vacancies. I further noted that in spite of the vacant positions, the Institute had recruited an additional Forty-six (46) staff on contract terms outside the approved structure.", null, null], ["45", "Tb Preventive Therapy for Hiv-Infected Alcohol Users in Uganda: An Evaluation of Safety, Tolerability and Adherence (ADEPTT)", "\uf0b7 I noted that the closing balance of USD 12,178.00 was different from the balance brought forward as at 1st September 2017 of USD 9,615.58 creating a difference of USD 2,562.42. The difference could not be explained by management and was therefore disclosed in the Fund accountability statement as unaccounted for funds."], [null, "Project 2018 Opinion", null], [null, "Unqualified", null], [null, "", null], ["46 MUST- Public Engagement Fund Grant, \u2018Unpacking Design Thinking Principles Through Biomedical Engineering Student\u2019s Innovation Cafes\u2019 Bmeic Project \u2013 2020 Opinion Unqualified \uf0b7 No Reportable issues. \uf0b7", null, null], ["47", "MUST- Serial Killers to Mosquitoes; The Spatial Targeting of Larval Habitats in Rural Uganda Using", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 287, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "275", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 287, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "(Breeding Sites) Project \u2013", null], [null, "2019", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["48 Epidemiology of Coronary Artery Disease Among People with Hiv In Rural Sub-Sahara Africa (CAD) Project 2019 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["49", "MUST- Interventions to Reduce Alcohol Use and Increase Adherence to TB Prevention Therapy Among", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"], ["50 MUST-Population Effectiveness of Dolutegravir Implementation in Sub- Saharan Africa: A Prospective Observational Cohort Study\u201d (DISCO), 2020 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["51", "MUST- Mobile Technology to Extend Clinic \u2013 Based Counseling For Hiv+ In Uganda (Extend), Project \u2013", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"], ["52 MUST- Mama Namtoto: Barriers and Enablers to Gender, Equity and Scale- Up in Tanzania Project Code 108547-002, 2018 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["53", "Must- Research Aimed at Developing Sustainable Low Field Magnetic Resonance Imaging (MRI-NIH) Project", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 288, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "276", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 288, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\u2013 2019", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["54 Advancing Hiv Research at MUST Through A Research Administration Training Project with the University of Virginia (RASA) -2020 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["55", "MUST- Resistance Testing Versus Adherence Support for Management of Patients with Virologic Failure on", "\uf0b7 I noted that the opening bank balance of USD 58,902 was different from the balance brought forward as at 1st July 2017 of USD 49,244, thus creating unexplained difference of USD 9,658. The difference was disclosed in the Fund accountability statement as unaccounted for funds."], [null, "First-Line Antiretroviral Therapy in Sub-Saharan Africa (Revamp) Project No. 04/05-16 \u2013 2018 Opinion", null], [null, "Unqualified", null], [null, "", null], ["56 MUST- Analysis of Past and Projected Future Land Use Change and Its Impact on Sediment Fluxes in The Rwizi Catchment (Vlir Rwizi) Project \u2013 2018 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["57", "MUST- Smart Discharge to Improve Post-Discharge Health Outcomes in Children: A Prospective", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"], ["58 Social Networks, Hiv Stigma, And the Hiv Care Cascade in Rural Uganda Project Of Mbarara Universisty Of Science and Technology- 2019 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["59", "MUST-The Virologic And Pharmacologic", "\uf0b7 No Material Reportable issues."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 289, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "277", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 289, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Determinants of Dolutegravir Failure in East", "\uf0b7"], [null, "Africa (Tld) Project 2019", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["60 MUST- Voices of The Indigenous People Of Uganda Project 2020 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["61", "Education Service Commission", "\uf0b7 I noted the Commission closed the year with outstanding payables/domestic Arrears worth UGX.0.255Bn."], [null, "2020/21 Opinion Unqualified", null], ["62 Multinational Statistical Capacity Building Program for Managing for Development Results - Phase 4.2 (MSCB-AFDB) Project 2017 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["63", "Multinational Statistical Capacity Building Program for Managing for Development Results -", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"], ["64 Multinational Statistical Capacity Building Program for Managing for Development Results - Phase 4.2 (MSCB-AFDB) Project 2019 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 290, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "278", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 290, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, null], ["65", "Multinational Statistical Capacity Building Program for Managing for Development Results -", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"], ["66 Mandela National Stadium Limited 2020/21 Opinion Unqualified \uf0b7 I noted that the Company had no approved strategic plan that is aligned to NDPIII at the time of audit. \uf0b7 I noted that although the Company realized 101% of the budgeted, the original budget was revised from UGX.6.07Bn to UGX.2.63bn to match the expected revenue. \uf0b7 Out of the total receipts for the financial year of UGX.2.66bn, UGX. 1.36 Bn was resulting into an unspent balance of UGX.1.3bn representing an absorption level of 51%. \uf0b7 I noted that the Stadium quantified all its five (5) outputs and all the outputs were partially implemented whereby out of forty four (44) activities, the entity fully implemented seven (7) activities (16%), partially implemented five (5) activities (11%), while thirty two (32) activities (73%) remained unimplemented. \uf0b7 I noted that MNSL liabilities remained on a higher side despite a registered decrease from UGX.5.38Bn in the F/Y 2019/2020 to UGX.3.89Bn as at the end of the financial year under review representing a reduction of UGX.1.49 (28%). \uf0b7 I noted that Mandela National stadium closed the financial year with a receivables figure of UGX.2.42Bn, a reduction of only 7% from receivables of UGX.2.59 as at the end of the previous FYR: 2019/2020. \uf0b7 I noted that the Company did not implement its Staffing Strategy of the current running strategic plan 2018-2023. \uf0b7 I noted that stadium Land continues to have illegal occupants.", null, null], ["67", "The Albertine Region Sustainable Development Project (ARSDP) - MOES", "\uf0b7 Assessment of the Project\u2019s performance for the five year Project work plan implementation status revealed that one objective/goal had been achieved, while the remaining seven (7) were partially achieved."], [null, "Component 2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 291, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "279", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 291, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "UGX.25.18Bn were fully quantified."], [null, null, "\uf0b7 I noted One (1) output with two (2) activities and expenditure worth UGX"], [null, null, "14.53Bn was fully implemented. That is all the two (2) activities within"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 292, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": [["", null, "UGX.25.18Bn were fully quantified."], [null, null, "\uf0b7 I noted One (1) output with two (2) activities and expenditure worth UGX"], [null, null, "14.53Bn was fully implemented. That is all the two (2) activities within"], [null, null, "this output were fully implemented. I further noted that One (1) output"], [null, null, "with Five (5) activities worth UGX.3.60Bn was partially implemented. I"], [null, null, "also noted that One (1) output with one (1) activity worth UGX.0.68Bn"], [null, null, "was not implemented. That is; the one (1) activity was not implemented"], [null, null, "at all."], [null, null, "\uf0b7 Review of the Implementation status of the aide Memoir reports by the"], [null, null, "World bank for the Project monitoring mission activity for the period 27th"], [null, null, "July -3rdAugust 2020, 2nd-10th December 2020 Mission and 16th-25th"], [null, null, "March, 2021 revealed that some of the agreed upon"], [null, null, "actions/recommendations between the World Bank and MoES"], [null, null, "\uf0b7 Implementation status of aide Memoir reports indicated that some"], [null, null, "recommendations had either been partially implemented or not"], [null, null, "implemented."], [null, null, "\uf0b7 I noted that there was no internal audit review carried out on the"], [null, null, "operations of ARSDP during the period under review contrary to the"], [null, null, "requirement in Section II (B) of the ARSDP Financing agreement."], ["68 Kyambogo University 2020/21 Opinion Unqualified \uf0b7 I noted that the University prepared a strategic plan and obtained a certificate of compliance on the 27th of September 2021 from National planning Authority (NPA). \uf0b7 The University collected UGX.40.9Bn (53%) of its budgeted non-tax revenue of UGX.77.1Bn. I further noted that the university received UGX.130.07Bn (93%) out of the budgeted GOU receipts amount of UGX.140.6Bn. \uf0b7 Out of the total warrants for the financial year of UGX.130.07Bn, only UGX.124.5 was spent by the University resulting into unspent balance of UGX.5.53Bn representing an absorption level of 96%. \uf0b7 The University received Donor financing to the tune of UGX.3.11Bn of which only UGX.2.68Bn had been included in the budget reflecting off budget receipts of UGX.0.43Bn. \uf0b7 I noted that out of the 14 outputs sampled, 4 out puts (29%) were fully quantified, 8 out puts (57%) were insufficiently quantified while 2 out puts (14%) were not quantified at all. I also noted that the University did not fully implement any of the 4 fully quantified out puts. \uf0b7 The University had outstanding domestic arrears and outstanding receivables of UGX.13.6Bn and UGX.23.2Bn, respectively. \uf0b7 Some of the University land had illegal land occupants. I further noted that there were variations between the area on the Certificate of Tittle and actual Area on the ground for plot M902 of the University land. \uf0b7 Out of the 1,671 approved posts for the University, only 928 (55.5%) were filled leaving 743 (45.5%) posts vacant. This has a negative impact on education service delivery. \uf0b7 The University had MOUs for only 40 of the 112 affiliated Institutions. I further noted that of the 40 MOUs availed; MOUs for 9 Institutions had expired. \uf0b7", null, null], ["69", "The National Council for Higher Education", "\uf0b7 Out of budgeted NTR collections of UGX. 6.25bn, only UGX. 2.96Bn was"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 292, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "280", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 292, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "2020/21 Opinion Unqualified", "realized, representing a performance of 47.4%. \uf0b7 The Council budgeted to receive UGX.5.4Bn from Government out of which UGX.5.01Bn was availed, resulting in a shortfall of UGX0.39Bn, which is 7.2% of the budget."], [null, "", null], ["70 National Curriculum Development Centre 2020/21 Opinion Unqualified \uf0b7 I noted that whereas NCDC had prepared a strategic plan and whereas a notification of approval had been provided by NPA, a certificate of approval was yet to be obtained. \uf0b7 Out of the budgeted NTR of UGX.250,000,000 for the financial year under review, UGX.93,000,000 was collected representing a performance of 37.2% of the target. \uf0b7 The entity budgeted to receive UGX.40.163Bn from Treasury out of which UGX.37.138 Bn was warranted, resulting into a budget shortfall of UGX.3.025Bn which is 7.5% of the budget. \uf0b7 The Centre received off-budget financing to the tune of UGX.1,661,966,260 which was not transferred to the Consolidated Fund as required by the law and hence not appropriated. \uf0b7 Out of the total receipts for the financial year of UGX 37.137bn a sum of UGX. 36.929bn was spent by the entity resulting into an under absorption of UGX.0.208bn representing absorption level of 99.4%. \uf0b7 Out of the eleven (11) outputs with a total of seventy three (73) activities and expenditure of UGX.36.88 Bn, nine (9) outputs with a total of sixty eight (68) activities and expenditure worth UGX 35.95 Bn were fully quantified, one (1) output with a total of two (2) activities and expenditure worth UGX.0.16Bn were insufficiently quantified, and one (1) output with a total of one (1) activity and expenditure worth UGX 0.77Bn was not quantified to enable assessment of performance. \uf0b7 I assessed the implementation of nine (9) out puts that were fully quantified with a total of sixty eight (68) activities worth UGX.35.95Bn and noted the following; Two (2) outputs with 2 (two) activities worth UGX 0.75 Bn were fully implemented. The entity implemented the two (2) activities (100%) within the outputs. Secondly; seven (7) outputs with a total of sixty six (66) activities worth UGX.35.20Bn were partially implemented. Out of the sixty six (66) activities, the entity fully implemented forty one (41) activities (62%); partially implemented seven (7) activities (11%) and eighteen (18) activities (27%) remained unimplemented. \uf0b7 I noted that goods and services totalling to UGX.5,296,396,760 did not have corresponding WHT transactions totalling to UGX.317,783,806 on the IFMS payment file. I further noted that there was no evidence of exemptions. \uf0b7 Payments totalling to UGX.7,616,021 were made to staff of the Centre contrary to the e-cash guidelines. Similarly, funds totalling to UGX.31,448,969 were irregularly paid to payees who were already", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 293, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": [["", "2020/21 Opinion Unqualified", "realized, representing a performance of 47.4%. \uf0b7 The Council budgeted to receive UGX.5.4Bn from Government out of which UGX.5.01Bn was availed, resulting in a shortfall of UGX0.39Bn, which is 7.2% of the budget."], [null, "", null], ["70 National Curriculum Development Centre 2020/21 Opinion Unqualified \uf0b7 I noted that whereas NCDC had prepared a strategic plan and whereas a notification of approval had been provided by NPA, a certificate of approval was yet to be obtained. \uf0b7 Out of the budgeted NTR of UGX.250,000,000 for the financial year under review, UGX.93,000,000 was collected representing a performance of 37.2% of the target. \uf0b7 The entity budgeted to receive UGX.40.163Bn from Treasury out of which UGX.37.138 Bn was warranted, resulting into a budget shortfall of UGX.3.025Bn which is 7.5% of the budget. \uf0b7 The Centre received off-budget financing to the tune of UGX.1,661,966,260 which was not transferred to the Consolidated Fund as required by the law and hence not appropriated. \uf0b7 Out of the total receipts for the financial year of UGX 37.137bn a sum of UGX. 36.929bn was spent by the entity resulting into an under absorption of UGX.0.208bn representing absorption level of 99.4%. \uf0b7 Out of the eleven (11) outputs with a total of seventy three (73) activities and expenditure of UGX.36.88 Bn, nine (9) outputs with a total of sixty eight (68) activities and expenditure worth UGX 35.95 Bn were fully quantified, one (1) output with a total of two (2) activities and expenditure worth UGX.0.16Bn were insufficiently quantified, and one (1) output with a total of one (1) activity and expenditure worth UGX 0.77Bn was not quantified to enable assessment of performance. \uf0b7 I assessed the implementation of nine (9) out puts that were fully quantified with a total of sixty eight (68) activities worth UGX.35.95Bn and noted the following; Two (2) outputs with 2 (two) activities worth UGX 0.75 Bn were fully implemented. The entity implemented the two (2) activities (100%) within the outputs. Secondly; seven (7) outputs with a total of sixty six (66) activities worth UGX.35.20Bn were partially implemented. Out of the sixty six (66) activities, the entity fully implemented forty one (41) activities (62%); partially implemented seven (7) activities (11%) and eighteen (18) activities (27%) remained unimplemented. \uf0b7 I noted that goods and services totalling to UGX.5,296,396,760 did not have corresponding WHT transactions totalling to UGX.317,783,806 on the IFMS payment file. I further noted that there was no evidence of exemptions. \uf0b7 Payments totalling to UGX.7,616,021 were made to staff of the Centre contrary to the e-cash guidelines. Similarly, funds totalling to UGX.31,448,969 were irregularly paid to payees who were already", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 293, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "281", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 293, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["registered suppliers/vendors on IFMS. Also Funds to the tune of UGX.22,105,200, were utilized for expenses that were not provided for in the budget, to cater for COVID-19 SOPs.", null, null], ["71", "Makerere-Sida Bilateral Research Program 2020/21", "\uf0b7 No material Issues to report on"], [null, null, "\uf0b7"], ["72 Pharm-Biotechnology and Traditional Medicine (Pharmbiotrac) Centre Ace Ii Project 2020/21 Opinion Unqualified \uf0b7 I noted that a sum of USD.4,754,402 (88%) was disbursed in the 4 years period to 30th June 2021 against the planned cumulative expenditure of USD 5,404,514. \uf0b7 I noted that out of the total available financing for the financial year of USD.1,506,515 only USD.1,105,054 was spent by the Project resulting into an unspent balance of USD.401,461 representing an absorption level of 73%. \uf0b7 I noted that all the ten (10) outputs with a total of eighty seven (87) activities and expenditure of USD.1,105,054 were clearly quantified to enable assessment of performance. \uf0b7 I noted that all the ten (10) outputs with a total of eighty seven (87) activities worth USD. 1.1million were partially implemented. Out of eighty seven (87) activities, the entity fully implemented forty five (45) activities (52%), the entity partially implemented fifteen (15) activities (17%), while twenty seven (27) activities (31%) remained unimplemented. \uf0b7 \uf0b7 I noted that the Project had not obtained Patent rights over the various Products it had developed.", null, null], ["73", "Ministry of Education and Sports (MOES)", "\uf0b7 I noted that the Ministry\u2019s Strategic plan was not yet approved by National Planning Authority at the time of audit."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 294, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "282", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 294, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 Out of a sum of UGX. 23.44Bn released to the ministry in respect of"], [null, "Covid-19 response related expenditure only UGX.9.62 (55.4%) remained"], [null, "unspent and was subsequently swept back to the Consolidated Fund"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 295, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None"], "type": "table"}}, {"content": [["", "\uf0b7 Out of a sum of UGX. 23.44Bn released to the ministry in respect of"], [null, "Covid-19 response related expenditure only UGX.9.62 (55.4%) remained"], [null, "unspent and was subsequently swept back to the Consolidated Fund"], [null, "Account."], [null, "\uf0b7 I noted under Note 18 to the financial statements and the statement of"], [null, "financial position that the ministry had receivables totaling to"], [null, "UGX.10.64Bn at the beginning of the financial year which increased to"], [null, "UGX.11,684,417,736 at closure of the year. The outstanding amounts"], [null, "relate to advances which were made to various educational institutions"], [null, "and District Local Government."], [null, "\uf0b7 The ministry had outstanding payables amounting to UGX.39.45 Bn at the"], [null, "closure of the financial year. This was a reduction of UGX.10.74Bn"], [null, "(21.4%) from UGX.50.19Bn in the FY 2019/20. I further noted that UGX."], [null, "29.79Bn (75.5%) of the outstanding amount has been outstanding for"], [null, "more than one year. I also noted that whereas the Ministry had"], [null, "outstanding obligations UGX.50.19Bn at the beginning of the financial"], [null, "year, only UGX.16.69Bn was provided for in the budget resulting into a"], [null, "funding gap of UGX.33.51Bn."], [null, "\uf0b7 Only UGX.18.81Bn of the appropriation for pensions of UGX.28.52Bn"], [null, "(66%) was absorbed leading to under absorption of funds by UGX.9.71Bn"], [null, "(34%). In addition, the Ministry had accumulated pension arrears"], [null, "totaling to UGX.1.47Bn due to delayed payment due to missing"], [null, "documents on pension files."], [null, "\uf0b7 Out of the total verified outstanding court awards of UGX.10.18 Bn, a"], [null, "sum of UGX.4.69Bn (46.1%) relates to accumulated interest costs arising"], [null, "from delayed settlement of court awards. I further noted that whereas"], [null, "the ministry had obligations to the tune of UGX. 15.98Bn and other on-"], [null, "going cases during the financial year, only UGX.1.66Bn was provided for"], [null, "court awards and compensations in the work plan for the financial year"], [null, "under review."], [null, "\uf0b7 Post closure audit inspection on Uganda Teacher School Effectiveness\u2019"], [null, "project (UTSEP) in the Ministry of Education revealed UGX.1.58Bn"], [null, "remained unutilized as at the closure of the F/Y (30th June 2021)."], [null, "\uf0b7 I noted that UGX.3.9Bn of the UGX.5.55Bn advanced to UBOS before"], [null, "project closure date (31st July 20) to carry out data collection"], [null, "(enumeration) for the comprehensive Education Institutions baseline,"], [null, "which was expected to be completed by 30th April 2020 remained"], [null, "outstanding."], [null, "\uf0b7 I noted that the Ministry of Education and Sports still holds the mandate"], [null, "of managing Government scholarships, however information on"], [null, "Scholarship offered at the different Missions and other Government"], [null, "organizations was not available at the Secretariat. In addition, there was"], [null, "no scholarship Policy. I also noted that out of a total of 280 scholarships"], [null, "offered in the previous three years, only 162 were utilized resulting into"], [null, "an under absorption of 118 (42%) scholarships."], ["74 Opec Fund for International Development (OFID)- Vocational Education Project Phase 11 2020/21 Opinion Unqualified \uf0b7 I noted that the 5 year project with total budget of UGX.59.43 Bn that started in June 2017 had only received a total of UGX 14.09 Bn by end of financial year 2020/2021. \uf0b7 Out of the total amount of UGX.14.09Bn availed for financing the Project for the four and a half years covered; only UGX.12.3 Bn (87%) had been absorbed while the unspent balance of UGX.1.7bn was swept back to the Consolidated Fund. \uf0b7 I noted that whereas the Project closing date was 31st December 2021,", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 295, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None"], "type": "table"}}, {"content": "283", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 295, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["two critical project Components 1 & 2 (civil works, supply of equipment and tools) that form 85% of the total project budget had not taken off by the time of concluding the audit (2nd December 2021. \uf0b7 I observed that out of the absorbed funds worth UGX.12.3Bn, UGX.6.6bn (54%) was spent on other Arab funded Projects other than OFID project. \uf0b7 I noted that a total amount of UGX. 6.6Bn of the UGX.12.3 Bn GOU component was irregularly spent on other Arab funded Projects of IDBI, IDBII, KFAED and BADEA without authority.", null, null], ["75", "Uganda Skills Development Project (USDP)- PSFU 2020/21", "\uf0b7 I noted that the Project has made cummulative disbursements of USD.15,345,592 against cummulative commitments of USD.17,617,457 representing 87% performance."], [null, "Opinion Unqualified", null], ["76 Uganda Skills Development Project (USDP) -MOES Opinion Unqualified \uf0b7 I noted that at the close of the financial year 2020/2021, out of the two (2) planned strategic targets/objectives, one objective/goal had been achieved, while the other one had been partially achieved. \uf0b7 Out of the budgeted amount of UGX.58.82Bn budgeted to be received from World Bank during the financial year 2020/2021; a sum of UGX.46.53Bn was received indicating performance of 79% of the target. Similarly, the project budgeted to receive UGX.1.25Bn, of which UGX.1.07Bn was warranted, resulting in a shortfall of UGX. 0.18 Bn (14.4%) of the budget. \uf0b7 I noted that all project outputs were fully quantified. I also noted that the project fully implemented one of the sampled outputs, partially implemented one and two outputs were not implemented. \uf0b7 I noted delayed Signing of Contract for Supply of a Spray track for UTC Lira valued at Euros 205,200 had delayed for 9 months by end of November 2021, following the contracts committee\u2019s approval on 23rd/02/2021. \uf0b7 I noted delayed Installation and testing of Equipment: USD. 8,304,848 by 5 months at the time of audit at the end of November. I further noted that furniture supplies and civil works had also delayed with the delayed period ranging from 1-7 months.", null, null], ["77", "Imagining Gender Futures in Uganda (IMAGENU) Project \u2013 DFC Project No. 17-07-AU- Gulu University -", "\uf0b7 There were no reportable issues."], [null, null, "\uf0b7"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 296, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "284 \n78 Makerere University Busines School. \n2020/21 \nOpinion Unqualified \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 296, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the University had its plan approved and certified by NPA and the plan is aligned to the national development plan. This greatly supports the achievement of NDP-III objectives.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity budgeted to collect NTR of 56.845Bn during the year under review. Out of this, only 33.589bn was collected, representing a performance of 59.1% of the target.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The University budgeted to receive UGX.102.629Bn out of which UGX.97.03Bn was availed, resulting in a shortfall of UGX5.59Bn, which is 5.5% of the budget.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the total warrants of UGX.97.03Bn received during the financial year. UGX.96.85Bn was spent by the entity resulting in an unspent balance of UGX.0.18Bn representing an absorption level of 99.8%. The unspent funds were swept back to the consolidated fund as required by the PFMA.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the School received off-budget financing to the tune of UGX. 549Bn from NOHRED/NORAD Project Support which was not declared to treasury and, therefore, not appropriated to the entity by Parliament.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I reviewed the extent of quantification of outputs and activities for a sample of twelve (12) outputs with a total of seventy three (73) activities and expenditure of UGX.91.667Bn and noted that five (5) outputs with a total of fourteen (14) activities and expenditure worth UGX.3.031Bn were fully quantified. One (1) output with a total of twenty four (24) activities and expenditure worth UGX.77.002Bn, was insufficiently quantified while six (6) outputs with a total of thirty five (35) activities and expenditure worth UGX 11.633Bn were not quantified at all.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I assessed the implementation of five (5) outputs that were fully quantified with a total of fourteen (14) activities worth UGX 3.031Bn and noted that; Three (3) outputs with eight (8) activities and expenditure worth UGX 1.694Bn were fully implemented. One (1) output with two (2) activities worth UGX.1.336Bn was partially implemented while one (1) output with four (4) activities with a budget of UGX.1.159Bn was not implemented.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The entity disclosed receivables to the tune of UGX.21,730,133,664. This reflected an increase in receivables by UGX.12,025,676,995 (124%) from the previous year\u2019s balance of UGX.9,704,456,669. The accumulation of receivables impacts negatively on the operations of the University and the education service delivery.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Statement of Financial Position showed accumulation of payables to the tune of UGX.1,215,592,931 as at 30th June 2021. I noted that these payables were accumulated in the current year and largely related to suppliers of goods and services. Accumulation of payables poses a risk of litigation and or loss of trust against the University from the suppliers of the goods and services.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The financial statements showed that MUBS was involved in several court cases/legal proceedings of a total value UGX.2,899,977,221 in various courts of law that remained pending as at the financial year end. There is a risk that in case of un-favourable rulings, the School may incur more financial losses.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- A review of the statement of cash flow revealed payment of domestic arrears of UGX.9,601,334,785 against UGX.330,708,964 that was budgeted and warranted for payment of domestic arrears. Payment of", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n285", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", null, null], ["79", "The Norwegian Programme for Capacity Development In Higher Education And", "\uf0b7 The Project ended, and as at the end of the six-month period ended 31st December, 2020, funds to the tune of USD. 272,213 (Nok2,054,787) remained unspent, and it was refunded to the Funders."], [null, "Research For Development (Norhed) 2020", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], ["80 Environment for Development Initiative (Efd- Mak Centre) Project Makerere University for The Period 1st January - 31st December 2020 Opinion Unqualified \uf0b7 No material Issues reported", null, null], ["82", "Nurture: Research Training and Mentoring Program for Career Development of", "\uf0b7 No material Issues reported"], [null, null, ""], ["SCIENCE AND INNOVATION SECTOR", null, null], ["1.", "Kiira Motors Corporation. 2019/2020", "\uf0b7 I noted that at the time of the audit (June 2020), out of the planned six (6) strategic targets/goals, three (3) targets had been fully achieved and three (3) were partially achieved"], [null, "Opinion Unqualified", null], ["2\\. Presidential Initiative on Banana Industrial Development (PIBID). \uf0b7 I noted that out of the 3 strategic targets, PIBID partially attained them, with the hope of fully attaining the targets by the end of the strategic", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 298, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "286", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 298, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["2019/2020 Opinion Unqualified plan period. \uf0b7 NTR of UGX.99 Million was collected but not remitted to the consolidated fund and was instead spent at source. \uf0b7 It was observed that the entity has not taken off full operations as it remains cash strapped with limited subventions from the Ministry of Science Technology and innovation. \uf0b7 There was no evidence of the establishment of the Institutional Framework and Governance Board and the renewal of the appointment of the Board and Management Committee Members. \uf0b7 During the financial year, a total of UGX.29,230,320 was paid to the Executive Director as man-day allowance for signing 12 contracts on behalf of the organization, yet this is one of her roles for which a monthly salary is paid. \uf0b7 A total of UGX.272,694,000 was paid to various staff as allowances for working over the weekend. \uf0b7 The internal audit department had only one draft internal audit report with no evidence that the report was submitted to the Accounting Officer and Internal Auditor General. \uf0b7 PIBID recruited staff during the year 2019/2020 without an approved recruitment plan for the period. \uf0b7 Audit noted that PIBID did not have an approved salary structure on which it bases to pay individual staff \uf0b7 I noted that the entity lacked land titles for its land at Sanga (approximately 50 acres) and land where the water source is located at Kyamugambira (approximately 4 acres). \uf0b7 Management deducted UGX.633,205,884, as PAYE, from employee\u2019s salaries but was not remitted to Uganda Revenue Authority. \uf0b7 It was observed that outstanding obligations to the National Security Fund at the end of the Financial Year 2019/2020 were UGX.829,409,254.", null, null], ["3.", "Uganda Institute of Communication Technology (UICT).", "\uf0b7 I noted that out of the budgeted revenue of UGX.3,359,386,101 for the year 2019/2020, only UGX.1,893,012,622 was collected representing a performance of only 56% of the target."], [null, "2019/2020 Opinion", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 299, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": [["2019/2020 Opinion Unqualified plan period. \uf0b7 NTR of UGX.99 Million was collected but not remitted to the consolidated fund and was instead spent at source. \uf0b7 It was observed that the entity has not taken off full operations as it remains cash strapped with limited subventions from the Ministry of Science Technology and innovation. \uf0b7 There was no evidence of the establishment of the Institutional Framework and Governance Board and the renewal of the appointment of the Board and Management Committee Members. \uf0b7 During the financial year, a total of UGX.29,230,320 was paid to the Executive Director as man-day allowance for signing 12 contracts on behalf of the organization, yet this is one of her roles for which a monthly salary is paid. \uf0b7 A total of UGX.272,694,000 was paid to various staff as allowances for working over the weekend. \uf0b7 The internal audit department had only one draft internal audit report with no evidence that the report was submitted to the Accounting Officer and Internal Auditor General. \uf0b7 PIBID recruited staff during the year 2019/2020 without an approved recruitment plan for the period. \uf0b7 Audit noted that PIBID did not have an approved salary structure on which it bases to pay individual staff \uf0b7 I noted that the entity lacked land titles for its land at Sanga (approximately 50 acres) and land where the water source is located at Kyamugambira (approximately 4 acres). \uf0b7 Management deducted UGX.633,205,884, as PAYE, from employee\u2019s salaries but was not remitted to Uganda Revenue Authority. \uf0b7 It was observed that outstanding obligations to the National Security Fund at the end of the Financial Year 2019/2020 were UGX.829,409,254.", null, null], ["3.", "Uganda Institute of Communication Technology (UICT).", "\uf0b7 I noted that out of the budgeted revenue of UGX.3,359,386,101 for the year 2019/2020, only UGX.1,893,012,622 was collected representing a performance of only 56% of the target."], [null, "2019/2020 Opinion", null], [null, "Unqualified", ""], [null, null, "budget lines."], [null, null, "\uf0b7 I noted that the entity had outstanding trade and other receivables"], [null, null, "amounting to UGX.384,635,852."], [null, null, "\uf0b7 I noted temporary staffs that have been working at the Institute for over"], [null, null, "10 years with continuous contract renewals."], [null, null, "\uf0b7 A review of the staff establishment showed that only 41 positions were"], [null, null, "filled out of the established 99 positions, leaving 58 positions vacant."], [null, null, "\uf0b7 I noted that there was neither staff training nor an annual training plan in"], [null, null, "place."], [null, null, "\uf0b7 Contrary to Section 34 (1) of the VAT Act 1996, I noted that"], [null, null, "UGX.4,534,592 worth of VAT remained outstanding as at 30th June 2020."], ["4\\. Ministry of Science and \uf0b7 The Ministry of Science Technology and Innovation was merged with the", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 299, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": "287", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 299, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Technology and Innovation. 2020/21 Opinion Unqualified President\u2019s Office effective July 2021. I however did not obtain evidence of a proper transition plan which has led to delayed disbursement of funding for subventions and independent projects. The merger further rendered 136 technical scientist staff redundant and were not paid emoluments by the end of November, 2021. I advised management to ensure that a smooth transition process is undertaken. \uf0b7 Out of the total budget for the financial year of UGX.150Bn, only UGX.144.6Bn was received by the Ministry resulting into a shortfall of UGX.5.737Bn (equivalent to 3.5% of the budget). Shortfalls in revenue result into non implementation of planned activities. \uf0b7 Out of 20 quantified activities worth UGX.105.9Bn that were assessed; 13 activities representing 65% were fully implemented, 5 activities representing 25% were partially implemented, while 2 activities representing 10% were not implemented. I advised management to roll over critical activities to subsequent years and ensure that they are implemented before the end of the National Development Plan III. \uf0b7 I noted that funds to the tune of UGX.834Mn were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. I advised management to always ensure that proper authorization is obtained before implementing any unbudgeted activities. \uf0b7 Most of the research projects that had received funds for COVID-19 Vaccines and Treatments had not made much progress. Delays were majorly attributed to the late disbursement of funds and delayed delivery of Equipment. I advised management to ensure thorough due diligence before funds are allocated to the projects.", null, null], ["5", "Kiira Motors Corporation. 2020/21 Opinion Unqualified", "\uf0b7 Cabinet approved the roadmap for the commercialisation of the Kiira Electric vehicle project with a seed fund of UGX.143.7Bn to be availed over a period of 4 years effective 2018/19. Only 59% of the seed fund had been released in the previous three financial years, casting doubt as to whether the balance of UGX.58.4Bn (41%) would be released in the"], [null, null, "remaining one year. Failure to promptly fund the project, may lead to"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 300, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": [["Technology and Innovation. 2020/21 Opinion Unqualified President\u2019s Office effective July 2021. I however did not obtain evidence of a proper transition plan which has led to delayed disbursement of funding for subventions and independent projects. The merger further rendered 136 technical scientist staff redundant and were not paid emoluments by the end of November, 2021. I advised management to ensure that a smooth transition process is undertaken. \uf0b7 Out of the total budget for the financial year of UGX.150Bn, only UGX.144.6Bn was received by the Ministry resulting into a shortfall of UGX.5.737Bn (equivalent to 3.5% of the budget). Shortfalls in revenue result into non implementation of planned activities. \uf0b7 Out of 20 quantified activities worth UGX.105.9Bn that were assessed; 13 activities representing 65% were fully implemented, 5 activities representing 25% were partially implemented, while 2 activities representing 10% were not implemented. I advised management to roll over critical activities to subsequent years and ensure that they are implemented before the end of the National Development Plan III. \uf0b7 I noted that funds to the tune of UGX.834Mn were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. I advised management to always ensure that proper authorization is obtained before implementing any unbudgeted activities. \uf0b7 Most of the research projects that had received funds for COVID-19 Vaccines and Treatments had not made much progress. Delays were majorly attributed to the late disbursement of funds and delayed delivery of Equipment. I advised management to ensure thorough due diligence before funds are allocated to the projects.", null, null], ["5", "Kiira Motors Corporation. 2020/21 Opinion Unqualified", "\uf0b7 Cabinet approved the roadmap for the commercialisation of the Kiira Electric vehicle project with a seed fund of UGX.143.7Bn to be availed over a period of 4 years effective 2018/19. Only 59% of the seed fund had been released in the previous three financial years, casting doubt as to whether the balance of UGX.58.4Bn (41%) would be released in the"], [null, null, "remaining one year. Failure to promptly fund the project, may lead to"], [null, null, "high-cost overruns and delays in realising the intended objectives. In"], [null, null, "addition, it may cast doubts on its sustainability."], [null, null, "\uf0b7 KMC signed a Memorandum of Understanding (MOU) with National"], [null, null, "Enterprise Corporation (NEC) on the 15th January 2019 for the"], [null, null, "construction of the Kiira Vehicle Plant start-up facilities at the cost of"], [null, null, "UGX.63.64Bn. I noted that of the civil works that were to be completed"], [null, null, "by June 2021 (a period of 2 years and six (6) months), only 82% of those"], [null, null, "works had been completed due to insufficient funding. Underfunding has"], [null, null, "affected the progress of the plant construction which further delays the"], [null, null, "realisation of the intended objectives."], [null, null, "\uf0b7 Ministry of Science, Technology and Innovation (represented by Kiira"], [null, null, "Motors Corporation) and Makerere University were collaborating in the"], [null, null, "Development of a Low-Cost Open Design Medical Ventilator named"], [null, null, "Bulamu, that could be manufactured locally. Although UGX.74Mn was"], [null, null, "received from Resilient Africa Network Ran Ltd towards the completion of"], [null, null, "the development of the Ventilator, the development was behind schedule."], [null, null, "The delays may affect the realisation of intended objectives."], [null, null, "\uf0b7 I noted that Makerere University received UGX.8.92Bn for the Kiira"], [null, null, "Motors Project between FY2012/13 and FY2015/16 for the construction of"], [null, null, "the Kiira Vehicle Plant Start-Up facilities in Jinja. However, the university"], [null, null, "had not released these funds for over eight years. I advised management"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 300, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": "288", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 300, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "to follow up on the matter with all responsible stakeholders."], ["6 Uganda National Council for Science and Technology. 2020/21 Opinion Unqualified \uf0b7 I noted that out of the budgeted revenue of UGX.20.53Bn for 2020/21; UGX.24.59Bn was collected, representing a performance of 120% of the target. \uf0b7 Out of the 41 outputs assessed, 34 outputs representing 83% were fully implemented; four (4) outputs representing 10% were partially implemented, while three (3), representing 7%, were not implemented. \uf0b7 I noted that there was no evidence that the Accounting Officer prepared or submitted the annual budget performance reports of the Council by 31st July 2021 as required by regulations. \uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to the line Ministry for consolidation and onward transmission to the Ministry of Finance Economic and Economic Planning. \uf0b7 I established that UGX.94Mn was directly paid to staff\u2019s personal bank accounts, yet this money could have been directly paid to the intended final recipients. \uf0b7 Out of the 85 planned activities assessed, 69 outputs/activities representing 81% were fully implemented; 9 outputs/activities representing 11% were partially implemented, while seven (7) outputs/activities representing 8% were not implemented at all. \uf0b7 I noted that the Council did not produce the annual report as required by the UNCST Act. \uf0b7 A review of the procurement file for the Supply of ICT Equipment under EDCTP-SCRECU Project revealed no evidence of any public bid opening session, which creates doubts as to whether the bidders attended the bid opening session. \uf0b7 Audit noted that the Council had outstanding Pay As You Earn (PAYE) payments relating to July 2019 and June 2020 amounting to UGX.45,457,013 as of 30th June 2021, which had not been remitted to Uganda Revenue Authority", null, null], ["7", "Uganda Industrial Research Institute (UIRI). 2020/21 Opinion", "\uf0b7 I noted that 3.2 million masks were tested, treated and packaged, but the contract for the distribution of the reusable face masks was terminated after only 1.5 million masks had been consumed. The stock of over 1.7 million face masks has remained unutilised at the time of reporting. Government is likely to incur nugatory expenditure of almost UGX.4.08Bn"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 301, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": [["", null, "to follow up on the matter with all responsible stakeholders."], ["6 Uganda National Council for Science and Technology. 2020/21 Opinion Unqualified \uf0b7 I noted that out of the budgeted revenue of UGX.20.53Bn for 2020/21; UGX.24.59Bn was collected, representing a performance of 120% of the target. \uf0b7 Out of the 41 outputs assessed, 34 outputs representing 83% were fully implemented; four (4) outputs representing 10% were partially implemented, while three (3), representing 7%, were not implemented. \uf0b7 I noted that there was no evidence that the Accounting Officer prepared or submitted the annual budget performance reports of the Council by 31st July 2021 as required by regulations. \uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to the line Ministry for consolidation and onward transmission to the Ministry of Finance Economic and Economic Planning. \uf0b7 I established that UGX.94Mn was directly paid to staff\u2019s personal bank accounts, yet this money could have been directly paid to the intended final recipients. \uf0b7 Out of the 85 planned activities assessed, 69 outputs/activities representing 81% were fully implemented; 9 outputs/activities representing 11% were partially implemented, while seven (7) outputs/activities representing 8% were not implemented at all. \uf0b7 I noted that the Council did not produce the annual report as required by the UNCST Act. \uf0b7 A review of the procurement file for the Supply of ICT Equipment under EDCTP-SCRECU Project revealed no evidence of any public bid opening session, which creates doubts as to whether the bidders attended the bid opening session. \uf0b7 Audit noted that the Council had outstanding Pay As You Earn (PAYE) payments relating to July 2019 and June 2020 amounting to UGX.45,457,013 as of 30th June 2021, which had not been remitted to Uganda Revenue Authority", null, null], ["7", "Uganda Industrial Research Institute (UIRI). 2020/21 Opinion", "\uf0b7 I noted that 3.2 million masks were tested, treated and packaged, but the contract for the distribution of the reusable face masks was terminated after only 1.5 million masks had been consumed. The stock of over 1.7 million face masks has remained unutilised at the time of reporting. Government is likely to incur nugatory expenditure of almost UGX.4.08Bn"], [null, "Unqualified", "in the event no market is obtained for the masks."], [null, null, "\uf0b7 I noted that a number of machinery at the UIRI Namanve campus had"], [null, null, "been procured ahead of the proposed contract on mask production in the"], [null, null, "textile section. I noted that some equipment has remained unused/idle or"], [null, null, "has not been put to use due to lack of technical support from the supplier"], [null, null, "to operationalize the equipment. Management attributed the failure to the"], [null, null, "restrictions on international travel for the supplier\u2019s technical staff to"], [null, null, "come."], [null, null, "\uf0b7 The absence of a Board Chairperson has resulted in the failure of the"], [null, null, "Board to be constituted to meet and handle its mandate as provided for"], [null, null, "under Section 7 of the UIRI Act 2003. There is no evidence that the"], [null, null, "Board has ever met. There is a risk that the entity will lose strategic"], [null, null, "focus, since there is no supervisory oversight over its operations."], [null, null, "\uf0b7 I observed that the Institute signed MoUs with the different incubatees in"], [null, null, "which funds have been spent to support the projects. However, the"], [null, null, "Institute has not signed any binding contracts with the participants, which"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 301, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": "289", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 301, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "makes dispute resolution difficult in case it arises. In addition, I noted"], [null, null, "that 50 of the 95 incubatees reviewed had expired MoUs at the time of"], [null, null, "reporting, while others were not paying NTR to the Institute as per"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 302, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": [["", null, "makes dispute resolution difficult in case it arises. In addition, I noted"], [null, null, "that 50 of the 95 incubatees reviewed had expired MoUs at the time of"], [null, null, "reporting, while others were not paying NTR to the Institute as per"], [null, null, "agreement."], [null, null, "\uf0b7 It was observed that UIRI paid a total of UGX.1.286Bn in gratuity, for"], [null, null, "which PAYE was wrongly computed, resulting into an overpayment of"], [null, null, "UGX.100,778,201 to staff. The staff over payments can lead to financial"], [null, null, "loss to government, in the event the Institute is unable to recover from"], [null, null, "the concerned staff."], ["GENDER AND SOCIAL DEVELOPMENT SECTOR \uf0b7", null, null], ["1", "Equal Opportunities Commission. 2020/21", "\uf0b7 Out of the approved budget of UGX.12,071,754,441, a sum of UGX.12,016,602,345 was realized resulting into a shortfall of UGX. 55,152,096.00, representing 0.46%. \uf0b7 Out of the warrants of UGX.12,016,602,345, a sum of UGX.11,874,386,080 was spent indicating an absorption rate of 98.8 %."], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "representing 91% of the total budget, and noted that 1 output (11%)"], [null, null, "with 04 activities and expenditure worth UGX. 1.05Bn were fully"], [null, null, "quantified. In addition, Four (4) outputs with twenty-five 25) activities"], [null, null, "worth UGX.9.47 Bn were partially implemented. Out of the twenty-five"], [null, null, "(25) activities, the entity fully implemented sixteen (16) activities, two (2)"], [null, null, "activities were partially implemented, while seven (7) activities remained"], [null, null, "unimplemented."], [null, null, "\uf0b7 I noted long outstanding receivables of UGX.211,105,359 from interdicted"], [null, null, "staff, and management has not yet instituted recovery measures due to"], [null, null, "the ongoing court cases."], [null, null, "\uf0b7 I noted that funds to the tune of UGX.63,568,761 were irregularly re-"], [null, null, "allocated from the activities on which they were budgeted and spent on"], [null, null, "other activities without seeking and obtaining the necessary approvals."], [null, null, "\uf0b7 I noted that 244 accumulated cases from 2017/18 are still pending as at"], [null, null, "30th June 2021. Over the last three years 48% of the registered cases"], [null, null, "have remained un-concluded during the year of registration. In addition,"], [null, null, "the legal department that handles petitions is at a 50% staffing level."], [null, null, "\uf0b7 I noted that the Commission has 81 approved staff positions, but only 50"], [null, null, "(62%) positions were filled leaving 31 (31%) posts vacant."], [null, null, "\uf0b7 I noted that the land and building on plot 7c, Luthuli close, Bugolobi"], [null, null, "where the EOC offices are located was transferred to the Commission by"], [null, null, "the Ministry of Gender, labour and Social Development. However, there"], [null, null, "was no trace of the original title, and there was no documentary evidence"], [null, null, "of handover of the title to EOC management."], [null, null, "\uf0b7 I noted that the report on gender and equity compliance of the budget"], [null, null, "framework papers was produced in December 2020, eleven (11) months"], [null, null, "later than the Parliamentary submission of the required certification and"], [null, null, "responsive measures of February 2020, contrary to the PFMA."], [null, null, "\uf0b7 I noted that the Commission lacked an independent Audit Committee,"], [null, null, "however, the functions of the Committee were being undertaken by the"], [null, null, "Commissioners who are part of the Commission management, thus"], [null, null, "posing serious challenges of conflict of interest."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 302, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": "290 \n2 Ministry of Gender, Labour and Social Development (MoGLSD) \n2020/21 \nOpinion \nUnqualified", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 302, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the approved budget of UGX. 153.01Bn, a sum of UGX.148.47Bn was warranted resulting into a shortfall of UGX.4.54Bn, representing 2.97% of the budget.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out UGX.148.47Bn warranted, a sum of UGX.147.63Bn was spent indicating an absorption rate of 99.4%.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Ministry received off-budget financing of UGX.11.598 Bn that was not appropriated by Parliament.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I sampled fifteen (15) outputs with a total of thirty (30) activities and expenditure worth UGX.105.44Bn, representing 87.76% of the total budget, and noted that 9 outputs (36%) with 11 activities worth UGX.79.33Bn were not quantified at all. In addition, out of the 16 quantified outputs with 20 activities assessed, 12 outputs (75%) were achieved, 15 activities (75%) were fully achieved/implemented, while 4 out puts with 5 activities representing 25% were partially achieved/implemented.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Ministry had payables of UGX 37,394,048,164. Of these, a sum of UGX 36,075,485,050 (96.5%) related to funds not remitted to older persons under the Social Assistance Grant and Empowerment Programme (SAGE).", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Ministry made a cumulative total disbursement of UGX.113.22Bn to the Youth Livelihood Programme (YLP) by 30th June 2021 to 13,095 Youth groups. However, out of the expected recoverable funds of UGX.78.10Bn, only UGX.40.14Bn was recovered, leaving an outstanding amount of UGX.37.96Bn.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The Ministry recovered UGX.40.14Bn YLP funds from Local Governments, but only UGX.37.59Bn was transferred to the recovery account in BOU, leaving a balance of UGX.2.54Bn.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that out of the total UGX. 37.59Bn received on the YLP revolving fund account in Bank of Uganda, only UGX.19.93Bn (53%) was revolved to other Youth Interest Groups, leaving a balance of UGX.17.65Bn (47%) not revolved.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the budgeted UGX.188Bn for the Women Entrepreneur Programme (UWEP) for the period of five years since financial year 2015/16, only 135Bn (72%) had been released over the same period leading to a programme budget shortfall of UGX.53Bn (28%).", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of UGX.27.61Bn due for recovery under UWEP by 30th June, 2021, a sum of UGX.20.19Bn was recovered leaving a balance of UGX.7.42Bn, thus indicating a recovery rate of 73%.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A sum of UGX.2.64Bn recovered under the UWEP could not be tagged to specific Local Governments and individual women groups.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Labour advisory (LAB) Board did not function in the financial year under review to deliberate on matters affecting workers. This meant that no advisory services were extended to Government on matters of employment and industrial relations.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Medical Arbitration Board (MAB) met only in one quarter during the entire financial year (February 2021) despite having over 150 pending cases awaiting arbitration as at 30th June 2021. I further noted that some cases have been pending for over 9 years.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that Uganda has only three signed bilateral agreements in protection of migrant workers with Saudi Arabia, the Hashemite Kingdom of Jordan and the United Arab Emirates. Agreements with other", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "291", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", null, null], ["3", "National Council for People with Disabilities 2020/21", "\uf0b7 Out of the approved budget of UGX.1,236,047,430 expected through the MOGLSD a sum of UGX.921,555,246 was realized resulting into a shortfall of UGX. 314,492,184, which is 75% of the budget. The shortfall has since"], [null, null, "led to 43% increase in payables relating to mainly unpaid gratuities to"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 304, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", null, null], ["3", "National Council for People with Disabilities 2020/21", "\uf0b7 Out of the approved budget of UGX.1,236,047,430 expected through the MOGLSD a sum of UGX.921,555,246 was realized resulting into a shortfall of UGX. 314,492,184, which is 75% of the budget. The shortfall has since"], [null, null, "led to 43% increase in payables relating to mainly unpaid gratuities to"], [null, "Opinion Unqualified", "staff, totalling UGX 539,360,000 at year end."], [null, null, "\uf0b7"], [null, null, "\uf0b7 Out of the total funds available of UGX.922,507,816 a sum of UGX.896,409,230 was spent indicating an absorption level of 97.3 %."], [null, null, "The unspent balance of UGX. 26,098,586 related to the production of the"], [null, null, "disability status report activities that were not undertaken."], [null, null, "\uf0b7"], [null, null, "\uf0b7 I sampled eleven (11) outputs with thirteen (13) activities worth UGX."], [null, null, "877,320,000, representing 71% of the total budget, and noted that 10"], [null, null, "outputs (91%) with eleven (11) activities and expenditure worth UGX."], [null, null, "0.5899Bn were fully quantified. In addition, One (1) output with two (2)"], [null, null, "activities worth UGX.0.1221Bn was insufficiently quantified. Out of the"], [null, null, "ten (10) fully quantified outputs, three (3) outputs with three (3)"], [null, null, "activities worth UGX 0.0135Bn were fully implemented; six (6) outputs"], [null, null, "with seven (7) activities worth UGX 0.558Bnwere partially implemented"], [null, null, "and one (1) output with two (2) activities worth UGX 0.0184 were not"], [null, null, "implemented. The disability status report was not developed."], [null, null, "\uf0b7"], [null, null, "\uf0b7 To-date, council has not fully taken over the property of the Uganda"], [null, null, "Foundation for the blind, as such land located at Kireka and Mayuge has"], [null, null, "since been encroached upon by unknown persons. Council is at risk of"], [null, null, "losing these and other properties due to delays in taking possession and"], [null, null, "title."], ["4 National Council for Older Persons (NCOP) 2020/21 Opinion Unqualified \uf0b7 Out of the budgeted revenue of UGX. 726,000,000 for the financial year 2020/2021, UGX. 726,606,000 was received representing over 100% availability of funds for expenditure. This resulted in excess revenue of UGX. 606,000. \uf0b7 Out of the released funds amounting to UGX. 726,606,000 and unbudgeted Non-Tax revenue of UGX 1,198,590, only UGX.709,472,400 was spent by the entity resulting into an unspent balance of UGX. 18,332,190, representing absorption level of 97.5%.", null, null], ["5", "Uganda National Cultural Centre 2020/21", "\uf0b7 Out of the approved budget of UGX 15,407,572,000 a sum of UGX 13,245,324,701 was realized, resulting into a shortfall of UGX 2,162,247,299 representing 14% of the total budget. \uf0b7 Out of the total receipts of UGX 13,245,324,701, only UGX 10,700,171020 was spent by the entity resulting in an unspent balance of"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 Following parliament\u2019s pronouncement to collect UGX 1.6 Bn from a"], [null, null, "private company for the use of Nommo Gallery, Recovery measures have"], [null, null, "remained futile. UNCC has since stopped charging rent from the"], [null, null, "company."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 304, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "292", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 304, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 Covid-19 stimulus funds amounting to UGX 6.8 Bn were paid in two"], [null, null, "batches to music/Arts promoters, without clearly documented criteria."], ["6 The National Children Authority (NCA) 2020/21 Opinion Unqualified \uf0b7 Out of the approved budget of UGX. 901,908,000 a sum of UGX. 826,112,357 was realized resulting into a shortfall of 104,143,334, representing 8.7%. \uf0b7 Out of the subvention receipts of UGX. 797,764,666 and non-tax revenue of UGX 28,347,691, a sum of UGX. 825,311,734 was spent indicating an absorption rate of 99.9%. \uf0b7 The Authority has no governing board and this has led to absence of policy and operational guidelines, and irregular short term employment contracts. \uf0b7 The report on the state of children under the lock down period revealed limited access of reading materials provided, increase in physical abuse, teenage pregnancies and in some instances death. This was due to inadequacies in law enforcement, capacity and resource constraints for extension works at district level and lack of community awareness on the child rights legal framework.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 305, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", null, "\uf0b7 Covid-19 stimulus funds amounting to UGX 6.8 Bn were paid in two"], [null, null, "batches to music/Arts promoters, without clearly documented criteria."], ["6 The National Children Authority (NCA) 2020/21 Opinion Unqualified \uf0b7 Out of the approved budget of UGX. 901,908,000 a sum of UGX. 826,112,357 was realized resulting into a shortfall of 104,143,334, representing 8.7%. \uf0b7 Out of the subvention receipts of UGX. 797,764,666 and non-tax revenue of UGX 28,347,691, a sum of UGX. 825,311,734 was spent indicating an absorption rate of 99.9%. \uf0b7 The Authority has no governing board and this has led to absence of policy and operational guidelines, and irregular short term employment contracts. \uf0b7 The report on the state of children under the lock down period revealed limited access of reading materials provided, increase in physical abuse, teenage pregnancies and in some instances death. This was due to inadequacies in law enforcement, capacity and resource constraints for extension works at district level and lack of community awareness on the child rights legal framework.", null, null], ["7", "National Library of Uganda 2020/21", "\uf0b7 Out of the approved budget of UGX.1,228,432,118 expected, a sum of UG.1,076,772,693 was realized resulting into a shortfall of UGX."], [null, null, "151,659,425, which is 87.6% of the budget. The shortfall has since led to"], [null, "Opinion Unqualified", "increased rental and gratuity arrears."], [null, null, "\uf0b7 Out of the total funds available of UGX. 1,076,772,693 a sum of UGX.1,041,279,372 was spent indicating an absorption level of 96.7%."], [null, null, "The unspent balance of UGX. 35,493,321 was meant for the clearance"], [null, null, "costs of the periodical book donations from Book Aid International"], [null, null, "\uf0b7 I sampled eleven (11) outputs with a total of twelve (12) activities worth"], [null, null, "UGX.852,906,000, representing 69.4% of the total budget, and noted"], [null, null, "that Ten (10) outputs with a total of eleven (11) activities and"], [null, null, "expenditure worth UGX.0.801Bn were fully quantified. In addition, One"], [null, null, "(01) output with One (01) activity and expenditure worth UGX.0.012 Bn"], [null, null, "was not quantified. Out of the ten (10) fully quantified outputs, One (1)"], [null, null, "output with one (1) activity and expenditure worth UGX 0.010Bn was fully"], [null, null, "implemented. Six (06) outputs with seven (7) activities worth"], [null, null, "UGX.0.775Bn were partially implemented. Three (3) outputs with two (3)"], [null, null, "activities worth UGX.0.028Bn were not implemented. Review of the entity"], [null, null, "strategic plan 2016-2021 and production of a new one, and Sensitization"], [null, null, "of publishers on ISBN requirements were some of the activities not"], [null, null, "undertaken."], [null, null, "\uf0b7 NLU has outstanding rental obligations of up to UGX.145,351,824 which"], [null, null, "only attract litigation."], [null, null, "\uf0b7 2 Acres of land initially allocated to the NLU has been re-allocated without"], [null, null, "compensation."], ["8 National Women\u2019s Council 2020/21 Opinion Unqualified \uf0b7 Out of the approved budget of UGX. UGX.3,589,554,501, a sum of UGX.3,644,076,229 was realized resulting into a shortfall of UGX.31,238,272, representing 99% performance. \uf0b7 Out of the total released funds for the financial year of UGX.3,644,076,229, only UGX.3,597,158,934 was spent by the entity resulting into an unspent balance of UGX.46,917,295 representing an absorption level of 99%. \uf0b7 I noted that NWC did not link its budget to the strategic plan with activities worth UGX.1,686,300,000 that were specified in the entity", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 305, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "293", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 305, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["strategic plan for implementation during the fourth year (20/21) of the plan not being included in the budget for FY 2020-2021. NWC strategic plan is not aligned to that of the MoGLSD and hence not aligned to the NDP III. \uf0b7 All nineteen (19) outputs with thirty-five (35) activities and expenditure of UGX.3,597,158,934 were not quantified to enable assessment extent of output and activity implementation. \uf0b7 No risk assessments or review of internal controls were undertaken on the council\u2019s operational processes during the year.", null, null], ["9", "National Youth Council 2020/21 Opinion Unqualified", "\uf0b7 The entity budgeted to receive UGX.3.075Bn out of which UGX.2080Bn was received, resulting in a shortfall of UGX.0.995 Bn which is 32% of the budget. I also noted that out of the total receipts for the financial year of UGX 2.080 Bn, UGX 2.079 Bn was spent by the entity representing absorption level of 100%."], [null, "", null], ["10 National Social Security Fund 2020/21 Opinion Unqualified \uf0b7 No significant matters to report on. \uf0b7", null, null], ["11", "UNFPA Funded Programme Ref; UGA08CMH/HIV/GBV/UFP/A YP/FGM implemented by", "\uf0b7 No significant matters to report on."], [null, null, ""], ["12 UNFPA Funded Programme Ref: UGA08CMH/HIV/GBV/UFP/A YP/FGM implemented by The Ministry of Health, 2020 Opinion Unqualified \uf0b7 No significant matters to report on.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 306, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "294", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 306, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, null], ["13", "UNFPA Funded Programme Ref; Uga08cmh/Hiv/Gbv/Ufp/Ayp /Fgm Implemented by The", "\uf0b7 No significant matters to report on."], [null, null, "\uf0b7"], ["14 UNFPA Country Programme Component of Data and Populationdynamics Implemented by Ministry of Gender, Labour & Social Development (Mglsd) 2020 Opinion Unqualified \uf0b7 No significant matters to report on.", null, null], ["15", "Unfpa Funded Programmeme Component of Data and Population Dynamics Implemented by", "\uf0b7 No significant matters to report on."], [null, null, ""], ["16 Unfpa Funded Programme Component of Data and Population Dynamics Implemented by National Population Council (Npc) 2020 Opinion Unqualified \uf0b7 No significant matters to report on.", null, null], ["17", "Unfpa Funded Programme Component of Data and Population Dynamics Implemented by Uganda", "\uf0b7 No significant matters to report on."], [null, null, ""], ["HEALTH SECTOR", null, null], ["1.", "Centre for Disease Control and Prevention (CDC) Opinion Unqualified", "\uf0b7 I noted a variance of US$.241,921 between the expenditure recorded in the accounting system and the expenditure reported in the quarterly financial reports for the year ended 30th September 2020. The expenditure reported per quarterly reports totaled US$.3,177,866 as opposed to the audited total expenditure of US$.2,935,945."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 307, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "295", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 307, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "Agreement Grant/ Notice of Award vs actual expenditures showed that"], [null, "", "management of CDC \u2013 UPS had executed most of the budgeted activities"], [null, null, "for the year ended 30th September 2020. The overall budget"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 308, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", "", "Agreement Grant/ Notice of Award vs actual expenditures showed that"], [null, "", "management of CDC \u2013 UPS had executed most of the budgeted activities"], [null, null, "for the year ended 30th September 2020. The overall budget"], [null, null, "performance was 97%."], [null, null, "\uf0b7 I further noted instances of budget over runs to a tune of US$.198,986"], [null, null, "on three budget lines, a practise not permitted under the Cooperative"], [null, null, "Agreement."], [null, null, "\uf0b7 From the tests conducted on a sample of non-payroll disbursements (i.e."], [null, null, "supplies contract costs, Fringe Benefits, travel and other direct costs), I"], [null, null, "noted that cost totalling to US $ 54,135 were inadequately supported."], [null, null, "\uf0b7"], [null, null, "\uf0b7 I noted that monthly financial returns are supposed to be submitted by"], [null, null, "the 15th day of the subsequent month, but this was not complied"], ["2 Centre for Disease Control Project (PEPFAR Grant No: 6NU2GGH002221-01-01) 30 th September 2020 Opinion Unqualified \uf0b7 I noted that there was low absorption of project funds. I noted that out of the total receipts; only USD 1,864,527 (UGX. 6,884,001,756) was utilized leaving a balance of USD. 868,756 (UGX. 3,207,525,075); representing an absorption level of 68.2%. \uf0b7 I observed that the Project Chart of Accounts was not aligned with the IFMS Accounting codes. \uf0b7 I noted significant delays in the approval and payment for most activities whereby the average lead time for processing a payment was over three (3) months", null, null], ["3.", "The Italian Support to the Ugandan Health Sector Strategic Plan III (HSSP III) and the Peace, Recovery", "\uf0b7 The entire budgeted revenue of UGX.10,543,205,000 in respect of external financing by the Government of the Italian Republic was not received during the year. As a result, no planned activity was implemented."], [null, "and Development Plan (PRDP) for Northern Uganda - Karamoja Region Staff Housing Project (KRSHP) \u2013 Ministry of Health Project. 2019/20", null], [null, "Opinion", ""], [null, "Unqualified", null], [null, "", null], ["4\\. The Rehabilitation and Expansion of Kayunga and Yumbe Hospitals Project (KAYUP) -BADEA No. 0761, OFID No. 1628P and SFD No. 6/620 - Ministry of Health Project. 2019/20 \uf0b7 The project experienced significant revenue shortfalls. Out of the expected receipts of USD 19,064,124.79, the project received funding totalling USD.8,252,401.61 constituting USD. 6,240,515.26 from external sources and USD.2,011,886.35 (UGX. 7,505,000,000) from GoU counterpart contribution. This translated into a budget shortfall of USD 10,811,723.18 (representing 56.71% of the approved budget). \uf0b7 There were delays in Project implementation. The project became effective on 16th April 2015 and was initially expected to be completed on 28th February 2020 which was later extended to 31st December 2021. However, the cumulative project progress was at 99.5% as at 30th June 2020\\. Major delays were identified in the procurement and installation of Medical equipment, Ambulances, mini-buses and Pick-ups.", null, null], ["5.", "Uganda National Health Research Organization (UNHRO).", "\uf0b7 UNHRO did not have an approved strategic plan for the period 2015/16 - 2019/20. The organization implemented a draft strategic plan for five years 2015/2016-2019/2020. I observed that the entity did not fully"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 308, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "296", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 308, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "2019/20", "achieve any of the 6 strategic objectives in its expired draft strategic plan"], [null, "Opinion Unqualified", "it has been implementing for the last five years. \uf0b7 I noted that the Organization did not have a governing Board during the year under review, after the term of office for all former members of the Board expired in 2016."], [null, "", null], ["6\\. Uganda Nurses and Midwives Council (UNMC). 2019/20 Opinion Qualified \uf0b7 The Council made payments worth UGX 1,465,751,440 in the year ended 30th June 2019 which did not have supporting documents such as invoices, payment request forms and payment vouchers. I noted that no action had been taken by Management to account for the funds in the year ended 30th June 2020. \uf0b7 Management reported a financial loss of UGX.444,400,000 during the year. The amount was transferred from UNMC\u2019s Stanbic Bank Account No. 9030005852950 to M/S RAM Engineering (U) Ltd under fraudulent circumstances. \uf0b7 Council failed to collect budgeted revenue amounting to UGX 557,669,951 during the year. \uf0b7 Council had a total of UGX. 7.77bn available for implementation of planned activities. The total receipts for the financial year under review were UGX 2.71 bn. However, only UGX 1.84bn was absorbed (representing 23.7%) leaving a balance of UGX. 5.93bn. \uf0b7 I observed that the Council partially implemented six (6) of its planned outputs with a total of Nineteen (19) activities worth UGX 268.41M. I also observed that seven (7) outputs with a total of twenty (20) activities were not implemented at all. \uf0b7 The entity did not prepare and submit the annual monitoring plans to MoFPED and NPA as required. Further, the entity did not prepare and submit quarterly monitoring reports to the MoFPED as required. \uf0b7 A review of the Organization\u2019s Annual cumulative performance report and", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 309, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "297", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 309, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["the entity work plan revealed cases where the reported set targets were not consistent with the set targets in the entity work plans. \uf0b7 I observed conflicting in the Council governing laws. Section 51(2) of the Public Finance Management Act, 2015 requires the Accounting Officer of a public corporation, within two months after the end of each financial year, to prepare and submit to the Accountant-General, a summary statement of financial performance of the public corporation and give a copy of the summary statement to the Secretary to the Treasury. On the contrary, Section 18 (1) Part IV of the Nurses and Midwives Act, 1996 requires the Council to keep proper books of accounts and prepare the annual financial statements of accounts for the immediately preceding financial year not later than three months in the following year. Conflict in the governing laws hampers effective execution of UNMC mandate. \uf0b7 Section 4 of the UNMC Act 1996, requires each Council member to be a seconded representative of a particular institution or body and must be appointed by the Minister. However, a review of Council Members records revealed that out of the seventeen (17) members, none of them were seconded representatives of their respective bodies. \uf0b7 Good Corporate Governance practices require separation of duties of board members to ensure their independence in the discharge of duties. On the contrary, a review of the composition of the Audit Committee revealed that Chairperson of the full council is also a member of the committee. \uf0b7 I noted that the Council had not been managed by a substantive Registrar since 2017. The current Registrar\u2019s initial appointment ran from November 2018 to March 2019. However, management did not provide a valid appointment letter to confirm her appointment after March 2019. \uf0b7 A review of the Governing council minute ref FC/08/14/06/2020 revealed that council members were concerned about the significant delays in issuing of Practicing Certificates that hindered the recruitment of nurses in the industry. Furthermore, Management did not avail status reports on certificates that were produced. \uf0b7 Payment files and PPDA monthly reports revealed that supplies and service worth UGX 46,183,800 were procured and paid without going through the procurement process given that there were no LPOs or procurement documents availed to confirm that the supplier went through the procurement process. \uf0b7 UNMC has three (3) operational vehicles. However, a detailed review of the fleet management revealed that there were no log books maintained to track the vehicle movements as required by the regulations. Further, there were no records being maintained to keep track of vehicle history, performance, servicing, overheads, repairs and maintenance.", null, null], ["7.", "Uganda Sanitation Fund (USF) \u2013 Ministry of Health Project. 2019/20 Opinion", "\uf0b7 A review of the annual work plan and the performance reports for the Uganda Sanitation Fund revealed that there were inconsistencies in planned targets and those reported upon. Furthermore, the planned targets/outputs in the work plan lacked sufficient detail (description of outputs) to facilitate a meaningful comparison with the targets in the performance reports."], [null, "Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 310, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "298", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 310, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "the quarterly district performance work plans and reports submitted to"], [null, null, "the Ministry, revealed that, the quarterly release of funds from MOFPED"], [null, null, "was not done on time. As a result, Quarter 1 funds were disbursed in"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 311, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", null, "the quarterly district performance work plans and reports submitted to"], [null, null, "the Ministry, revealed that, the quarterly release of funds from MOFPED"], [null, null, "was not done on time. As a result, Quarter 1 funds were disbursed in"], [null, null, "quarter 2, quarter 2 funds were disbursed in quarter 3, and quarter 3"], [null, null, "funds disbursed in quarter 4."], [null, null, "\uf0b7 Since the project\u2019s inception, only a total of UGX.1.3bn (USD 386,259)"], [null, null, "out of the agreed GOU counterpart funding commitment of USD"], [null, null, "2,000,000 had been disbursed to the districts resulting into a funding"], [null, null, "shortfall of USD 1,613,741."], [null, null, "\uf0b7 The program\u2019s average national progress on Open Defecation Free (ODF)"], [null, null, "target stood at 60.9% yet the project is in its last year of implementation."], [null, null, "An Assessment of the 9-year targets (July 2011 to June 2020) revealed"], [null, null, "that out of the targeted 11,354 villages, only 9,632 achieved ODF targets,"], [null, null, "representing 84.8%; a total of 140 of the 400 targeted parishes"], [null, null, "representing 35% achieved ODF; and only 27 of the targeted 360 sub"], [null, null, "counties achieved the ODF target representing 7.5% achieved ODF"], [null, null, "status."], ["8 Allied Health Professionals Council. 2019/20 Opinion Unqualified \uf0b7 The Governing Council stated that a material uncertainty existed regarding the continued operation of Allied Health Professionals Council in the foreseeable future. \uf0b7 Management\u2019s judgement was informed by a letter from the PS - Ministry of Public Service to all Accounting Officers in which guidance was provided on the modalities for management of Public Institutions during the implementation of recommendations on the rationalization of Agencies and Public Expenditure. \uf0b7 I noted that out of the ten (10) sampled outputs with a total of ten (10) activities and expenditure of UGX. 3.127bn, only five (5) outputs with five (5) activities and expenditure worth UGX 3.017Bn were fully quantified. The balance of five (5) outputs with five (5) activities and expenditure worth UGX.011Bn were insufficiently quantified which made it difficult to assess extent of their delivery. \uf0b7 I observed that out of the five (5) outputs that were fully quantified, three (3) outputs with three (3) activities worth UGX. 1.918Bn were fully implemented. However, the remaining two (2) outputs with two (2) activities worth UGX.1.099Bn were partially implemented. \uf0b7 The Council fleet of six (6) sampled vehicles was not annually inspected during the three (3) year period under review to assess their mechanical condition and road worthiness. \uf0b7 Whereas the Council designated a Transport Officer responsible for transport matters, fuel registers were not maintained for all the six (6) motor vehicles sampled out of nine (9) vehicles held by the Council. \uf0b7 I noted that nine (9) out of the ten (10) Regional Offices were not allocated vehicles to facilitate their operations.", null, null], ["9", "Joint Clinical Research Centre. 2019/20", "\uf0b7 The entity budgeted to receive UGX 20,906,339,925 from development partners out of which UGX 19,707,530,000 was received resulting in a shortfall of UGX 1,198,809,925. In addition, out of budgeted local revenue of UGX 4,366,651,934, only UGX 2,693,800,000 was generated resulting into a shortfall of UGX 1,672,851,934."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 311, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "299", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 311, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "activities (12%) were partially implemented while forty-four (44) activities"], [null, null, "(28%), were not implemented by the time of audit."], [null, null, "\uf0b7 I reviewed the balance of \u2018payables falling within one year\u2019 reported in"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 312, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", null, "activities (12%) were partially implemented while forty-four (44) activities"], [null, null, "(28%), were not implemented by the time of audit."], [null, null, "\uf0b7 I reviewed the balance of \u2018payables falling within one year\u2019 reported in"], [null, null, "the Statement of Financial Position and Note 21 and noted an increase of"], [null, null, "UGX 121,010,000 from UGX 1,138,910,000 (30th June 2019) to UGX"], [null, null, "1,259,920,000 (30th June 2020). I further reviewed the ageing of the"], [null, null, "payables and noted that included in the outstanding balance of UGX"], [null, null, "1,259,920,000 are payables worth UGX 357,139,495 that had remained"], [null, null, "outstanding for over 90 days."], [null, null, "\uf0b7 Seventeen (17) running motor vehicles which were fully depreciated"], [null, null, "according to the JCRC Fleet Management Policy and had zero net book"], [null, null, "value in the schedule of fixed assets were still in use. The entity did not"], [null, null, "revalue or make annual reviews of its expectations with regard to the"], [null, null, "residual values and useful lives of the vehicles in question resulting into"], [null, null, "under valuation/understatement of non-current assets in use in the"], [null, null, "statement of financial position."], [null, null, "\uf0b7 The Principal Private Secretary to His Excellency the President\u2019s letter ref:"], [null, null, "PO/1 dated 12th February 2019 directed the Hon. Minister of Finance,"], [null, null, "Planning & Economic Development to increase Government funding to"], [null, null, "the Centre from UGX.240 million to UGX.5 billion annually in the"], [null, null, "subsequent years, that is, with effect from the Financial Year 2019/20."], [null, null, "According to the various communications by the Centre\u2019s Executive"], [null, null, "Director, the increment in funding was necessitated by the declining"], [null, null, "donor support."], [null, null, "\uf0b7 However, the no-objection for the implementation of the directive was"], [null, null, "only granted to the PS/ST by the PS MOH through letter ref: 45/415/01"], [null, null, "dated 4th February 2020. This was when the financial year 2019/20"], [null, null, "budget was in the third quarter of implementation."], [null, null, "\uf0b7 Contrary to the PPDA requirements, the entity delayed to submit ten (10)"], [null, null, "out of twelve (12) monthly procurement and disposal reports to the"], [null, null, "Authority for the financial year under review."], [null, null, "\uf0b7 The Centre had a procurement plan worth for the year under review. I"], [null, null, "noted that out of the planned procurements worth UGX 6,956,028,077,"], [null, null, "procurements worth UGX 5,434,128,077 (78%) were implemented while"], [null, null, "those worth UGX 1,521,900,000 (22%) were not conducted."], ["10 Uganda Medical and Dental Practitioners Council. 2019/20 Opinion Unqualified \uf0b7 The Governing Council stated that a material uncertainty existed regarding the continued operation of Allied Health Professionals Council in the foreseeable future. \uf0b7 Management\u2019s judgement was informed by a letter from the PS - Ministry of Public Service to all Accounting Officers in which guidance was provided on the modalities for management of Public Institutions during the implementation of recommendations on the rationalization of Agencies and Public Expenditure. \uf0b7 I noted that out of the budgeted Non-Tax revenue UGX.2,891,430,000, only UGX.1,650,811,279 was realized during the year under review (representing 57% performance). This hampered effective service delivery. \uf0b7 Contrary to the statutory deadline of 31st day of March for the publication all up-to-date registers in the gazette, registers for 2020 had not been published in the gazette by the time of audit in November 2020.", null, null], ["11", "The Rehabilitation and Expansion of Kayunga and", "\uf0b7 The project experienced significant revenue shortfalls. Out of the expected receipts of USD 19,064,124.79, the project received funding"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 312, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "300", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 312, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Yumbe Hospitals Project", "totalling USD.8,252,401.61 constituting USD. 6,240,515.26 from external"], [null, "(KAYUP) -BADEA No. 0761,", "sources and USD.2,011,886.35 (UGX. 7,505,000,000) from GoU"], [null, "OFID No. 1628P and SFD", "counterpart contribution. This translated into a budget shortfall of USD"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 313, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", "Yumbe Hospitals Project", "totalling USD.8,252,401.61 constituting USD. 6,240,515.26 from external"], [null, "(KAYUP) -BADEA No. 0761,", "sources and USD.2,011,886.35 (UGX. 7,505,000,000) from GoU"], [null, "OFID No. 1628P and SFD", "counterpart contribution. This translated into a budget shortfall of USD"], [null, "No. 6/620 \u2013 Ministry of Health Project. 2019/20 Opinion Unqualified", "10,811,723.18 (representing 56.71% of the approved budget). \uf0b7 There were delays in Project implementation. The project became effective on 16th April 2015 and was initially expected to be completed on 28th February 2020 which was later extended to 31st December 2021. However, the cumulative project progress was at 99.5% as at 30th June 2020\\. Major delays were identified in the procurement and installation of"], [null, null, "Medical equipment, Ambulances, mini-buses and Pick-ups."], ["12 Uganda-Spain Debt Swap Project. 2019/20 Opinion Unqualified \uf0b7 I noted that out of the two (2) planned project outputs for the year, one (1) output was fully implemented while one (1) output was partially implemented. Management attributed the level of performance to delayed commencement of the preparation of the detailed designs for the refurbishment and equipping of Busolwe General Hospital which involved approval of extra charges for the consultant to revise the site survey report. According to management, the COVID-19 pandemic further affected the operations of the Consultant. \uf0b7 During the year under review, the Project received a sum of UGX 15.69Bn of which UGX.10.63Bn was spent resulting in an unspent balance of UGX.5.06Bn (representing an absorption level of 67.8%).", null, null], ["13", "Uganda Reproductive Health Voucher Project (URHVP) GPOBA Grant Number TF015995. 2019/20", "\uf0b7 A review of the project financial statements as at 30th June 2020 (Note 2 & Annex 6.0) together with underlying financial records revealed that the project had bank balances of USD 49.85 and UGX.792 in Bank of Uganda at the time of closure. However, Management did not avail documentary proof of closure of these Accounts at the end of the project when sought."], [null, "Opinion Unqualified", null], ["14 Butabika National Mental Referral Hospital. Opinion Unqualified \uf0b7 The entity budgeted to collect NTR of UGX 1.24bn during the year under review. However, the hospital collected UGX. 1.15bn thereby resulting into a shortfall of UGX 0.09bn. \uf0b7 The Hospital received the entire revised annual budget of UGX 17.023bn out of which UGX 16.551bn was spent resulting in unutilized funds of UGX 0.472bn. The unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account. \uf0b7 I noted that the entity submitted all the quarterly performance reports after the prescribed deadline. The Accounting Officer explained that due to COVID-19 restrictions, the support offices were operating at 10% which led to delays in preparation and submission of the quarterly performance reports. \uf0b7 According to the patient admission schedule and the strategic plan, the Hospital currently handles between 750 and 780 in-patients per month compared to its bed capacity of 550 patients. This implies that 200 to 230 admitted patients either share beds or sleep on the floor. \uf0b7 I noted that UGX.93,717,182 was utilized for repairs and service for vehicles during the year under review. However, there were no repair and service analysis registers for the 13 vehicles that were maintained. Furthermore, it was observed that the Hospital Transport Officer did not maintain service charts for all the 13 vehicles.", null, null], ["15", "Kawempe National Referral", "\uf0b7 The entity budgeted to collect NTR of UGX. 449m during the year under"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 313, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "301", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 313, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Hospital.", "review, and UGX. 451m was realized, representing a performance of"], [null, "Opinion Unqualified", "100.4% of the target. \uf0b7 Out of the total receipts for the financial year of UGX 11.723 bn, UGX. 11.385Bn was spent by the entity resulting in an unspent balance of UGX.0.337Bn (representing an absorption level of 97.1%). The unspent"], [null, null, "balance at the end of the financial year was subsequently swept back to"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 314, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", "Hospital.", "review, and UGX. 451m was realized, representing a performance of"], [null, "Opinion Unqualified", "100.4% of the target. \uf0b7 Out of the total receipts for the financial year of UGX 11.723 bn, UGX. 11.385Bn was spent by the entity resulting in an unspent balance of UGX.0.337Bn (representing an absorption level of 97.1%). The unspent"], [null, null, "balance at the end of the financial year was subsequently swept back to"], [null, null, "the consolidated fund account."], [null, null, "\uf0b7 I noted that all the eight (8) outputs selected for budget performance"], [null, null, "assessment with a total of eleven (11) activities and actual expenditure of"], [null, null, "UGX 4.6bn were fully quantified. This therefore enabled me to assess the"], [null, null, "Hospital\u2019s performance during the year under review."], [null, null, "\uf0b7 Out of the eight (8) sampled outputs, two (2) outputs were fully"], [null, null, "implemented while six (6) were partially implemented. I further noted"], [null, null, "that out of the planned eleven (11) activities under the sampled outputs,"], [null, null, "two (2) activities were fully achieved while nine (9) were partially"], [null, null, "achieved."], [null, null, "\uf0b7 A total of UGX 36,870,179 worth of expenditure was charged on other"], [null, null, "than the budget lines on which the funds were appropriated without"], [null, null, "seeking the necessary approval from the relevant authorities."], [null, null, "\uf0b7 I noted that the Hospital submitted all the quarterly performance reports"], [null, null, "beyond the prescribed deadlines."], [null, null, "\uf0b7 From my review of the annual performance reports and physical"], [null, null, "inspections/verification of outputs reported, I did not observe"], [null, null, "inconsistencies in the reported performance."], [null, null, "\uf0b7 I noted that the Hospital accumulated payables/domestic arrears to tune"], [null, null, "of UGX. 799,186,746 up from UGX. 365,151,250 as at 30th June 2020."], [null, null, "\uf0b7 I noted that whereas the Board of Survey Report for the year ended 30th"], [null, null, "June 2021 established that the Hospital had a closing inventory of various"], [null, null, "items; this state of affairs was not disclosed as part of the Financial"], [null, null, "Statements under Annex (ii)-Schedule of Inventory, thereby rendering"], [null, null, "the financial statements incomplete."], [null, null, "\uf0b7 It was noted that the Hospital stored expired medicines without disposing"], [null, null, "them as required by the law. Out of the seventy four (74) items of"], [null, null, "expired drugs, I observed that thirty six (36) had expired by end of"], [null, null, "December 2020 (representing 49%). Under the circumstances, lives of"], [null, null, "patients are threatened by the existence of expired medicines at the"], [null, null, "hospital premises."], [null, null, "\uf0b7 I noted that the Referral Hospital was heavily congested with patients"], [null, null, "crowded in the wards and some sleeping on the floors. This was further"], [null, null, "evidenced by the data collected on Bed Occupancy Rates which showed"], [null, null, "an average BOR of 113% for the year under review. Congestion was also"], [null, null, "observed in the stores where some items were placed directly on the"], [null, null, "floor exposing them to damage."], [null, null, "\uf0b7 From a review of payments and procurements made during the year, I"], [null, null, "noted that procurements of goods worth UGX 187,406,417 were not"], [null, null, "supported with ledgers in the stores to track delivery and utilization of the"], [null, null, "accountable inventories procured."], ["16 Kiruddu National Referral Hospital. Opinion Unqualified \uf0b7 I noted that the Hospital\u2019s 5-Year Strategic Plan (FY 2020/21-2024/25) had been approved by National Planning Authority (NPA) by the time of audit. \uf0b7 The entity budgeted to collect NTR of UGX. 1,520,000,000 during the", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 314, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "302", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 314, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["year under review, and UGX. 719,423,137 was realized, representing a performance of 46.9% of the target. \uf0b7 Out of the total warrants of UGX.18.8Bn received during the financial year, UGX. 18.3Bn was spent by the entity resulting in an unspent balance of UGX. 0.5Bn (representing an absorption level of 97.3%). The unspent funds were swept back to the consolidated fund as required by the PFMA. \uf0b7 Out of the ten (10) outputs selected for budget performance assessment with a total of twenty four (24) activities and expenditure of UGX 12.16bn, I noted that seven (7) outputs with a total of fourteen (14) activities and expenditure worth UGX 9.99bn were fully quantified. Two (2) outputs with a total of eight (8) activities and expenditure worth UGX 1.9Bn, was insufficiently quantified. One (1) output with a total of two (2) activities and expenditure worth UGX 0.27bn were not quantified at all to enable performance assessment. \uf0b7 Out of the seven (7) outputs that were fully quantified with a total of fourteen (14) activities, four (4) outputs with a total of six (6) activities were fully implemented. Three (3) outputs with a total of eight (8) activities worth UGX 8.45bn were partially implemented. Out of the eight (08) activities, the entity fully implemented two (02) activities (25%) while six (06) activities (75%) remained partially implemented. \uf0b7 I noted that the Hospital submitted three (3) out of four (4) quarterly performance reports to Treasury within the prescribed deadlines. However, there was no documentary proof of preparation and submission of annual monitoring plans and reports to MoFPED and NPA as required. I further noted inconsistences in the financial information reported in the performance reports when compared with the financial statements. \uf0b7 A review of drugs supply chain management revealed that on several occasions there were drug stock-outs which left Kiruddu Hospital without several essential, vital and necessary drugs. \uf0b7 Inspection of the hospital drug stores revealed that some drugs/chemicals had expired in the Hospital stores. This could have been due to low utilization rates, receipt of drugs with short shelf life or placement of orders that do not match the usage patterns. \uf0b7 I noted that 55 new recruits were not cleared by Ministry of Public Service as required. The Accounting Officer attributed the anomaly to the need to fill critical vacant positions in the hospital.", null, null], ["17", "National Drug Authority.", "\uf0b7 NDA had an approved five-year strategic plan FY 2020/21-2024/25 which was well aligned to the National Development Plan in terms of timelines."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 315, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["year under review, and UGX. 719,423,137 was realized, representing a performance of 46.9% of the target. \uf0b7 Out of the total warrants of UGX.18.8Bn received during the financial year, UGX. 18.3Bn was spent by the entity resulting in an unspent balance of UGX. 0.5Bn (representing an absorption level of 97.3%). The unspent funds were swept back to the consolidated fund as required by the PFMA. \uf0b7 Out of the ten (10) outputs selected for budget performance assessment with a total of twenty four (24) activities and expenditure of UGX 12.16bn, I noted that seven (7) outputs with a total of fourteen (14) activities and expenditure worth UGX 9.99bn were fully quantified. Two (2) outputs with a total of eight (8) activities and expenditure worth UGX 1.9Bn, was insufficiently quantified. One (1) output with a total of two (2) activities and expenditure worth UGX 0.27bn were not quantified at all to enable performance assessment. \uf0b7 Out of the seven (7) outputs that were fully quantified with a total of fourteen (14) activities, four (4) outputs with a total of six (6) activities were fully implemented. Three (3) outputs with a total of eight (8) activities worth UGX 8.45bn were partially implemented. Out of the eight (08) activities, the entity fully implemented two (02) activities (25%) while six (06) activities (75%) remained partially implemented. \uf0b7 I noted that the Hospital submitted three (3) out of four (4) quarterly performance reports to Treasury within the prescribed deadlines. However, there was no documentary proof of preparation and submission of annual monitoring plans and reports to MoFPED and NPA as required. I further noted inconsistences in the financial information reported in the performance reports when compared with the financial statements. \uf0b7 A review of drugs supply chain management revealed that on several occasions there were drug stock-outs which left Kiruddu Hospital without several essential, vital and necessary drugs. \uf0b7 Inspection of the hospital drug stores revealed that some drugs/chemicals had expired in the Hospital stores. This could have been due to low utilization rates, receipt of drugs with short shelf life or placement of orders that do not match the usage patterns. \uf0b7 I noted that 55 new recruits were not cleared by Ministry of Public Service as required. The Accounting Officer attributed the anomaly to the need to fill critical vacant positions in the hospital.", null, null], ["17", "National Drug Authority.", "\uf0b7 NDA had an approved five-year strategic plan FY 2020/21-2024/25 which was well aligned to the National Development Plan in terms of timelines."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 315, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "303", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 315, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "of non-recoverability, thus denying the Authority realization of revenue"], [null, null, "for achievement of its objectives."], [null, null, "\uf0b7 Seventeen (17) running motor vehicles were fully depreciated during the"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 316, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", null, "of non-recoverability, thus denying the Authority realization of revenue"], [null, null, "for achievement of its objectives."], [null, null, "\uf0b7 Seventeen (17) running motor vehicles were fully depreciated during the"], [null, null, "previous year, reflected at zero book value and removed from the"], [null, null, "Statement of Financial Position. Removal from the statement of financial"], [null, null, "position of assets still in use and with no evidence that future economic"], [null, null, "benefits will not be expected from disposal of the same, misrepresents"], [null, null, "the entity\u2019s financial position."], [null, null, "\uf0b7 There was slow progress on the civil works NDA laboratory Tower."], [null, null, "Further, works for the amended building plans for the NDA laboratory"], [null, null, "Tower had commenced by the time of audit in August 2021 prior to"], [null, null, "approval by the Metropolitan Physical Planning Authority contrary to"], [null, null, "Section 22 (1f) of the KCCA Act 2010."], [null, null, "\uf0b7 The Authority fully paid UGX.343,694,683 in advance to providers"], [null, null, "awarded contracts for the supply of analytical equipment without"], [null, null, "obtaining appropriate advance payment security. I also noted that the"], [null, null, "Authority signed contracts to a tune of USD 14,872.8 with two domestic"], [null, null, "suppliers in foreign currency."], ["18 Uganda National Health Research Organization. Opinion Unqualified \uf0b7 The Sessional Parliamentary Committee on Social services recommended the granting of a vote status to the Organization. This was followed by issuance of statutory instruments and the gazetting and commencement of the Uganda National Health Research Organisation Act, 2011 on the 22nd day of January 2016. However, I noted that the Organization had not been granted a vote status by the time of audit. \uf0b7 I noted that the Organization did not have a governing Board during the year under review, after the term of office for all former members of the Board expired in 2016. \uf0b7 The employment contract on file for the Director General expired in April 2018 and had not been renewed by the time of audit. \uf0b7 Only 12 out of the approved 26 positions in the Organizational Structure had been filled resulting into a staffing gap of 14 positions. \uf0b7 The Organization was financed by a subvention of only UGX.240m out of which 94% was earmarked for wage leaving only 6% for operational costs.", null, null], ["19", "Uganda National Health Research Organization. Opinion Unqualified", "\uf0b7 The Sessional Parliamentary Committee on Social services recommended the granting of a vote status to the Organization. This was followed by issuance of statutory instruments and the gazetting and commencement of the Uganda National Health Research Organisation Act, 2011 on the 22nd day of January 2016. However, I noted that the Organization had"], [null, null, "not been granted a vote status by the time of audit."], [null, null, "\uf0b7 I noted that the Organization did not have a governing Board during the"], [null, null, "year under review, after the term of office for all former members of the"], [null, null, "Board expired in 2016."], [null, null, "\uf0b7 The employment contract on file for the Director General expired in April"], [null, null, "2018 and had not been renewed by the time of audit."], [null, null, "\uf0b7 Only 12 out of the approved 26 positions in the Organizational Structure"], [null, null, "had been filled resulting into a staffing gap of 14 positions."], [null, null, "\uf0b7 The Organization was financed by a subvention of only UGX.240m out of"], [null, null, "which 94% was earmarked for wage leaving only 6% for operational cos"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 316, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "304", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 316, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["20 Joint Clinical Research Centre (JCRC). Opinion Unqualified \uf0b7 JCRC reported trade and other receivables of UGX.4,210,400,000. Out of this UGX.95,254,972 related to the previous financial year. I noted that JCRC did not make any provision for bad debts as required by IFRS 9 and its Manual. Failure to make provisions may result into overstating reported receivables due to unaccounted for risks of non-recoverability. In addition, there was no evidence from the Finance Committee that a review of the bad debts position was annually done. Management explained that in addition to sending out constant reminders to the listed debtors, Management would review the list further for presentation to the Finance Committee of the Board. I advised the Accounting officer to make the required provisions for bad debts in accordance with Standards and the Manual \uf0b7 I noted that JCRC signed contracts with local service providers in foreign currency to a tune of USD 32,258.7. The contracts were for supply of Bone density kits (USD 25,515); supply of Hematology reagents (USD 2,060), and; for internet services (USD 4,683). I advised the Accounting Officer to take heed of the PS/ST recommendation and ensure that all local contracts are awarded in Uganda Shillings.", null, null], ["21", "Uganda Blood Transfusion Services (UBTS).", "\uf0b7 I noted that the entity had prepared and approved its plan. However, approval and certification had not yet been obtained from the National Planning Authority."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 317, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "305", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 317, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "reflected as Plot 27 instead of 2F on the cover page of the title deed for"], [null, "the land currently occupied by Nakasero Blood Bank. Management wrote"], [null, "to the Secretary Uganda Land Commission about the anomaly in a letter"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 318, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None"], "type": "table"}}, {"content": [["", "reflected as Plot 27 instead of 2F on the cover page of the title deed for"], [null, "the land currently occupied by Nakasero Blood Bank. Management wrote"], [null, "to the Secretary Uganda Land Commission about the anomaly in a letter"], [null, "dated 5/4/2012 Reference number UBTS/ADM/LT/01, no response had"], [null, "been received to date. Furthermore, 0.079 hectares of Nakasero Blood"], [null, "Bank were reported to have been encroached on by the fence of Pearl of"], [null, "Africa Hotel on plots 2E and 7A1-9A1 as per the boundary opening"], [null, "reports of 23rd November 2009 (S.M Geoteam ltd) and 2nd August 2013"], [null, "(Terrain Consult) who had been appointed by UBTS."], [null, "\uf0b7 I noted a one year\u2019s delayed execution of works for the completion of the"], [null, "remodelling of a store at Nakasero Blood Bank. A sum of UGX 2.86bn had"], [null, "so far been paid against the contract sum of UGX.3.77bn."], [null, "\uf0b7 I noted that a total of UGX.0.968Bn was spent on the Blood Safety"], [null, "Information System during the year. Whereas there was information on"], [null, "blood collected, stored and issued during the year, there was no"], [null, "information on how the 224,303 units of blood that had been issued to"], [null, "the different health facilities had been utilized."], ["22 Uganda Virus Research Institute. Opinion Unqualified \uf0b7 I noted that the entity had prepared and approved its plan. However, approval and certification had not yet been obtained from the National Planning Authority. \uf0b7 I noted that the entity did not budget or collect NTR during the year under review. \uf0b7 This was attributed to the breakdown of the Nitrogen plant three years ago which was the main source of revenue. However, the Institute received funds from GoU and was in the process of procuring a new Nitrogen plant. \uf0b7 The Institute received the entire budget of UGX.8.97bn out of which UGX.8.95bn was spent by the entity resulting in an unspent balance of UGX.20.76m (representing an absorption level of 98.8%). The unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account. \uf0b7 Two (2) outputs with a total of two (2) activities and expenditure of UGX 2.23bn were fully quantified out of the eight (8) outputs with a total of twenty-two (22) activities and expenditure of UGX 8.20bn sampled for assessment. None of the two (2) quantified activities under the two (2) outputs was implemented at all. \uf0b7 Two (2) outputs with a total of seven (7) activities and expenditure worth UGX.4.99Bn were insufficiently quantified. Out of the seven (7) activities, two (2) activities (29%) was quantified, while the balance of five (5) activities (71%) were not clearly quantified to enable the assessment of performance. \uf0b7 Four (4) outputs with a total of thirteen (13) activities and expenditure worth UGX 980m were not quantified at all. That is none of the thirteen (13) activities within these outputs was quantified at all. \uf0b7 I noted that funds to the tune of UGX 53,300,000 were irregularly reallocated from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 I noted that the entity submitted performance reports for Q1, Q2, Q3, Q4 after the prescribed deadline.", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 318, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None"], "type": "table"}}, {"content": "306", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 318, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 Payables worth UGX 0.409bn remained outstanding from financial year ended 30th June 2019 to-date. I noted that management did not provide for the settlement of domestic arears in the approved budget estimates for the year under review. \uf0b7 A review of the staff structure of Uganda Virus Research Institute revealed that out of the approved structure of 237, only 75 positions were filled leaving 162 staff positions vacant. \uf0b7 A review of a sample of 19 procurement files with a total value of UGX.1.61Bn revealed that the Institute did not require suppliers to provide any form of an acceptable performance guarantee for procurements worth UGX.1.42Bn. \uf0b7 Analysis of payment records and review of staff files revealed that 5 staff of the Institution had retired but had not yet accessed the pension payroll although the six months pensions processing period had elapsed.", null, null], ["23", "National Medical Stores.", "\uf0b7 I noted that the Corporation budgeted to collect NTR of UGX.56.37Bn during the year under review. Out of this, only UGX.39.80Bn was collected thereby resulting into a shortfall of UGX.16.57bn."], [null, "Opinion Unqualified", null], ["24 Uganda Heart Institute. Opinion Unqualified \uf0b7 I noted that the Hospital\u2019s 5-Year Strategic Plan (FY 2020/21 -2024/25) was approved by National Planning Authority (NPA) on 27th September 2021 vide certificate no. 26(3). \uf0b7 Out of eight (8) outputs with a total of forty eight (48) activities and expenditure of UGX.11.50Bn sampled for assessment, I noted that four", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 319, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "307", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 319, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["(4) outputs with a total of seventeen (17) activities and expenditure worth UGX 7.196Bn were fully quantified; four (4) outputs with a total of thirty one (31) activities and expenditure worth UGX 4.306Bn were insufficiently quantified. \uf0b7 I assessed the extent of delivery of the 4 outputs that were fully quantified and noted that one (1) output with a total of two (2) activities worth UGX 0.439Bn was fully implemented. \uf0b7 Two (2) outputs with a total of fourteen (14) activities worth UGX 6.606Bn were partially implemented. Out of the fourteen (14) activities, the entity fully implemented four (4) (29%) activities; seven (7) activities (50%) were partially implemented while three (3) (21%) activities remained unimplemented. One (1) output with only one (1) activity worth 0.15Bn was not implemented at all. \uf0b7 I noted that funds to the tune of UGX. 24.13m were irregularly re- allocated from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The entity submitted performance reports for Q1, Q2, Q3, and Q4 after the prescribed deadline. In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which are important in ensuring that the budget performs as expected. \uf0b7 From my review of the annual cumulative performance reports and physical inspections/verification of performance, I did not observe any inconsistencies with the results of my verification. \uf0b7 I noted that insufficient budget provisions (UGX.73,885,634) were made towards settlement of domestic arrears yet the arrears brought forward from the previous year were UGX.1,429,802,685. \uf0b7 The Institute had NTR debtors to the tune of UGX. 282.97m at the end of the financial year under review. These were receivables from various insurance companies, MDAs and institutions for services rendered by the Institute. \uf0b7 The Land Commission received a presidential directive to allocate Uganda Heart Institute 10 acres of land in Nakawa Naguru to facilitate the setting up of a Cardiac Centre of Excellence with a 250 bed hospital. However, I noted that during the year there were encumbrances on part of the allocated land which resulted in the loss of 3 acres after consensual withdrawal of a law suit. \uf0b7 Whereas the total contract sum of UGX. 3.5bn had been paid out for the renovation of the Intensive Care Unit on Block 1C, the works remained incomplete at the time of writing this report. \uf0b7 A review of the staff structure of Uganda Heart Institute revealed that out of the approved structure of 189, only 160 positions were filled leaving 29 staff positions vacant.", null, null], ["25", "Mulago Specialized Women & Neonatal Hospital.", "\uf0b7 The entity budgeted to collect NTR of UGX. 7bn during the year under review, and UGX. 3.64bn was realized, representing a performance of 52% of the target."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 320, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "308", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 320, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "five (25) activities and expenditure of UGX 17.7bn, only eight (8) outputs"], [null, "with a total of fourteen (14) activities worth UGX 9.1bn were fully"], [null, "quantified. Two (2) outputs with a total of nine (9) activities and"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 321, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None"], "type": "table"}}, {"content": [["", "five (25) activities and expenditure of UGX 17.7bn, only eight (8) outputs"], [null, "with a total of fourteen (14) activities worth UGX 9.1bn were fully"], [null, "quantified. Two (2) outputs with a total of nine (9) activities and"], [null, "expenditure worth UGX.8Bn, was insufficiently quantified. I observed that"], [null, "out of the nine (9) activities, six (6) activities (66.7%) were quantified,"], [null, "while the balance of three (3) activities (33.3%) were not clearly"], [null, "quantified to enable the assessment of performance. Two (2) outputs"], [null, "with a total of two (2) activities and expenditure worth UGX 0.550Bn"], [null, "were not quantified at all. That is none of the two (2) activities within"], [null, "these outputs was quantified at all."], [null, "\uf0b7 Out of the eight (8) fully quantified outputs with a total of fourteen (14)"], [null, "activities and expenditure worth UGX.9.1Bn, seven (7) outputs with ten"], [null, "(10) activities and expenditure worth UGX 4.8Bn were fully implemented."], [null, "One (1) output with four (4) activities worth UGX.4.4Bn was partially"], [null, "implemented. Out of the four (4) activities, the entity fully implemented"], [null, "three (3) activities; one (1) activity was partially implemented, while no"], [null, "activity remained unimplemented."], [null, "\uf0b7 A well equipped kitchen with boilers, fridges, gas cookers, cabinets, a"], [null, "chimney and a full outer gas tank was constructed at the Hospital."], [null, "However, it was not yet in use at the time of audit."], [null, "\uf0b7 I noted that the Hospital submitted all the quarterly performance reports"], [null, "beyond the prescribed deadlines."], [null, "\uf0b7 From my review of the annual performance reports and physical"], [null, "inspections/verification of outputs reported, I did not observe"], [null, "inconsistencies in the reported performance."], [null, "\uf0b7 I noted that the hospital reported a payables figure of UGX.2,180,857,756"], [null, "of which UGX. 427,844,778 related to PAYE which was deducted but"], [null, "remained unremitted by close of the year under review."], ["26 Mulago National Referral Hospital. 2020/21 Opinion Qualified \uf0b7 Transfers of UGX.3,867,161,000 received from the Ministry of Health were not recognized in the Statement of Financial Performance. The receipts were also not reported in Note 5 to the Financial Statements. It was further noted that the funds which were received on the Hospital\u2019s Infrastructure Development Account were transfers from Ministry of Health meant for intern allowances. \uf0b7 The Hospital had liabilities of UGX 2,952,608,319 from the previous year (FY 2019/20) in respect of payables (UGX 2,304,366,476) and deposits (UGX 648,241,843). However, payments totalling to UGX3,775,748,845 in respect of the liabilities were made. The Hospital therefore made payments for non-existent liabilities amounting to UGX 1,471,382,369. \uf0b7 Management made an adjustment to the opening balance of payables amounting to UGX 2,097,368,767 (statement of outstanding commitments on Page 33 of the financial statements). However, there was no explanation provided on the cause of the adjustment or the composition of this figure. \uf0b7 The Hospital misstated transfers to the Treasury during the year by UGX 1,296,483,686 in its financial statements. \uf0b7 The entity did not have a strategic plan approved by NPA during the year. \uf0b7 The Hospital did not budget to collect NTR during the year under review. However, the financial statements indicated that NTR amounting to UGX. 1,808,626,491 was collected during the year. \uf0b7 Out of the total warrants of UGX.63,573,318,357 received during the financial year, UGX.59,379,356,427 was spent by the entity resulting in", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 321, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None"], "type": "table"}}, {"content": "309", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 321, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["an unspent balance of UGX.4,193,961,930 representing an absorption level of 93.4%. \uf0b7 The Hospital spent UGX. 474,479,100 on refurbishment of the MRI machine. It was noted that the MRI machine was delivered and installed in 2018 and has since never been put to use. \uf0b7 Works under the construction contract for 150 units of staff houses at the Hospital of UGX. 30,228,600,856 have been delayed. \uf0b7 I noted that vital medical equipment was in poor working condition, while others were fully not functional and required replacement. The equipment included: autoclaves in the central sterile service department; patient monitors in the accident and emergency surgical unit; blood coagulation machine in the clinical laboratory unit; ICU beds in the intensive care unit, and CT machine in the Radiology department.", null, null], ["27", "Allied Health Professionals Council (AHPC).", "\uf0b7 The Council did not have a strategic plan approved by NPA during the year."], [null, "2020/21", null], ["28 Health Service Commission. 2020/21 Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by the end of the year under review. \uf0b7 The Commission did not budget to collect NTR during the year under review. However, the financial statements indicated that NTR amounting to UGX.21,850,000 was collected during the year. \uf0b7 There was no evidence to show that the procurement method and the Evaluation Committee were approved by the Contracts Committee for six sampled procurements worth UGX48,310,800. Lack of approval contravenes the PPDA Regulations. In the circumstances, the Evaluation Committees executed the assignment without authority.", null, null], ["29", "Uganda AIDS Commission. 2020/21", "\uf0b7 I noted that the entity had prepared a strategic plan. However, this had"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 322, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "310", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 322, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Opinion Unqualified", "not been approved by the end of the year under review. \uf0b7 The Commission did not budget to collect NTR during the year under review. However, the financial statements indicated that NTR amounting to UGX. 37,800,000 was collected during the year."], [null, "", null], ["30 Allied Health Professionals Council (AHPC). 2020/21 Opinion Unqualified \uf0b7 The Council did not have a strategic plan approved by NPA during the year. \uf0b7 The entity budgeted to collect internal revenue of UGX.4.771Bn during the year under review. Out of this, only UGX.3.783Bn was realized, representing a performance of 79% of the target. \uf0b7 AHPC planned to implement five (5) outputs in the year under review. I assessed the implementation of three (3) outputs which had 16 activities and noted that all the 3 outputs with their 16 activities were fully quantified. with a total of sixteen (16) activities worth UGX.1.380Bn and noted that; \uf0b7 Out of the sampled 3 outputs with a total of 16 activities, I noted that one (1) output with four (4) activities and expenditure worth UGX 0.515Bn was fully implemented that is all the four (4) activities within this output were fully implemented. Two (2) outputs with twelve (12) activities worth UGX.0.865Bn were partially implemented. Out of the twelve (12) activities, the entity fully implemented one (1) activity; seven (7) activities were partially implemented while four (4) activities were not implemented. \uf0b7 The Council did not implement some of its planned activities during the year. Examples include: Verification and publication of Allied Health Professionals in the Gazette; Licensing of private Allied Health units and training institutions, and; ICT support supervision in regions. \uf0b7 The Governing Council stated that a material uncertainty existed regarding the continued operation of Allied Health Professionals Council in", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 323, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "311", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 323, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["the foreseeable future. This was based on the communication by the Permanent Secretary Ministry of Public Service (PS/MoPS) to the Permanent Secretary Ministry of Health among others in which the PS/MoPS communicated a Cabinet decision of 22nd February 2021 that required the commencement of merging, rationalization and mainstreaming of Government Agencies between financial years 2021/2022 and 2022/2023. There is a high possibility that the Council may not remain a going concern beyond the stated period. \uf0b7 The Council did not make any publication in the Gazette during the year under review, contrary to The Allied Health Professionals\u2019 Act (cap 268). In the absence of such a publication, the unsuspecting public may not be protected from quack practitioners.", null, null], ["31", "Uganda Global Fund To Fight Tuberculosis And Malaria Project \u2013 HIV", "\uf0b7 No significant findings"], [null, null, ""], ["32 Uganda Global Fund to Fight Aids, Tuberculosis And Malaria Project \u2013 HIV Component. 2020 Opinion Unqualified \uf0b7 No significant findings", null, null], ["33", "Uganda Global Fund to Fight Aids, Tuberculosis and Malaria Project-Tuberculosis", "\uf0b7 No significant findings"], [null, null, ""], ["34 Ministry of Health. 2020/21 Opinion Unqualified \uf0b7 I noted that whereas the Ministry submitted a draft 5-Year Strategic plan (FYs 2020/21-2024/25) to National Planning Authority for approval on 29th July 2021, a certificate had not been issued by the Authority by the time of audit. \uf0b7 The entity did not budget for NTR during the year under review. However, UGX 7.205Bn was collected. \uf0b7 The Ministry budgeted to receive UGX 147.112Bn. This budget was later revised to UGX 376.884Bn, out of which UGX 376.837Bn was warranted, resulting into a shortfall of UGX 47m (representing 0.012% of the approved budget). \uf0b7 Out of the total UGX 1,029.646Bn received during the year under review, UGX 852.099Bn was spent by the entity resulting in an unspent balance of UGX. 177.547Bn (representing an absorption level of 82.8%). The unspent funds included; UGX 0.61Bn of NTR which was swept back to the Consolidated Fund as required by the PFMA, while UGX 5Bn remained on the MoH Contingency Fund and the balance of UGX 171.937Bn remained on project Accounts. \uf0b7 Out of a sample of forty nine (49) outputs with a total of one hundred ninety seven (197) activities and expenditure of UGX 777.8Bn, twenty", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 324, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "Aids, \n312 \nfour (24) 48.9% outputs with a total of fifty nine (59) activities and expenditure worth UGX 140.4Bn were fully quantified. Fifteen (15) 30.6% outputs with a total of one hundred twenty one (121) activities and expenditure worth UGX 373.5Bn were insufficiently quantified. I observed that out of the one hundred twenty one (121) activities, sixty nine(69) activities (57%) were quantified, while the balance of fifty two (52) activities (43%) were not clearly quantified to enable the assessment of performance. Ten (10) 20.4% outputs with a total of seventeen (17) activities and expenditure worth UGX 263.9Bn were not quantified at all.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 324, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of twenty four (24) outputs that were fully quantified with a total of fifty nine (59) activities worth UGX 140.4Bn, eight (8) (33.3%) outputs with eleven (11) activities and expenditure worth UGX 101.8Bn were fully implemented; ten (10) (41.7%) outputs with forty two (42) activities worth UGX 32.5Bn were partially implemented. Out of the forty two (42) activities, eleven (11) activities were fully implemented; thirteen (13) activities were partially implemented, while eighteen (18) activities remained unimplemented. Six (6) (25% )outputs with six (6) activities worth UGX 6.1Bn could not be assessed to establish their level of implementation because four (4) of these outputs were not reported on, while two (2) outputs were inaccurately reported on i.e. different activities were planned for but different activities were reported on.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Ministry of Health received off-budget financing from Development Partners to a tune of UGX 8.44Bn, which was not declared to Treasury and, therefore, not appropriated to the entity by Parliament.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The entity submitted performance reports for Q1, Q2, and Q3, Q4 after the prescribed deadlines. In addition, I did not obtain documentary proof of in the form of monitoring plans and reports which are important in ensuring that the budget performs as expected.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The task force reporting functionality planned to produce bi-weekly, monthly, quarterly, bi-annual and annual COVID-19 performance reports. However, these were not prepared and discussed in a timely manner.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the Ministry of Health did not prepare a COVID-19 activity work plan upon receipt of UGX 253,596,115,200 meant for management of COVID-19.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the Supplementary release of UGX 223.596Bn, the Contingency Fund allocation of UGX 30Bn, and the unutilized balance from FY 2019/2020 of UGX 0.5Bn, a total of UGX.249.025bn (Supplementary UGX 223.596Bn, and Contingency Funding of UGX 25.429Bn) was spent leaving a balance of UGX 5.071Bn unspent as at 30th June 2021 (representing an absorption level of 98% of the total available funds)", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the entity conducted COVID-19 related procurements worth UGX 105,937,028,042 in the FY 2019/20 out of which UGX 92,960,878,888 had been paid by 30th June 2021. During the year under review (FY 2020/21), procurements worth UGX 191,254,414,946 were conducted out of which UGX 184,690,133,663 was paid by 30th June 2021.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that 37,501,136 masks that were delivered by various suppliers at a cost of UGX 90.2bn were not supported with documentary proof of certification by UNBS to ensure conformance with the desired technical quality specifications.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Whereas the first GoU allocation for procurement of vaccines amounting to UGX 18.5bn was transferred to National Medical Stores on 29th March 2021, vaccination doses procured by the Government of Uganda were yet to be delivered to NMS by 30th June 2021. Delayed delivery of the", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "313", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["vaccines is likely to hamper the timely attainment of the vaccination targets set by government. \uf0b7 The Ministry did not comply with PPDA Regulatory Framework with respect to COVID-19 related procurements valued at UGX. 13.7bn. \uf0b7 Whereas Mulago National Referral Hospital had running contracts for cleaning, waste disposal and security services with 3 suppliers prior to the COVID-19 pandemic, the Ministry of Health directly paid these suppliers a total of UGX 1,071,968,797 in respect of Cleaning & waste disposal Services (UGX 794,999,997) and Security services (UGX 276,968,800) rendered at Mulago COVID-19 Treatment Centre. Under the circumstances, there is a risk of double payment. \uf0b7 I noted that Pay As You Earn (PAYE) amounting to UGX 626,630,608 was not deducted from hardship allowances paid to various officials. Failure to deduct taxes may attract interest and penalties from the Tax Body.", null, null], ["", "LEGISLATURE", ""], ["", null, null], ["1\\. Parliamentary Pension Scheme. 2020/21 Opinion Unqualified \uf0b7 A total of UGX.5,557,452,584 was utilized during the year against the approved budgeted t of UGX.6,601,744,660. The Under absorption of resources implies that the scheme did not carry out all the year\u2019s intended activities, hence not meeting its intended objectives. Some of the activities that were not or partially implemented were; \uf0b7 Recruitment of staff \uf0b7 IT Annual Maintenance Plans \uf0b7 Strategic Partnership Meetings \uf0b7 As observed last financial year 2019/2020, some members on the Board of Trustees are still signatories to the Bank Accounts of the Scheme. The Board\u2019s involvement in the day-to-day operations of the scheme erodes its oversight role. For instance, the Board cannot hold management to account for failure, to implement. agreed activities when the Board is actively participating in the daily operations of the scheme.", null, null], ["2.", "Parliamentary Commission. 2020/21", "\uf0b7 I noted that the Authority\u2019s strategic plan had not been certified by NPA by the time of audit, contrary to the Planning Regulations."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 326, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "314 \nUGX.62,477,592,377 as at 30th June 2021. \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 326, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Authority did not remit statutory deductions to URA and NSSF amounting to UGX.1.86Bn.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 327, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 327, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Authority incurred avoidable expenditure of UGX.7.8Bn as interest due to delayed site handover for civil works constructions.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 327, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 327, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the Authority had not adopted the Computerized Government Financial Management Information Systems (GFMIS) for management of its inventories as required by the Treasury Instructions.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}], "page": 327, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "315 \nANNEXURE II: SUMMARY OF ENTITY FINDINGS AND OPINIONS FOR LOCAL GOVERNMENTS", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, {"headings_1": {"content": "v.", "page": 140, "level": 3}}]], "page": 327, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "S/N Fort Portal Branch", "metadata": {"headings": [{"headings_0": {"content": "S/N Fort Portal Branch", "page": 328, "level": 3}}, {"headings_1": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "S/N Fort Portal Branch", "page": 328, "level": 3}}, {"headings_1": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "1. Bundibugyo DLG", "metadata": {"headings": [{"headings_0": {"content": "S/N Fort Portal Branch", "page": 328, "level": 3}}, {"headings_1": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Opinion Unqualified", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified", "page": 328, "level": 3}}, {"headings_1": {"content": "S/N Fort Portal Branch", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified", "page": 328, "level": 3}}, {"headings_1": {"content": "S/N Fort Portal Branch", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "2. Kabarole DLG", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified", "page": 328, "level": 3}}, {"headings_1": {"content": "S/N Fort Portal Branch", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Opinion Unqualified", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified", "page": 328, "level": 3}}, {"headings_1": {"content": "Opinion Unqualified", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Summary of Key Findings \uf0b7 I noted a number of anomalies during review of the district payroll such as; Failure to submit wage estimates to MoPs, over payment of salaries worth UGX.29, 467,392, Underpayment of salaries of UGX.2, 160,338; payment of salaries worth UGX.45,", "metadata": {"headings": [{"headings_0": {"content": "Summary of Key Findings \uf0b7 I noted a number of anomalies during review of the district payroll such as; Failure to submit wage estimates to MoPs, over payment of salaries worth UGX.29, 467,392, Underpayment of salaries of UGX.2, 160,338; payment of salaries worth UGX.45,", "page": 328, "level": 3}}, {"headings_1": {"content": "Opinion Unqualified", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "977,978 to sixteen (16) staffs who were no longer in service, delayed access to payroll by sixty (60) new employees and failure to prepare monthly wage, pension and gratuity performance analysis on payroll to MoPS.", "metadata": {"headings": [{"headings_0": {"content": "Summary of Key Findings \uf0b7 I noted a number of anomalies during review of the district payroll such as; Failure to submit wage estimates to MoPs, over payment of salaries worth UGX.29, 467,392, Underpayment of salaries of UGX.2, 160,338; payment of salaries worth UGX.45,", "page": 328, "level": 3}}, {"headings_1": {"content": "Opinion Unqualified", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit.", "page": 328, "level": 3}}, {"headings_1": {"content": "Summary of Key Findings \uf0b7 I noted a number of anomalies during review of the district payroll such as; Failure to submit wage estimates to MoPs, over payment of salaries worth UGX.29, 467,392, Underpayment of salaries of UGX.2, 160,338; payment of salaries worth UGX.45,", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX.", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit.", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "2,978,972,164; under performance of the donor & government releases worth UGX.1,536,961,363; partial submission of quarterly monitoring reports to OPM & MoFPED", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX.", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit.", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The district received off-budget financing to a tune of UGX. UGX.7, 989,897 directly from UNFPA for undertaking activities which was never declared to the PSST and as such no supplementary appropriation was issued as guided by the PSST.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district received off-budget financing to a tune of UGX. UGX.7, 989,897 directly from UNFPA for undertaking activities which was never declared to the PSST and as such no supplementary appropriation was issued as guided by the PSST.", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX.", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 The district lost a court case (Busobozi Juma Vs Bundibugyo DLG); but failed to honour this court ruling resulting into", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district lost a court case (Busobozi Juma Vs Bundibugyo DLG); but failed to honour this court ruling resulting into", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district received off-budget financing to a tune of UGX. UGX.7, 989,897 directly from UNFPA for undertaking activities which was never declared to the PSST and as such no supplementary appropriation was issued as guided by the PSST.", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "attachment of three (3) District Motor vehicles.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district lost a court case (Busobozi Juma Vs Bundibugyo DLG); but failed to honour this court ruling resulting into", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district received off-budget financing to a tune of UGX. UGX.7, 989,897 directly from UNFPA for undertaking activities which was never declared to the PSST and as such no supplementary appropriation was issued as guided by the PSST.", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I further noted the district failed to absorb UGX.950, 886,390 of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I further noted the district failed to absorb UGX.950, 886,390 of", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district lost a court case (Busobozi Juma Vs Bundibugyo DLG); but failed to honour this court ruling resulting into", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the UgIFT funds received and the balance was swept back to the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I further noted the district failed to absorb UGX.950, 886,390 of", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district lost a court case (Busobozi Juma Vs Bundibugyo DLG); but failed to honour this court ruling resulting into", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Consolidated Fund Account at the end of the financial year.", "metadata": {"headings": [{"headings_0": {"content": "Consolidated Fund Account at the end of the financial year.", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 I further noted the district failed to absorb UGX.950, 886,390 of", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I further noted that the district had unutilized funds of UGX.336, 284,000 meant for the construction of Kabango Seed School which was swept back to the Consolidated Fund.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I further noted that the district had unutilized funds of UGX.336, 284,000 meant for the construction of Kabango Seed School which was swept back to the Consolidated Fund.", "page": 328, "level": 3}}, {"headings_1": {"content": "Consolidated Fund Account at the end of the financial year.", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of pension worth UGX.288,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of pension worth UGX.288,", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 I further noted that the district had unutilized funds of UGX.336, 284,000 meant for the construction of Kabango Seed School which was swept back to the Consolidated Fund.", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "866,531; Underpayment of pension worth UGX.271, 215,401;", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of pension worth UGX.288,", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 I further noted that the district had unutilized funds of UGX.336, 284,000 meant for the construction of Kabango Seed School which was swept back to the Consolidated Fund.", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Wrong computation of gratuity worth net overpayment of UGX. 54,578,592; payment of salaries worth UGX. 3,051,636 to two", "metadata": {"headings": [{"headings_0": {"content": "Wrong computation of gratuity worth net overpayment of UGX. 54,578,592; payment of salaries worth UGX. 3,051,636 to two", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of pension worth UGX.288,", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "(2) staffs that was no longer in service and irregular deduction of loan instalments worth UGX.9, 061,174.", "metadata": {"headings": [{"headings_0": {"content": "Wrong computation of gratuity worth net overpayment of UGX. 54,578,592; payment of salaries worth UGX. 3,051,636 to two", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of pension worth UGX.288,", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 Additionally, I observed that there was delayed access to payroll", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Additionally, I observed that there was delayed access to payroll", "page": 328, "level": 3}}, {"headings_1": {"content": "Wrong computation of gratuity worth net overpayment of UGX. 54,578,592; payment of salaries worth UGX. 3,051,636 to two", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "by twenty three (23) new employees and nine (9) pensioners;", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Additionally, I observed that there was delayed access to payroll", "page": 328, "level": 3}}, {"headings_1": {"content": "Wrong computation of gratuity worth net overpayment of UGX. 54,578,592; payment of salaries worth UGX. 3,051,636 to two", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "failure to utilize wage funds of UGX.2.38Bn; un-deducted PAYE", "metadata": {"headings": [{"headings_0": {"content": "failure to utilize wage funds of UGX.2.38Bn; un-deducted PAYE", "page": 328, "level": 3}}, {"headings_1": {"content": "\uf0b7 Additionally, I observed that there was delayed access to payroll", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of twenty two (22) staffs worth", "metadata": {"headings": [{"headings_0": {"content": "from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of twenty two (22) staffs worth", "page": 328, "level": 2}}, {"headings_1": {"content": "failure to utilize wage funds of UGX.2.38Bn; un-deducted PAYE", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.35,678,772 off the IPPS", "metadata": {"headings": [{"headings_0": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}, {"headings_1": {"content": "from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of twenty two (22) staffs worth", "page": 328, "level": 2}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "316", "metadata": {"headings": [{"headings_0": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}, {"headings_1": {"content": "from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of twenty two (22) staffs worth", "page": 328, "level": 2}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; under absorption of funds worth UGX.5,185,210,873 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.768,125,595; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines.", null, null], ["03.", "Kamwenge DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; over payment of pension"]], "metadata": {"headings": [{"headings_0": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}, {"headings_1": {"content": "from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of twenty two (22) staffs worth", "page": 328, "level": 2}}], "page": 329, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["\uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; under absorption of funds worth UGX.5,185,210,873 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.768,125,595; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines.", null, null], ["03.", "Kamwenge DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; over payment of pension"], [null, "Opinion Unqualified", "worth UGX.18,610,306; Underpayment of pension worth UGX."], [null, null, "20,537,350; Wrong computation of gratuity worth net"], [null, "", "overpayment of UGX. 126, 160257; payment of salaries worth"], [null, null, "UGX. 3,042,398 to six (6) staffs that was no longer in service;"], [null, null, "irregular deduction of loan instalments worth UGX.9,912,197 and"], [null, null, "failure to remit payroll deductions worth UGX.1,206,334,606"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by eleven (11) new employees; failure to utilize wage funds of"], [null, null, "UGX.2.32Bn; un-deducted PAYE from political leaders\u2019 gratuity"], [null, null, "resulting in unpaid tax of UGX.9,904,129; payment of forty three"], [null, null, "(43) staffs worth UGX.73,835,431 off the IPPS and failure to"], [null, null, "prepare monthly wage, pension and gratuity performance"], [null, null, "analysis report on payroll to MoPS"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.446,776,818 on"], [null, null, "wrong budget lines other than those prescribed for salary,"], [null, null, "pension and gratuity"], [null, null, ""], [null, null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds worth"], [null, null, "UGX.9, 615,375,142 that was eventually swept back to"], [null, null, "consolidated fund account at end of financial year; combined"], [null, null, "under performance worth UGX. 18,033,399,211 from planned"], [null, null, "donor funds, NTR, releases from Government & other"], [null, null, "Government units ; delayed submission of quarterly monitoring"], [null, null, "reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I observed that a total sum of UGX.792, 482,750 due from the"], [null, null, "groups that were funded in 2014/15, 2015/16, 2016/17, 2017/18"], [null, null, "and 2018/19 were still outstanding and therefore reported as"], [null, null, "revenue arrears at the year end."], [null, null, ""], [null, null, "\uf0b7 The district lacks evidence of ownership in form of titles for its"], [null, null, "land at Kabuga-Rubaba measuring 1,321 hectares."], [null, null, ""], [null, null, "\uf0b7 During a physical inspection of the Constructions, I noted a"]], "metadata": {"headings": [{"headings_0": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}, {"headings_1": {"content": "from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of twenty two (22) staffs worth", "page": 328, "level": 2}}], "page": 329, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "317", "metadata": {"headings": [{"headings_0": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}, {"headings_1": {"content": "from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of twenty two (22) staffs worth", "page": 328, "level": 2}}], "page": 329, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "number of shoddy works in Bwizi Seed School and upgrade"], [null, null, "Kabingo Health Centre II to Health Centre III."], ["04\\. Kasese DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, over payment of Salary and gratuity worth UGX. UGX.3, 574,714; Underpayment of pension worth UGX. 705,886; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.21, 251,680; payment of salaries worth UGX. 990,729 to two (2) staffs that was no longer in service and irregular deduction of loan instalments worth UGX.11, 312,968. \uf0b7 Additionally, I observed that there was delayed access to payroll by four (04) new employees and five (5) pensioners; failure to utilize wage funds of UGX.0.01Bn; over remittance UGX.14,857,510 was made to UNATU and UBA, and an under remittance of UGX.162,609,619 to URA and LST respectively; and payment of twenty nine (29) staffs & two (2) pensioners a total of UGX.35,824,742 off the IPPS \uf0b7 The district mischarged expenditure worth UGX.99,558,770 on wrong budget lines other than those prescribed for gratuity \uf0b7 The district\u2019s strategic plan was not certified by National Planning Authority. \uf0b7 I noted that the verification forms and copies of the verification cards for 150 new employees and 8 pensioners/beneficiaries were not on the respective personal files. \uf0b7 The district has uncollected Non Tax Revenue arrears to the tune of UGX.702, 009,983 that has remained outstanding for more than a year. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX. 6,349,941,923 that were eventually swept back to consolidated fund account at end of financial year; combined under performance worth UGX. 11,758,099,498 from planned donor funds, NTR, releases from Government & other Government units ; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Ninety one (91) pieces of land owned by the District lacked evidence of ownership in form of titles. \uf0b7 Out of the total funds of UGX.822, 539,506 UgIFT funds received, the district only utilized UGX.314,732,415 (38.26%) resulting into unspent balance of UGX.507,807,091.", null, null], ["05.", "Kyegegwa DLG", "\uf0b7 I noted a number of issues during the review of the district"], ["", "", null], [null, "Opinion", "pension and payroll such as;"], [null, "Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}, {"headings_1": {"content": "from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of twenty two (22) staffs worth", "page": 328, "level": 2}}], "page": 330, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; under absorption of funds worth UGX.5,185,210,873 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.768,125,595; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines.", "None", "None"], "type": "table"}}, {"content": "318", "metadata": {"headings": [{"headings_0": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}, {"headings_1": {"content": "from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of twenty two (22) staffs worth", "page": 328, "level": 2}}], "page": 330, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The district delayed to submit wage estimates to MoPs by the 30 th of September of the previous year as required. This may", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district delayed to submit wage estimates to MoPs by the 30 th of September of the previous year as required. This may", "page": 331, "level": 3}}, {"headings_1": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "lead to wage shortfalls/over provision due to lack of clarity and analysis of wage estimates by MoPS.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district delayed to submit wage estimates to MoPs by the 30 th of September of the previous year as required. This may", "page": 331, "level": 3}}, {"headings_1": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 Unpaid accrued gratuity worth UGX.92,701,695 by year end and Under absorption of wage funds worth UGX.1.13Bn that meant", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Unpaid accrued gratuity worth UGX.92,701,695 by year end and Under absorption of wage funds worth UGX.1.13Bn that meant", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district delayed to submit wage estimates to MoPs by the 30 th of September of the previous year as required. This may", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "some employees and pensioners were unpaid", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Unpaid accrued gratuity worth UGX.92,701,695 by year end and Under absorption of wage funds worth UGX.1.13Bn that meant", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district delayed to submit wage estimates to MoPs by the 30 th of September of the previous year as required. This may", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The verification forms and copies of the verification cards for 50", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The verification forms and copies of the verification cards for 50", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 Unpaid accrued gratuity worth UGX.92,701,695 by year end and Under absorption of wage funds worth UGX.1.13Bn that meant", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "employees were not on the respective personal files", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The verification forms and copies of the verification cards for 50", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 Unpaid accrued gratuity worth UGX.92,701,695 by year end and Under absorption of wage funds worth UGX.1.13Bn that meant", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The District did not prepare monthly wage, pension and gratuity", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The District did not prepare monthly wage, pension and gratuity", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 The verification forms and copies of the verification cards for 50", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "performance analysis and thus did not submit quarterly returns", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The District did not prepare monthly wage, pension and gratuity", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 The verification forms and copies of the verification cards for 50", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "on payroll to MoPS, contrary to Paragraph 2.1 of Establishment", "metadata": {"headings": [{"headings_0": {"content": "on payroll to MoPS, contrary to Paragraph 2.1 of Establishment", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 The District did not prepare monthly wage, pension and gratuity", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Notice No. 1 of 2020. This led to under absorption of wage, pension and gratuity budgets", "metadata": {"headings": [{"headings_0": {"content": "on payroll to MoPS, contrary to Paragraph 2.1 of Establishment", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 The District did not prepare monthly wage, pension and gratuity", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "page": 331, "level": 3}}, {"headings_1": {"content": "on payroll to MoPS, contrary to Paragraph 2.1 of Establishment", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "pay change reports", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "page": 331, "level": 3}}, {"headings_1": {"content": "on payroll to MoPS, contrary to Paragraph 2.1 of Establishment", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- 37 newly recruited/ transferred employees and 6 pensioners delayed to access payroll this affects staff moral and", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "page": 331, "level": 3}}, {"headings_1": {"content": "on payroll to MoPS, contrary to Paragraph 2.1 of Establishment", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "page": 331, "level": 3}}, {"headings_1": {"content": "on payroll to MoPS, contrary to Paragraph 2.1 of Establishment", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "accumulation of domestic arrears and paid UGX.1,446,726 was", "metadata": {"headings": [{"headings_0": {"content": "accumulation of domestic arrears and paid UGX.1,446,726 was", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "paid to 2 former staff who had either retired or died \n", "metadata": {"headings": [{"headings_0": {"content": "accumulation of domestic arrears and paid UGX.1,446,726 was", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "page": 331, "level": 3}}, [{"headings_0": {"content": "accumulation of domestic arrears and paid UGX.1,446,726 was", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "page": 331, "level": 3}}]], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The district did not subject political leaders\u2019 gratuity totalling to", "metadata": {"headings": [{"headings_0": {"content": "accumulation of domestic arrears and paid UGX.1,446,726 was", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "UGX.43,741,660 to the computation of PAYE in IPPS, leading to", "metadata": {"headings": [{"headings_0": {"content": "UGX.43,741,660 to the computation of PAYE in IPPS, leading to", "page": 331, "level": 3}}, {"headings_1": {"content": "accumulation of domestic arrears and paid UGX.1,446,726 was", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "an under deduction of UGX.13,224,798, contrary to section 19(1)", "metadata": {"headings": [{"headings_0": {"content": "an under deduction of UGX.13,224,798, contrary to section 19(1)", "page": 331, "level": 3}}, {"headings_1": {"content": "UGX.43,741,660 to the computation of PAYE in IPPS, leading to", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "(a) of the Income Tax Act", "metadata": {"headings": [{"headings_0": {"content": "an under deduction of UGX.13,224,798, contrary to section 19(1)", "page": 331, "level": 3}}, {"headings_1": {"content": "UGX.43,741,660 to the computation of PAYE in IPPS, leading to", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The district made unauthorised loan deductions totalling UGX.157,604,005. The deductions were from 84 employees that", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district made unauthorised loan deductions totalling UGX.157,604,005. The deductions were from 84 employees that", "page": 331, "level": 3}}, {"headings_1": {"content": "an under deduction of UGX.13,224,798, contrary to section 19(1)", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "neither had letters of undertaking nor existed in the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll", "metadata": {"headings": [{"headings_0": {"content": "neither had letters of undertaking nor existed in the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll", "page": 331, "level": 2}}, {"headings_1": {"content": "\uf0b7 The district made unauthorised loan deductions totalling UGX.157,604,005. The deductions were from 84 employees that", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Deduction Management System, operated by PCA-Payroll Consults Africa", "metadata": {"headings": [{"headings_0": {"content": "neither had letters of undertaking nor existed in the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll", "page": 331, "level": 2}}, {"headings_1": {"content": "\uf0b7 The district made unauthorised loan deductions totalling UGX.157,604,005. The deductions were from 84 employees that", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted unrecovered overdue YLP and UWEP receivables worth", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted unrecovered overdue YLP and UWEP receivables worth", "page": 331, "level": 3}}, {"headings_1": {"content": "neither had letters of undertaking nor existed in the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll", "page": 331, "level": 2}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "541,572,633 and 196,364,405 from beneficiary groups that has affected the revolution of the funds among other groups in the queue", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted unrecovered overdue YLP and UWEP receivables worth", "page": 331, "level": 3}}, {"headings_1": {"content": "neither had letters of undertaking nor existed in the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll", "page": 331, "level": 2}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted unrecovered overdue YLP and UWEP receivables worth", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "budget such as delayed submission of quarterly reports; underperformance of revenue worth 9,414,937,826; under absorption of funds worth UGX.3,780,702,017 that affected", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted unrecovered overdue YLP and UWEP receivables worth", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "319", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "at Kitayunjwa Seed School , ICT and science equipment for"], [null, "Kitayunjwa Seed School, Upgrading of Kagumba HC II to HC III"], [null, "and Procurement of medical equipment for Kagumba HC I and"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 332, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", "at Kitayunjwa Seed School , ICT and science equipment for"], [null, "Kitayunjwa Seed School, Upgrading of Kagumba HC II to HC III"], [null, "and Procurement of medical equipment for Kagumba HC I and"], [null, "Bubago HCII"], [null, "\uf0b7 I noted that the management had not prepared and approved a"], [null, "strategic plan that is aligned to the NDP-III at the time of audit"], [null, "\uf0b7 I noted ddelayed works for Construction of Karwenyi Health"], [null, "Center III under UgIFT. The contract was awarded to M/s.Nicole"], [null, "Associates Ltd at a contact sum of UGX.529, 682,320 and should"], [null, "have been completed on 07.09.19 but was still having pending"], [null, "works"], [null, "\uf0b7 I noted incomplete construction works on Rwentuuha seed"], [null, "school for works that should have ended by 07.04.2020"], [null, "\uf0b7 I noted funds shortfall of UGX.91, 745,203 for funds meant for"], [null, "road maintenance from URF that affected the implementation of"], [null, "planned works"], ["06\\. Kyenjojo DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, over payment of Gratuity worth UGX. UGX.4, 503,576; Underpayment of pension worth UGX. 10,233,398; payment of salaries worth UGX. 13, 121,357 to nine (9) staffs that was no longer in service and unauthorized deduction of loan instalments worth UGX. 21,809,702. \uf0b7 Additionally, I observed that there was delayed access to payroll by ten (10) new employees and two (2) pensioners; failure to utilize wage funds of UGX.0.96Bn; unremitted payroll deductions of UGX. 6,025,083 and failure to prepare monthly wage, pension and gratuity performance analysis report on payroll to MoPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX.3, 847,060,490 that was eventually swept back to consolidated fund account at end of financial year; combined under performance worth UGX. 22,372,196,592 from planned donor funds, NTR, releases from Government & other Government units; \uf0b7 Out of UGX.1, 300,000,000 received for Upgrading of Kigoyera HC II to HC III only UGX.480, 191,731 was utilized and the balance was swept back to the Treasury at the end of the financial year. \uf0b7 I noted shoddy works for M/s Build line Contractors Uganda LTD at a contract sum of UGX.2, 050,045,030. Although the end date was extended to 30th August 2020 and the contract sum revised to UGX.2, 150,170,030 to cater for variations", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 332, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "320", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 332, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 The districts strategic plan was not certified by National Planning Authority therefore I could not confirm that it is aligned to NDP- III.", null, null], ["07.", "Ntoroko DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 333, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_5"], "type": "table"}}, {"content": [["\uf0b7 The districts strategic plan was not certified by National Planning Authority therefore I could not confirm that it is aligned to NDP- III.", null, null], ["07.", "Ntoroko DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs; Underpayment of in payroll worth UGX."], [null, "Unqualified", "5,813,601; un-deducted PAYE from political leaders\u2019 gratuity"], [null, "", "resulting in unpaid tax of UGX.8, 062,325; Loan deductions"], [null, null, "relating to all the 279 employees did not have letters of"], [null, null, "undertaking and evidence of consent on file; One hundred five"], [null, null, "(105) staffs were paid using wrong salary scales, leading to over"], [null, null, "payments of UGX.9,200,722."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by thirty seven (37) new employees and one (01) pensioner;"], [null, null, "failure to utilize wage funds of UGX.0.026Bn; unremitted PAYE"], [null, null, "deductions of UGX.58,118,104, to URA; failure to prepare"], [null, null, "monthly wage, pension and gratuity performance analysis report"], [null, null, "on payroll to MoPS"], [null, null, ""], [null, null, "\uf0b7 I noted that the verification forms and copies of the verification"], [null, null, "cards for 50 employees were not on the respective personal files"], [null, null, ""], [null, null, "\uf0b7 The district\u2019s strategic plan was not certified by National Planning"], [null, null, "Authority therefore I could not confirm that it is aligned to NDP-"], [null, null, "III."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds worth"], [null, null, "UGX.824, 523,482 that was eventually swept back to"], [null, null, "consolidated fund account at end of financial year and a"], [null, null, "combined revenue under performance worth UGX. 1,971,531,402"], [null, null, "from planned donor funds, NTR, releases from other Government"], [null, null, "units"], [null, null, ""], [null, null, "\uf0b7 I noted that the Upgrade of Butungama HCIII under UgiFT works"], [null, null, "had stalled and behind schedule by 14 months."], ["08\\. Fort portal MC Unqualified Opinion \uf0b7 I noted a number of anomalies during review of the Municipal pension & salary payrolls such as; Failure to submit wage estimates to MoPs; Overpayment of UGX.1,547,570 Underpayment of in payroll worth UGX.674,289; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.3,015,540; failure to utilize wage funds of UGX.0.655Bn; Payment of 4 employees who were no longer in service; Under remittance of salary deductions worth UGX. UGX.68,499,107; Delayed remittance of deductions to UCLA/UBA of 5 to 90 days \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX.9, 264,101,819 that was eventually swept back to consolidated fund account at end of financial year; combined under performance worth UGX. 22,372,196,592 from planned", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 333, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_5"], "type": "table"}}, {"content": "321", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 333, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", null, null], ["", "Branch Jinja", "Summary of Key Findings"], ["01\\. Namutumba DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, over payment of Gratuity worth UGX. 6,699,263; Underpayment of salaries worth UGX 3,970,280; payment of salaries worth UGX. 34,532,950 to eighteen (18) staffs who were no longer in service; under remittance of payroll deduction of UGX. 42,851,131; unauthorized excess loan deductions worth UGX. 336,561,515 for one hundred seventy four (174) employees \uf0b7 Additionally, I observed that there was delayed access to payroll by ninety one (91) newly recruited/ transferred employees and nineteen (19) pensioners; eight (8) pensioners failed to access the pension payroll; failure to utilize wage funds of UGX.0.70Bn; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.9, 275,220; failure to prepare monthly wage, pension and gratuity performance analysis report on payroll to MoPS and overpayment of pensioners due to wrong computation worth UGX. 66,739,381 and payment of 05 employees worth UGX. 3,371,913 without authorization of pay change report. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX. 1,074,919,818 that were eventually swept back to consolidated fund account at end of financial year; under performance worth UGX. 183,402,134 from planned donor funds, NTR and releases from Government.; partial implementation of planned activities \uf0b7 The district mischarged expenditure worth UGX.41,963,816 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 09 staff and 10 pensioners were paid a total of UGX 461,890,255 off the IPPS.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 334, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "322", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 334, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that the District had uncovered funds (receivables) of UGX. 1,400,354,319 that affected the budget implementation of planned activities \uf0b7 The District\u2019s strategic plan is in place but no evidence of approval by the National Planning Authority was availed at the time of audit. \uf0b7 I noted that the construction works of a seed secondary school at Nabweyo did not take off in the financial year under review and the funds amounting to UGX. 344,284,000 were swept back to treasury. \uf0b7 The district lacked land titles for 17 pieces measuring approximately 299.3 acres which exposed the land to loss and encroachment. \uf0b7 The District received a sum of UGX. 223,381,891 for (06) secondary schools and (109) primary schools meant for the procurement of learning materials. However, the bank statements had not been availed for review at the time of audit.", null, null], ["02.", "Buyende DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 335, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["\uf0b7 I noted that the District had uncovered funds (receivables) of UGX. 1,400,354,319 that affected the budget implementation of planned activities \uf0b7 The District\u2019s strategic plan is in place but no evidence of approval by the National Planning Authority was availed at the time of audit. \uf0b7 I noted that the construction works of a seed secondary school at Nabweyo did not take off in the financial year under review and the funds amounting to UGX. 344,284,000 were swept back to treasury. \uf0b7 The district lacked land titles for 17 pieces measuring approximately 299.3 acres which exposed the land to loss and encroachment. \uf0b7 The District received a sum of UGX. 223,381,891 for (06) secondary schools and (109) primary schools meant for the procurement of learning materials. However, the bank statements had not been availed for review at the time of audit.", null, null], ["02.", "Buyende DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion: Unqualified", "estimates to MoPs, unpaid salaries of UGX 5,941,021 to nine (9)"], [null, null, "employees; Underpayment of salaries to staff worth UGX"], [null, null, "205,153,235; under payment of UGX 6,386,999 to pensioners;"], [null, null, "over payment of UGX 9,607,227; payment of salaries worth UGX."], [null, null, "11,313,061 to six (06) staffs who were no longer in service;"], [null, null, "under remittance of payroll deduction of UGX.205,612,209;"], [null, null, "unauthorized excess loan deductions worth UGX. 17,355,601 for"], [null, null, "168 employees"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by twenty nine (29) newly recruited/ transferred employees and"], [null, null, "seven (07) pensioners; un-deducted PAYE from political leaders\u2019"], [null, null, "gratuity resulting in unpaid tax of UGX. 12,019,045; failure to"], [null, null, "prepare monthly wage, pension and gratuity performance"], [null, null, "analysis report on payroll to MoPS and overpayment of"], [null, null, "pensioners due to wrong computation worth UGX. 20,650,780"], [null, null, "and payment of funds worth UGX. 8,205,747 off the IPPS system"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds worth UGX."], [null, null, "2,000,000,000,000 that were eventually swept back to"], [null, null, "consolidated fund account at end of financial year; under"], [null, null, "performance worth UGX. 2,097,035,126 from planned donor"], [null, null, "funds, NTR and releases from Government.; partial"], [null, null, "implementation of planned activities"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX. 71,513,039 on"], [null, null, "wrong budget lines other than those prescribed for salary,"], [null, null, "pension or gratuity"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 335, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "323", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 335, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", ""], [null, "\uf0b7 I noted that the entity had prepared a strategic plan but the"], [null, "National Planning Authority had not yet approved it at the time of"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 336, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": [["", ""], [null, "\uf0b7 I noted that the entity had prepared a strategic plan but the"], [null, "National Planning Authority had not yet approved it at the time of"], [null, "audit."], [null, ""], [null, "\uf0b7 Failure to quantify outputs, partial and non-implementation of"], [null, "planned activities, late submission of quarterly reports"], [null, ""], [null, "\uf0b7 I noted that funds to the tune of UGX. 571,677,701 were"], [null, "irregularly diverted from the activities on which they were"], [null, "budgeted and spent on other activities without seeking and"], [null, "obtaining the necessary approvals."], [null, ""], [null, "\uf0b7 Of the 9 road equipments at the district, 03 were grounded and"], [null, "in need of major repairs and I also observed lack of vital road"], [null, "equipment such as an excavator, a backhoe, supervision double"], [null, "cabin pickup and 02 supervision motor cycles."], [null, ""], [null, "\uf0b7 Delayed construction works on Buyende Seed School and expired"], [null, "performance security for the contract from the contractor was"], [null, "also noted"], [null, ""], [null, "\uf0b7 I note that there undelivered ICT Equipments worth UGX."], [null, "148,842,899 to Buyende Seed Secondary School; unutilized"], [null, "funds worth UGX. 178,400,391 meant for procurement of"], [null, "learning materials for (05) secondary schools and (91) primary"], [null, "schools."], [null, ""], [null, "\uf0b7 I noted that accountability amounting to UGX. 61,788,892 were"], [null, "not presented for verification by the time of audit."], [null, ""], [null, "\uf0b7 The district lacked land titles for 48 pieces measuring"], [null, "approximately 1,942 hectares which exposed the land to loss and"], [null, "encroachment."], ["03\\. Jinja DLG Opinion: Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, unpaid salaries and pension arrears of UGX 484,546,138; Underpayment of salaries to staff worth UGX. 40,243,749; under payment of UGX 6,386,999 to pensioners; over payment of UGX 9,607,227; payment of salaries worth UGX. 2,763,055 to six (06) staffs who were no longer in service \uf0b7 Additionally, I observed that there was delayed access to payroll by Fifteen (15) newly recruited/ transferred employees and three (03) pensioners; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 10,866,949; failure to prepare monthly wage, pension and gratuity performance analysis report on payroll to MoPS and payment to 06 staff and 09 pensioners of funds worth UGX. 62,763,120 off the IPPS system \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to Quantify outputs; partial &", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 336, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": "324", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 336, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["non-implementation of planned activities and delayed submission of performance reports; under absorption of funds worth UGX. 1,890,511,130 that were eventually swept back to consolidated fund account at end of financial year; under performance of NTR worth UGX. 341,038,789 \uf0b7 The district has outstanding unrecovered YLP and UWEP advances worth UGX. 1,164,605,343", null, null], ["04.", "Jinja MC", "\uf0b7 I noted a number of anomalies during review of the municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 337, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["non-implementation of planned activities and delayed submission of performance reports; under absorption of funds worth UGX. 1,890,511,130 that were eventually swept back to consolidated fund account at end of financial year; under performance of NTR worth UGX. 341,038,789 \uf0b7 The district has outstanding unrecovered YLP and UWEP advances worth UGX. 1,164,605,343", null, null], ["04.", "Jinja MC", "\uf0b7 I noted a number of anomalies during review of the municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion: Unqualified", "estimates to MoPs, failure to utilize wage funds of UGX.0.5Bn;"], [null, null, "unpaid salaries and pension arrears of UGX 484,546,138;"], [null, null, "Underpayment of salaries to staff worth UGX 2,179,634; under"], [null, null, "payment of UGX.54,373,901 to pensioners; over payment of"], [null, null, "gratuity worth UGX 34,302,808 to one pensioner arising from"], [null, null, "wrong computation; Underpayment of pensions worth UGX"], [null, null, "49,155,207; nonpayment of a pensioner worth UGX 10,907,334"], [null, null, "and payment of salaries worth UGX. 1,158,981 to two (02) staffs"], [null, null, "who were no longer in service"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by eight (08) newly recruited/ transferred employees and thirty"], [null, null, "five (35) pensioners; failure to prepare monthly wage, pension"], [null, null, "and gratuity performance analysis report on payroll to MoPS; Net"], [null, null, "under remittance of payroll deductions worth UGX. 42,851,131;"], [null, null, "payment of a staff and a pensioner worth UGX 13,515,274 off"], [null, null, "the IPPS and payment to 03 employees worth UGX. 6,202,537"], [null, null, "without signed pay change reports."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to Quantify outputs; delayed"], [null, null, "submission of performance reports; under absorption of funds"], [null, null, "worth UGX 2,361,255,255 that were eventually swept back to"], [null, null, "consolidated fund account at end of financial year; under"], [null, null, "performance of NTR & transfers from other Government Units"], [null, null, "worth UGX. 6,353,273,753"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had prepared a strategic plan but the"], [null, null, "National Planning Authority had not yet approved it at the time of"], [null, null, "audit"], [null, null, ""], [null, null, "\uf0b7 The Municipal Council had outstanding payables of UGX"], [null, null, "894,801,904 by the end of the year"], [null, null, ""], [null, null, "\uf0b7 The Municipality mischarged UGX. 132,864,963 on wrong"], [null, null, "account codes other than those prescribed for salary, pension or"], [null, null, "gratuity."], [null, null, ""], [null, null, "\uf0b7 I noted underfunding of UGX. 41,469,000 from URF that affected"], [null, null, "the routine manual, mechanized and periodic road maintenance"], [null, null, "under force account mechanism."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 337, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "325", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 337, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 I noted that the Municipal Council had 12-road equipment of"], [null, null, "which two (02) were grounded and in need of major repairs."], [null, null, "Additionally, I also observed that the Municipal lacked vital road"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 338, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["", null, "\uf0b7 I noted that the Municipal Council had 12-road equipment of"], [null, null, "which two (02) were grounded and in need of major repairs."], [null, null, "Additionally, I also observed that the Municipal lacked vital road"], [null, null, "equipment like a water bowser, a roller, chips spreader and a"], [null, null, "jet/pothole patcher."], [null, null, ""], [null, null, "\uf0b7 Under USMID, the Municipal Council had unspent balance of UGX"], [null, null, "1,701,586,908, meant for road construction works and"], [null, null, "incomplete road works by the year end"], [null, null, ""], [null, null, "\uf0b7 Under UgIFT, I noted that the construction works on Kimaka"], [null, null, "Health Centre III at a cost of UGX. 493,924,741 had stalled for"], [null, null, "over a year and the contractor had abandoned the site."], [null, null, ""], [null, null, "\uf0b7 The Municipal Council lacked land titles for 16 pieces measuring"], [null, null, "approximately over 34.265 hectares which exposed the land to"], [null, null, "possible loss and encroachment."], [null, null, ""], [null, null, "\uf0b7 I noted that Council was involved in 13 ongoing court cases"], [null, null, "which could lead to possible loss of funds."], ["05\\. Kaliro DLG Opinion: Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.0.4Bn; Underpayment of salaries to staff worth UGX. 24,360,137; under payment of UGX. 44,242,332 to pensioners and payment of salaries worth UGX. 2,246,579 to 5 staffs who were no longer in service \uf0b7 Additionally, I observed that there was delayed access to payroll by fifty-one (51) newly recruited/transferred employees and 03 pensioners; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 8,194,860. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to Quantify outputs; delayed submission of performance reports; under absorption of funds worth UGX. 1,575,930,542 that were eventually swept back to consolidated fund account at end of financial year; under performance of NTR & transfers from other Government Units worth UGX. 288,478,184. \uf0b7 I noted that the district had outstanding receivables of UGX. 1,240,015,837 at year end that had not been collected \uf0b7 There was delayed physical progress of the works at Buyinda health centre, Kasokwe Health Centre and Bukamba Seed Secondary School. This was attributed to effects of Covid-19 pandemic. \uf0b7 I noted that Kaliro DLG did not have land titles for 38 pieces of land measuring approximately 283.25 acres.", null, null], ["06.", "Kamuli MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 338, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "326", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 338, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion: Unqualified", "estimates to MoPs, failure to utilize wage funds of UGX.0.4Bn;"], [null, null, "Underpayment of salaries to staff worth UGX 17,301,287;"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 339, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion: Unqualified", "estimates to MoPs, failure to utilize wage funds of UGX.0.4Bn;"], [null, null, "Underpayment of salaries to staff worth UGX 17,301,287;"], [null, "", "overpayment to 239 staff worth UGX 12,549,285 under payment"], [null, null, "of gratuity worth UGX. 8,102,108 to pensioners; payment of"], [null, null, "salaries worth UGX. 5,528,605 to 2 staffs who were no longer in"], [null, null, "service; over and under remittance of salary deductions"], [null, null, "amounting to UGX 1,392,544 and UGX 30,126,523"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by 25 newly recruited/ transferred employees and 05 pensioners;"], [null, null, "un-deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX. 2,026,660; Unauthorized payroll deductions"], [null, null, "worth UGX 156,349,689 relating to 84 without letters of"], [null, null, "undertaking; over deductions payments worth UGX. 2,876,352"], [null, null, "and paid 03 staff and 07 politicians were worth UGX 14,156,592"], [null, null, "off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to Quantify outputs; delayed"], [null, null, "submission of performance reports; inaccurate reporting of"], [null, null, "performance; under absorption of funds worth UGX"], [null, null, "9,850,625,641 that were eventually swept back to consolidated"], [null, null, "fund account at end of financial year; under performance of NTR"], [null, null, "& transfers from other Government Units worth UGX."], [null, null, "609,177,435"], [null, null, ""], [null, null, "\uf0b7 I noted that the Municipal Council had outstanding receivables of"], [null, null, "UGX 592,620,187 that had not been recovered by year end."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had prepared a strategic plan but the"], [null, null, "National Planning Authority had not yet approved it at the time of"], [null, null, "audit."], [null, null, ""], [null, null, "\uf0b7 Failure to quantify outputs, partial or non-implementation of"], [null, null, "activities not quantified late submission of quarterly reports and."], [null, null, ""], [null, null, "\uf0b7 The Municipal Council had unspent funds under the USMID grant"], [null, null, "worth UGX. 9,421,230,865, which was subsequently swept back"], [null, null, "to the Consolidated Fund. Additionally, that the road construction"], [null, null, "works did not take off in the financial year under review."], [null, null, ""], [null, null, "\uf0b7 I noted that the construction works of two classroom blocks and"], [null, null, "water borne toilet at Busoga High School at UGX. 309,872,760"], [null, null, "were incomplete."], [null, null, ""], [null, null, "\uf0b7 The Municipal Council lacked land titles for 11 pieces which"], [null, null, "exposed the land to loss and encroachment."], [null, null, ""], ["07\\. Mayuge DLG Opinion: Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.1.2Bn; I also noted that there was an under payment of salaries and", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 339, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "327", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 339, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["pensions worth UGX. 1,193,840,180; Unpaid salaries worth UGX. 14,134,729; over payments of UGX. 17,722,575 to pensioners; 71 staff were paid using wrong salary scales, leading to monthly over payments of UGX. 1,177,702 and under payments of UGX. 1,257,209 respectively; nine (09) employees and fifteen (15) pensioners failed to access the payroll during the year; under remittance of salary deductions worth UGX. 45,320,114 \uf0b7 Additionally, I observed that there was delayed access to payroll by one hundred nine (109) newly recruited/ transferred employees and sixteen (16) pensioners; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 13,865,233; Unauthorized loan deductions worth UGX. 52,171,779 relating to 59 employees due to absence of Letters of undertaking; over deductions payments worth UGX. 2,876,352 and Paid 07 employees and 09 pensioners worth UGX. 89,285,252 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to Quantify outputs; delayed submission of performance reports; inaccurate reporting of performance; under absorption of funds worth UGX 2,017,223,134 that were eventually swept back to consolidated fund account at end of financial year; under performance of NTR & transfers from other Government Units worth UGX. 1,017,773,209 and delayed completion for the construction of Bukatube health and Nkombe Health Centre III \uf0b7 I noted that the district had outstanding receivables of UGX. 1,559,419,200 by year end \uf0b7 The Mayuge District had outstanding pension liabilities of UGX. 1,251,580,052 by the end of the year. \uf0b7 I noted that Mayuge District received off-budget financing to a tune of UGX 58,291,066 directly from Ministry of Local Governments for undertaking activities which were never declared to the PS/ST. \uf0b7 I noted that there is illegal mining of sand being carried out at the district lakeshores. The Accounting Officer explained that management had written to the prospective stakeholders in the sand mining activities giving guidance on the sustainable way of carrying out the activity including closure of some of the sand mines. \uf0b7 I noted that Mayuge DLG did not have land titles for 33 pieces of land measuring approximately 1430.761 Ha.", null, null], ["08.", "Lugazi MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 340, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["pensions worth UGX. 1,193,840,180; Unpaid salaries worth UGX. 14,134,729; over payments of UGX. 17,722,575 to pensioners; 71 staff were paid using wrong salary scales, leading to monthly over payments of UGX. 1,177,702 and under payments of UGX. 1,257,209 respectively; nine (09) employees and fifteen (15) pensioners failed to access the payroll during the year; under remittance of salary deductions worth UGX. 45,320,114 \uf0b7 Additionally, I observed that there was delayed access to payroll by one hundred nine (109) newly recruited/ transferred employees and sixteen (16) pensioners; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 13,865,233; Unauthorized loan deductions worth UGX. 52,171,779 relating to 59 employees due to absence of Letters of undertaking; over deductions payments worth UGX. 2,876,352 and Paid 07 employees and 09 pensioners worth UGX. 89,285,252 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to Quantify outputs; delayed submission of performance reports; inaccurate reporting of performance; under absorption of funds worth UGX 2,017,223,134 that were eventually swept back to consolidated fund account at end of financial year; under performance of NTR & transfers from other Government Units worth UGX. 1,017,773,209 and delayed completion for the construction of Bukatube health and Nkombe Health Centre III \uf0b7 I noted that the district had outstanding receivables of UGX. 1,559,419,200 by year end \uf0b7 The Mayuge District had outstanding pension liabilities of UGX. 1,251,580,052 by the end of the year. \uf0b7 I noted that Mayuge District received off-budget financing to a tune of UGX 58,291,066 directly from Ministry of Local Governments for undertaking activities which were never declared to the PS/ST. \uf0b7 I noted that there is illegal mining of sand being carried out at the district lakeshores. The Accounting Officer explained that management had written to the prospective stakeholders in the sand mining activities giving guidance on the sustainable way of carrying out the activity including closure of some of the sand mines. \uf0b7 I noted that Mayuge DLG did not have land titles for 33 pieces of land measuring approximately 1430.761 Ha.", null, null], ["08.", "Lugazi MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs, failure to utilize wage funds of UGX.0.4Bn; I"], [null, null, "also noted that there was an under payment of salaries worth"], [null, "", "UGX. 8,183,158; Unpaid salaries worth UGX. 34,305,160; Under"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 340, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "328", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 340, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "payments of UGX. 321,560,027 to pensioners; over payments of"], [null, "UGX. 7,263,946 and under payments of UGX. 1,360,106 arising"], [null, "from use of wrong bands; over and under remittance of salary"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 341, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": [["", "payments of UGX. 321,560,027 to pensioners; over payments of"], [null, "UGX. 7,263,946 and under payments of UGX. 1,360,106 arising"], [null, "from use of wrong bands; over and under remittance of salary"], [null, "deduction worth UGX. 2,697,535 and UGX. 35,487,023"], [null, "respectively"], [null, ""], [null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, "by 14 newly recruited/ transferred employees and thirteen (13)"], [null, "pensioners; un-deducted PAYE from political leaders\u2019 gratuity"], [null, "resulting in unpaid tax of UGX. 3,289,681; Unauthorized loan"], [null, "deductions worth UGX. 565,433,218 relating to 500 employees"], [null, "due to absence of Letters of undertaking; over deductions"], [null, "payments worth UGX. 2,876,352 and paid 15 staff and 10"], [null, "pensioners a total of UGX. 27,696,793 off the IPPS"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; Failure to Quantify outputs; delayed"], [null, "submission of performance reports; under absorption of funds"], [null, "worth UGX 14,415,862,633 that were eventually swept back to"], [null, "consolidated fund account at end of financial year"], [null, ""], [null, "\uf0b7 I noted that the Municipal Council had outstanding receivables of"], [null, "UGX. 1,973,054,521 by the year end that remained unrecovered"], [null, ""], [null, ""], [null, "\uf0b7 Under absorption of funds worth UGX. 14,177,800,402 under the"], [null, "USMID program that was eventually swept back to the"], [null, "consolidated fund."], [null, ""], [null, "\uf0b7 I noted under performance of funds worth UGX 17,916,865 from"], [null, "Uganda Road Fund meant for road maintenance in the"], [null, "municipality."], [null, ""], [null, "\uf0b7 I noted that Council was involved in 06 ongoing court cases"], ["09\\. Namayingo DLG Opinion: Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.0.72Bn; Unpaid salaries and pensions worth UGX. 49,235,421; under payments of UGX. 129,040,476 to pensioners; over and under payment of salaries worth UGX. 14,206,136 and UGX. 4,684,855 respectively due to use of wrong salary scales \uf0b7 Additionally, I noted there was un-deduction of PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 9,992,741; Unauthorized loan deductions worth UGX. 702,716,508 relating to 458 employees due to absence of Letters of undertaking; paid 33 staff and 16 pensioners a total of UGX. 38,434,320 off the IPPS \uf0b7 I observed that twenty-four (24) newly recruited/transferred employees and ten (10) pensioners delayed to access payroll; four (04) employees & seventeen (17) pensioners had not yet accessed the payroll by the close of the financial year and", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 341, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": "329", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 341, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["payment of 5 employees who were no longer in service \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 1,299,253,676 that were eventually swept back to consolidated fund account at end of financial year and under performance of revenues worth UGX. 896,645,767 \uf0b7 The District mischarged funds worth UGX. 5,057,686 on account codes other than those prescribed for salary, pension and gratuity. \uf0b7 Further, the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS, \uf0b7 I noted that the district had outstanding receivables of UGX. 1,063,954,752 that had not been recovered. \uf0b7 There was a delay in the physical progress of works at Bukana health centre III and Syanyonja Health centre. \uf0b7 I noted that Namayingo DLG did not have land titles for 113 pieces of land measuring approximately 357.3 hectares and 09 pieces of land were in the process of being titled.", null, null], ["10.", "Bugweri DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 342, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["payment of 5 employees who were no longer in service \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 1,299,253,676 that were eventually swept back to consolidated fund account at end of financial year and under performance of revenues worth UGX. 896,645,767 \uf0b7 The District mischarged funds worth UGX. 5,057,686 on account codes other than those prescribed for salary, pension and gratuity. \uf0b7 Further, the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS, \uf0b7 I noted that the district had outstanding receivables of UGX. 1,063,954,752 that had not been recovered. \uf0b7 There was a delay in the physical progress of works at Bukana health centre III and Syanyonja Health centre. \uf0b7 I noted that Namayingo DLG did not have land titles for 113 pieces of land measuring approximately 357.3 hectares and 09 pieces of land were in the process of being titled.", null, null], ["10.", "Bugweri DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.38Bn;"], [null, "Unqualified", "Unpaid pensions worth UGX. 110,127,127; Over payments of"], [null, "", "UGX. 3,000,000 to pensioners; over and under payment of"], [null, null, "salaries worth 9,273,543 and UGX. 4,410,477 respectively due to"], [null, null, "use of wrong bands"], [null, null, ""], [null, null, "\uf0b7 Additionally, I noted there was un-deduction of PAYE from"], [null, null, "political leaders\u2019 gratuity resulting in unpaid tax of UGX."], [null, null, "1,040,880; paid 23 staff and 15 pensioners were paid a total of"], [null, null, "UGX. 33,868,147 and UGX. 190,371,130 off the IPPS; over and"], [null, null, "under remittances of pay roll deductions of UGX. 532,326,787"], [null, null, "and UGX. 31,529,271 respectively; Payment of UGX.35,780,089"], [null, null, "to 09 employees who were no longer in service; wrong"], [null, null, "computation of gratuity benefits of 01 pensioner (TAJJUBA"], [null, null, "STEPHEN 417573) that resulted into an over payment of gratuity"], [null, null, "by UGX. 26, 936,170."], [null, null, ""], [null, null, "\uf0b7 I observed that 22 newly recruited employees and 15 pensioners"], [null, null, "delayed to access the pension payroll and the district did not"], [null, null, "prepare monthly wage, pension and gratuity performance"], [null, null, "analysis and thus did not submit quarterly returns on payroll to"], [null, null, "MoPS"], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 342, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "330", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 342, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; Failure to quantify outputs; partial and"], [null, "non-implementation of planned activities delayed submission of"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 343, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": [["", "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; Failure to quantify outputs; partial and"], [null, "non-implementation of planned activities delayed submission of"], [null, "performance reports; under absorption of funds worth UGX."], [null, "944,877,155 that were eventually swept back to consolidated"], [null, "fund account at end of financial year and under performance of"], [null, "revenues worth UGX. 6,114,158,151"], [null, ""], [null, "\uf0b7 I noted that the District had outstanding receivables worth UGX."], [null, "499,741,444 that was not yet recovered."], [null, ""], [null, "\uf0b7 I noted that the district had prepared a draft strategic plan but it"], [null, "had not yet been approved by the National Planning Authority."], [null, ""], [null, "\uf0b7 I noted that Bugweri District received off-budget financing to a"], [null, "tune of UGX. 860,199,000 without seeking approval."], [null, ""], [null, "\uf0b7 I noted that funds to the tune of UGX. 129,996,921 were"], [null, "misclassified."], [null, ""], [null, "\uf0b7 I noted that the District lacked land titles for 31 pieces of land"], [null, "measuring approximately 179 acres including schools, sub"], [null, "counties and health centers."], [null, ""], [null, "\uf0b7 Bugweri district received a sum of UGX. 155,136,081 for (06)"], [null, "secondary schools and (54) primary schools meant for the"], [null, "procurement of learning materials in March, 2021 but disbursed"], [null, "only UGX. 136,182,515 to the respective schools on 4 th June,"], [null, "2021 leaving an outstanding amount of UGX. 18,953,562 which"], [null, "remained unaccounted for."], [null, ""], [null, "\uf0b7 I noted that expenditure totaling UGX. 374,878,394 lacked"], [null, "adequate supporting documentation at the close of the financial"], [null, "year"], ["11\\. Bugiri Municipal Council Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.0.53Bn and over payment of salaries worth UGX. 4,618,049 due to use of wrong bands \uf0b7 Additionally, I observed that there was delayed access to payroll by 11 employees on the salary payroll and 03 pensioners on the pension pay roll; over and underpayment of salaries worth UGX. 5,020,000 UGX. 1,353,000; paid 15 staff and 03 pensioners were paid a total of UGX. 58,059,084 off the IPPS and paid five (5) employees a total of UGX. 29,073,390 without signed pay change reports \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 568,033,989 that were eventually swept back to consolidated", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 343, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": "331", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 343, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["fund account at end of financial year and under performance of revenues worth UGX. 334,420,647. \uf0b7 I noted that funds to the tune of UGX. 33,234,682 were paid on the wrong account codes. \uf0b7 I noted that the Council had outstanding receivables of UGX. 585,573,492. That remained unrecovered by year end \uf0b7 I noted that the entity\u2019s NDP-III was still in draft form and had not had its Strategic plan approved by NPA at the time of audit. \uf0b7 Road maintenance works was affected by budget shortfalls for funds worth GX 63,409,282 from URF. \uf0b7 I noted that expenditure totaling UGX. 37,580,848 advanced to staff and various suppliers to carry out activities lacked adequate supporting documents. \uf0b7 I noted that the Council lacked land titles for 07 pieces of its land.", null, null], ["12.", "Kamuli DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 344, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["fund account at end of financial year and under performance of revenues worth UGX. 334,420,647. \uf0b7 I noted that funds to the tune of UGX. 33,234,682 were paid on the wrong account codes. \uf0b7 I noted that the Council had outstanding receivables of UGX. 585,573,492. That remained unrecovered by year end \uf0b7 I noted that the entity\u2019s NDP-III was still in draft form and had not had its Strategic plan approved by NPA at the time of audit. \uf0b7 Road maintenance works was affected by budget shortfalls for funds worth GX 63,409,282 from URF. \uf0b7 I noted that expenditure totaling UGX. 37,580,848 advanced to staff and various suppliers to carry out activities lacked adequate supporting documents. \uf0b7 I noted that the Council lacked land titles for 07 pieces of its land.", null, null], ["12.", "Kamuli DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs, failure to utilize wage funds of UGX.1.3Bn;"], [null, null, "Unpaid pensions worth UGX. 129,711,499; Under payments of"], [null, "", "UGX. 789,022,349 to pensioners; under payment of salaries"], [null, null, "worth UGX. 16,604,611 and nonpayment of salaries worth UGX."], [null, null, "13,045,994"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by 25 newly recruited/ transferred employees and 14 pensioners;"], [null, null, "un-deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX.13,801,906; Unauthorized loan deductions"], [null, null, "worth UGX. 179,141,809 due to absence of Letters of"], [null, null, "undertaking; over/ under remittance of salary deductions worth"], [null, null, "UGX. 2,758,277 and paid UGX.5, 049,620 to 13 staff who had"], [null, null, "retired, transferred, absconded or died."], [null, null, ""], [null, null, "\uf0b7 I noted that Kamuli District had outstanding receivables figure of"], [null, null, "UGX. 1,309,756,172 that remained unrecovered by year end."], [null, null, ""], [null, null, "\uf0b7 I noted, the entity did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to quantify outputs; partial and"], [null, null, "non-implementation of planned activities delayed submission of"], [null, null, "performance reports; under absorption of funds worth UGX."], [null, null, "3,884,528,244 that was eventually swept back to consolidated"], [null, null, "fund account at end of financial year and under performance of"], [null, null, "revenues worth UGX. 1,734,443,308"], [null, null, ""], [null, null, "\uf0b7 I noted that Kamuli District received off-budget financing to a"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 344, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "332", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 344, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "tune of UGX. 185,243,153 directly from Ministry of Health (MoH)"], [null, "and Marie topes for undertaking activities which was never"], [null, "declared to the PSST and as such no supplementary"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 345, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": [["", "tune of UGX. 185,243,153 directly from Ministry of Health (MoH)"], [null, "and Marie topes for undertaking activities which was never"], [null, "declared to the PSST and as such no supplementary"], [null, "appropriation was issued as guided by the PSST."], [null, ""], [null, "\uf0b7 I noted that the District lacked land titles for 194 pieces of land"], [null, "measuring approximately 546 acres including schools and health"], [null, "centers."], [null, ""], [null, "\uf0b7 I noted delays in the construction works on Kitayunjwa seed"], [null, "secondary school and construction works of seed secondary"], [null, "schools at Nabwigulu and Kagumba did not take off in the"], [null, "financial year under review and the funds were swept back to"], [null, "treasury."], [null, ""], [null, "\uf0b7 I noted at the time of inspection on 25th August, 2021 that"], [null, "science kits and chemicals that were delivered for Kitayunjwa"], [null, "Seed School were still in the district stores."], [null, ""], [null, "\uf0b7 I observed that works at Kagumba HC II were still ongoing and"], [null, "the works progress was behind"], [null, ""], [null, "\uf0b7 Under URF, There was underfunding of UGX 49,538,044 under"], [null, "URF for road maintenance"], ["13\\. Jinja RRH Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the Hospital pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.1.7Bn; over payment of gratuity worth UGX. 12,702,466 resulting from wrong computations; under payments of pension and gratuity of UGX. 393,563,387; under payment of salaries worth UGX. 43,160,618 and nonpayment of salaries worth UGX. 5,193,740 to eight employees; 14 pensioners were paid a total of UGX. 622,229,852 off the IPPS; twenty two (22) pensioners delayed to access the pension payroll; paid 4 employees who had retired worth UGX. 6,149,095 and under remittance of pay roll deductions amounting to UGX. 39,740,732 \uf0b7 The Hospital had payables of UGX. 1,184,835,800 for payment of utilities, pension and gratuity. \uf0b7 I noted that the entity did not have an approved strategic plan that was aligned to the NDP-III at the time of audit. \uf0b7 I noted that the Referral Hospital received off-budget financing to a tune of UGX.1,482,640,867, which was not declared to treasury. \uf0b7 Expenditure totaling UGX. 154,045,146 was misclassified through wrong coding \uf0b7 The referral hospital received UGX. 581,089,500 as covid 19 funds. Out of which UGX. 385,881,400 was utilized but UGX.30, 585,000 lacked adequate supporting documentation at the close", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 345, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": "333", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 345, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["of the financial year. Further, I observed there was unspent balance of UGX. 195,208,100 \uf0b7 I noted that NTR totaling to UGX.74, 272,140 was spent at source contrary to regulations \uf0b7 Jinja RRH made Payments totaling UGX.41, 914,100 for clearing domestic arrears lacked appropriate supporting documents, UGX.76, 523,500 paid to M/S Rodek Enterprises Ltd towards settlement of outstanding bills for cleaning services of the hospital had not been cleared by Ernst and Young. \uf0b7 The hospital received off-budget financing from the Ministry of health amounting to UGX. 1,482,640,867. \uf0b7 I noted that the hospital commenced construction of a storey staff house on 15 th /04/2019 with an intended completion date of 14 th /10/2021 at a contract price of UGX. 3,205,111,734 but was noted to be incomplete to date, with outstanding advance payment of UGX. 73,337,302 to the contractor. \uf0b7 Expenditures worth UGX. 166,012,755 lacked adequate supporting documents \uf0b7 The Hospital had stock outs of Essential medicines for supportive treatment of Covid-19 during the year with an average stock out period of more than a month. Several drugs that expired during the year had not yet been removed from the shelves as required. \uf0b7 I observed that the hospital did not carry out regular maintenance of the available medical equipment. \uf0b7 I noted that the Hospital did not have land titles for 5 pieces of land measuring approximately 46.7 acres. \uf0b7 I noted that some of the buildings in the hospital were in a dilapidated state while other blocks accommodating nurses were not fit for accommodation due to their dilapidated state and there was lack of hygiene facilities such as latrines and bathrooms.", null, null], ["14.", "Bugiri DA", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 346, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": [["of the financial year. Further, I observed there was unspent balance of UGX. 195,208,100 \uf0b7 I noted that NTR totaling to UGX.74, 272,140 was spent at source contrary to regulations \uf0b7 Jinja RRH made Payments totaling UGX.41, 914,100 for clearing domestic arrears lacked appropriate supporting documents, UGX.76, 523,500 paid to M/S Rodek Enterprises Ltd towards settlement of outstanding bills for cleaning services of the hospital had not been cleared by Ernst and Young. \uf0b7 The hospital received off-budget financing from the Ministry of health amounting to UGX. 1,482,640,867. \uf0b7 I noted that the hospital commenced construction of a storey staff house on 15 th /04/2019 with an intended completion date of 14 th /10/2021 at a contract price of UGX. 3,205,111,734 but was noted to be incomplete to date, with outstanding advance payment of UGX. 73,337,302 to the contractor. \uf0b7 Expenditures worth UGX. 166,012,755 lacked adequate supporting documents \uf0b7 The Hospital had stock outs of Essential medicines for supportive treatment of Covid-19 during the year with an average stock out period of more than a month. Several drugs that expired during the year had not yet been removed from the shelves as required. \uf0b7 I observed that the hospital did not carry out regular maintenance of the available medical equipment. \uf0b7 I noted that the Hospital did not have land titles for 5 pieces of land measuring approximately 46.7 acres. \uf0b7 I noted that some of the buildings in the hospital were in a dilapidated state while other blocks accommodating nurses were not fit for accommodation due to their dilapidated state and there was lack of hygiene facilities such as latrines and bathrooms.", null, null], ["14.", "Bugiri DA", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Unqualified Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.017Bn;"], [null, null, "un-deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX.13,100,078"], [null, null, ""], [null, null, "\uf0b7 Additionally, 68 newly recruited/ transferred employees and 04"], [null, null, "pensioners delayed to access the payroll; paid 7 employees who"], [null, null, "were no longer in service worth UGX. 4,090,197; Unpaid salaries"], [null, null, "worth UGX. 6,074,121; underpayment and overpayment of"], [null, null, "pensions & gratuity worth UGX. 26,897,618 and UGX. 13,600,648"], [null, null, "respectively and the district made unauthorized loan deductions"], [null, null, "from 49 employees worth UGX. 150,566,095"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 346, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": "334", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 346, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", ""], [null, "\uf0b7 I noted that Bugiri District had outstanding receivables of UGX."], [null, "1,140,326,136 that had remained unrecovered"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 347, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", ""], [null, "\uf0b7 I noted that Bugiri District had outstanding receivables of UGX."], [null, "1,140,326,136 that had remained unrecovered"], [null, ""], [null, "\uf0b7 Payables of UGX. 30,517,114 remained unsettled by year end"], [null, ""], [null, "\uf0b7 I noted that the entity had prepared a draft Strategic plan but"], [null, "had not yet been approved by NPA at the time of audit."], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; Failure to quantify outputs; partial and"], [null, "non-implementation of planned activities delayed submission of"], [null, "performance reports; under absorption of funds worth UGX. UGX."], [null, "422,963,116 that was eventually swept back to consolidated fund"], [null, "account at end of financial year and under performance of"], [null, "revenues worth UGX. 3,550,589,111"], [null, ""], [null, "\uf0b7 I noted that funds to the tune of UGX. 172,737,949 were"], [null, "irregularly diverted from the activities on which they were"], [null, "budgeted and spent on other activities without seeking and"], [null, "obtaining the necessary approvals."], [null, ""], [null, "\uf0b7 I noted that construction works for Budhaya Seed secondary"], [null, "school did not take off"], [null, ""], [null, "\uf0b7 Underfunding worth UGX 24,751,000 was noted for URF meant"], [null, "for road maintenance"], [null, ""], [null, "\uf0b7 I noted that the District lacked land titles for 16 pieces of land"], [null, "measuring approximately 106.7 acres including schools, sub"], [null, "counties and health centers."], [null, ""], [null, "\uf0b7 Bugiri district received a sum of UGX. 204,224,148 for (08)"], [null, "secondary schools and (140) primary schools meant for the"], [null, "procurement of learning materials. I noted that (47) schools had"], [null, "irregularly utilized the funds totaling to UGX. 50,639,930 without"], [null, "proper guidance, (58) schools had not utilized the funds, while"], [null, "bank statements as at end of October 2021 for (43) schools were"], [null, "not presented to enable establishment of whether the funds had"], [null, "been utilized without proper guidance or not."], ["15\\. Njeru MC Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the Municipal pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.0.31Bn; Under and overpayment of salaries worth UGX. 8,321,986 and UGX. 31,890,939 respectively; under payments of pensions worth UGX. 4,693,227; paid 12 staff a total of UGX. 13,933,412 off the IPPS; the Municipal Council did not prepare monthly wage, pension and gratuity performance analysis for submission to MoPS and Paid UGX. 6,413,424 to 05 staff who were no longer in service \uf0b7 Additionally, I noted that 18 newly recruited/ transferred employees and 08 pensioners delayed to access the pension", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 347, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "335", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 347, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["payroll and 01 pensioner had never accessed the payroll; 15 employees were paid a total of UGX. 16,677,139 without signed pay change reports; over and under payment of thirteen (13) pensioners worth UGX. 34,733,352 and UGX. 24,197,298 respectively arising from wrong computation of gratuity benefits \uf0b7 The municipality paid 322 employees using the wrong bands, leading to monthly over payments of UGX. 7,147,390 and under payments of UGX. 2,837,275 \uf0b7 The Municipal Council made unauthorized loan deductions totaling UGX. 14,734,700 from 19 employees that lacked evidence of signing letters of undertaking \uf0b7 The Municipal Council had outstanding unrecovered funds (receivables) of UGX. 891,306,154 by close of financial year \uf0b7 I noted that the Municipal Council had prepared but had not had the strategic plan approved and aligned to the NDP-III at the time of audit \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 1,815,926,807 that was eventually swept back to consolidated fund account at end of financial year and under performance of revenues worth UGX. 2,234,326,614 \uf0b7 URF underfunding of UGX. 86,246,400 meant for road maintenance was noted \uf0b7 Njeru MC received a sum of UGX. 84,619,384 for (48) primary and secondary schools meant for the procurement of learning materials in March, 2021 and disbursed UGX. 84,619,384 (100%) to (48) schools on 28th June, 2021. However, the various school\u2019s bank statements had not been availed for review at the time of audit \uf0b7 I noted that the Municipal Council did not have land titles for 12 out of 22 pieces of land including schools and health centers", null, null], ["16.", "Iganga DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 348, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", ""], "type": "table"}}, {"content": [["payroll and 01 pensioner had never accessed the payroll; 15 employees were paid a total of UGX. 16,677,139 without signed pay change reports; over and under payment of thirteen (13) pensioners worth UGX. 34,733,352 and UGX. 24,197,298 respectively arising from wrong computation of gratuity benefits \uf0b7 The municipality paid 322 employees using the wrong bands, leading to monthly over payments of UGX. 7,147,390 and under payments of UGX. 2,837,275 \uf0b7 The Municipal Council made unauthorized loan deductions totaling UGX. 14,734,700 from 19 employees that lacked evidence of signing letters of undertaking \uf0b7 The Municipal Council had outstanding unrecovered funds (receivables) of UGX. 891,306,154 by close of financial year \uf0b7 I noted that the Municipal Council had prepared but had not had the strategic plan approved and aligned to the NDP-III at the time of audit \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 1,815,926,807 that was eventually swept back to consolidated fund account at end of financial year and under performance of revenues worth UGX. 2,234,326,614 \uf0b7 URF underfunding of UGX. 86,246,400 meant for road maintenance was noted \uf0b7 Njeru MC received a sum of UGX. 84,619,384 for (48) primary and secondary schools meant for the procurement of learning materials in March, 2021 and disbursed UGX. 84,619,384 (100%) to (48) schools on 28th June, 2021. However, the various school\u2019s bank statements had not been availed for review at the time of audit \uf0b7 I noted that the Municipal Council did not have land titles for 12 out of 22 pieces of land including schools and health centers", null, null], ["16.", "Iganga DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.1.07Bn;"], [null, "Unqualified", "under payment of salaries worth UGX. 32,546,140; non-"], [null, "", "payments of pensioners worth UGX. 80,485,339; paid 16 staff"], [null, null, "using wrong bands, leading to monthly over payments of UGX."], [null, null, "287,429 and under payments of UGX. 526,840; paid UGX."], [null, null, "4,349,175 to 07 staff who had retired, transferred or absconded;"], [null, null, "over and under remittance of salary deductions worth UGX."], [null, null, "7,428,040 and UGX. 42,133,941 respectively"], [null, null, ""], [null, null, "\uf0b7 Additionally, I noted that there was Un-deducted PAYE from"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 348, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", ""], "type": "table"}}, {"content": "336", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 348, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "political leaders\u2019 gratuity resulting in unpaid tax of"], [null, "UGX.10,059,827; 32 pensioners delayed to access the pension"], [null, "payroll and 19 pensioners had never accessed the payroll and"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 349, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", ""], "type": "table"}}, {"content": [["", "political leaders\u2019 gratuity resulting in unpaid tax of"], [null, "UGX.10,059,827; 32 pensioners delayed to access the pension"], [null, "payroll and 19 pensioners had never accessed the payroll and"], [null, "therefore not paid; 55 employees were paid a total of UGX. 30"], [null, "million without signed pay change reports and 73 employees and"], [null, "34 pensioners were paid a total of UGX. 1,166,247,120 off the"], [null, "IPPS"], [null, ""], [null, "\uf0b7 The district had outstanding unrecovered funds (receivables) of"], [null, "UGX. 1,705,945,185 by the end of the period"], [null, ""], [null, "\uf0b7 I noted that the district was engrossed in a number of court"], [null, "cases estimated at UGX. 3,832,685,041"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; Failure to quantify outputs; partial and"], [null, "non-implementation of planned activities delayed submission of"], [null, "performance reports; under absorption of funds worth UGX."], [null, "2,137,465,419 that was eventually swept back to consolidated"], [null, "fund account at end of financial year and under performance of"], [null, "revenues worth UGX. 9,278,908,203"], [null, ""], [null, "\uf0b7 I noted that the entity had not prepared and approved a"], [null, "strategic plan that is aligned to the NDP-III"], [null, ""], [null, "\uf0b7 I noted that the District had 04 pieces of land that were not titled"], [null, "as well as 33 pieces of land under its supervision that were also"], [null, "not titled"], [null, ""], [null, "\uf0b7 There was URF underfunding of UGX 57,904,000 meant for road"], [null, "maintenance that affected road roads in the district."], ["17\\. Luuka DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.1.60Bn; under payment of salaries UGX. 33,624,349 \uf0b7 The District had with payments leading to over and over payments of UGX. 188,313272 due to wrong computation; underpayments of UGX. 39,314,543 to 32 pensioners resulting from wrong computation of gratuity benefits; made over and under payments of UGX. 16,741,697 and UGX. 8,347,743 respectively due to use of wrong salary bands \uf0b7 Paid UGX. 21,149,890 to 10 staff, who had retired, transferred, absconded or died; under remitted salary deductions worth UGX. 319,599,269; the District made unauthorized loan deductions totaling UGX. 158,654,625 from 115 employees; Un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 2,659,020 and under payment of pensioners worth UGX. 485,724,648 \uf0b7 Additionally, I noted that 41 newly recruited/ transferred employees and 19 pensioners delayed to access payroll; 47", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 349, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", ""], "type": "table"}}, {"content": "337", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 349, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["employees were paid a total of UGX. 215,642,700 without signed pay change reports; the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS; I noted that 21 staff and 01 pensioner were paid a total of UGX. 37,733,743 off the IPPS \uf0b7 The district mischarged funds worth UGX. 40,695,963 on account codes other than those prescribed for salary, pension and gratuity \uf0b7 I noted the district had outstanding unrecovered receivables of UGX. 885,992,084 by the year end. \uf0b7 I noted that the Council was engrossed in 03 court cases with individuals which could lead to possible loss of funds \uf0b7 I noted that the entity had prepared but not had the strategic plan approved and aligned to the NDP-III at the time of audit \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 652,127,207 that was eventually swept back to consolidated fund account at end of financial year and under performance of revenues worth UGX.673,814,209 \uf0b7 The District commenced construction works on Ikumbya seed secondary school under the Education Sector in the FY 2018/2019. At the time of inspection on 28th October, 2021, I observed that works were still ongoing at 87% progress, with all structures yet to be properly floored, with partial painting, no glasses, no roofing of latrine and the compound yet to be cleared and set \uf0b7 Luuka DLG budgeted for and received UGX. 344,284,000 for the initial stages of the construction of Buwanda Seed Secondary in the FY 2020/2021. However, construction works did not take off in the financial year under review and the funds were swept back to treasury \uf0b7 Luuka DLG received a sum of UGX. 217,156,943 for 89 primary schools and 8 secondary schools meant for the procurement of learning materials on 1st April, 2021 and disbursed UGX. 136,640,827 (63%) to 53 primary schools and 5 secondary schools on 28th June, 2021. UGX. 80,516,116 was not disbursed by the district. However, the respective school bank statement and receipts had not been availed for review at the time of audit, and as such, I could not establish whether the funds were still on the accounts", null, null], ["18.", "Iganga MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 350, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": [["employees were paid a total of UGX. 215,642,700 without signed pay change reports; the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS; I noted that 21 staff and 01 pensioner were paid a total of UGX. 37,733,743 off the IPPS \uf0b7 The district mischarged funds worth UGX. 40,695,963 on account codes other than those prescribed for salary, pension and gratuity \uf0b7 I noted the district had outstanding unrecovered receivables of UGX. 885,992,084 by the year end. \uf0b7 I noted that the Council was engrossed in 03 court cases with individuals which could lead to possible loss of funds \uf0b7 I noted that the entity had prepared but not had the strategic plan approved and aligned to the NDP-III at the time of audit \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 652,127,207 that was eventually swept back to consolidated fund account at end of financial year and under performance of revenues worth UGX.673,814,209 \uf0b7 The District commenced construction works on Ikumbya seed secondary school under the Education Sector in the FY 2018/2019. At the time of inspection on 28th October, 2021, I observed that works were still ongoing at 87% progress, with all structures yet to be properly floored, with partial painting, no glasses, no roofing of latrine and the compound yet to be cleared and set \uf0b7 Luuka DLG budgeted for and received UGX. 344,284,000 for the initial stages of the construction of Buwanda Seed Secondary in the FY 2020/2021. However, construction works did not take off in the financial year under review and the funds were swept back to treasury \uf0b7 Luuka DLG received a sum of UGX. 217,156,943 for 89 primary schools and 8 secondary schools meant for the procurement of learning materials on 1st April, 2021 and disbursed UGX. 136,640,827 (63%) to 53 primary schools and 5 secondary schools on 28th June, 2021. UGX. 80,516,116 was not disbursed by the district. However, the respective school bank statement and receipts had not been availed for review at the time of audit, and as such, I could not establish whether the funds were still on the accounts", null, null], ["18.", "Iganga MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 350, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "338", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 350, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], [null, "Unqualified", "under payment of salaries worth UGX. 119,289,474; irregularly"], [null, "", "paid one staff who had retired UGX. 1,971,915; over remittance"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 351, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], [null, "Unqualified", "under payment of salaries worth UGX. 119,289,474; irregularly"], [null, "", "paid one staff who had retired UGX. 1,971,915; over remittance"], [null, null, "of payroll deductions worth UGX.10,164,672"], [null, null, ""], [null, null, "\uf0b7 Additionally, the Municipal Council did not prepare monthly wage,"], [null, null, "pension and gratuity performance analysis and thus did not"], [null, null, "submit quarterly returns on payroll to MoPS; 22 staff were paid a"], [null, null, "total of UGX. 37,734,317 off the IPPS; 15 employees were paid a"], [null, null, "total of UGX.7.9 million without signed pay change reports; 03"], [null, null, "newly recruited/transferred employees and 6 pensioners delayed"], [null, null, "to access payroll; Un-deducted PAYE from political leaders\u2019"], [null, null, "gratuity resulting in unpaid tax of UGX. 2,607,660"], [null, null, ""], [null, null, "\uf0b7 I noted that the verification forms and copies of the verification"], [null, null, "cards for all employees and pensioners/beneficiaries were not on"], [null, null, "the respective personal files"], [null, null, ""], [null, null, "\uf0b7 The Municipal Council had outstanding receivables of UGX."], [null, null, "1,705,945,185 that had not been recovered by year end."], [null, null, ""], [null, null, "\uf0b7 Municipal Council had outstanding payables of UGX. 650,570,897"], [null, null, "unsettled by year"], [null, null, ""], [null, null, "\uf0b7 I noted that the Municipal Council had not prepared and"], [null, null, "approved a strategic plan that is aligned to the NDP-III at the"], [null, null, "time of audit"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to quantify outputs; partial and"], [null, null, "non-implementation of planned activities delayed submission of"], [null, null, "performance reports; under performance of revenues worth UGX."], [null, null, "801,240,396"], [null, null, ""], [null, null, "\uf0b7 Noted URF underfunding of UGX 24,821,498 that affected road"], [null, null, "maintenance at the Municipality"], [null, null, ""], [null, null, "\uf0b7 Iganga Municipal Council did not have land titles for 15 of the 25"], [null, null, "pieces of land with some land files deemed missing (Bupala"], [null, null, "land)."], ["Branch Kampala Summary of Key Findings", null, null], ["01.", "Buikwe DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Over payment of salary to 7"], [null, "Opinion Unqualified", "staffs worth UGX. 6,542,796; Underpayment of salaries to 24"], [null, null, "employees worth UGX. 20,560,692; payment of salaries worth"], [null, "", "UGX 4,697,808 to two (2) staffs that was no longer in service and irregular deduction of loan instalments worth UGX."], [null, null, "56,120,313 for 23 employees."], [null, "", "\uf0b7 Additionally, I observed that there was delayed access to payroll by ten (10) new employees; un-deducted PAYE from political"], [null, null, "leaders\u2019 gratuity resulting in unpaid tax of UGX. 10,214,875; and"], [null, null, "unpaid pension and gratuity worth UGX. 95,481,460"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 351, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "339", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 351, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds worth"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 352, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds worth"], [null, null, "UGX.1.11Bn that was swept back to consolidated fund account"], [null, null, "and under performance of the releases from government worth"], [null, null, "UGX.2,590,769,685;"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX. 55,352,971 on"], [null, null, "wrong budget lines"], [null, null, ""], [null, null, "\uf0b7 The district had unrecovered funds worth UGX. 597,864,391 from"], [null, null, "YLP and UWEP groups."], [null, null, ""], [null, null, "\uf0b7 I noted off budget funding worth UGX.1,460,725,115 received for"], [null, null, "Result Based Financing (RBF) from the ministry of Finance."], [null, null, ""], [null, null, "\uf0b7 I also noted that the original copy of the title for Plot 18"], [null, null, "Kyaggwe block 564, land at Nansagazi landing site measuring"], [null, null, "7.06 hectares was missing from the safe."], ["02\\. Buvuma DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Over payment of salaries worth UGX. UGX.1,243,832; Underpayment of salaries worth UGX. UGX.1,667,474; Wrong computation of gratuity for four (4) pensioners worth UGX.2,382,045 and UGX.1,325,359 respectively; under remittance of employee\u2019s salary deductions worth UGX.139,719,468; unpaid salaries worth UGX. 0.883 Bn and delayed remittance of deductions to UCLA/UBA worth UGX.224 million \uf0b7 Additionally, I observed that there was delayed access to payroll by twenty (20) new employees and two (2) pensioners; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.18,624,938 and payment of one (1) pensioner worth UGX.10,519,628 off the IPPS. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial implementation of planned activities; under absorption of funds worth UGX. 0.888 Bn; under performance of the releases from other government units worth UGX.1,004,434; delayed submission of quarterly monitoring reports to OPM & MoFPED and late submission of performance reports \uf0b7 The district mischarged expenditure worth UGX.31,344,359 on wrong budget \uf0b7 I noted unrecovered funds of YLP and UWEP worth UGX.426,197,440 and UGX.161,592,376 respectively", null, null], ["03.", "ENTEBBE MC", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the Municipal"], [null, "Opinion", "pension & salary payrolls such as; Over payment of salaries"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 352, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "340", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 352, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Unqualified", "worth UGX.5,237,820; payment of salaries worth UGX.2,734,481"], [null, "", "to three (03) staffs that were no longer in service; over and"], [null, null, "under remittance of salaries worth UGX17,579,629 and"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 353, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", "Unqualified", "worth UGX.5,237,820; payment of salaries worth UGX.2,734,481"], [null, "", "to three (03) staffs that were no longer in service; over and"], [null, null, "under remittance of salaries worth UGX17,579,629 and"], [null, null, "UGX,8,495,808 respectively"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by ten (10) pensioners and un-deducted PAYE from political"], [null, null, "leaders\u2019 gratuity resulting in unpaid tax of UGX,2,607,660"], [null, null, ""], [null, null, "\uf0b7 The MC had outstanding receivables totaling to UGX.1,"], [null, null, "280,357,120 for YLP, UWEP and uncollected local revenue."], [null, null, ""], [null, null, "\uf0b7 Municipal Council outstanding commitments of UGX 170,801,502"], [null, null, "by close of the financial year"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds worth UGX."], [null, null, "5,594,339,871; under performance of the donor worth UGX"], [null, null, "80,040,000 & shortfalls in local revenue worth"], [null, null, "UGX.3,507,045,896;"], [null, null, ""], [null, null, "\uf0b7 I noted that there was an over commitment by the Municipal"], [null, null, "council of funds worth UGX. 6,503,237,230 under the USMID"], [null, null, "project through and agreement signed with M/s China Wu Yi Co."], [null, null, "Ltd on the 21 st April 2021."], [null, null, ""], ["04\\. Luwero DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salary worth UGX.150 million; unpaid salaries worth UGX.1.254 Bn and under/over remittance of employee salaries worth UGX.165,627,734 and UGX.37,026,373 respectively \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit. \uf0b7 Additionally, I observed that there was delayed access to payroll by thirty-eight (38) new/transferred employees and twenty- two (22) pensioners and un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.15,523,074 \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under performance worth UGX. 1,317,898,459; incomplete works at Katikamu Seed Secondary School and under absorption of funds worth UGX.1.256 Bn \uf0b7 The district received off-budget financing worth UGX.1,002,619,377 directly from Ministry of Health under Result Based Financing Programme (RBF) \uf0b7 The district mischarged expenditure worth UGX.8,575,441 on wrong budget lines. \uf0b7", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 353, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "341", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 353, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["05.", "MITYANA DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Over payment of salaries"], [null, "Opinion Unqualified", "worth UGX.2,992,554; Wrong computation of gratuity worth net"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 354, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["05.", "MITYANA DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Over payment of salaries"], [null, "Opinion Unqualified", "worth UGX.2,992,554; Wrong computation of gratuity worth net"], [null, null, "overpayment of UGX. 2,271,141; payment of salaries worth"], [null, null, "UGX.4,057,892 to ten (10) staffs that were no longer in service;"], [null, null, "irregular deduction of loan instalments for three (3) staff worth"], [null, null, "UGX. 1,085,168; over and under remittance of employees\u2019"], [null, null, "salaries worth UGX. 9,347,419 and UGX.52,480,527 respectively"], [null, null, "and payroll deductions to UCLA/UBA worth UGX. 10,193,805"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by thirty (30) new employees and sixteen (16) pensioners; un-"], [null, null, "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid"], [null, null, "tax of UGX. 12,460, 278 and unremitted PAYE worth"], [null, null, "UGX.41,763,487"], [null, null, ""], [null, null, "\uf0b7 Failure to remit local government revenue worth UGX.49,502,388"], [null, null, "to LLGs"], [null, null, ""], [null, null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 I noted issues such as incomplete works and under absorption of"], [null, null, "funds worth UGX.0.7 Bn in the implementation of the approved"], [null, null, "budget."], [null, null, ""], [null, null, "\uf0b7 The district lacked a title of land where the health Centre is being"], [null, null, "constructed."], [null, null, ""], ["06\\. Mukono DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of pensioners/employees worth UGX2,503,100 and UGX. 5,442,660 respectively. Underpayment worth UGX. 4,860,118; payment of salaries worth UGX.6,175,829 to nine (9) staffs that was no longer in service and irregular deduction of loan instalments for five (5) staff worth 3,165,094 \uf0b7 Additionally, I observed that there was delayed access to payroll by fourteen (14) new employees and fourteen (14) pensioners; failure to utilize wage funds of UGX.0.1 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 12,104,504 and payment of five (5) staffs and three (3) pensioners worth UGX.9,195,665 off the IPPS; over/ under remittance of employee\u2019s salary deductions worth UGX. 2,345,800 and UGX. 97,808,530 respectively. \uf0b7 I noted that 14 employees were paid a total of UGX. 2,875,407 without signed pay change reports. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete works at Mukono General", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 354, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "342", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 354, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Hospital and Kimenyedde Seed Secondary School; under absorption of funds worth UGX.0.4bn that was swept back to consolidated fund account and under performance worth UGX.1, 909251149;", null, null], ["07.", "MUKONO MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 355, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["Hospital and Kimenyedde Seed Secondary School; under absorption of funds worth UGX.0.4bn that was swept back to consolidated fund account and under performance worth UGX.1, 909251149;", null, null], ["07.", "MUKONO MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, payment of salaries worth UGX 11.1M to nine"], [null, "Unqualified", "(9) staffs that was no longer in service and unpaid pension worth"], [null, "", "UGX.106.9M"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by four (4) new employees and seven (7) pensioners; un-"], [null, null, "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid"], [null, null, "tax of UGX 2.6M and payment of fifty-four (54) staffs and one"], [null, null, "(1) pensioner worth UGX 60.5M off the IPPS"], [null, null, ""], [null, null, "\uf0b7 The Municipal Council did not have an approved strategic plan"], [null, null, "that is aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 I noted an issue of under performance of the releases from other"], [null, null, "government units worth UGX.2,529,600,000; in the"], [null, null, "implementation of the approved budget"], ["08\\. Nakaseke DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit pension and gratuity estimates to MoPs, Underpayment of pension/gratuity worth UGX.104,392,407; irregular deduction of loan instalments of seven (7) employees worth UGX.7, 853,306; unpaid pension and gratuity worth UGX.77, 373,425; over and under remittance of employee salaries deductions worth UGX.51, 659,500 and UGX.3, 303,310 respectively and unpaid pension arrears worth UGX.245,882,164 \uf0b7 The district had outstanding Payables worth UGX.467,701,993 and Receivables worth UGX.1,660,675,633 by close of financial year \uf0b7 Additionally, I observed that there was delayed access to payroll by twenty-two (22) employees and twenty-five (25) pensioners; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of 14, 265,549 and payment of two (2) pensioners worth UGX.6,199,129 and 1 staff worth UGX.26,750,870 off the IPPS \uf0b7 I noted that Butalangu HCIII lacked laboratory, th\u00e9\u00e2tre and maternity ward equipment \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works on roads- Kinyogoga- Kyabalongo- Kitindo 18.0Km and Kalagala- Kyamaweno- Kinyogoga 34km; incomplete works at Kalenge HC III and under absorption of funds worth UGX.0.3 billion that was swept back to consolidated fund account.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 355, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "343", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 355, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["09.", "Nakasongola District", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; under payment of pension"], [null, "Opinion Unqualified", "worth UGX. UGX.1,510,120; Underpayment of salary worth"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 356, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["09.", "Nakasongola District", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; under payment of pension"], [null, "Opinion Unqualified", "worth UGX. UGX.1,510,120; Underpayment of salary worth"], [null, null, "UGX.13million; Wrong computation of gratuity worth net"], [null, "", "overpayment of two (2) pensioners worth UGX.20,784,707;"], [null, null, "payment of salaries worth UGX. 23,149,880 to eighteen (18)"], [null, null, "staffs that were no longer in service and irregular deduction of"], [null, null, "loan instalments worth UGX.307,637,65."], [null, null, ""], [null, null, "\uf0b7 Under remittance of salary deductions worth UGX.132,371,427"], [null, null, ""], [null, null, "\uf0b7 I noted that the district made payroll deductions of UGX.16"], [null, null, "million, but did not remit to UCLA/UBA."], [null, null, ""], [null, null, "\uf0b7 I noted outstanding UWEP and YLP advances worth"], [null, null, "UGX.665,481,500 by year end"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by eighteen (18) new employees and thirteen (13) pensioners"], [null, null, "and un-deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX.12,011,160"], [null, null, ""], [null, null, "\uf0b7 The district had outstanding pension and gratuity arrears worth"], [null, null, "UGX.234,272,456 at year end."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; un implemented works at a Seed"], [null, null, "School; under absorption of funds worth UGX.0.6 billion and"], [null, null, "under performance of the releases from other government units"], [null, null, "worth 169 Mn;"], [null, null, "\uf0b7"], ["10\\. Nansana MC Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the Municipal pension & salary payrolls such as; Over payment of salaries/pension worth UGX. 2,494,859 and UGX.24,488,037 respectively; Underpayment of pension worth UGX.11,791,871; and irregular deduction of loan instalments worth UGX.18,027,312. \uf0b7 Un recovered UWEP/YLP funds of UGX.899,208,480 \uf0b7 The Municipal Council did not have an approved strategic plan that is aligned to the NDP-III at the time of audit. \uf0b7 Additionally, I observed that there was delayed access to payroll by three (3) new employees and nineteen (19) pensioners; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 3,122,640 \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works on the road construction; under absorption of funds worth UGX.0.278 billion that was swept back to consolidated fund account and under performance of the releases from other government units worth", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 356, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "344", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 356, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["UGX.534,603,597; \uf0b7 Failure to prepare monthly wage, pension and gratuity performance analysis \uf0b7 The Municipal Council reported receivables balance of UGX.1,780,766,221 \uf0b7 The Municipal Council had outstanding payables of UGX. 87,603,199 by close of the financial year \uf0b7 I noted that UGX.1,131,374,846 (103%) was spent on 2km reflecting over expenditure of UGX.51,408,546. The cost variations in projects planned works affects implementation of other maintenance activities.", null, null], ["11.", "Wakiso District", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as Underpayment of pension"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 357, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["UGX.534,603,597; \uf0b7 Failure to prepare monthly wage, pension and gratuity performance analysis \uf0b7 The Municipal Council reported receivables balance of UGX.1,780,766,221 \uf0b7 The Municipal Council had outstanding payables of UGX. 87,603,199 by close of the financial year \uf0b7 I noted that UGX.1,131,374,846 (103%) was spent on 2km reflecting over expenditure of UGX.51,408,546. The cost variations in projects planned works affects implementation of other maintenance activities.", null, null], ["11.", "Wakiso District", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as Underpayment of pension"], [null, "Opinion", "worth UGX.2, 010,117,938; payment of salaries worth UGX.5,"], [null, "Unqualified", "278,315 to five (5) staffs that was no longer in service; unpaid"], [null, "", "salaries UGX.8, 379,873 and accrued pension worth"], [null, null, "UGX.265,144,965"], [null, null, ""], [null, null, "\uf0b7 The outstanding payables for pension and gratuity worth UGX.2,"], [null, null, "405,604,903"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by seventeen (17) pensioners; failure to utilize wage funds of"], [null, null, "UGX.0.7 Bn; un-deducted PAYE from political leaders\u2019 gratuity"], [null, null, "resulting in unpaid tax of 14, 993,898 and payment eleven (11)"], [null, null, "pensioners worth UGX.303, 639,396 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; shoddy works at Nakitokolo HCIII;"], [null, null, "delayed works at Kasoozo HCIII; incomplete works at Wakiso"], [null, null, "Seed School; under absorption of funds worth"], [null, null, "UGX.1,108,628,816 that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX.6,616,905,830;"], [null, null, ""], ["12\\. KIRA MC Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the Municipal pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salary worth UGX. 12,367,380; Underpayment of salary worth UGX. 1,513,296; Wrong computation of gratuity worth net overpayment of UGX.23,863,854 and payment of salaries worth UGX 9,760,420 to nine (09) staffs that were no longer in service \uf0b7 I noted Over remittance of salary deductions worth UGX. 36,961,624 \uf0b7 I noted outstanding receivables worth of UGX. 3,171,846,861 \uf0b7 Additionally, I observed that there was delayed access to payroll", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 357, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "345", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 357, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["by three (3) new employees and sixteen (16) pensioners; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 3,015,540 and payment worth UGX. 435,546,906 off the IPPS \uf0b7 failure to prepare monthly wage, pension and gratuity performance analysis \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete construction works; under absorption of funds worth UGX.0.16Bn that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.3,402,046,314 and failure to submit quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the Municipal Council received off-budget financing worth UGX135,974,720 for Result Based Financing (RBF) from the Ministry of Health \uf0b7 The district mischarged expenditure worth UGX. 20,821,532 on wrong budget lines.", null, null], ["13.", "MAKINDYE SABAGABO", "\uf0b7 I noted a number of anomalies during review of the municipal"], ["", "MC", "pension & salary payrolls such as, Over payment of salary worth"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 358, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["by three (3) new employees and sixteen (16) pensioners; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 3,015,540 and payment worth UGX. 435,546,906 off the IPPS \uf0b7 failure to prepare monthly wage, pension and gratuity performance analysis \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete construction works; under absorption of funds worth UGX.0.16Bn that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.3,402,046,314 and failure to submit quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the Municipal Council received off-budget financing worth UGX135,974,720 for Result Based Financing (RBF) from the Ministry of Health \uf0b7 The district mischarged expenditure worth UGX. 20,821,532 on wrong budget lines.", null, null], ["13.", "MAKINDYE SABAGABO", "\uf0b7 I noted a number of anomalies during review of the municipal"], ["", "MC", "pension & salary payrolls such as, Over payment of salary worth"], [null, "", "UGX. 8,992,140; Wrong computation of gratuity worth net"], [null, "Opinion Unqualified", "underpayment of UGX. 9,709,876; payment of salaries worth"], [null, null, "UGX 20,892,893 to staffs that was no longer in service and"], [null, "", "irregular deduction of loan instalments worth UGX. 29,407,510."], [null, null, ""], [null, null, "\uf0b7 The Municipal Council reported payables worth UGX.532,235,004"], [null, null, "at end the financial year"], [null, null, ""], [null, null, "\uf0b7 The Municipal Council reported receivables worth"], [null, null, "UGX.750,391,890"], [null, null, ""], [null, null, "\uf0b7 The Municipal Council did not have an approved strategic plan"], [null, null, "that is aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by four (4) new employees and four (4) pensioners and un-"], [null, null, "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid"], [null, null, "tax of UGX.3,015,540"], [null, null, ""], [null, null, "\uf0b7 Un recovered UWEP/YLP funds worth UGX.459,332,075"], [null, null, ""], [null, null, "\uf0b7 I noted issues in the implementation of the approved budget"], [null, null, "such as; incomplete works on Mutundwe-Kisugula-Bunamwaya"], [null, null, "road; under absorption of funds worth UGX. 0.421 billion. and"], [null, null, "under performance of the releases from other government units"], [null, null, "worth UGX.6,801,993,716"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX. 304,575,692 on"], [null, null, "wrong budget lines."]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 358, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "346", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 358, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, ""], [null, null, "\uf0b7 A total of 19.1km at an estimated cost of UGX.70, 200,000 was"], [null, null, "planned to be undertaken. The audit revealed that 19.1 km were"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 359, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", null, ""], [null, null, "\uf0b7 A total of 19.1km at an estimated cost of UGX.70, 200,000 was"], [null, null, "planned to be undertaken. The audit revealed that 19.1 km were"], [null, null, "actually undertaken at a cost of UGX.152, 254,000 leading to an"], [null, null, "over expenditure of UGX. 82,054,000."], [null, null, ""], [null, null, "\uf0b7 I noted unrecovered funds from groups worth UGX.459,332,075"], ["Masaka Branch \uf0b7 Summary of Key Findings", null, null], ["01.", "Bukomansimbi DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, Underpayment of salary worth"], [null, "Unqualified", "UGX.13,134,104; payment of salaries worth UGX.5,195,665 to"], [null, "", "one (1) staff that was no longer in service; unpaid salary worth"], [null, null, "UGX.20,579,078; under payments of 5 pensioners worth"], [null, null, "UGX.1,133,789; under remittance of payroll deduction worth"], [null, null, "UGX.185,012,274; Amount worth UGX.10,081,159 wasn\u2019t"], [null, null, "remitted to UCLA/UBA and amount worth UGX.175,148,725 had"], [null, null, "not been remitted to URA"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by Sixteen (16) newly recruited/ transferred employees and Ten"], [null, null, "(10) pensioners; un-deducted PAYE from political leaders\u2019"], [null, null, "gratuity worth UGX.33,045,600, leading to an under deduction"], [null, null, "worth UGX.26,510,404 and payment of twenty (20) staffs worth"], [null, null, "UGX.4, 725,034 off the IPPS."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had prepared a strategic plan but the"], [null, null, "National Planning Authority had not yet approved it at the time of"], [null, null, "audit."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; the shortfalls in local revenue"], [null, null, "collections of UGX 9,848,129; Donor financing worth UGX."], [null, null, "759,350,373; under absorption of funds worth UGX.340,000,000"], [null, null, "that was swept back to consolidated fund account; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, "and Shoddy works in construction of classroom blocks"], [null, null, ""], [null, null, "\uf0b7 The district lacked land title for land on which Bukango Seed"], [null, null, "Secondary School is situated."], [null, null, ""], ["02\\. Kalangala DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district payroll such as; an unabsorbed balance of UGX 1.08 billion; an Over payment of salaries worth UGX 1,265,254, Underpayment of salaries of UGX.37, 719,627; Payment of salaries worth UGX. 1,480,155 to one (1) staff who had retired; under remittance of salary deductions worth UGX. 73,649,208 from employees\u2019 salaries; Deductions worth UGX. 100,753,524 relating to 57 employees without letters of under taking; unremitted deduction to UCLA/UBA worth UGX.2, 210, 654. \uf0b7 Additionally, I observed that the district did not remit deductions worth UGX.51,366,809 to URA; un-deducted PAYE from political", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 359, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "347", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 359, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["leaders\u2019 gratuity worth UGX.51,416,102, leading to an under deduction worth UGX UGX.11,323,785; Delays in accessing pay roll and pension payroll; payment of salaries worth UGX.14,222,733 to Nine (9) staffs who were off IPPS; \uf0b7 I noted that the entity had not prepared and approved its strategic plan by NPA and thus could not confirm if the plan is aligned to NDP 111 \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under performance of revenues worth UGX.867,111,016 and under absorption of funds worth UGX.675,040,597 that was swept back to consolidated fund account at the year end. \uf0b7 Mischarged funds worth UGX.357,586,292 on inappropriate budget codes", null, null], ["03.", "Kyotera DLG", "\uf0b7 I noted a number of anomalies during review of Kyotera district"], ["", "", "payroll such as; Failure to submit wage estimates to MoPs;"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 360, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["leaders\u2019 gratuity worth UGX.51,416,102, leading to an under deduction worth UGX UGX.11,323,785; Delays in accessing pay roll and pension payroll; payment of salaries worth UGX.14,222,733 to Nine (9) staffs who were off IPPS; \uf0b7 I noted that the entity had not prepared and approved its strategic plan by NPA and thus could not confirm if the plan is aligned to NDP 111 \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under performance of revenues worth UGX.867,111,016 and under absorption of funds worth UGX.675,040,597 that was swept back to consolidated fund account at the year end. \uf0b7 Mischarged funds worth UGX.357,586,292 on inappropriate budget codes", null, null], ["03.", "Kyotera DLG", "\uf0b7 I noted a number of anomalies during review of Kyotera district"], ["", "", "payroll such as; Failure to submit wage estimates to MoPs;"], [null, "Opinion Unqualified", "unabsorbed wage fund balance of UGX. 0.32 billion; Over"], [null, null, "payment of salaries worth UGX.29, 467,392; Unauthorized loan"], [null, "", "deductions worth UGX.148 million from 100 employees with no"], [null, null, "undertaking letters; un-deducted PAYE from political leaders\u2019"], [null, null, "gratuity worth UGX 57,855,806, leading to an under deduction"], [null, null, "worth UGX.13, 730,838."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there were delays in accessing"], [null, null, "salary and pension payroll; Failed to prepare monthly wage,"], [null, null, "pension and gratuity performance analysis for submission to"], [null, null, "MoPS and Payment of salaries worth UGX.7, 166,620 to Three"], [null, null, "(3) staffs who were off the IPPS."], [null, null, ""], [null, null, "\uf0b7 The district mischarged UGX.4, 876,514 on inappropriate budget"], [null, null, "codes other than those budget for"], [null, null, ""], [null, null, "\uf0b7 I noted that the district had prepared a draft strategic plan"], [null, null, "pending approval by NPA at the time of audit;"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to quantify outputs; partial and"], [null, null, "non-implementation of planned activities delayed submission of"], [null, null, "performance reports; delay commencement of work by"], [null, null, "contractor under the UGIFT program; under performance of"], [null, null, "revenues worth UGX.725,450,031 and under absorption of"], [null, null, "UGX.993, 780,260"], [null, null, ""], [null, null, "\uf0b7 Received off budget financing worth UGX.319,540,631 from"], [null, null, "Ministry of Health (MOH)"], [null, null, ""], [null, null, "\uf0b7 Not secured ownership of the land where the seed school and"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 360, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "348", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 360, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "health Center are being constructed"], [null, null, ""], ["04\\. Lwengo DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district payroll such as; Delay to submit wage estimates to MoPs; An unabsorbed wage funds worth UGX.1.5 billion; an under payment of salaries worth UGX 8,075,359; Accrued Pensions worth UGX.90,656,783 not yet paid; Over payment of gratuity worth UGX. 11,742,937 and under payment of gratuity amounting to UGX. 15,885,858; Payment of salaries worth UGX. 8,620,432 to Eighteen (18) staffs who had retired. \uf0b7 Additionally, I noted unauthorized loan deduction worth UGX.8 million to International Medical Link (IML); un-deducted PAYE from political leaders\u2019 gratuity worth UGX.87,948,356, leading to an under deduction worth UGX.12,070,409; Delays in accessing pay roll and pension payroll. \uf0b7 I noted that the entity had prepared a strategic plan which had not yet been approved by NPA in respect to alignment to the NDP-III; \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under performance of revenues worth UGX. UGX.541,868,161 and under absorption of UGX.1,952,031,565 \uf0b7 Received off budget financing worth UGX.223,549,580 from Ministry of Health without informing the PSST", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 361, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", null, "health Center are being constructed"], [null, null, ""], ["04\\. Lwengo DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district payroll such as; Delay to submit wage estimates to MoPs; An unabsorbed wage funds worth UGX.1.5 billion; an under payment of salaries worth UGX 8,075,359; Accrued Pensions worth UGX.90,656,783 not yet paid; Over payment of gratuity worth UGX. 11,742,937 and under payment of gratuity amounting to UGX. 15,885,858; Payment of salaries worth UGX. 8,620,432 to Eighteen (18) staffs who had retired. \uf0b7 Additionally, I noted unauthorized loan deduction worth UGX.8 million to International Medical Link (IML); un-deducted PAYE from political leaders\u2019 gratuity worth UGX.87,948,356, leading to an under deduction worth UGX.12,070,409; Delays in accessing pay roll and pension payroll. \uf0b7 I noted that the entity had prepared a strategic plan which had not yet been approved by NPA in respect to alignment to the NDP-III; \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under performance of revenues worth UGX. UGX.541,868,161 and under absorption of UGX.1,952,031,565 \uf0b7 Received off budget financing worth UGX.223,549,580 from Ministry of Health without informing the PSST", null, null], ["05.", "Masaka", "\uf0b7 I noted that Masaka District submitted wage estimates to MoPs"], ["", "DLG", "on 30th March 2020, which was a delay of 182 days; an"], [null, "", "unabsorbed balance of UGX 0.85 billion; under payment of UGX"], [null, "Opinion Unqualified", "of salaries worth 58,950,820; under payment pension worth UGX"], [null, null, "198,728,097 and unpaid pension of UGX 53,041,554; The District"], [null, null, "wrongly computed the gratuity benefit of 21"], [null, null, "pensioner/beneficiary leading to over payment of UGX 1,431,442"], [null, null, "and under payment of UGX 37,726,688; UGX. 82,631,676 was"], [null, null, "paid to 38 staff who had retired, transferred, absconded or died;"], [null, null, "an over and under remittance amounting to UGX. 14,013,953"], [null, null, "and UGX. 12,619,869 of payroll deduction."], [null, null, ""], [null, null, "\uf0b7 Additionally, the District made payroll loan deductions of UGX.1,"], [null, null, "064,546,679, but did not remit UGX.10, 874,315 to UCLA/UBA;"], [null, null, "under deduction of PAYE worth UGX. 8,988,018 from payments"], [null, null, "to political leaders; noted that 30 newly recruited/ transferred"], [null, null, "employees and 41 pensioners delayed to access payroll; I noted"], [null, null, "that 24 employees were paid a total of UGX. 263,080,952"], [null, null, "without signed pay change reports; 07 staffs and 19 pensioners"], [null, null, "were paid a total of UGX.20, 688,721 and UGX.85, 258,552"], [null, null, "respectively off the IPPS."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 361, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "349", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 361, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 The district mischarged funds worth UGX. 15,255,772 on account"], [null, null, "codes other than those prescribed for either salary, pension or"], [null, null, "gratuity"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 362, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", null, "\uf0b7 The district mischarged funds worth UGX. 15,255,772 on account"], [null, null, "codes other than those prescribed for either salary, pension or"], [null, null, "gratuity"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had had not prepared and approved the"], [null, null, "strategic plan at the time of audit;"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to quantify outputs; partial and"], [null, null, "non-implementation of planned activities delayed submission of"], [null, null, "performance reports; under performance of revenues worth UGX."], [null, null, "11,296,979,720 and under absorption of UGX. 1,258,107,623;"], [null, null, "Incomplete works at Bukakata seed Secondary School"], [null, null, ""], ["06\\. Sembabule DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; an unabsorbed balance of UGX.0.73billion; an under payment of salaries worth UGX.9, 696,016; Delays in accessing pension payroll; Failure to prepare monthly wage, pension and gratuity performance analysis; 72 staffs and 14 pensioners were paid a total of UGX.76,444,546 off the IPPS. \uf0b7 I noted that the management had prepared a strategic plan which had not yet been approved by NPA to confirm its alignment with NDP-III; \uf0b7 underperformance 275,905,089; under absorption of funds worth UGX.1,229,179,117; Partial Implantation of One (1) output with a total of two (2) activities worth UGX.0.89Bn; Late submission of performance reports; \uf0b7 I noted underfunding from URF for road maintenance worth UGX.27,517,358 that affected implementation of planned activities", null, null], ["07.", "Lyantonde DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, Underpayment of pension worth"], [null, "Unqualified", "UGX.27,094,530; Overpayment of Salary worth UGX.29,716,471;"], [null, "", "an unabsorbed balance of UGX.0.26 billion that was subsequently"], [null, null, "swept back to the consolidated fund account and wrong"], [null, null, "computation of gratuity benefit for four (04) pensioner worth net"], [null, null, "overpayment of UGX.4,437,740"], [null, null, ""], [null, null, "\uf0b7 Further, the district made payment of salaries worth"], [null, null, "UGX.3,279,528 to four (4) staffs that who had either retired,"], [null, null, "transferred, absconded or died; an over and over remittance of"], [null, null, "payroll deductions worth UGX.6,685,000 and UGX.8,713,886"], [null, null, "respectively; made unauthorized loan deductions worth"], [null, null, "UGX.736,802,204 from 400 employees that never had letters of"], [null, null, "undertaking"], [null, null, ""], [null, null, "\uf0b7 Additionally, Tax deductions worth UGX.7,073,772 had not been"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 362, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "350", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 362, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "remitted to URA; un-deducted PAYE from political leaders\u2019"], [null, "gratuity resulting in unpaid tax of A UGX.8,109,728; Twenty-"], [null, "Seven (27) employees recruited did not access the payroll and"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 363, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", "remitted to URA; un-deducted PAYE from political leaders\u2019"], [null, "gratuity resulting in unpaid tax of A UGX.8,109,728; Twenty-"], [null, "Seven (27) employees recruited did not access the payroll and"], [null, "delays in accessing payroll and pension payroll."], [null, ""], [null, "\uf0b7 The district mischarged funds worth UGX.5,870,000 on account"], [null, "code other than those prescribed salary, pension and gratuity;"], [null, ""], [null, "\uf0b7 The District paid Seventeen (17) employees worth UGX.22,"], [null, "846,471 without signed pay change reports; failed to prepare"], [null, "monthly wage, pension and gratuity performance analysis and"], [null, "salaries payment worth UGX.85, 678,850 was paid to Seven (7)"], [null, "staffs off the IPPS."], [null, ""], [null, "\uf0b7 I noted that the entity had prepared its strategic plan but it was"], [null, "not yet approved by NPA"], [null, ""], [null, "\uf0b7 Under performance worth; under absorption worth; Late"], [null, "submission of Reports;"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; Failure to quantify outputs; partial and"], [null, "non-implementation of planned activities delayed submission of"], [null, "performance reports; under performance of revenues worth UGX."], [null, "68,650,450 and under absorption of UGX.773,177,804"], [null, ""], ["08\\. Kassanda DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, an unabsorbed balance of UGX.0.20 billion; unpaid accrued pensions worth UGX.89,374,764;Payment of salaries worth UGX.29,042,083 to Eighteen (18) staffs who had either retired, transferred, absconded or died; an over and under remittance of deductions worth UGX.80,614,103 and UGX.11,056,051 respectively; made unauthorized loan deductions worth UGX.684,121,646 from 271 employees that neither had letters of undertaking nor letters of consent. \uf0b7 Additionally, I observed a deduction of worth UGX.31,937,764 from 26 employees who were not in approval and deduction report and a deductions of UGX.63,539,341 from 51 employees who were not in active deduction report but were in approval report; 15 employees had irregular loan end dates; Delays in accessing payroll and pension payroll; Payment of Sixteen (16) staffs and Six (06) pensioners worth UGX.205,954,862 off the IPPS; and payments worth UGX.47,984,473 off the payroll to 33 employees. \uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit; \uf0b7 I noted a number issues in the budget performance such as", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 363, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "351", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 363, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Underperformance of funds worth UGX.243,523,703; Under absorption of funds worth UGX.744,143,791; Failure to quantify outputs; partial and non-implementation and late submission of performance reports.", null, null], ["09.", "Mubende DLG", "\uf0b7 I noted that the District delayed to submit wage estimates to"], ["", "", "MoPs; An under absorption worth UGX.1.36 Billion and was"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 364, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["Underperformance of funds worth UGX.243,523,703; Under absorption of funds worth UGX.744,143,791; Failure to quantify outputs; partial and non-implementation and late submission of performance reports.", null, null], ["09.", "Mubende DLG", "\uf0b7 I noted that the District delayed to submit wage estimates to"], ["", "", "MoPs; An under absorption worth UGX.1.36 Billion and was"], [null, "Opinion", "subsequently swept back to the consolidated fund account;"], [null, "Unqualified", "unpaid salaries worth UGX.9,974,064; Over payment of one (1)"], [null, "", "pensioner worth UGX.2,420,407; Unpaid salaries & pension worth"], [null, null, "UGX.163,350,521; Under payments worth UGX.765,835 to"], [null, null, "Twenty (20) staffs using wrong salary scale; Payment of salaries"], [null, null, "worth UGX.17,448,575 to Fourteen (14) staffs who had either"], [null, null, "retired, transferred, absconded or died;"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed an under remittance of salary deduction"], [null, null, "worth UGX.246,546,709; Made unauthorized loan deductions"], [null, null, "worth UGX.123,209,904 from 30 employees that neither had"], [null, null, "letters of undertaking nor evidence of consent; Delays in"], [null, null, "accessing payroll and pension payroll; Residual Arrear payments"], [null, null, "worth UGX.380,760,596 paid to 17 staffs who were not part of"], [null, null, "MOFPED approved schedule; Unpaid pension to Six (6)"], [null, null, "pensioners worth UGX.118,064,322; Failed to prepare monthly"], [null, null, "wage, pension and gratuity performance analysis for submission"], [null, null, "to MoPS; Payment of Five (5) staffs worth UGX.4,831,538 off the"], [null, null, "IPPS;"], [null, null, ""], [null, null, "\uf0b7 I noted that the district had prepared its strategic plan but had"], [null, null, "not had its plan approved by NPA at the time of audit;"], [null, null, ""], [null, null, "\uf0b7 I noted a number issues in the budget performance such as"], [null, null, "Underperformance of funds worth UGX.117,978,419; Under"], [null, null, "absorption of funds worth UGX.1,625,514,838; Failure to quantify"], [null, null, "outputs; partial and non-implementation and late submission of"], [null, null, "performance reports."], ["10. Gomba Opinion Unqualified \uf0b7 I noted that the District delayed to submit wage estimates to MoPS; an unabsorbed balance of UGX.0.8 billion; over payment of UGX.649, 200 to Mujabi James; an under payment of UGX.1, 764,651; Unpaid salaries worth UGX.1, 176,393; noted that the District had an outstanding Accrual worth UGX.17, 271,309 at the end of the year; the District made unauthorized loan deductions worth UGX.7, 592,724 from 4 employees that neither had letters of undertaking nor existed in the reports. \uf0b7 Additionally, I observed delays in accessing payroll and pension payroll; I noted that five (05) ineligible persons accessed the payroll using forged Education Service Commission (ESC) minutes; Twenty Seven (27) staffs were paid worth UGX.31, 972,130 off the IPPS. \uf0b7 I noted that the entity had not had the strategic plan approved at the time of audit \uf0b7 I noted a number of issues in the implementation of budget such", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 364, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "352", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 364, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["as; Underperformance worth UGX.113,179,395; under absorption of funds worth UGX.1,088,912,187 that was subsequently swept back to the consolidated fund account; Late submission of reports.", null, null], ["", "Hoima Branch", "Summary of Key Findings"], ["01 Buliisa DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salary worth UGX.516,940 to one (1) employee; payment of salaries worth UGX.962,591 to two (2) staffs that was no longer in service; unauthorized loan deductions worth UGX.19,720,463 from 20 employees and net under payment of payroll deductions worth UGX.218,852,589 \uf0b7 Additionally, I observed that there was delayed access to payroll by twelve (12) new employees and three (3) pensioners; failure to utilize wage funds of UGX.1.39Bn; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.8,971,020 and payment of worth UGX.1,646,800 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs that affected measurement of performance, partial or non- implementation of planned activities, late submission of quarterly reports; under absorption of funds worth UGX.721,028,206 that was swept back to consolidated fund account; under performance of the donor & releases from the government worth UGX.1,359,130,302 \uf0b7 I noted that the district had prepared and submitted the Strategic plan to NPA but was still pending approval. \uf0b7 In regards to Covid-19 funds, I noted that out of the total receipts of UGX.81, 933,334, the district absorbed UGX.81, 933,334, representing absorption level of 100%. Additionally, I noted that the distribution of many of non-cash items delayed.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 365, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["as; Underperformance worth UGX.113,179,395; under absorption of funds worth UGX.1,088,912,187 that was subsequently swept back to the consolidated fund account; Late submission of reports.", null, null], ["", "Hoima Branch", "Summary of Key Findings"], ["01 Buliisa DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salary worth UGX.516,940 to one (1) employee; payment of salaries worth UGX.962,591 to two (2) staffs that was no longer in service; unauthorized loan deductions worth UGX.19,720,463 from 20 employees and net under payment of payroll deductions worth UGX.218,852,589 \uf0b7 Additionally, I observed that there was delayed access to payroll by twelve (12) new employees and three (3) pensioners; failure to utilize wage funds of UGX.1.39Bn; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.8,971,020 and payment of worth UGX.1,646,800 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs that affected measurement of performance, partial or non- implementation of planned activities, late submission of quarterly reports; under absorption of funds worth UGX.721,028,206 that was swept back to consolidated fund account; under performance of the donor & releases from the government worth UGX.1,359,130,302 \uf0b7 I noted that the district had prepared and submitted the Strategic plan to NPA but was still pending approval. \uf0b7 In regards to Covid-19 funds, I noted that out of the total receipts of UGX.81, 933,334, the district absorbed UGX.81, 933,334, representing absorption level of 100%. Additionally, I noted that the distribution of many of non-cash items delayed.", null, null], ["02.", "Hoima MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs, Over payment of salary worth UGX"], [null, null, "UGX.7,453,884 to (3) staffs; under payment of funds worth"], [null, "", "UGX.29,604,189 and unauthorized loan deductions worth"], [null, null, "UGX.37,990,205 from 35 employees"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to"], [null, null, "payroll by seven (7) new employees and ten (10) pensioners;"], [null, null, "failure to utilize wage funds of UGX.0.28Bn; un-deducted PAYE"], [null, null, "from political leaders\u2019 gratuity resulting in unpaid tax of"], [null, null, "UGX.12,771,000 and payment of two (2) staffs & seven(7)"], [null, null, "pensioners a total of UGX.368,827,383 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 365, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "353", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 365, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "approved budget such as; Failure to quantify outputs that"], [null, "affected measurement of performance, partial or non-"], [null, "implementation of planned activities; Incomplete road works"], [null, "under absorption of funds worth UGX.29,660,979,614 that was"], [null, "swept back to consolidated fund account; under performance"], [null, "of the donor & releases from the government worth"], [null, "UGX.2,515,468,499"], [null, ""], [null, "\uf0b7 The district mischarged expenditure worth UGX.45, 235,346 on"], [null, "wrong budget lines."], [null, ""], [null, "\uf0b7 I noted that UGX.5,060,453 was paid as residual salary arrears"], [null, "to 5 employees who had not missed salaries in the previous"], [null, "financial year(s)"], [null, ""], [null, "\uf0b7 Payment of funds worth UGX.33,792,884 without authorization"], [null, "of the pay change reports"], [null, ""], [null, "\uf0b7 I noted that the entity\u2019s strategic plan was still in draft form"], [null, "and not approved to confirm that is aligned to the NDP-III at"], [null, "the time of audit."], [null, ""], [null, "\uf0b7 UGX.19,240,000 remained unaccounted for at the close of the"], [null, "financial year"], [null, ""], ["03\\. Hoima DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, over payment of salary worth UGX. 1,380,792 to staffs; under payment of funds worth UGX.; payment of salaries worth UGX.27,668,323 were paid to twenty (20) staffs and eleven (11) pensioners were paid a total of UGX.251,898,925 off the IPPS that was no longer in service unauthorized loan deductions worth UGX.721,600,940 from 432 employees \uf0b7 Additionally, I observed that there was delayed access to payroll by ten (10) new employees and eleven (11) pensioners; failure to utilize wage funds of UGX 16.16Bn; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.7,763,400 \uf0b7 The district mischarged expenditure worth UGX.180, 754,659 on wrong budget lines. \uf0b7 I noted that the verification forms and copies of the verification cards for 126 employees and 43 pensioners were not on the respective personal files \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial implementation of planned activities; partially implemented ; late submission of quarterly reports; under absorption of funds worth UGX.1.9Bn that was", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 366, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "354", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 366, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["swept back to consolidated fund account; \uf0b7 Delayed submission of regular reports \uf0b7 I noted that the Hoima district did not have an approved strategic plan that is aligned to NDP-III and therefore lacks a certificate of compliance issued by National Planning Authority. \uf0b7 Regarding Covid-19 funds, Out of the total receipts of UGX.111, 450,000, the District absorbed UGX.111, 450,000 representing an absorption level of 100%.", null, null], ["04.", "Hoima RRH", "\uf0b7 I noted a number of anomalies during review of the hospital"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 367, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["swept back to consolidated fund account; \uf0b7 Delayed submission of regular reports \uf0b7 I noted that the Hoima district did not have an approved strategic plan that is aligned to NDP-III and therefore lacks a certificate of compliance issued by National Planning Authority. \uf0b7 Regarding Covid-19 funds, Out of the total receipts of UGX.111, 450,000, the District absorbed UGX.111, 450,000 representing an absorption level of 100%.", null, null], ["04.", "Hoima RRH", "\uf0b7 I noted a number of anomalies during review of the hospital"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates by the hospital to MoPs, over payment of pension"], [null, null, "worth UGX.3, 138,332. ; Underpayment of worth 2,282,632; The"], [null, "", "deductions were from nine (9) employees\u2019 salaries worth"], [null, null, "UGX18,438,987"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by twenty (20) new employees and four (4) pensioners;;un paid"], [null, null, "pensioners worth UGX 13372393.un-deducted PAYE from political"], [null, null, "leaders\u2019 gratuity resulting in unpaid tax of UGX.13372393 Failure"], [null, null, "to quantify outputs,"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; failure to quantify outputs, partial"], [null, null, "implementation or non-implementation of planned activities"], [null, null, "under absorption of funds worth UGX.1.78Bn that was swept"], [null, null, "back to consolidated fund account; under performance of the"], [null, null, "donor & releases from other government units worth"], [null, null, "UGX.0.03Bn; delayed submission of quarterly monitoring reports"], [null, null, "to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 The hospital mischarged expenditure worth UGX.38 million on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and"], [null, null, "not approved to confirm that is aligned to the NDP-III at the time"], [null, null, "of audit."], [null, null, ""], [null, null, "\uf0b7 Failure to quantify outputs, partial implementation or non-"], [null, null, "implementation of planned activities"], ["05\\. Kagadi DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Wrong computation of gratuity worth net overpayment of UGX. 1,8273,030; payment of salaries to three(3) staffs that was no longer in service and under remittance worth UGX. 35,519,020; and payment of two (2) staffs worth UGX. 3450720 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; unabsorbed balance worth UGX 1.5Bn partial implementation of funds worth UGX 0.155Bn under", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 367, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "355", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 367, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["absorption of funds worth UGX. 12,314,490,181 that was swept back to consolidated fund account; under performance of the donor & releases from other government units 3,329,413,255; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and not approved to confirm that is aligned to the NDP-III at the time of audit. \uf0b7 I noted a delay of 9 days for the month of July in the remittance of PAYE deductions to URA", null, null], ["06.", "Kakumiro DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 368, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["absorption of funds worth UGX. 12,314,490,181 that was swept back to consolidated fund account; under performance of the donor & releases from other government units 3,329,413,255; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and not approved to confirm that is aligned to the NDP-III at the time of audit. \uf0b7 I noted a delay of 9 days for the month of July in the remittance of PAYE deductions to URA", null, null], ["06.", "Kakumiro DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs; Underpayment of salaries worth UGX."], [null, null, "10,643,039 to employees underpayment pension worth UGX.4,"], [null, "", "511,350; under remittance worth UGX.146, 308,447 and"], [null, null, "payment of three (3) staffs worth UGX.8,763,215 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; unspent balance worth UGX"], [null, null, "2275637090 ; under absorption of funds worth"], [null, null, "UGX.9,191,378,616 that was swept back to consolidated fund"], [null, null, "account; partial or non-implementation of planned activities"], [null, null, "worth 0.37Bn under performance of the donor & releases from"], [null, null, "other government units worth UGX.0.4Bn; delayed submission of"], [null, null, "quarterly monitoring reports to OPM & MoFPED unabsorbed"], [null, null, "funds worth UGX.138,823,634; delayed completion of"], [null, null, "construction works at St Matia Mulumba seed secondary school."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and"], [null, null, "not approved to confirm that is aligned to the NDP-III at the time"], [null, null, "of audit."], [null, null, ""], [null, null, "\uf0b7 I noted that the District did not remit PAYE deductions for the"], [null, null, "month of May worth UGX.138, 823,634 to URA."], [null, null, ""], [null, null, "\uf0b7 I noted that the district had ongoing service delivery"], [null, null, ""], ["07 Kibaale DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of pension worth UGX.288, 866,531; Underpayment of pension worth UGX.4,082,68 underpayment of pensioners UGX.387,086,804; payment of salaries worth UGX.20,837,768 to fifteen (15) staffs that was no longer in service \uf0b7 I noted a number of issues in the implementation of the approved budget such as unspent balance worth UGX.1,861,400,617; underperformance of budgets worth UGX.14,350,250,339; delayed submission of quarterly monitoring reports to OPM & MoFPED; delayed completion of construction works at Nyamarwa Seed School secondary school;", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 368, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "356", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 368, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["under deduction of PAYE to URA worth 20,837,768 \uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and not approved to confirm that is aligned to the NDP-III at the time of audit. \uf0b7 I noted a number of issues in the implementation of the approved budget such as unspent balance worthUGX.1;861;400,617;unabsorbed funds worth UG.1.35 billion; delayed completion of construction works at Nyamarwa Seed School secondary school; under deduction of PAYE to URA worth 20,837,768 \uf0b7 I noted that funds amounting to UGX.24, 910,982 related to gratuity expense but were charged on pension arrears code. \uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification interface and noted in- adequate sensitization and training in the use and navigation of the system, System was not reliable and effective and operational challenges were encountered; such as delayed update of changes in employee details by NIRA, NID interface does not show facial images for some employees and network challenges.", null, null], ["08", "Kikuube DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 369, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["under deduction of PAYE to URA worth 20,837,768 \uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and not approved to confirm that is aligned to the NDP-III at the time of audit. \uf0b7 I noted a number of issues in the implementation of the approved budget such as unspent balance worthUGX.1;861;400,617;unabsorbed funds worth UG.1.35 billion; delayed completion of construction works at Nyamarwa Seed School secondary school; under deduction of PAYE to URA worth 20,837,768 \uf0b7 I noted that funds amounting to UGX.24, 910,982 related to gratuity expense but were charged on pension arrears code. \uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification interface and noted in- adequate sensitization and training in the use and navigation of the system, System was not reliable and effective and operational challenges were encountered; such as delayed update of changes in employee details by NIRA, NID interface does not show facial images for some employees and network challenges.", null, null], ["08", "Kikuube DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs, Over payment of salaries worth"], [null, null, "UGX.4,919,860; Salaries worth UGX. 5,747,552 to six (6) staffs"], [null, "", "that was no longer in service and payment of twenty two (22)"], [null, null, "staffs worth UGX.198,611,180 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds; under"], [null, null, "performance of the donor & releases from other government"], [null, null, "units worth UGX.9.19Bn; partial implementation of funds worth"], [null, null, "UGX. o.95 delayed submission of quarterly monitoring reports to"], [null, null, "OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted that whereas UGX.756,788,804 was deducted from"], [null, null, "employees\u2019 salaries to be remitted to different beneficiaries,"], [null, null, "UGX.758,906,480 was remitted leading to an over and under"], [null, null, "remittance of UGX.2,117,676"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and"], [null, null, "not approved to confirm that is aligned to the NDP-III at the time"], [null, null, "of audit."], [null, null, "\uf0b7 Payments to ten (10) employees worth 1457195 without signed a"], [null, null, "pay change report"], [null, null, ""], [null, null, "\uf0b7 I noted that UGX.68, 527,000 remained unaccounted for at the"], [null, null, "close of the financial year."], [null, null, ""], [null, null, "\uf0b7 I noted delayed completion of Nyairongo Seed Secondary School"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 369, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "357", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 369, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, ""], [null, null, "\uf0b7 Under Development Response to Displacement Impacts Project"], [null, null, "(DRDIP), I noted that Procurements worth UGX.2,524,177,097"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 370, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", null, ""], [null, null, "\uf0b7 Under Development Response to Displacement Impacts Project"], [null, null, "(DRDIP), I noted that Procurements worth UGX.2,524,177,097"], [null, null, "were undertaken using community procurement method which"], [null, null, "were not reported in quarterly reports submitted to the Authority."], [null, null, "Besides, they were not included in the approved integrated"], [null, null, "annual work plan of the District."], [null, null, ""], ["09 Kyankwanzi Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Underpayment of pension worth UGX.2,819,483 and payment of eight (8) staffs worth UGX.8,810,706 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; failure to quantify outputs, partial and non-implementation of planned activities; unabsorbed wage fund balance worth UGX.0.84Bn; under deduction of PAYE worth UGX.8, 593, 471; unabsorbed balance worth UGX. 69,083,003; under absorption of funds worth UGX.198,251,670 that was swept back to consolidated fund account; under performance under performance worth UGX 1.11Bn. \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines. \uf0b7 The district mischarged expenditure worth UGX.50, 174,102 on wrong budget lines. \uf0b7 I noted outstanding pensioners arrears worth UGX.40,454,541 \uf0b7 I noted that the entity did not prepare monthly wage, pension and gratuity performance analysis and did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted that the entity had prepared and approved the strategic plan but it was not certified by National Planning Authority.", null, null], ["10.", "Masindi DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs, Over and under payment of salaries;"], [null, null, "Overpayment of pension worth UG.37, 427,367 and under"], [null, "", "payment of pension worth UGX.870,105,650; payment of"], [null, null, "salaries to nine (9) staffs but were no longer in service."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; unabsorbed balance worth"], [null, null, "1,240,110,296; under performance of the donor & releases from"], [null, null, "other government units worth UGX.164Bn that was swept back"], [null, null, "to consolidated fund account; partial and non-implementation of"], [null, null, "planned activities; delayed submission of quarterly monitoring"], [null, null, "reports to OPM & MoFPED and payment of worth 208,659,885"], [null, null, "eleven staff(11) off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted that whereas UGX.3,312,092,285 was deducted from"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 370, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "358", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 370, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "employees\u2019 salaries to be remitted to different beneficiaries, only"], [null, null, "UGX.3,309,501,072 was remitted leading to a variance"], [null, null, "amounting to UGX.19,992,521."]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 371, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", null, "employees\u2019 salaries to be remitted to different beneficiaries, only"], [null, null, "UGX.3,309,501,072 was remitted leading to a variance"], [null, null, "amounting to UGX.19,992,521."], [null, null, ""], [null, null, "\uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2"], [null, null, "months the months"], [null, null, ""], [null, null, "\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID"], [null, null, "staff/pensioner/beneficiaries\u2019 verification interface and noted in-"], [null, null, "adequate sensitization and training in the use and navigation of"], [null, null, "the system, system was not reliable and effective and operational"], [null, null, "challenges were encountered; such as delays to capture changes"], [null, null, "on NIRA by IPPS."], [null, null, ""], [null, null, "\uf0b7 I noted that the District prepared a work plan to guide the"], [null, null, "utilization of funds that were received."], [null, null, ""], ["11\\. Masindi MC Opinion Qualified \uf0b7 I noted a number of anomalies during review of the municipal pension & salary payrolls such as; Failure to submit wage estimates to MoPs; over and underpayment of salaries worth UGX.33,863,477 to seventeen (17) staffs that was no longer in service and irregular deduction of loan instalments worth UGX.9, 061,174; under deduction of PAYE amounting to 11,411,400 and 19 staff and 13 pensioners were paid a total of UGX.315,332,447 off IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX.1, 362,275,792 that was swept back to consolidated fund account; partial or non-implementation of planned activities; under performance of the donor & releases from other government units worth UGX. 282,855,823; delayed submission of quarterly monitoring reports to OPM & MoFPED; \uf0b7 I noted that the entity had prepared and approved the strategic plan but it was not certified by National Planning Authority. \uf0b7 I noted that whereas UGX.1,427,190,853 was deducted from employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,149,993,408 was remitted leading to an under remittance amounting to UGX.280,237,640 and over remittance of UGX.3,040,195 \uf0b7 I noted that funds amounting to UGX.195,443,591 in relation to pension and gratuity were charged on wrong account codes \uf0b7 I noted that 73 employees were paid a total of UGX.UGX.61, 299,481 without signed pay change reports.", null, null], ["12.", "Kiboga DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, over payment of salaries worth UGX3,"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 371, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "359", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 371, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Unqualified", "632,888; Underpayment of salaries worth UGX.6,345,609;"], [null, "", "overpayment of pension UGX.1, 338,228 and under payment of"], [null, null, "pension of UGX.3, 404,504; salaries worth UGX. 3,051,636 to"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 372, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", "Unqualified", "632,888; Underpayment of salaries worth UGX.6,345,609;"], [null, "", "overpayment of pension UGX.1, 338,228 and under payment of"], [null, null, "pension of UGX.3, 404,504; salaries worth UGX. 3,051,636 to"], [null, null, "two (2) staffs that was no longer in service"], [null, null, ""], [null, null, "\uf0b7 I further noted under deduction of PAYE of UGX.5,724,180 to"], [null, null, "URA and two pensioners were paid a total of UGX.69,008,452 off"], [null, null, "the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; unabsorbed wage fund of"], [null, null, "UGX.0.41Bn; under performance of the donor & releases from"], [null, null, "other government units worth UGX.1,037,635,628; failure to"], [null, null, "quantify outputs, partial and non-implementation of planned"], [null, null, "activities; under absorption of government grants and Non"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had prepared and approved the strategic"], [null, null, "plan but it was not certified by National Planning Authority."], [null, null, ""], [null, null, "\uf0b7 I noted that funds amounting to UGX.40, 000,000 in relation to"], [null, null, "COVID funds returned by the area Members of Parliament had"], [null, null, "properly been accounted for."], [null, null, ""], [null, null, "\uf0b7 I noted that different departments at Kiboga district Hospital"], [null, null, "lacked the required personal protective gear to aid staff execute"], [null, null, "their duties during the pandemic"], ["13\\. Kiryandongo DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of pension salaries worth UGX.1,935,272; overpayment of pension UGX.1,423,052 and under payments of pension UGX.3,591,459; payment of salaries worth UGX. 7,153,511 three (3) staffs that was no longer in service and irregular deduction of loan worth UGX.45, 559,753. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; un absorbed balance wage funds worth UGX 0.28Bn; un quantified outputs; under absorption of funds worth UGX.2,939,664,455 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.4,624,951,481; staff payment worth 4,070,605 off the IPPS ;partial and non-implementation of planned activities delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the entity had prepared and approved the strategic plan but it was not certified by National Planning Authority. \uf0b7 Deduction Management System, operated by PCA-Payroll Consults Africa. \uf0b7 I noted that 23 employees were paid a total of UGX.46,112,214 without signed pay change reports", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 372, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "360", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 372, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted lack of evidence of formal appointment for the contract committee members of the district", null, null], ["", "Gulu Branch", "Summary of Key Findings"], ["01 Agago DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, over payment of salaries worth UGX. 25,241,289; Underpayment of salaries worth UGX. 164,307,857; Underpayment of pension worth UGX 93,335,963; payment of salaries worth UGX. 28,901,916 to seventeen(17) staffs that was no longer in service \uf0b7 Additionally, I observed that there was delayed access to payroll by five (05) new employees and sixteen (16) pensioners; failure to utilize wage funds of UGX.0.3Bn; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 13,352,540 and payment of twenty two (22) staffs worth of UGX 642,221,799 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; under absorption of funds worth UGX. 484,346,069 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.1.994Bn. \uf0b7 I noted that UGX.13.7 million was paid as residual salary arrears to eleven (11) employees who had not missed salaries in the previous financial year(s). \uf0b7 I noted that the verification forms and copies of the verification cards for 04 employees and 16 pensioners/beneficiaries were not on the respective personal files \uf0b7 The district had outstanding unrecovered receivables of UGX. 1,376,134,925 at year end. \uf0b7 I noted that the entity had not prepared a strategic plan at the time of audit. \uf0b7 I noted that Agago District received off-budget financing to a tune of UGX. 90.5 million. \uf0b7 I noted that funds to the tune of UGX .237,168,404 were irregularly diverted from the activities", null, null], ["02", "Alebtong DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs, Over payment of salaries worth"], [null, null, "UGX.20,617,118; Underpayment of salaries worth"], [null, "", "UGX.21,081,264, payment of salaries worth UGX. 26,612,830 to"], [null, null, "twenty(20) staffs that was no longer in service"], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 373, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "361", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 373, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, "by thirty three (33) new employees and twenty three(23)"], [null, "pensioners; failure to utilize wage funds of UGX.0.8Bn; un-"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 374, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, "by thirty three (33) new employees and twenty three(23)"], [null, "pensioners; failure to utilize wage funds of UGX.0.8Bn; un-"], [null, "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid"], [null, "tax of UGX. 9,060,528"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as;;"], [null, "Partial implementation, late submission of quarterly reports;"], [null, "Under absorption of UGX.1,493,165,616 that was swept back to"], [null, "consolidated fund account; under performance of the donor &"], [null, "releases from other government units worth UGX.1.994Bn"], [null, ""], [null, "\uf0b7 The district mischarged UGX. 198, 594,102 charged on account"], [null, "codes other than those prescribed for either salary, pension or"], [null, "gratuity."], [null, ""], [null, "\uf0b7 I noted that the district paid unverified residual arrears worth"], [null, "UGX. 119,498,458 to 12 pensioners"], [null, "\uf0b7 I noted that the District had outstanding receivables amounting"], [null, "to UGX.2,175,996,458 arising from Contractor\u2019s Prepayment YLP"], [null, "& UWEP"], [null, ""], [null, "\uf0b7 I noted that the district had outstanding payables of"], [null, "UGX.1,732,017,300 (Deposits received UGX.1,689,530,652,"], [null, "Sundry creditors of UGX.25,650,000 and Pension liabilities"], [null, "UGX.16,836,648) amounted to UGX. 3,464,034,600."], [null, ""], [null, "\uf0b7 I noted that the entity had prepared a strategic plan but the"], [null, "National Planning Authority had not yet approved it at the time of"], [null, "audit."], [null, ""], [null, "\uf0b7 I noted that UGX.580, 701,955 was charged on items which did"], [null, "not reflect the nature of the expenditure."], [null, ""], [null, "\uf0b7 I noted during the review of expenditure that the district received"], [null, "UGX.183,961,496 to be transferred to schools for printing"], [null, "materials. These funds were never transferred to the schools."], [null, ""], [null, "\uf0b7 Over/ under remittance of pays amounted to UGX. 6,239,435 and"], [null, "UGX. 180,339,880 respectively"], ["03 Amuru DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salaries worth UGX 9,787,296, Underpayment of salaries and pensioners worth UGX 122,296,566 and UGX 157,253,083 respectively ; payment of salaries worth UGX. 129,399,583 to twenty two (22) staffs that was no longer in service. Under remittance of employees\u2019 salaries deductions worth UGX. 11,492,067. \uf0b7 Additionally, I observed that there was delayed access to payroll by sixty six (66) new employees and thirteen (13) pensioners;", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 374, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "362", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 374, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["failure to utilize wage funds of UGX.1,094,631,066; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 2,140,892 and payment of two (02) pensioners worth UGX. 45,794,020 off the IPPS. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial and non-implementation of outputs and activities; non-submission of quarterly wage returns to MoPS; incomplete works such as; Amuru Seed School, Otwee HC III, Giragira-Guruguru and Gotgweno-Maroawobi road and culvert installation under Periodic maintenance of Lakang- Kidimon-Atoro road; under absorption of funds worth UGX.1,854,436,151 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX. 13,266,132,540; \uf0b7 The district mischarged expenditure worth UGX. 122,058,859 on wrong budget lines. \uf0b7 I noted that UGX. 75,499,557 was paid as residual arrears to 8 pensioners who had not been verified (and thus not part of schedule) by MoFPED \uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 The district has payables worth UGX. 1,560,778,573 and receivables worth UGX. 1682,711,064", null, null], ["04", "APAC DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 375, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": [["failure to utilize wage funds of UGX.1,094,631,066; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 2,140,892 and payment of two (02) pensioners worth UGX. 45,794,020 off the IPPS. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial and non-implementation of outputs and activities; non-submission of quarterly wage returns to MoPS; incomplete works such as; Amuru Seed School, Otwee HC III, Giragira-Guruguru and Gotgweno-Maroawobi road and culvert installation under Periodic maintenance of Lakang- Kidimon-Atoro road; under absorption of funds worth UGX.1,854,436,151 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX. 13,266,132,540; \uf0b7 The district mischarged expenditure worth UGX. 122,058,859 on wrong budget lines. \uf0b7 I noted that UGX. 75,499,557 was paid as residual arrears to 8 pensioners who had not been verified (and thus not part of schedule) by MoFPED \uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 The district has payables worth UGX. 1,560,778,573 and receivables worth UGX. 1682,711,064", null, null], ["04", "APAC DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Qualified Opinion", "estimates to MoPs, Over payment of salaries worth UGX"], [null, null, "170,469,321 and over payment of pension worth UGX."], [null, null, "764,207,203; Underpayment of salaries worth UGX. 43,539,065;"], [null, null, "Wrong computation of gratuity worth net overpayment of UGX."], [null, null, "7650,338, 704; payment of salaries worth UGX. 2,257,209 to"], [null, null, "two (2) staffs who were no longer in service; unpaid salaries"], [null, null, "worth UGX. 29,321,020"], [null, null, ""], [null, null, "\uf0b7 I noted over and/or under remittance of salary deductions worth"], [null, null, "UGX.906, 079,942 and UGX.10, 641,906 respectively."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by eleven (11) new employees and one (1) pensioners; failure to"], [null, null, "utilize wage funds of UGX. 364,298,971; un-deducted PAYE from"], [null, null, "political leaders\u2019 gratuity resulting in unpaid tax of UGX."], [null, null, "7,747,080. and payment of staff off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; partial implantation of out puts;"], [null, null, "incomplete works ; under absorption of funds worth UGX. 1.7 Bn"], [null, null, "that was swept back to consolidated fund account; under"], [null, null, "performance of the donor & releases from other government"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 375, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": "363", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 375, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "units worth UGX.622,073,000; non submission of quarterly"], [null, null, "monitoring reports to OPM & MoFPED"], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 376, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", null, "units worth UGX.622,073,000; non submission of quarterly"], [null, null, "monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 I noted that Apac DLG had revenue arrears worth UGX."], [null, null, "715,864,939 by year end"], [null, null, ""], [null, null, "\uf0b7 Outstanding unpaid pension arrears worth UGX. 702,052,938 by"], [null, null, "year end"], [null, null, ""], [null, null, "\uf0b7 I noted that no funds were paid as residual arrears to pensioners"], [null, null, "and staff that had not been verified and were not part of"], [null, null, "schedule provided by MoFPED for payment."], [null, null, ""], [null, null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit."], ["05 Gulu District Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs; Underpayment of pension worth UGX 299,950,406; Wrong computation of gratuity worth net overpayment of UGX. 1,249,233 and under remittance of salary deductions worth UGX. 8,451,617. \uf0b7 Additionally, I observed that there was delayed access to payroll by two (02) new employees and five (05) pensioners; failure to utilize wage funds of UGX 4.97 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 11,003,344.and payment of sixteen (16) staffs and five (05) pensioners worth UGX 114,877,542 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as;; incomplete works; partial implantation of outputs; under absorption of funds worth UGX 4,900,216,339 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.4,034,373,129; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 I noted that the district has outstanding receivables worth UGX. 2,063,196,780 by the year end", null, null], ["06", "Gulu RRH", "\uf0b7 I noted a number of anomalies during review of the"], ["", "", "Hospitalpension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs; Underpayment of salaries worth UGX. UGX"], [null, null, "8,236,293. Under remittance of salaries worth UGX.197, 476,295."], [null, "", ""]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 376, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "364", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 376, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, "by thirty one (31) new employees and seven (7) pensioners;"], [null, "failure to utilize wage funds of UGX. 1.87 billion.; un-deducted"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 377, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "units worth UGX.622,073,000; non submission of quarterly"], "type": "table"}}, {"content": [["", "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, "by thirty one (31) new employees and seven (7) pensioners;"], [null, "failure to utilize wage funds of UGX. 1.87 billion.; un-deducted"], [null, "PAYE from political leaders\u2019 gratuity resulting in unpaid tax of"], [null, "UGX.10,746,540 and payment of nine (9) staffs and ten (10)"], [null, "pensioners worth UGX. 461,890,255 off the IPPS"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; shoddy works in construction of"], [null, "classrooms; incomplete works, I noted there was noted delayed"], [null, "completion of the construction of 54 staff houses; partial"], [null, "implementation of actives; under absorption of funds worth UGX."], [null, "1,939,617,659 that was swept back to consolidated fund"], [null, "account"], [null, ""], [null, "\uf0b7 The district mischarged expenditure worth UGX. 34,589,597 on"], [null, "wrong budget lines."], [null, ""], [null, "\uf0b7 I noted that 24 employees were paid worth UGX. 118,822,759"], [null, "without signed any way."], [null, ""], [null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, "aligned to the NDP-III at the time of audit"], [null, ""], [null, "\uf0b7 I reviewed the approved Local revenue estimates for the financial"], [null, "year 2020/2021 and noted that the Hospital did not budget for"], [null, "NTR during the year but collected UGX. 206,100,000."], [null, ""], [null, "\uf0b7 I noted that the hospital had an off budget financing worth UGX."], [null, "1,092,948,429 during the financial year."], [null, ""], ["07 Kole DLG Opinion Qualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs; Over payment of pension worth UGX.288, 866,531; Underpayment of pension worth UGX.271, 215,401; Wrong computation of gratuity worth net overpayment of UGX. 54,578,592; payment of salaries two (2) staffs who were no longer in service and irregular deduction of loan instalments worth UGX.9, 061,174. \uf0b7 Additionally, I observed that there was delayed access to payroll by twenty three (23) new employees and fourteen (14) pensioners; failure to utilize wage funds of UGX. 0.4 Billion; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 6,473,220 and payment of twenty two (22) staffs worth UGX.35,678,772 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify out puts; partial and non-implementation of planned activities, inaccurate reporting, and delayed submission of quarterly reports; under absorption of funds worth UGX. 1,095,317,475 that was swept", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], "page": 377, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "units worth UGX.622,073,000; non submission of quarterly"], "type": "table"}}, {"content": "365 \nback to consolidated fund account; under performance of the donor & releases from other government units worth", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}, [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}]], "page": 377, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "8,664,323,677", "metadata": {"headings": [{"headings_0": {"content": "8,664,323,677", "page": 378, "level": 3}}, {"headings_1": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 The district mischarged expenditure worth UGX.639, 863,720", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district mischarged expenditure worth UGX.639, 863,720", "page": 378, "level": 3}}, {"headings_1": {"content": "8,664,323,677", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "on wrong budget lines.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district mischarged expenditure worth UGX.639, 863,720", "page": 378, "level": 3}}, {"headings_1": {"content": "8,664,323,677", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that UGX.349,542,400 in respect of staff advances and", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.349,542,400 in respect of staff advances and", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district mischarged expenditure worth UGX.639, 863,720", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "fuel deposits was not accounted for", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.349,542,400 in respect of staff advances and", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district mischarged expenditure worth UGX.639, 863,720", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted wrong recognition of deposits received figure of UGX.269, 970,000 in relation to Youth Livelihood Programme", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted wrong recognition of deposits received figure of UGX.269, 970,000 in relation to Youth Livelihood Programme", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.349,542,400 in respect of staff advances and", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "(YLP) and Uganda Women Entrepreneur Project (UWEP).", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted wrong recognition of deposits received figure of UGX.269, 970,000 in relation to Youth Livelihood Programme", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.349,542,400 in respect of staff advances and", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that UGX.43, 200,000 was paid to one (1) purported pensioner who was neither on the IPPS payroll register nor", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.43, 200,000 was paid to one (1) purported pensioner who was neither on the IPPS payroll register nor", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted wrong recognition of deposits received figure of UGX.269, 970,000 in relation to Youth Livelihood Programme", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "possessed the necessary documentation to support their existence.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.43, 200,000 was paid to one (1) purported pensioner who was neither on the IPPS payroll register nor", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted wrong recognition of deposits received figure of UGX.269, 970,000 in relation to Youth Livelihood Programme", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the district did not submit loan deductions worth UGX. 3,800,833 to UCLA/UBA.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district did not submit loan deductions worth UGX. 3,800,833 to UCLA/UBA.", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.43, 200,000 was paid to one (1) purported pensioner who was neither on the IPPS payroll register nor", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the District failed to remit tax worth UGX.407,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District failed to remit tax worth UGX.407,", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district did not submit loan deductions worth UGX. 3,800,833 to UCLA/UBA.", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "791,480 to URA.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District failed to remit tax worth UGX.407,", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district did not submit loan deductions worth UGX. 3,800,833 to UCLA/UBA.", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that UGX.34,062,213 was paid as residual arrears to one", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.34,062,213 was paid as residual arrears to one", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District failed to remit tax worth UGX.407,", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "(1) staff and two (2) pensioners who had not been verified (and thus not part of schedule) by MoFPED.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.34,062,213 was paid as residual arrears to one", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District failed to remit tax worth UGX.407,", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted over remittance of payroll deductions worth", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.34,062,213 was paid as residual arrears to one", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District failed to remit tax worth UGX.407,", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.34,062,213 was paid as residual arrears to one", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District failed to remit tax worth UGX.407,", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UGX.450,413,838", "metadata": {"headings": [{"headings_0": {"content": "UGX.450,413,838", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.34,062,213 was paid as residual arrears to one", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that UGX. 34,062,213 were charged on account codes", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX. 34,062,213 were charged on account codes", "page": 378, "level": 3}}, {"headings_1": {"content": "UGX.450,413,838", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "other than those prescribed for salary, pension or gratuity.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX. 34,062,213 were charged on account codes", "page": 378, "level": 3}}, {"headings_1": {"content": "UGX.450,413,838", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District had a receivables figure of UGX.1, 072,183,415 as presented in the Statement of Financial Position", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District had a receivables figure of UGX.1, 072,183,415 as presented in the Statement of Financial Position", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX. 34,062,213 were charged on account codes", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "and disclosed in note 19 to the financial statements.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District had a receivables figure of UGX.1, 072,183,415 as presented in the Statement of Financial Position", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX. 34,062,213 were charged on account codes", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I further noted that the District had a payables worth UGX.1,244,267,887", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I further noted that the District had a payables worth UGX.1,244,267,887", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District had a receivables figure of UGX.1, 072,183,415 as presented in the Statement of Financial Position", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted a number of misstatements in the financial statements of the districts such as; un-reconciling balances for PPE, treatment", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of misstatements in the financial statements of the districts such as; un-reconciling balances for PPE, treatment", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I further noted that the District had a payables worth UGX.1,244,267,887", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "of revenue surpluses, omission of domestic arrears paid during", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of misstatements in the financial statements of the districts such as; un-reconciling balances for PPE, treatment", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I further noted that the District had a payables worth UGX.1,244,267,887", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "the year of UGX.74,024,139,", "metadata": {"headings": [{"headings_0": {"content": "the year of UGX.74,024,139,", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of misstatements in the financial statements of the districts such as; un-reconciling balances for PPE, treatment", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}, {"headings_1": {"content": "the year of UGX.74,024,139,", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "366", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["never declared to the PS/ST. \uf0b7 Under UGIFT, I noted delayed completion of construction of Okwerodot Seed Secondary School, Okole HCII and Ayer HCIII upgrade.", null, null], ["08", "Lira Municipal", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 379, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["never declared to the PS/ST. \uf0b7 Under UGIFT, I noted delayed completion of construction of Okwerodot Seed Secondary School, Okole HCII and Ayer HCIII upgrade.", null, null], ["08", "Lira Municipal", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, over payment of pension worth"], [null, "Unqualified", "UGX.438,769,830 , underpayment of salaries worth"], [null, "", "UGX.14,238,411; Underpayment of pension worth UGX."], [null, null, "390,304,000;"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by five (5) pensioners; four (04) pensionaries do not have"], [null, null, "access to payroll; failure to utilize wage funds of UGX.0.6 billion;"], [null, null, "un-deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX.3, 734,640 and payment of nine (09)"], [null, null, "pensionaries worth UGX. 217,577,695 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete works; non implantation of"], [null, null, "municipal activities; under absorption of funds worth UGX."], [null, null, "UGX.12, 094,641,795 that were swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX. 236,796,670; late submission of"], [null, null, "quarterly reports"], [null, null, ""], [null, null, "\uf0b7 The municipal mischarged expenditure worth UGX. 63,933,741"], [null, null, "on wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 Under remitted payroll deductions worth UGX.4,119,401"], [null, null, ""], [null, null, "\uf0b7 I noted that the municipal paid unverified residual arrears worth"], [null, null, "UGX. 320,216,040 to 39 pensioners"], [null, null, ""], [null, null, "\uf0b7 I noted that 08 employees were paid a total of UGX.20, 975,837"], [null, null, "without signed pay change reports."], [null, null, ""], [null, null, "\uf0b7 I noted that the Municipal Council has an outstanding payables"], [null, null, "balance of UGX.383, 550,743 by year end as recognized in the"], [null, null, "statement of financial position on page 8 of the financial"], [null, null, "statements."], [null, null, ""], [null, null, "\uf0b7 I noted that municipal council has outstanding payables worth"], [null, null, "UGX. 383,550,743 and outstanding debtors worth UGX."], [null, null, "634,438,200"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had not had their prepared strategic plan"], [null, null, "approved as aligned to the NDP-III at the time of audit."], [null, null, ""], ["09 Lira RRH \uf0b7 I noted a number of anomalies during review of Lira RR Hospital pension & salary payrolls such as; Failure to submit wage", null, null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 379, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "367", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 379, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Unqualified estimates to MoPs, over payment of salaries worth UGX. UGX.10, 939,040; Underpayment of salaries worth UGX. UGX 19,371,873. Over payment of pension worth UGX 222,915,780. \uf0b7 Additionally, I observed that there was delayed access to payroll by three (3) pensioners; failure to utilize wage funds of UGX.1.50 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of one (01) pensioner worth UGX 48,955,200 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete works partial and implementation of activities; under absorption of funds worth UGX.1,866,855,791 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.13,220,968,441; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX. 53,750,617 on wrong budget lines. \uf0b7 Under remittance of salary deductions worth UGX. 115,855,754 \uf0b7 I noted that UGX. 18,767,338 was paid as residual arrears to 13 staff who had not been verified by MoFPED \uf0b7 I observed that a sum of UGX.339,276,432 had been paid to a contractor as advance payments", null, null], ["10", "Gulu MC", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the municipal"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 380, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["never declared to the PS/ST. \uf0b7 Under UGIFT, I noted delayed completion of construction of Okwerodot Seed Secondary School, Okole HCII and Ayer HCIII upgrade.", "None", "None"], "type": "table"}}, {"content": [["Opinion Unqualified estimates to MoPs, over payment of salaries worth UGX. UGX.10, 939,040; Underpayment of salaries worth UGX. UGX 19,371,873. Over payment of pension worth UGX 222,915,780. \uf0b7 Additionally, I observed that there was delayed access to payroll by three (3) pensioners; failure to utilize wage funds of UGX.1.50 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of one (01) pensioner worth UGX 48,955,200 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete works partial and implementation of activities; under absorption of funds worth UGX.1,866,855,791 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.13,220,968,441; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX. 53,750,617 on wrong budget lines. \uf0b7 Under remittance of salary deductions worth UGX. 115,855,754 \uf0b7 I noted that UGX. 18,767,338 was paid as residual arrears to 13 staff who had not been verified by MoFPED \uf0b7 I observed that a sum of UGX.339,276,432 had been paid to a contractor as advance payments", null, null], ["10", "Gulu MC", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the municipal"], [null, "Opinion", "council pension & salary payrolls such as; Failure to submit wage"], [null, "Unqualified", "estimates to MoPs, Underpayment of salaries worth"], [null, "", "UGX.26,212,810; payment of salaries worth UGX.64,323,258 to"], [null, null, "twenty nine (29) staffs that was no longer in service"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by one (01) new employee and twenty four (24) pensioners;"], [null, null, "failure to utilize wage funds of UGX. 0.33 billion; un-deducted"], [null, null, "PAYE from political leaders\u2019 gratuity resulting in unpaid tax of"], [null, null, "UGX. 4,415,984 and payment of seven (07) staffs and 08"], [null, null, "pensioners worth UGX. 73,991,598 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete work; partial and non-"], [null, null, "implementation of activities; under absorption of funds worth"], [null, null, "UGX. 37,873,163,059 that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX.5,244,627,728; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.313, 804,373 on"], [null, null, "wrong budget lines."]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 380, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["never declared to the PS/ST. \uf0b7 Under UGIFT, I noted delayed completion of construction of Okwerodot Seed Secondary School, Okole HCII and Ayer HCIII upgrade.", "None", "None"], "type": "table"}}, {"content": "368", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 380, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", ""], [null, "\uf0b7 A review of the pension payroll data and IFMS payments,"], [null, "revealed variances between amounts on the payroll and"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 381, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["never declared to the PS/ST. \uf0b7 Under UGIFT, I noted delayed completion of construction of Okwerodot Seed Secondary School, Okole HCII and Ayer HCIII upgrade.", "None"], "type": "table"}}, {"content": [["", ""], [null, "\uf0b7 A review of the pension payroll data and IFMS payments,"], [null, "revealed variances between amounts on the payroll and"], [null, "payments to individual pensioners, leading to an over and under"], [null, "payment of UGX.108,837,902 and UGX.1,323,647,325"], [null, "respectively."], [null, ""], [null, "\uf0b7 I noted that the entity had not had their prepared strategic plan"], [null, "approved as aligned to the NDP-III at the time of audit."], [null, ""], [null, "\uf0b7 I noted that 58 employees were paid a total of UGX."], [null, "UGX.48,537,458 without Unauthorized pay changed reports"], [null, ""], [null, "\uf0b7 I also noted that UGX.163, 186,521 accrued within the year and"], [null, "had not yet been paid to pensioners by the end of the year."], [null, ""], [null, "\uf0b7 Over and under payments of UGX 2,050,016 and UGX.625, 974"], [null, "respectively of 59 staff arising from the use a wrong salary scale."], [null, ""], [null, "\uf0b7 Overpayment of pension of arrears worth UGX.48,674,235 to"], [null, "nine (09) pensioners"], [null, ""], [null, "\uf0b7 I noted that Municipal Council paid out a total of UGX.6.3 million"], [null, "to 07 non-existent staff."], [null, ""], [null, "\uf0b7 I noted that UGX.75, 010,130 was paid to 08 purported"], [null, "pensioners that were neither on the IPPS payroll register nor"], [null, "possessed the necessary documentation to support their"], [null, "existence."], [null, ""], [null, "\uf0b7 I noted that the Municipal Council made PAYE deductions of"], [null, "UGX. 1,439,481,558, but did not remit UGX.2, 162,681 to URA."], [null, ""], [null, "\uf0b7 I noted that UGX.82, 533,859 was paid as residual arrears to 14"], [null, "pensioners who had not been verified."], [null, ""], [null, "\uf0b7 I noted that the council has receivables worth U GX.3,"], [null, "153,612,053 at end of the financial year."], [null, ""], [null, "\uf0b7 I noted that expenditure amounting to UGX.113,162,472"], [null, "remained unaccounted for."], [null, ""], ["11 Lira DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs,; payment of salaries worth UGX.14,683,834 to eight (8) staffs that was no longer in service . \uf0b7 Additionally, I observed that there was delayed access to payroll by fourteen (14) new employees and eight (8) pensioners; failure to utilize wage funds of UGX.0.5 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,794,810; Over and under payment salaries worth of", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 381, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["never declared to the PS/ST. \uf0b7 Under UGIFT, I noted delayed completion of construction of Okwerodot Seed Secondary School, Okole HCII and Ayer HCIII upgrade.", "None"], "type": "table"}}, {"content": "369", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 381, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["UGX.115,309,480 and UGX.131,175,021 respectively; under payments of salaries worth UGX.530,320 of 18 staff arising from the use a wrong salary scale \uf0b7 Over and under payment of pension worth of UGX.30, 707,444 and UGX.598, 762,255 respectively. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; the District failed to achieve the intended services from the implemented 02 outputs; under absorption of funds worth UGX. 1,005,249,173 that were swept back to consolidated fund account; over performance and under performance of the donor & releases from other government units worth UGX. 8,559,440,754 delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines. \uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit. \uf0b7 I noted that the district had an off budget financing worth UGX.220, 983,855 during the financial year. \uf0b7 I noted that 21 employees were paid a total of UGX. 9,941,845 without signed pay change reports. \uf0b7 I noted that the District had outstanding receivables worth UGX. 898,553,933 and outstanding payables worth UGX.920,018,518", null, null], ["12", "Oyam DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 382, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": [["UGX.115,309,480 and UGX.131,175,021 respectively; under payments of salaries worth UGX.530,320 of 18 staff arising from the use a wrong salary scale \uf0b7 Over and under payment of pension worth of UGX.30, 707,444 and UGX.598, 762,255 respectively. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; the District failed to achieve the intended services from the implemented 02 outputs; under absorption of funds worth UGX. 1,005,249,173 that were swept back to consolidated fund account; over performance and under performance of the donor & releases from other government units worth UGX. 8,559,440,754 delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines. \uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit. \uf0b7 I noted that the district had an off budget financing worth UGX.220, 983,855 during the financial year. \uf0b7 I noted that 21 employees were paid a total of UGX. 9,941,845 without signed pay change reports. \uf0b7 I noted that the District had outstanding receivables worth UGX. 898,553,933 and outstanding payables worth UGX.920,018,518", null, null], ["12", "Oyam DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Qualified Opinion", "estimates to MoPs, over payment of salaries worth UGX."], [null, null, "81,486,802; Underpayment of salaries worth UGX. 54,366,065;"], [null, null, "payment of salaries worth UGX.74, 935,902 to thirty three (33)"], [null, null, "staffs that was no longer in service .unpaid salary worth UGX.91,"], [null, null, "771,432."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by thirteen (13) new employees and sixteen (16) pensioners;"], [null, null, "failure to utilize wage funds of UGX. UGX.0.58 billion; un-"], [null, null, "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid"], [null, null, "tax of UGX.12, 437,406."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had not had their prepared strategic plan"], [null, null, "approved as aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 The District did not recognize as a receivable an advance"], [null, null, "payment of UGX.414,149,184 made on 28 th June 2021 for the"], [null, null, "supply and installation of medical equipment to 64 Health Center"], [null, null, "IIIs under Uganda Intergovernmental Fiscal Transfer Program"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 382, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": "370", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 382, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "(UgIFT) (LOT 3)."], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX. 609,529,053 on"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 383, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["UGX.115,309,480 and UGX.131,175,021 respectively; under payments of salaries worth UGX.530,320 of 18 staff arising from the use a wrong salary scale \uf0b7 Over and under payment of pension worth of UGX.30, 707,444 and UGX.598, 762,255 respectively. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; the District failed to achieve the intended services from the implemented 02 outputs; under absorption of funds worth UGX. 1,005,249,173 that were swept back to consolidated fund account; over performance and under performance of the donor & releases from other government units worth UGX. 8,559,440,754 delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines. \uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit. \uf0b7 I noted that the district had an off budget financing worth UGX.220, 983,855 during the financial year. \uf0b7 I noted that 21 employees were paid a total of UGX. 9,941,845 without signed pay change reports. \uf0b7 I noted that the District had outstanding receivables worth UGX. 898,553,933 and outstanding payables worth UGX.920,018,518", "None", "None"], "type": "table"}}, {"content": [["", "", "(UgIFT) (LOT 3)."], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX. 609,529,053 on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 Over payments of UGX.1, 104,810 respectively of 27 staff arising"], [null, null, "from the use of wrong salary scales."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete works; partial and non-"], [null, null, "implementation of activities; under absorption of funds worth"], [null, null, "UGX. 972,008,324 that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX. 1,163,405,949; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 Over and under payment of pension to pensionaries worth"], [null, null, "UGX.34, 619,402, and UGX.126, 248,570 respectively."], [null, null, ""], [null, null, "\uf0b7 I noted that the District has unauthorized loan deductions worth"], [null, null, "UGX.178,342,254."], [null, null, ""], [null, null, "\uf0b7 Payment of pension arrears worth UGX.22,125,006 to ineligible"], [null, null, "pensioners"], [null, null, ""], [null, null, "\uf0b7 I noted 700 vacant staff position at the district that affected"], [null, null, "service delivery"], [null, null, ""], [null, null, "\uf0b7 The district had outstanding payables worth UGX.2, 865,939,536"], [null, null, "and Overdue receivables worth UGX.2, 865,939,536 by the end"], [null, null, "of the financial year."], [null, null, ""], [null, null, "\uf0b7 UGX.590, 863,502 paid to the contractor on the 28 th June 2021"], [null, null, "was not supported by certificates of works done."], [null, null, ""], [null, null, "\uf0b7 I noted that expenditure amounting to UGX.31, 252,804"], [null, null, "remained unaccounted."], [null, null, ""], [null, null, "\uf0b7 I noted that management irregularly paid out UGX.411, 867,050"], [null, null, "to individual staff personal bank accounts to purportedly"], [null, null, "implement several council activities instead of directly paying the"], [null, null, "eligible suppliers and service providers. In addition, these"], [null, null, "individuals were neither imprest holders nor cashiers who are"], [null, null, "mandated to hold cash among other duties."], ["13", "Pader DLG Un Qualified Opinion \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salaries worth UGX.42,537,857payment of pension worth UGX.288, 866,531; Underpayment of pension worth UGX.910,301,025.; payment of", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 383, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["UGX.115,309,480 and UGX.131,175,021 respectively; under payments of salaries worth UGX.530,320 of 18 staff arising from the use a wrong salary scale \uf0b7 Over and under payment of pension worth of UGX.30, 707,444 and UGX.598, 762,255 respectively. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; the District failed to achieve the intended services from the implemented 02 outputs; under absorption of funds worth UGX. 1,005,249,173 that were swept back to consolidated fund account; over performance and under performance of the donor & releases from other government units worth UGX. 8,559,440,754 delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines. \uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit. \uf0b7 I noted that the district had an off budget financing worth UGX.220, 983,855 during the financial year. \uf0b7 I noted that 21 employees were paid a total of UGX. 9,941,845 without signed pay change reports. \uf0b7 I noted that the District had outstanding receivables worth UGX. 898,553,933 and outstanding payables worth UGX.920,018,518", "None", "None"], "type": "table"}}, {"content": "371", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 383, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["salaries worth UGX.7,410,931 to seven (07) staffs that was no longer in service \uf0b7 Additionally, I observed that there was delayed access to payroll by twenty three (23) new employees and two (2) pensioners; failure to utilize wage funds of UGX.2.38Bn; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.310,309,590 and payment of twenty two (22) staffs worth UGX.35,678,772 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; under absorption of funds that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.2,942,949,626; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Over payment of salary worth UGX.608,719 arising from use of wrong scale \uf0b7 I noted that the District made unauthorized loan deductions worth UGX. 45,223,516. \uf0b7 I noted that UGX.113, 671,178 was charged on account codes other than those prescribed for salary, pension and gratuity. \uf0b7 The District had an outstanding payables balance of UGX.1,365,231,670 as reported in the statement of financial position \uf0b7 The District had in its statement of financial position, long outstanding debtors (Advances) amounting to UGX.927, 029,154, which relate to the previous financial years. \uf0b7 I noted that the entity had prepared a strategic plan but the National Planning Authority had not yet approved it at the time of audit. \uf0b7 I undertook an assessment to establish if there has been service delivery from a sample of outputs that were implemented and noted that the upgrade of Lapul\u2013Ocwida Health Center II to III had not been completed because the contractor abandoned the site. \uf0b7 I noted that UGX.42, 534,087 was charged on items which did not reflect the nature of the expenditure. \uf0b7 The district has an approved staff structure of 2,215 positions. Out of the approved staff structure, 1,229 (55%) are filled leaving 986 (45%) vacant.", null, null], ["", "Soroti Branch", "Summary of Key Findings"], ["01 Amolatar DLG \uf0b7 I noted a number of anomalies during review of the district", null, null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 384, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "372", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], "page": 384, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "pension & salary payrolls such as; Failure to submit wage Opinion estimates to MoPs, over payment of pension worth UGX. Unqualified 3,624,783; Underpayment of pension worth UGX. 5,353,736 w; payment of salaries worth UGX. 12,633,711 fourteen (14) staffs", "metadata": {"headings": [{"headings_0": {"content": "pension & salary payrolls such as; Failure to submit wage Opinion estimates to MoPs, over payment of pension worth UGX. Unqualified 3,624,783; Underpayment of pension worth UGX. 5,353,736 w; payment of salaries worth UGX. 12,633,711 fourteen (14) staffs", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "that was no longer in service \n", "metadata": {"headings": [{"headings_0": {"content": "pension & salary payrolls such as; Failure to submit wage Opinion estimates to MoPs, over payment of pension worth UGX. Unqualified 3,624,783; Underpayment of pension worth UGX. 5,353,736 w; payment of salaries worth UGX. 12,633,711 fourteen (14) staffs", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, [{"headings_0": {"content": "pension & salary payrolls such as; Failure to submit wage Opinion estimates to MoPs, over payment of pension worth UGX. Unqualified 3,624,783; Underpayment of pension worth UGX. 5,353,736 w; payment of salaries worth UGX. 12,633,711 fourteen (14) staffs", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}]], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 13,781,047 and payment of 32 staffs and 02", "metadata": {"headings": [{"headings_0": {"content": "pension & salary payrolls such as; Failure to submit wage Opinion estimates to MoPs, over payment of pension worth UGX. Unqualified 3,624,783; Underpayment of pension worth UGX. 5,353,736 w; payment of salaries worth UGX. 12,633,711 fourteen (14) staffs", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "pensioners worth UGX. 34,292,421 off the IPPS and delayed", "metadata": {"headings": [{"headings_0": {"content": "pensioners worth UGX. 34,292,421 off the IPPS and delayed", "page": 385, "level": 3}}, {"headings_1": {"content": "pension & salary payrolls such as; Failure to submit wage Opinion estimates to MoPs, over payment of pension worth UGX. Unqualified 3,624,783; Underpayment of pension worth UGX. 5,353,736 w; payment of salaries worth UGX. 12,633,711 fourteen (14) staffs", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "submission of remittances of PAYE to URA", "metadata": {"headings": [{"headings_0": {"content": "pensioners worth UGX. 34,292,421 off the IPPS and delayed", "page": 385, "level": 3}}, {"headings_1": {"content": "pension & salary payrolls such as; Failure to submit wage Opinion estimates to MoPs, over payment of pension worth UGX. Unqualified 3,624,783; Underpayment of pension worth UGX. 5,353,736 w; payment of salaries worth UGX. 12,633,711 fourteen (14) staffs", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted a number of issues in the implementation of the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of the", "page": 385, "level": 3}}, {"headings_1": {"content": "pensioners worth UGX. 34,292,421 off the IPPS and delayed", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "approved budget such as; partial and non-implementation of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of the", "page": 385, "level": 3}}, {"headings_1": {"content": "pensioners worth UGX. 34,292,421 off the IPPS and delayed", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "planned activities; unabsorbed wage fund of UGX0.95 billion; under absorption of funds worth UGX.3,620,479,221 that was", "metadata": {"headings": [{"headings_0": {"content": "planned activities; unabsorbed wage fund of UGX0.95 billion; under absorption of funds worth UGX.3,620,479,221 that was", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of the", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.2,409,034,822; non submission of quarterly monitoring reports to OPM & MoFPED;", "metadata": {"headings": [{"headings_0": {"content": "planned activities; unabsorbed wage fund of UGX0.95 billion; under absorption of funds worth UGX.3,620,479,221 that was", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of the", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that whereas UGX. 2,463,002,481 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that whereas UGX. 2,463,002,481 was deducted from", "page": 385, "level": 3}}, {"headings_1": {"content": "planned activities; unabsorbed wage fund of UGX0.95 billion; under absorption of funds worth UGX.3,620,479,221 that was", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "employees\u2019 salaries to be remitted to different beneficiaries,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that whereas UGX. 2,463,002,481 was deducted from", "page": 385, "level": 3}}, {"headings_1": {"content": "planned activities; unabsorbed wage fund of UGX0.95 billion; under absorption of funds worth UGX.3,620,479,221 that was", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UGX.2,451,377,682.was remitted, leading to an over and under", "metadata": {"headings": [{"headings_0": {"content": "UGX.2,451,377,682.was remitted, leading to an over and under", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that whereas UGX. 2,463,002,481 was deducted from", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "remittance amounting to UGX.1,529,715 and UGX.13,154,514 respectively.", "metadata": {"headings": [{"headings_0": {"content": "UGX.2,451,377,682.was remitted, leading to an over and under", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that whereas UGX. 2,463,002,481 was deducted from", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The district mischarged UGX. 30,489,944 for pension arrears on", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district mischarged UGX. 30,489,944 for pension arrears on", "page": 385, "level": 3}}, {"headings_1": {"content": "UGX.2,451,377,682.was remitted, leading to an over and under", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "account code for gratuity.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district mischarged UGX. 30,489,944 for pension arrears on", "page": 385, "level": 3}}, {"headings_1": {"content": "UGX.2,451,377,682.was remitted, leading to an over and under", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the district had not paid pension arrears of UGX.121,391,408 by the end of the financial year and the total", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district had not paid pension arrears of UGX.121,391,408 by the end of the financial year and the total", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district mischarged UGX. 30,489,944 for pension arrears on", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "liabilities of UGX.1,794,377,044 \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district had not paid pension arrears of UGX.121,391,408 by the end of the financial year and the total", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district mischarged UGX. 30,489,944 for pension arrears on", "page": 385, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that the district had not paid pension arrears of UGX.121,391,408 by the end of the financial year and the total", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district mischarged UGX. 30,489,944 for pension arrears on", "page": 385, "level": 3}}]], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that expenditure of UGX.10, 037,020 remained unaccounted for by the close of the financial year.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district had not paid pension arrears of UGX.121,391,408 by the end of the financial year and the total", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district mischarged UGX. 30,489,944 for pension arrears on", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 I noted that the entity did not prepare and have an approved", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity did not prepare and have an approved", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district had not paid pension arrears of UGX.121,391,408 by the end of the financial year and the total", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "strategic plan aligned to NDP-III.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity did not prepare and have an approved", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district had not paid pension arrears of UGX.121,391,408 by the end of the financial year and the total", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that Amolatar District received off-budget financing to a tune of UGX.29, 056,000 directly from United Nations Development Fund (UNCDF) for local revenue enhancement and", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Amolatar District received off-budget financing to a tune of UGX.29, 056,000 directly from United Nations Development Fund (UNCDF) for local revenue enhancement and", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity did not prepare and have an approved", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "construction of Development Initiative for Northern Uganda", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Amolatar District received off-budget financing to a tune of UGX.29, 056,000 directly from United Nations Development Fund (UNCDF) for local revenue enhancement and", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity did not prepare and have an approved", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "(DINU) centre which was never declared to the PS/ST and as", "metadata": {"headings": [{"headings_0": {"content": "(DINU) centre which was never declared to the PS/ST and as", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Amolatar District received off-budget financing to a tune of UGX.29, 056,000 directly from United Nations Development Fund (UNCDF) for local revenue enhancement and", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "such no supplementary appropriation was issued as guided by the PS/ST.", "metadata": {"headings": [{"headings_0": {"content": "(DINU) centre which was never declared to the PS/ST and as", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Amolatar District received off-budget financing to a tune of UGX.29, 056,000 directly from United Nations Development Fund (UNCDF) for local revenue enhancement and", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}, {"headings_1": {"content": "(DINU) centre which was never declared to the PS/ST and as", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the district had not disposed of assets.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}, {"headings_1": {"content": "(DINU) centre which was never declared to the PS/ST and as", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "373", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", null, null], ["01.", "Bukedea 0 DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "2", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 386, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", null, null], ["01.", "Bukedea 0 DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "2", "pension & salary payrolls such as; Failure to submit wage"], ["", "Opinion", "estimates to MoPs,; Underpayment of pension worth"], [null, "Unqualified", "UGX.4,244,574. ; Wrong computation of gratuity worth net"], [null, "", "overpayment of UGX 4,368,548; delayed remittance of payroll"], [null, null, "deductions to URA and one staff was paid a total of"], [null, null, "UGX.14.8million off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as;partial implementation of planned"], [null, null, "activities; an absorbed wage fund balance 0.6Bn; under"], [null, null, "absorption of funds worth UGX.2.93Bn that was swept back to"], [null, null, "consolidated fund account; under performance of the donor &"], [null, null, "releases from other government units worth UGX.0.6Bn; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity did not prepare and have an approved"], [null, null, "strategic plan aligned to NDP-III."], [null, null, ""], [null, null, "\uf0b7 I noted that whereas UGX.4,007,788,020 was deducted from"], [null, null, "employees\u2019 salaries to be remitted to different beneficiaries,"], [null, null, "UGX.3,853,954,791 was remitted, leading to an over/ under"], [null, null, "remittance of UGX.116,697,024/UGX.270,530,253 respectively"], [null, null, "\uf0b7"], [null, null, "\uf0b7 I also noted that within total liabilities are deposits of UGX.994,"], [null, null, "994,899 regarding to YLP and UWEP."], [null, null, ""], [null, null, "\uf0b7 Bukedea HCIV experienced drug stock outs for several essential"], [null, null, "medicines during the year"], [null, null, ""], [null, null, "\uf0b7 The district awarded contracts and made payment of UGX."], [null, null, "47,362,136 without proof of active VAT registration. As a result,"], [null, null, "VAT amounting of UGX. 7,222,726 was paid to non-registered"], [null, null, "company/deregistered due to non-compliance."], [null, null, ""], [null, null, "\uf0b7 The district had received unbudgeted for funding worth UGX."], [null, null, "254,695,138 for printing of home study materials but this was"], [null, null, "not even approved as a supplementary budget by the council."], [null, null, ""], [null, null, "\uf0b7 An outstanding receivables balance of UGX. 303,281,690 during"], [null, null, "the financial year that remained unrecovered"], ["02\\. 0 3 Dokolo DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over Underpayment of salaries worth UGX.169,757,747 and several staff were paid a total of UGX.6.4million off the IPPS. \uf0b7 I noted a number of issues in the implementation of the approved budget such as;partial implementation of planned activities; unabsorbed wage funds of UGX.0.128Bn; under", null, null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 386, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "374", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 386, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["performance of the donor & releases from other government units worth UGX.6.258Bn; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the entity did not prepare and have an approved strategic plan aligned to NDP-III. \uf0b7 I noted delays in the remittance of PAYE deductions to URA in 2 out of 12 months, with an average delay. \uf0b7 I noted that the district did not subject political leaders\u2019 gratuity totaling to UGX.33, 217,800 to the computation of PAYE in IPPS, leading to revenue loss of UGX.10, 036,690. \uf0b7 Outstanding payables during the year worth UGX.7,108,292 remained unsettled by year end \uf0b7 Uncounted for funds at the close of the financial year amounted to UGX.13,212,000 \uf0b7 It was noted that two (2) contracts worth UGX.36,371,630 were awarded to contractors VAT inclusive to a tune of UGX.5,548,214 yet the individual contractors were either not VAT registered or had been de-registered by the tax authority. \uf0b7 An outstanding receivables balance of UGX.346,165,052 due from UWEP and YLP groups", null, null], ["03.", "Kaberamaido 0 DLG", ""], ["", "4", "\uf0b7 I noted a number of anomalies during review of the district"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 387, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["performance of the donor & releases from other government units worth UGX.6.258Bn; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the entity did not prepare and have an approved strategic plan aligned to NDP-III. \uf0b7 I noted delays in the remittance of PAYE deductions to URA in 2 out of 12 months, with an average delay. \uf0b7 I noted that the district did not subject political leaders\u2019 gratuity totaling to UGX.33, 217,800 to the computation of PAYE in IPPS, leading to revenue loss of UGX.10, 036,690. \uf0b7 Outstanding payables during the year worth UGX.7,108,292 remained unsettled by year end \uf0b7 Uncounted for funds at the close of the financial year amounted to UGX.13,212,000 \uf0b7 It was noted that two (2) contracts worth UGX.36,371,630 were awarded to contractors VAT inclusive to a tune of UGX.5,548,214 yet the individual contractors were either not VAT registered or had been de-registered by the tax authority. \uf0b7 An outstanding receivables balance of UGX.346,165,052 due from UWEP and YLP groups", null, null], ["03.", "Kaberamaido 0 DLG", ""], ["", "4", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "Opinion.", "pension & salary payrolls such as; Failure to submit wage"], [null, "Unqualified", "estimates to MoPs, over payment of salaries worth UGX.1,"], [null, "", "255,265; Underpayment of salaries worth UGX. 1, 222,507;"], [null, null, "salaries worth UGX.1,960,136 was paid to 1 staff who had retired"], [null, null, "and Paid UGX.3,300,000 and UGX.54,988,606 to 2 employees"], [null, null, "and 2 pensioners respectively off IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; unabsorbed wage funds worth UGX"], [null, null, "0.4Bn; under payment UGX. 37,655,834 under absorption of"], [null, null, "other received funds worth UGX.26, 816,534 that was swept"], [null, null, "back to consolidated fund account; under performance of the"], [null, null, "donor & releases from other government units worth"], [null, null, "UGX.464,763,581; delayed submission of quarterly monitoring"], [null, null, "reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity did not prepare and have an approved"], [null, null, "strategic plan aligned to NDP-III."], [null, null, "\uf0b7"], [null, null, "\uf0b7 I noted that the District made PAYE deductions of UGX.1,"], [null, null, "260,530,351 and remitted to URA and delays in the remittance of"], [null, null, "PAYE deductions to URA ranging from 1\u201313 days."], [null, null, ""], [null, null, "\uf0b7 I noted that Kaberamaido District did not subject political leaders\u2019"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 387, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "375", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 387, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "gratuity totaling to UGX. 37,211,942 to the computation of PAYE"], [null, null, "in IPPS, leading to an under deduction of UGX. 11,183,595."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 388, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["", null, "gratuity totaling to UGX. 37,211,942 to the computation of PAYE"], [null, null, "in IPPS, leading to an under deduction of UGX. 11,183,595."], [null, null, ""], [null, null, "\uf0b7 I observed a number of issues during my inspection of"], [null, null, "Kaberamaido Hospital such as; equipment such as Ultra sound"], [null, null, "machines and Scanners were idle due to lack of specialized"], [null, null, "human resources to operate them and the hospital has (4) small"], [null, null, "oxygen concentrators which are obsolete; Poor infrastructural"], [null, null, "development of kaberamido hospital"], [null, null, ""], [null, null, "\uf0b7 A review of the approved work plan and budget revealed that the"], [null, null, "district made budget provisions for vehicle maintenance during"], [null, null, "the period under review amounting to UGX.98, 812,000."], [null, null, "However, almost all the district vehicles were not functional due"], [null, null, "to failure to maintain and repair them and the approximated cost"], [null, null, "amounted to UGX.298, 400,000."], [null, null, ""], ["04\\. 0 5 Kalaki DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs; Underpayment of pension worth UGX.13,901,641; payment of salaries worth UGX. 1,573,970 to five (5) staffs that was no longer in service and payment of UGX 19.29 million to five (5) employees off the IPPS \uf0b7 I noted a number of issues in implementation of approved budget such as; under absorption of funds worth UGX.1,197,062,675 that was swept back to consolidated fund account;. un absorbed funds worth UGX.2.385Bn under performance of the donor & releases from other government units worth UGX.2,685,815,492 and non-submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the entity did not prepare and have an approved strategic plan aligned to NDP-III. \uf0b7 I observed that whereas UGX.1,565,039,555 was deducted from employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,487,680,407 was remitted, leading to an over/under remittance of UGX.6,339,201 and UGX.83,698,349 respectively. \uf0b7 Disclosed in the statement of financial position on page (15) are receivables of UGX.752,701,227 as supported by Note (19) relating to UWEP and YLP funds which remained due to the revolving fund and close of the financial year", null, null], ["06", "Katakwi DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, over and under payment of salaries worth"], [null, "Unqualified", "UGX. 1,541,478 and UGX. 24,265,506 respectively; under"], [null, "", "remittance salary deductions worth UGX. 10,723,784;"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed failure to utilize wage funds of"], [null, null, "UGX.0.1Bn; un-deducted PAYE from political leaders\u2019 gratuity"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 388, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "376", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 388, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "resulting in unpaid tax of UGX. 13,353,316; I noted that 4 newly"], [null, "recruited/ transferred employees and 24 pensioners delayed to"], [null, "access payroll; the Katakwi District did not prepare monthly"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 389, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None"], "type": "table"}}, {"content": [["", "resulting in unpaid tax of UGX. 13,353,316; I noted that 4 newly"], [null, "recruited/ transferred employees and 24 pensioners delayed to"], [null, "access payroll; the Katakwi District did not prepare monthly"], [null, "wage, pension and gratuity performance analysis and thus did"], [null, "not submit quarterly returns on payroll to MoPS; paid 32 staff"], [null, "and 02 pensioners worth UGX. 34,292,421 off the IPPS"], [null, ""], [null, "\uf0b7 I noted that the district had not paid salary and pension arrears"], [null, "of UGX.176,136,812 and UGX.210,481,886 respectively and"], [null, "deposits under total liabilities of UGX.1,469,427,540, comprising"], [null, "of YLP and UWEP amounts due to the revolving fund"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; shoddy works in construction of"], [null, "classrooms; incomplete works; under absorption of funds worth"], [null, "UGX. 360,155,363 that was swept back to consolidated fund"], [null, "account; under performance of the donor & releases from other"], [null, "government units worth UGX.1,868,819,492; delayed"], [null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, ""], [null, "\uf0b7 A total of 37 km at an estimated cost of UGX.220, 000,000 was"], [null, "worked on, however on physical inspection it was noted that"], [null, "some road sections were not well graded with poor road shaping,"], [null, "spot gravelling while others lacked access roads to the"], [null, "community."], [null, ""], [null, "\uf0b7 The district had received unbudgeted funding worth"], [null, "UGX.186,033,984 on 20 th January 2021 for printing of home"], [null, "study materials which was not approved as a supplementary"], [null, "budget by the council, remained un-transferred to schools until"], [null, "23 rd June 2021 and had not been utilized by the beneficiary"], [null, "schools at the time of audit.(August 2021)."], [null, ""], [null, "\uf0b7 An audit of Katakwi district hospital revealed instances of drug"], [null, "stock outs, failure to keep records of essential medicines such as"], [null, "oxygen and blood, expiry of drugs and staffing gaps at the"], [null, "district hospital."], [null, ""], [null, "\uf0b7 The district signed a contract with UK General Services Limited"], [null, "for Upgrade of Palam HC III to III funded under Transitional"], [null, "Development Grant (TDG) (KATA522/WRKS/20-21/00032) at a"], [null, "contract price of UGX.296, 838,010, UGX.265, 076,343 (89%) of"], [null, "the contract sum had been paid leaving only 10% retention due"], [null, "to the contractor but on inspection it was noted that the works"], [null, "were in complete and the contractor was not found on site."], ["07 KUMI DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs; Underpayment of pension worth UGX 40,603,995; payment of salaries worth UGX. 41,743,339 to fourteen (14) staffs that was no longer in service \uf0b7 Additionally, I observed that there was delayed access to payroll", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 389, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None"], "type": "table"}}, {"content": "377", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 389, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["by seventy eigth (78) new employees and six (06) pensioners and 15 pensioners did not access the pension payroll by the end of FY 2020/21; failure to utilize wage funds of UGX 0.7 billion.; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 8,722,103.and payment of seven (07) staffs worth UGX 8,054,219 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial implementation of activities, under absorption of funds worth UGX. 1,189,642,702 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.9,484,212,313; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Over and under remittance amounting to UGX. 1,447,689 and UGX. 27,903,716 respectively. \uf0b7 I noted that the District has receivables worth UGX 207,343,250. \uf0b7 I noted that the District had payables of worth UGX. 1,061,619,255 \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit. \uf0b7 The district lacked land titles for 58 pieces measuring 948.809 acres which exposed the land to loss and encroachment. \uf0b7 The district received a sum of UGX 202,441,411 for primary and secondary for procurement of learning materials. I noted that the above funds were still on the schools accounts. \uf0b7 Vacant staff position of 82 was noted at the district \uf0b7 The district mischarged expenditure worth of UGX.23,818,896 on wrong budget lines.", null, null], ["08", "Soroti CITY", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the district"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 390, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["by seventy eigth (78) new employees and six (06) pensioners and 15 pensioners did not access the pension payroll by the end of FY 2020/21; failure to utilize wage funds of UGX 0.7 billion.; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 8,722,103.and payment of seven (07) staffs worth UGX 8,054,219 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial implementation of activities, under absorption of funds worth UGX. 1,189,642,702 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.9,484,212,313; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Over and under remittance amounting to UGX. 1,447,689 and UGX. 27,903,716 respectively. \uf0b7 I noted that the District has receivables worth UGX 207,343,250. \uf0b7 I noted that the District had payables of worth UGX. 1,061,619,255 \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit. \uf0b7 The district lacked land titles for 58 pieces measuring 948.809 acres which exposed the land to loss and encroachment. \uf0b7 The district received a sum of UGX 202,441,411 for primary and secondary for procurement of learning materials. I noted that the above funds were still on the schools accounts. \uf0b7 Vacant staff position of 82 was noted at the district \uf0b7 The district mischarged expenditure worth of UGX.23,818,896 on wrong budget lines.", null, null], ["08", "Soroti CITY", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the district"], [null, "Opinion", "pension & salary payrolls such as; Failure to submit wage"], [null, "Unqualified", "estimates to MoPs worth 0.20Bn; Underpayment of pension"], [null, "", "worth UGX 17,693,503; payment of salaries worth UGX."], [null, null, "4,422,604 to two (2) staffs that was no longer in service"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by twenty three (2) new employees and nine (2) pensioners;"], [null, null, ""], [null, null, "\uf0b7 I noted under absorption of funds worth UGX.569,370,362 that"], [null, null, "was swept back to consolidated fund account; under"], [null, null, "performance of the donor & releases from other government"], [null, null, "units worth UGX.3,241,130,000; delayed submission of quarterly"], [null, null, "monitoring reports to OPM & MoFPED partial implementation of"], [null, null, "planned activities unquantified output 2 pensioners delayed to"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 390, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "378", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 390, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "access the pension payroll, with delays of 2 months."], [null, ""], [null, "\uf0b7 The district did not have an approved strategic plan that is"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 391, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None"], "type": "table"}}, {"content": [["", "access the pension payroll, with delays of 2 months."], [null, ""], [null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, "aligned to the NDP-III at the time of audit."], [null, ""], [null, "\uf0b7 I noted that whereas UGX.1,672,354,754 was deducted from"], [null, "employees\u2019 salaries to be remitted to different beneficiaries,"], [null, "UGX.1,720,244,218 was remitted, leading to an over remittance"], [null, "of UGX.47,889,464."], [null, ""], [null, "\uf0b7 I noted that the City did not subject political leaders\u2019 gratuity"], [null, "totaling to UGX.10, 718,400 to the computation of PAYE in IPPS,"], [null, "leading to a revenue loss of UGX.3,212,520."], [null, "."], [null, "\uf0b7 I noted that UGX.16, 952,389 was charged on account codes"], [null, "other than those prescribed for salary, pension and gratuity."], [null, "\uf0b7 9 staff and 1 pensioner were paid a total of UGX.9, 175,032 off"], [null, "the IPPS."], [null, "\uf0b7"], [null, "\uf0b7 It was noted that the health centre experienced expiry of several"], [null, "essential medicines."], [null, "\uf0b7 An audit of a sample of essential drugs revealed that there were"], [null, "discrepancies between quantities ordered and those actually"], [null, "delivered by National Medical Stores."], [null, ""], [null, "\uf0b7 I noted that from the financial year 2015/16 to 2018/19 the City"], [null, "had disbursed a total of UGX.213,350,031 out of which a sum of"], [null, "only UGX.48,137,000(23%) was recovered leaving an"], [null, "outstanding balance of UGX.173,473,68"], [null, "\uf0b7 AN outstanding balance of UGX.84,288,225 ."], ["09 Soroti DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; delayed to submit wage estimates to MoPs; an unabsorbed balance of UGX.0.1Bn; an over payment of UGX.2,539,634; Unpaid Salaries worth UGX.39,755,425; an under payment of UGX.40,539,361; payment of salaries worth UGX.2,618,034 to two (2) staffs that had retired and the other died; an over/under remittance of UGX.24,004,085 and UGX.70,000 respectively; loan deduction worth UGX.1,025,336,368 from 643 employees that had no letters of undertaking but exist in the reports. \uf0b7 I further un-deducted PAYE from political leaders\u2019 gratuity resulting to an under deduction of UGX.10,594,893; delay in accessing payroll and pension payroll; the district mischarged expenditure worth UGX.23,558,053 on wrong budget lines; Paid residual arrears worth UGX.361,354,056 to 15 pensioners who had not been verified; Failed to prepare monthly wage, pension and gratuity performance analysis; Failed also to submit quarterly returns on payroll to MoPS; Payment worth UGX.1,109,575,875 was paid to 26 pensioners off the IPPS; \uf0b7 I noted that the entity prepared and submitted the Strategic Plan to National Planning Authority but had not been approved by the", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 391, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None"], "type": "table"}}, {"content": "379", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 391, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["time of audit; the district had an Outstanding total liabilities worth UGX.1,315,447,223; Underperformance worth UGX.1,770,722,988; Under absorption worth UGX.620,661,204 which was subsequently swept back to the consolidated fund account; Failed to prepare annual monitoring plans. \uf0b7 The district received Amount worth UGX.51,440,000 under covid 19 response; the district had several pieces of land whose titles had not been secured; an outstanding balance worth UGX.1,028,188,380 from groups; shoddy works in construction of roads; Un utilized amount of money worth UGX.176,968,673 meant for the procurement of learning materials for primary and secondary schools", null, null], ["10", "Kapelebyong DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 392, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["time of audit; the district had an Outstanding total liabilities worth UGX.1,315,447,223; Underperformance worth UGX.1,770,722,988; Under absorption worth UGX.620,661,204 which was subsequently swept back to the consolidated fund account; Failed to prepare annual monitoring plans. \uf0b7 The district received Amount worth UGX.51,440,000 under covid 19 response; the district had several pieces of land whose titles had not been secured; an outstanding balance worth UGX.1,028,188,380 from groups; shoddy works in construction of roads; Un utilized amount of money worth UGX.176,968,673 meant for the procurement of learning materials for primary and secondary schools", null, null], ["10", "Kapelebyong DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, under payment of pension worth UGX."], [null, "Unqualified", "13,840,658; Underpayment of salaries worth UGX. 23,446,654.."], [null, "", "Accrued payment of pension worth UGX. 1,623,473. under"], [null, null, "remittance of salaries worth UGX. 35,257,436."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by two (2) pensioners; failure to utilize wage funds of UGX."], [null, null, "1,030,154,088.; un-deducted PAYE from political leaders\u2019 gratuity"], [null, null, "resulting in unpaid tax of UGX.6,156,000 and payment of six"], [null, null, "(06) staffs worth UGX. 19,428,658 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete works; partial"], [null, null, "implementation of activities, under absorption of funds worth"], [null, null, "UGX. 1,089, 751 811, that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX.537,701,164; delayed submission"], [null, null, "of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 Outstanding liabilities worth UGX.912,708,330"], [null, null, ""], [null, null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 A total of UGX.20, 000,000 was received as COVID 19"], [null, null, "supplementary funding"], [null, null, ""], [null, null, "\uf0b7 I noted that the district has funds worth UGX. 589,150,272"], [null, null, "relating to YLP and UWEP"], [null, null, ""], [null, null, "\uf0b7 The district received unbudgeted funding worth UGX. 76,174,518"], [null, null, ""], [null, null, "\uf0b7 I noted that the district has outstanding payables (YLP)/ UWEP"], [null, null, "worth UGX. 331,343,011 and UGX. 251,879,775 respectively"], [null, null, "."], [null, null, "\uf0b7 The district awarded contracts and made payments amounting to"], [null, null, "UGX.97, 981,512 without proof of active VAT registration, as a"], [null, null, "result, VAT amounting of UGX.14, 946,332 was paid to non-"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 392, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "380", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 392, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "registered or de-registered companies."], ["11 SERERE DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salaries worth UGX.5,681,385; Underpayment of salaries worth UGX.7,111,988; under remittance of salaries worth UGX.32,910,176 \uf0b7 I further noted failure to utilize wage funds of UGX.0.6 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,721, UGX.416million off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as;; under absorption of funds worth UGX.1.18Bn that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.7.721Bn; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Un recovered YLP and UWEP deposits worth UGX.1,086,363,675 \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit. \uf0b7 I noted that the district had received unbudgeted for funding worth UGX. 254,695,138 \uf0b7 Unrecovered YLP and UWEP fund worth UGX. 873,681,064", null, null], ["12", "Amuria DLG", ""]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 393, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["", null, "registered or de-registered companies."], ["11 SERERE DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salaries worth UGX.5,681,385; Underpayment of salaries worth UGX.7,111,988; under remittance of salaries worth UGX.32,910,176 \uf0b7 I further noted failure to utilize wage funds of UGX.0.6 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,721, UGX.416million off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as;; under absorption of funds worth UGX.1.18Bn that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.7.721Bn; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Un recovered YLP and UWEP deposits worth UGX.1,086,363,675 \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit. \uf0b7 I noted that the district had received unbudgeted for funding worth UGX. 254,695,138 \uf0b7 Unrecovered YLP and UWEP fund worth UGX. 873,681,064", null, null], ["12", "Amuria DLG", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the district"], [null, "Opinion", "pension & salary payrolls such as; Failure to submit wage"], [null, "Un-Qualified", "estimates to MoPs, over payment of salaries worth"], [null, "", "UGX.467,333, under payment of salaries worth UGX.607,250"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by seven (07) new employees and fourteen (14) pensioners;"], [null, null, "failure to utilize wage funds of UGX.1,303,509,217.; un-deducted"], [null, null, "PAYE from political leaders\u2019 gratuity resulting in unpaid tax of"], [null, null, "UGX.12,243,797 and payment of one (01) staffs worth of"], [null, null, "UGX.5,393,465 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as;; under absorption of funds worth"], [null, null, "UGX.1,872,205,072 that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX.2,531,940,210; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted that the District has unauthorized loan deductions worth"], [null, null, "UGX.694,591,280."]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 393, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "381", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 393, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "at the time of audit"], [null, ""], [null, "\uf0b7 The district received off-budget financing to a tune of UGX. .46,"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 394, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None"], "type": "table"}}, {"content": [["", "at the time of audit"], [null, ""], [null, "\uf0b7 The district received off-budget financing to a tune of UGX. .46,"], [null, "449,000 directly from UNFPA for undertaking activities which was"], [null, "never declared to the PSST and as such no supplementary"], [null, "appropriation was issued as guided by the PSST."], [null, ""], [null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, "aligned to the NDP-III at the time of audit."], [null, ""], [null, "\uf0b7 I noted that Note 19, Net Receivables, to the financial"], [null, "Statements, Amuria District had receivables of UGX.808,524,096"], [null, "relating to UWEP and YLP funds at the beginning of the current"], [null, "financial year. Further review revealed that the receivables"], [null, "increased to UGX.1, 003,497,681."], [null, ""], [null, "\uf0b7 I noted that funds totaling UGX.7,747,000 were irregularly"], [null, "diverted from the activities on which they were budgeted and"], [null, "spent on other activities without seeking or obtaining the"], [null, "necessary approvals."], [null, ""], [null, "\uf0b7 I noted that that tracer medicines like Oxytocin, Coatem"], [null, "(Artemether + Lumefantrine) 24 Tablets 30 strips, Gloves,"], [null, "Determine test kit and Mama kits worth UGX.4,615,129 was not"], [null, "accounted for by the Hospital Management."], [null, "\uf0b7 I noted that out of 154 pieces of land, only 8 (5%) had titles."], ["13 Kumi MC Opinion Un-qualified \uf0b7 I noted a number of anomalies during review of the Municipal pension & salary payrolls such as; Under absorption worth UGX.212,168,628; under payment worth UGX.35,246,285; Outstanding payment worth UGX.2,256,948 meant for 5 employees; an under payment of Pension, Gratuity worth UGX.33,299; Accrued payment worth UGX.13,261,366; payment of salaries worth UGX.5,189,355 to Nine (9) staffs who had either retired, transferred, absconded or died. \uf0b7 Additionally, I observed an over remittance of UGX.13, 281,172; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.3, 889,440; delayed in accessing payroll and pension payroll; Failed to prepare monthly wage, pension and gratuity performance analysis; Failed to submit quarterly returns on payroll to MoPS; Salary payment worth UGX.5, 582,676 was paid to 12 staffs off the IPPS. Receivables worth UGX.1, 132,227,490 relating to UWEP and YLP funds. \uf0b7 I noted that the entity does not have an approved strategic plan that is aligned to the NDP-III at the time of audit; Underperformance worth UGX.389,604,927; under Absorption UGX.297,497,115. \uf0b7 I noted that UGX.9, 350,000 was charged on items which did not reflect the nature of the expenditure. \uf0b7 I noted that all the pieces of land owned by the municipality", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 394, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None"], "type": "table"}}, {"content": "382", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 394, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["lacked Titles; the entity Lacked approved Physical Development Plan and detailed Plans; Underperformance of the public Health and Hygiene Promotion worth UGX.2,996,879; an outstanding balance worth UGX.256,828,714 and UGX.148,878,891 from YLP groups and UWEP groups respectively", null, null], ["14", "Ngora DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as Underpayment of salary worth"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 395, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["lacked Titles; the entity Lacked approved Physical Development Plan and detailed Plans; Underperformance of the public Health and Hygiene Promotion worth UGX.2,996,879; an outstanding balance worth UGX.256,828,714 and UGX.148,878,891 from YLP groups and UWEP groups respectively", null, null], ["14", "Ngora DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as Underpayment of salary worth"], [null, "Opinion", "UGX.39,027,007; irregular deduction of loan instalments worth"], [null, "Un-Qualified", "UGX.834,880,411; pension and gratuity under/Non-payments of"], [null, "", "UGX.155,180,697; over remittance of salary deductions worth"], [null, null, "UGX.100,096,201 and eighty-seven (87) vacant staff positions"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed failure to utilize wage funds of UGX.0.4"], [null, null, "Bn; un-deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX.10,637,490 and payment of one (1) staff"], [null, null, "worth UGX.1,776,726 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted outstanding receivables of UGX.1,131,962,894 relating to"], [null, null, "UWEP and YLP"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete works; under absorption of"], [null, null, "funds worth UGX.652,569,804 that was swept back to"], [null, null, "consolidated fund account; under performance of the donor &"], [null, null, "releases from other government units worth UGX 2,214,950,254;"], [null, null, ""], [null, null, "\uf0b7 The DLG did not have an approved strategic plan that is aligned"], [null, null, "to the NDP-III at the time of audit"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.44, 007,809 on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity did not prepare monthly wage, pension"], [null, null, "and gratuity performance analysis and did not submit quarterly"], [null, null, "returns on payroll to MoPS."], [null, null, ""], [null, null, "\uf0b7 I noted that out of the total receipts/ Warrants for Covid-relief"], [null, null, "funds UGX.39,990,000 the entity did not absorb any Funds."], [null, null, ""], [null, null, "\uf0b7 I noted Drug Stock Outs and Expired medicines in Ngora HC. IV"], [null, null, ""], [null, null, "\uf0b7 I noted Lack of land titles for the district land"], [null, null, ""], [null, null, "\uf0b7 I noted un recovered youth group funds worth UGX.930,137,986."], [null, null, ""], ["15 Soroti Regional Referral Hospital Opinion Un-Qualified \uf0b7 I noted a number of anomalies during review of the hospital pension & salary payrolls such as; Failure to submit wage estimates to MoPs, over payment of salary worth UGX 8,16,582; Underpayment of salary worth UGX.1,039,133payment of salaries worth UGX 15,516,178 to seven (7) staffs that was no longer in service and irregular deduction of loan instalments worth UGX.61,946,480.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 395, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "383", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 395, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted an over/under payment for gratuity worth UGX8,109,089 and UGX.28,338,806 respectively \uf0b7 I noted under/over remittance of salary deductions worth UGX.6,037,243,966 and UGX.30,277 respectively \uf0b7 Additionally, I observed that there was delayed access to payroll by thirteen (13) new employees \uf0b7 I noted under remittance of PAYE deductions worth5.2Mn \uf0b7 I noted under remittance of salary deductions to UCLA/UBA worth 0.84Mn \uf0b7 I noted issues in the implementation of the approved budget such as; under absorption of funds worth UGX.0.33 that was swept back to consolidated fund account and partially quantified and un quantified planned output \uf0b7 The hospital did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 The district mischarged expenditure worth UGX.105Mn on wrong budget lines. \uf0b7 I noted that 03 employees were paid a total of UGX.27.8 million without signed pay change reports. \uf0b7 I noted that the Hospital did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted that the RRH received off-budget financing of UGX.1,652,793,876. \uf0b7 I noted. under absorption of COVID-19 relief funds worth UGX.6,068,828 \uf0b7 I noted that the Hospital had stock outs of Essential medicines for supportive treatment of Covid-19 during the year", null, null], ["16", "Otuke DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; delay to submit wage"], [null, "Opinion Un-Qualified", "estimates to MoPs, accrued pension worth UGX.10,251,154;"], [null, null, "under payments of pension and gratuity of UGX.5,374,525.; an"], [null, "", "under remittance of salary deductions worth UGX.122,929,219."], [null, null, ""], [null, null, "\uf0b7 I noted Pension, Salary and retentions arears worth"], [null, null, "UGX.440,155,588"], [null, null, ""], [null, null, "\uf0b7 I noted un recovered youth group funds worth"], [null, null, "UGX.898,559,384"], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 396, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "384", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 396, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 Additionally, I observed failure to utilize wage funds of"], [null, null, "UGX.0.97Bn; un-deducted PAYE from political leaders\u2019 gratuity"], [null, null, "resulting in unpaid tax of UGX.9,454,537 and payment of two (2)"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 397, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["", null, "\uf0b7 Additionally, I observed failure to utilize wage funds of"], [null, null, "UGX.0.97Bn; un-deducted PAYE from political leaders\u2019 gratuity"], [null, null, "resulting in unpaid tax of UGX.9,454,537 and payment of two (2)"], [null, null, "staffs worth UGX.13,339,271 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted issues in the implementation of the approved budget"], [null, null, "such as; absorption of funds worth UGX.0.58Bn that was swept"], [null, null, "back to consolidated fund account; under performance of the"], [null, null, "donor & releases from other government units worth UGX"], [null, null, "1.452Bn"], [null, null, ""], [null, null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 I noted that the district did not prepare monthly wage, pension"], [null, null, "and gratuity performance analysis and thus did not submit"], [null, null, "quarterly returns on payroll to MoPS."], [null, null, ""], [null, null, "\uf0b7 I noted that one employee was paid a total of UGX.18 million"], [null, null, "without signed pay change reports."], [null, null, ""], [null, null, "\uf0b7 I also noted un recovered YLP and UWEP funds worth"], [null, null, "UGX.1,514,330,911"], [null, null, ""], [null, null, "\uf0b7 I noted that the district received off-budget financing from"], [null, null, "donors"], [null, null, ""], [null, null, "\uf0b7 I noted that the district only recovered UGX.185,893,762 (31%)"], [null, null, "out of disbursed amount of UGX.597,983,600 (Interest Inclusive)"], [null, null, "leaving an outstanding amount of UGX.412,089,838 disbursed in"], [null, null, "financial Years 2016/2017,2017/2018, 2018/2019 and"], [null, null, "2020/2021."], ["Moroto Branch \uf0b7 Summary of Key Findings", null, null], ["01", "Moroto DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs; payment of salaries worth UGX. 944,615 to"], [null, "Unqualified", "two (2) staffs that was no longer in service"], [null, "", ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by two (02) new employees and nine (9) pensioners; failure to"], [null, null, "utilize wage funds UGX.1.9 Bn; un-deducted PAYE from political"], [null, null, "leaders\u2019 gratuity resulting in unpaid tax of UGX. 16,712,548 and"], [null, null, "payment of one hundred twenty six (126) staffs worth UGX."], [null, null, "113,636,936 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted Under payment of pension/ gratuity worth UGX 969,963"], [null, null, ""], [null, null, "\uf0b7 Over remittance of salaries worth UGX. 42,443,292."], [null, null, ""], [null, null, "\uf0b7 I noted that loan deductions amounting to UGX. 444 million"], [null, null, "relating to 236 employees lacked letters of undertaking."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 397, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "385", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 397, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete works; partial and non-"], [null, null, "implementation of activities worth UGX. 0.842Bn under"], [null, null, "absorption of funds worth UGX. 2.173 Bn that was swept back to"], [null, null, "consolidated fund account; under performance of the donor &"], [null, null, "releases from other government units worth UGX.4,318,906,529"], [null, null, "delayed submission of quarterly monitoring reports to OPM &"], [null, null, "MoFPED"], [null, null, "Under performance of the URF fund worth UGX 9,622,000"], [null, null, ""], [null, null, "\uf0b7 I noted Failure to maintain a repayments ledger for all YIG\u2019s"], [null, null, "(Youth Interest Groups)"], [null, null, "I noted Failure to maintain a repayments ledger for all UWEP"], [null, null, "Groups."], [null, null, ""], ["02 Napak DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salaries worth UGX.25,677,705 \uf0b7 Additionally, I observed that there was delayed access to payroll by fifteen (15) new employees and one (01) pensioners; failure to utilize wage funds of UGX. 0.7 Billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. UGX 9,299,652. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete works; partial implementation; under absorption of funds worth UGX. 2.406 Bn that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.88,076,485; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Overpayment of salaries to 04 staff worth UGX. 263,929 arising from wrong scale. \uf0b7 I noted Under payment of pension/ gratuity worth UGX 274,445,221 \uf0b7 Over remittance of salaries worth 212,895,556. \uf0b7 I noted that the entity\u2019s strategic plan was prepared but not yet approved by NDP \uf0b7 I noted mischarges worth UGX. 23,485,083 by the district", null, null], ["03", "Abim DLG", ""], ["", "Qualified Opinion", "\uf0b7 I noted a number of anomalies during review of the district"], [null, null, "pension & salary payrolls such as; Failure to submit wage"], [null, null, "estimates to MoPs; Overpayments of salaries worth UGX."], [null, null, "2,172,750."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 398, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": "386", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], "page": 398, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 Additionally, I observed that there was delayed access to payroll", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Additionally, I observed that there was delayed access to payroll", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "by twenty one hundred two (102) new employees and six (06)", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Additionally, I observed that there was delayed access to payroll", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "pensioners; failure to utilize wage funds of UGX.0.8 billion; un-", "metadata": {"headings": [{"headings_0": {"content": "pensioners; failure to utilize wage funds of UGX.0.8 billion; un-", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 Additionally, I observed that there was delayed access to payroll", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 8,922,417and payment of nineteen(19) staffs worth", "metadata": {"headings": [{"headings_0": {"content": "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 8,922,417and payment of nineteen(19) staffs worth", "page": 399, "level": 2}}, {"headings_1": {"content": "pensioners; failure to utilize wage funds of UGX.0.8 billion; un-", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX 46,305,014 off the IPPS", "metadata": {"headings": [{"headings_0": {"content": "UGX 46,305,014 off the IPPS", "page": 399, "level": 3}}, {"headings_1": {"content": "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 8,922,417and payment of nineteen(19) staffs worth", "page": 399, "level": 2}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted a number of issues in the implementation of the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of the", "page": 399, "level": 3}}, {"headings_1": {"content": "UGX 46,305,014 off the IPPS", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "approved budget such as; incomplete works; partial implementation of activities under absorption of funds worth", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of the", "page": 399, "level": 3}}, {"headings_1": {"content": "UGX 46,305,014 off the IPPS", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UGX.1.3Bn that was swept back to consolidated fund account;", "metadata": {"headings": [{"headings_0": {"content": "UGX.1.3Bn that was swept back to consolidated fund account;", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of the", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "under performance of the donor & releases from other", "metadata": {"headings": [{"headings_0": {"content": "UGX.1.3Bn that was swept back to consolidated fund account;", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of the", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "government units worth UGX. 5.87Bn; delayed submission of", "metadata": {"headings": [{"headings_0": {"content": "government units worth UGX. 5.87Bn; delayed submission of", "page": 399, "level": 3}}, {"headings_1": {"content": "UGX.1.3Bn that was swept back to consolidated fund account;", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "quarterly monitoring reports to OPM & MoFPED", "metadata": {"headings": [{"headings_0": {"content": "government units worth UGX. 5.87Bn; delayed submission of", "page": 399, "level": 3}}, {"headings_1": {"content": "UGX.1.3Bn that was swept back to consolidated fund account;", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the district has an outstanding payables worth UGX. 43,702,393 by the end of the year", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district has an outstanding payables worth UGX. 43,702,393 by the end of the year", "page": 399, "level": 3}}, {"headings_1": {"content": "government units worth UGX. 5.87Bn; delayed submission of", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 Over payment of pension to 11 pensionaries worth UGX.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Over payment of pension to 11 pensionaries worth UGX.", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district has an outstanding payables worth UGX. 43,702,393 by the end of the year", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "2,318,376 arising from wrong scale.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Over payment of pension to 11 pensionaries worth UGX.", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district has an outstanding payables worth UGX. 43,702,393 by the end of the year", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted Misclassification of Expenditure worth UGX.296,881,279", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted Misclassification of Expenditure worth UGX.296,881,279", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 Over payment of pension to 11 pensionaries worth UGX.", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that UGX 130,582,400 accrued within the year and had", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX 130,582,400 accrued within the year and had", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Misclassification of Expenditure worth UGX.296,881,279", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "not yet been paid to pensioners by the year end. \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX 130,582,400 accrued within the year and had", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Misclassification of Expenditure worth UGX.296,881,279", "page": 399, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that UGX 130,582,400 accrued within the year and had", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Misclassification of Expenditure worth UGX.296,881,279", "page": 399, "level": 3}}]], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Under remittance of salaries deduction worth to UGX.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX 130,582,400 accrued within the year and had", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Misclassification of Expenditure worth UGX.296,881,279", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "352,211,360.", "metadata": {"headings": [{"headings_0": {"content": "352,211,360.", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX 130,582,400 accrued within the year and had", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that funds amounting to 2 million relating to pension and", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that funds amounting to 2 million relating to pension and", "page": 399, "level": 3}}, {"headings_1": {"content": "352,211,360.", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "gratuity were incorrectly charged on salaries and pension codes.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that funds amounting to 2 million relating to pension and", "page": 399, "level": 3}}, {"headings_1": {"content": "352,211,360.", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the Abim district did not have an approved strategic", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the Abim district did not have an approved strategic", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that funds amounting to 2 million relating to pension and", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "plan that is aligned to NDP-III and therefore lacks a certificate of compliance issued by National Planning Authority..", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the Abim district did not have an approved strategic", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that funds amounting to 2 million relating to pension and", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted misclassification of expenditure UGX.296,881,279 by", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted misclassification of expenditure UGX.296,881,279 by", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the Abim district did not have an approved strategic", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Abim DLG", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted misclassification of expenditure UGX.296,881,279 by", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the Abim district did not have an approved strategic", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted Lack of land title for Nyakwae Seed Secondary School.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted Lack of land title for Nyakwae Seed Secondary School.", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted misclassification of expenditure UGX.296,881,279 by", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted Irregular disbursement of UGX 175,113,737 for NUSAF", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted Irregular disbursement of UGX 175,113,737 for NUSAF", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Lack of land title for Nyakwae Seed Secondary School.", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "funds", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted Irregular disbursement of UGX 175,113,737 for NUSAF", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Lack of land title for Nyakwae Seed Secondary School.", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Irregular disbursement of UGX 175,113,737 for NUSAF", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX. 109,898,354 \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Irregular disbursement of UGX 175,113,737 for NUSAF", "page": 399, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Irregular disbursement of UGX 175,113,737 for NUSAF", "page": 399, "level": 3}}]], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Unaccounted for funds worth 1,412,507,436 at year end", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Irregular disbursement of UGX 175,113,737 for NUSAF", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Irregular disbursement of UGX 175,113,737 for NUSAF", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted Transfer from other Government units indicates", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Irregular disbursement of UGX 175,113,737 for NUSAF", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "387", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "of UGX. 1,073,044,082 more than the amount warrantied by"], [null, null, "Ugx. 224,945,899. The trial balance also indicate a figure of"], [null, null, "Ugx.1,194,065"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 400, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", null, "of UGX. 1,073,044,082 more than the amount warrantied by"], [null, null, "Ugx. 224,945,899. The trial balance also indicate a figure of"], [null, null, "Ugx.1,194,065"], [null, null, ""], [null, null, "\uf0b7 I noted Statement of Cash Flow indicates a total amount from"], [null, null, "operating, investing and financing activities as"], [null, null, "Ugx.17,850,462,341 while the payment file indicates it as"], [null, null, "Ugx.17,808,775,851 leading to an overstatement of Ugx."], [null, null, "41,686,490."], [null, null, ""], [null, null, "\uf0b7 I noted Unsupported receivables figure in the Statement Of"], [null, null, "Financial Position of UGX. 1,683,003,314 as there is no schedule"], [null, null, "of receivables attached to the financial statement."], [null, null, ""], ["04 Kaboong DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salaries worth UGX.12,181,796; failure to utilize wage funds of UGX. UGX.1.9billion.; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 9,870,780 I noted a number of issues in the implementation of the approved budget such; incomplete works; partial implementation of activities, under absorption of funds worth UGX.2.042Bn that was swept back to consolidated fund account; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines. \uf0b7 I noted under remittance of salaries worth UGX. 55,693,284 \uf0b7 The district mischarged expenditure worth UGX. 551,346,221 on wrong budget lines. \uf0b7 I noted 93 vacant positions at the district \uf0b7 I noted unbudgeted Funds from Ministry of Education and Sports to Kaabong DLG UGX.42,343,319 \uf0b7 I noted Irregular disbursement of NUSAF 3 Funds to M/S Agromax (U) Limited UGX.717,390,988", null, null], ["05", "Amudat DLG", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the district"], [null, "Opinion Unqualified", "pension & salary payrolls such as; Failure to submit wage"], [null, null, "estimates to MoPs, irregular deduction of loan instalments worth"], [null, "", "UGX.1,036,328; failure to utilize wage funds of UGX.0.851 billion"], [null, null, "un -deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX.6,432,420. and payment of two hundred two"], [null, null, "(222) staffs worth UGX.161,371,533 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete works; partial"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 400, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "388", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 400, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "implementation and quantified under absorption of funds worth"], [null, null, "UGX.4.3Bn that was swept back to consolidated fund account;"], [null, null, "under performance of the donor & releases from other"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 401, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["", null, "implementation and quantified under absorption of funds worth"], [null, null, "UGX.4.3Bn that was swept back to consolidated fund account;"], [null, null, "under performance of the donor & releases from other"], [null, null, "government units worth UGX.1,744,210,000; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 Over remittance of salaries worth UGX. 36,510,817"], [null, null, ""], [null, null, "\uf0b7 I further noted that all loan deductions relating to 7 employees"], [null, null, "did not have evidence of consent by the employees"], [null, null, "\uf0b7 UGX.101,273,688 was paid as residual arrears to 2 pensioners"], [null, null, "who had not been verified (and thus not part of schedule) by"], [null, null, "MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had not prepared and approved a"], [null, null, "strategic plan that is aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 I noted that district failed to recover worth UGX.390,319,125 of"], [null, null, "YLP funds"], [null, null, ""], [null, null, "\uf0b7 I noted that the district has outstanding balance worth"], [null, null, "UGX.390,319,125 from UWEP"], ["06 Kotido DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs; payment of salaries worth UGX.1,395,233 to two (2) staffs that was no longer in service. \uf0b7 Additionally, I observed that there was delayed access to payroll by thirty nine (39) new employees; failure to utilize wage funds of UGX.4.127billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.8, 766,597. \uf0b7 Under remittance of salary deduction worth UGX.18, 888,478. \uf0b7 I noted that the district has unauthorized loan deductions worth UGX.196,780,103 \uf0b7 I noted that the Kotido district did not have an approved strategic plan that is aligned to NDP-III by the time of audit. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete works; partial implementation and no quantified activities under absorption of funds worth UGX.1,291,391,337that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.1,603,270,000; delayed submission of quarterly monitoring reports to OPM & MoFPED", null, null], ["07", "Kotido MC", "\uf0b7 I noted a number of anomalies during review of the municipal"], ["", "", "council pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 401, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "389", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 401, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Opinion", "estimates to MoPs,; payment of salaries worth UGX.1,819,248 to"], [null, "Unqualified", "two (2) staffs that was no longer in service ; failure to utilize"], [null, "", "wage funds of UGX.0.8 billion.; un-deducted PAYE from political"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 402, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["", "Opinion", "estimates to MoPs,; payment of salaries worth UGX.1,819,248 to"], [null, "Unqualified", "two (2) staffs that was no longer in service ; failure to utilize"], [null, "", "wage funds of UGX.0.8 billion.; un-deducted PAYE from political"], [null, null, "leaders\u2019 gratuity resulting in unpaid tax of UGX.12,448,800 and"], [null, null, "payment of sixteen (16) staffs worth UGX.68,011,511 off the"], [null, null, "IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as;; incomplete works; partial"], [null, null, "implantation non quantified under absorption of funds worth"], [null, null, "UGX.211,565,285 873 that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX.1,089,757,389; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted Over payment of salaries worth UGX.882,243 to 25 staff"], [null, null, "arising from wrong scale"], [null, null, ""], [null, null, "\uf0b7 I noted under remittance of salaries worth UGX. 43,787,620"], [null, null, ""], [null, null, "\uf0b7 I noted that the Municipal Council has unauthorized loan"], [null, null, "deductions worth UGX.14.77 million"], [null, null, ""], [null, null, "\uf0b7 I noted that the municipal council had not prepared and"], [null, null, "approved a strategic plan that is aligned to the NDP-III at the"], [null, null, "time of audit."], [null, null, "\uf0b7 The municipal has un recovered UWEP funds worth"], [null, null, "UGX.277,734,805."], [null, null, ""], ["08 Karenga DLG Opinion Unqualified \uf0b7 I noted anomalies during review of the district pension & salary payrolls such as; seventy-three (73) vacant positions; failure to utilize wage funds of UGX.1.089Bn.; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.5,294,160 and payment of eight (8) staffs worth UGX. 28,433,650 off the IPPS; under remittance of employee salary deductions worth UGX.361,889,043 \uf0b7 I noted issues in the implementation of the approved budget such as; under absorption of funds worth UGX.636,616,391 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.4,959,037,208 \uf0b7 The DLG did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines \uf0b7 I noted that Karenga district did not include IPPS recurrent costs in its budget.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 402, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "390", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 402, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that the entity did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted un quantified, partially implemented and un implemented planned output \uf0b7 I noted underperformance of maintenance funds worth UGX.35,851,027 \uf0b7 I noted that administrative advances worth UGX.36,367,220 remained unaccounted for at year end", null, null], ["09", "Nakapiripirit DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 403, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["\uf0b7 I noted that the entity did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted un quantified, partially implemented and un implemented planned output \uf0b7 I noted underperformance of maintenance funds worth UGX.35,851,027 \uf0b7 I noted that administrative advances worth UGX.36,367,220 remained unaccounted for at year end", null, null], ["09", "Nakapiripirit DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, Over payment of salary worth"], [null, "Unqualified", "UGX.6,225,884; Underpayment of salary worth UGX."], [null, "", "120,957,229; pension worth UGX.102,547,496 and payment of"], [null, null, "residual arrears to 17 pensioners (not part of schedule) worth"], [null, null, "UGX.228,354,584"], [null, null, ""], [null, null, "\uf0b7 I noted outstanding receivables worth UGX.748,268,485 by year"], [null, null, "end"], [null, null, "\uf0b7 I noted outstanding payables worth UGX.204,060,122 by year"], [null, null, "end"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by four (4) new employees and five (5) pensioners; failure to"], [null, null, "utilize wage funds of UGX.0.8 Bn, un-deducted PAYE from"], [null, null, "political leaders\u2019 gratuity resulting in unpaid tax of"], [null, null, "UGX.11,064,133and payment of twenty-six (6) staff and two (2)"], [null, null, "pensioners worth UGX.67,526,067 off the IPPS; over/under"], [null, null, "remittance of employee salary deductions worth UGX.12,510,739"], [null, null, "and UGX.30,390,380 respectively"], [null, null, ""], [null, null, "\uf0b7 The DLG did not have an approved strategic plan that is aligned"], [null, null, "to the NDP-III at the time of audit"], [null, null, "\uf0b7 I noted partially quantified, partially implemented and un"], [null, null, "implemented planned output"], [null, null, ""], [null, null, "\uf0b7 I noted issues in the implementation of the approved budget"], [null, null, "such as; under absorption of funds worth UGX.387,179,529 that"], [null, null, "was swept back to consolidated fund account; under"], [null, null, "performance of the donor & releases from other government"], [null, null, "units worth UGX.3,798,701,446;"], [null, null, ""], [null, null, "\uf0b7 I noted that the district did not prepare monthly wage, pension"], [null, null, "and gratuity performance analysis and thus did not submit"], [null, null, "quarterly returns on payroll to MoPS"], [null, null, "\uf0b7 ."], [null, null, "\uf0b7 I noted that funds to the tune of UGX.37,212,320 were"], [null, null, "irregularly diverted from the activities on which they were"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 403, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "391", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 403, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "budgeted and spent on other activities without seeking and"], [null, null, "obtaining the necessary approvals."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 404, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["", null, "budgeted and spent on other activities without seeking and"], [null, null, "obtaining the necessary approvals."], [null, null, ""], [null, null, "\uf0b7 Irregularities in evaluation and award of contract to Ramiram"], [null, null, "Company Ltd for the construction of a teachers\u2019 house in Doo"], [null, null, "Primary under procurement reference NAKP543/WRKS/20-"], [null, null, "21/00003"], [null, null, "\uf0b7 The district entered into a VAT exclusive contract with Bole"], [null, null, "Engineering Ltd (TIN:) vide NAKP543/WRKS/20-21/00005 worth"], [null, null, "UGX.55,000,000 despite the company being registered for VAT"], ["10 Moroto MC Opinion Unqualified \uf0b7 I noted anomalies during review of the Municipal pension & salary payrolls such as; Failure to submit wage estimates to MoPs Underpayment of salary worth UGX. 359,225; \uf0b7 Additionally, I observed that there was delayed access to payroll by two (2) pensioners; failure to utilize wage funds of UGX.0.32 Bn; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.3,314,340 over/under remittance of employee salary deductions worth UGX.5,297,009 and under UGX.1,329,429 respectively \uf0b7 The MC did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 I noted issues in the implementation of the approved budget such as; under performance of the donor & releases from other government units worth UGX. 439,621,456; un quantified planned output \uf0b7 I noted that the Municipal Council did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS . \uf0b7 I noted that Expenditure amounting to UGX.40,544,000 remained unsupported as at the close of the financial year", null, null], ["11", "Nabilatuk DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, Over payment of salary worth"], [null, "Unqualified", "UGX.41,886,731; Underpayment of salary worth UGX.88,251,765"], [null, "", "irregular deduction of loan instalments of twenty-seven (27)"], [null, null, "employees worth UGX.32,111,398 and excess loan deductions for"], [null, null, "eighteen (18) employees worth UGX.23,960,268"], [null, null, ""], [null, null, "\uf0b7 I noted payments to non-existent staff worth UGX.12,263,143"], [null, null, ""], [null, null, "\uf0b7 I noted over/under remittance of employee salary deductions"], [null, null, "worth UGX.22,136,522 and UGX.28,681,822 respectively"], [null, null, ""], [null, null, "\uf0b7 I noted outstanding receivables worth UGX.306,557,669."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by twenty-seven (27) new employees; failure to utilize wage"], [null, null, "funds of UGX.0.766 Bn; un-deducted PAYE from political leaders\u2019"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 404, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "392", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 404, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "gratuity resulting in unpaid tax of UGX.111,240 and payment of"], [null, null, "thirty-five (35) staff pensioners worth UGX.52,863,034 off the"], [null, null, "IPPS and residual arrears to two (2) staff UGX.3,128,128"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 405, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["", null, "gratuity resulting in unpaid tax of UGX.111,240 and payment of"], [null, null, "thirty-five (35) staff pensioners worth UGX.52,863,034 off the"], [null, null, "IPPS and residual arrears to two (2) staff UGX.3,128,128"], [null, null, ""], [null, null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; un implemented works on construction"], [null, null, "of Nataparengan piped water system and rehabilitation of"], [null, null, "Lorukumo piped water system; under absorption of funds worth"], [null, null, "UGX.353,461,659 that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX.686,812,859;"], [null, null, ""], [null, null, "\uf0b7 I noted partially quantified and partially implemented planned"], [null, null, "output"], [null, null, ""], [null, null, "\uf0b7 I noted that the district did not prepare monthly wage, pension"], [null, null, "and gratuity performance analysis and thus did not submit"], [null, null, "quarterly returns on payroll to MoPS"], [null, null, ""], [null, null, "\uf0b7 I noted that Nabilatuk District received off-budget financing to a"], [null, null, "tune of UGX.12,464,800 directly from the Drylands Projects"], ["Mbale Branch Summary of Key Findings", null, null], ["01", "Bulambuli DLG", "\uf0b7 I noted a number of anomalies during review of the DLG pension"], ["", "", "& salary payrolls such as; delay to submit wage estimates to"], [null, "Opinion Unqualified", "MoPs; Underpayment of payroll worth UGX.53, 413,352; Wrong"], [null, null, "computation of gratuity worth net overpayment of UGX."], [null, "", "4,908,163 and payment of salaries worth UGX.799, 094 to one"], [null, null, "(1) staff that was no longer in service."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had receivables worth UGX 865,908,605"], [null, null, "and had Payables worth UGX.5,000,000 at close of financial year"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was failure to utilize wage"], [null, null, "funds of UGX.1.6Bn; un-deducted PAYE from political leaders\u2019"], [null, null, "gratuity resulting in unpaid tax of UGX.16,798,690and payment"], [null, null, "of nine (9) pensioners worth UGX.170,017,059 off the IPPS;"], [null, null, "partially implemented output worth UGX. 0.863Bn and un"], [null, null, "implemented output worth UGX.0.558Bn"], [null, null, ""], [null, null, "\uf0b7 I noted that the District LG did not prepare monthly wage,"], [null, null, "pension and gratuity performance analysis report for submission"], [null, null, "to MoPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; shoddy works at Bumugusha - Sisiyi"], [null, null, "Road, Gimayote - Malama Road, the boreholes; incomplete works"], [null, null, "on Buyaga-Muyembe road, Bulaago and Bwikhonge Health"], [null, null, "Centre IIs to IIIs; under absorption of funds worth"], [null, null, "UGX.2,653,035,652 that was swept back to consolidated fund"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 405, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "393", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 405, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "account; under performance of the donor & releases from other"], [null, "government units worth UGX.234,118787; non submission of"], [null, "quarterly monitoring reports to OPM & MoFPED; delayed"], [null, "submission of performance reports and unremitted lower local"], [null, "government revenue worth UGX 47,216,000"], [null, ""], [null, "\uf0b7 The District mischarged expenditure worth UGX 103,936,059 on"], [null, "wrong budget lines."], [null, ""], [null, "\uf0b7 I observed that key positions, including that of District engineer,"], [null, "District production officer, District education officer, and District"], [null, "planner had remained vacant by end of year."], [null, ""], [null, "\uf0b7 I noted drug stock out at Bulaago Health Centre"], [null, ""], [null, "\uf0b7 I observed that the district lacked vital road equipment such as:"], [null, "Motor Grader, Wheel Loader, Bulldozer, Excavator and Cargo"], [null, "Truck"], [null, ""], [null, "\uf0b7 I noted an Under-deduction of LST worth UGX 214,800,000 and"], [null, "PAYE worth UGX 32,139,829."], [null, ""], ["02 Manafwa DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the DLG pension & salary payrolls such as; failure to submit wage estimates to MoPs, over payment of salaries worth UGX. 14,044,594; Underpayment of salaries worth UGX. 10,735,580; Wrong computation of gratuity worth net overpayment of UGX. 14,474,704 \uf0b7 I noted an over and under remittance of employee salary deductions worth UGX 129,973,902 \uf0b7 I observed that there was failure to utilize wage funds worth UGX.0.890 billion \uf0b7 I noted under deduction of PAYE from employee salary worth UGX. 20,600,350. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX. 2,423,640,138 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.2,041,524,555; delayed submission of quarterly monitoring reports to OPM & MoFPED; partial implementation of planned activities and under performance of funds meant for maintenance worth UGX. 7,252,593 \uf0b7 The DLG mischarged expenditure worth UGX. 476,473,064 on wrong budget lines \uf0b7 I however noted that UGX. 2,521,572 was paid as residual arrears to 10 staff and 2 pensioners who had not been verified (and thus not part of schedule) by MoFPED.", null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 406, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "394", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 406, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that 2 employees were paid a total of UGX. 7,461,459 without signed pay change reports. \uf0b7 I noted that the DLG did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted outstanding payables worth UGX. 1,239,952,064.", null, null], ["03", "TORORO DLG", "\uf0b7 I noted a number of anomalies during review of the DLG pension"], ["", "", "& salary payrolls such as; Failure to submit wage estimates to"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 407, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["\uf0b7 I noted that 2 employees were paid a total of UGX. 7,461,459 without signed pay change reports. \uf0b7 I noted that the DLG did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted outstanding payables worth UGX. 1,239,952,064.", null, null], ["03", "TORORO DLG", "\uf0b7 I noted a number of anomalies during review of the DLG pension"], ["", "", "& salary payrolls such as; Failure to submit wage estimates to"], [null, "OPINION: UNQUALIFIED", "MoPs, over payment of salaries worth UGX.4,068,031;"], [null, null, "Underpayment of salaries worth UGX.15,716,191 and payment of"], [null, "", "salaries worth UGX.57,446,500 to staffs that was no longer in"], [null, null, "service accrued pension worth UGX.47,240,461"], [null, null, ""], [null, null, "\uf0b7 I noted an over and under remittance of employee salary"], [null, null, "deductions worth UGX.6,208,787"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by one hundred seventeen (117) new employees; failure to"], [null, null, "utilize wage funds of UGX.2.18 Bn, un-deducted PAYE from"], [null, null, "political leaders\u2019 gratuity resulting in unpaid tax of UGX."], [null, null, "11,370,060 and payment of four (4) staffs worth UGX 3,683,801"], [null, null, "off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; failure to quantify planned output;"], [null, null, "partial and non- implementation of planned activities; under"], [null, null, "absorption of funds worth UGX. 2,597,410,656 that was swept"], [null, null, "back to consolidated fund account; under performance of the"], [null, null, "donor & releases from other government units worth UGX."], [null, null, "11.87Bn."], [null, null, ""], [null, null, "\uf0b7 The DLG mischarged expenditure worth UGX.45,068,279 on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 I noted that the DLG did not prepare monthly wage, pension and"], [null, null, "gratuity performance analysis reports and did not submit"], [null, null, "quarterly returns on payroll to MoPS"], [null, null, ""], [null, null, "\uf0b7 I noted payables worth UGX.335, 571,661 outstanding at year"], [null, null, "end."], ["04 MBALE CITY OPINION: Unqualified \uf0b7 I noted a number of anomalies during review of the city pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salary and pension worth UGX.810,144,208; Underpayment of salary and pension worth UGX.915,374,687; Wrong computation of salaries worth net overpayment of UGX.91,569,052; payment of salaries worth UGX 30,376,995 to twenty six (26) staffs that were no longer in service and irregular deduction of loan instalments of one hundred seventeen (117) worth UGX. 159,385,584. \uf0b7 I noted receivables from other UWEP, YLP and other debtors", null, null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 407, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "395", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 407, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["worth UGX. 2,239,688,779 by the close of the financial year under review. \uf0b7 I noted outstanding payables worth UGX 545,408,158 at the end of the financial year. \uf0b7 The city did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 Additionally, I observed failure to utilize wage funds of UGX. 1,235,588,920; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.3,015,540and payment of staffs and pensioners worth UGX.161,000,660 off the IPPS; unpaid salaries worth UGX.161,000,660; payment of consolidated health lunch allowance to ineligible staff worth UGX.2,170,750 and a net over payment of arrears of UGX.64,535,832 \uf0b7 I noted an over and under deduction of loans worth UGX.13,477,848 and UGX.14,453,773 respectively \uf0b7 I noted that the city did not prepare monthly wage, pension and gratuity performance analysis and did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial and unquantified planned output, partial and non-implemented planned output ; shoddy works on Nambozo road incomplete works on Nambozo road; under absorption of funds worth UGX.1,600,759,501 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.3.17Bn; over absorption of funds worth UGX 73,268,000 \uf0b7 The city mischarged expenditure worth UGX 65,785,703 on wrong budget line \uf0b7 I noted non regular maintenance of street lights", null, null], ["05", "Bukwo DLG", "\uf0b7 I noted a number of anomalies during review of the DLG pension"], ["", "", "& salary payrolls such as; Failure to submit wage estimates to"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 408, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["worth UGX. 2,239,688,779 by the close of the financial year under review. \uf0b7 I noted outstanding payables worth UGX 545,408,158 at the end of the financial year. \uf0b7 The city did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 Additionally, I observed failure to utilize wage funds of UGX. 1,235,588,920; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.3,015,540and payment of staffs and pensioners worth UGX.161,000,660 off the IPPS; unpaid salaries worth UGX.161,000,660; payment of consolidated health lunch allowance to ineligible staff worth UGX.2,170,750 and a net over payment of arrears of UGX.64,535,832 \uf0b7 I noted an over and under deduction of loans worth UGX.13,477,848 and UGX.14,453,773 respectively \uf0b7 I noted that the city did not prepare monthly wage, pension and gratuity performance analysis and did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial and unquantified planned output, partial and non-implemented planned output ; shoddy works on Nambozo road incomplete works on Nambozo road; under absorption of funds worth UGX.1,600,759,501 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.3.17Bn; over absorption of funds worth UGX 73,268,000 \uf0b7 The city mischarged expenditure worth UGX 65,785,703 on wrong budget line \uf0b7 I noted non regular maintenance of street lights", null, null], ["05", "Bukwo DLG", "\uf0b7 I noted a number of anomalies during review of the DLG pension"], ["", "", "& salary payrolls such as; Failure to submit wage estimates to"], [null, "Opinion", "MoPs, Over payment of salary worth UGX.4,296,996;"], [null, "Unqualified", "Underpayment of salary, gratuity and pension worth"], [null, "", "UGX.16,337,404 and delayed deletion of 4 staff from the payroll"], [null, null, "worth UGX.9,328,845"], [null, null, ""], [null, null, "\uf0b7 I noted that the district did not prepare monthly wage, pension"], [null, null, "and gratuity performance analysis and thus did not submit"], [null, null, "quarterly returns on payroll to MoPS"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by 0ne (1) new employee and nine (2) pensioners; failure to"], [null, null, "utilize wage funds of UGX.0.568 billion; un-deducted PAYE from"], [null, null, "political leaders\u2019 gratuity resulting in unpaid tax of"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 408, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "396", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 408, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "UGX.11,064,570 over and under remittance of employee salary"], [null, "deductions worth UGX.1,789,798 and UGX.14,974,441"], [null, "respectively"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; delayed works at the HCIIs; under"], [null, "absorption of funds worth UGX.2,421,073,740 that was swept"], [null, "back to consolidated fund account; under performance of the"], [null, "donor & releases from other government units worth"], [null, "UGX.6,333,457,050; partial and un quantified planned output"], [null, "and partial and un implemented planned output"], [null, ""], [null, "\uf0b7 The district did not prepare annual monitoring plans neither were"], [null, "quarterly monitoring reports prepared and submitted."], [null, ""], [null, "\uf0b7 I noted underperformance of budgeted funds for NUSAF-3"], [null, "projects worth UGX.183,000,000 and URF funds worth"], [null, "UGX.10,265,009 that affected implementation of the programs"], [null, ""], [null, "\uf0b7 I observed that the district lacked vital road equipment like an"], [null, "excavator, a bulldozer, a pedestrian roller and tampers/rammers."], [null, ""], [null, "\uf0b7 I noted an under absorption of funds worth UGX 1,005,458,204"], [null, "relating to construction of the college, secondary school and"], [null, "upgrading of HCIIs"], [null, ""], [null, "\uf0b7 The district lacked titles for 36 pieces of its land."], ["06 Sironko DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salary worth UGX.3,937,076; Underpayment of salary worth UGX.9,336,463 delayed deletion of 3 staff from the payroll worth UGX.2,418,531 and 365 positions vacant \uf0b7 I noted residual arrear payments to one (1) pensioner who was not on the schedule worth UGX.25,856,920 \uf0b7 I noted outstanding receivables worth UGX.1, 395,021,574 and payables worth UGX.1, 271,747,912 by the end of the year. \uf0b7 Additionally, I observed that there was delayed access to payroll by nineteen (19) new employees and two (2) pensioners; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.13,980,570 over/under remittance of employee salary deductions worth UGX.12,620,619 and UGX.18,207,521 respectively \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 I noted partial and unquantified planned output, partial and non- implemented planned output", null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 409, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "397", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 409, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted issues in the implementation of the approved budget such as; delayed works at Buyobo Health Centre, Buteeza/Bumirisa Seed Secondary School; under performance of the donor & releases from other government units worth UGX.31,073,887; \uf0b7 The district lacked land tittles for 14 of its properties \uf0b7 I noted that the district did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted Un recovered YLP/Women groups funds worth UGX 1,076,861,319", null, null], ["07", "Namisidwa DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 410, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["\uf0b7 I noted issues in the implementation of the approved budget such as; delayed works at Buyobo Health Centre, Buteeza/Bumirisa Seed Secondary School; under performance of the donor & releases from other government units worth UGX.31,073,887; \uf0b7 The district lacked land tittles for 14 of its properties \uf0b7 I noted that the district did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted Un recovered YLP/Women groups funds worth UGX 1,076,861,319", null, null], ["07", "Namisidwa DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, payment of salaries worth UGX.9,737,931 to"], [null, "UnQualified", "twelve (12) staffs that were no longer in service over/under"], [null, "", "remittances of employee salary deductions worth"], [null, null, "UGX.15,456,000 and UGX.9,368,000 respectively"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by eleven (11) pensioners; failure to utilize wage funds of"], [null, null, "UGX.1.8 billion; un-deducted PAYE from political leaders\u2019 gratuity"], [null, null, "resulting in unpaid tax of UGX.10,343,040 and payment of"], [null, null, "twenty twelve (12) staffs worth UGX.44,528,289 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to Construct Namboko Seed"], [null, null, "Secondary School ; delayed works of Mukoto Seed Secondary"], [null, null, "School ; under absorption of funds worth UGX.1,965,728,111"], [null, null, "that was swept back to consolidated fund account; under"], [null, null, "performance of the donor & releases from other government"], [null, null, "units worth UGX.639,520,961; delayed submission of quarterly"], [null, null, "monitoring reports to OPM & MoFPED; Un implemented"], [null, null, "procurement plan worth UGX 2,601,160,000 and"], [null, null, "Underperformance of maintenance funds worth UGX.27,667,500."], [null, null, ""], [null, null, "\uf0b7 District received off-budget financing worth UGX.153,248,760"], [null, null, "directly from Ministry of Health (MoH)"], [null, null, ""], [null, null, "\uf0b7 I noted outstanding receivables worth UGX 1,380,786,175"], [null, null, ""], [null, null, "\uf0b7"], [null, null, "\uf0b7 The entity did not prepare and submit the annual monitoring"], [null, null, "plans to Moped, MoLG and NPA as required."], [null, null, "\uf0b7 I noted Underperformance of UWEP/YLP funds worth of"], [null, null, "UGX.170,000,000"], [null, null, "\uf0b7 I noted district land lacked titles"], ["08 Bududa DLG \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage", null, null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 410, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "398", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 410, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Unqualified estimates to MoPs, over payment of salary worth UGX. 40,955,029 Underpayment of salary due to wrong salary scales worth UGX 1,770,196 and Wrong computation of gratuity worth net overpayment of UGX. 16,342,974; \uf0b7 I noted payment to twelve (12) employees without signed pay change reports worth UGX. 33,563,249 \uf0b7 Additionally, I observed that there was; failure to utilize wage funds of UGX.0.386 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 25,271,520; over/under remittance of employee salary deductions wort UGX. 374,322,700 and UGX. 2,544,986 respectively and residual arrears to 10 staff and 5 pensioners (not part of schedule) worth UGX. 53,269,453 \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete works on five Community Access Roads (CARs); under absorption of funds worth UGX. 3,358,629,901 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.12,509,500; Under performance of maintenance funds worth UGX. 2,807,020 and un implemented procurement plan worth UGX.357,489,000 \uf0b7 I noted an under absorption of preliminary expenditures worth UGX 327,911,000 \uf0b7 I noted partial and non-implemented planned output \uf0b7 The district mischarged expenditure worth UGX. 53,269,453 on wrong budget lines. \uf0b7 It was noted that the district did not conduct revenue assessment. \uf0b7 I noted that the lacked District signed MOUs for Donor funds received during the year worth UGX. 25,203,300 from United Nations Children Fund (UNICEF) and World Health Organization (WHO).", null, null], ["09", "KIBUKU DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Underpayment of pension"], [null, "Opinion", "worth UGX.97,316,845.; payment of salaries worth"], [null, "Unqualified", "UGX.7,336,993 to fourteen (14) staffs that was no longer in"], [null, "", "service and over remittance of employee salary deductions"], [null, null, "UGX.430,578,979"], [null, null, ""], [null, null, "\uf0b7 I noted outstanding payables worth UGX 128,739,122 at year"], [null, null, "end."], [null, null, ""], [null, null, "\uf0b7 I observed that there was delayed access to payroll by twenty-"], [null, null, "seven (27) new employees and nineteen (19) pensioners and"], [null, null, "420 vacant staff positions"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 411, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "399", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 411, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; I noted partial and unquantified"], [null, null, "planned output, partial and non-implemented planned output;"], [null, null, "under absorption of funds worth UGX 5,639,972,053 that was"], [null, null, "swept back to consolidated fund account; under performance of"], [null, null, "the donor & releases from other government units worth"], [null, null, "UGX.789,212,932 and failed submission of quarterly monitoring"], [null, null, "reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.47,252,328 on"], [null, null, "wrong budget lines"], [null, null, ""], [null, null, "\uf0b7 I noted that Kibuku Health Centre IV experienced drug stock outs"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity failed to procure assorted medical"], [null, null, "equipment for upgraded HCs worth UGX.210,937,500"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity failed to conduct pre-bid meetings for 23"], [null, null, "contracts as provided for in the tender documents"], [null, null, "\uf0b7 I noted unrecovered funds from Women groups worth"], [null, null, "UGX.522,692,690"], ["ARUA BRANCH Summary of Key Findings", null, null], ["01.", "Obongi DLG", "\uf0b7 I reviewed funds absorption and noted that UGX.4.6 billion (100%) was spent out of the total receipts of UGX.5.9 billion,"], ["", "", null], [null, "Opinion", null], [null, "Unqualified", "resulting in an unabsorbed balance of UGX.1.3 billion. The unabsorbed balance was subsequently swept back to the"], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 412, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "400", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 412, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "following;"], [null, "\uf0b7 The Entity budgeted to receive UGX.17,548,360,000 as transfers"], [null, "from other Government Units. However, only"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 413, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["", "following;"], [null, "\uf0b7 The Entity budgeted to receive UGX.17,548,360,000 as transfers"], [null, "from other Government Units. However, only"], [null, "UGX.14,007,769,263 (80%) was received. The Accounting Officer"], [null, "explained that low Local Revenue performance was due to the"], [null, "effects of COVID 19 lockdown that affected the performance of"], [null, "markets and secondly the disaster of floods impacted negatively"], [null, "on our major source of revenue, fisheries where most landing"], [null, "sites were flooded."], [null, "\uf0b7 The Entity budgeted to receive UGX.17,548,360,000 as transfers"], [null, "from other Government Units. However, only"], [null, "UGX.14,007,769,263 (80%) was received. The Accounting Officer"], [null, "explained that The under-performance of other government"], [null, "transfers was due to low performance of DRDIP. The funding for"], [null, "DRDIP was only for approved sub projects which were generated"], [null, "by the beneficiary groups."], [null, "\uf0b7 The District budgeted to receive UGX. 655,424,300 as"], [null, "external/donor financing out of which UGX.630,174,440 (96 %),"], [null, "was receivedThe Accounting Officer explained that External"], [null, "Financing performed very well up to 96% and all planned"], [null, "activities were implemented as planned. The difference of only"], [null, "4% has had no impact the implementation of the planned"], [null, "activities"], [null, "\uf0b7 Out of the total receipts for the financial year of"], [null, "UGX.27,315,767,447, UGX.42,423,071,166 (92%) was spent by"], [null, "the entity resulting in an unspent balance of UGX."], [null, "22,056,617,661 (81%). The unspent balance at the end of the"], [null, "financial year was subsequently swept back to the consolidated"], [null, "fund account. I advised the Accounting Officer to ensure that"], [null, "funds for these activities are in subsequent year un implemented"], [null, "activities rolled over and subsequently ensure the speedy"], [null, "implementation."], [null, "\uf0b7 I noted that the District received a total of UGX.22,103,714 as"], [null, "capitation grant. I reviewed the bank statements sampled"], [null, "schools and noted that the funds were still on the school"], [null, "accounts by 30th September, 2021 and had hence not been"], [null, "utilized. I advised the Accounting Officer to liaise with relevant"], [null, "authorities and ensure that these funds are put to productive"], [null, "usage."], ["02\\. ZOMBO DLG Opinion Unqualified \uf0b7 I reviewed funds absorption and noted that UGX.12.35 billion (81.78%) was spent out of the total receipts of UGX.15.1 billion, resulting in an unabsorbed balance of UGX.2.75 billion. The unabsorbed balance was subsequently swept back to the consolidated fund account. \uf0b7 A comparison of base pay in the IPPS payroll registers with the salary structure for 2020/21, revealed that 23 staff were paid", null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 413, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "401", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 413, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "using wrong salary scales, leading to under payments of UGX", "metadata": {"headings": [{"headings_0": {"content": "using wrong salary scales, leading to under payments of UGX", "page": 414, "level": 3}}, {"headings_1": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "0.932 million, contrary to Section B\u2013a (6) & (7) of the Uganda", "metadata": {"headings": [{"headings_0": {"content": "using wrong salary scales, leading to under payments of UGX", "page": 414, "level": 3}}, {"headings_1": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Public Service Standing Orders, 2010.", "metadata": {"headings": [{"headings_0": {"content": "Public Service Standing Orders, 2010.", "page": 414, "level": 3}}, {"headings_1": {"content": "using wrong salary scales, leading to under payments of UGX", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that UGX.20,116,483 was paid to 12 staff who had either retired, transferred, absconded or died. I advised the Accounting Officer to ensure prompt removal of staff from the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.20,116,483 was paid to 12 staff who had either retired, transferred, absconded or died. I advised the Accounting Officer to ensure prompt removal of staff from the", "page": 414, "level": 3}}, {"headings_1": {"content": "Public Service Standing Orders, 2010.", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "payroll.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.20,116,483 was paid to 12 staff who had either retired, transferred, absconded or died. I advised the Accounting Officer to ensure prompt removal of staff from the", "page": 414, "level": 3}}, {"headings_1": {"content": "Public Service Standing Orders, 2010.", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.3,328,551,409 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.20,116,483 was paid to 12 staff who had either retired, transferred, absconded or died. I advised the Accounting Officer to ensure prompt removal of staff from the", "page": 414, "level": 3}}, {"headings_1": {"content": "Public Service Standing Orders, 2010.", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.20,116,483 was paid to 12 staff who had either retired, transferred, absconded or died. I advised the Accounting Officer to ensure prompt removal of staff from the", "page": 414, "level": 3}}, {"headings_1": {"content": "Public Service Standing Orders, 2010.", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.3,319,064,736 was remitted, leading to an over and/or", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.3,319,064,736 was remitted, leading to an over and/or", "page": 414, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.20,116,483 was paid to 12 staff who had either retired, transferred, absconded or died. I advised the Accounting Officer to ensure prompt removal of staff from the", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "under remittance amounting to UGX.7,357,520 and UGX", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.3,319,064,736 was remitted, leading to an over and/or", "page": 414, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.20,116,483 was paid to 12 staff who had either retired, transferred, absconded or died. I advised the Accounting Officer to ensure prompt removal of staff from the", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "6,415,791 respectively. The Accounting Officer explained that the", "metadata": {"headings": [{"headings_0": {"content": "6,415,791 respectively. The Accounting Officer explained that the", "page": 414, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.3,319,064,736 was remitted, leading to an over and/or", "page": 414, "level": 2}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "underpayment would be paid during subsequent remittances.", "metadata": {"headings": [{"headings_0": {"content": "6,415,791 respectively. The Accounting Officer explained that the", "page": 414, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.3,319,064,736 was remitted, leading to an over and/or", "page": 414, "level": 2}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX 680 million. The deductions were from 461", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX 680 million. The deductions were from 461", "page": 414, "level": 3}}, {"headings_1": {"content": "6,415,791 respectively. The Accounting Officer explained that the", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "employees that neither had letters of undertaking nor existed in", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX 680 million. The deductions were from 461", "page": 414, "level": 3}}, {"headings_1": {"content": "6,415,791 respectively. The Accounting Officer explained that the", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "metadata": {"headings": [{"headings_0": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 414, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX 680 million. The deductions were from 461", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "PDMS-Payroll Deduction Management System, operated by PCA- Payroll Consults Africa.", "metadata": {"headings": [{"headings_0": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 414, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX 680 million. The deductions were from 461", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 13 newly recruited/ transferred employees delayed", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 13 newly recruited/ transferred employees delayed", "page": 414, "level": 3}}, {"headings_1": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 414, "level": 2}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "to access payroll, with delays ranging between 1-2 months.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 13 newly recruited/ transferred employees delayed", "page": 414, "level": 3}}, {"headings_1": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 414, "level": 2}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Delayed access to payroll leads to demotivation of the affected", "metadata": {"headings": [{"headings_0": {"content": "Delayed access to payroll leads to demotivation of the affected", "page": 414, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 13 newly recruited/ transferred employees delayed", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "staff and accumulation of salary arrears.", "metadata": {"headings": [{"headings_0": {"content": "Delayed access to payroll leads to demotivation of the affected", "page": 414, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 13 newly recruited/ transferred employees delayed", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "page": 414, "level": 3}}, {"headings_1": {"content": "Delayed access to payroll leads to demotivation of the affected", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the pension payroll leads to poor wellbeing of the affected retirees as well as accumulation of pension arrears. \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "page": 414, "level": 3}}, {"headings_1": {"content": "Delayed access to payroll leads to demotivation of the affected", "page": 414, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "page": 414, "level": 3}}, {"headings_1": {"content": "Delayed access to payroll leads to demotivation of the affected", "page": 414, "level": 3}}]], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that there were variances of UGX.263,261,431", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "page": 414, "level": 3}}, {"headings_1": {"content": "Delayed access to payroll leads to demotivation of the affected", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "between the figures in the MoPS IPPS and district payroll registers. I advised the Accounting Officer to ensure that the district IPPS payroll registers are consistent with MoPS payroll", "metadata": {"headings": [{"headings_0": {"content": "between the figures in the MoPS IPPS and district payroll registers. I advised the Accounting Officer to ensure that the district IPPS payroll registers are consistent with MoPS payroll", "page": 414, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "data. \n", "metadata": {"headings": [{"headings_0": {"content": "between the figures in the MoPS IPPS and district payroll registers. I advised the Accounting Officer to ensure that the district IPPS payroll registers are consistent with MoPS payroll", "page": 414, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "page": 414, "level": 3}}, [{"headings_0": {"content": "between the figures in the MoPS IPPS and district payroll registers. I advised the Accounting Officer to ensure that the district IPPS payroll registers are consistent with MoPS payroll", "page": 414, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "page": 414, "level": 3}}]], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Included in the Statement of Financial Position on page 7 of the Financial Statements are receivables worth UGX.485,694,634 as", "metadata": {"headings": [{"headings_0": {"content": "between the figures in the MoPS IPPS and district payroll registers. I advised the Accounting Officer to ensure that the district IPPS payroll registers are consistent with MoPS payroll", "page": 414, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "supported by Note 19 to the financial statements. The amount for the previous financial year was UGX.193,836,559. The amounts relate to advances to Youth and Women Interest groups. I advised the Accounting Officer to continue sensitizing Youth Interest Groups and women groups to recover the funds.", "metadata": {"headings": [{"headings_0": {"content": "supported by Note 19 to the financial statements. The amount for the previous financial year was UGX.193,836,559. The amounts relate to advances to Youth and Women Interest groups. I advised the Accounting Officer to continue sensitizing Youth Interest Groups and women groups to recover the funds.", "page": 414, "level": 3}}, {"headings_1": {"content": "between the figures in the MoPS IPPS and district payroll registers. I advised the Accounting Officer to ensure that the district IPPS payroll registers are consistent with MoPS payroll", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the District had deposits worth UGX.396,301,510 presented in the Statement of Financial Position and disclosed in note 25 to the financial statements. The figure increased by", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District had deposits worth UGX.396,301,510 presented in the Statement of Financial Position and disclosed in note 25 to the financial statements. The figure increased by", "page": 414, "level": 3}}, {"headings_1": {"content": "supported by Note 19 to the financial statements. The amount for the previous financial year was UGX.193,836,559. The amounts relate to advances to Youth and Women Interest groups. I advised the Accounting Officer to continue sensitizing Youth Interest Groups and women groups to recover the funds.", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.4,000,000 from UGX.394,301,510 which were recoveries of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District had deposits worth UGX.396,301,510 presented in the Statement of Financial Position and disclosed in note 25 to the financial statements. The figure increased by", "page": 414, "level": 3}}, {"headings_1": {"content": "supported by Note 19 to the financial statements. The amount for the previous financial year was UGX.193,836,559. The amounts relate to advances to Youth and Women Interest groups. I advised the Accounting Officer to continue sensitizing Youth Interest Groups and women groups to recover the funds.", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "the Youth Livelihood Programme (YLP) as recommended by", "metadata": {"headings": [{"headings_0": {"content": "the Youth Livelihood Programme (YLP) as recommended by", "page": 414, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District had deposits worth UGX.396,301,510 presented in the Statement of Financial Position and disclosed in note 25 to the financial statements. The figure increased by", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Inspectorate of Government.", "metadata": {"headings": [{"headings_0": {"content": "the Youth Livelihood Programme (YLP) as recommended by", "page": 414, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District had deposits worth UGX.396,301,510 presented in the Statement of Financial Position and disclosed in note 25 to the financial statements. The figure increased by", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that though the district had prepared the Strategic plan,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that though the district had prepared the Strategic plan,", "page": 414, "level": 3}}, {"headings_1": {"content": "the Youth Livelihood Programme (YLP) as recommended by", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "402 \nit was still in draft form at the time of audit and certification from", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that though the district had prepared the Strategic plan,", "page": 414, "level": 3}}, {"headings_1": {"content": "the Youth Livelihood Programme (YLP) as recommended by", "page": 414, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that though the district had prepared the Strategic plan,", "page": 414, "level": 3}}, {"headings_1": {"content": "the Youth Livelihood Programme (YLP) as recommended by", "page": 414, "level": 3}}]], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "NPA had not been obtained. I advised the Accounting Officer to liaise with NPA to expedite the process of reviewing and approval", "metadata": {"headings": [{"headings_0": {"content": "NPA had not been obtained. I advised the Accounting Officer to liaise with NPA to expedite the process of reviewing and approval", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that though the district had prepared the Strategic plan,", "page": 414, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the Strategic Plan of the District.", "metadata": {"headings": [{"headings_0": {"content": "NPA had not been obtained. I advised the Accounting Officer to liaise with NPA to expedite the process of reviewing and approval", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that though the district had prepared the Strategic plan,", "page": 414, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 415, "level": 3}}, {"headings_1": {"content": "NPA had not been obtained. I advised the Accounting Officer to liaise with NPA to expedite the process of reviewing and approval", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.1,040,800,000 during the year but collected UGX.296,535,563 representing (29%) performance. The", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 415, "level": 3}}, {"headings_1": {"content": "NPA had not been obtained. I advised the Accounting Officer to liaise with NPA to expedite the process of reviewing and approval", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "shortfalls in Local Revenue collections of UGX.744,264,437 (71%) were recorded in Local Service Tax, Land Fees , Business Licence, other tax revenues, administrative fees and Application Fees.", "metadata": {"headings": [{"headings_0": {"content": "shortfalls in Local Revenue collections of UGX.744,264,437 (71%) were recorded in Local Service Tax, Land Fees , Business Licence, other tax revenues, administrative fees and Application Fees.", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- The District budgeted to receive UGX. 1,426,989,000 as external/donor financing out of which UGX.1,304,944 (0.09%), was received.", "metadata": {"headings": [{"headings_0": {"content": "shortfalls in Local Revenue collections of UGX.744,264,437 (71%) were recorded in Local Service Tax, Land Fees , Business Licence, other tax revenues, administrative fees and Application Fees.", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "shortfalls in Local Revenue collections of UGX.744,264,437 (71%) were recorded in Local Service Tax, Land Fees , Business Licence, other tax revenues, administrative fees and Application Fees.", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 Out of the total receipts for the financial year of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 415, "level": 3}}, {"headings_1": {"content": "shortfalls in Local Revenue collections of UGX.744,264,437 (71%) were recorded in Local Service Tax, Land Fees , Business Licence, other tax revenues, administrative fees and Application Fees.", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.28,843,895,403, UGX.25,055,771,226 (97%) was spent by the district resulting in an unspent balance of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 415, "level": 3}}, {"headings_1": {"content": "shortfalls in Local Revenue collections of UGX.744,264,437 (71%) were recorded in Local Service Tax, Land Fees , Business Licence, other tax revenues, administrative fees and Application Fees.", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UGX.3,788,124,204. The unspent balance at the end of the", "metadata": {"headings": [{"headings_0": {"content": "UGX.3,788,124,204. The unspent balance at the end of the", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "financial year was subsequently swept back to the consolidated fund account.", "metadata": {"headings": [{"headings_0": {"content": "UGX.3,788,124,204. The unspent balance at the end of the", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the district prepared annual monitoring plans dated 02/08/2021, but had not been submitted to MoFPED, MoLG and NPA as required by the time of audit (10/09/2021). Further, the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district prepared annual monitoring plans dated 02/08/2021, but had not been submitted to MoFPED, MoLG and NPA as required by the time of audit (10/09/2021). Further, the", "page": 415, "level": 3}}, {"headings_1": {"content": "UGX.3,788,124,204. The unspent balance at the end of the", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "district had not also submitted quarterly monitoring reports to the Office of the Prime Minister and MoFPED as required by the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district prepared annual monitoring plans dated 02/08/2021, but had not been submitted to MoFPED, MoLG and NPA as required by the time of audit (10/09/2021). Further, the", "page": 415, "level": 3}}, {"headings_1": {"content": "UGX.3,788,124,204. The unspent balance at the end of the", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "time of audit (10/09/2021). This practice is not only in", "metadata": {"headings": [{"headings_0": {"content": "time of audit (10/09/2021). This practice is not only in", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district prepared annual monitoring plans dated 02/08/2021, but had not been submitted to MoFPED, MoLG and NPA as required by the time of audit (10/09/2021). Further, the", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "contravention of the circular instructions but also hinders efforts of timely monitoring of the implementation of the budget.", "metadata": {"headings": [{"headings_0": {"content": "time of audit (10/09/2021). This practice is not only in", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district prepared annual monitoring plans dated 02/08/2021, but had not been submitted to MoFPED, MoLG and NPA as required by the time of audit (10/09/2021). Further, the", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that management submitted performance reports for Q1", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that management submitted performance reports for Q1", "page": 415, "level": 3}}, {"headings_1": {"content": "time of audit (10/09/2021). This practice is not only in", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "and Q2 in time while performance reports for Q3 and Q4 were submitted after deadline given for submission of the reports.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that management submitted performance reports for Q1", "page": 415, "level": 3}}, {"headings_1": {"content": "time of audit (10/09/2021). This practice is not only in", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management submitted performance reports for Q1", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "are important in ensuring that the budget performs as expected.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management submitted performance reports for Q1", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted delayed completion of Construction of Atyak Seed Secondary School under the UGIFT project, A joint supervision", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted delayed completion of Construction of Atyak Seed Secondary School under the UGIFT project, A joint supervision", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "report dated 18/5/2021 was reviewed and put the work so far done at only 66% and cumulative total payments had been made", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted delayed completion of Construction of Atyak Seed Secondary School under the UGIFT project, A joint supervision", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "of UGX 1,365,729,024 ( representing 65% of the contract sum) by end of year. By the time of the audit in September 2021,", "metadata": {"headings": [{"headings_0": {"content": "of UGX 1,365,729,024 ( representing 65% of the contract sum) by end of year. By the time of the audit in September 2021,", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted delayed completion of Construction of Atyak Seed Secondary School under the UGIFT project, A joint supervision", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "about 5% of the works were still incomplete yet the contract had long expired.", "metadata": {"headings": [{"headings_0": {"content": "of UGX 1,365,729,024 ( representing 65% of the contract sum) by end of year. By the time of the audit in September 2021,", "page": 415, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted delayed completion of Construction of Atyak Seed Secondary School under the UGIFT project, A joint supervision", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}, {"headings_1": {"content": "of UGX 1,365,729,024 ( representing 65% of the contract sum) by end of year. By the time of the audit in September 2021,", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "reviewed the bank statements for sampled schools and noted that the funds were still on the schools\u2019 accounts by 30th \n403", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}, {"headings_1": {"content": "of UGX 1,365,729,024 ( representing 65% of the contract sum) by end of year. By the time of the audit in September 2021,", "page": 415, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}, {"headings_1": {"content": "of UGX 1,365,729,024 ( representing 65% of the contract sum) by end of year. By the time of the audit in September 2021,", "page": 415, "level": 3}}]], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["September, 2021 and had hence not been utilised.", null, null], ["03.", "YUMBE DLG", "\uf0b7 I reviewed payroll funds absorption and noted that UGX.22 billion (94%) was spent out of the total receipts of UGX.23.5 billion,"], ["", "", null], [null, "Opinion", null], [null, "Unqualified", "resulting in an unabsorbed balance of UGX.1.44 billion. The unabsorbed balance was subsequently swept back to the"], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}, {"headings_1": {"content": "of UGX 1,365,729,024 ( representing 65% of the contract sum) by end of year. By the time of the audit in September 2021,", "page": 415, "level": 3}}], "page": 416, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "404 \ncomputing PAYE.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}, {"headings_1": {"content": "of UGX 1,365,729,024 ( representing 65% of the contract sum) by end of year. By the time of the audit in September 2021,", "page": 415, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}, {"headings_1": {"content": "of UGX 1,365,729,024 ( representing 65% of the contract sum) by end of year. By the time of the audit in September 2021,", "page": 415, "level": 3}}]], "page": 416, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 20 pensioners delayed to access the pension payroll, with delays ranging between 4.5 months. I advised the Accounting Officer to ensure that pensioners promptly access the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 20 pensioners delayed to access the pension payroll, with delays ranging between 4.5 months. I advised the Accounting Officer to ensure that pensioners promptly access the", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "payroll and are subsequently paid.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 20 pensioners delayed to access the pension payroll, with delays ranging between 4.5 months. I advised the Accounting Officer to ensure that pensioners promptly access the", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 16 employees were paid a total of UGX.52 million without signed pay change reports. This affects the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 16 employees were paid a total of UGX.52 million without signed pay change reports. This affects the", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 20 pensioners delayed to access the pension payroll, with delays ranging between 4.5 months. I advised the Accounting Officer to ensure that pensioners promptly access the", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "integrity/credibility of the payroll and creates an avenue for payroll abuse.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 16 employees were paid a total of UGX.52 million without signed pay change reports. This affects the", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 20 pensioners delayed to access the pension payroll, with delays ranging between 4.5 months. I advised the Accounting Officer to ensure that pensioners promptly access the", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 16 employees were paid a total of UGX.52 million without signed pay change reports. This affects the", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "and gratuity performance analysis and thus did not submit", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 16 employees were paid a total of UGX.52 million without signed pay change reports. This affects the", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "quarterly returns on payroll to MoPS, contrary to Paragraph 2.1", "metadata": {"headings": [{"headings_0": {"content": "quarterly returns on payroll to MoPS, contrary to Paragraph 2.1", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "of Establishment Notice No. 1 of 2020. The Accounting Officer took note of the observation and stated that action has been initiated during Q1 of the FY 2021/22.", "metadata": {"headings": [{"headings_0": {"content": "quarterly returns on payroll to MoPS, contrary to Paragraph 2.1", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 A comparison of the payroll register and IFMS payment file, I noted that 3 pensioners were paid a total of UGX.75,420,453 off the IPPS. The Accounting Officer explained that Pension and", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 A comparison of the payroll register and IFMS payment file, I noted that 3 pensioners were paid a total of UGX.75,420,453 off the IPPS. The Accounting Officer explained that Pension and", "page": 417, "level": 3}}, {"headings_1": {"content": "quarterly returns on payroll to MoPS, contrary to Paragraph 2.1", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "gratuity arrears had their schedule of payment; therefore, they would not be paid through IPPS.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 A comparison of the payroll register and IFMS payment file, I noted that 3 pensioners were paid a total of UGX.75,420,453 off the IPPS. The Accounting Officer explained that Pension and", "page": 417, "level": 3}}, {"headings_1": {"content": "quarterly returns on payroll to MoPS, contrary to Paragraph 2.1", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the district had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit. I advise Management to urgently prepare and have approved a strategic plan that is aligned to NDP-III to facilitate the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit. I advise Management to urgently prepare and have approved a strategic plan that is aligned to NDP-III to facilitate the", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 A comparison of the payroll register and IFMS payment file, I noted that 3 pensioners were paid a total of UGX.75,420,453 off the IPPS. The Accounting Officer explained that Pension and", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "achievement of the NDP objectives.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit. I advise Management to urgently prepare and have approved a strategic plan that is aligned to NDP-III to facilitate the", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 A comparison of the payroll register and IFMS payment file, I noted that 3 pensioners were paid a total of UGX.75,420,453 off the IPPS. The Accounting Officer explained that Pension and", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit. I advise Management to urgently prepare and have approved a strategic plan that is aligned to NDP-III to facilitate the", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX. 663,494,100 during the year but collected UGX.445,457,586 representing (67%) performance. I advised the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit. I advise Management to urgently prepare and have approved a strategic plan that is aligned to NDP-III to facilitate the", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Accounting Officer to always ensure that NTR is collected as", "metadata": {"headings": [{"headings_0": {"content": "Accounting Officer to always ensure that NTR is collected as", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "budgeted.", "metadata": {"headings": [{"headings_0": {"content": "Accounting Officer to always ensure that NTR is collected as", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The District budgeted to receive UGX.54,077,677,212 (revised) as grants from the Treasury. I noted that, UGX.48,328,375,344", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.54,077,677,212 (revised) as grants from the Treasury. I noted that, UGX.48,328,375,344", "page": 417, "level": 3}}, {"headings_1": {"content": "Accounting Officer to always ensure that NTR is collected as", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "was warranted/ received representing 89% performance.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.54,077,677,212 (revised) as grants from the Treasury. I noted that, UGX.48,328,375,344", "page": 417, "level": 3}}, {"headings_1": {"content": "Accounting Officer to always ensure that NTR is collected as", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The District budgeted to receive UGX.38,231,319,640 as", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.38,231,319,640 as", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 The District budgeted to receive UGX.54,077,677,212 (revised) as grants from the Treasury. I noted that, UGX.48,328,375,344", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "transfers from other Government Units. However, only UGX.23,692,222,658 (62%) was received.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.38,231,319,640 as", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 The District budgeted to receive UGX.54,077,677,212 (revised) as grants from the Treasury. I noted that, UGX.48,328,375,344", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The District budgeted to receive UGX.5,980,183,220 as", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.5,980,183,220 as", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 The District budgeted to receive UGX.38,231,319,640 as", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "external/donor financing out of which UGX.2,031,658,591 (34%), was received.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.5,980,183,220 as", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 The District budgeted to receive UGX.38,231,319,640 as", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 Out of the total receipts for the financial year of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 The District budgeted to receive UGX.5,980,183,220 as", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.74,531,220,778, UGX.57,130,020,926 (76.6%) was spent by the district resulting in an unspent balance of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 The District budgeted to receive UGX.5,980,183,220 as", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the financial year was subsequently swept back to the \n405", "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}, [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}]], "page": 417, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "consolidated fund account. I advised the Accounting Officer to"], [null, "ensure that the rolled over activities are given priority during"], [null, "implementation."]], "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}], "page": 418, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", "consolidated fund account. I advised the Accounting Officer to"], [null, "ensure that the rolled over activities are given priority during"], [null, "implementation."], [null, "\uf0b7 I noted that Management submitted performance reports for Q2,"], [null, "Q3 and Q4 after the deadline. In addition, I did not obtain"], [null, "evidence to confirm that the Accounting Officer Prepared"], [null, "Monitoring Plans and reports which are important in ensuring"], [null, "that the budget performs as expected."], [null, "\uf0b7 Contrary to Section 34 (1) of the Public Finance Management Act"], [null, "2015, I observed the District constructed two (2) operating"], [null, "theaterstheatres worth UGX.666,903,480 at Ariwa Health Centre"], [null, "(HC) III and Baraka HC III in the financial year 2017/18 and"], [null, "were not functional and without operating equipment by close of"], [null, "audit. The unutilized operating theatre denies services to the"], [null, "community"], ["04\\. TEREGO DLG Opinion Unqualified \uf0b7 Terego District Local Government (DLG), being a newly created District curved out of Arua District, I noted that the payroll for the year under review was managed by Arua DLG. As a result, the pay roll analysis for Terego District was made under the audit of Arua DLG. \uf0b7 I, noted that although the district aligned its targets for the F/Y 2020/2021 with the DDPIII and NDPIII, the District strategic plan had not been approved. I advised the Accounting Officer to urgently prepare and approved a strategic plan that is aligned to NDP-III to facilitate the achievement of the NDP objectives \uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect UGX. 116,717,055 during the year but collected UGX.89,153,132 representing (76%) performance. The shortfalls in Local Revenue collections of UGX. UGX.27,563,923(24%) were recorded in Local Service Tax, Land Fees , Business Licence, other tax revenues, administrative fees and Application Fees. \uf0b7 The District budgeted to receive UGX. 23,749,241,508 (revised) as grants from the Treasury. I noted that, UGX. 1,894,332.444 was warranted/ received representing 8% performance. Revenue shortfalls affect the implementation of planned activities. \uf0b7 The Entity budgeted to receive UGX.4,406,498,162 as transfers from other Government Units. However, only UGX.4,006,498,162 (90%) was received. Revenue shortfalls affected the implementation of planned activities. \uf0b7 The District budgeted to receive UGX. 0.8Bn as external/donor financing out of which UGX. 0.4Bn (50%), was received. Revenue shortfalls affect the implementation of planned activities. The Accounting Officer explained that, for external financing the key donor projects funded by UNHCR and UNICEF use the calendar year for Budgeting and reporting as at the close", null]], "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}], "page": 418, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "406", "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}], "page": 418, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["of the financial year 2020/2021 their Budget release was only for the six months thus explaining the poor performance. \uf0b7 Out of the total receipts for the financial year of UGX. 6.5Bn, UGX. 5.9Bn (91%) was spent by the entity resulting in an unspent balance of UGX. 0.6 Bn (91%). The unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account. The funds were meant for activities that were not fully implemented by the end of the financial year and these include Salaries worth UGX.475,796,820. \uf0b7 During field Inspection carried out on service delivery areas at Yinga HC III, I observed the following; \uf0d8 Fridge for storage of blood donated by IRC and UNICEF was not installed consequently, cases of anaemia are referred to other facilities; \uf0d8 Motorised borehole that was installed by OXFAM had been disconnected for six months; \uf0d8 the piped water system installed at the facility had broken down for the period of six months; \uf0d8 As per interview of in-charge of the facility, the facility had not been supplied drugs for two quarters leading to drug stock-outs. This led to the referral of cases that would have been handled at the facility; \uf0d8 The generator that was donated to the HC has never been installed during the two years it has been at the facility \uf0b7 I reviewed of the governance structures of Terego DLG and noted that the district did not have a District Land Board in place. Consequently, the institutional land of the district was not titled. Further, there were reports of land disputes as seen in the Council Minutes dated 21st May 2021. \uf0b7 I reviewed the execution of the annual procurement plan of Terego district for the year under review revealed that projects worth UGX.740,372,862 were not executed in the year, hence hindering service delivery to the intended beneficiaries. \uf0b7 I reviewed the implementation of the DRDIP project in the district and observed that 16 beneficiary projects funded to the tune of UGX.1,620,066,939 had not yet been implemented. The Accounting Officer promised immediate action. I await the outcome of the Accounting Officers action.", null, null], ["05.", "NEBBI DLG", "\uf0b7 I noted that the District did not submit wage estimates to MoPS,"], ["", "", "as required. I advised the Accounting Officer to always submit"]], "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}], "page": 419, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "consolidated fund account. I advised the Accounting Officer to"], "type": "table"}}, {"content": [["of the financial year 2020/2021 their Budget release was only for the six months thus explaining the poor performance. \uf0b7 Out of the total receipts for the financial year of UGX. 6.5Bn, UGX. 5.9Bn (91%) was spent by the entity resulting in an unspent balance of UGX. 0.6 Bn (91%). The unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account. The funds were meant for activities that were not fully implemented by the end of the financial year and these include Salaries worth UGX.475,796,820. \uf0b7 During field Inspection carried out on service delivery areas at Yinga HC III, I observed the following; \uf0d8 Fridge for storage of blood donated by IRC and UNICEF was not installed consequently, cases of anaemia are referred to other facilities; \uf0d8 Motorised borehole that was installed by OXFAM had been disconnected for six months; \uf0d8 the piped water system installed at the facility had broken down for the period of six months; \uf0d8 As per interview of in-charge of the facility, the facility had not been supplied drugs for two quarters leading to drug stock-outs. This led to the referral of cases that would have been handled at the facility; \uf0d8 The generator that was donated to the HC has never been installed during the two years it has been at the facility \uf0b7 I reviewed of the governance structures of Terego DLG and noted that the district did not have a District Land Board in place. Consequently, the institutional land of the district was not titled. Further, there were reports of land disputes as seen in the Council Minutes dated 21st May 2021. \uf0b7 I reviewed the execution of the annual procurement plan of Terego district for the year under review revealed that projects worth UGX.740,372,862 were not executed in the year, hence hindering service delivery to the intended beneficiaries. \uf0b7 I reviewed the implementation of the DRDIP project in the district and observed that 16 beneficiary projects funded to the tune of UGX.1,620,066,939 had not yet been implemented. The Accounting Officer promised immediate action. I await the outcome of the Accounting Officers action.", null, null], ["05.", "NEBBI DLG", "\uf0b7 I noted that the District did not submit wage estimates to MoPS,"], ["", "", "as required. I advised the Accounting Officer to always submit"], [null, "Opinion", "wage estimates to MoPs by 30th September of the preceding"], [null, "Unqualified", "year."], [null, "", ""], [null, null, "\uf0b7 I reviewed funds absorption and noted that UGX.19,924,679,353"], [null, null, "(92%) was spent out of the total receipts of UGX."], [null, null, "21,572,885,359, resulting in an unabsorbed balance of UGX."], [null, null, "1,648,206,006. The unabsorbed balance was subsequently swept"]], "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}], "page": 419, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "consolidated fund account. I advised the Accounting Officer to"], "type": "table"}}, {"content": "407 \nback to the consolidated fund account hence denying the use of funds for other deserving service delivery areas. \n", "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}, [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}], [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}]], "page": 419, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.4,339,048,878 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "employees\u2019 salaries to be remitted to different beneficiaries only, UGX.4,333,222,745 was remitted, leading to an over remittance", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries only, UGX.4,333,222,745 was remitted, leading to an over remittance", "page": 420, "level": 2}}, {"headings_1": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "of UGX.4,849,344 and under remittance of UGX.10,675,477.", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries only, UGX.4,333,222,745 was remitted, leading to an over remittance", "page": 420, "level": 2}}, {"headings_1": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "page": 420, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries only, UGX.4,333,222,745 was remitted, leading to an over remittance", "page": 420, "level": 2}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "totaling UGX.87,617,577. The deductions were from 78 employees that neither had letters of undertaking nor existed in", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "page": 420, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries only, UGX.4,333,222,745 was remitted, leading to an over remittance", "page": 420, "level": 2}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "metadata": {"headings": [{"headings_0": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 420, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "PDMS-Payroll Deduction Management System, operated by PCA- Payroll Consults Africa.", "metadata": {"headings": [{"headings_0": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 420, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I compared the loan deductions in June 2021 on the IPPS payroll against the active deductions amounts on the Payroll Consults Africa (PCA) system and discovered that there were 160 instances where the amount on IPPS being deducted is either", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I compared the loan deductions in June 2021 on the IPPS payroll against the active deductions amounts on the Payroll Consults Africa (PCA) system and discovered that there were 160 instances where the amount on IPPS being deducted is either", "page": 420, "level": 3}}, {"headings_1": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 420, "level": 2}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "more or less than the amount on the active deductions implying that there is a weakness in the system of loan deductions where many employees are either over paying for loans they picked or are underpaying.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I compared the loan deductions in June 2021 on the IPPS payroll against the active deductions amounts on the Payroll Consults Africa (PCA) system and discovered that there were 160 instances where the amount on IPPS being deducted is either", "page": 420, "level": 3}}, {"headings_1": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 420, "level": 2}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 In a sample of 14 teachers selected, I noted that the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 In a sample of 14 teachers selected, I noted that the", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I compared the loan deductions in June 2021 on the IPPS payroll against the active deductions amounts on the Payroll Consults Africa (PCA) system and discovered that there were 160 instances where the amount on IPPS being deducted is either", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "district/votes were not affecting annual salary increments on", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 In a sample of 14 teachers selected, I noted that the", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I compared the loan deductions in June 2021 on the IPPS payroll against the active deductions amounts on the Payroll Consults Africa (PCA) system and discovered that there were 160 instances where the amount on IPPS being deducted is either", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "employee salaries. This may lead to demotivation of staff.", "metadata": {"headings": [{"headings_0": {"content": "employee salaries. This may lead to demotivation of staff.", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 In a sample of 14 teachers selected, I noted that the", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the district had not yet prepared a strategic plan at", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district had not yet prepared a strategic plan at", "page": 420, "level": 3}}, {"headings_1": {"content": "employee salaries. This may lead to demotivation of staff.", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the time of audit, I advised the Accounting Officer to ensure that the strategic plan is implemented upon approval.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district had not yet prepared a strategic plan at", "page": 420, "level": 3}}, {"headings_1": {"content": "employee salaries. This may lead to demotivation of staff.", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I advised the Accounting Officer to ensure that the strategic plan is implemented upon approval. I advised the Accounting Officer to always ensure that NTR is collected as budgeted. The district budgeted to receive UGX.6, 748,502,080 as transfers from other Government Units. However, only UGX.1,325,146,185 (20%) was", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I advised the Accounting Officer to ensure that the strategic plan is implemented upon approval. I advised the Accounting Officer to always ensure that NTR is collected as budgeted. The district budgeted to receive UGX.6, 748,502,080 as transfers from other Government Units. However, only UGX.1,325,146,185 (20%) was", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district had not yet prepared a strategic plan at", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "received. Revenue shortfalls affected the implementation of planned activities.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I advised the Accounting Officer to ensure that the strategic plan is implemented upon approval. I advised the Accounting Officer to always ensure that NTR is collected as budgeted. The district budgeted to receive UGX.6, 748,502,080 as transfers from other Government Units. However, only UGX.1,325,146,185 (20%) was", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district had not yet prepared a strategic plan at", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The district budgeted to receive UGX.2,213,127,500 as", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district budgeted to receive UGX.2,213,127,500 as", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I advised the Accounting Officer to ensure that the strategic plan is implemented upon approval. I advised the Accounting Officer to always ensure that NTR is collected as budgeted. The district budgeted to receive UGX.6, 748,502,080 as transfers from other Government Units. However, only UGX.1,325,146,185 (20%) was", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "external/donor financing, out of which UGX.261,434,917 (12%),", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The district budgeted to receive UGX.2,213,127,500 as", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I advised the Accounting Officer to ensure that the strategic plan is implemented upon approval. I advised the Accounting Officer to always ensure that NTR is collected as budgeted. The district budgeted to receive UGX.6, 748,502,080 as transfers from other Government Units. However, only UGX.1,325,146,185 (20%) was", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "was received. Revenue shortfalls affect the implementation of", "metadata": {"headings": [{"headings_0": {"content": "was received. Revenue shortfalls affect the implementation of", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district budgeted to receive UGX.2,213,127,500 as", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "planned activities.", "metadata": {"headings": [{"headings_0": {"content": "was received. Revenue shortfalls affect the implementation of", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 The district budgeted to receive UGX.2,213,127,500 as", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 District failed spent fund balance of UGX.681, 679,315 meant for Start of construction of Ndhew Seed Secondary School, Drilling of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 District failed spent fund balance of UGX.681, 679,315 meant for Start of construction of Ndhew Seed Secondary School, Drilling of", "page": 420, "level": 3}}, {"headings_1": {"content": "was received. Revenue shortfalls affect the implementation of", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "boreholes, and Payment of gratuity.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 District failed spent fund balance of UGX.681, 679,315 meant for Start of construction of Ndhew Seed Secondary School, Drilling of", "page": 420, "level": 3}}, {"headings_1": {"content": "was received. Revenue shortfalls affect the implementation of", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 District failed spent fund balance of UGX.681, 679,315 meant for Start of construction of Ndhew Seed Secondary School, Drilling of", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "quarters after the deadlines given for submission of the reports,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 District failed spent fund balance of UGX.681, 679,315 meant for Start of construction of Ndhew Seed Secondary School, Drilling of", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "408", "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "are essential in ensuring that the budget performs as expected."], [null, ""], [null, "\uf0b7 From my review of the annual performance report, I noted that"]], "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], "page": 421, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", "are essential in ensuring that the budget performs as expected."], [null, ""], [null, "\uf0b7 From my review of the annual performance report, I noted that"], [null, "some outputs were not captured in the performance report,"], [null, "these included Purchase and supply of ICT Equipment for Atego"], [null, "Seed Secondary, and Purchase and supply of laboratory"], [null, "equipment to Atego Seed Secondary School."], [null, ""], [null, "\uf0b7 I noted that the District received a total of UGX.48,565,353. I"], [null, "reviewed the bank statements sampled schools and noted that"], [null, "the funds were still on the school accounts by 30th September,"], [null, "2021 and had hence not been utilized."], [null, ""], ["06\\. NEBBI MC Opinion Unqualified \uf0b7 I noted that the Municipal Council did not submit wage estimates to MoPs, as required. I advised the Accounting Officer to always submit wage estimates to MoPs by 30th September of the preceding year. \uf0b7 A review of the pension payroll data and IFMS payments, revealed variances between amounts on the payroll and payments to individual pensioners, leading to over payments of UGX. 4,584,882 contrary to article 254 (1) & (3) of the 1995 constitution (as amended). I further noted that there was an under payment of UGX.32,297,600 as well. The Accounting Officer acknowledged the shortcoming and promised future action. \uf0b7 A comparison of base pay in the Integrated Personnel and Payroll System (IPPS) payroll registers with the salary structure for 2020/21, revealed that 6 staff were paid using wrong salary scales, leading to over payments of UGX.3,190,260 contrary to Section B\u2013a (6) & (7) of the Uganda Public Service Standing Orders, 2010. \uf0b7 I noted that whereas UGX.722,140,725 was deducted from employees\u2019 salaries to be remitted to different beneficiaries, UGX.703,333,159 was remitted, leading to an under remittance of UGX.18,807,566. \uf0b7 I noted that the Municipal Council made unauthorized loan deductions totaling UGX.38,493,134. The deductions were from 24 employees that neither had letters of undertaking nor existed in the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll Deduction Management System, operated by Payroll Consults Africa (PCA). \uf0b7 I noted that the Municipal Council did not subject political leaders\u2019 gratuity totaling to UGX.10,962,600 to the computation of PAYE in IPPS, leading to an under deduction of UGX.3,288,780 contrary to section 19 (1) (a) of the Income Tax Act. \uf0b7 I noted that, there was minimal movement in receivables as only", null]], "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], "page": 421, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "409", "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], "page": 421, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["UGX.4,156,000 was recovered from the reported amount of UGX.528,709,420 previously, implying no significant effort was put into recovery. \uf0b7 I noted that the Municipal Council had not prepared and approved a strategic plan that is aligned to the NDP-III. \uf0b7 I noted budget underperformance of UGX.2,132,255,571 from government grants and local revenue which affected activity implementation \uf0b7 The municipality failed to spent funds worth UGX.522,335,106 and the unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account. \uf0b7 I noted that UGX.20,661,647 was charged on items which did not reflect the nature of the expenditure. I advised the Accounting Officer to always ensure that the correct codes are charged and seek approvals for any virement or reallocations", null, null], ["07.", "MARACHA DLG", "\uf0b7 I noted that the District did not submit wage estimates to MoPS,"], ["", "", "as required. I advised the Accounting Officer to always submit"]], "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], "page": 422, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "are essential in ensuring that the budget performs as expected."], "type": "table"}}, {"content": [["UGX.4,156,000 was recovered from the reported amount of UGX.528,709,420 previously, implying no significant effort was put into recovery. \uf0b7 I noted that the Municipal Council had not prepared and approved a strategic plan that is aligned to the NDP-III. \uf0b7 I noted budget underperformance of UGX.2,132,255,571 from government grants and local revenue which affected activity implementation \uf0b7 The municipality failed to spent funds worth UGX.522,335,106 and the unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account. \uf0b7 I noted that UGX.20,661,647 was charged on items which did not reflect the nature of the expenditure. I advised the Accounting Officer to always ensure that the correct codes are charged and seek approvals for any virement or reallocations", null, null], ["07.", "MARACHA DLG", "\uf0b7 I noted that the District did not submit wage estimates to MoPS,"], ["", "", "as required. I advised the Accounting Officer to always submit"], [null, "Opinion Unqualified", "wage estimates to MoPs by 30th September of the preceding"], [null, null, "year."], [null, "", ""], [null, null, "\uf0b7 I reviewed funds absorption and noted unabsorbed balance of"], [null, null, "UGX. 1.2 billion meant for payment mostly pensioners due to"], [null, null, "slow processing of pension benefits by the beneficiaries"], [null, null, ""], [null, null, "\uf0b7 A comparison of base pay in the IPPS payroll registers with the"], [null, null, "salary structure for 2020/21, revealed that 4 staff were paid"], [null, null, "using wrong salary scales, leading to over payments of"], [null, null, "UGX.25,197,900, and under payment of UGX.544,068 contrary to"], [null, null, "Section B\u2013a (6) & (7) of the Uganda Public Service Standing"], [null, null, "Orders, 2010. The Accounting Officer acknowledged the audit"], [null, null, "observation and promised to follow the audit recommendation."], [null, null, ""], [null, null, "\uf0b7 I noted that UGX.11, 634,613 was paid to 32 staff who had"], [null, null, "either retired, transferred, absconded or died. I advised the"], [null, null, "Accounting Officer to ensure prompt removal of staff from the"], [null, null, "payroll and recover payments of salaries to staff who have left"], [null, null, "active employment."], [null, null, ""], [null, null, "\uf0b7 I noted that whereas UGX3,361,569,932 was deducted from"], [null, null, "employees\u2019 salaries to be remitted to different beneficiaries,"], [null, null, "UGX3,358,721,257 was remitted, leading to an over remittance"], [null, null, "of UGX.6,609,552 and under remittance of UGX.9,458,227, I"], [null, null, "advised the Accounting Officer to reconcile IPPS deductions"], [null, null, "against IFMS remittances and recover the over remittances and"], [null, null, "pay the under remittances."], [null, null, ""], [null, null, "\uf0b7 I noted that the District made unauthorized loan deductions"], [null, null, "totaling UGX.100.4 million. The deductions were from 93"], [null, null, "employees that neither had letters of undertaking nor existed in"]], "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], "page": 422, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "are essential in ensuring that the budget performs as expected."], "type": "table"}}, {"content": "410", "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], "page": 422, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the"], [null, null, "PDMS-Payroll Deduction Management System, operated by PCA-"], [null, null, "Payroll Consults Africa."]], "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], "page": 423, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": [["", "", "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the"], [null, null, "PDMS-Payroll Deduction Management System, operated by PCA-"], [null, null, "Payroll Consults Africa."], [null, null, ""], [null, null, "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity"], [null, null, "totaling to UGX.37,848,204 to the computation of PAYE in IPPS,"], [null, null, "leading to an under deduction of UGX.11,377,861, contrary to"], [null, null, "section 19(1) (a) of the Income Tax Act."], [null, null, ""], [null, null, "\uf0b7 I noted that the District did not prepare monthly wage, pension"], [null, null, "and gratuity performance analysis and thus did not submit"], [null, null, "quarterly returns on payroll to MoPS, contrary to Paragraph 2.1"], [null, null, "of Establishment Notice No. 1 of 2020."], [null, null, ""], [null, null, "\uf0b7 I noted that 3 staff were paid a total of UGX.15 Million off the"], [null, null, "IPPS. I advised the Accounting Officer to ensure that salaries,"], [null, null, "pension and gratuity is processed and paid through the IPPS."], [null, null, ""], [null, null, "\uf0b7 I noted that the strategic plan of Maracha District was still not"], [null, null, "approved and therefore it was still in draft form."], [null, null, ""], [null, null, "\uf0b7 I reviewed the approved Local revenue estimates for the financial"], [null, null, "year 2020/2021 and noted that the District budgeted to collect"], [null, null, "UGX.215,093,000 during the year but collected UGX.143,"], [null, null, "183,859 representing (66.6%) performance. The shortfalls in"], [null, null, "Local Revenue collections of UGX.71,909,141 (33.4%) were"], [null, null, "recorded in Land fees, business licenses, other tax revenues and"], [null, null, "Administrative fees and licenses. Revenue shortfalls affected the"], [null, null, "implementation of planned activities."], [null, null, ""], [null, null, "\uf0b7 The Entity budgeted to receive UGX. 8, 429,617,471 as transfers"], [null, null, "from other Government Units. However, only UGX. 139, 292,268"], [null, null, "(1.7%) was received, Revenue shortfalls affected the"], [null, null, "implementation of planned activities."], [null, null, ""], [null, null, "\uf0b7 The Entity did not also submit quarterly monitoring reports to the"], [null, null, "Office of the Prime Minister and MoFPED as required. I advised"], [null, null, "the Accounting Officer to ensure that monitoring plans and"], [null, null, "reports are timely submitted accordingly."], [null, null, ""], [null, null, "\uf0b7 Contrary to Regulation 47 of the PPDA (Contract) Regulations,"], [null, null, "2014, the entity on 29th June 2021 paid UGX.178, 391,142 to"], [null, null, "the contractor upgrading Odupiri HC II to HC III without an"], [null, null, "interim payment certificate. On inspection in September 2021,"], [null, null, "On physical inspection, I noted that the construction was still at"], [null, null, "ring beam stage hence severely delayed and the contractor was"], [null, null, "not on site and therefore there was no construction works."], [null, null, ""], [null, null, "\uf0b7 I noted that the District received a total of UGX.166,590,846 I"], [null, null, "reviewed the bank statements sampled schools and noted that"], [null, null, "the funds were still on the school accounts by 30 th September,"], [null, null, "2021 and had hence not been utilised."], ["08.", "MADI-OKOLLO DLG \uf0b7 I noted that the District did not submit wage estimates to MoPs,", null]], "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], "page": 423, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "411", "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], "page": 423, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "as required. The submission was made late. The Accounting Opinion Officer promised to handle this issue as per the requirement in Unqualified", "metadata": {"headings": [{"headings_0": {"content": "as required. The submission was made late. The Accounting Opinion Officer promised to handle this issue as per the requirement in Unqualified", "page": 424, "level": 3}}, {"headings_1": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the subsequent years.", "metadata": {"headings": [{"headings_0": {"content": "as required. The submission was made late. The Accounting Opinion Officer promised to handle this issue as per the requirement in Unqualified", "page": 424, "level": 3}}, {"headings_1": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.7.4 billion (73%) was spent out of the total receipts of UGX.10.18 billion, resulting in an unabsorbed balance of UGX.2.78 billion. I advised the Accounting Officer to consider the unimplemented", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.7.4 billion (73%) was spent out of the total receipts of UGX.10.18 billion, resulting in an unabsorbed balance of UGX.2.78 billion. I advised the Accounting Officer to consider the unimplemented", "page": 424, "level": 3}}, {"headings_1": {"content": "as required. The submission was made late. The Accounting Opinion Officer promised to handle this issue as per the requirement in Unqualified", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "activities in the next work plan.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.7.4 billion (73%) was spent out of the total receipts of UGX.10.18 billion, resulting in an unabsorbed balance of UGX.2.78 billion. I advised the Accounting Officer to consider the unimplemented", "page": 424, "level": 3}}, {"headings_1": {"content": "as required. The submission was made late. The Accounting Opinion Officer promised to handle this issue as per the requirement in Unqualified", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.7.4 billion (73%) was spent out of the total receipts of UGX.10.18 billion, resulting in an unabsorbed balance of UGX.2.78 billion. I advised the Accounting Officer to consider the unimplemented", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "salary structure for 2020/21, revealed that 17 staff were paid", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.7.4 billion (73%) was spent out of the total receipts of UGX.10.18 billion, resulting in an unabsorbed balance of UGX.2.78 billion. I advised the Accounting Officer to consider the unimplemented", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "using wrong salary scales, leading to under payments of UGX.", "metadata": {"headings": [{"headings_0": {"content": "using wrong salary scales, leading to under payments of UGX.", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "2.1 million, contrary to Section B\u2013a (6) & (7) of the Uganda", "metadata": {"headings": [{"headings_0": {"content": "using wrong salary scales, leading to under payments of UGX.", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Public Service Standing Orders, 2010.", "metadata": {"headings": [{"headings_0": {"content": "Public Service Standing Orders, 2010.", "page": 424, "level": 3}}, {"headings_1": {"content": "using wrong salary scales, leading to under payments of UGX.", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Public Service Standing Orders, 2010.", "page": 424, "level": 3}}, {"headings_1": {"content": "using wrong salary scales, leading to under payments of UGX.", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.1,901,582,442 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "Public Service Standing Orders, 2010.", "page": 424, "level": 3}}, {"headings_1": {"content": "using wrong salary scales, leading to under payments of UGX.", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,868,292,549 was remitted, leading to an over and under", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,868,292,549 was remitted, leading to an over and under", "page": 424, "level": 3}}, {"headings_1": {"content": "Public Service Standing Orders, 2010.", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "remittance of UGX.28,854,515 and UGX.62,144,408 respectively", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,868,292,549 was remitted, leading to an over and under", "page": 424, "level": 3}}, {"headings_1": {"content": "Public Service Standing Orders, 2010.", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX.108million from 55 employees that neither had", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX.108million from 55 employees that neither had", "page": 424, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,868,292,549 was remitted, leading to an over and under", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "letters of undertaking nor existed in the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll Deduction Management System, operated by PCA-Payroll Consults Africa", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX.108million from 55 employees that neither had", "page": 424, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,868,292,549 was remitted, leading to an over and under", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 424, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX.108million from 55 employees that neither had", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "totalling to UGX 40,202,400 to the computation of PAYE in IPPS, leading to an under deduction of UGX 12,439,426, contrary to section 19 (1) (a) of the Income Tax Act. The", "metadata": {"headings": [{"headings_0": {"content": "totalling to UGX 40,202,400 to the computation of PAYE in IPPS, leading to an under deduction of UGX 12,439,426, contrary to section 19 (1) (a) of the Income Tax Act. The", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 424, "level": 2}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that 32 newly recruited/ transferred employees and 5", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 32 newly recruited/ transferred employees and 5", "page": 424, "level": 3}}, {"headings_1": {"content": "totalling to UGX 40,202,400 to the computation of PAYE in IPPS, leading to an under deduction of UGX 12,439,426, contrary to section 19 (1) (a) of the Income Tax Act. The", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "pensioners delayed to access payroll, delayed access to payroll leads to demotivation of the affected staff and accumulation of salary arrears.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 32 newly recruited/ transferred employees and 5", "page": 424, "level": 3}}, {"headings_1": {"content": "totalling to UGX 40,202,400 to the computation of PAYE in IPPS, leading to an under deduction of UGX 12,439,426, contrary to section 19 (1) (a) of the Income Tax Act. The", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 14 staff and were paid a total of UGX 19,228,208 off the IPPS. This control weakness creates an opportunity for", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 14 staff and were paid a total of UGX 19,228,208 off the IPPS. This control weakness creates an opportunity for", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 32 newly recruited/ transferred employees and 5", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "payment of salaries and pension to non-eligible persons, hence loss of funds to Government.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 14 staff and were paid a total of UGX 19,228,208 off the IPPS. This control weakness creates an opportunity for", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 32 newly recruited/ transferred employees and 5", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 14 staff and were paid a total of UGX 19,228,208 off the IPPS. This control weakness creates an opportunity for", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX. 302,248,400 during the year but collected UGX.209,081,450 representing (69%) performance. The \n412", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}]], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["shortfalls in Local Revenue collections of UGX. UGX. 93,166,950 (31%) were recorded in Land fees, business licenses, other tax revenues and Administrative fees and licenses. \uf0b7 I noted that Management submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which are important in ensuring that the budget performs as expected. The Accounting Officer admitted the shortcoming and promised to address the matter. \uf0b7 I noted that there was a general delay in the implementation of NUSAF 3 sub- projects without any justification. \uf0b7 Madi-Okollo District contracted M/s TIC Lokere Enterprises Ltd for the rehabilitation of Inde mile 10 Yoro base camp feeder road under DRDIP programme at a cost of UGX.1, 238,943,750. However, I noted that there was delayed Completion of the contract, Failure to install culverts at critical points of the road and Poorly installed culverts. \uf0b7 I noted that advances of UGX. 52,332,500 remained not accounted for, at year end. The funds were advanced to staff to carry out various activities. In the absence of the relevant accountability documents, it was not possible to confirm that the funds were used for the intended purposes. \uf0b7 I noted that there were un-utilized Market at Rhino Camp. The Market was constructed at an estimated cost of UGX.700,000,000. The market lock ups had been turned into residential apartments instead and the market stalls have been abandoned and now only used for drying cassava.4", null, null], ["09.", "KOBOKO MC", "\uf0b7 I noted that the Municipal Council did not submit wage estimates"], ["", "", "to MoPs by 30th September of the preceding year as required."]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}], "page": 425, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["shortfalls in Local Revenue collections of UGX. UGX. 93,166,950 (31%) were recorded in Land fees, business licenses, other tax revenues and Administrative fees and licenses. \uf0b7 I noted that Management submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which are important in ensuring that the budget performs as expected. The Accounting Officer admitted the shortcoming and promised to address the matter. \uf0b7 I noted that there was a general delay in the implementation of NUSAF 3 sub- projects without any justification. \uf0b7 Madi-Okollo District contracted M/s TIC Lokere Enterprises Ltd for the rehabilitation of Inde mile 10 Yoro base camp feeder road under DRDIP programme at a cost of UGX.1, 238,943,750. However, I noted that there was delayed Completion of the contract, Failure to install culverts at critical points of the road and Poorly installed culverts. \uf0b7 I noted that advances of UGX. 52,332,500 remained not accounted for, at year end. The funds were advanced to staff to carry out various activities. In the absence of the relevant accountability documents, it was not possible to confirm that the funds were used for the intended purposes. \uf0b7 I noted that there were un-utilized Market at Rhino Camp. The Market was constructed at an estimated cost of UGX.700,000,000. The market lock ups had been turned into residential apartments instead and the market stalls have been abandoned and now only used for drying cassava.4", null, null], ["09.", "KOBOKO MC", "\uf0b7 I noted that the Municipal Council did not submit wage estimates"], ["", "", "to MoPs by 30th September of the preceding year as required."], [null, "Opinion Unqualified", ""], [null, null, "\uf0b7 The Municipal did not absorb wage funds worth UGX.0.33 billion."], [null, "", ""], [null, null, "\uf0b7 The Council had outstanding domestic arrears worth UGX"], [null, null, "113,354,578 that accrued within the year"], [null, null, ""], [null, null, "\uf0b7 I noted that the Municipal Council made unauthorized loan"], [null, null, "deductions totaling UGX. 18,148,668. from 16 employees that"], [null, null, "neither had letters of undertaking nor existed in the \u201cactive"], [null, null, "deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll"], [null, null, "Deduction Management System, operated by PCA-Payroll"], [null, null, "Consults Africa."], [null, null, ""], [null, null, "\uf0b7 I noted that 6 pensioners delayed to access the pension payroll"], [null, null, ""], [null, null, "\uf0b7 I noted that 5 staff was paid a total of UGX. 6,488,549 off the"], [null, null, "IPPS."], [null, null, ""], [null, null, "\uf0b7 I noted that the Municipal Council did not have an approved plan"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}], "page": 425, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "413", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}], "page": 425, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "neither did it have certification of the plan by NPA."], [null, ""], [null, "\uf0b7 I noted underperformance in all revenue sources totaling UGX."], [null, "4,384,175,589 that affected implementation of planned activities"], [null, "at the council I further noted delayed submission of quarterly"], [null, "performance reports to OPM and MoFPED"], [null, ""], ["10\\. ARUA REGIONAL REFERRAL HOSPITAL Opinion Unqualified \uf0b7 Through re-computation of gratuity benefits, I noted that there were variances of over payments of UGX.21,706,000 and under payment of UGX.19,700,433. I also re-computed pension benefits, and I further noted that there were variances of over payment of UGX.5, 798,629 and under payments of UGX.10, 401,528. The Accounting Officer explained that gratuity payments are automatically computed through the IPPS system. Consultations with system officers in MOPS were underway to have the error rectified. \uf0b7 I noted that UGX.6,659,448 was paid to 03 staff who had been transferred to other entities. These were payment for services not rendered to the Hospital, resulting in loss of funds to Government. \uf0b7 I noted that deductions to UCLA/UBA were concurrently remitted as salary was paid except for the month of April, 2021 where there was no remittance at all yet UGX.16,434,444 was deducted \uf0b7 I noted that the Hospital did not include Hospital Management Board Member\u2019s retainer fees of UGX.33,600,000 in the computation of PAYE leading to under deduction of PAYE of UGX.10,080,000 contrary to section 19(1) (a) of the Income Tax Act. \uf0b7 I noted that the Hospital did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS, contrary to Paragraph 2.1 of Establishment Notice No. 1 of 2020. \uf0b7 The Hospital had outstanding (unsettled) domestic arrears worth UGX. 1,255,228,566 by close of financial year \uf0b7 I noted that the Hospital had not prepared and approved a strategic plan that is aligned to the NDP-III. \uf0b7 I noted the Hospital received off-budget financing from Ministry of Health and development partners for undertaking various activities not budgeted to a tune of UGX.1,925,620,637 which was not transferred to the consolidated fund as required by the law. \uf0b7 The Hospital Ambulance number UG6812M had been stolen from the hospital yard. By close of the audit, the ambulance had not been recovered by management. Also the value of the ambulance had not been updated in the assets register as", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}], "page": 426, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["shortfalls in Local Revenue collections of UGX. UGX. 93,166,950 (31%) were recorded in Land fees, business licenses, other tax revenues and Administrative fees and licenses. \uf0b7 I noted that Management submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which are important in ensuring that the budget performs as expected. The Accounting Officer admitted the shortcoming and promised to address the matter. \uf0b7 I noted that there was a general delay in the implementation of NUSAF 3 sub- projects without any justification. \uf0b7 Madi-Okollo District contracted M/s TIC Lokere Enterprises Ltd for the rehabilitation of Inde mile 10 Yoro base camp feeder road under DRDIP programme at a cost of UGX.1, 238,943,750. However, I noted that there was delayed Completion of the contract, Failure to install culverts at critical points of the road and Poorly installed culverts. \uf0b7 I noted that advances of UGX. 52,332,500 remained not accounted for, at year end. The funds were advanced to staff to carry out various activities. In the absence of the relevant accountability documents, it was not possible to confirm that the funds were used for the intended purposes. \uf0b7 I noted that there were un-utilized Market at Rhino Camp. The Market was constructed at an estimated cost of UGX.700,000,000. The market lock ups had been turned into residential apartments instead and the market stalls have been abandoned and now only used for drying cassava.4", "None"], "type": "table"}}, {"content": "414", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}], "page": 426, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["required. \uf0b7 I noted that the Hospital did not have a land title for Hospital land plot 43 \u2013 Hospital cell with an estimated size of 13.478 acres which it currently occupied. There was no evidence of ownership of property and there was no guarantee that the land was free from encroachment.", null, null], ["11.", "MOYO DLG", ""], ["", "", "\uf0b7 I noted that UGX.12,035,376 was paid to 8 staff who had either"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}], "page": 427, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["shortfalls in Local Revenue collections of UGX. UGX. 93,166,950 (31%) were recorded in Land fees, business licenses, other tax revenues and Administrative fees and licenses. \uf0b7 I noted that Management submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which are important in ensuring that the budget performs as expected. The Accounting Officer admitted the shortcoming and promised to address the matter. \uf0b7 I noted that there was a general delay in the implementation of NUSAF 3 sub- projects without any justification. \uf0b7 Madi-Okollo District contracted M/s TIC Lokere Enterprises Ltd for the rehabilitation of Inde mile 10 Yoro base camp feeder road under DRDIP programme at a cost of UGX.1, 238,943,750. However, I noted that there was delayed Completion of the contract, Failure to install culverts at critical points of the road and Poorly installed culverts. \uf0b7 I noted that advances of UGX. 52,332,500 remained not accounted for, at year end. The funds were advanced to staff to carry out various activities. In the absence of the relevant accountability documents, it was not possible to confirm that the funds were used for the intended purposes. \uf0b7 I noted that there were un-utilized Market at Rhino Camp. The Market was constructed at an estimated cost of UGX.700,000,000. The market lock ups had been turned into residential apartments instead and the market stalls have been abandoned and now only used for drying cassava.4", "None", "None"], "type": "table"}}, {"content": [["required. \uf0b7 I noted that the Hospital did not have a land title for Hospital land plot 43 \u2013 Hospital cell with an estimated size of 13.478 acres which it currently occupied. There was no evidence of ownership of property and there was no guarantee that the land was free from encroachment.", null, null], ["11.", "MOYO DLG", ""], ["", "", "\uf0b7 I noted that UGX.12,035,376 was paid to 8 staff who had either"], [null, "", "retired, transferred, absconded or died. I advised the Accounting"], [null, "Opinion Unqualified", "Officer to ensure prompt removal of staff from the payroll."], [null, null, ""], [null, "", "\uf0b7 I noted that whereas UGX.2,467,253,134 was deducted from"], [null, null, "employees\u2019 salaries to be remitted to different beneficiaries,"], [null, null, "UGX.2,499,884,543 was remitted, leading to an under remittance"], [null, null, "amounting to UGX.519,984 and over remittance of"], [null, null, "UGX.33,151,393. I advised the Accounting Officer to ensure"], [null, null, "prompt removal of staff from the payroll."], [null, null, ""], [null, null, "\uf0b7 I noted that whereas UGX.2,467,253,134 was deducted from"], [null, null, "employees\u2019 salaries to be remitted to different beneficiaries,"], [null, null, "UGX.2,499,884,543 was remitted, leading to an under remittance"], [null, null, "amounting to UGX.519,984 and over remittance of"], [null, null, "UGX.33,151,393."], [null, null, ""], [null, null, "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity"], [null, null, "totalling to UGX.28,087,200 to the computation of PAYE in IPPS,"], [null, null, "leading to an under deduction of UGX.8,520,960 contrary to"], [null, null, "section 19(1) (a) of the Income Tax Act."], [null, null, ""], [null, null, "\uf0b7 I noted that 6 pensioners delayed to access the pension payroll,"], [null, null, "with delays ranging between 1-2 months. Delayed access to the"], [null, null, "pension payroll leads to poor wellbeing of the affected retirees as"], [null, null, "well as accumulation of pension arrears."], [null, null, ""], [null, null, "\uf0b7 I noted that the District/Municipal Council did not prepare"], [null, null, "monthly wage, pension and gratuity performance analysis and"], [null, null, "thus did not submit quarterly returns on payroll to MoPS,"], [null, null, "contrary to Paragraph 2.1 of Establishment Notice No. 1 of 2020."], [null, null, ""], [null, null, "\uf0b7 Revenue underperformance of UGX.9,484,876,432 due to"], [null, null, "shortfall in NTR, government transfers and donor funding"], [null, null, ""], [null, null, "\uf0b7 The district did not absorb funds worth of UGX.940, 729,263 and"], [null, null, "these funds were subsequently swept back to the consolidated"], [null, null, "fund account."], [null, null, ""], [null, null, "\uf0b7 I further noted that funds received under USMID totaling to"], [null, null, "UGX.1,342,227,081 were not absorbed and as such swept back"], [null, null, "to the consolidated fund"], ["12\\. KOBOKO DLG \uf0b7 I noted that there was an under payment of UGX 83,675,196 of pension and gratuity", null, null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}], "page": 427, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["shortfalls in Local Revenue collections of UGX. UGX. 93,166,950 (31%) were recorded in Land fees, business licenses, other tax revenues and Administrative fees and licenses. \uf0b7 I noted that Management submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which are important in ensuring that the budget performs as expected. The Accounting Officer admitted the shortcoming and promised to address the matter. \uf0b7 I noted that there was a general delay in the implementation of NUSAF 3 sub- projects without any justification. \uf0b7 Madi-Okollo District contracted M/s TIC Lokere Enterprises Ltd for the rehabilitation of Inde mile 10 Yoro base camp feeder road under DRDIP programme at a cost of UGX.1, 238,943,750. However, I noted that there was delayed Completion of the contract, Failure to install culverts at critical points of the road and Poorly installed culverts. \uf0b7 I noted that advances of UGX. 52,332,500 remained not accounted for, at year end. The funds were advanced to staff to carry out various activities. In the absence of the relevant accountability documents, it was not possible to confirm that the funds were used for the intended purposes. \uf0b7 I noted that there were un-utilized Market at Rhino Camp. The Market was constructed at an estimated cost of UGX.700,000,000. The market lock ups had been turned into residential apartments instead and the market stalls have been abandoned and now only used for drying cassava.4", "None", "None"], "type": "table"}}, {"content": "415", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}], "page": 427, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Opinion Unqualified \uf0b7 I noted that UGX 5,703,084 was paid to 2 staff who had either", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified \uf0b7 I noted that UGX 5,703,084 was paid to 2 staff who had either", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "retired or died", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified \uf0b7 I noted that UGX 5,703,084 was paid to 2 staff who had either", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that whereas UGX. 2,007,415,658 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that whereas UGX. 2,007,415,658 was deducted from", "page": 428, "level": 3}}, {"headings_1": {"content": "Opinion Unqualified \uf0b7 I noted that UGX 5,703,084 was paid to 2 staff who had either", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.", "page": 428, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that whereas UGX. 2,007,415,658 was deducted from", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "1,866,468,850 was remitted, leading to an under remittance of", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.", "page": 428, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that whereas UGX. 2,007,415,658 was deducted from", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UGX.140,946,808", "metadata": {"headings": [{"headings_0": {"content": "UGX.140,946,808", "page": 428, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.", "page": 428, "level": 2}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "page": 428, "level": 3}}, {"headings_1": {"content": "UGX.140,946,808", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "totaling UGX. 111,107,631", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "page": 428, "level": 3}}, {"headings_1": {"content": "UGX.140,946,808", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 14 newly recruited/ transferred employees and 6", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 14 newly recruited/ transferred employees and 6", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "pensioners", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 14 newly recruited/ transferred employees and 6", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 25 staff were paid a total of UGX. 27,346,176 off the IPPS", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 25 staff were paid a total of UGX. 27,346,176 off the IPPS", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 14 newly recruited/ transferred employees and 6", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- The district has outstanding payables worth UGX.736,710,419 in the current financial year", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 25 staff were paid a total of UGX. 27,346,176 off the IPPS", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 14 newly recruited/ transferred employees and 6", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 25 staff were paid a total of UGX. 27,346,176 off the IPPS", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 14 newly recruited/ transferred employees and 6", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity had not prepared and approved its", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity had not prepared and approved its", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 25 staff were paid a total of UGX. 27,346,176 off the IPPS", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "strategic plan at the time of audit", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity had not prepared and approved its", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 25 staff were paid a total of UGX. 27,346,176 off the IPPS", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved its", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "budget such as partial or non-implementation of planned", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not prepared and approved its", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "activities and budget shortfall of UGX.8,706,420,377 that affected", "metadata": {"headings": [{"headings_0": {"content": "activities and budget shortfall of UGX.8,706,420,377 that affected", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "implementation of planned activities; late submission of quarterly", "metadata": {"headings": [{"headings_0": {"content": "activities and budget shortfall of UGX.8,706,420,377 that affected", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "reports to Office of the Prime Minister and MoFPED", "metadata": {"headings": [{"headings_0": {"content": "reports to Office of the Prime Minister and MoFPED", "page": 428, "level": 3}}, {"headings_1": {"content": "activities and budget shortfall of UGX.8,706,420,377 that affected", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 Construction of Multipurpose Hall, ICT, Library Block , teachers houses, pay ground and water installation at Padrombu", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Construction of Multipurpose Hall, ICT, Library Block , teachers houses, pay ground and water installation at Padrombu", "page": 428, "level": 3}}, {"headings_1": {"content": "reports to Office of the Prime Minister and MoFPED", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "SeedSchool UGX.1,234,362,772 has delayed and is incomplete", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Construction of Multipurpose Hall, ICT, Library Block , teachers houses, pay ground and water installation at Padrombu", "page": 428, "level": 3}}, {"headings_1": {"content": "reports to Office of the Prime Minister and MoFPED", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "and the Contractor was not on site", "metadata": {"headings": [{"headings_0": {"content": "and the Contractor was not on site", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 Construction of Multipurpose Hall, ICT, Library Block , teachers houses, pay ground and water installation at Padrombu", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- Nyangilia Ps briquette making sub project was advanced", "metadata": {"headings": [{"headings_0": {"content": "and the Contractor was not on site", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 Construction of Multipurpose Hall, ICT, Library Block , teachers houses, pay ground and water installation at Padrombu", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "and the Contractor was not on site", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 Construction of Multipurpose Hall, ICT, Library Block , teachers houses, pay ground and water installation at Padrombu", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UGX.51,257,476 on Voucher No/EFT number 36222842 for the purpose of making fuel energy through briquettes. During field inspections undertaken on 24/11/2021, I noted that sub project", "metadata": {"headings": [{"headings_0": {"content": "UGX.51,257,476 on Voucher No/EFT number 36222842 for the purpose of making fuel energy through briquettes. During field inspections undertaken on 24/11/2021, I noted that sub project", "page": 428, "level": 3}}, {"headings_1": {"content": "and the Contractor was not on site", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "had not yet taken off and the group members could not be traced", "metadata": {"headings": [{"headings_0": {"content": "UGX.51,257,476 on Voucher No/EFT number 36222842 for the purpose of making fuel energy through briquettes. During field inspections undertaken on 24/11/2021, I noted that sub project", "page": 428, "level": 3}}, {"headings_1": {"content": "and the Contractor was not on site", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that Koboko District received a total of UGX. 113,097,405 for supply of additional learning materials. I reviewed the bank", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Koboko District received a total of UGX. 113,097,405 for supply of additional learning materials. I reviewed the bank", "page": 428, "level": 3}}, {"headings_1": {"content": "UGX.51,257,476 on Voucher No/EFT number 36222842 for the purpose of making fuel energy through briquettes. During field inspections undertaken on 24/11/2021, I noted that sub project", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "statements for sampled schools and noted that the funds were", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Koboko District received a total of UGX. 113,097,405 for supply of additional learning materials. I reviewed the bank", "page": 428, "level": 3}}, {"headings_1": {"content": "UGX.51,257,476 on Voucher No/EFT number 36222842 for the purpose of making fuel energy through briquettes. During field inspections undertaken on 24/11/2021, I noted that sub project", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "still on the schools\u2019 accounts by 30 th September, 2021 and had", "metadata": {"headings": [{"headings_0": {"content": "still on the schools\u2019 accounts by 30 th September, 2021 and had", "page": 428, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that Koboko District received a total of UGX. 113,097,405 for supply of additional learning materials. I reviewed the bank", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "hence not been utilised", "metadata": {"headings": [{"headings_0": {"content": "still on the schools\u2019 accounts by 30 th September, 2021 and had", "page": 428, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that Koboko District received a total of UGX. 113,097,405 for supply of additional learning materials. I reviewed the bank", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that management ignored the element of competition in", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}, {"headings_1": {"content": "still on the schools\u2019 accounts by 30 th September, 2021 and had", "page": 428, "level": 2}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the procurement of some items worth UGX.1,236,462,077", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}, {"headings_1": {"content": "still on the schools\u2019 accounts by 30 th September, 2021 and had", "page": 428, "level": 2}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "416", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", null, null], ["13.", "ARUA DLG", "\uf0b7 I was not availed with evidence that the district submitted wage"], ["", "", "estimates to MoPs as required."]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 429, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", null, null], ["13.", "ARUA DLG", "\uf0b7 I was not availed with evidence that the district submitted wage"], ["", "", "estimates to MoPs as required."], [null, "Opinions", ""], [null, "Unqualified", "\uf0b7 The district failed to absorb wage funds worth UGX.2.14 billion"], [null, "", "and the funds were swept back into the consolidated fund"], [null, null, "account at year end."], [null, null, ""], [null, null, "\uf0b7 The district made over payments of UGX.17, 088,304 various"], [null, null, "pensioners."], [null, null, ""], [null, null, "\uf0b7 I noted that UGX.10, 115,392 was paid to 15 staffs that neither"], [null, null, "appeared on the IPPS payroll register nor had the necessary"], [null, null, "documentation in their personal files to support their existence."], [null, null, ""], [null, null, "\uf0b7 I noted that 58 employees were paid salaries above their"], [null, null, "applicable salary band resulting in overpayments totalling"], [null, null, "UGX.37,427,696 while 6 employees were paid salaries below"], [null, null, "their applicable salary band resulting in underpayments totalling"], [null, null, "UGX.2,441,988."], [null, null, ""], [null, null, "\uf0b7 The District wrongly computed gratuity benefits for 01 pensioner"], [null, null, "that resulted in an overpayment of UGX.17,088,304."], [null, null, ""], [null, null, "\uf0b7 I noted that UGX.66,918,755 was paid to 49 staff who had either"], [null, null, "retired, transferred, absconded or died."], [null, null, ""], [null, null, "\uf0b7 The district over and under remitted payroll deductions worth"], [null, null, "UGX.246,912,350 and UGX.201,704,458 due to wrong coding in"], [null, null, "the system"], [null, null, ""], [null, null, "\uf0b7 I noted that the District made unauthorized loan deductions"], [null, null, "totaling UGX.386, 522,646. The deductions were from 419"], [null, null, "employees that neither had letters of undertaking nor existed in"], [null, null, "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports"], [null, null, ""], [null, null, "\uf0b7 I further noted that loan deductions relating to 16 (sixteen)"], [null, null, "employees did not have evidence of consent by the employees."], [null, null, ""], [null, null, "\uf0b7 The District made PAYE deductions of UGX UGX.314, 021,935 for"], [null, null, "the month of February 2021, but did not remit to URA as"], [null, null, "required"], [null, null, ""], [null, null, "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity"], [null, null, "totalling to UGX.105,792,166 to the computation of PAYE in IPPS,"], [null, null, "leading to an under deduction of UGX.33,858,520, contrary to"], [null, null, "section 19(1) (a) of the Income Tax Act and also noted tha t 58"], [null, null, "pensioners delayed to access the pension payroll during the year."], [null, null, ""], [null, null, "\uf0b7 I noted that unqualifying funds amounting to UGX.52, 328,174"], [null, null, "were charged on account codes prescribed for salary, pension"], [null, null, "and gratuity."]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 429, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "417", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 429, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", ""], [null, "\uf0b7 I noted that 29 employees were paid a total of UGX.51,348,377"], [null, "without signed pay change reports."]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 430, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None"], "type": "table"}}, {"content": [["", ""], [null, "\uf0b7 I noted that 29 employees were paid a total of UGX.51,348,377"], [null, "without signed pay change reports."], [null, ""], [null, "\uf0b7 I noted that 1,302 staff was paid a total of UGX. 3,048,993,948"], [null, "off the IPPS that arose from wrong coding of Arua DLG staff"], [null, "under Madi-Okollo DLG payroll arising from the separation of the"], [null, "payroll following the creation of Madi-Okollo district."], [null, ""], [null, "\uf0b7 The budget of Arua DLG was not adjusted/collapsed following"], [null, "the issuance of the supplementary budgets to the new local"], [null, "governments. Consequently, the budget of Arua DLG for the year"], [null, "under review is unrealistic. Further, activities meant to be"], [null, "undertaken by the new local governments were undertaken by"], [null, "Arua DLG for example the payment of general staff salaries"], [null, "totaling UGX.6,397,754,797 for Terego DLG staff and"], [null, "UGX.8,348,159,119 for Arua city staff. This distorts the budget"], [null, "performance measurement for the local governments involved."], [null, ""], [null, "\uf0b7 I noted underperformance of revenues from NTR, transfer from"], [null, "government units and donor funding worth UGX.30.7Bn that"], [null, "affected budget implementation"], [null, ""], [null, "\uf0b7 The district failed to absorb funds worth UGX.9.3Bn and these"], [null, "funds were subsequently swept back to the consolidated fund"], [null, "account."], [null, ""], [null, "\uf0b7 The district mischarged funds worth UGX.373, 406,160 on"], [null, "various codes other those budgeted for. Further, I noted that"], [null, "funds to the tune of UGX.93, 269,685 were spent on other"], [null, "activities without seeking and obtaining the necessary approvals."], [null, ""], [null, "\uf0b7 I noted outstanding recoveries of funds from YLP and UWEP"], [null, "groups worth UGX.1, 793,009,954 by the year end."], [null, ""], [null, "\uf0b7 I noted that Arua District received a total of UGX.490,472,016. I"], [null, "reviewed the bank statements sampled schools and noted that"], [null, "the funds were still on the school accounts by 30th September,"], [null, "2021 and had hence not been utilized."], ["14\\. ADJUMANI DLG Opinion Unqualified \uf0b7 I reviewed funds absorption for salary and pension payments and noted under absorption of UGX.1.2 billion which may have led to non payment of eligible employees and pensioners \uf0b7 I noted that UGX.3,339,798 was paid to 4 staff who had retired. These were payments for services not rendered to the District, resulting in loss of funds to Government. \uf0b7 I noted that the District made unauthorized loan deductions amounting to UGX.39,469,082 relating to 40 employees that neither existed in the \u201cactive deduction\u201d nor the \u201cmy approval\u201d reports on the PDMS as evidence of approval. \uf0b7 I noted that 3 pensioners delayed to access the pension payroll", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 430, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None"], "type": "table"}}, {"content": "418", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 430, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["during the year with average delay period of 39 days to access the pension payroll. \uf0b7 I noted that the District did not submit quarterly returns on payroll to MoPS. This led to accumulations of arrears, under absorption of wage, pension and gratuity budget and delays in granting clearance to recruit. \uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 5 staff was paid a total of UGX.7, 145,972 off the IPPS. This control weakness created an opportunity for payment of salaries to non-eligible persons. \uf0b7 I noted that the verification form and copies of the verification card for 6 pensioners/beneficiaries were not on their files. I was therefore unable to validate, authenticate the accuracy of the payroll records (salary and pension) on the IPPS. \uf0b7 I noted that the District Development Plan III was still in a draft form and had not yet been approved. \uf0b7 The district did not receive funds worth UGX.14,639,062,373 \uf0b7 The district failed to absorb funds worth UGX. 1,621,646,255 by the end of the financial year and the funds were subsequently swept back to the consolidated fund account that affected construction of roads and bridges, Installation of streetlights; and Construction of Leisure Park among others \uf0b7 The funds were meant for activities that were not fully implemented by the end of the financial year and these include; \uf0b7 A review of the revenue management process revealed that there was no invoice register for the amount billed during the year in place and schedule of debtors detailing debtor\u2019s records. I also noted that the district does not have a streamlined policy to be followed to recover the outstanding revenues/amounts. \uf0b7 I noted outstanding YLP balance of UGX.707, 536,351 that has not been recovered by the district which is affecting the revolution of the funds to other groups in the queue \uf0b7 The district had outstanding unrecovered the UWEP funds worth UGX.406,275,629 by close of the year \uf0b7 I noted that the District received a total of UGX. 129,300,127. I reviewed the bank statements sampled schools and noted that the funds were still on the school accounts by 30th September, 2021 and had hence not been utilized.", null, null], ["15.", "Pakwach DLG", "\uf0b7 I noted that the District did not submit wage estimates to MoPs"], ["", "", "by 30th September of the preceding year a required"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 431, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None", "None"], "type": "table"}}, {"content": [["during the year with average delay period of 39 days to access the pension payroll. \uf0b7 I noted that the District did not submit quarterly returns on payroll to MoPS. This led to accumulations of arrears, under absorption of wage, pension and gratuity budget and delays in granting clearance to recruit. \uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 5 staff was paid a total of UGX.7, 145,972 off the IPPS. This control weakness created an opportunity for payment of salaries to non-eligible persons. \uf0b7 I noted that the verification form and copies of the verification card for 6 pensioners/beneficiaries were not on their files. I was therefore unable to validate, authenticate the accuracy of the payroll records (salary and pension) on the IPPS. \uf0b7 I noted that the District Development Plan III was still in a draft form and had not yet been approved. \uf0b7 The district did not receive funds worth UGX.14,639,062,373 \uf0b7 The district failed to absorb funds worth UGX. 1,621,646,255 by the end of the financial year and the funds were subsequently swept back to the consolidated fund account that affected construction of roads and bridges, Installation of streetlights; and Construction of Leisure Park among others \uf0b7 The funds were meant for activities that were not fully implemented by the end of the financial year and these include; \uf0b7 A review of the revenue management process revealed that there was no invoice register for the amount billed during the year in place and schedule of debtors detailing debtor\u2019s records. I also noted that the district does not have a streamlined policy to be followed to recover the outstanding revenues/amounts. \uf0b7 I noted outstanding YLP balance of UGX.707, 536,351 that has not been recovered by the district which is affecting the revolution of the funds to other groups in the queue \uf0b7 The district had outstanding unrecovered the UWEP funds worth UGX.406,275,629 by close of the year \uf0b7 I noted that the District received a total of UGX. 129,300,127. I reviewed the bank statements sampled schools and noted that the funds were still on the school accounts by 30th September, 2021 and had hence not been utilized.", null, null], ["15.", "Pakwach DLG", "\uf0b7 I noted that the District did not submit wage estimates to MoPs"], ["", "", "by 30th September of the preceding year a required"], [null, "Opinion", ""], [null, "Unqualified", "\uf0b7 I reviewed funds absorption and noted that UGX. 10.209 Bn"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 431, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None", "None"], "type": "table"}}, {"content": "419", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 431, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "(94%) was spent out of the total receipts of UGX.10.885 Bn,"], [null, "resulting in an unabsorbed balance of UGX. 0.676 Million. The"], [null, "unabsorbed balance was subsequently swept back to the"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 432, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None"], "type": "table"}}, {"content": [["", "(94%) was spent out of the total receipts of UGX.10.885 Bn,"], [null, "resulting in an unabsorbed balance of UGX. 0.676 Million. The"], [null, "unabsorbed balance was subsequently swept back to the"], [null, "consolidated fund account"], [null, ""], [null, "\uf0b7 I reviewed funds absorption and noted that UGX.19.4 billion"], [null, "(94%) was spent out of the total receipts of UGX.20.6 billion,"], [null, "resulting in an under absorption of UGX.1.2 billion. I further"], [null, "noted an unexplained under absorption of salaries funds totaling"], [null, "UGX. 235,934,838 and under absorption of pension and gratuity"], [null, "totaling UGX.930, 294,356."], [null, ""], [null, "\uf0b7 I noted that UGX.3, 339,798 was paid to 4 staff who had retired."], [null, "These were payments for services not rendered to the District,"], [null, "resulting in loss of funds to Government."], [null, ""], [null, "\uf0b7 I further noted that loan deductions for a sample of 10"], [null, "employees lacked letters of undertaking and did not have"], [null, "evidence of consent."], [null, ""], [null, "\uf0b7 I also noted loan deductions for twenty-eight (28) staff, totaling"], [null, "UGX.33,119,091, were above the approved deduction amount"], [null, "and Loans for fifteen (15) staff totaling UGX.132,794,500 had"], [null, "unreasonable loan end-dates."], [null, ""], [null, "\uf0b7 I noted that the District did not submit quarterly returns on"], [null, "payroll to MoPS. This led to accumulations of arrears, under"], [null, "absorption of wage, pension and gratuity budget and delays in"], [null, "granting clearance to recruit."], [null, ""], [null, "\uf0b7 From a comparison of the payroll register and IFMS payment file,"], [null, "I noted that 5 staff were paid a total of UGX.7, 145,972 off the"], [null, "IPPS. This control weakness created an opportunity for payment"], [null, "of salaries to non-eligible persons"], ["16\\. ARUA MC Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX. 7,083,040,397 constituted 25% of the Municipal Council\u2019s budget for 2020/2021 of 28.3Bn. \uf0b7 I noted that the Municipal Council delayed to submit wage estimates to MoPs, as required. \uf0b7 I reviewed funds absorption and noted that UGX.6.7 billion (98%) was spent out of the total receipts of UGX.6.9 billion for salaries, pension and gratuity \uf0b7 I noted that whereas UGX.1,510,024,063 was deducted from employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,502,519,098 was remitted leading to an under remittance amounting to UGX.7,504,965 \uf0b7 I noted that the entity did not include political leaders\u2019 gratuity of UGX.8,939,400 in the computation of PAYE leading to under deduction of PAYE of UGX.2,681,820", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 432, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None"], "type": "table"}}, {"content": "420", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 432, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that the verification form and copies of the verification card for 09 pensioners/beneficiaries were not on their files \uf0b7 I further noted that the Municipal Council Development Plan III was still in a draft form and had not yet been approved \uf0b7 I noted that the Municipal Council had off-budget receipts totaling UGX.1, 069,848,174 during the year. \uf0b7 I noted a number of issues in the implementation of approved budget suchas as failure to fully quantify outputs, partial and non-implementation of planned activities; over absorption of UGX.761,755,708; revenue underperformance of UGX.2,530,484,439 \uf0b7 I noted that UGX.210,033,250 meant for surfacing of Staff Lane and Construction of Municipal Bypass was utilised for supply and installation of solar street lights on Oluko Road \uf0b7 \uf0b7 I noted that the entity submitted performance report for Q4 after the deadline given for submission of the reports \uf0b7 I noted that there were unapproved overpayments of UGX.1,427,380,000 relating to USMID works on School road and Adroa road \uf0b7 I noted that the Municipal Council made advance payment of UGX.333,383,989 to contractors without bank guarantees \uf0b7 I noted low bidder participation in 3 of the 11 sampled procurements \uf0b7 I noted that the Municipal Council did not receive its approved supplementary development budget totaling UGX.14,340,000,000 under Supplementary Expenditure Estimates Supplied Addendum No.1 to Schedule No.2 for F/Y 2020/2021 \uf0b7 I noted that the Municipal Council did not have an approved staff structure/establishment.", null, null], ["", "MBARARA BRANCH", "Summary of Key Findings"], ["01\\. MBARARA DLG Opinion Unqualified \uf0b7 I analyzed the approved budget and releases to Mbarara District for salary, pension and gratuity in the period under review and noted that the wage and Pension Pay roll of UGX.20,650,503,996 constituted 68% of the District\u2019s budget for 2020/2021 of UGX.30.38 Bn \uf0b7 I noted that the District delayed to submit wage estimates to MoPS, contrary to the Establishment Notice. The submission was made on 18th February 2020, which is 140 days after the required date \uf0b7 I reviewed funds absorption and noted that UGX.19.6 billion (95%) was spent out of the total receipts of UGX.20.7 billion, resulting in an unabsorbed balance of UGX.1.1 billion.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 433, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None", "None"], "type": "table"}}, {"content": "421", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 433, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that the District made unauthorised loan deductions totalling UGX.11.8 million. The deductions were from 40 employees that neither existed in the \u201cactive deduction\u201d nor the \u201cmy approval\u201d reports on the Payroll Deduction Management System (PDMS), operated by Payroll Consults Africa (PCA) \uf0b7 I noted that the District made payroll deductions of UGX. 813,620,096, but did not remit concurrently with the salary payments in 11 out of 12 months. The delay ranged from 5 to 84 days \uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2 months of November 2020 and January 2021 of six (06) and eighty (08) days respectively \uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX. 16,304,260 to the computation of PAYE in IPPS, leading to an under deduction of UGX.4,891,278 \uf0b7 I noted that of the 29 newly recruited/transferred, 13 employees delayed to access payroll, with delays ranging between 6 to 12 weeks \uf0b7 pensioners delayed to access the pension payroll, with delays ranging between 7-10 months \uf0b7 Gratuity and pensions of UGX. 601,669,910 was charged on Salary account which did not reflect the nature of the expenditure \uf0b7 I noted that the District prepared monthly wage, pension and gratuity performance analysis but did not submit quarterly returns on payroll to MoPS \uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect UGX.1,293,851,871 during the year but collected UGX.974,341,070 representing (75%) performance. \uf0b7 The Entity budgeted to receive UGX.2,077,267,871 as transfers from other Government Units. However, only UGX.583,148,567 (28%) was received. Revenue shortfalls affected the implementation of planned activities \uf0b7 The District budgeted to receive UGX.693,590,000 as external/donor financing out of which UGX.53,180,000 (7.7%), was received \uf0b7 I noted that management did not submit quarterly monitoring reports to the Office of the Prime Minister and Mofped as required", null, null], ["02.", "RUBANDA DLG Opinion Unqualified", "\uf0b7 I analysed the approved budget and releases to Rubanda District for salary, pension and gratuity in the period under review and noted that the wage and Pension Pay roll of UGX.17,152,929,012"], [null, null, "constituted 49% of the District\u2019s budget for 2020/2021 of"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 434, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None", "None"], "type": "table"}}, {"content": [["\uf0b7 I noted that the District made unauthorised loan deductions totalling UGX.11.8 million. The deductions were from 40 employees that neither existed in the \u201cactive deduction\u201d nor the \u201cmy approval\u201d reports on the Payroll Deduction Management System (PDMS), operated by Payroll Consults Africa (PCA) \uf0b7 I noted that the District made payroll deductions of UGX. 813,620,096, but did not remit concurrently with the salary payments in 11 out of 12 months. The delay ranged from 5 to 84 days \uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2 months of November 2020 and January 2021 of six (06) and eighty (08) days respectively \uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX. 16,304,260 to the computation of PAYE in IPPS, leading to an under deduction of UGX.4,891,278 \uf0b7 I noted that of the 29 newly recruited/transferred, 13 employees delayed to access payroll, with delays ranging between 6 to 12 weeks \uf0b7 pensioners delayed to access the pension payroll, with delays ranging between 7-10 months \uf0b7 Gratuity and pensions of UGX. 601,669,910 was charged on Salary account which did not reflect the nature of the expenditure \uf0b7 I noted that the District prepared monthly wage, pension and gratuity performance analysis but did not submit quarterly returns on payroll to MoPS \uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect UGX.1,293,851,871 during the year but collected UGX.974,341,070 representing (75%) performance. \uf0b7 The Entity budgeted to receive UGX.2,077,267,871 as transfers from other Government Units. However, only UGX.583,148,567 (28%) was received. Revenue shortfalls affected the implementation of planned activities \uf0b7 The District budgeted to receive UGX.693,590,000 as external/donor financing out of which UGX.53,180,000 (7.7%), was received \uf0b7 I noted that management did not submit quarterly monitoring reports to the Office of the Prime Minister and Mofped as required", null, null], ["02.", "RUBANDA DLG Opinion Unqualified", "\uf0b7 I analysed the approved budget and releases to Rubanda District for salary, pension and gratuity in the period under review and noted that the wage and Pension Pay roll of UGX.17,152,929,012"], [null, null, "constituted 49% of the District\u2019s budget for 2020/2021 of"], [null, null, "UGX.34.85 Bn"], [null, null, "\uf0b7 I reviewed the wage funds absorption and noted that UGX.17.29"], [null, null, "billion(96) was spent out of the total receipts of UGX18.02 billion,"], [null, null, "resulting in an unabsorbed balance of UGX.0.73 billion"], [null, null, "\uf0b7 A review of the payroll data (IPPS) and IFMS payments revealed"], [null, null, "variances between amounts on the approved payroll and"], [null, null, "payments to individual employees, leading to over payment of"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 434, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None", "None"], "type": "table"}}, {"content": "422", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 434, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "UGX. 12,101,332"], [null, "\uf0b7 I noted that 15 employees on the IPPS payroll did not receive"], [null, "salary of UGX. 37,502,687"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 435, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None"], "type": "table"}}, {"content": [["", "UGX. 12,101,332"], [null, "\uf0b7 I noted that 15 employees on the IPPS payroll did not receive"], [null, "salary of UGX. 37,502,687"], [null, "\uf0b7 A comparison of base pay in the IPPS payroll registers with the"], [null, "salary structure for 2020/21, revealed that June payments were"], [null, "made using wrong salary scales, leading to over payments of"], [null, "UGX. 3,197,252, and under payments of UGX. 978,860"], [null, "\uf0b7 I noted that whereas UGX. 4,119,399,533 was deducted from"], [null, "employees\u2019 salaries to be remitted to different beneficiaries, UGX."], [null, "4,110,103,755 was remitted, leading to an over and under"], [null, "remittance amounting to UGX.(234,929,994) and"], [null, "UGX.244,225,772 respectively"], [null, "\uf0b7 I noted that the District made unauthorised loan deductions"], [null, "totalling UGX. 41,736,635 from 22 employees that neither had"], [null, "letters of undertaking nor existed in the \u201cactive deduction\u201d or the"], [null, "\u201cmy approval\u201d reports on the Payroll Deduction Management"], [null, "System (PDMS)"], [null, "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity"], [null, "totalling to UGX. 30,155,400 to the computation of PAYE in IPPS,"], [null, "leading to an under deduction of UGX. 9,113,820 I noted that 9"], [null, "pensioners delayed to access the pension payroll, with delays"], [null, "ranging between 6-15 months"], [null, "\uf0b7 I noted that the District did not prepare monthly wage, pension"], [null, "and gratuity performance analysis and thus did not submit"], [null, "quarterly returns on payroll to MoPS"], [null, "\uf0b7 I observed that there were variances of UGX. 5,667,077 and"], [null, "UGX.7.076,946 between the MoPS IPPS and entity payroll"], [null, "registers availed by the core FTP system"], [null, "\uf0b7 I noted that at the time of audit October 2021 the district"], [null, "strategic plan was not approved by NPA."], [null, "\uf0b7 I noted that the district had planned to collect local revenue of"], [null, "UGX0.587Million but was only able to collect 0.351 million"], [null, "representing 60% performance."], [null, "\uf0b7 Of the UGX.10.13Bn budgeted as transfers from other"], [null, "Government Units, only UGX.0.8 Bn was received representing"], [null, "8% performance"], [null, "\uf0b7 The district did not receive any external/donor financing despite"], [null, "having a budget of UGX0.89Bn"], ["03\\. KAZO DLG Opinion Unqualified \uf0b7 I analysed the approved budget and releases to Kazo district for salary, pension and gratuity in the period under review and noted that the wage and Pension Pay roll of UGX.10,993,531,909 constituted 64.1% of the District\u2019s budget for 2020/2021 of UGX.17,131,504,889 \uf0b7 A comparison of base pay in the IPPS payroll registers with the salary structure for 2020/21, revealed that 20 staff were paid using wrong salary scales, leading to over payments of", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 435, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None"], "type": "table"}}, {"content": "423", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], "page": 435, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UGX269,392", "metadata": {"headings": [{"headings_0": {"content": "UGX269,392", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that UGX.1,605,867 was paid to 3 staff who had either", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.1,605,867 was paid to 3 staff who had either", "page": 436, "level": 3}}, {"headings_1": {"content": "UGX269,392", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "absconded or died", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.1,605,867 was paid to 3 staff who had either", "page": 436, "level": 3}}, {"headings_1": {"content": "UGX269,392", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District made unauthorised loan deductions", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorised loan deductions", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.1,605,867 was paid to 3 staff who had either", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "totalling UGX.43,661,032. The deductions were from 12 employees that neither had letters of undertaking nor existed in", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorised loan deductions", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.1,605,867 was paid to 3 staff who had either", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "metadata": {"headings": [{"headings_0": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 436, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorised loan deductions", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "PDMS-Payroll Deduction Management System, operated by PCA- Payroll Consults Africa.", "metadata": {"headings": [{"headings_0": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 436, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorised loan deductions", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I further noted that loan deductions relating to 12 employees did", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I further noted that loan deductions relating to 12 employees did", "page": 436, "level": 3}}, {"headings_1": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 436, "level": 2}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "not have evidence of consent", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I further noted that loan deductions relating to 12 employees did", "page": 436, "level": 3}}, {"headings_1": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 436, "level": 2}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District made payroll deductions but did not", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions but did not", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I further noted that loan deductions relating to 12 employees did", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "remit concurrently with the salary payments in 7 out of 8", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions but did not", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I further noted that loan deductions relating to 12 employees did", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "months. On average, it delayed by 7 days", "metadata": {"headings": [{"headings_0": {"content": "months. On average, it delayed by 7 days", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made payroll deductions but did not", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 436, "level": 2}}, {"headings_1": {"content": "months. On average, it delayed by 7 days", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "totalling to UGX.29,166,600 to the computation of PAYE in IPPS,", "metadata": {"headings": [{"headings_0": {"content": "totalling to UGX.29,166,600 to the computation of PAYE in IPPS,", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 436, "level": 2}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "leading to an under deduction of UGX.8,652,480", "metadata": {"headings": [{"headings_0": {"content": "totalling to UGX.29,166,600 to the computation of PAYE in IPPS,", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 436, "level": 2}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 436, "level": 3}}, {"headings_1": {"content": "totalling to UGX.29,166,600 to the computation of PAYE in IPPS,", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 436, "level": 3}}, {"headings_1": {"content": "totalling to UGX.29,166,600 to the computation of PAYE in IPPS,", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the district was implementing a strategic plan (2020/21- 2024/25) that had not been approved by National", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district was implementing a strategic plan (2020/21- 2024/25) that had not been approved by National", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Planning Authority", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district was implementing a strategic plan (2020/21- 2024/25) that had not been approved by National", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the district only managed to collect local revenue of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district only managed to collect local revenue of", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district was implementing a strategic plan (2020/21- 2024/25) that had not been approved by National", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX327,102,266 of the budgeted UGX 824,355,800 representing 40% performance", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district only managed to collect local revenue of", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district was implementing a strategic plan (2020/21- 2024/25) that had not been approved by National", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that Transfers received from the consolidated fund", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Transfers received from the consolidated fund", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district only managed to collect local revenue of", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "performed at 90%", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Transfers received from the consolidated fund", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district only managed to collect local revenue of", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted the district did not receive any external financing despite", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted the district did not receive any external financing despite", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Transfers received from the consolidated fund", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "having a budget of UGX 33,504,000", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted the district did not receive any external financing despite", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Transfers received from the consolidated fund", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District received off-budget financing of UGX.552,762,500 which was never paid into the consolidated", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District received off-budget financing of UGX.552,762,500 which was never paid into the consolidated", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted the district did not receive any external financing despite", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "fund as required by the law", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District received off-budget financing of UGX.552,762,500 which was never paid into the consolidated", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted the district did not receive any external financing despite", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 Out of the total receipts for the financial year of UGX.15.12bn", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of UGX.15.12bn", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District received off-budget financing of UGX.552,762,500 which was never paid into the consolidated", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "(including opening balance of UGX.367,655,139) UGX.14.46bn was spent by the entity resulting in an unspent balance of UGX.0.65 Bn representing absorption level of 96%", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of UGX.15.12bn", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District received off-budget financing of UGX.552,762,500 which was never paid into the consolidated", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I assessed the implementation of twenty two (22) outputs that", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I assessed the implementation of twenty two (22) outputs that", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of UGX.15.12bn", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "were fully quantified with a total of twenty-one (22) activities", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I assessed the implementation of twenty two (22) outputs that", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of UGX.15.12bn", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "worth UGX 1.83Bn and noted that Eighteen (18) outputs with total expenditure amounting to UGX 1.16 Bn were fully implemented representing 70.6% of the outputs, Four (4) outputs with total expenditure amounting to UGX.0.67 Bn were", "metadata": {"headings": [{"headings_0": {"content": "worth UGX 1.83Bn and noted that Eighteen (18) outputs with total expenditure amounting to UGX 1.16 Bn were fully implemented representing 70.6% of the outputs, Four (4) outputs with total expenditure amounting to UGX.0.67 Bn were", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I assessed the implementation of twenty two (22) outputs that", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "partially implemented representing 29.4% of the outputs.", "metadata": {"headings": [{"headings_0": {"content": "worth UGX 1.83Bn and noted that Eighteen (18) outputs with total expenditure amounting to UGX 1.16 Bn were fully implemented representing 70.6% of the outputs, Four (4) outputs with total expenditure amounting to UGX.0.67 Bn were", "page": 436, "level": 3}}, {"headings_1": {"content": "\uf0b7 I assessed the implementation of twenty two (22) outputs that", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 436, "level": 3}}, {"headings_1": {"content": "worth UGX 1.83Bn and noted that Eighteen (18) outputs with total expenditure amounting to UGX 1.16 Bn were fully implemented representing 70.6% of the outputs, Four (4) outputs with total expenditure amounting to UGX.0.67 Bn were", "page": 436, "level": 3}}], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Q2, Q3, Q4 after the deadline given for submission of the reports \n424", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 436, "level": 3}}, {"headings_1": {"content": "worth UGX 1.83Bn and noted that Eighteen (18) outputs with total expenditure amounting to UGX 1.16 Bn were fully implemented representing 70.6% of the outputs, Four (4) outputs with total expenditure amounting to UGX.0.67 Bn were", "page": 436, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 436, "level": 3}}, {"headings_1": {"content": "worth UGX 1.83Bn and noted that Eighteen (18) outputs with total expenditure amounting to UGX 1.16 Bn were fully implemented representing 70.6% of the outputs, Four (4) outputs with total expenditure amounting to UGX.0.67 Bn were", "page": 436, "level": 3}}]], "page": 436, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "4. INSINGIRO DLG", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 436, "level": 3}}, {"headings_1": {"content": "worth UGX 1.83Bn and noted that Eighteen (18) outputs with total expenditure amounting to UGX 1.16 Bn were fully implemented representing 70.6% of the outputs, Four (4) outputs with total expenditure amounting to UGX.0.67 Bn were", "page": 436, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 436, "level": 3}}, {"headings_1": {"content": "worth UGX 1.83Bn and noted that Eighteen (18) outputs with total expenditure amounting to UGX 1.16 Bn were fully implemented representing 70.6% of the outputs, Four (4) outputs with total expenditure amounting to UGX.0.67 Bn were", "page": 436, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Opinion Unqualified", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 436, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I analysed the approved budget and releases to the District for", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I analysed the approved budget and releases to the District for", "page": 437, "level": 3}}, {"headings_1": {"content": "Opinion Unqualified", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "salary, pension and gratuity in the period under review and noted that the wage and Pension Pay roll of UGX.25,700,415,566", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I analysed the approved budget and releases to the District for", "page": 437, "level": 3}}, {"headings_1": {"content": "Opinion Unqualified", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "constituted 29.4% of the District\u2019s budget for 2020/2021 of", "metadata": {"headings": [{"headings_0": {"content": "constituted 29.4% of the District\u2019s budget for 2020/2021 of", "page": 437, "level": 2}}, {"headings_1": {"content": "\uf0b7 I analysed the approved budget and releases to the District for", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.87.35 Bn", "metadata": {"headings": [{"headings_0": {"content": "constituted 29.4% of the District\u2019s budget for 2020/2021 of", "page": 437, "level": 2}}, {"headings_1": {"content": "\uf0b7 I analysed the approved budget and releases to the District for", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District delayed to submit wage estimates to MoPs, as required. The submission was made after 30th September 2020. This may lead to wage shortfalls/over provision", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District delayed to submit wage estimates to MoPs, as required. The submission was made after 30th September 2020. This may lead to wage shortfalls/over provision", "page": 437, "level": 3}}, {"headings_1": {"content": "constituted 29.4% of the District\u2019s budget for 2020/2021 of", "page": 437, "level": 2}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "due to lack of clarity and analysis of wage estimates by MoPS", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District delayed to submit wage estimates to MoPs, as required. The submission was made after 30th September 2020. This may lead to wage shortfalls/over provision", "page": 437, "level": 3}}, {"headings_1": {"content": "constituted 29.4% of the District\u2019s budget for 2020/2021 of", "page": 437, "level": 2}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The District paid out a total of UGX.14,568,696 to 12 non- existent staff. These were not on the IPPS payroll register and", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The District paid out a total of UGX.14,568,696 to 12 non- existent staff. These were not on the IPPS payroll register and", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District delayed to submit wage estimates to MoPs, as required. The submission was made after 30th September 2020. This may lead to wage shortfalls/over provision", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "also lacked the necessary documentation to support their existence", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The District paid out a total of UGX.14,568,696 to 12 non- existent staff. These were not on the IPPS payroll register and", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District delayed to submit wage estimates to MoPs, as required. The submission was made after 30th September 2020. This may lead to wage shortfalls/over provision", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 The District paid out a total of UGX.14,568,696 to 12 non- existent staff. These were not on the IPPS payroll register and", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "salary structure for 2020/21 revealed that seventeen (17) staff were paid using wrong salary scales, leading to under payment of UGX.189,881", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 The District paid out a total of UGX.14,568,696 to 12 non- existent staff. These were not on the IPPS payroll register and", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that UGX.9,922,552 was paid to five (5) staff who had", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.9,922,552 was paid to five (5) staff who had", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "either retired, transferred, absconded or died", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.9,922,552 was paid to five (5) staff who had", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.5,426,888,768 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.9,922,552 was paid to five (5) staff who had", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.9,922,552 was paid to five (5) staff who had", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "employees\u2019 salaries to be remitted to different beneficiaries,", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries,", "page": 437, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.9,922,552 was paid to five (5) staff who had", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.4,951,234,873 was remitted, leading to an under remittance of UGX.475,653,895", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries,", "page": 437, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.9,922,552 was paid to five (5) staff who had", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 437, "level": 2}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries,", "page": 437, "level": 2}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "totalling to UGX.42,781,000 to the computation of PAYE in IPPS,", "metadata": {"headings": [{"headings_0": {"content": "totalling to UGX.42,781,000 to the computation of PAYE in IPPS,", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 437, "level": 2}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "leading to an under deduction of UGX.12,900,150", "metadata": {"headings": [{"headings_0": {"content": "totalling to UGX.42,781,000 to the computation of PAYE in IPPS,", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 437, "level": 2}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that one retiree who was last paid in October, 2020 had", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that one retiree who was last paid in October, 2020 had", "page": 437, "level": 3}}, {"headings_1": {"content": "totalling to UGX.42,781,000 to the computation of PAYE in IPPS,", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "not yet accessed the pension payroll by the time of audit", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that one retiree who was last paid in October, 2020 had", "page": 437, "level": 3}}, {"headings_1": {"content": "totalling to UGX.42,781,000 to the computation of PAYE in IPPS,", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that UGX.12,152,847 was diverted to Bangirana Josaphat M employee no 524376) as residual pension arrears from April 2015 to October 2019. However, these had not been verified and therefore not part of schedule provided by MoFPED", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.12,152,847 was diverted to Bangirana Josaphat M employee no 524376) as residual pension arrears from April 2015 to October 2019. However, these had not been verified and therefore not part of schedule provided by MoFPED", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that one retiree who was last paid in October, 2020 had", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that 05 employees were paid a total of UGX.9,087,270", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 05 employees were paid a total of UGX.9,087,270", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.12,152,847 was diverted to Bangirana Josaphat M employee no 524376) as residual pension arrears from April 2015 to October 2019. However, these had not been verified and therefore not part of schedule provided by MoFPED", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "without signed pay change reports", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 05 employees were paid a total of UGX.9,087,270", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.12,152,847 was diverted to Bangirana Josaphat M employee no 524376) as residual pension arrears from April 2015 to October 2019. However, these had not been verified and therefore not part of schedule provided by MoFPED", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 05 employees were paid a total of UGX.9,087,270", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 05 employees were paid a total of UGX.9,087,270", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that twelve (12) staff and 02 pensioners were paid a", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that twelve (12) staff and 02 pensioners were paid a", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "total of UGX.32,785,938 off the IPPS \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that twelve (12) staff and 02 pensioners were paid a", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 437, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that twelve (12) staff and 02 pensioners were paid a", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 437, "level": 3}}]], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that there were variances of UGX.12,355,491", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that twelve (12) staff and 02 pensioners were paid a", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "between the figures in the MoPS IPPS and entity payroll registers", "metadata": {"headings": [{"headings_0": {"content": "between the figures in the MoPS IPPS and entity payroll registers", "page": 437, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that twelve (12) staff and 02 pensioners were paid a", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}, {"headings_1": {"content": "between the figures in the MoPS IPPS and entity payroll registers", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.1,029,300,000 during the year but collected UGX. 778,835,482 representing (83%) performance \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}, {"headings_1": {"content": "between the figures in the MoPS IPPS and entity payroll registers", "page": 437, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}, {"headings_1": {"content": "between the figures in the MoPS IPPS and entity payroll registers", "page": 437, "level": 3}}]], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The entity budgeted to receive UGX.39,034,900,000 as transfers", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}, {"headings_1": {"content": "between the figures in the MoPS IPPS and entity payroll registers", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "425 \nfrom other Government Units. However, only UGX.16,417,071,378 (42%) was received", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}, {"headings_1": {"content": "between the figures in the MoPS IPPS and entity payroll registers", "page": 437, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}, {"headings_1": {"content": "between the figures in the MoPS IPPS and entity payroll registers", "page": 437, "level": 3}}]], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The District budgeted to receive UGX.3,112,206,100 as", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.3,112,206,100 as", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "external/donor financing out of which UGX.1,226,592,425", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.3,112,206,100 as", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "(39.4%)", "metadata": {"headings": [{"headings_0": {"content": "(39.4%)", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 The District budgeted to receive UGX.3,112,206,100 as", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 Out of the total receipts for the financial year of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 438, "level": 3}}, {"headings_1": {"content": "(39.4%)", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "(UGX.61,860,404,265 \u2013 1,313,798,884), UGX.61,310,829,945 (89%) was spent by the entity resulting in an unspent balance of UGX.764,224,564 (08%).", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 438, "level": 3}}, {"headings_1": {"content": "(39.4%)", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I assessed the implementation of thirty two (32) outputs that", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I assessed the implementation of thirty two (32) outputs that", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "were fully quantified with a total of thirty two (32) activities worth UGX.3.505 Bn and noted the following", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I assessed the implementation of thirty two (32) outputs that", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 Thirty (30) outputs with a total of thirty (30) activities worth", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Thirty (30) outputs with a total of thirty (30) activities worth", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I assessed the implementation of thirty two (32) outputs that", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.2.771 Bn were fully implemented.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Thirty (30) outputs with a total of thirty (30) activities worth", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I assessed the implementation of thirty two (32) outputs that", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 Two (02) outputs with a total of two (02) activities worth UGX.0.734 Bn were partially implemented by the time of audit", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Two (02) outputs with a total of two (02) activities worth UGX.0.734 Bn were partially implemented by the time of audit", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 Thirty (30) outputs with a total of thirty (30) activities worth", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required.", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 Two (02) outputs with a total of two (02) activities worth UGX.0.734 Bn were partially implemented by the time of audit", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 The entity had not also submitted quarterly monitoring reports to", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The entity had not also submitted quarterly monitoring reports to", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required.", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the Office of the Prime Minister and Moped as required by the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The entity had not also submitted quarterly monitoring reports to", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required.", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "time of audit 10th of September 2021 I noted that Management submitted performance reports for Q1, Q2, Q3 and 4 after the", "metadata": {"headings": [{"headings_0": {"content": "time of audit 10th of September 2021 I noted that Management submitted performance reports for Q1, Q2, Q3 and 4 after the", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 The entity had not also submitted quarterly monitoring reports to", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "deadline given for submission of the reports", "metadata": {"headings": [{"headings_0": {"content": "time of audit 10th of September 2021 I noted that Management submitted performance reports for Q1, Q2, Q3 and 4 after the", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 The entity had not also submitted quarterly monitoring reports to", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I audited the Construction of Ruborogota seed school under UgIFT and I observed that no liquidated damages were charged", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I audited the Construction of Ruborogota seed school under UgIFT and I observed that no liquidated damages were charged", "page": 438, "level": 3}}, {"headings_1": {"content": "time of audit 10th of September 2021 I noted that Management submitted performance reports for Q1, Q2, Q3 and 4 after the", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "to the contractor by management as stipulated in terms and", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I audited the Construction of Ruborogota seed school under UgIFT and I observed that no liquidated damages were charged", "page": 438, "level": 3}}, {"headings_1": {"content": "time of audit 10th of September 2021 I noted that Management submitted performance reports for Q1, Q2, Q3 and 4 after the", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "conditions of the agreement. I further noted that overall physical", "metadata": {"headings": [{"headings_0": {"content": "conditions of the agreement. I further noted that overall physical", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I audited the Construction of Ruborogota seed school under UgIFT and I observed that no liquidated damages were charged", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "progress was at 75.2% and the financial progress was at 68% as", "metadata": {"headings": [{"headings_0": {"content": "conditions of the agreement. I further noted that overall physical", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I audited the Construction of Ruborogota seed school under UgIFT and I observed that no liquidated damages were charged", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "per monthly progress report of July 2021 implying", "metadata": {"headings": [{"headings_0": {"content": "per monthly progress report of July 2021 implying", "page": 438, "level": 3}}, {"headings_1": {"content": "conditions of the agreement. I further noted that overall physical", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.667,629,755 were lying idle on the account", "metadata": {"headings": [{"headings_0": {"content": "per monthly progress report of July 2021 implying", "page": 438, "level": 3}}, {"headings_1": {"content": "conditions of the agreement. I further noted that overall physical", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that taxes amounting to UGX.3,344,640 were never paid", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that taxes amounting to UGX.3,344,640 were never paid", "page": 438, "level": 3}}, {"headings_1": {"content": "per monthly progress report of July 2021 implying", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "to URA as summarised in the table I inspected various prices of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that taxes amounting to UGX.3,344,640 were never paid", "page": 438, "level": 3}}, {"headings_1": {"content": "per monthly progress report of July 2021 implying", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "land owned by the District and noted that most of it lacked land", "metadata": {"headings": [{"headings_0": {"content": "land owned by the District and noted that most of it lacked land", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that taxes amounting to UGX.3,344,640 were never paid", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "titles and three pieces of land (6.6 acres) had been encroached on by private developers", "metadata": {"headings": [{"headings_0": {"content": "land owned by the District and noted that most of it lacked land", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that taxes amounting to UGX.3,344,640 were never paid", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that most of the District land did not have certificates of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that most of the District land did not have certificates of", "page": 438, "level": 3}}, {"headings_1": {"content": "land owned by the District and noted that most of it lacked land", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "title", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that most of the District land did not have certificates of", "page": 438, "level": 3}}, {"headings_1": {"content": "land owned by the District and noted that most of it lacked land", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that as per quarter 2nd 2020/2021 Youth Livelihood Programme Performance Report by the focal person to the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that as per quarter 2nd 2020/2021 Youth Livelihood Programme Performance Report by the focal person to the", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that most of the District land did not have certificates of", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Accounting Officer, dated 30st December 2020, that", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that as per quarter 2nd 2020/2021 Youth Livelihood Programme Performance Report by the focal person to the", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that most of the District land did not have certificates of", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving", "metadata": {"headings": [{"headings_0": {"content": "UGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that as per quarter 2nd 2020/2021 Youth Livelihood Programme Performance Report by the focal person to the", "page": 438, "level": 3}}], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.1,367,353,783 unrecovered \n426", "metadata": {"headings": [{"headings_0": {"content": "UGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that as per quarter 2nd 2020/2021 Youth Livelihood Programme Performance Report by the focal person to the", "page": 438, "level": 3}}, [{"headings_0": {"content": "UGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that as per quarter 2nd 2020/2021 Youth Livelihood Programme Performance Report by the focal person to the", "page": 438, "level": 3}}]], "page": 438, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "5. BUHWEJU DLG", "metadata": {"headings": [{"headings_0": {"content": "UGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that as per quarter 2nd 2020/2021 Youth Livelihood Programme Performance Report by the focal person to the", "page": 438, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "UGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving", "page": 438, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that as per quarter 2nd 2020/2021 Youth Livelihood Programme Performance Report by the focal person to the", "page": 438, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Opinion Unqualified", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified", "page": 439, "level": 3}}, {"headings_1": {"content": "UGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving", "page": 438, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the wage and pension pay roll of UGX.9,342,366,801", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the wage and pension pay roll of UGX.9,342,366,801", "page": 439, "level": 3}}, {"headings_1": {"content": "Opinion Unqualified", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "constituted 54% of the District\u2019s budget for 2020/2021 of", "metadata": {"headings": [{"headings_0": {"content": "constituted 54% of the District\u2019s budget for 2020/2021 of", "page": 439, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the wage and pension pay roll of UGX.9,342,366,801", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.17,438,067,437.", "metadata": {"headings": [{"headings_0": {"content": "UGX.17,438,067,437.", "page": 439, "level": 3}}, {"headings_1": {"content": "constituted 54% of the District\u2019s budget for 2020/2021 of", "page": 439, "level": 2}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "page": 439, "level": 3}}, {"headings_1": {"content": "UGX.17,438,067,437.", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "MoPs, as required", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "page": 439, "level": 3}}, {"headings_1": {"content": "UGX.17,438,067,437.", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.9.34 billion (107%) was spent out of the total receipts of UGX.8.57 billion, resulting in an excess expenditure of UGX.0.64 billion", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.9.34 billion (107%) was spent out of the total receipts of UGX.8.57 billion, resulting in an excess expenditure of UGX.0.64 billion", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- I noted a salary over payment of UGX.278,550,496\n- I noted a salary under payment of UGX.36,127,180", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.9.34 billion (107%) was spent out of the total receipts of UGX.8.57 billion, resulting in an excess expenditure of UGX.0.64 billion", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.9.34 billion (107%) was spent out of the total receipts of UGX.8.57 billion, resulting in an excess expenditure of UGX.0.64 billion", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I was not availed with the pension payroll data and I was unable to compare pension and gratuity payroll amount with IFMS", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I was not availed with the pension payroll data and I was unable to compare pension and gratuity payroll amount with IFMS", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.9.34 billion (107%) was spent out of the total receipts of UGX.8.57 billion, resulting in an excess expenditure of UGX.0.64 billion", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "payments of UGX.608,581,426 and UGX.302,628,319 for gratuity and pension respectively", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I was not availed with the pension payroll data and I was unable to compare pension and gratuity payroll amount with IFMS", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.9.34 billion (107%) was spent out of the total receipts of UGX.8.57 billion, resulting in an excess expenditure of UGX.0.64 billion", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 116 staff were paid salary using wrong salary scales,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 116 staff were paid salary using wrong salary scales,", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I was not availed with the pension payroll data and I was unable to compare pension and gratuity payroll amount with IFMS", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "leading to over payments of UGX.72,081,318", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 116 staff were paid salary using wrong salary scales,", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I was not availed with the pension payroll data and I was unable to compare pension and gratuity payroll amount with IFMS", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I was not availed with information on staff departures and I", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I was not availed with information on staff departures and I", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 116 staff were paid salary using wrong salary scales,", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "could not ascertain the duration of the delayed deletions", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I was not availed with information on staff departures and I", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 116 staff were paid salary using wrong salary scales,", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that UGX.756,742,653 was deducted from employees\u2019", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I was not availed with information on staff departures and I", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 116 staff were paid salary using wrong salary scales,", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I was not availed with information on staff departures and I", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 116 staff were paid salary using wrong salary scales,", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "salaries to be remitted to Uganda Consumer Lenders'", "metadata": {"headings": [{"headings_0": {"content": "salaries to be remitted to Uganda Consumer Lenders'", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I was not availed with information on staff departures and I", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Association/Uganda Bankers' Association, and UGX.756,916,127 was remitted, leading to an over remittance of UGX.173,474", "metadata": {"headings": [{"headings_0": {"content": "Association/Uganda Bankers' Association, and UGX.756,916,127 was remitted, leading to an over remittance of UGX.173,474", "page": 439, "level": 3}}, {"headings_1": {"content": "salaries to be remitted to Uganda Consumer Lenders'", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.756,742,653, but did not remit concurrently with the salary payments in all the 6 months. On average, it delayed by 41 days", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.756,742,653, but did not remit concurrently with the salary payments in all the 6 months. On average, it delayed by 41 days", "page": 439, "level": 3}}, {"headings_1": {"content": "Association/Uganda Bankers' Association, and UGX.756,916,127 was remitted, leading to an over remittance of UGX.173,474", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.756,742,653, but did not remit concurrently with the salary payments in all the 6 months. On average, it delayed by 41 days", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "ranging from 2 \u2013 46 days", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.756,742,653, but did not remit concurrently with the salary payments in all the 6 months. On average, it delayed by 41 days", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I was not availed with lists of new staff and leavers, I could", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I was not availed with lists of new staff and leavers, I could", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "therefore not establish the timing of accessibility to the payroll by the new staff.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I was not availed with lists of new staff and leavers, I could", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that salary entries amounting to UGX.184,483,367 to", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that salary entries amounting to UGX.184,483,367 to", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I was not availed with lists of new staff and leavers, I could", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "several employees were not supported by signed pay change reports", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that salary entries amounting to UGX.184,483,367 to", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I was not availed with lists of new staff and leavers, I could", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that salary entries amounting to UGX.184,483,367 to", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "and gratuity performance analysis and did not submit quarterly returns on payroll to MoPS", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that salary entries amounting to UGX.184,483,367 to", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 102 staff were paid a total of UGX.499,116,733 off", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 102 staff were paid a total of UGX.499,116,733 off", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the IPPS", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 102 staff were paid a total of UGX.499,116,733 off", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the verification form and copies of the verification", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the verification form and copies of the verification", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 102 staff were paid a total of UGX.499,116,733 off", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "card for employees and pensioners/beneficiaries on their files were not availed for audit review", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the verification form and copies of the verification", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 102 staff were paid a total of UGX.499,116,733 off", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID", "page": 439, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the verification form and copies of the verification", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "metadata": {"headings": [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}, {"headings_1": {"content": "\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "following; \n427", "metadata": {"headings": [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}, {"headings_1": {"content": "\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID", "page": 439, "level": 3}}, [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}, {"headings_1": {"content": "\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID", "page": 439, "level": 3}}]], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 In-adequate sensitization and training in the use and navigation of the system \uf0b7 System was not reliable and effective \uf0b7 Operational challenges were encountered; \uf0b7 E.g. Un-reliable network in Buhweju where HR staff had to physically travel to the neighbouring Districts to be able to download documents such as pension payroll registers. \uf0b7 Inadequate staffing of the HR department \uf0b7 I noted that the district budgeted to collect UGX.155,201,000 during the year but collected UGX.136,282,651 representing (88%) performance. The shortfalls in Local Revenue collections of UGX. 18,918,349 (12%) were recorded in Local Service Tax, Land Fees and Application Fees \uf0b7 I noted that entity budgeted to receive UGX.758,657,000 as transfers from other Government Units. However, only UGX.537,760,298 (70.9%) was received \uf0b7 I assessed the implementation of seven (7) outputs that were fully quantified with a total of seven (7) activities worth UGX 1.6 Bn and noted the following. \uf0b7 Five (05) outputs with a total of five (05) activities worth UGX.1.03Bn were fully implemented. The entity implemented all the five (05) activities (100%) within these outputs. \uf0b7 Two (02) outputs with a total of two (02) activities worth UGX.0.5 Bn were partially implemented. \uf0b7 I noted that the district had commenced implementation of two (2) UgIFT projects namely; Upgrading of Engaju HC II to HC III and Upgrade of Rushambya HC II to HC III and noted the following; \uf0b7 Upgrading of Rushambya Health Centre II to Health Centre III; The medical facility had been completed but lacked medical equipment to enable functionality and service delivery \uf0b7 Upgrade of Engaju HC II to HC III; The project stalled but medical equipment had been procured and an advance payment of UGX. 211,119,458 was made during the year", null, null], ["06.", "BUSHENYI DLG Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Pay roll of UGX.21,998,865,997 constituted 54% of the District\u2019s budget for 2020/2021 of UGX.40,645,826,438."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}, {"headings_1": {"content": "\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID", "page": 439, "level": 3}}], "page": 440, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "428", "metadata": {"headings": [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}, {"headings_1": {"content": "\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID", "page": 439, "level": 3}}], "page": 440, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.1,504,757,075 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}, {"headings_1": {"content": "\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID", "page": 439, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}, {"headings_1": {"content": "\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID", "page": 439, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,517,190,079 was remitted, leading to an over/ under", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,517,190,079 was remitted, leading to an over/ under", "page": 441, "level": 2}}, {"headings_1": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "remittance of UGX.12,433,004 and UGX.6,100,834", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,517,190,079 was remitted, leading to an over/ under", "page": 441, "level": 2}}, {"headings_1": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District made payroll deductions but did not", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions but did not", "page": 441, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,517,190,079 was remitted, leading to an over/ under", "page": 441, "level": 2}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "remit concurrently with the salary payments in 5 out of 7", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions but did not", "page": 441, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,517,190,079 was remitted, leading to an over/ under", "page": 441, "level": 2}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "months. On average, it delayed by 7 days", "metadata": {"headings": [{"headings_0": {"content": "months. On average, it delayed by 7 days", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made payroll deductions but did not", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the district had outstanding salary arrears from", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district had outstanding salary arrears from", "page": 441, "level": 3}}, {"headings_1": {"content": "months. On average, it delayed by 7 days", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "previous years\u2019 worth UGX.34,719,743 that remained unpaid at", "metadata": {"headings": [{"headings_0": {"content": "previous years\u2019 worth UGX.34,719,743 that remained unpaid at", "page": 441, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the district had outstanding salary arrears from", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the end of the financial year", "metadata": {"headings": [{"headings_0": {"content": "previous years\u2019 worth UGX.34,719,743 that remained unpaid at", "page": 441, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the district had outstanding salary arrears from", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I carried out a survey to establish the effectiveness and reliability", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I carried out a survey to establish the effectiveness and reliability", "page": 441, "level": 3}}, {"headings_1": {"content": "previous years\u2019 worth UGX.34,719,743 that remained unpaid at", "page": 441, "level": 2}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "metadata": {"headings": [{"headings_0": {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "page": 441, "level": 2}}, {"headings_1": {"content": "\uf0b7 I carried out a survey to establish the effectiveness and reliability", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "interface and noted the following; \n", "metadata": {"headings": [{"headings_0": {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "page": 441, "level": 2}}, {"headings_1": {"content": "\uf0b7 I carried out a survey to establish the effectiveness and reliability", "page": 441, "level": 3}}, [{"headings_0": {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "page": 441, "level": 2}}, {"headings_1": {"content": "\uf0b7 I carried out a survey to establish the effectiveness and reliability", "page": 441, "level": 3}}]], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Operational challenges were encountered;", "metadata": {"headings": [{"headings_0": {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "page": 441, "level": 2}}, {"headings_1": {"content": "\uf0b7 I carried out a survey to establish the effectiveness and reliability", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 Mismatches of names that take long to be corrected by NIRA and", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Mismatches of names that take long to be corrected by NIRA and", "page": 441, "level": 3}}, {"headings_1": {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "page": 441, "level": 2}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "affects ability to timely access people on payroll.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Mismatches of names that take long to be corrected by NIRA and", "page": 441, "level": 3}}, {"headings_1": {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "page": 441, "level": 2}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- In some cases, the status under IPPS remain \u201cNOT VERIFIED\u201d", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Mismatches of names that take long to be corrected by NIRA and", "page": 441, "level": 3}}, {"headings_1": {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "page": 441, "level": 2}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Mismatches of names that take long to be corrected by NIRA and", "page": 441, "level": 3}}, {"headings_1": {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "page": 441, "level": 2}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "even when the record is verified and approved. This again", "metadata": {"headings": [{"headings_0": {"content": "even when the record is verified and approved. This again", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 Mismatches of names that take long to be corrected by NIRA and", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "requires one to contact Ministry of Public service for an", "metadata": {"headings": [{"headings_0": {"content": "requires one to contact Ministry of Public service for an", "page": 441, "level": 3}}, {"headings_1": {"content": "even when the record is verified and approved. This again", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "intervention.", "metadata": {"headings": [{"headings_0": {"content": "requires one to contact Ministry of Public service for an", "page": 441, "level": 3}}, {"headings_1": {"content": "even when the record is verified and approved. This again", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "page": 441, "level": 3}}, {"headings_1": {"content": "requires one to contact Ministry of Public service for an", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- I noted that Bushenyi District budgeted to collect", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "page": 441, "level": 3}}, {"headings_1": {"content": "requires one to contact Ministry of Public service for an", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "page": 441, "level": 3}}, {"headings_1": {"content": "requires one to contact Ministry of Public service for an", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UGX.630,746,210 in the year under review however the entity", "metadata": {"headings": [{"headings_0": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "only collected UGX.393,072,939 representing 62% performance.", "metadata": {"headings": [{"headings_0": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The entity budgeted to receive UGX.29,905,844,709 from the consolidated fund out of which UGX.28,011,829,956 was received representing causing a shortfall of UGX.1,894,014,753 representing 94% performance", "metadata": {"headings": [{"headings_0": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "page": 441, "level": 3}}, [{"headings_0": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "page": 441, "level": 3}}]], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The entity budgeted to receive UGX.9,669,035,803 as transfers", "metadata": {"headings": [{"headings_0": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "from other Government Units out of which UGX.1,522,149,995", "metadata": {"headings": [{"headings_0": {"content": "from other Government Units out of which UGX.1,522,149,995", "page": 441, "level": 3}}, {"headings_1": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "were received representing 16% performance leading to a shortfall of UGX. 8,146,885,809 (84%)", "metadata": {"headings": [{"headings_0": {"content": "from other Government Units out of which UGX.1,522,149,995", "page": 441, "level": 3}}, {"headings_1": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The entity budgeted to receive UGX.440,199,716 as", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The entity budgeted to receive UGX.440,199,716 as", "page": 441, "level": 3}}, {"headings_1": {"content": "from other Government Units out of which UGX.1,522,149,995", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "external/donor financing out of which UGX.86,160,000 was received representing 6% performance", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The entity budgeted to receive UGX.440,199,716 as", "page": 441, "level": 3}}, {"headings_1": {"content": "from other Government Units out of which UGX.1,522,149,995", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I assessed the implementation of Twenty two (22) outputs that were fully quantified with a total of Twenty two (22) activities worth UGX 3.13 Bn and noted the following;", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I assessed the implementation of Twenty two (22) outputs that were fully quantified with a total of Twenty two (22) activities worth UGX 3.13 Bn and noted the following;", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 The entity budgeted to receive UGX.440,199,716 as", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 Fifteen (15) outputs with a total of fifteen (15) activities worth", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Fifteen (15) outputs with a total of fifteen (15) activities worth", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 I assessed the implementation of Twenty two (22) outputs that were fully quantified with a total of Twenty two (22) activities worth UGX 3.13 Bn and noted the following;", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.2.38 Bn were fully implemented.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Fifteen (15) outputs with a total of fifteen (15) activities worth", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 I assessed the implementation of Twenty two (22) outputs that were fully quantified with a total of Twenty two (22) activities worth UGX 3.13 Bn and noted the following;", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 Five(05) outputs with a total of Five(05) activities worth UGX 0.70 Bn were partially implemented by the time of audit.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Five(05) outputs with a total of Five(05) activities worth UGX 0.70 Bn were partially implemented by the time of audit.", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 Fifteen (15) outputs with a total of fifteen (15) activities worth", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit.", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 Five(05) outputs with a total of Five(05) activities worth UGX 0.70 Bn were partially implemented by the time of audit.", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "429", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit.", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 Five(05) outputs with a total of Five(05) activities worth UGX 0.70 Bn were partially implemented by the time of audit.", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 I noted that the entity submitted performance reports for Q1,"], [null, null, "Q2, Q3, Q4 after the deadline given for submission"], [null, null, "\uf0b7 A total of 261.4km at an estimated cost of UGX.94,152,000 was"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit.", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 Five(05) outputs with a total of Five(05) activities worth UGX 0.70 Bn were partially implemented by the time of audit.", "page": 441, "level": 3}}], "page": 442, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", null, "\uf0b7 I noted that the entity submitted performance reports for Q1,"], [null, null, "Q2, Q3, Q4 after the deadline given for submission"], [null, null, "\uf0b7 A total of 261.4km at an estimated cost of UGX.94,152,000 was"], [null, null, "planned to be undertaken, I noted that UGX.75,588,000 was"], [null, null, "received and all used for maintaining 209.9 Km implying a"], [null, null, "shortfall of UGX.18,564,000 which affected implementation of"], [null, null, "51.5Km of roads"], ["07\\. IBANDA DLG Opinion Unqualified \uf0b7 I noted the wage and Pension Pay roll of UGX.13,873,913,709 constituted 56% of the District\u2019s budget for 2020/2021 of UGX.24,675,034,751 \uf0b7 I reviewed payroll funds absorption and noted that UGX.11.6 billion (90.6%) was spent out of the total receipts of UGX.12.8 billion, resulting in an unabsorbed balance of UGX.1.1 billion. \uf0b7 I noted that the District made payroll deductions but did not remit it concurrently with the salary payments in 6 months. The delays ranged from 5 to 28 days \uf0b7 I noted that 191 newly recruited/transferred employees delayed to access payroll, with delays ranging between 1-9 months \uf0b7 I noted that only eight (8) pensioners delayed to access the pension payroll, with delays ranging between 2-7 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that although the entity had prepared a strategic plan that at the time of audit, it had not yet been approved as aligned to the NDP-III \uf0b7 I noted that the entity budgeted to receive UGX.22.11Bn as grants from the Treasury. However, only UGX.19.45Bn was received representing 88% performance leading to budget shortfall of UGX.2.66 Bn (12%). \uf0b7 I noted that the entity budgeted to receive UGX.1.48Bn as transfers from other Government Units. However, only UGX.1.22Bn was received representing 82.4% performance leading to revenue shortfall of UGX. 0.26Bn (17.6%). \uf0b7 I noted that the entity budgeted to receive UGX. 0.39Bn as external/donor financing out of which UGX.0.14Bn was received representing 36% performance leading to revenue shortfall of UGX.0.25Bn (63%). \uf0b7 The entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required. \uf0b7 The entity also did not submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED as required", null, null], ["08.", "KABALE DLG Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Pay roll of UGX.23,557,107,073 constituted 49.6% of the District\u2019s budget for 2020/2021 of UGX.47,484,993,193,"], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit.", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 Five(05) outputs with a total of Five(05) activities worth UGX 0.70 Bn were partially implemented by the time of audit.", "page": 441, "level": 3}}], "page": 442, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "430", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit.", "page": 441, "level": 3}}, {"headings_1": {"content": "\uf0b7 Five(05) outputs with a total of Five(05) activities worth UGX 0.70 Bn were partially implemented by the time of audit.", "page": 441, "level": 3}}], "page": 442, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that UGX.52,165,651 was paid to 30 staff who had either", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.52,165,651 was paid to 30 staff who had either", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit.", "page": 441, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "retired, transferred, absconded or died", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.52,165,651 was paid to 30 staff who had either", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit.", "page": 441, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District made unauthorised loan deductions totalling to UGX.107 million. The deductions were from 30 employees that did not have letters of undertaking. Of the 30", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorised loan deductions totalling to UGX.107 million. The deductions were from 30 employees that did not have letters of undertaking. Of the 30", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.52,165,651 was paid to 30 staff who had either", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "employees, 26 employees did not exist in the \u201cactive deduction\u201d while 04 employees did not exist in the \u201cmy approval\u201d reports on the PDMS-Payroll Deduction Management System, operated by PCA-Payroll Consults Africa", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorised loan deductions totalling to UGX.107 million. The deductions were from 30 employees that did not have letters of undertaking. Of the 30", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.52,165,651 was paid to 30 staff who had either", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.4.8 Bn,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.4.8 Bn,", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorised loan deductions totalling to UGX.107 million. The deductions were from 30 employees that did not have letters of undertaking. Of the 30", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "but did not remit concurrently with the salary payments in 5 out", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.4.8 Bn,", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorised loan deductions totalling to UGX.107 million. The deductions were from 30 employees that did not have letters of undertaking. Of the 30", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "of 12 months. On average, it delayed by 21 days", "metadata": {"headings": [{"headings_0": {"content": "of 12 months. On average, it delayed by 21 days", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.4.8 Bn,", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 443, "level": 3}}, {"headings_1": {"content": "of 12 months. On average, it delayed by 21 days", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "ranging from 16 \u2013 15 days", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 443, "level": 3}}, {"headings_1": {"content": "of 12 months. On average, it delayed by 21 days", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX.36,127,200 to the computation of PAYE in IPPS,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX.36,127,200 to the computation of PAYE in IPPS,", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "leading to an under deduction of UGX.9,608,560", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX.36,127,200 to the computation of PAYE in IPPS,", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 76 newly recruited/ transferred employees delayed", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 76 newly recruited/ transferred employees delayed", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX.36,127,200 to the computation of PAYE in IPPS,", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "to access payroll, with delays ranging between 1-2 months, while 50 new recruits did not access the payroll during the financial", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 76 newly recruited/ transferred employees delayed", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX.36,127,200 to the computation of PAYE in IPPS,", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "year", "metadata": {"headings": [{"headings_0": {"content": "year", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 76 newly recruited/ transferred employees delayed", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that 36 pensioners delayed to access the pension payroll,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 36 pensioners delayed to access the pension payroll,", "page": 443, "level": 3}}, {"headings_1": {"content": "year", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "with delays ranging between 1 - 3 months, whereas 16 pensioners did not access the payroll", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 36 pensioners delayed to access the pension payroll,", "page": 443, "level": 3}}, {"headings_1": {"content": "year", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 03 staff and 26 pensioners were paid a total of UGX 81,673,064 off the IPPS", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 03 staff and 26 pensioners were paid a total of UGX 81,673,064 off the IPPS", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 36 pensioners delayed to access the pension payroll,", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I observed that there were variances of UGX.250 Million between the figures in the MoPS IPPS and entity payroll registers", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I observed that there were variances of UGX.250 Million between the figures in the MoPS IPPS and entity payroll registers", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 03 staff and 26 pensioners were paid a total of UGX 81,673,064 off the IPPS", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I observed that there were variances of UGX.250 Million between the figures in the MoPS IPPS and entity payroll registers", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "that at the time of audit, it had not yet been approved as aligned to the NDP-III", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I observed that there were variances of UGX.250 Million between the figures in the MoPS IPPS and entity payroll registers", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect UGX.0.47Bn during the year but collected UGX.0.402 Bn", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect UGX.0.47Bn during the year but collected UGX.0.402 Bn", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "representing (85%) performance.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect UGX.0.47Bn during the year but collected UGX.0.402 Bn", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District budgeted to receive UGX.37.08 Bn (revised) as grants from the Treasury but UGX.33.54 Bn was", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.37.08 Bn (revised) as grants from the Treasury but UGX.33.54 Bn was", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect UGX.0.47Bn during the year but collected UGX.0.402 Bn", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "warranted/ received representing 91% performance.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.37.08 Bn (revised) as grants from the Treasury but UGX.33.54 Bn was", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect UGX.0.47Bn during the year but collected UGX.0.402 Bn", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the Entity budgeted to receive UGX.9.06 Bn as transfers from other Government Units. However, only UGX.1.45", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the Entity budgeted to receive UGX.9.06 Bn as transfers from other Government Units. However, only UGX.1.45", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.37.08 Bn (revised) as grants from the Treasury but UGX.33.54 Bn was", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Bn (16%) was received", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the Entity budgeted to receive UGX.9.06 Bn as transfers from other Government Units. However, only UGX.1.45", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.37.08 Bn (revised) as grants from the Treasury but UGX.33.54 Bn was", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District budgeted to receive UGX.0.86 Bn as external/donor financing out of which UGX.0.11 Bn (12%), was", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.0.86 Bn as external/donor financing out of which UGX.0.11 Bn (12%), was", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the Entity budgeted to receive UGX.9.06 Bn as transfers from other Government Units. However, only UGX.1.45", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "received", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.0.86 Bn as external/donor financing out of which UGX.0.11 Bn (12%), was", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the Entity budgeted to receive UGX.9.06 Bn as transfers from other Government Units. However, only UGX.1.45", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.0.86 Bn as external/donor financing out of which UGX.0.11 Bn (12%), was", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "431", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.0.86 Bn as external/donor financing out of which UGX.0.11 Bn (12%), was", "page": 443, "level": 3}}], "page": 443, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "resulting in an unspent balance of UGX.0.63 Bn (0.8%)."], [null, "\uf0b7 I noted that Management submitted performance reports for Q1,"], [null, "Q2, Q3 and Q4 after the deadline given for submission of the"], [null, "reports"], ["09\\. KANUNGU DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.28,863,148,598 constituted 66% of the District\u2019s budget for 2020/2021 of UGX.43.7 Bn \uf0b7 I noted that the District delayed to submit wage estimates to MoPs, as required \uf0b7 I reviewed Payroll funds absorption and noted that UGX.27 billion (95%) was spent out of the total receipts of UGX.28 billion, resulting in an unabsorbed balance of UGX.1 billion \uf0b7 I noted under payment of salary amounting to UGX 84,270,346 \uf0b7 I noted that 116 staff were paid using wrong salary scales, leading to over payments of UGX.33,520,148, \uf0b7 I noted that UGX.13,922,650 was paid to 11 staff who had either retired, transferred, absconded or died \uf0b7 I noted that the District made payroll deductions of UGX.6,465,198,289, but did not remit concurrently with the salary payments in 11 out of 12 months. On average, it delayed by 11 days \uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2 months \uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX.58,306,246 to the computation of PAYE in IPPS, leading to an under deduction of UGX.17,588,374 \uf0b7 I noted that 11 newly recruited/ transferred employees delayed to access payroll, with delays ranging between 1-6 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that 11 staff were paid a total of UGX.6,647,285 off the IPPS \uf0b7 I carried out a survey to establish the effectiveness and reliability of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification interface and noted the following; \uf0b7 In-adequate sensitization and training in the use and navigation of the IPPS. As a result, the HR team was unable to obtain pension payrolls for the financial year under review and the interface files for both salary and pension for the month of October 2020. \uf0b7 Lack/inadequate verification and ineffectiveness of the system may affect the integrity of the IPPS payroll \uf0b7 I noted that the District budgeted to collect UGX. 969,000,605", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.0.86 Bn as external/donor financing out of which UGX.0.11 Bn (12%), was", "page": 443, "level": 3}}], "page": 444, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "432", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.0.86 Bn as external/donor financing out of which UGX.0.11 Bn (12%), was", "page": 443, "level": 3}}], "page": 444, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["during the year but collected UGX.349,340,889 representing (36%) performance \uf0b7 I noted that the Entity budgeted to receive UGX.2,914,268,788 as transfers from other Government Units. However, only UGX.1,346,142,527 (46%) \uf0b7 I noted that the District budgeted to receive UGX.958,677,000 as external/donor financing out of which UGX.121,361,000(14%), was received \uf0b7 I noted that out of the total receipts for the financial year of UGX.37,438,548,600, UGX.36,912,545,231 (99%) was spent by the entity resulting in an unspent balance of UGX.526,003,369 (1%). \uf0b7 I noted that UGX.66,181,436 was charged on items which did not reflect the nature of the expenditure as shown in \uf0b7 I noted an irregular payment of VAT UGX 28,258,475 to contractors for the upgrade of Ntungamo HC II to HC III in Butogata Subcounty despite aid-funded projects being VAT exempt . The irregular payment was attributed to the irregular inclusion of the VAT amount in the contract price during the procurement process. \uf0b7 I noted that the District budgeted to receive UGX.931,475,272 from Uganda Road Fund for maintenance of 256.9 km of district roads, and UGX.900,073,304 (97%) was received and was utilised on maintenance of 242.5 km of roads, with a shortfall of UGX.31,401,970(3%) which left 14.4 km of roads not worked on.", null, null], ["10.", "KIRUHURA DLG Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Pay roll of UGX.12,779,567,829 constituted 50% of the District\u2019s budget for 2020/2021 of UGX.25.49 Bn"], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.0.86 Bn as external/donor financing out of which UGX.0.11 Bn (12%), was", "page": 443, "level": 3}}], "page": 445, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "resulting in an unspent balance of UGX.0.63 Bn (0.8%)."], "type": "table"}}, {"content": "433 \nnot have evidence of consent by the employees", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.0.86 Bn as external/donor financing out of which UGX.0.11 Bn (12%), was", "page": 443, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District budgeted to receive UGX.0.86 Bn as external/donor financing out of which UGX.0.11 Bn (12%), was", "page": 443, "level": 3}}]], "page": 445, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.919,811,264, but did not remit the deductions concurrently", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.919,811,264, but did not remit the deductions concurrently", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "with the salary payments in 5 out of 9 months", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.919,811,264, but did not remit the deductions concurrently", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 446, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.919,811,264, but did not remit the deductions concurrently", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "totalling to UGX 30,692,400 to the computation of PAYE in IPPS,", "metadata": {"headings": [{"headings_0": {"content": "totalling to UGX 30,692,400 to the computation of PAYE in IPPS,", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 446, "level": 2}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "leading to an under deduction of UGX.8,941,216", "metadata": {"headings": [{"headings_0": {"content": "totalling to UGX 30,692,400 to the computation of PAYE in IPPS,", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 446, "level": 2}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 38 newly recruited/transferred employees delayed to", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 38 newly recruited/transferred employees delayed to", "page": 446, "level": 3}}, {"headings_1": {"content": "totalling to UGX 30,692,400 to the computation of PAYE in IPPS,", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "access the payroll, with delays ranging between 1-2 months", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 38 newly recruited/transferred employees delayed to", "page": 446, "level": 3}}, {"headings_1": {"content": "totalling to UGX 30,692,400 to the computation of PAYE in IPPS,", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that only five(5) out a sample of 52 pensioners delayed", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that only five(5) out a sample of 52 pensioners delayed", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 38 newly recruited/transferred employees delayed to", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "to access the pension payroll, with delays ranging up to a month", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that only five(5) out a sample of 52 pensioners delayed", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 38 newly recruited/transferred employees delayed to", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 15 staff were paid a total of UGX 12,719,746", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 15 staff were paid a total of UGX 12,719,746", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that only five(5) out a sample of 52 pensioners delayed", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "respectively off the IPPS", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 15 staff were paid a total of UGX 12,719,746", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that only five(5) out a sample of 52 pensioners delayed", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 15 staff were paid a total of UGX 12,719,746", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "that at the time of audit, it had not yet been approved as aligned to the NDP-III", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 15 staff were paid a total of UGX 12,719,746", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that Kiruhura District budgeted to collect UGX.1.19Bn during the year under review. The entity collected UGX.0.43Bn", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kiruhura District budgeted to collect UGX.1.19Bn during the year under review. The entity collected UGX.0.43Bn", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "representing 36.16% performance", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kiruhura District budgeted to collect UGX.1.19Bn during the year under review. The entity collected UGX.0.43Bn", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.2.78 Bn as", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.2.78 Bn as", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Kiruhura District budgeted to collect UGX.1.19Bn during the year under review. The entity collected UGX.0.43Bn", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "transfers from other Government Units. However, only UGX.1.53Bn was received representing 55.14% performance", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.2.78 Bn as", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Kiruhura District budgeted to collect UGX.1.19Bn during the year under review. The entity collected UGX.0.43Bn", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.0.85Bn as external/donor financing out of which UGX.0.065Bn was received", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.0.85Bn as external/donor financing out of which UGX.0.065Bn was received", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.2.78 Bn as", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "representing 7.75% performance", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.0.85Bn as external/donor financing out of which UGX.0.065Bn was received", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.2.78 Bn as", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that Out of the total warrants for the financial year of UGX.22.39 Bn, UGX.20.25Bn was utilized and spent by the entity resulting in an unspent balance of UGX.2.14 Bn representing an", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Out of the total warrants for the financial year of UGX.22.39 Bn, UGX.20.25Bn was utilized and spent by the entity resulting in an unspent balance of UGX.2.14 Bn representing an", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.0.85Bn as external/donor financing out of which UGX.0.065Bn was received", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "absorption level of 90%.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Out of the total warrants for the financial year of UGX.22.39 Bn, UGX.20.25Bn was utilized and spent by the entity resulting in an unspent balance of UGX.2.14 Bn representing an", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.0.85Bn as external/donor financing out of which UGX.0.065Bn was received", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I assessed the implementation of eight (8) outputs that were", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I assessed the implementation of eight (8) outputs that were", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Out of the total warrants for the financial year of UGX.22.39 Bn, UGX.20.25Bn was utilized and spent by the entity resulting in an unspent balance of UGX.2.14 Bn representing an", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "fully quantified with a total of twenty-one (21) activities worth UGX.2.96Bn and noted the following. \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I assessed the implementation of eight (8) outputs that were", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Out of the total warrants for the financial year of UGX.22.39 Bn, UGX.20.25Bn was utilized and spent by the entity resulting in an unspent balance of UGX.2.14 Bn representing an", "page": 446, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I assessed the implementation of eight (8) outputs that were", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Out of the total warrants for the financial year of UGX.22.39 Bn, UGX.20.25Bn was utilized and spent by the entity resulting in an unspent balance of UGX.2.14 Bn representing an", "page": 446, "level": 3}}]], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Three (3) outputs with total expenditure amounting to", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I assessed the implementation of eight (8) outputs that were", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that Out of the total warrants for the financial year of UGX.22.39 Bn, UGX.20.25Bn was utilized and spent by the entity resulting in an unspent balance of UGX.2.14 Bn representing an", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "UGX.0.688Bn were fully implemented representing 37.5% of the", "metadata": {"headings": [{"headings_0": {"content": "UGX.0.688Bn were fully implemented representing 37.5% of the", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I assessed the implementation of eight (8) outputs that were", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "outputs.", "metadata": {"headings": [{"headings_0": {"content": "UGX.0.688Bn were fully implemented representing 37.5% of the", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I assessed the implementation of eight (8) outputs that were", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 Five (5) outputs with total expenditure amounting to UGX.2.27Bn", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Five (5) outputs with total expenditure amounting to UGX.2.27Bn", "page": 446, "level": 3}}, {"headings_1": {"content": "UGX.0.688Bn were fully implemented representing 37.5% of the", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "were partially implemented representing 62.45% of the outputs", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Five (5) outputs with total expenditure amounting to UGX.2.27Bn", "page": 446, "level": 3}}, {"headings_1": {"content": "UGX.0.688Bn were fully implemented representing 37.5% of the", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required.", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 Five (5) outputs with total expenditure amounting to UGX.2.27Bn", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the entity also did not submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED as", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity also did not submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED as", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required.", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "required", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity also did not submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED as", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required.", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity also did not submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED as", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Q2, Q3, Q4 after the deadline given for submission of the reports", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity also did not submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED as", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "434", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "cumulative performance reports and physical"], [null, "inspections/verification of performance."], [null, "\uf0b7 I reviewed the implementation of Uganda Road Fund and noted"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 446, "level": 3}}], "page": 447, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", "cumulative performance reports and physical"], [null, "inspections/verification of performance."], [null, "\uf0b7 I reviewed the implementation of Uganda Road Fund and noted"], [null, "the following;"], [null, "\uf0b7 A total of UGX.726,279,445 was budgeted for however the"], [null, "District Council received UGX.1,148,526,601 (158%)"], [null, "\uf0b7 A total of 221.90 km at an estimated cost of UGX.31,213,190"], [null, "was planned to be undertaken. However, audit revealed that no"], [null, "work was actually undertaken. Thus the entire 221.90 km were"], [null, "not maintained"], [null, "\uf0b7 A total of 6 km at an estimated cost of UGX.17,983,012 was"], [null, "planned to be undertaken. Audit revealed that 34.6 km was"], [null, "undertaken at a cost of UGX.187,493,520. I noted that the initial"], [null, "plan (budget) was not revised when additional funds were"], [null, "received."], ["11\\. KISORO DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.29,217,966,405 constituted 72% of the District\u2019s budget for 2020/2021 of UGX.40.68 Bn \uf0b7 I noted that the District did not submit wage estimates to MoPs, as required. \uf0b7 I noted an over payment of Pension of UGX.5,223,859 \uf0b7 I also noted that the District made payroll deductions of UGX2.595 billion, but did not remit concurrently with the salary payments in 6 out of 6 months sampled. On average, it delayed by 13.5 days \uf0b7 I noted delays in the remittance of PAYE deductions to URA ranging from 3 \u2013 32 days \uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX.419,638,073 \\` to the computation of PAYE in IPPS, leading to an under deduction of UGX.125,070,214 \uf0b7 I noted that 7 pensioners delayed to access the pension payroll, with delays ranging between 1-4 months \uf0b7 I noted that the Districts prepared monthly wage, pension and gratuity performance analysis but did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that 15 staff were paid a total of UGX.47,243,693 off the IPPS \uf0b7 I observed that there were variances of UGX.29,495,726 between the figures in the interface files and entity payroll registers \uf0b7 Some information on the NIRA interface is sometimes not visible/available for instance date of birth and the photo which delays the verification exercise \uf0b7 I noted that Kisoro DLG budgeted to collect UGX.461,618,300 during the year under review. The entity collected", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 446, "level": 3}}], "page": 447, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "435", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 446, "level": 3}}], "page": 447, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["UGX.256,912,576 representing 55.7% performance. \uf0b7 I noted that the entity budgeted to receive UGX.1.10Bn as transfers from other Government Units out of which UGX.0.73Bn was received representing 66.2% performance \uf0b7 I noted thata the entity budgeted to receive 1.5Bn from external assistance but received 0.11Bn representing 7.6%. \uf0b7 I assessed the implementation of fifteen (15) outputs that were fully quantified with a total of fifteen (15) activities worth UGX.3.81Bn and noted the following; \uf0b7 Thirteen (13) outputs with Thirteen (13) activities worth UGX.3.808 Bn were fully implemented representing 58.6% of the outputs. \uf0b7 Two (2) outputs with two activities(2) worth UGX.0.54 Bn were not implemented representing 3.6% of the outputs(included in the schedule at UGX.0 because no funds were spent) \uf0b7 I noted that the entity submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports \uf0b7 I noted the delayed completion of Nyakinama Seed School (UGIFT project) worth 2,331,850,894 \uf0b7 I noted that the District budgeted and received funds worth UGX.344,284,000 under UGIFT program for the construction of Mwumba Progressive SS. However, this project did not take off due to delays in the procurement process and at the time of audit in August, 2021, the project had not started with a delay of 12 months.", null, null], ["12.", "MBARARA CITY Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Payroll of UGX.17,869,060,735 constituted 39.4% of the Municipal Council\u2019s budget for 2020/2021 of UGX.45,355,732,366."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 446, "level": 3}}], "page": 448, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "cumulative performance reports and physical"], "type": "table"}}, {"content": "436 \nto access payroll, with delays ranging between 1-2 months", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 446, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 446, "level": 3}}]], "page": 448, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 22 pensioners delayed to access the pension payroll,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 22 pensioners delayed to access the pension payroll,", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "with delays ranging between 1 to 10 months", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 22 pensioners delayed to access the pension payroll,", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the Municipal Council did not prepare monthly wage,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the Municipal Council did not prepare monthly wage,", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 22 pensioners delayed to access the pension payroll,", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the Municipal Council did not prepare monthly wage,", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 22 pensioners delayed to access the pension payroll,", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I observed that there were variances of UGX.7,662,578 between", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I observed that there were variances of UGX.7,662,578 between", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the Municipal Council did not prepare monthly wage,", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the MoPS IPPS and Entity payroll registers", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I observed that there were variances of UGX.7,662,578 between", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the Municipal Council did not prepare monthly wage,", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The merger of both IPPS and NIRA system have not been fully", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The merger of both IPPS and NIRA system have not been fully", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I observed that there were variances of UGX.7,662,578 between", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "done in that when there is a system error each entity has to clear an error in its jurisdiction thus time consuming and affecting timely service delivery.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The merger of both IPPS and NIRA system have not been fully", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I observed that there were variances of UGX.7,662,578 between", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 The system has not been fully decentralized to the extent that system errors under Employee verification system (issues) with NIRA have to be handled at the Headquarter and this contributes", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The system has not been fully decentralized to the extent that system errors under Employee verification system (issues) with NIRA have to be handled at the Headquarter and this contributes", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 The merger of both IPPS and NIRA system have not been fully", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "to multiple negative factors such delayed clearance of technical issues at least a period of three month or more.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The system has not been fully decentralized to the extent that system errors under Employee verification system (issues) with NIRA have to be handled at the Headquarter and this contributes", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 The merger of both IPPS and NIRA system have not been fully", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan, at", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan, at", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 The system has not been fully decentralized to the extent that system errors under Employee verification system (issues) with NIRA have to be handled at the Headquarter and this contributes", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "the time of audit, it had not yet been approved as aligned to the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan, at", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 The system has not been fully decentralized to the extent that system errors under Employee verification system (issues) with NIRA have to be handled at the Headquarter and this contributes", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "NDP-III.", "metadata": {"headings": [{"headings_0": {"content": "NDP-III.", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan, at", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the entity collected local revenue of UGX.3.54Bn of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity collected local revenue of UGX.3.54Bn of", "page": 449, "level": 3}}, {"headings_1": {"content": "NDP-III.", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "6.42Bn representing 55.25% performance", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity collected local revenue of UGX.3.54Bn of", "page": 449, "level": 3}}, {"headings_1": {"content": "NDP-III.", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.37.49Bn as grants from the Treasury. However, UGX.31.59 Bn was received,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.37.49Bn as grants from the Treasury. However, UGX.31.59 Bn was received,", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity collected local revenue of UGX.3.54Bn of", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "representing 84.26% performance", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.37.49Bn as grants from the Treasury. However, UGX.31.59 Bn was received,", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity collected local revenue of UGX.3.54Bn of", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1.45Bn as", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1.45Bn as", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.37.49Bn as grants from the Treasury. However, UGX.31.59 Bn was received,", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "transfers from other Government Units. However, UGX.7.65Bn was received representing 527.59% performance", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1.45Bn as", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.37.49Bn as grants from the Treasury. However, UGX.31.59 Bn was received,", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.42.84Bn, UGX 36.68Bn was spent by the entity resulting in an unspent balance of UGX 6.15 Bn representing an absorption", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.42.84Bn, UGX 36.68Bn was spent by the entity resulting in an unspent balance of UGX 6.15 Bn representing an absorption", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1.45Bn as", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "level of 85.6%.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.42.84Bn, UGX 36.68Bn was spent by the entity resulting in an unspent balance of UGX 6.15 Bn representing an absorption", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1.45Bn as", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the management submitted performance reports for Q1, Q2, Q3, Q4 after the deadline given for submission", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the management submitted performance reports for Q1, Q2, Q3, Q4 after the deadline given for submission", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.42.84Bn, UGX 36.68Bn was spent by the entity resulting in an unspent balance of UGX 6.15 Bn representing an absorption", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the management submitted performance reports for Q1, Q2, Q3, Q4 after the deadline given for submission", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "months after the expected/ contracted end date", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the management submitted performance reports for Q1, Q2, Q3, Q4 after the deadline given for submission", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "progress report revealed that planned works were completed on 22/08/2020, eleven (11) months outside the contract period without approval. \n437", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}]], "page": 449, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["13\\. MITOOMA DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.18,505,405,927 constituted 63% of the District\u2019s budget for 2020/2021 of UGX.29,350,754,495. \uf0b7 I noted that the District did not to submit wage estimates to MoPS, as required \uf0b7 I noted delays in the remittance of PAYE deductions to URA of up to 100 days \uf0b7 I noted that 47 newly recruited/transferred employees delayed to access payroll, with delays ranging between 2-14 months \uf0b7 I noted that 7 pensioners delayed to access the pension payroll, with delays ranging between 1-14 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that 6 pensioners were paid a total of UGX.26,607,195 off the IPPS \uf0b7 I observed that there were variances of UGX.514,103,048 between the figures in the MoPS IPPS and entity payroll registers, \uf0b7 Operational challenges were encountered; E.g. Un-reliable network in Mitooma where HR staff had to physically travel to the neighbouring Bushenyi District to be able to download documents such as pension payroll registers. \uf0b7 I noted that the upgrade of Mayanga HC II to HC III contracted to Khalsa (U) Ltd was still under construction and only at roofing stage by the time of audit inspection on 13th October, 2021. However, the medical equipment had already been procured and delivered under a separate contract to M/s Rodrisa Supplies Limited who was expected to supply, deliver, instal, train and commission the medical equipment. Procurement of medical equipment for a health facility still at foundation stage may lead to obsolescence, pilferage and physical damage leading to nugatory expenditure.", null, null], ["14.", "NTUNGAMO DLG Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Pay roll of UGX.35,484,605,345 constituted 56% of the District\u2019s budget for 2020/2021 of UGX.63,733,887,733."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}], "page": 450, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "438", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}], "page": 450, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity"], [null, "totalling to UGX.60,526,800 to the computation of PAYE in IPPS,"], [null, "leading to an under deduction of UGX.14,374,090"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}], "page": 451, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["13\\. MITOOMA DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.18,505,405,927 constituted 63% of the District\u2019s budget for 2020/2021 of UGX.29,350,754,495. \uf0b7 I noted that the District did not to submit wage estimates to MoPS, as required \uf0b7 I noted delays in the remittance of PAYE deductions to URA of up to 100 days \uf0b7 I noted that 47 newly recruited/transferred employees delayed to access payroll, with delays ranging between 2-14 months \uf0b7 I noted that 7 pensioners delayed to access the pension payroll, with delays ranging between 1-14 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that 6 pensioners were paid a total of UGX.26,607,195 off the IPPS \uf0b7 I observed that there were variances of UGX.514,103,048 between the figures in the MoPS IPPS and entity payroll registers, \uf0b7 Operational challenges were encountered; E.g. Un-reliable network in Mitooma where HR staff had to physically travel to the neighbouring Bushenyi District to be able to download documents such as pension payroll registers. \uf0b7 I noted that the upgrade of Mayanga HC II to HC III contracted to Khalsa (U) Ltd was still under construction and only at roofing stage by the time of audit inspection on 13th October, 2021. However, the medical equipment had already been procured and delivered under a separate contract to M/s Rodrisa Supplies Limited who was expected to supply, deliver, instal, train and commission the medical equipment. Procurement of medical equipment for a health facility still at foundation stage may lead to obsolescence, pilferage and physical damage leading to nugatory expenditure.", "None"], "type": "table"}}, {"content": [["", "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity"], [null, "totalling to UGX.60,526,800 to the computation of PAYE in IPPS,"], [null, "leading to an under deduction of UGX.14,374,090"], [null, "\uf0b7 I noted that the entity did not prepare monthly wage, pension"], [null, "and gratuity performance analysis, and did not submit quarterly"], [null, "returns on payroll to MoPS"], [null, "\uf0b7 I noted that 29 staff were paid a total of UGX.91,713,882 off the"], [null, "IPPS"], [null, "\uf0b7 I carried out a survey to establish the effectiveness and reliability"], [null, "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification"], [null, "interface and noted the following;"], [null, "\uf0b7 I noted that the entity had no approved a strategic plan at the"], [null, "time of audit"], [null, "\uf0b7 I noted that the District budgeted to collect UGX.1,554,984,179"], [null, "during the year but collected UGX.1,127,109,918 representing"], [null, "(72%) performance"], [null, "\uf0b7 I noted that the entity budgeted to receive UGX.8,698,586,134"], [null, "as transfers from other Government Units out of which"], [null, "UGX.1,307,013,923 was received representing 15% performance"], [null, "leading to a shortfall of UGX.7,391,572,211(85%)"], [null, "\uf0b7 I noted that the entity budgeted to receive UGX.1,901,504,814"], [null, "as external/donor financing out of which UGX.267,332,705 was"], [null, "received representing 14% performance"], [null, "\uf0b7 Out of the total receipts for the financial year of UGX. 53.52,"], [null, "UGX. 51.85 (97%) was spent by the entity resulting in an"], [null, "unspent balance of UGX. 1.67 (3%)."], [null, "\uf0b7 I carried out an audit inspection of the Construction of Kihanga"], [null, "seed Secondary school (UGX.718,168,225) in September 2021,"], [null, "and noted that the project had been abandoned and behind"], [null, "schedule by 20 months"], [null, "\uf0b7 I noted that most of the District land did not have certificates of"], [null, "land titles"], ["15\\. RUKIGA DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.15,291,042,432 constituted 50.4% of the District\u2019s budget for 2020/2021 of UGX.30,313,124,744 \uf0b7 I noted that the District did not submit wage estimates to MoPS, as required \uf0b7 I reviewed payroll funds absorption and noted that UGX.13.167 billion (86%) was spent out of the total receipts of UGX.15.29 billion, resulting in an unabsorbed balance of UGX 2.12 billion \uf0b7 I noted that whereas UGX.909,840,551 was deducted from employees\u2019 salaries to be remitted to different beneficiaries, UGX.909,338,143 was remitted, leading to an over/under remittance of UGX.153,842 and UGX.656,250 respectively \uf0b7 I noted that the District made payroll deductions of UGX 0.844", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}], "page": 451, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["13\\. MITOOMA DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.18,505,405,927 constituted 63% of the District\u2019s budget for 2020/2021 of UGX.29,350,754,495. \uf0b7 I noted that the District did not to submit wage estimates to MoPS, as required \uf0b7 I noted delays in the remittance of PAYE deductions to URA of up to 100 days \uf0b7 I noted that 47 newly recruited/transferred employees delayed to access payroll, with delays ranging between 2-14 months \uf0b7 I noted that 7 pensioners delayed to access the pension payroll, with delays ranging between 1-14 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that 6 pensioners were paid a total of UGX.26,607,195 off the IPPS \uf0b7 I observed that there were variances of UGX.514,103,048 between the figures in the MoPS IPPS and entity payroll registers, \uf0b7 Operational challenges were encountered; E.g. Un-reliable network in Mitooma where HR staff had to physically travel to the neighbouring Bushenyi District to be able to download documents such as pension payroll registers. \uf0b7 I noted that the upgrade of Mayanga HC II to HC III contracted to Khalsa (U) Ltd was still under construction and only at roofing stage by the time of audit inspection on 13th October, 2021. However, the medical equipment had already been procured and delivered under a separate contract to M/s Rodrisa Supplies Limited who was expected to supply, deliver, instal, train and commission the medical equipment. Procurement of medical equipment for a health facility still at foundation stage may lead to obsolescence, pilferage and physical damage leading to nugatory expenditure.", "None"], "type": "table"}}, {"content": "439", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}], "page": 451, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["billion, but did not remit concurrently with the salary payments in 11 out of 12 months. On average, it delayed by 6.5 days \uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX.34,918,061 to the computation of PAYE in IPPS, leading to an under deduction of UGX.10,880,299 \uf0b7 I noted that 6 newly recruited/transferred employees delayed to access payroll, with delays ranging between 1- 3.5 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis nor submitted quarterly returns on payroll to MoPS \uf0b7 I noted that UGX.24,681,002 was paid to 16 staffs that were off the IPPS payroll register \uf0b7 I observed that there were variances of UGX30,377,765 between the figures in the interface files and entity payroll registers \uf0b7 I noted that the entity prepared a strategic plan but was not yet approved. \uf0b7 I noted that Rukiga DLG budgeted to collect UGX. 285,061,188 during the year under review. The entity collected UGX.155,082,884 representing 54% performance. \uf0b7 I noted that the entity budgeted to receive UGX.8.77Bn as transfers from other Government Units out of which UGX.0.68Bn was received representing 11% performance \uf0b7 I noted that the entity budgeted to receive 1.02Bn from external assistance but received 0.05Bn representing 5%. \uf0b7 I noted that out of UGX.21,252,068,152 warrants to finance the council\u2019s budget, only UGX.18,677,785,569 (88%) was spent leaving a balance of UGX.2,574,282,583 (14%) un utilized \uf0b7 I noted that the entity did not also submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED as required. \uf0b7 I noted that the entity submitted performance reports for Q3, and Q4 after the deadline given for submission of the reports \uf0b7 I noted that the District Council budgeted to receive UGX.467,373,000 (Excluding funds to be transferred to LLGs) from Uganda Road Fund for maintenance of 80.9kms of District roads, and UGX.252,363,000 (54%%) was received and was utilised on maintenance of 74.7kms of roads, installation of culverts, equipment repairs and supervision with a shortfall of UGX.215,010,000 (46%) As a result of revenue shortage, 6.2KMs of roads were not maintained under periodic maintenance as planned", null, null], ["16.", "RUKUNGIRI DLG Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Pay roll of UGX.30,042,268,241 constituted 66.8% of the District\u2019s budget for 2020/2021 of UGX.44.95 Bn."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}], "page": 452, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["13\\. MITOOMA DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.18,505,405,927 constituted 63% of the District\u2019s budget for 2020/2021 of UGX.29,350,754,495. \uf0b7 I noted that the District did not to submit wage estimates to MoPS, as required \uf0b7 I noted delays in the remittance of PAYE deductions to URA of up to 100 days \uf0b7 I noted that 47 newly recruited/transferred employees delayed to access payroll, with delays ranging between 2-14 months \uf0b7 I noted that 7 pensioners delayed to access the pension payroll, with delays ranging between 1-14 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that 6 pensioners were paid a total of UGX.26,607,195 off the IPPS \uf0b7 I observed that there were variances of UGX.514,103,048 between the figures in the MoPS IPPS and entity payroll registers, \uf0b7 Operational challenges were encountered; E.g. Un-reliable network in Mitooma where HR staff had to physically travel to the neighbouring Bushenyi District to be able to download documents such as pension payroll registers. \uf0b7 I noted that the upgrade of Mayanga HC II to HC III contracted to Khalsa (U) Ltd was still under construction and only at roofing stage by the time of audit inspection on 13th October, 2021. However, the medical equipment had already been procured and delivered under a separate contract to M/s Rodrisa Supplies Limited who was expected to supply, deliver, instal, train and commission the medical equipment. Procurement of medical equipment for a health facility still at foundation stage may lead to obsolescence, pilferage and physical damage leading to nugatory expenditure.", "None", "None"], "type": "table"}}, {"content": "440 \nas required", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}]], "page": 452, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that two Education Officers (Twinomuhwezi Julius IPPS no.328279 and Abaho Besigye Gerald IPPS no. 326667) under U4 who were erroneously captured as Assistant Education Officers and paid under U5 thus an over payment of UGX 304,295", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that two Education Officers (Twinomuhwezi Julius IPPS no.328279 and Abaho Besigye Gerald IPPS no. 326667) under U4 who were erroneously captured as Assistant Education Officers and paid under U5 thus an over payment of UGX 304,295", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that UGX.28,077,304 was paid to 19 staff who had either", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.28,077,304 was paid to 19 staff who had either", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that two Education Officers (Twinomuhwezi Julius IPPS no.328279 and Abaho Besigye Gerald IPPS no. 326667) under U4 who were erroneously captured as Assistant Education Officers and paid under U5 thus an over payment of UGX 304,295", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "retired, transferred, absconded or died \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.28,077,304 was paid to 19 staff who had either", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that two Education Officers (Twinomuhwezi Julius IPPS no.328279 and Abaho Besigye Gerald IPPS no. 326667) under U4 who were erroneously captured as Assistant Education Officers and paid under U5 thus an over payment of UGX 304,295", "page": 453, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that UGX.28,077,304 was paid to 19 staff who had either", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that two Education Officers (Twinomuhwezi Julius IPPS no.328279 and Abaho Besigye Gerald IPPS no. 326667) under U4 who were erroneously captured as Assistant Education Officers and paid under U5 thus an over payment of UGX 304,295", "page": 453, "level": 3}}]], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.6,307,960,826 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.28,077,304 was paid to 19 staff who had either", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that two Education Officers (Twinomuhwezi Julius IPPS no.328279 and Abaho Besigye Gerald IPPS no. 326667) under U4 who were erroneously captured as Assistant Education Officers and paid under U5 thus an over payment of UGX 304,295", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX", "page": 453, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.28,077,304 was paid to 19 staff who had either", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "6,304,814,535 was remitted, leading to an over/ under remittance of UGX.5,128,867 and UGX.8,275,158 respectively", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX", "page": 453, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.28,077,304 was paid to 19 staff who had either", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.2.259", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.2.259", "page": 453, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX", "page": 453, "level": 2}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "billion, but did not remit concurrently with the salary payments in 10 out of 12 months. On average, it delayed by 6.5 days", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.2.259", "page": 453, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX", "page": 453, "level": 2}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.2.259", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "ranging from 2 \u2013 22 days", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.2.259", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 453, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "totalling to UGX.11,718,959 to the computation of PAYE in IPPS,", "metadata": {"headings": [{"headings_0": {"content": "totalling to UGX.11,718,959 to the computation of PAYE in IPPS,", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 453, "level": 2}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "leading to an under deduction of UGX.3,715,200", "metadata": {"headings": [{"headings_0": {"content": "totalling to UGX.11,718,959 to the computation of PAYE in IPPS,", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 453, "level": 2}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 7 newly recruited/ transferred employees delayed to", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 7 newly recruited/ transferred employees delayed to", "page": 453, "level": 3}}, {"headings_1": {"content": "totalling to UGX.11,718,959 to the computation of PAYE in IPPS,", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "access payroll, with delays ranging between 1-5 months", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 7 newly recruited/ transferred employees delayed to", "page": 453, "level": 3}}, {"headings_1": {"content": "totalling to UGX.11,718,959 to the computation of PAYE in IPPS,", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 1 pensioner delayed to access the pension payroll,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 1 pensioner delayed to access the pension payroll,", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 7 newly recruited/ transferred employees delayed to", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "with delays of over of 6 months", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 1 pensioner delayed to access the pension payroll,", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 7 newly recruited/ transferred employees delayed to", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the Districts prepared monthly wage, pension and", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the Districts prepared monthly wage, pension and", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 1 pensioner delayed to access the pension payroll,", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "gratuity performance analysis but did not submit quarterly returns on payroll to MoPS", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the Districts prepared monthly wage, pension and", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 1 pensioner delayed to access the pension payroll,", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I observed that there were variances of UGX 190,771,973", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I observed that there were variances of UGX 190,771,973", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the Districts prepared monthly wage, pension and", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "between the figures in the interface files and entity payroll registers", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I observed that there were variances of UGX 190,771,973", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the Districts prepared monthly wage, pension and", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity had not approved a strategic plan that is aligned to the NDP-III at the time of audit", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity had not approved a strategic plan that is aligned to the NDP-III at the time of audit", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I observed that there were variances of UGX 190,771,973", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity had not approved a strategic plan that is aligned to the NDP-III at the time of audit", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I observed that there were variances of UGX 190,771,973", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted Rukungiri DLG budgeted to collect UGX.776,944,000", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity had not approved a strategic plan that is aligned to the NDP-III at the time of audit", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I observed that there were variances of UGX 190,771,973", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "during the year under review. However the entity collected", "metadata": {"headings": [{"headings_0": {"content": "during the year under review. However the entity collected", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not approved a strategic plan that is aligned to the NDP-III at the time of audit", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.625,618,740 representing 81% performance.", "metadata": {"headings": [{"headings_0": {"content": "during the year under review. However the entity collected", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity had not approved a strategic plan that is aligned to the NDP-III at the time of audit", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1,411,248,710 as transfers from other Government Units out of which", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1,411,248,710 as transfers from other Government Units out of which", "page": 453, "level": 3}}, {"headings_1": {"content": "during the year under review. However the entity collected", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.888,876,678 was received representing 63% performance", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1,411,248,710 as transfers from other Government Units out of which", "page": 453, "level": 3}}, {"headings_1": {"content": "during the year under review. However the entity collected", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity budgeted to receive 1.05Bn from external", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive 1.05Bn from external", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1,411,248,710 as transfers from other Government Units out of which", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "assistance but received 0.116 Bn representing 11%.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive 1.05Bn from external", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1,411,248,710 as transfers from other Government Units out of which", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that out of UGX.42,031,304,808 warrants to finance the", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that out of UGX.42,031,304,808 warrants to finance the", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity budgeted to receive 1.05Bn from external", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "council\u2019s budget, only UGX.40,435,316,368 (96%) was spent", "metadata": {"headings": [{"headings_0": {"content": "council\u2019s budget, only UGX.40,435,316,368 (96%) was spent", "page": 453, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that out of UGX.42,031,304,808 warrants to finance the", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "leaving a balance of UGX.1,595,988,440 (4%) un utilized", "metadata": {"headings": [{"headings_0": {"content": "leaving a balance of UGX.1,595,988,440 (4%) un utilized", "page": 453, "level": 3}}, {"headings_1": {"content": "council\u2019s budget, only UGX.40,435,316,368 (96%) was spent", "page": 453, "level": 2}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that the entity submitted performance reports for Q2,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q2,", "page": 453, "level": 3}}, {"headings_1": {"content": "leaving a balance of UGX.1,595,988,440 (4%) un utilized", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Q3, and Q4 after the deadline", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q2,", "page": 453, "level": 3}}, {"headings_1": {"content": "leaving a balance of UGX.1,595,988,440 (4%) un utilized", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted the delayed completion of Kebisoni Seed School (UGIFT", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted the delayed completion of Kebisoni Seed School (UGIFT", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q2,", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "441 \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted the delayed completion of Kebisoni Seed School (UGIFT", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q2,", "page": 453, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted the delayed completion of Kebisoni Seed School (UGIFT", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q2,", "page": 453, "level": 3}}]], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "17. RWAMPARA DLG", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted the delayed completion of Kebisoni Seed School (UGIFT", "page": 453, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q2,", "page": 453, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Opinion Unqualified", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted the delayed completion of Kebisoni Seed School (UGIFT", "page": 453, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "project). Project behind schedule by four(04) months", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted the delayed completion of Kebisoni Seed School (UGIFT", "page": 453, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that The District received UGX.499,963,986 (96.3%) of its Uganda Road fund and as a result was not able to maintain", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that The District received UGX.499,963,986 (96.3%) of its Uganda Road fund and as a result was not able to maintain", "page": 454, "level": 3}}, {"headings_1": {"content": "Opinion Unqualified", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "14.2 Km of roads as planned", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that The District received UGX.499,963,986 (96.3%) of its Uganda Road fund and as a result was not able to maintain", "page": 454, "level": 3}}, {"headings_1": {"content": "Opinion Unqualified", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the wage and Pension Pay roll of", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the wage and Pension Pay roll of", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that The District received UGX.499,963,986 (96.3%) of its Uganda Road fund and as a result was not able to maintain", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.12,530,332,963 constituted 62% of the District\u2019s budget for", "metadata": {"headings": [{"headings_0": {"content": "UGX.12,530,332,963 constituted 62% of the District\u2019s budget for", "page": 454, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the wage and Pension Pay roll of", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "2020/2021 of UGX.20,291,699,406.", "metadata": {"headings": [{"headings_0": {"content": "UGX.12,530,332,963 constituted 62% of the District\u2019s budget for", "page": 454, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that the wage and Pension Pay roll of", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "page": 454, "level": 3}}, {"headings_1": {"content": "UGX.12,530,332,963 constituted 62% of the District\u2019s budget for", "page": 454, "level": 2}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "MoPS, as required", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "page": 454, "level": 3}}, {"headings_1": {"content": "UGX.12,530,332,963 constituted 62% of the District\u2019s budget for", "page": 454, "level": 2}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted salary overpayment of UGX 6,766,726", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted salary overpayment of UGX 6,766,726", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I further noted that there was an under payment of UGX.30,357,501", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I further noted that there was an under payment of UGX.30,357,501", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted salary overpayment of UGX 6,766,726", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted pension and gratuity overpayment of UGX 2,144,892", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted pension and gratuity overpayment of UGX 2,144,892", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I further noted that there was an under payment of UGX.30,357,501", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted that UGX.4,580,492 was paid to 4 staff who had either", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.4,580,492 was paid to 4 staff who had either", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted pension and gratuity overpayment of UGX 2,144,892", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "retired or died", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.4,580,492 was paid to 4 staff who had either", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted pension and gratuity overpayment of UGX 2,144,892", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.2,342,683,197 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.4,580,492 was paid to 4 staff who had either", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted pension and gratuity overpayment of UGX 2,144,892", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.4,580,492 was paid to 4 staff who had either", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted pension and gratuity overpayment of UGX 2,144,892", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.2,336,599,219 was remitted, leading to an over remittance", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.2,336,599,219 was remitted, leading to an over remittance", "page": 454, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.4,580,492 was paid to 4 staff who had either", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "of UGX.1,549,064 and under remittance of UGX.7,633,042", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.2,336,599,219 was remitted, leading to an over remittance", "page": 454, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted that UGX.4,580,492 was paid to 4 staff who had either", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totalling UGX.48 million. The deductions were from 28 employees", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totalling UGX.48 million. The deductions were from 28 employees", "page": 454, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.2,336,599,219 was remitted, leading to an over remittance", "page": 454, "level": 2}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "that had no letters of undertaking however existed in the \u201cactive deduction\u201d and the \u201cmy approval\u201d reports on the PDMS-Payroll Deduction Management System, operated by PCA-Payroll Consults Africa", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totalling UGX.48 million. The deductions were from 28 employees", "page": 454, "level": 3}}, {"headings_1": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.2,336,599,219 was remitted, leading to an over remittance", "page": 454, "level": 2}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that deductions to UCLA/UBA were not remitted concurrently with salary payments for 12 out 12 months. I also", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that deductions to UCLA/UBA were not remitted concurrently with salary payments for 12 out 12 months. I also", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totalling UGX.48 million. The deductions were from 28 employees", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "noted that there was an average delay to remit deductions to", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that deductions to UCLA/UBA were not remitted concurrently with salary payments for 12 out 12 months. I also", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totalling UGX.48 million. The deductions were from 28 employees", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "UCLA/UBA of 21.3 days", "metadata": {"headings": [{"headings_0": {"content": "UCLA/UBA of 21.3 days", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that deductions to UCLA/UBA were not remitted concurrently with salary payments for 12 out 12 months. I also", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2", "page": 454, "level": 3}}, {"headings_1": {"content": "UCLA/UBA of 21.3 days", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "months. I also noted that there was an average delay to remit deductions to URA of 0.5 days", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2", "page": 454, "level": 3}}, {"headings_1": {"content": "UCLA/UBA of 21.3 days", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 454, "level": 2}}, {"headings_1": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "totalling to UGX.3,114,720 to the computation of PAYE in IPPS,", "metadata": {"headings": [{"headings_0": {"content": "totalling to UGX.3,114,720 to the computation of PAYE in IPPS,", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 454, "level": 2}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "leading to an under deduction of UGX.934,416", "metadata": {"headings": [{"headings_0": {"content": "totalling to UGX.3,114,720 to the computation of PAYE in IPPS,", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 454, "level": 2}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 51 newly recruited/ transferred employees delayed", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 51 newly recruited/ transferred employees delayed", "page": 454, "level": 3}}, {"headings_1": {"content": "totalling to UGX.3,114,720 to the computation of PAYE in IPPS,", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "to access payroll, with delays ranging between 9 weeks", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 51 newly recruited/ transferred employees delayed", "page": 454, "level": 3}}, {"headings_1": {"content": "totalling to UGX.3,114,720 to the computation of PAYE in IPPS,", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that 15 pensioners delayed to access the pension payroll,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 15 pensioners delayed to access the pension payroll,", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 51 newly recruited/ transferred employees delayed", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "with delays ranging between 3-4 months", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that 15 pensioners delayed to access the pension payroll,", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 51 newly recruited/ transferred employees delayed", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 noted that the District did not prepare monthly wage, pension", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 noted that the District did not prepare monthly wage, pension", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 15 pensioners delayed to access the pension payroll,", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 noted that the District did not prepare monthly wage, pension", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that 15 pensioners delayed to access the pension payroll,", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 noted that the District did not prepare monthly wage, pension", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "that at the time of audit, it had not yet been approved as aligned \n442", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 noted that the District did not prepare monthly wage, pension", "page": 454, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 noted that the District did not prepare monthly wage, pension", "page": 454, "level": 3}}]], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["to the NDP-III \uf0b7 I noted that Rwampara District budgeted to collect UGX.0.392bn during the year under review. The entity collected UGX.0.379bn representing 96.68% performance. \uf0b7 I noted that the entity budgeted to receive UGX.1.51 Bn as transfers from other Government Units. However, only UGX.0.68 Bn was received representing 45% performance leading to revenue shortfall of UGX. 0.83Bn (55%).", null, null], ["18.", "SHEEMA DLG Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Pay roll of UGX.18,356,082,529 constituted 65% of the District\u2019s budget for 2020/2021 of UGX.27,950,550,703"], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 noted that the District did not prepare monthly wage, pension", "page": 454, "level": 3}}], "page": 455, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "443", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "page": 454, "level": 3}}, {"headings_1": {"content": "\uf0b7 noted that the District did not prepare monthly wage, pension", "page": 454, "level": 3}}], "page": 455, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "transfers from other Government Units out of which", "metadata": {"headings": [{"headings_0": {"content": "transfers from other Government Units out of which", "page": 456, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "page": 454, "level": 3}}], "page": 456, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "UGX.892,442,495 was received representing 93% performance.", "metadata": {"headings": [{"headings_0": {"content": "transfers from other Government Units out of which", "page": 456, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "page": 454, "level": 3}}], "page": 456, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the district budgeted to receive UGX.279,500,000 as", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district budgeted to receive UGX.279,500,000 as", "page": 456, "level": 3}}, {"headings_1": {"content": "transfers from other Government Units out of which", "page": 456, "level": 3}}], "page": 456, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "external/donor financing out of which UGX.130,287,709 million was received representing 47% performance", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district budgeted to receive UGX.279,500,000 as", "page": 456, "level": 3}}, {"headings_1": {"content": "transfers from other Government Units out of which", "page": 456, "level": 3}}], "page": 456, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.26.95Bn,) UGX.25,32Bn was spent by the entity resulting in an unspent balance of UGX.1.63 Bn representing an absorption", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.26.95Bn,) UGX.25,32Bn was spent by the entity resulting in an unspent balance of UGX.1.63 Bn representing an absorption", "page": 456, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district budgeted to receive UGX.279,500,000 as", "page": 456, "level": 3}}], "page": 456, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "level of 94%.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.26.95Bn,) UGX.25,32Bn was spent by the entity resulting in an unspent balance of UGX.1.63 Bn representing an absorption", "page": 456, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that the district budgeted to receive UGX.279,500,000 as", "page": 456, "level": 3}}], "page": 456, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 456, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.26.95Bn,) UGX.25,32Bn was spent by the entity resulting in an unspent balance of UGX.1.63 Bn representing an absorption", "page": 456, "level": 3}}], "page": 456, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Q2, Q3, Q4 after the deadline given for submission of the reports \n444", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 456, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.26.95Bn,) UGX.25,32Bn was spent by the entity resulting in an unspent balance of UGX.1.63 Bn representing an absorption", "page": 456, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 456, "level": 3}}, {"headings_1": {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.26.95Bn,) UGX.25,32Bn was spent by the entity resulting in an unspent balance of UGX.1.63 Bn representing an absorption", "page": 456, "level": 3}}]], "page": 456, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}], "table_of_contents": [{"content": ["LIST OF ACRONYMS - ix", "GLOSSARY OF TERMS - xi", "FOREWORD BY THE AUDITOR GENERAL - xii", "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT - 1", " 1.0 INTRODUCTION AND PURPOSE - 1", " 1.1 General Introduction - 1", " 1.2 Purpose - 1", " 1.3 Summary of Audit Results - 2", " 1.3.1 General Performance - 2", " 1.3.2 Summary of Opinions - 3", "PART 2: CONSOLIDATED FINANCIAL STATEMENTS - 4", "REPORT OF THE AUDITOR GENERAL ON THE CONSOLIDATED FINANCIAL STATEMENTS - 4", "2.0", "2.1 REPORT AND OPINION OF THE AUDITOR GENERAL ON THE GOVERNMENT OF UGANDA", "CONSOLIDATED FINANCIAL STATEMENTS FOR THE YEAR ENDED 30 TH JUNE 2021 - 4", "Opinion\u2026 .\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026 - 4", "Basis for Opinion - 4", "Key Audit Matter - 4", "Implementation of the approved budget - 4", "2.1.1.", "COVID 19 expenditure - 11", "2.1.2.", "Compensations/Acquisition of Right of Way for Selected Transmission Lines Projects - 14", "2.1.3.", "Emphasis of Matter - 16", "Other Matter - 17", " 2.1.4 Tax policy - 17", "Audit of public debt - 19", "2.1.5.", "Management of ICT in government - 25", "2.1.6.", "Audit of public investments - 27", "2.1.7.", "Continued expenditure off the IFMS \u2013 UGX 695,372,792,876 - 30", "2.1.8.", "Other Information - 31", "Responsibilities of Management for the Consolidated Financial Statements - 31", "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements - 32", "Other Reporting Responsibilities - 33"], "page": 3}, {"content": ["JUSTICE LAW AND ORDER SECTOR - 65", "Management of cases and Case backlog - 65", "3.4.1.", "Operationalisation of the Joint Venture Agreement - 66", "3.4.2.", "INFORMATION COMMUNICATION TECHNOLOGY SECTOR - 67", "3.5.", "Absence of a National IT Governance/Oversight System - 67", "3.5.1.", "Failure by MDAs to Pay for National Backbone Infrastructure Services - 67", "3.5.2.", "Uncollected Revenue from Media Operators - 67", "3.5.3.", "Lack of a Communications Tribunal - 68", "3.5.4.", " 3.6 ACCOUNTABILITY SECTOR - 69", "Approval of supplementary funding without matching revenue - 69", "3.6.1.", "Underperformance in Revenue Collection - 69", "3.6.2.", "3.6.3.", "Overstay of projects in the Public Investment Plan (PIP)-UGX.39.01Tn - 69", "Un recovered Advances; UGX.2,819,193,074 - 70", "3.6.5.", "Absence of a monitoring and evaluation framework for impact assessment for tax exemptions - 70", "3.6.6.", " 3.7 ENERGY SECTOR - 71", "Capitalization of Uganda National Oil Company and its Subsidiary Companies - 71", "3.7.1.", "Implementation of the Electricity Connection Policy(ECP) - 71", "3.7.2.", "Vandalism and Theft of UETCL Grid Assets - 72", "3.7.3.", "Deemed Energy Purchases: UGX.87.7 Billion and Power Evacuation Losses UGX.15.29 Billion - 72", "3.7.4.", "Delayed Commissioning of Karuma HPP - 73", "3.7.5.", "3.7.6.", "GENDER AND SOCIAL DEVELOPMENT SECTOR - 75", "Labour Externalization Inadequacies - 75", "3.8.1.", "Implementation of the Uganda Women Entrepreneurship Programme - 76", "3.8.2.", " 3.9 LAND SECTOR - 77", "Management of Government Land Matters - 77", "3.9.1.", " 3.10 EDUCATION SECTOR - 77", " 3.10.1 Management of Bilateral Scholarships - 77", "Management of Research Grants by Public Universities in Uganda - 78", "3.10.2.", "WATER & ENVIRONMENT SECTOR - 80", "3.11.", "Afforestation and Restoration of Selected Central Forest Reserves (CFRS) by the (NFA) - 80", "3.11.1.", " 3.12 WORKS SECTOR - 81", "Uganda National Roads Authority - 81", "3.12.1.", "Ministry of Works and Transport - 82", "3.12.2.", "v"], "page": 5}, {"content": [" 3.12.3 Uganda Railways Corporation - 83", "Uganda Civil Aviation Authority - 83", "3.12.4.", " 3.13 HEALTH SECTOR - 85", " 3.13.1 Mulago National Referral Hospital - 85", " 3.13.2 National Drug Authority - 86", "SCIENCE, TECHNOLOGY AND INNOVATION SECTOR - 86", "3.14.", "Closure of the Ministry of Science, Technology and Innovation - 86", "3.14.1.", "Un-deployed Staff upon the abolition of the Ministry - 87", "3.14.2.", "Progress on the COVID-19 Vaccine, Diagnostics and Treatment Projects - 87", "3.14.3.", " 3.15 TRADE SECTOR - 88", " 3.16 TOURISM SECTOR - 89", "HIGHLIGHTS FROM THE AUDIT OF LOWER LOCAL GOVERNMENTS FOR THE PERIOD 2019/2020 - 90", "3.17.", " 3.17.1 Under staffing - 90", "Budget implementation in sample LLGs for FY 2018/2019 and 2019/2020 - 91", "3.17.2.", " 3.17.3 Quality of Financial Statements - 92", "Land Management in Local Governments - 92", "3.17.4.", "Lack of Urban Physical Planning Committees - 93", "3.17.5.", "HIGHLIGHTS FROM THE ENGINEERING AUDITS - 94", "4.0.", "4.1.", "Engineering Audit of Selected Road and Building Projects in Kampala Capital City Authority (KCCA) - 98", " 5.0 INFORMATION SYSTEMS AUDITS - 100", "Information Systems Audit of Civil Aviation Authority - 100", "5.1.", "Information Systems Audit of the Academic Management Information System (AIMS) - 102", "5.2.", "Information Systems Audit of Uganda National Land Information System (Ug-NLIS) - 105", "5.3.", " 6.0 SPECIAL VERIFICATIONS - 108", "Verification of Assets and Liabilities for Uganda Telecom (In-Administration) - 108", "6.1.", "Verification of Terminal Benefits/Pension of former Employees UPTC - 109", "6.2.", "HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS - 111", "7.0.", "Value for Money Audit on the Management of Government Investments by UDC - 111", "7.1.", "7.2 A Value for Money Audit on The Afforestation and Restoration of Selected Central Forest Reserves", "(CFRs) by the National Forestry Authority (NFA) - 113", "7.3 A Value for Money Audit on the Implementation of the Uganda Women Entrepreneurship Programme", "\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026.115", "A Value for Money Audit Report on the Management of Research Grants by Public Universities - 117", "7.4.", "vi"], "page": 6}, {"content": ["Value for Money Audit on The Management Of MATIP-1 Markets by Municipalities - 121", "Prevention and Response to Incidents of Fire by Uganda Police Force - 122", "7.6.", "Value for Money Audit on the Performance of the Agriculture Cluster Development Project - 125", "7.7.", "7.8 Follow up on the Value for Money Audit on the Compensation of Project Affected Persons under the", "Refinery Project by the Ministry of Energy and Mineral Development - 126", "7.9 VFM Audit on the Implementation of the Uganda Reproductive Maternal and Child Health Services", "Improvement Project (URMCHSIP) - 127", "ANNEXURES - 129", "ANNEXURE I: SUMMARY OF ENTITY FINDINGS AND OPINIONS FOR MDAs, COMMISSIONS, STATUTORY", "CORPORATIONS AND STATE ENTERPRISES AND PROJECTS - 129", "ANNEXURE II: SUMMARY OF ENTITY FINDINGS AND OPINIONS FOR LOCAL GOVERNMENTS - 316", "ANNEXURE III: REPORTS AND CONSOLIDATED GOVERNMENT OF UGANDA FINANCIAL STATEMENTS - 445"], "page": 7}, {"content": ["Table 1: Status of audit performance for audit year 2021 - 2", "Table 2: Summary of Current Year Opinions - 3", "Table 3: Trend of Opinions for MDAs, Higher Local Governments for the last three years - 3", "Table 4: Tax arrears - 19", "Table 5: Debt portfolio analysis - 20", "Table 6: Total revenue ratio - 22", "Table 7: Tax to GDP ratio - 23", "Table 8: Noncompliance with the 70% capital threshold - 28", "Table 9: Absorption of fund - 29", "Table 10: Showing Level of Absorption for Wage, Pension and Gratuity - 36", "Table 11: Entities with unsupported expenditure - 45", "Table 12 Un-consolidated local governmentsSn - 46", "Table 13: Status of implementation of UgIFT projects - 47", "Table 14: UgIFT projects without land titles - 48", "Table 15: Entities not Consolidated, but Disclosed in summary statement - 53", "Table 16: Entities neither reported nor Disclosed in the consolidated summary statement - 53", "Table 17: Entities not assessed - 54", "Table 18: Profitability of Public Corporation and State Enterprises - 55", "Table 19: Returns on Assets - 56", "Table 20: Enterprise Liquidity - 57", "Table 21: Liquidity assessment for financial institutions - 58", "Table 22: Loans and Advances performance - 59", "Table 23: Enterprises' ability to service loan obligations - 59", "Table 24: Comparison of consolidated quantities of production inputs - 63", "Table 25: Information Systems within the JLOS Sector - 65", "Table 26: Understaffing in Lower Local Government - 90", "Table 27: Performance of Central Government Grant - 91", "Table 28: Performance of Local Revenue - 91", "Table 29: Unjustified Payments and Overpayments - 99", "Table 30: Creditors Verified - 108", "Table 31: Summary of claims presented for Verification - 110", "Table 32: Summary of Verified claims payable - 110", "Table 33: Challenges of Project Implementation - 112"], "page": 8}]} \ No newline at end of file +{"paragraphs": [{"content": [["ACRONYM", "DESCRIPTION"], ["AG", "Auditor General"], ["AO Accounting Officer", null], ["Bn", "Billion"], ["BoU Bank of Uganda", null], ["CAs", "Contracting Authorities"], ["CFR Central Forest Reserve", null], ["DGAL", "Directorate of Government Analytical Laboratory"], ["DLB District Land Board", null], ["FY", "Financial Year"], ["GDP Gross Domestic Product", null], ["GoU", "Government of Uganda"], ["ICT Information Communication Technology", null], ["IDA", "International Development Association"], ["IESBA International Ethics Standards Board for Accountants", null], ["IFMS", "Integrated Financial Management System"], ["IMF International Monetary Fund", null], ["KIS", "Kalangala Infrastructure Services"], ["MAAIF Ministry of Agriculture Animal Industry and Fisheries", null], ["MDAs", "Ministries, Departments and Agencies"], ["MEMD Ministry of Energy and Mineral Development", null], ["MOFPED", "Ministry of Finance, Planning, and Economic Development"], ["MoGLSD Ministry of Gender Labour and Social Development", null], ["MoU", "Memoranda of Understanding"], ["MTEF Medium Term Expenditure Framework", null], ["NAA", "National Audit Act"], ["NBI National Backbone Infrastructure", null], ["NDP", "National Development Plan"], ["NDPII Second National Development Plan", null], ["NEF", "National Environment Fund"], ["NEMA National Environment Management Authority", null], ["NFA", "National Forestry Authority"], ["NGO Non-Governmental Organisation", null], ["NIN", "National Identification Number"], ["NIRA National Identification Registration Authority", null], ["NPA", "National Planning Authority"], ["NWSC National Water and Sewerage Corporation", null], ["OAG", "Office of the Auditor General"], ["PAPs Project Affected Persons", null], ["PDMF", "Public Debt Management Framework"], ["PFMA Public Finance Management Act, 2015", null], ["PS/ST", "Permanent Secretary/Secretary to the Treasury"], ["PSST Permanent Secretary and Secretary to Treasury", null], ["TAI", "Treasury Accounting Instructions, 2016"], ["TIN Tax Identification Number", null], ["Tn", "Trillion"], ["TWGs Technical Working Groups", null], ["UCC", "Uganda Communications Commission"]], "metadata": {"headings": [{"headings_0": {"content": "viii", "page": 8, "level": 2}}], "page": 9, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1"], "type": "table"}}, {"content": "ix", "metadata": {"headings": [{"headings_0": {"content": "ix", "page": 9, "level": 2}}], "page": 9, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["UCF Uganda Consolidated Fund", null], ["UDC", "Uganda Development Corporation"], ["UETCL Uganda Electricity Transmission Company Limited", null], ["UGX", "Uganda Shillings"], ["URA Uganda Revenue Authority", null], ["USD", "United States Dollars"], ["USMID Uganda Support for Municipal Infrastructure Development", null], ["WMD", "Wetlands Management Department"], ["YIGs Youth Interest Groups", null], ["YLP", "Youth Livelihood Programme"]], "metadata": {"headings": [{"headings_0": {"content": "ix", "page": 9, "level": 2}}], "page": 10, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["ACRONYM", "DESCRIPTION"], "type": "table"}}, {"content": "x \nGLOSSARY OF TERMS", "metadata": {"headings": [{"headings_0": {"content": "ix", "page": 9, "level": 2}}, [{"headings_0": {"content": "ix", "page": 9, "level": 2}}]], "page": 10, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Term", "Definition"], ["Classified Expenditure", "The expenses and commitments incurred by an authorised agency for the"], ["", "collection and dissemination of information related to national security"], [null, "interests"], ["Contingent Liability A potential liability that may occur depending on the outcome of an uncertain future event.", null], ["Domestic Arrears", "Domestic arrears refer to short-term debts incurred by Governments against"], ["", "unpaid procurement invoices for supply of goods and services during the"], [null, "financial year"], ["External Debt Portion of a country's debt that was borrowed from foreign lenders including commercial banks, Governments or international financial institutions.", null], ["Garnishee order", "A form of enforcing a judgment debt against a creditor to recover money."], ["Nugatory Expenditure Expenditure that does not achieve any result", null], ["Off-budget financing", "Off-buget refers to expenditure that is not funded through the budget"], ["Recruitment Refers to the process of attracting, screening, selecting, and on boarding a qualified person for a job, provided by an employer in another territory and the preparation for their departure.", null], ["Revolving Fund", "A fund that is continually replenished as withdrawals are made."], ["", null]], "metadata": {"headings": [{"headings_0": {"content": "ix", "page": 9, "level": 2}}], "page": 11, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["ACRONYM", "DESCRIPTION"], "type": "table"}}, {"content": "xi \nFOREWORD BY THE AUDITOR GENERAL \nIn accordance with my audit mandate set out under Article 163 of the Constitution of the Republic of Uganda, 1995 (as amended) and the National Audit Act, 2008, I hereby present to you the Annual Audit Report on the Consolidated Public Accounts of Uganda; Local Government; and Summary Statement of Financial Performance of Public Corporations, and State Enterprises and Companies in which Government has a controlling interest. \nIn delivering my mandate, I audited financial statements for 128 MDAs, 107 Statutory Corporations 145 Local Governments and 2048 Lower Local Governments. In addition, I undertook four (4) thematic audits covering, Management of Covid-19 pandemic intervention, compensations of Project Affected Persons, implementation of the approved budget, and Payroll and Pension payments. \nThe Office reviewed its audit process to comply with the Covid-19 guidelines from the Ministry of Health and Ministry of Public Service, by conducting some critical meetings virtually and coping with a lean staff. In addition, Stakeholders have increased their call to strengthen accountability in the wake of the Pandemic triggering special audits and investigations relating to Covid-19 expenditure. \nDue to the impact of the Pandemic, some audits were not conducted as planned, but we are committed to continuously adding value to society by making recommendations that enhance accountability and improved service delivery through audit services. \nI extend my gratitude to the Government of Uganda and all other stakeholders for the support rendered to my office during the audit year. I also thank my staff for their unwavering commitment during this challenging period. \nJohn F.S. Muwanga AUDITOR GENERAL \n31 st December 2021 \nxii \nPART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE \n1.1 General Introduction \nI am required by Article 163(3) of the Constitution of the Republic of Uganda and Section 13 and 19 of the National Audit Act 2008 to audit and report on the public accounts of Uganda and of all public offices including the Courts, the Central and Local Government Administrations, Universities and Public Institutions of like nature and any Public Corporations or other bodies established by an Act of Parliament. \nSection 13 (b) of the National Audit Act 2008 further requires me to conduct the following audits: \n", "metadata": {"headings": [{"headings_0": {"content": "xi", "page": 11, "level": 2}}, [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}], [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}], [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}], [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}], [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}], [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}], [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}], [{"headings_0": {"content": "FOREWORD BY THE AUDITOR GENERAL", "page": 12, "level": 2}}], [{"headings_0": {"content": "xii", "page": 12, "level": 2}}], [{"headings_0": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}], [{"headings_0": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}], [{"headings_0": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}], [{"headings_0": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}], [{"headings_0": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}]], "page": 11, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- Financial audits\n- Value for money", "metadata": {"headings": [{"headings_0": {"content": "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT 1.0 INTRODUCTION AND PURPOSE", "page": 13, "level": 4}}], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 Engineering", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Engineering", "page": 13, "level": 1}}], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- Information Systems\n- Special/Forensic Audits\n- Gender and Environment and any other audits in respect of any project or activity involving public funds\n- Classified expenditure\n- Government investments\n- Procurement audits, and\n- Treasury Memoranda", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Engineering", "page": 13, "level": 1}}], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nUnder Article 163 (4) of the Constitution, I am also required to submit to Parliament annually a report of the accounts audited by me for the year immediately preceding. I am therefore, issuing this report in accordance with the above provisions. \n1.2 Purpose \nThe purpose of this report is to provide: \n(i) \nA summary of audit results and opinions for audits done in the year \n(ii) \nA report and Opinion of the Auditor General on the; \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Engineering", "page": 13, "level": 1}}, [{"headings_0": {"content": "\uf0b7 Engineering", "page": 13, "level": 1}}], [{"headings_0": {"content": "\uf0b7 Engineering", "page": 13, "level": 1}}], [{"headings_0": {"content": "(i)", "page": 13, "level": 2}}], [{"headings_0": {"content": "(i)", "page": 13, "level": 2}}], [{"headings_0": {"content": "(ii)", "page": 13, "level": 2}}], [{"headings_0": {"content": "(ii)", "page": 13, "level": 2}}], [{"headings_0": {"content": "(ii)", "page": 13, "level": 2}}]], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Consolidated Financial Statements of the Government of the Republic of Uganda for the year ended 30 th June 2021\n- Consolidated Financial Statements of Local Governments for the year ended 30 th June 2021\n- The Consolidated Summary Statement of Financial Performance of Public Corporations and State Enterprises for the year ended 30 th June 2021", "metadata": {"headings": [{"headings_0": {"content": "(ii)", "page": 13, "level": 2}}], "page": 13, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": [["Category of Audited entities", "Type of Opinions", null, null, null, "Total"], ["", "Unqualified", "Qualified", "Adverse", "Disclaimer", ""], ["Ministries, Departments and Agencies 116 12 0 0 128", null, null, null, null, null], ["Commissions, Statutory", "100", "7", "0", "0", "107"], ["Authorities and State", null, null, null, null, null], ["Enterprises", null, null, null, null, null], ["Projects 144 2 0 0 146", null, null, null, null, null], ["Districts Local Governments", "110", "5", "0", "0", "115"], ["Regional Referral hospitals 6 0 0 0 6", null, null, null, null, null], ["Municipal Councils and Cities", "23", "1", "0", "0", "24"], ["Funds 3 0 0 0 3", null, null, null, null, null], ["TOTAL", "502", "27", "0", "0", "529"]], "metadata": {"headings": [{"headings_0": {"content": "Table 2: Summary of Current Year Opinions", "page": 15, "level": 3}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5"], "type": "table"}}, {"content": "\\*The table above excludes Lower Local Governments \nTable 3: Trend of Opinions for MDAs, Higher Local Governments for the last three years", "metadata": {"headings": [{"headings_0": {"content": "Table 2: Summary of Current Year Opinions", "page": 15, "level": 3}}, [{"headings_0": {"content": "Table 3: Trend of Opinions for MDAs, Higher Local Governments for the last three years", "page": 15, "level": 3}}]], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Type of Opinion", "2020/21", "2019/20", "2018/19"], ["Unqualified", "502", "420", "433"], ["Qualified 27 33 54", null, null, null], ["Adverse", "0", "0", "0"], ["Disclaimer 0 0 0", null, null, null], ["Total", "529", "453", "487"]], "metadata": {"headings": [{"headings_0": {"content": "Table 3: Trend of Opinions for MDAs, Higher Local Governments for the last three years", "page": 15, "level": 3}}], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "Figure 1: Summary of opinions for the last 3 years \n600 500 400 300 \nUnqualified qualified \n200 100 0 \n2018/19 2019/20 2020/21 \n3 \nPART 2: CONSOLIDATED FINANCIAL STATEMENTS \n2.0 \nREPORT OF THE AUDITOR GENERAL ON THE CONSOLIDATED FINANCIAL STATEMENTS \n2.1 \nREPORT AND OPINION OF THE AUDITOR GENERAL ON THE GOVERNMENT OF UGANDA CONSOLIDATED FINANCIAL STATEMENTS FOR THE YEAR ENDED 30 TH JUNE 2021 \nTHE RT. HON. SPEAKER OF PARLIAMENT \nOpinion \nI have audited the accompanying Consolidated Financial Statements of the Government of the Republic of Uganda for the year ended 30 th June 2021. These financial statements comprise of the Consolidated Statement of Financial Position as at 30 th June 2021, the Consolidated Statement of Financial Performance, and Consolidated Cash Flow Statement together with other accompanying statements, notes, and accounting policies. \nIn my opinion, the Consolidated Financial statements of the Government of the Republic of Uganda for the financial year ended 30th June 2021 are prepared, in all material respects, in accordance with Section 52 of the Public Finance Management Act, 2015 and the Financial Reporting Guide, 2018. \nBasis for Opinion", "metadata": {"headings": [{"headings_0": {"content": "Figure 1: Summary of opinions for the last 3 years", "page": 15, "level": 3}}, [{"headings_0": {"content": "Figure 1: Summary of opinions for the last 3 years", "page": 15, "level": 3}}], [{"headings_0": {"content": "Unqualified qualified", "page": 15, "level": 4}}], [{"headings_0": {"content": "Unqualified qualified", "page": 15, "level": 4}}], [{"headings_0": {"content": "2018/19 2019/20 2020/21", "page": 15, "level": 4}}], [{"headings_0": {"content": "2018/19 2019/20 2020/21", "page": 15, "level": 4}}], [{"headings_0": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}], [{"headings_0": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}], [{"headings_0": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}], [{"headings_0": {"content": "PART 2: CONSOLIDATED FINANCIAL STATEMENTS", "page": 16, "level": 2}}], [{"headings_0": {"content": "Opinion", "page": 16, "level": 2}}], [{"headings_0": {"content": "Opinion", "page": 16, "level": 2}}], [{"headings_0": {"content": "Opinion", "page": 16, "level": 2}}], [{"headings_0": {"content": "Opinion", "page": 16, "level": 2}}]], "page": 15, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- UGX (Bn) - ance UGX (Bn)-UGX UGX (%)", "metadata": {"headings": [{"headings_0": {"content": "The table below summaries the performance of revenue by source;", "page": 17, "level": 3}}], "page": 17, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Domestic Resources \nTaxes 20,218.68 20,218.68 18,252 1,966.68 90 \nNon-Tax 1,805.98 1,805.98 1,648 157.98 91 revenue 1 \nDomestic 3,560.32 6,794 6,794 - 100 financing \nDomestic 7,486.1 7,486.1 7,420 66.1 99 refinancing \n1 Includes Appropriation in Aid of UGX 215 billion. \n5", "metadata": {"headings": [{"headings_0": {"content": "The table below summaries the performance of revenue by source;", "page": 17, "level": 3}}, [{"headings_0": {"content": "The table below summaries the performance of revenue by source;", "page": 17, "level": 3}}], [{"headings_0": {"content": "1 Includes Appropriation in Aid of UGX 215 billion.", "page": 17, "level": 3}}], [{"headings_0": {"content": "1 Includes Appropriation in Aid of UGX 215 billion.", "page": 17, "level": 3}}]], "page": 17, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN Finding", null, null, null, null, null, null, "Recommendation"], ["\uf0b7 \uf0b7 A \uf0b7 \uf0b7 A \uf0b7", "External Resources", null, null, null, null, null, null], [null, "Budget support", null, null, null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "1 Includes Appropriation in Aid of UGX 215 billion.", "page": 17, "level": 3}}], "page": 18, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4", "column_7", "column_8", "column_9", "column_10", "column_11"], "type": "table"}}, {"content": [["SN Finding", null, null, null, null, null, null, "Recommendation"], ["\uf0b7 \uf0b7 A \uf0b7 \uf0b7 A \uf0b7", "External Resources", null, null, null, null, null, null], [null, "Budget support", null, null, null, null, null, null], [null, "Grants", "133.56", "133.56", "62.85", "70.71", "47", null], [null, "", null, null, null, null, null, null], [null, "Loans", "2,773.12", "2,773.12", "3,134.13", "-361.01", "113", null], [null, "Project support", "", "", "", "", "", null], [null, "", null, null, null, null, null, null], [null, "Grants", "1,586.35", "1,586.35", "1,026.04", "560.31", "65", null], [null, "Loans", "7,928.98", "7,928.98", "6,822.23", "1,106.75", "86", null], [null, "", null, null, null, null, null, null], [null, "Grand Total", "45,493.09", "48,726.77", "45,159.25", "1,667.06", "93", null], [null, "", null, null, null, null, null, null], [null, "Actual funding for the budget during the financial year was UGX.", null, null, null, null, null, null], [null, "45,159.25Bn (93%) against a revised revenue budget of UGX.", null, null, null, null, null, null], [null, "48,726.77Bn, indicating a shortfall of UGX. 3,567.52Bn. The details of", null, null, null, null, null, null], [null, "funding source are provided below.", null, null, null, null, null, null], [null, "", null, null, null, null, null, null], [null, "Taxes total tax revenue collected during the year was UGX.", null, null, null, null, null, null], [null, "19,697.7Bn, representing 90% of the approved estimates.", null, null, null, null, null, null], [null, "", null, null, null, null, null, null], [null, "Non-tax revenue total of UGX.1,605.42Bn was realised from this source against a", null, null, null, null, null, null], [null, "target of UGX.1,805.98Bn representing a performance of 89%.", null, null, null, null, null, null], [null, "Budgeting for NTR remains a challenge at the Treasury, as the", null, null, null, null, null, null], [null, "figures included in the revenue estimates are not agreed with", null, null, null, null, null, null], [null, "individual votes, and a number of entities do not reflect NTR in their", null, null, null, null, null, null], [null, "budgets.", null, null, null, null, null, null], [null, "", null, null, null, null, null, null], [null, "Budget support Government planned to raise a total of UGX.2,906.68 Bn for budget", null, null, null, null, null, null], [null, "support of which 5% was grants while 95% was from loans. Grants", null, null, null, null, null, null], [null, "underperformed by 52% while Government acquired loans of", null, null, null, null, null, null], [null, "UGX.361 Bn in excess of what was planned translating into a 113%", null, null, null, null, null, null], [null, "performance. The increase in loans for budget support related to", null, null, null, null, null, null], [null, "additional borrowing that was secured in light of COVID -19", null, null, null, null, null, null], [null, "disruptions.", null, null, null, null, null, null], [null, "", null, null, null, null, null, null], [null, "Project support total of UGX.9,515.33 Bn (20%) of the approved budget was", null, null, null, null, null, null], [null, "planned for project support of which grants and loans were", null, null, null, null, null, null], [null, "UGX.1,586.35 Bn and UGX.7,928.98 Bn respectively. Grants", null, null, null, null, null, null], [null, "underperformed by 60% (UGX.1,026.04 Bn) while UGX.6,822.23 Bn", null, null, null, null, null, null], [null, "(83%) was realised from the loans.", null, null, null, null, null, null], [null, "", null, null, null, null, null, null], [null, "Domestic refinancing Government planned to pay back maturing Treasury Instruments by", null, null, null, null, null, null], [null, "borrowing afresh from the market (domestic refinance) to a tune of", null, null, null, null, null, null], [null, "UGX.7,486.1 Bn, of which UGX.7,420Bn (99%) was realised.", null, null, null, null, null, null], [null, "", null, null, null, null, null, null], [null, "Management attributed the Tax and Non tax Revenue shortfall", null, null, null, null, null, null], [null, "mainly to the lockdown measures that were instituted by government", null, null, null, null, null, null], [null, "curb the spread of the COVID 19 that constrained revenue major", null, null, null, null, null, null], [null, "sources and the slow Economic growth which is a major contributor", null, null, null, null, null, null], [null, "taxes that declined from the projected 6.4% to 3.1%. Deficits", null, null, null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "1 Includes Appropriation in Aid of UGX 215 billion.", "page": 17, "level": 3}}], "page": 18, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4", "column_7", "column_8", "column_9", "column_10", "column_11"], "type": "table"}}, {"content": "each The \nto \nto \n6", "metadata": {"headings": [{"headings_0": {"content": "each The", "page": 18, "level": 3}}, [{"headings_0": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}]], "page": 18, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["SN Finding", "Recommendation"], ["were registered in CIT, VAT, excise duty and Corporation Tax since companies were not working. The EFRIS has now been rolled out and Digital stamps implementation is under way to revive revenue collection. Management also indicated that NTR Budget estimates books have been revised and the budget process for NTR enhanced to incorporate Universities fees collection which was a major challenge in terms of providing the right estimates. The NTR Budget consultation process for FY 2022/23 had been concluded for all Votes and a realistic target set for NTR collections.", null], ["b) Unfunded approved budget During the year under review, Government budgeted to spend a total of UGX.45,439 Bn, which was later revised to UGX.51,625 Bn. An analysis of warrants approved revealed that a total of UGX.46,657 Bn was approved against the budgeted amounts, thus representing 90% performance. A sum of UGX.4,968 Bn was not availed for expenditure. See table below; Entity Percenta ge Total Revised Budget \u2013 UGX(bn) Total warrants - UGX(bn) Variance- UGX(bn) Central Govt 73.42% 37,904.70 35,717.10 2,187.7 Local Govt 8.38% 4,327.80 4,218.40 109.4 Local Revenue 0.42% 217.4 115.3 102.0 Project Financing 17.77% 9,176.00 6,606.80 2,569.2 Total 51,626.00 46,657.60 4,968.4 Failure to fully fund the revised budget affected the implementation of the planned activities which were intended to contribute to the achievement of the NDP III and Vision 2040. The detailed impact of this shortfall on the entity activities has been reported in the individual entity reports. Notably, there was a significant variance in project financing which is explained by under absorption by the various implementing MDAs. It was observed that whereas the performance contracts with Accounting Officers are premised on availing the appropriated budgets during the year, such contracts are not revised in situations of shortfalls in budgets. The Secretary to Treasury indicated that the funds releases to Votes are in line with the available resources issued in quarterly expenditure limits which are supported by actual revenue collections from URA and also indicated that Ministry of finance provides guidance by way of circulars to all Votes to fund only critical activities within the work plans in line with the available resources. The Secretary to Treasury committed to improving releases as I advised the PSST to provide guidance to MDAs in regard to the prioritization of activities to the levels of availed resources in cases of shortfalls.", null]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}], "page": 19, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_7"], "type": "table"}}, {"content": "7", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}], "page": 19, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN Finding", "Recommendation"], ["revenue collections improve with the economy recovering from the current economic shocks.", null], ["c) Unspent warrants/under absorption of funds UGX .3,018.44Bn Section 45 (3) of the Public Finance Management Act, 2015 states that an Accounting Officer shall enter into an annual budget performance contract with the Secretary to the Treasury which shall bind the Accounting Officer to deliver on the activities in the work plan of the vote for a Financial year. It was observed that warrants worth UGX.46,657.6 billion were approved in respect of various entities for which only UGX.43,639.2 billion was paid out leaving UGX.3,018.4 billion (6.5% of approved warrants) unspent. The details are indicated in the table below; Approved Warrants (UGX\u2019 billion) Total Payments (UGX\u2019 billion) Unspent funds (UGX\u2019 billion) ENTI TY Wage Non - Wage Develop ment wage Non - Wage Develo pment wag e Non- Wage Dev CG 2,710 23,647 15,771 2,637 21,32 15,725 73 2,327 45 Missi ons 28 149 18 28 149 17.9 - - - LG 2,271 1,071 992.1 2,151 1,025 586 119 46 406 TOTA L 5,009 24,867 16,781 4,816 22,494 16,329 193 2,373 452 From the above, it can be seen that 79% of the unspent funds related to non-wage expenditure while wage and development expenditure posted underperformance of 6% and 15% respectively. 98% of the unspent funds under non-wage related to Vote 130 (Treasury Operations) and were meant to settle interest costs and treasury bills and Bonds redemptions. The occurrence has an implication of increasing financing costs incurred by the government since the interest costs and redemptions are done by Bank of Uganda which in turn charges the treasury for the advance. Most of the unspent funds under wage related to pension payments casting doubt on the existence of the said pensioners. Under absorption negatively affects service delivery since some of the planned projects and activities are not undertaken. The Secretary to Treasury indicated that GoU operates a Cash budget which is based on actual inflows. The year under audit experienced cash shortfalls arising from, Domestic revenue shortfall as a result of the Covid -19 pandemic , late disbursements from IMF ,which came in on 30 June 2021 & Non disbursement from Afri-Exim Bank and African Development Fund. The occurrence contributed to delay in implementation of planned activities hence the under absorption of funds.", "I advised the"]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}], "page": 20, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_11"], "type": "table"}}, {"content": [["SN Finding", "Recommendation"], ["revenue collections improve with the economy recovering from the current economic shocks.", null], ["c) Unspent warrants/under absorption of funds UGX .3,018.44Bn Section 45 (3) of the Public Finance Management Act, 2015 states that an Accounting Officer shall enter into an annual budget performance contract with the Secretary to the Treasury which shall bind the Accounting Officer to deliver on the activities in the work plan of the vote for a Financial year. It was observed that warrants worth UGX.46,657.6 billion were approved in respect of various entities for which only UGX.43,639.2 billion was paid out leaving UGX.3,018.4 billion (6.5% of approved warrants) unspent. The details are indicated in the table below; Approved Warrants (UGX\u2019 billion) Total Payments (UGX\u2019 billion) Unspent funds (UGX\u2019 billion) ENTI TY Wage Non - Wage Develop ment wage Non - Wage Develo pment wag e Non- Wage Dev CG 2,710 23,647 15,771 2,637 21,32 15,725 73 2,327 45 Missi ons 28 149 18 28 149 17.9 - - - LG 2,271 1,071 992.1 2,151 1,025 586 119 46 406 TOTA L 5,009 24,867 16,781 4,816 22,494 16,329 193 2,373 452 From the above, it can be seen that 79% of the unspent funds related to non-wage expenditure while wage and development expenditure posted underperformance of 6% and 15% respectively. 98% of the unspent funds under non-wage related to Vote 130 (Treasury Operations) and were meant to settle interest costs and treasury bills and Bonds redemptions. The occurrence has an implication of increasing financing costs incurred by the government since the interest costs and redemptions are done by Bank of Uganda which in turn charges the treasury for the advance. Most of the unspent funds under wage related to pension payments casting doubt on the existence of the said pensioners. Under absorption negatively affects service delivery since some of the planned projects and activities are not undertaken. The Secretary to Treasury indicated that GoU operates a Cash budget which is based on actual inflows. The year under audit experienced cash shortfalls arising from, Domestic revenue shortfall as a result of the Covid -19 pandemic , late disbursements from IMF ,which came in on 30 June 2021 & Non disbursement from Afri-Exim Bank and African Development Fund. The occurrence contributed to delay in implementation of planned activities hence the under absorption of funds.", "I advised the"], [null, "Secretary to the"], [null, "Treasury to"], [null, "strengthen the cash"], [null, "forecasting function"], [null, "to avoid issuing"], [null, "warrants that cannot"], [null, "be financed."], [null, ""], [null, ""], ["d) Approval of supplementary funding without matching revenue Section 25(1) of the Public Finance and Accountability Act (PFMA) stipulates that the total supplementary expenditure that requires additional resources over and above what is approved by Parliament I await the outcome of the new measures.", null]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}], "page": 20, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_11"], "type": "table"}}, {"content": "8", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}], "page": 20, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN", "Finding", "Recommendation"], ["shall not exceed 3% of the total approved budget for that financial year, without the approval of Parliament. It was established that during the financial year ended 30 th June 2021, supplementary funding totalling UGX.6.13Tn was granted by the Minister of Finance, Planning and Economic Development. It was, however, noted that the source of the funding for the supplementary expenditure was not clearly shown before approval was granted. As a result, the supplementary expenditure was instead financed by internal budget cuts from various votes thus affecting implementation of plans/ activities by the affected votes. I noted that, although the budget was increased to UGX.51.625Tn, it was only funded to the tune of UGX.46.6Tn (90%funding). Continued approval of supplementary budgets without a corresponding increase in revenue/financing could be attributed to fiscal indiscipline which leads to increased funding gap affecting the earlier budget objectives and plans. The Secretary to Treasury responded that for the Financial Year 2022/23, the Ministry of Finance was using zero based budgeting approach to prioritize critical activities and expenditures to avoid supplementary requests during execution. The budget for 2022/23 is being used as a launchpad for restricting supplementary budgets to stabilize GoU budget execution going forward.", null, null], ["e)", "Budgeting for Non-Tax Revenue", "I advised the PSST"]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}], "page": 21, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["SN", "Finding", "Recommendation"], ["shall not exceed 3% of the total approved budget for that financial year, without the approval of Parliament. It was established that during the financial year ended 30 th June 2021, supplementary funding totalling UGX.6.13Tn was granted by the Minister of Finance, Planning and Economic Development. It was, however, noted that the source of the funding for the supplementary expenditure was not clearly shown before approval was granted. As a result, the supplementary expenditure was instead financed by internal budget cuts from various votes thus affecting implementation of plans/ activities by the affected votes. I noted that, although the budget was increased to UGX.51.625Tn, it was only funded to the tune of UGX.46.6Tn (90%funding). Continued approval of supplementary budgets without a corresponding increase in revenue/financing could be attributed to fiscal indiscipline which leads to increased funding gap affecting the earlier budget objectives and plans. The Secretary to Treasury responded that for the Financial Year 2022/23, the Ministry of Finance was using zero based budgeting approach to prioritize critical activities and expenditures to avoid supplementary requests during execution. The budget for 2022/23 is being used as a launchpad for restricting supplementary budgets to stabilize GoU budget execution going forward.", null, null], ["e)", "Budgeting for Non-Tax Revenue", "I advised the PSST"], [null, "", "to ensure that all"], [null, "Section 6 of the Budget Execution Circular for the FY 2020/21", "Ministries,"], [null, "provides that all work plans and Budgets for FY2020/21 are prepared", "Departments and"], [null, "and approved using the Program Budgeting System (PBS). All", "Agencies budget for"], [null, "Budgets, irrespective of the source of financing (GoU, NTR/AIA,", "the Non-Tax Revenue"], [null, "Donor or LG Revenue), will be migrated and loaded into the", "and have the details"], [null, "Integrated Financial Management System (IFMS) to facilitate Budget", "provided in the IFMS"], [null, "Implementation and reporting.", "and the PBS."], [null, "", ""], [null, "According to the approved budget estimates for the FY2020/21, it", null], [null, "was projected that a total of UGX.1.590 Tn would be collected as", null], [null, "NTR. Review of the Performance Budgeting System(PBS) tool used", null], [null, "by the Government and IFMS records revealed that that NTR Budgets", null], [null, "for the respective MDAs were neither uploaded on PBS nor IFMS. The", null], [null, "budgeting tool only had details regarding expenditure, and no", null], [null, "revenue was included. I further noted that several Accounting", null], [null, "Officers disowned the figures incorporated in the NTR Estimates", null], [null, "book, indicating that they had not been consulted in arriving at the", null], [null, "estimates incorporated therein.", null], [null, "", null], [null, "As a result, I was unable to compare respective entity budget figures", null], [null, "with the URA NTR collections that totalled to UGX.1.605Tn. The", null], [null, "absence of revenue estimates for each entity undermines", null], [null, "transparency, affects motivation of staff, and hampers performance", null], [null, "assessment.", null], [null, "", null], [null, "Management responded that for the budget of FY 2022/23,", null]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}], "page": 21, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "9", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}], "page": 21, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN", "Finding", "Recommendation"], ["", "respective MDAs had been requested to submit their NTR estimates", null], [null, "which will be uploaded and reflected on the PBS as had been done", null]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}], "page": 22, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": [["SN", "Finding", "Recommendation"], ["", "respective MDAs had been requested to submit their NTR estimates", null], [null, "which will be uploaded and reflected on the PBS as had been done", null], [null, "in the NTR estimates booklets. PBS has been upgraded to include the", null], [null, "NTR budgets for Votes. The approved estimates will also be uploaded", null], [null, "on the IFMS for follow up on monthly performance reports.", null], [null, "", null], [null, "", null], [null, "", null], [null, "", null], ["f) Quantification of activities and Implementation of planned outputs Section 13 (15, b) of the PFMA 2015 states that a policy statement submitted by a vote shall contain the annual and three months\u2019 work plans, outputs, targets and performance indicators of the work plans. Regulation 11 (3) of PFMR 2016 requires that a vote prepares a work plan that indicates the outputs of the vote for the financial year; the indicators to be used to gauge the performance of the outputs and funds allocated to each activity. I sampled 94 entities for purposes of assessing the extent of quantification and implementation of planned outputs I noted that out of the 1,681 outputs worth UGX.9.8tn sampled for review, 1,151 outputs (68.5%) worth UGX.6.8tn were fully quantified, 307 outputs (18.3%) worth UGX.2.1tn were partially quantified while 223 out puts (13.2%) worth UGX.902Bn were not quantified at all. Out of a total of 1,151 quantified out-puts worth UGX.6.8tn assessed, 465 (40.4%) output worth UGX.2.5tn were fully implemented, 592 outputs (51.4%) worth UGX.4.1tn were partially implemented, while 94 (8.2%) out-puts worth UGX.146bn were not implemented at all. The graph below shows the extent of implementation; Failure to fully quantify the planned activities makes the assessment of implementation difficult. The Accounting Officers indicated that the outbreak of the Covid-19 Pandemic affected the implementation of the 2019/2020 budget, especially activities in the last half of the financial year. I advised the PSST to follow up the matter with the Accounting Officers of the various MDAs to ensure that there is full quantification of activities and outputs.", null, null], ["g)", "Existence of Strategic plans that are aligned to NDP-III", "I advised the PSST"], [null, null, "to follow up the"], [null, "Paragraph 5 of the budget execution circular for the financial year", "matter with NPA and"], [null, "2020/2021 cites poor alignment of Government Budgets with the", "ensure that the"], [null, "National Development Plans. The PS/ST urged Accounting Officers to", "entities have"], [null, "ensure that all activities for Financial Year 2020/2021 are aligned", "strategic plans that"], [null, "with NDP III and implemented accordingly. Regulation 26 (1) of the", "are aligned to NDP-"], [null, "National Planning Authority (development of Plans) regulations", "III and certified by"], [null, "require entities to submit to NPA their five-year development plans", "NPA."], [null, "for certification before approval.", ""], [null, "", null], [null, "This being the first year of implementation of the NDP-III, MDAs", null], [null, "were expected to prepare strategic plans aligned to NDP III and", null], [null, "ensure that these plans are certified by NPA before approval. These", null], [null, "plans would then be the basis for preparation of the entity annual", null]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}], "page": 22, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": "10", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}], "page": 22, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN", "Finding", "Recommendation"], ["", "plans.", null], [null, "", null], [null, "From the procedures undertaken I noted that out of 94 entities", null], [null, "sampled, 75 were supposed to prepare strategic plans that were", null], [null, "aligned to NDPII. However, out of 75 only 25 (33%) had their", null], [null, "strategic plans certified by NPA. The balance of 50 representing 67%", null], [null, "were not certified by NPA. There is a risk that activities implemented", null], [null, "by these entities during the financial year 2020/2021 were not", null], [null, "aligned to the NDP-III which negatively affects the achievement of", null], [null, "NDP-III objectives.", null], [null, "", null], ["h) Off Budget Financing/Receipts Section 43 (1) of the PFMA 2015 states that all expenditure incurred by the government on externally financed projects in a financial year shall be appropriated by parliament. Paragraph 29 of the Budget Execution Circular for the Financial year states that if an external agency provides funds in the course of implementation of the budget or any funds remain unspent at the expiry of an appropriation, these must be declared and a supplementary issued in line with the Public Finance Management Act 2015. I noted that 30 entities received off-budget financing to a tune of UGX.627.124Bn, which was never declared to the PS/ST and was also not appropriated by Parliament. As such, no supplementary appropriation was issued as guided by the PS/ST. These funds were received directly from development partners for undertaking activities not budgeted for. Off-budget financing distorts planning, may result in duplication of activities, contrary to Section 43(1) of the PFMA 2015 and the budget execution guidelines. The Accounting Officers explained that this was due to limitations of the PBS system which has no provision for inputting such receipts and in some cases funds are received during the year which were not expected at the time of planning. I advised the Accounting Officers to comply with the law and guidance given by the PSST and ensure that in future, all funds received outside the approved budget are appropriated by way of a supplementary.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}], "page": 23, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "2.1.2. COVID 19 expenditure \nThe emergence of the Global Covid-19 pandemic presented a social and economic threat to many countries in the world, including Uganda. In response, the Government of Uganda developed and instituted several interventions to control and avert the effects of the pandemic on the economic and social wellbeing of its citizens. The interventions included instituting a total lockdown, closure of airports, restriction of cross boarder movements, and increased surveillance among others which in turn necessitated additional funding. Mobilisation of revenue was also negatively affected due to low economic activity. \nIn addition to the local revenue raised by the Government to support the budget, Government proceeded to secure additional funding to facilitate the efforts and interventions \n11 \nbeing undertaken to manage and control COVID-19 and its effects on the economy and the society in general. \nIn a letter dated 09th August 2021, the PSST advised me that the total amount released for COVID expenditure in the FY 2020/21 was UGX.2,371Bn of which a total of UGX.677Bn was disbursed for the settlement of domestic arrears. \nDuring the audit, I designed and performed procedures that I considered appropriate under the circumstances to enable me to gather evidence to address the specific objectives listed below; \ni) Confirm whether the funds received by Treasury were dully appropriated by parliament. \nii) \nEstablish whether funds appropriated and allocated were received by the different votes \niii) \nEstablish whether the appropriated funds were utilised for the purpose for which they were approved. \niv) \nAssess the existence and effectiveness of internal control systems. \nv) \nAssess the extent of achievement of planned output by the different entities \nvi) Establish whether all funds disbursed were properly accounted for and value for money was attained. \nvii) \nMake appropriate recommendations to strengthen accountability and transparency. \nFrom the procedures undertaken the following summarised key findings were noted, the detailed report was issued separately as the COVID 19 thematic report; \nSummary of key findings", "metadata": {"headings": [{"headings_0": {"content": "to", "page": 18, "level": 3}}, [{"headings_0": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "to", "page": 18, "level": 3}}], [{"headings_0": {"content": "ii)", "page": 24, "level": 3}}], [{"headings_0": {"content": "ii)", "page": 24, "level": 3}}], [{"headings_0": {"content": "iii)", "page": 24, "level": 3}}], [{"headings_0": {"content": "iii)", "page": 24, "level": 3}}], [{"headings_0": {"content": "iv)", "page": 24, "level": 3}}], [{"headings_0": {"content": "iv)", "page": 24, "level": 3}}], [{"headings_0": {"content": "v)", "page": 24, "level": 3}}], [{"headings_0": {"content": "v)", "page": 24, "level": 3}}], [{"headings_0": {"content": "vii)", "page": 24, "level": 3}}], [{"headings_0": {"content": "vii)", "page": 24, "level": 3}}], [{"headings_0": {"content": "vii)", "page": 24, "level": 3}}], [{"headings_0": {"content": "vii)", "page": 24, "level": 3}}]], "page": 23, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- USD 345million received by GoU in respect of support to Bank of Uganda for Balance of Payment was confirmed received and banked intact in Citi bank New York to enhance", "metadata": {"headings": [{"headings_0": {"content": "vii)", "page": 24, "level": 3}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nthe Country\u2019s foreign reserves.", "metadata": {"headings": [{"headings_0": {"content": "vii)", "page": 24, "level": 3}}, [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}]], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A total of UGX 676Bn was allocated and disbursed to various MDAs to settle domestic arrears with a view of improving liquidity within the local business community. I noted that 90% of funds used appropriately for the intended puropose; however, I noted diversion of funds to pay for unrelated expenditure worth UGX 4.897Bn (0.7%), unsupported domestic arrears of UGX 27.38Bn(4%), and Payment for contested/rejected domestic arrears of UGX.1.245Bn(0.2%). I also noted that UGX 33.8Bn (5%) was used to settle international obligations thus did not contribute to the stated objective since the funds were externalised.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UGX 260Bn allocated for the Emyooga programme was disbursed to Microfinance Support Centre with a goal of transforming household incomes by increasing employment opportunities and access to financial services to the rural areas. Audit confirmed that UGX 219.40Bn (84%) had so far been disbursed to 6,326 EMYOOGA SACCOs. It was, however, noted that the SACCOs were in the process of obtaining operational licenses; no MoUs had been entered into between the disbursing entity and the beneficiary SACCOs; UGX.34,716,666,049 (1.3%), though disbursed, remained un- accessed by the beneficiary SACCO.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n12", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}]], "page": 24, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A total of UGX.56.8Bn was disbursed to MSc to increase the funds available for on- lending to different businesses. I noted that MSc lacked capacity at zonal offices to appraise loans which was also manifested in the unbalanced approach for loan appraisals. A total of UGX 13b (23%) was disbursed to applicants without MSC finalising the perfection of securities for the collaterals. UGX.2.5Bn (4%) was irregularly advanced to applicants contrary to the credit policy. A total of UGX 3.149Bn (6%) was advanced to applicants with no collateral.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}]], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A total of UGX.31.033Bn was disbursed to the Ministry of Science Technology and innovation to support 23 selected projects of scientists and innovators engaged in CoVID-I9 scientific research, including the procurement of specialized machinery and equipment, development of vaccines, drug diagnostics, and other operational costs. The funds were divided into UGX.15.787Bn for purchase of Equipment and UGX.15.245Bn for Operational Costs. An MOU was entered with Presidential Scientific Initiative on Epidemics (PRESIDE) to provide technical and administrative oversight at an operational level. It was noted that most projects were progressing well. It was also noted that due to the general weaknesses identified, there was a need to provide more guidance to the beneficiaries on how to account for Government funds.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of UGX 558.68Bn appropriated, 531.8Bn was disbursed to Uganda Development Bank for recapitalization, leaving UGX 26.87Bn unremitted by the Ministry of Finance and Economic Development. From the amount disbursed, funds worth UGX 234bn had been paid out to various beneficiaries; by the time of the audit, the balance of UGX 292.66Bn was still deposited in commercial banks.\n- Of the amounts paid out, UGX95bn was sent to financial institutions and SACCOs following MoUs entered into by UDB and the financial Institutions, for the latter to on lend to stated beneficiaries.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Euros 1,602,370 (equivalent to UGX.7,136,910,000) received by UDBL from the European Union for the Tourism Sector. As at 10 th June 2021, 25 applications worth UGX 9.55 Bn had been approved, and grant disbursements worth UGX 4.34 Bn. had been processed to 14 projects.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Furthermore, the Ministry of Finance and Economic Development disbursed UGX.126.9Bn to Uganda Development Corporation, to finance projects aimed at supporting the private sector to avert the effects of Covid-19. I noted that the capitalisation grants to UDC are assigned to specific projects thereby nullifying the internal appraisal processes of UDC. 54% of the funds remained unutilised as the projects were not ready for investment.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UGX 253.59bn was released and received by the Ministry of Health. MoH used the money to procure medical supplies, 282 motor vehicles, pay allowances to medical workers, masks, intensive care equipment and build modular houses at 6 border points. All the planned activities were undertaken amidst many challenges. I noted a diversion of funds totalling UGX 7.98Bn. Though funds were paid for the acquisition of vaccines, there were delays in the delivery of the vaccines due to the global demand. There was a delay in the installation of intensive care equipment in Gulu, Mbarara, Bombo, and Lacor hospitals due to building inadequacies.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Whereas medical workers requested to be given UGX.150,000 per day as risk allowance, this was not possible and they were instead paid UGX.80,000 per day. They made a", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "13 \nrequest to parliament to have this amount exempted from taxes, but the issue was never resolved. In the meantime, UGX.2.2Bn meant for PAYE was not deducted from the allowances paid to medical workers in the period under review. \nKey Recommendations", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}]], "page": 25, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Management should ensure that compensating controls are put in place in times where conventional controls cannot be implemented.\n- Sensitisation of private individuals and organisations to whom public resources are entrusted should be done prior to disbursement of the funds.\n- The PS/ST should clearly communicate the intentions of given initiatives before funds are disbursed to implementing agencies to avoid a mismatch between the intended objectives and actual outputs.\n- Government entities and projects should be assessed for capacity to implement given tasks before funds are disbursed to them.", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}], "page": 26, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n2.1.3. \nCompensations/Acquisition of Right of Way for Selected Transmission Lines Projects \nThe Government, through the Ministry of Energy and Minerals Development, is responsible for provision of policy guidance in the development and exploitation of the energy resources, creation of an enabling environment to attract investment, and provision and utilization of energy resources. \nCurrently, UETCL\u2019s network consists of 2,989.2Km of high voltage lines distributed as; 1,008km of 220kv, 1,946km of 132kv and 35km of 66kv , with 25 substations with a total transformation capacity of 2829.5 MVA. However, this is still low, given that Uganda still has one of the lowest per capita electricity consumption in the world with 215 KWh per capita per year, given that the Sub-Saharan Africa\u2019s average is 552Kwh 2 . \nGovernment has spent significant amounts in compensation of Projected Affected Persons. In a period of 5 years, financial years between 2016/17 to 2019/20, a total of UGX.564.57Bn has been spent in compensations of PAPs. \nThe delays in undertaking the construction of the transmission lines has been largely attributed to inadequacies in the compensation of Project Affected Persons. The challenges \nfaced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a \nnumber of projects in the Energy Sector. \nOwing to concerns over the progress of the implementation of the transmission \ninfrastructure under UETCL, the Office of the Auditor General undertook an audit on the \ncompensation of PAPs under selected transmission line projects. The overall objective of the audit was to ascertain whether the compensation process of the Project Affected Persons (PAPs) was implemented in accordance with the Compensation Guidelines and other Government Legal Frameworks to enable efficient and effective service delivery. \nThe scope of the audit included the Grid Extension and Reinforcement Project (GERP) and the Mputa Transmission lines. The following are the summary of the key findings and recommendations made, and the details are in the thematic report on compensations; \n2 Uganda energy situation-energypedia. \n14 \nSummary of Key Findings:", "metadata": {"headings": [{"headings_0": {"content": "the Country\u2019s foreign reserves.", "page": 24, "level": 2}}, [{"headings_0": {"content": "2.1.3.", "page": 26, "level": 2}}], [{"headings_0": {"content": "2.1.3.", "page": 26, "level": 2}}], [{"headings_0": {"content": "2.1.3.", "page": 26, "level": 2}}], [{"headings_0": {"content": "2.1.3.", "page": 26, "level": 2}}], [{"headings_0": {"content": "2.1.3.", "page": 26, "level": 2}}], [{"headings_0": {"content": "2.1.3.", "page": 26, "level": 2}}], [{"headings_0": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}], [{"headings_0": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}], [{"headings_0": {"content": "faced in \u201cAcquisition of the Right of Way (ROW)\u201d have led to delayed implementation of a", "page": 26, "level": 2}}], [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}]], "page": 26, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- 56% of the PAPs for GERP and Mputa projects were not properly identified, and this resulted in a mismatch between the number of PAPs appearing on the payment files and the survey reports and Valuation Reports prepared by the Chief Government Valuer.", "metadata": {"headings": [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}, [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}]], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The valuation process was marred with a number of irregularities, which included; the use of un-updated district compensation rates; and unverified legal interests in the land; resulting in unnecessary revaluations and ligation which in turn delayed the RAP processes, thus affecting timely project completion.", "metadata": {"headings": [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The budgeting, disbursement, and absorption of compensation funds were not properly", "metadata": {"headings": [{"headings_0": {"content": "infrastructure under UETCL, the Office of the Auditor General undertook an audit on the", "page": 26, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation \nReports are supposed to guide the budgeting for compensations, management prepared budget estimates which were not supported, this resulted in over budgeting to the tune of UGX.111.3Bn.", "metadata": {"headings": [{"headings_0": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}, [{"headings_0": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}]], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- I noted that of the released compensation amount of UGX.21.5Bn for both GERP and Mputa Projects, only UGX.5.86Bn (27%) was paid to PAPs, thus resulting in unspent funds to the tune of UGX.15.64Bn (73%). This mostly affected the GERP Project which had UGX.13.17Bn not utilized, while Mputa had UGX.1.66Bn.", "metadata": {"headings": [{"headings_0": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I also noted significant delays in compensation of PAPs. 1,109 PAPs (52.2%) for Mputa and 821 (35%) for the GERP Transmission Line remained unpaid by the time of concluding the audit (November, 2021). This was mainly caused by outstanding", "metadata": {"headings": [{"headings_0": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \ngrievances whereby 52% and 15% of the grievances remained unresolved for GERP and \nMputa Projects, respectively. Relatedly, Compensations in kind also delayed whereby out of 149 PAPs identified, only 93 were resettled, leaving 56 PAPs not resettled. \n", "metadata": {"headings": [{"headings_0": {"content": "managed. There are seemingly budget slacks. Although the Survey and Valuation", "page": 27, "level": 1}}, [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}], [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}], [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}]], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted a number of inadequacies in the construction of the resettlement houses which included; irregular payments to contractors, delayed progress of works, discrepancies in drawing specifications and BOQs, poor materials used for construction, and a number of defects which were not rectified.", "metadata": {"headings": [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Key Recommendations", "metadata": {"headings": [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Management should always ensure that the RAP consultants thoroughly validate the preliminary information obtained during social survey and valuation processes, to enable", "metadata": {"headings": [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \naccurate justification of PAPs", "metadata": {"headings": [{"headings_0": {"content": "grievances whereby 52% and 15% of the grievances remained unresolved for GERP and", "page": 27, "level": 1}}, [{"headings_0": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}]], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The District Land Boards should ensure compensation rates are regularly updated and communicated to the CGV, to enable appropriate valuation of the land and properties.\n- Management should streamline its RAP processes, including proper identification of PAPs, clear valuation processes, and timely submission of PAP documentation, among others.\n- Management should ensure proper supervision and monitoring of construction works.", "metadata": {"headings": [{"headings_0": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n15 \nEmphasis of Matter \nWithout qualifying my opinion, I draw attention to the following matters in the consolidated \nfinancial statements that in my judgment are of such importance and fundamental to users\u2019 \nunderstanding of the financial statements;", "metadata": {"headings": [{"headings_0": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}, [{"headings_0": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "accurate justification of PAPs", "page": 27, "level": 1}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}]], "page": 27, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Government Loans (Borrowings) \u2013 UGX 69.6Tn", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nAs disclosed in the statement of financial performance, the government Loans have increased from UGX.56.9Tn, in 2020 to UGX UGX 69.6Tn in 2021 constituting an increase of UGX 12,718Bn (22.4%) increase. This position reflects the country\u2019s increased borrowing to combat the effects of the Covid19 pandemic.", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}]], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Domestic arrears \u2013 UGX 4.65Tn", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nAs disclosed in the statement of financial performance, the domestic arrears have increased from UGX.3.83Tn in 2020 to UGX 4.65Tn in 2021 constituting a 21% increase. The amount represents 9% of the revised budget of government of Uganda for the financial year 2020/21. This is an indication of the failed commitment control system. The growth trend appears unsustainable and on the rise. This could also be as a result of approving supplementary budgets with no matching funding. \nThe PS/ST explained that government is currently implementing a Domestic Arrears Strategy to clear significant amounts of the verified arrears. \n", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}]], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Contingent Liabilities \u2013 UGX 160Tn", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "As disclosed in the statement of contingent liabilities, Government contingent liabilities have increased to UGX160Tn up from UGX.11.5Tn reported in the previous year, representing a 1,290% increase. Most of the contigent Liabilities are arising out of court awards and compensations. The trend continues to appear unsustainable in the event that a significant percentage crystallises into liabilities. \n", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}]], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Classified Expenditure \u2013 UGX 840.8 Bn", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "As disclosed under note 8, a total of UGX 840.8 Bn relates to classified expenditure. In compliance with Section 24 of the Public Finance Management Act, 2015 (Classified Expenditure), this expenditure is to be audited separately and a separate audit report issued. \n", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}, [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}]], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Non-Consolidation of Subventions", "metadata": {"headings": [{"headings_0": {"content": "financial statements that in my judgment are of such importance and fundamental to users\u2019", "page": 28, "level": 2}}], "page": 28, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": [["Nature of Tax", "Total Amount written off (UGX)"], ["Value Added tax (VAT)", "348,986,568,013"], ["Stamp Duty 8,460,910,000", null], ["Pay As You Earn (PAYE)", "158,293,699,210"], ["Import Duty 98,569,989,826", null], ["Excise Duty", "52,685,114,511"], ["Income Tax 114,133,374,978", null], ["Withholding Tax", "28,604,598,593"], ["Total 809,734,255,131", null]], "metadata": {"headings": [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}], "page": 31, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1"], "type": "table"}}, {"content": "It has however been noted, that one year later, a total of UGX.212.747Bn has already been accumulated at the Ministry of Finance, Planning and Economic Development in tax arrears as 30 th June 2021. The occurrence is a manifestation that a tax write off is not the solution for the issue at hand. The tax arrears build up continues to negatively affect the revenue collection efforts of Uganda Revenue Authority. \nManagement responded that the writing off of tax arrears by the minister was consistent with the law, specifically Article 152 (1) of the Constitution and Section 40 of the Tax procedures Code Act. This discretionary power is useful because it addresses strategic circumstances which merit government interventions that were not provided for in the tax acts. Exercise of this discretion by the minister is reported to parliament every end of the quarter. \nI advised the Accounting Officer to review the practice and come up with a lasting solution in respect of companies to which tax incentives and other benefits a granted. \n2.1.5. \nAudit of public debt \na) Public Debt Portfolio Analysis \nThe reported total public debt as at 30 th June, 2021 stood at UGX.69,600 Bn, of which Domestic Debt Stock was UGX.25,288 Bn and the External Debt Stock was valued at UGX.44,312 Bn. This is an increase of UGX.13,429 Bn, equivalent to 23.9% when compared to the debt stock of UGX.56,892 Bn reported as at 30 th June 2020. The table below shows the details; \n19 \nTable 5: Debt portfolio analysis", "metadata": {"headings": [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}, [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}], [{"headings_0": {"content": "Due to Government\u2019s failure to provide the balance of the required land, the Ministry of", "page": 30, "level": 2}}], [{"headings_0": {"content": "2.1.5.", "page": 31, "level": 2}}], [{"headings_0": {"content": "2.1.5.", "page": 31, "level": 2}}], [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}], [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}], [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}], [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}]], "page": 31, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Financial year", "Domestic debt (UGX Bn)", "Foreign debt (UGX", "Total (UGX Bn)", "%"], ["ended", null, "Bn)", null, "change"], ["June 21", "25,288", "44,312", "69,600", "23.90%"], ["June 20 17,975 38,196 56,171 23.50%", null, null, null, null], ["June 19", "15,221", "30,905", "46,126", "11.10%"], ["June 18 13,059 28,386 41,445 23.60%", null, null, null, null], ["June 17", "11,407", "22,102", "33,509", ""]], "metadata": {"headings": [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "Source: Audited financial statements of Vote 130 \nFrom the above, I noted that there was a consistent increase in the total debt and from financial year 19/20 to 20/21, there was an increment of UGX. 13,429Bn (23.90%). The net increase in the debt is due to increased borrowing from both the domestic and external sources, with domestic debt accounting for a higher increase. \nPublic debt is continuously on the rise, a fact that is attributed to persistent budget deficits (mismatch of government revenue and expenditure), rollover of liquidity papers, new borrowings for various development projects and foreign exchange loss arising from the depreciation of Ugandan Shilling against stronger currencies. The graph below illustrates the trend of public debt stock by type over the past five years; \nFigure 2: The trend of public debt \n80,000 \n70,000 60,000 \n50,000 \nDomestic debt (UGX Bn) \n40,000 \nForeign debt (UGX Bn) \n30,000 Total (UGX Bn) \n20,000 10,000 \n0 \nJun-17 Jun-18 Jun-19 Jun-20 Jun-21 \nAlthough government has developed a domestic revenue mobilisation strategy, this appears not to be in harmony with the spending, raising concerns of sustainability. \nManagement indicated that revenue Mobilization had recently been affected by reduced economic activity as a result of restrictions imposed to slowdown the spread of COVID 19. COVID 19 has also led to additional expenditure pressures, which necessitated increased borrowing. Going forward, Government will focus on reducing expenditure and increasing revenues in a bid to bridge the fiscal gap and reduce the rate of debt accumulation. These commitments have been clearly spelt out in the Charter for Fiscal Responsibility, which is \n20 \nawaiting Parliamentary approval. Further to the above, Government is finalising the Public Investment Financing Strategy (PIFS) that will improve alignment of government programmes and projects to suitable financing options. The Strategy will in turn enhance the efforts in resources allocation, utilisation and address issues on debt sustainability. \nI await implementation of the Charter for Fiscal Responsibility. b) Assessment of debt sustainability", "metadata": {"headings": [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}, [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}], [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}], [{"headings_0": {"content": "a) Public Debt Portfolio Analysis", "page": 31, "level": 2}}], [{"headings_0": {"content": "80,000", "page": 32, "level": 4}}], [{"headings_0": {"content": "70,000 60,000", "page": 32, "level": 4}}], [{"headings_0": {"content": "50,000", "page": 32, "level": 4}}], [{"headings_0": {"content": "50,000", "page": 32, "level": 4}}], [{"headings_0": {"content": "40,000", "page": 32, "level": 4}}], [{"headings_0": {"content": "40,000", "page": 32, "level": 4}}], [{"headings_0": {"content": "30,000 Total (UGX Bn)", "page": 32, "level": 4}}], [{"headings_0": {"content": "20,000 10,000", "page": 32, "level": 4}}], [{"headings_0": {"content": "20,000 10,000", "page": 32, "level": 4}}], [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}], [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}], [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}], [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}], [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}], [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}]], "page": 32, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Debt to GDP Ratio", "metadata": {"headings": [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Debt to GDP ratios is a measure that compares what a country owes (total debt) and what it \nproduces (manufactures or a service). The ratio reliably indicates a country\u2019s ability to pay \nback its debt. A high debt-to-GDP ratio may make it more difficult for a country to pay both internal and external debts and may lead creditors to seek higher interest rates when lending due to the low credit rating of the country that pushes its lending risk high. \nThough the IMF has recommended 50% as the point of safety, many developed countries have gone up to 200%. However, according to the IMF, the developing countries are more prone to economic shocks and exchange rate risk, thus advising on a 50% threshold. \nA review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the \nyear under review. The graph below illustrates the movement; \nFigure 3: Debt to GDP ratio 160 \n140 \n120 \n100 \nTotal Debt(UGX Bn) \n80 \n60 \n40 29.0 31.0 34.0 35.0 \n20 \n- \nGDP \n47.0 \nDebt to GDP Ratio 41.0 \nJun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021 \nFrom the above, it can be seen that though Uganda\u2019s GDP has been increasing over the years since 2013/14, its debt position has also increased. The rate of increase of debt is higher than the rate of increment in the GDP levels, which creates a risk of reaching unsustainable levels in the future. \nManagement attributed the increased debt levels to Government\u2019s ambitious infrastructure \nprogram under National Development Plans I and II that were particularly focused on the energy (dams and power lines) and transport sectors. In addition, the need to expedite \n21 \ncommercial production of our oil resources has also necessitated the development of infrastructure which will aid the production process. \nIt was also indicated that the onset of the COVID-19 pandemic had led to a contraction in economic activity and shortfalls in domestic revenue collections while at the same time creating additional spending areas to mitigate the pandemic impact. To maintain debt at sustainable levels, Government had embarked on a fiscal consolidation strategy aimed at accelerating implementation of the Domestic Revenue Mobilisation Strategy and expenditure rationalisation. \nI advised the PSST to consider exploring ways of reducing dependence on debt and expediting the implementation of strategies to enhance revenue generation for the country and/or reducing/rationalising government expenditures.", "metadata": {"headings": [{"headings_0": {"content": "Jun-17 Jun-18 Jun-19 Jun-20 Jun-21", "page": 32, "level": 4}}, [{"headings_0": {"content": "produces (manufactures or a service). The ratio reliably indicates a country\u2019s ability to pay", "page": 33, "level": 2}}], [{"headings_0": {"content": "produces (manufactures or a service). The ratio reliably indicates a country\u2019s ability to pay", "page": 33, "level": 2}}], [{"headings_0": {"content": "produces (manufactures or a service). The ratio reliably indicates a country\u2019s ability to pay", "page": 33, "level": 2}}], [{"headings_0": {"content": "A review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the", "page": 33, "level": 2}}], [{"headings_0": {"content": "A review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the", "page": 33, "level": 2}}], [{"headings_0": {"content": "A review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the", "page": 33, "level": 2}}], [{"headings_0": {"content": "A review of Uganda\u2019s Debt to GDP revealed a 6% increase from 41% last year to 47% in the", "page": 33, "level": 2}}], [{"headings_0": {"content": "Total Debt(UGX Bn)", "page": 33, "level": 4}}], [{"headings_0": {"content": "Total Debt(UGX Bn)", "page": 33, "level": 4}}], [{"headings_0": {"content": "Total Debt(UGX Bn)", "page": 33, "level": 4}}], [{"headings_0": {"content": "40 29.0 31.0 34.0 35.0", "page": 33, "level": 4}}], [{"headings_0": {"content": "40 29.0 31.0 34.0 35.0", "page": 33, "level": 4}}], [{"headings_0": {"content": "40 29.0 31.0 34.0 35.0", "page": 33, "level": 4}}], [{"headings_0": {"content": "GDP", "page": 33, "level": 4}}], [{"headings_0": {"content": "GDP", "page": 33, "level": 4}}], [{"headings_0": {"content": "GDP", "page": 33, "level": 4}}], [{"headings_0": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}], [{"headings_0": {"content": "Jun 2016 Jun 2017 Jun 2018 Jun 2019 Jun 2020 Jun 2021", "page": 33, "level": 4}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}]], "page": 33, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Interest to Total revenue ratio", "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}], "page": 34, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nThis benchmark shows the proportion of the domestic revenue that goes into servicing domestic interest costs. Since donor grants are inherently subject to uncertainty, the interest cost of domestic debt is considered in relation to the domestically-raised component of the budget only. Government set the ceiling to be 12.5% in its debt strategy. The table 6 below shows the assessment of the benchmark over the years; \nTable 6: Total revenue ratio", "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}]], "page": 34, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Financial year", "Total domestic", "Total Interest - UGX", "% of Interest to", "Benchmark"], ["", "Revenue - UGX", null, "revenue", null], ["2020/21", "20,199,013,110,066", "3,118,535,556,062", "15.4", "< 12.5"], ["2019/20 17,453,981,414,553 2,475,531,497,733 14.2 < 12.5", null, null, null, null], ["2018/19", "17,128,743,726,614", "2,005,380,900,988", "11.71", "< 12.5"], ["2017/18 15,219,588,786,381 1,937,371,886,367 12.73 < 12.5", null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}], "page": 34, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "It has been established that the interest to revenue benchmark has been breached as evidenced above. Almost 15% of the revenue being collected is going into servicing interest payments. This is gradually reducing the funds available for funding other critical government expenditures, given that 25% goes to salaries and wages. \nManagement indicated that efforts were being made to reduce the interest to revenue ratio by taking steps to reduce the level of domestic borrowing a view to attaining the operational ceiling of 1% of GDP and also working to increase domestic revenues through the operationalization of the Domestic Revenue Mobilization Strategy (DRMS). The implementation of the DRMS had stalled in the last two years due to the pandemic-induced shocks. The DRMS aims to increase to tax to GDP ratio by 0.5 percentage points every year largely through the improvement of revenue administration. \nI advised the PS/ST to implement strategies of reducing the growth of interest expenditures at the same time increasing revenue mobilisation. \n", "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}], [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}]], "page": 34, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Low Tax to GDP ratio", "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}], "page": 34, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Section 2.1 (i) Public Debt and other Financial Liabilities Management Framework for the FY2018/19 to FY2022/23 provides that the Government of Uganda shall work towards 22 \nraising its tax-to-GDP ratio to the Sub-Sahara Africa\u2019s (SSA) average of 15.1% as part of Uganda\u2019s Financing Strategy to limit on borrowing. \nAudit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and \nnoted that from the start of the implementation of the framework in the FY2018/19, Uganda had made an improvement and currently stands at 13%; however, more strides have to be made to make it to 15% and more. Refer to the table 7 below; \nTable 7: Tax to GDP ratio", "metadata": {"headings": [{"headings_0": {"content": "Management attributed the increased debt levels to Government\u2019s ambitious infrastructure", "page": 33, "level": 2}}, [{"headings_0": {"content": "raising its tax-to-GDP ratio to the Sub-Sahara Africa\u2019s (SSA) average of 15.1% as part of Uganda\u2019s Financing Strategy to limit on borrowing.", "page": 35, "level": 2}}], [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}], [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}], [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}]], "page": 34, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Financial year", "GDP at Current Prices", "TAX collections", "Tax/GDP"], ["", "(UGX) Billions", "(UGX) Billions", null], ["2020/21", "147,962", "18,594", "13%"], ["2019/20 139,689 16,042 11%", null, null, null], ["2018/19", "132,090", "16,146", "12%"]], "metadata": {"headings": [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}], "page": 35, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "The continued failure to collect sufficient revenue will imply more borrowing and creates a risk that the Country may not achieve the World Bank Sustainable Development Goals by 2030.", "metadata": {"headings": [{"headings_0": {"content": "Audit reviewed the Country\u2019s tax collections and its Gross Domestic Product (GDP) and", "page": 35, "level": 2}}], "page": 35, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The Accounting Officer responded that the conclusion of the 15-year Interest Rate Swap transaction in June 2016 was a risk mitigating action against possible increases in US$ LIBOR which was made on the basis of historical US$ LIBOR rates. It could not take into account the ramifications of the CoVID-19 pandemic and the associated interventionist changes in US Monetary policy; as they were not evident in 2016. Current Indications are that restoration of market based interest rates will occur in the near future and hence pointing to the necessity to keep the SWAP in place as insurance against likely future interest rate increases. Government is currently undertaking a midterm review of the Public Debt Management Framework (PDMF) 2018. The proposed measure will therefore be considered and appropriate policy actions will be instituted for the remaining period of the framework and the longer term. \nI advised management is to develop a policy on management of interest rate risk to minimise the exposure. \ne) Failed on-lending scheme \nGovernment of Uganda has over the years, secured funds for on-lending to various ministries, departments and agencies to undertake various projects. Whereas MDAs signed \nthe on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay \nthe on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were \nfound to be compliant with the repayment of the loans. \n24 \nIt was further noted that; \n", "metadata": {"headings": [{"headings_0": {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "page": 36, "level": 2}}, [{"headings_0": {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "page": 36, "level": 2}}], [{"headings_0": {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "page": 36, "level": 2}}], [{"headings_0": {"content": "not give sufficient guidance on the use of instruments such as \u2018SWAPs\u2019 in risk management.", "page": 36, "level": 2}}], [{"headings_0": {"content": "the on-lent loan agreements, there was an inability by some of the MDA\u2019s to actually re-pay", "page": 36, "level": 2}}], [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}]], "page": 36, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- There were no criteria in place to assess which MDAs to lend to.\n- There was no record of assessment/ feasibility studies undertaken to establish whether the choice of on-lent financing was the best modality to finance the infrastructure projects.\n- I noted that Government used non-concessional loans for on-lending, which attracted higher interest rates and shorter grace periods for the loan repayments as compared to the concessional loans which made it very costly. Some MDAs have had challenges with absorption and thus repayment.", "metadata": {"headings": [{"headings_0": {"content": "the on-lent loans. It was oserved that only Four(4) out of the Thirteen(13) MDA\u2019s were", "page": 36, "level": 2}}], "page": 37, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- A sample of the cases reviewed revealed that a total of UGX.24,734,116,888 is outstanding as a result of decisions of the courts for refund of proceeds of corrupt practices but these are not provided for in the consolidated accounts as receivable.", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- In my 2019/20 report for the DPP, I also observed that a total of UGX.18,940,206,109 remained uncollected in spite of the setup of a department within the Office of the DPP responsible for enforcing the recovery of compensation orders.", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The gaps in the collection were partly attributed to the lack of a clear mandate to the DPP, especially in so far as recoveries of compensation would require civil processes which are outside the mandate of the criminal mandate of the Office of the DPP.", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Whereas the mandate of recovery would be a reserve of the Attorney General who is vested with the mandate to litigate civil matters, it was noted that the ODDP has in place a unit for recovery of funds arising out of prosecutions in DPP while IGG also has another.", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nFailure to enforce the recovery of court orders, denies government the funds that should have been generated and undermine the objective of recovering losses incurred by the government due to corrupt practices. \nIt is therefore important that the Government comes up with a regulatory framework that addresses the inadequate legislation on recovery of proceeds of crime, provide for: civil asset recovery, detailed procedures in conviction based recovery, asset management and \n26 \ndisposal, recovery of consequential benefits, and how to apply the recovered proceeds, among others. \nThe Accounting Officer responded that the Ministry had initiated consultations with the Office of DPP, IGG and Attorney General for establishment of comprehensive procedures for recovery of proceeds of crime, provide for civil asset recovery, provide for detailed guidelines in conviction based recovery, provide for asset management and disposal, recovery of consequential benefits including application of the recovered proceeds. \nI await the outcome of the consultations. \n2.1.7. \nAudit of public investments \na) Failure to Appraise Projects before funding - UGX.643,434Bn \nSection 3.18 of the Development Committee Guidelines provides that assessment of the project viability shall be measured by the following key indicators including: The Financial Cost Benefit Ratio (CBR), the financial Net Present Value (NPV) and the financial Internal Rate of Return (IRR). \nThe guide further requires that all new Projects requiring funding should undergo four levels of approvals before they can be admitted into the Public Investment Plan (PIP). The four levels include; preparing a project concept in line with NDP (II), preparing a Project Profile demonstrating Key results, undertaking a prefeasibility study and undertaking feasibility study. \nReview of the Public Investment Plan for the year ended 30 th /06/2021, revealed that out of a sample of 371 projects, 245 projects (66%) with total Project values of UGX.643,434 Bn did not have feasibility studies undertaken. \nFailure to conduct feasibility studies may lead to the projects failing to achieve the desired project output, duplication or conflicting Government interventions thus causing wasteful expenditure. \nManagement committed that going forward all projects will be appraised before inclusion in the PIP. In addition, the DC guidelines were being revised to take into consideration other exceptions, such as social projects, IT solutions among others. \nI await the outcome of the commitment. \nb) Non-compliance with the 70% Capital Threshold", "metadata": {"headings": [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}, [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], [{"headings_0": {"content": "government\u2019s investments in IT systems will be achieved.", "page": 38, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}], [{"headings_0": {"content": "2.1.7.", "page": 39, "level": 2}}], [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}]], "page": 38, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Section 2.2: Scope and Institutional arrangements of the Development Committee guidelines requires that Public investments admissible into the PIP shall be limited to public spending to acquire or establish physical assets necessary to facilitate production and delivery of economic, social and administrative services. Interventions that can be undertaken in the recurrent budget shall not be accommodated in the PIP. In this regard, for a project to be admitted into the PIP, its capital component shall account for at least 70% of the total project cost. It further states that interventions that can be undertaken in the recurrent budget shall not be accommodated in the PIP. \n27 \nAudit reviewed the Public Investment Plan for the year ending 30 th June 2021 and noted that 125 projects in the PIP with total budgets of UGX.4,410Bn did not meet the requirement of 70% capital intervention. The aggregate project expenditure on administrative functions was 75% while the aggregate capital expenditure requirements were only 25% of the entire total budget. I noted that some projects had 100% administrative expenditure. Refer to the table 8 below; \nTable 8 : Noncompliance with the 70% capital threshold", "metadata": {"headings": [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}, [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}]], "page": 39, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["No. of projects", "Total Budget -", "Capital", "Administrative", "% of"], ["", "UGX", "Expenditure - UGX", "expenditure - UGX", "administrative"], [null, "", null, null, "expenditure"], ["125", "4,410,809,884", "1,087,332,424", "3,323,477,460", "75%"]], "metadata": {"headings": [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}], "page": 40, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "If this remains unchecked by the development committee, the government runs a risk of spending project funds on recurrent expenditure and thus failing to meet the targets set in \nthe National Development Plan III. \nIn addition, it was noted that the Development Committee does not consider software and intellectual properties as assets. This implies that any innovations in the ICT sector will continue to be unfunded, despite their potential to generative substantial returns. \nManagement explained that Section 2.2 applies to new projects to be admitted into the PIP and the budget. This requirement is fully adhered to by the DC but as projects continue into execution, recurrent costs can go higher, depending on the requirements between OPEX and CAPEX. The current DC guidelines are currently under review to provide for among others social projects, Grants, software investments and intangible assets, among others. \nI advised the PS/ST to review the guidelines taking into account the project lifecycle and classification of assets to include intangible assets. \nc) Overstay of projects in the PIP - UGX.39,011Bn \nThe Public Investment Management Reform Strategy provides that projects are supposed to be delivered on budget and on time in order to achieve the desired goals and objectives. \nAudit observed that in the sample of 371 projects, 342 projects (92.2%) with budgets totalling to UGX.39,011Bn had gone past their planned exit periods, that date as far back as the FY2010/11, with some projects having been extended for more than 12 years. Audit noted that the projects continued to receive DC approval for continued stay on the PIP It was noted that only 40% of the projects in the Public Investment Plan (PIP) were still within their expected time period. \nThis was attributed to lack of adequate planning and readiness, delays in procurements, late acquisition of right of way, poor contract management and inadequate capacity to implement and evaluate ongoing projects, and unauthorized change in the scope, among others. \n28 \nThis has caused delays in the completion of key projects, cost overruns and high commitment fees on foreign debt on account of low absorption and failure to complete projects on time.", "metadata": {"headings": [{"headings_0": {"content": "b) Non-compliance with the 70% Capital Threshold", "page": 39, "level": 2}}, [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}]], "page": 40, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "Management attributed the overstay to implementation challenges which often lead to extensions in the PIP. Management also informed me that the Ministry had now adopted the resolution not to admit any project into the PIP and budget before completion of all required feasibility studies and ensuring that challenges that often lead to project extensions such as delays in acquisition of right of way, Environmental and Social impact assessment, among others are fulfilled before project commencement. In addition, the Ministry\u2019s leadership had directed that all old projects which continue to face implementation challenges either be cancelled and or renegotiated with the respective funders. \nI advised the PS/ST to devise a mechanism to improve the efficiency with which projects are implemented by ensuring that the causes identified above are addressed. \nd) Under absorption of funds by projects \nAccording to the approved Budget estimates of the FY2020/21, the Resource Envelope of Financial year 2020/21 approved by Parliament totals UGX.45,493.7Bn of which External Financing consists of Project Support of UGX.9,515.3Bn and General Budget Support \nUGX.2,906.7Bn. \nAudit obtained and reviewed cash inflows and expenditures of externally funded projects and noted poor absorption/performance of externally funded projects. Out of UGX.9,515.3Bn that was appropriated by Parliament, only UGX.4,516.5Bn (47%) was released. Relatedly, absorption of externally funded projects further declined in the year under audit. Out of the UGX.4,516.5Bn Disbursed for donor-funded projects, only UGX.2,937Bn was spent, representing 65.0% as compared to the 71% observed in the FY2019/20. The table 9 refers to; \nTable 9: Absorption of fund", "metadata": {"headings": [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}, [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], [{"headings_0": {"content": "the National Development Plan III.", "page": 40, "level": 2}}], [{"headings_0": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}], [{"headings_0": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}]], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["External", "Release", "Expenditure", "Release", "Expenditure", "%of funds", "%of funds"], ["financing", "(UGX) Bn", "(UGX)Bn", "Variance", "Variance", "not", "not"], ["Budget", null, null, "(UGX) Bn", "(UGX) Bn", "released", "Absorbed"], ["(UGX)Bn", null, null, null, null, "(UGX) Bn", "(UGX) Bn"], ["9,515.30", "4,516.50", "2,937", "4,998.80", "1,579.50", "53%", "35%"]], "metadata": {"headings": [{"headings_0": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5", "column_6"], "type": "table"}}, {"content": "The under absorption of externally funded projects in the FY2020/21 was mainly due to the following; \n", "metadata": {"headings": [{"headings_0": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}, [{"headings_0": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}]], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Implementation of unready projects, unrealistic conditions precedent to disbursements of funds which constrains decision making during project execution;\n- Covid-19 restrictions that affected implementation of projects\n- Delayed land acquisition;\n- Failure to quantify counterpart funding requirements at the time of project appraisal", "metadata": {"headings": [{"headings_0": {"content": "UGX.2,906.7Bn.", "page": 41, "level": 2}}], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "and; \n", "metadata": {"headings": [{"headings_0": {"content": "and;", "page": 41, "level": 2}}, [{"headings_0": {"content": "and;", "page": 41, "level": 2}}]], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- Cumbersome procurement processes as well as failure to undertake a comprehensive appraisal of projects.", "metadata": {"headings": [{"headings_0": {"content": "and;", "page": 41, "level": 2}}], "page": 41, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "My objectives are to obtain reasonable assurance about whether the consolidated financial statements of government as a whole are free from material misstatement, whether due to fraud or error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is a high level of assurance, but is not a guarantee that an audit conducted in accordance with ISSAIs will always detect a material misstatement when it exists. Misstatements can arise from fraud or error and are considered material if, individually or in the aggregate, they could reasonably be expected to influence the economic decisions of users taken on the basis of these financial statements. \nAs part of an audit in accordance with ISSAIs, I exercise professional judgment and maintain professional skepticism throughout the audit. I also;", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}, [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}]], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Identify and assess the risks of material misstatement of the consolidated financial statements, whether due to fraud or error, design and perform audit procedures responsive to those risks, and obtain audit evidence that is sufficient and appropriate to provide a basis for my opinion. The risk of not detecting a material misstatement resulting from fraud is higher than for one resulting from error, as fraud may involve collusion, forgery, intentional omissions, misrepresentations, or the override of internal control.", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Obtain an understanding of internal control relevant to the audit in order to design audit procedures that are appropriate in the circumstances, but not for the purpose of expressing", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nan opinion on the effectiveness of the government\u2019s internal control. \n", "metadata": {"headings": [{"headings_0": {"content": "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements", "page": 44, "level": 2}}, [{"headings_0": {"content": "an opinion on the effectiveness of the government\u2019s internal control.", "page": 44, "level": 2}}], [{"headings_0": {"content": "an opinion on the effectiveness of the government\u2019s internal control.", "page": 44, "level": 2}}]], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Evaluate the appropriateness of accounting policies used and the reasonableness of accounting estimates and related disclosures made by management.", "metadata": {"headings": [{"headings_0": {"content": "an opinion on the effectiveness of the government\u2019s internal control.", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern basis of \naccounting and, based on the audit evidence obtained, whether a material uncertainty exists \nrelated to events or conditions that may cast significant doubt on the government\u2019s ability to \ndeliver its mandate. If I conclude that a material uncertainty exists, I am required to draw attention in my auditor\u2019s report to the related disclosures in the financial statements or, if such disclosures are inadequate, to modify my opinion. My conclusions are based on the \naudit evidence obtained up to the date of my auditor\u2019s report. However, future events or \nconditions may cause the government to fail to deliver its mandate. \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern basis of", "page": 44, "level": 2}}, [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern basis of", "page": 44, "level": 2}}], [{"headings_0": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}], [{"headings_0": {"content": "related to events or conditions that may cast significant doubt on the government\u2019s ability to", "page": 44, "level": 2}}], [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}], [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}], [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}]], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- Evaluate the overall presentation, structure, and content of the financial statements, including the disclosures, and whether the financial statements represent the underlying transactions and events in a manner that achieves a fair presentation.", "metadata": {"headings": [{"headings_0": {"content": "audit evidence obtained up to the date of my auditor\u2019s report. However, future events or", "page": 44, "level": 2}}], "page": 44, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": [["No Observations", "Recommendations"], ["a) Payroll management in Local Governments", "I advised the"], ["Absorption of the released funds for payroll I reviewed funds absorption in 100 LGs and noted an under absorption of UGX79.62Bn. Out of the total receipts of UGX.1,539.37Bn, UGX.1,459.79Bn (94.8%) was absorbed. The unabsorbed balance was subsequently returned to the Consolidated Fund account as shown in the Table below. Table 10: Showing Level of Absorption for Wage, Pension and Gratuity Categ ory Approved Estimates (UGX) Bn Releases (UGX) Bn Expenditure (UGX) Bn Variance (UGX) Bn %age Absorpti on Wage 1,327.65 1,337.68 1,272.10 65.57 95.1 Pensi on/ gratu ity 204.20 201.69 187.63 14.05 93.0 1,531.85 1,539.37 1,459.73 79.62 94.8 Source: OAG analysis The under absorbed funds, denied the use of funds for other deserving service delivery areas. The under absorption was mainly attributed to Covid-19 pandemic and the lockdown, especially in the education sector. There was delayed deployment or non-recruitment of secondary school teachers for seed schools that had been recently constructed under the UgIFT projects.", "Accounting Officers to"], [null, "liaise with the relevant"], [null, "authorities and rollover"], [null, "the un-implemented"], [null, "activities to the"], [null, "subsequent period."], [null, ""], [null, ""], ["b) Management of Payroll Deductions i) Under/delayed remittance of Deduction Out of a sample of 84 LGs, I noted that whereas UGX 259.65 Bn was deducted from employees\u2019 salaries to be remitted to URA, UCLA/UBA and other beneficiaries, I noted that contrary to I advised the Accounting Officers to ensure that necessary payroll changes are made timely before payments are effected.", null]], "metadata": {"headings": [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}], "page": 48, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_7"], "type": "table"}}, {"content": "36 \nParagraph B-a(17) of the Uganda Public Standing Orders, 2010 I further advised the \nthere were: \n\uf0b7 Over remittances of UGX 2.16 Bn and \n", "metadata": {"headings": [{"headings_0": {"content": "2.2.1.", "page": 47, "level": 2}}, [{"headings_0": {"content": "Paragraph B-a(17) of the Uganda Public Standing Orders, 2010 I further advised the", "page": 49, "level": 3}}], [{"headings_0": {"content": "Paragraph B-a(17) of the Uganda Public Standing Orders, 2010 I further advised the", "page": 49, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "page": 49, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "page": 49, "level": 3}}]], "page": 48, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Under remittances of UGX 7.33 Bn as shown in table below.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Over remittances of UGX 2.16 Bn and", "page": 49, "level": 3}}], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Table 11: Showing over and under remittance of deductions \nOver remittance \nUnder remittance \nAccounting Officers to initiate strategies that ensure timely remittances of payroll deductions and the over remittances should Number of Amount Number of Amount be recovered. \nDetails Entities with (UGX) Bn Entities with (UGX) \nover under Bn \nremittance \nremittance \nPAYE 13 0.92 65 5.76 UCLA/ \n0 \nUBA 27 .92 48 1.15 \nLST 33 0.27 41 0.20 \nOthers 31 0.50 49 0.22 Total 2.16 7.33 Source: OAG Analysis \nIn addition, 85 LGs (79.4%) out of 107 delayed to remit the funds to UCLA/UBA, contrary to the requirement that payroll deductions are remitted concurrently with salary payments. The extreme \ndelays were noted in the districts shown in the table below. \nTable 12: Average delay in remittance to UCLA \nVote Number Vote Name \nAverage Delay (in Days) \n564 Amolatar DLG \n38 604 Napak dlg \n35 623 Nabilatuk dlg \n46 610 Buhweju DLG \n41 629 Obongi DLG \n55 556 Yumbe DLG \n35 633 Madi-Okollo DLG \n35 572 Oyam DLG \n36 Source: OAG Analysis \nI further noted that 48 LGs (45%) out of 107 delayed to remit the funds to URA, contrary to the requirement that withholding agents remit to URA any tax that has been withheld or that should have \nbeen withheld within fifteen days after the end of the month in which the payment subject to withholding tax was made by the \nwithholding agent. The extreme delays were noted in Mbarara MC, \nKaberamaido DLG, Buyende DLG and Buhweju DLG of 8, 9, 8 and 11 months respectively. \nDelayed/ non remittance of deductions to UCLA/UBA could lead to \ndelays in up-dating loan status with the various financial institutions causing un-necessary default charges on employees \nwhile delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears \nthat had not been paid by 30 th June 2021. \n37", "metadata": {"headings": [{"headings_0": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}, [{"headings_0": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}], [{"headings_0": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}], [{"headings_0": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}], [{"headings_0": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}], [{"headings_0": {"content": "Table 11: Showing over and under remittance of deductions", "page": 49, "level": 3}}], [{"headings_0": {"content": "In addition, 85 LGs (79.4%) out of 107 delayed to remit the funds to UCLA/UBA, contrary to the requirement that payroll deductions are remitted concurrently with salary payments. The extreme", "page": 49, "level": 3}}], [{"headings_0": {"content": "In addition, 85 LGs (79.4%) out of 107 delayed to remit the funds to UCLA/UBA, contrary to the requirement that payroll deductions are remitted concurrently with salary payments. The extreme", "page": 49, "level": 3}}], [{"headings_0": {"content": "Table 12: Average delay in remittance to UCLA", "page": 49, "level": 3}}], [{"headings_0": {"content": "Table 12: Average delay in remittance to UCLA", "page": 49, "level": 3}}], [{"headings_0": {"content": "I further noted that 48 LGs (45%) out of 107 delayed to remit the funds to URA, contrary to the requirement that withholding agents remit to URA any tax that has been withheld or that should have", "page": 49, "level": 3}}], [{"headings_0": {"content": "I further noted that 48 LGs (45%) out of 107 delayed to remit the funds to URA, contrary to the requirement that withholding agents remit to URA any tax that has been withheld or that should have", "page": 49, "level": 3}}], [{"headings_0": {"content": "withholding agent. The extreme delays were noted in Mbarara MC,", "page": 49, "level": 3}}], [{"headings_0": {"content": "withholding agent. The extreme delays were noted in Mbarara MC,", "page": 49, "level": 3}}], [{"headings_0": {"content": "Delayed/ non remittance of deductions to UCLA/UBA could lead to", "page": 49, "level": 3}}], [{"headings_0": {"content": "Delayed/ non remittance of deductions to UCLA/UBA could lead to", "page": 49, "level": 3}}], [{"headings_0": {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "page": 49, "level": 3}}], [{"headings_0": {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "page": 49, "level": 3}}], [{"headings_0": {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "page": 49, "level": 3}}]], "page": 49, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["The Accounting Officers did not provide satisfactory explanations to justify the over remittances. For the under payments, the Accounting Officers attributed it mainly to suspension of staff salaries due to disciplinary issues, delayed removal of staff from the payroll and delays in resolving issues such as abscondment where payments were withheld. For delays in remittance of deductions, the Accounting Officers attributed it to delays in reconciliation of interface deduction files. ii) Un-authorized loans deductions I noted that 48 LGs made unauthorised loans deductions totaling UGX 11.10 Bn. The deductions were from 6,835 employees that lacked letters of consent/ undertaking. I further noted that out of the 48 LGs, 23 LGs (48%) registered 1,916 employees with deductions totaling to UGX 3.77 Bn that did not exist in the Payroll Deduction Management System (PDMS), operated by PCA-Payroll Consults Africa. There is a risk of making deductions from staff that have no loans, which deprives them of their earnings. The inconsistencies in the PDMS undermine the relevance of the system and affect the integrity of the data therein. The Accounting Officers acknowledged the shortcoming and explained that letters of undertaking were being signed although file copies were not being retained for future reference. They further explained that the inconsistencies in the PDMS data were attributed to PCA who largely control and manage the system. I advised Government through MoPS to ensure that PCA makes the necessary data reconciliation and update the information on the PDMS regarding the deductions. I further advised the Accounting Officers to ensure that all loan applications are backed by letters of undertaking and approved through the PDMS.", null, null, null, null, null, null], ["c) Access to Payrolls i) Delayed access to salary payroll I noted that 2,178 newly recruited employees in 75 LGs delayed to access payroll, with delays ranging from 1-34 months. I further noted that 407 employees in 17 LGs had not yet accessed the payroll by the close of the financial year. Delayed access to payroll leads to demotivation of the affected staff and accumulation of salary arrears. The Accounting Officers attributed the shortcoming mainly to delayed submission of key personnel documents and data mismatch between IPPS & NIRA. I advised the Accounting Officers to sensitise the newly recruited employees on the timely submission of the key documents. I further urged the Accounting Officers to ensure timely validation of the newly recruited employees and to liaise with the relevant authorities to improve effectiveness and reliability of the MoPS/NID interface.", null, null, null, null, null, null], ["", "ii) Delayed access to pension payroll noted that 780 pensioners delayed to access the pension payroll,", null, null, null, null, "I advised the"]], "metadata": {"headings": [{"headings_0": {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "page": 49, "level": 3}}], "page": 50, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5", "column_6"], "type": "table"}}, {"content": [["The Accounting Officers did not provide satisfactory explanations to justify the over remittances. For the under payments, the Accounting Officers attributed it mainly to suspension of staff salaries due to disciplinary issues, delayed removal of staff from the payroll and delays in resolving issues such as abscondment where payments were withheld. For delays in remittance of deductions, the Accounting Officers attributed it to delays in reconciliation of interface deduction files. ii) Un-authorized loans deductions I noted that 48 LGs made unauthorised loans deductions totaling UGX 11.10 Bn. The deductions were from 6,835 employees that lacked letters of consent/ undertaking. I further noted that out of the 48 LGs, 23 LGs (48%) registered 1,916 employees with deductions totaling to UGX 3.77 Bn that did not exist in the Payroll Deduction Management System (PDMS), operated by PCA-Payroll Consults Africa. There is a risk of making deductions from staff that have no loans, which deprives them of their earnings. The inconsistencies in the PDMS undermine the relevance of the system and affect the integrity of the data therein. The Accounting Officers acknowledged the shortcoming and explained that letters of undertaking were being signed although file copies were not being retained for future reference. They further explained that the inconsistencies in the PDMS data were attributed to PCA who largely control and manage the system. I advised Government through MoPS to ensure that PCA makes the necessary data reconciliation and update the information on the PDMS regarding the deductions. I further advised the Accounting Officers to ensure that all loan applications are backed by letters of undertaking and approved through the PDMS.", null, null, null, null, null, null], ["c) Access to Payrolls i) Delayed access to salary payroll I noted that 2,178 newly recruited employees in 75 LGs delayed to access payroll, with delays ranging from 1-34 months. I further noted that 407 employees in 17 LGs had not yet accessed the payroll by the close of the financial year. Delayed access to payroll leads to demotivation of the affected staff and accumulation of salary arrears. The Accounting Officers attributed the shortcoming mainly to delayed submission of key personnel documents and data mismatch between IPPS & NIRA. I advised the Accounting Officers to sensitise the newly recruited employees on the timely submission of the key documents. I further urged the Accounting Officers to ensure timely validation of the newly recruited employees and to liaise with the relevant authorities to improve effectiveness and reliability of the MoPS/NID interface.", null, null, null, null, null, null], ["", "ii) Delayed access to pension payroll noted that 780 pensioners delayed to access the pension payroll,", null, null, null, null, "I advised the"], ["I", null, null, null, null, null, "Accounting Officers to liaise with MoPS to initiate strategies of rectifying the inconsistencies with"], [null, "", "", "", "", "", "NIRA interface and to"], [null, "", "", "", "", "", "cause the beneficiaries"]], "metadata": {"headings": [{"headings_0": {"content": "while delayed remittance of PAYE attracts fines and penalties from the Revenue Authority. It further led to accumulation of arrears", "page": 49, "level": 3}}], "page": 50, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5", "column_6"], "type": "table"}}, {"content": "with \n107 09 146 \nby \n38", "metadata": {"headings": [{"headings_0": {"content": "with", "page": 50, "level": 3}}, [{"headings_0": {"content": "with", "page": 50, "level": 3}}], [{"headings_0": {"content": "by", "page": 50, "level": 3}}], [{"headings_0": {"content": "by", "page": 50, "level": 3}}]], "page": 50, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["", "", null, null, null, "to submit the essential"], [null, "Delayed access to the pension payroll leads to poor wellbeing of", null, null, null, "documents in time. I further advised PS/ST to ensure adequate allocation of pension and gratuity funds."], [null, "affected retirees as well as accumulation of pension arrears.", null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "by", "page": 50, "level": 3}}], "page": 51, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5"], "type": "table"}}, {"content": [["", "", null, null, null, "to submit the essential"], [null, "Delayed access to the pension payroll leads to poor wellbeing of", null, null, null, "documents in time. I further advised PS/ST to ensure adequate allocation of pension and gratuity funds."], [null, "affected retirees as well as accumulation of pension arrears.", null, null, null, null], [null, "", null, null, null, null], [null, "Accounting Officers attributed the shortcoming to mainly mismatch of data between NIRA and IPPS interfaces such as wrong dates of birth, delayed submission of documents and", null, null, null, null], [null, "inadequate budget allocation to cater for all retirees hence phased", null, null, null, null], [null, "access to the pension payroll.", null, null, null, null], [null, "", null, null, null, null], ["d) Delayed deletion of staff from the salary payroll I noted that in 78 LGs, a total of UGX 1.13 Bn was paid to 635 staff who had either retired, transferred, absconded or died. These were payment for services that were not rendered to the LGs, hence loss of funds to Government. This was mainly attributed to delayed communication from supervisors of the affected staff as well as failure to delete affected staff due to lack of validation on the MoPS/ NID interface. I advised the Accounting Officers to sensitise all supervisors on when and how to communicate such cases so as to ensure prompt removal of staff from the payroll. I further urged the Accounting Officers to ensure that all staff are validated on the MoPS/ NID interface. I also advised MoPS to automate the deletion of retirees on mandatory grounds.", null, null, null, null, null], ["e)", "Misclassification of salary, pension and gratuity expenditure 3.60 Bn in 33 LGs was charged on account codes other than", null, null, null, "I advised the"], ["", null, null, null, null, "Accounting Officers to ensure that wage, pension and gratuity expenditure is charged on the appropriate codes."], [null, "", "", "", "", ""], [null, "insufficient budget provisions for pensions and gratuity. I advised", null, null, null, null], [null, "Accounting Officers to liaise with MoFPED to ensure that", null, null, null, null], [null, "sufficient budget provisions are made.", null, null, null, null], ["f) Effectiveness and reliability of the IPPS/NID interface I reviewed the effectiveness and reliability of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification interface and made the following observations; \uf0b7 There was in-adequate sensitization and training in the use and navigation of the system \uf0b7 System was not reliable and effective \uf0b7 Operational challenges were encountered, including; \uf076 Un-reliable network \uf076 Failure to reflect changes in updated staff information \uf076 Mismatches of names that take long to be corrected by NIRA \uf076 Some information on the NIRA interface is sometimes not visible/available for instance date of birth and the I advised the Accounting Officers to engage MoPS and NIRA to have trainings conducted as well as resolve the system challenges.", null, null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "by", "page": 50, "level": 3}}], "page": 51, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5"], "type": "table"}}, {"content": "the The \nUGX \nThe the \n39 \nphoto which delays the verification exercise. \nThe ineffectiveness of the system my affect the integrity of the \nIPPS payroll. \nThe Accounting Officers noted the finding. \nOther Matter \nI consider it necessary to communicate the following matters other than those presented or disclosed in the financial statements. \n2.2.2. \nImplementation of the approved budget \nA review of the Local Governments approved budgets of UGX 5,615.86Bn out of which UGX 4,328.01 Bn was warranted/ availed by the end of the financial year. The total expenditure for the year was UGX 4,147.90 Bn out of which UGX 2,853.55Bn was spent on employee costs and transfers to other units implying that only UGX.1,294.35 Bn was available for implementation of service delivery outputs. \nFrom the procedures undertaken, I noted the following significant observations", "metadata": {"headings": [{"headings_0": {"content": "the The", "page": 51, "level": 3}}, [{"headings_0": {"content": "UGX", "page": 51, "level": 3}}], [{"headings_0": {"content": "The the", "page": 51, "level": 3}}], [{"headings_0": {"content": "The the", "page": 51, "level": 3}}], [{"headings_0": {"content": "The the", "page": 51, "level": 3}}], [{"headings_0": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], [{"headings_0": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], [{"headings_0": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], [{"headings_0": {"content": "The ineffectiveness of the system my affect the integrity of the", "page": 52, "level": 3}}], [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}], [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}], [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}], [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}]], "page": 51, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["No Observations Recommendations", null, null], ["1.0", "Existence of Strategic plans that are aligned to NDP-III Paragraph 5 of the budget execution circular for the financial", "I advised the"], ["", null, "Accounting Officers to"], [null, "year 2020/2021 cites poor alignment of Government Budgets", "follow up the matter"], [null, "with the National Development Plans. The PS/ST urged", "with NPA and ensure"], [null, "Accounting Officers to ensure that all activities for Financial", "that the entities have"], [null, "Year 2020/2021 are aligned with NDP III and implemented", "strategic plans that are"], [null, "accordingly. Regulation 26 (1) of the National Planning", "aligned to NDP-III and"], [null, "Authority (development of Plans) regulations require entities", "certified by NPA."], [null, "to submit to NPA their five-year development plans for", null], [null, "certification before approval.", null], [null, "", null], [null, "This being the first year of implementation of the NDP-III,", null], [null, "LGs were expected to prepare a strategic plan aligned to", null], [null, "NDP III and ensure that these plans are certified by NPA.", null], [null, "These plans would then be the basis for preparation of the", null], [null, "entity annual plans.", null], [null, "", null], [null, "From the procedures undertaken I noted that out of 86", null], [null, "entities sampled, none had prepared a strategic plan that", null], [null, "was aligned to NDP-III and certified by NPA. There is a risk", null], [null, "that activities implemented by these entities during the", null], [null, "financial year 2020/2021 were not aligned to the NDP-III", null], [null, "which negatively affects the achievement of NDP-III", null], [null, "objectives.", null], [null, "", null], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}], "page": 52, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "40", "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}], "page": 52, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["2.1 a) Absorption of released funds Out of the total receipts for the financial year of UGX 4,328.01 Bn, UGX 4,147.90 Bn (95.8%) was spent by the Local Governments resulting in an unspent balance of UGX 180.11 Bn (4.2%). The unspent balance at the end of the financial year was remitted back to the consolidated fund account. Under absorption of released funds results in non- implementation of planned activities and negates the purpose for which funds were disbursed, thereby affecting the achievement of the objectives in the NDPIII. For example, implementation of USMID projects in Municipal Councils and UgIFT projects in DLGs was not undertaken. The Accounting Officers attributed failure to utilise funds to COVID-19 which affected the recruitment exercise, late release of USMID funds and delays in the procurement process and lotting policy of contract works under UgIFT. I advised the Accounting Officer to liaise with line Ministries to revote the funds, roll over the activities and ensure they are subsequently implemented.", null, null], ["", "b) Revenue Performance i) Local Revenue performance The local governments budgeted to receive UGX 217.38 Bn", "I await the outcome of"], ["", null, "the interventions"]], "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}], "page": 53, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_6"], "type": "table"}}, {"content": [["2.1 a) Absorption of released funds Out of the total receipts for the financial year of UGX 4,328.01 Bn, UGX 4,147.90 Bn (95.8%) was spent by the Local Governments resulting in an unspent balance of UGX 180.11 Bn (4.2%). The unspent balance at the end of the financial year was remitted back to the consolidated fund account. Under absorption of released funds results in non- implementation of planned activities and negates the purpose for which funds were disbursed, thereby affecting the achievement of the objectives in the NDPIII. For example, implementation of USMID projects in Municipal Councils and UgIFT projects in DLGs was not undertaken. The Accounting Officers attributed failure to utilise funds to COVID-19 which affected the recruitment exercise, late release of USMID funds and delays in the procurement process and lotting policy of contract works under UgIFT. I advised the Accounting Officer to liaise with line Ministries to revote the funds, roll over the activities and ensure they are subsequently implemented.", null, null], ["", "b) Revenue Performance i) Local Revenue performance The local governments budgeted to receive UGX 217.38 Bn", "I await the outcome of"], ["", null, "the interventions"], [null, null, "instituted by GoU to"], [null, "(revised) as total revenue for the year. However, only UGX", "stimulate revenue"], [null, "96.28 Bn representing 44.29% of their revised budgets was", "collection."], [null, "received performance.", ""], [null, "", "In addition, I urged the"], [null, "Under collection of local revenue results in non-", "respective Accounting"], [null, "implementation of planned activities which affects service", "Officers to make"], [null, "delivery.", "budget revisions based"], [null, "The Accounting Officers of the respective local government", "on realistic forecasts in"], [null, "votes attributed the shortfall in local revenue to COVID 19", "such unforeseen"], [null, "effects.", "circumstances."], [null, "", ""], [null, "The Accountant General explained that Government of", null], [null, "Uganda (GoU) had provided some interventions including", null], [null, "vaccination and funding to revive the economy for activities", null], [null, "to resume and stimulate revenue collection.", null], [null, "", null], ["ii) Revenue from External financing The Local Governments budgeted to receive UGX 413.94 Bn as external/donor financing, out of which UGX 57 Bn (13.8%), was received Revenue shortfalls affect the implementation of planned activities. The Accounting Officer attributed this to the fact that the Local governments did not receive indicative planning figures from the donors for proper and realistic budgeting for the Financial Year under review.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}], "page": 53, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_6"], "type": "table"}}, {"content": "41", "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}], "page": 53, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iii) Off Budget Financing/Receipts \nI advise Government through the Ministry of Section 43 (1) of the PFMA 2015 states that all expenditure Finance to negotiate incurred by the government on externally financed projects and mainstream Donor in a financial year shall be appropriated by parliament. funding in the Local Paragraph 29 of the Budget Execution Circular for the Governments Budgeting Financial year states that if an external agency provides Process. \nfunds in the course of implementation of the budget or any \nfunds remain unspent at the expiry of an appropriation, \nthese must be declared and a supplementary issued in line \nwith the Public Finance Management Act 2015. \nI noted that 17 of the 86 LGs sampled received off-budget financing to a tune of UGX 14.20 Bn, which was never declared to the PS/ST and was also not appropriated by parliament. As such, no supplementary appropriation was issued as guided by the PS/ST. These funds were received directly from development partners for undertaking activities not budgeted for. Off-budget financing distorts planning, may result in duplication of activities, contrary to Section 43(1) of the PFMA 2015 and the budget execution guidelines issued by the PS/ST. \nThe Accounting Officers explained this was due to limitations of the PBS system which has no provision for inputting such receipts and in some cases funds are received during the year which were not expected at the time of planning. \n42", "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}], [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}], [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}]], "page": 54, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "iv) Quantification of activities and Implementation of I advised the planned outputs \nAccounting Officers to ensure that work plans Section 13 (15, b) of the PFMA 2015 states that a policy and budgets are fully statement submitted by a vote shall contain the annual and quantified and ensure three months\u2019 work plans, outputs, targets and performance that \nun-implemented indicators of the work plans. Regulation 11 (3) of PFMR 2016 \nactivities are rolled over requires that a vote prepares a work plan that indicates the to the subsequent outputs of the vote for the financial year; the indicators to periods \nfor be used to gauge the performance of the outputs and funds \nimplementation. allocated to each activity. \nI sampled 86 entities for purposes assessing the extent of quantification and implementation of planned outputs I noted that out of the 850 outputs worth UGX 254 Bn sampled for review, 675 outputs (79%) worth UGX 182 Bn were fully quantified, 58 outputs (7%) worth UGX 34 Bn were partially quantified while 117 out puts (14%) worth UGX 38 Bn were not quantified at all. \nOut of a total of 675 quantified out-puts worth UGX.182 Bn assessed, 475 (70.4%) output worth UGX 90.10 Bn were fully implemented, 172 outputs (25.5%) worth UGX 86.70 Bn were partially implemented, while 28 (4%) out-puts worth UGX 4.90 Bn were not implemented at all. The graph below shows the extent of implementation; \nExtent of implementation of quantified out- puts \n4% 26% \n70% \nFully Implemented \nPartially Implemented \nNot implemented \nThe Accounting Officers explained that implementation of activities was affected by the restrictions in movement imposed by government to curb the spread of Covid-19 and the fact that staff at the entities were working at 30% staffing levels. Failure to fully quantify the planned activities makes the assessment of implementation difficult while failure to implement planned activities denies citizens services. \n43 \n2.2.3. Operationalization of New Cities \nDuring the FY 2019/20 Government made a pronouncement upgrading ten (10) Municipal Councils (MCs) to City status effective 1 st July 2020. These include; Arua, Mbarara, Gulu, Jinja Fort portal, Mbale, Masaka, Soroti, Hoima and Lira \nDuring my audit of the above cities for the F/Year 2020/21, I noted the following;", "metadata": {"headings": [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}, [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}], [{"headings_0": {"content": "2.2.2.", "page": 52, "level": 2}}], [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}], [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}], [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}], [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}], [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}], [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}], [{"headings_0": {"content": "Extent of implementation of quantified out- puts", "page": 55, "level": 4}}], [{"headings_0": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}], [{"headings_0": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}], [{"headings_0": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}]], "page": 55, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "i) Government did not provide funding in the budgets of the newly created entities to enable them operate as cities. I noted that they continued to operate using the budgets of MCs. \nii) The High Court in Masaka was petitioned by some individuals to review the guidelines issued by the Minister of Local Governments for the new cities on grounds that they contravened the procedures set out in the Local Government Act. \niii) The cities lacked establishment structures against which the recruitment of the required human resource could be undertaken. \niv) There was no guidance on the allocation/sharing of assets. This has become a contentious matter between the councils of the newly created cities and those of the hosting districts. \nAs a result of the above, the high expectations of both the local political leadership and the general public have not been met. \nI advise Government to ensure that the new cities are fully operationalised. \n2.2.4. Capitation Grant for Printing of Home Study Materials \nThe Government through MoES released UGX 23 Bn for printing of home study materials to facilitate home learning during the COVID 19 lockdown. \nHowever, I noted that the study materials were not procured and the districts were advised to send the money to the school bank accounts with a condition that they should not spend until instructed to do so. \nAt the time of writing this report, the home study materials had not been printed \nand the funds were either used or lying idle on the schools\u2019 bank accounts. \nConsequently, the objective of ensuring that learners continued to learn during the lockdown was not achieved. \nThe Accounting Officers explained that no instructions were given as indicated by the MoES. \nI advise Government through MoES to always provide timely guidance and coordination in such events that require urgent government interventions. \nI also recommend that schools are given guidance on the utilization of the funds. \n44 \n2.2.5. Un-Accounted for Funds \nSection 43(2) of the of the Local Governments Financial and Accounting Regulations, 2007 require administrative advances to council employees to be authorized by the executive and accounted for within a month. \nI noted expenditure of UGX 3.37 Bn paid out for implementation of various activities in the LGs remained unaccounted at year-end as shown below \nTable 11: Entities with unsupported expenditure \nSn Entity \nAmount (UGX) Bn", "metadata": {"headings": [{"headings_0": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}, [{"headings_0": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}], [{"headings_0": {"content": "2.2.3. Operationalization of New Cities", "page": 56, "level": 4}}], [{"headings_0": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}], [{"headings_0": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}], [{"headings_0": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}], [{"headings_0": {"content": "2.2.4. Capitation Grant for Printing of Home Study Materials", "page": 56, "level": 4}}], [{"headings_0": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}], [{"headings_0": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}], [{"headings_0": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}], [{"headings_0": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}], [{"headings_0": {"content": "and the funds were either used or lying idle on the schools\u2019 bank accounts.", "page": 56, "level": 2}}], [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}], [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}], [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}], [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}], [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}]], "page": 56, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "1. ABIM DLG \n1.41\n2. BUGWERI DLG \n0.25\n3. BUKEDEA DLG \n0.01\n4. Hoima MC \n0.06\n5. Kikuube DLG \n0.07\n6. Kiryandongo DLG \n0.01\n7. KOLE DLG \n0.26\n8. MADI-OKOLLO DLG \n0.05\n9. MOROTO DLG \n0.03\n10. MOROTO MC \n1.19\n11. OYAM DLG \n0.03\n12. Total 3.37", "metadata": {"headings": [{"headings_0": {"content": "2.2.5. Un-Accounted for Funds", "page": 57, "level": 2}}], "page": 57, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": [["SN.", "Sector", "Status of", "No. of", "%age", "Commencement period"], ["", null, "implementation", "projects", "Status", null], ["1", "Education", "Completed", "2", "8.3%", "Previous financial year(s)"], ["Completed and handed over 1 4.2% Previous financial year(s) Incomplete 20 83.3% Previous financial year(s) 1 4.2% 2020/2021 Subtotal 24 100%", null, null, null, null, null], ["2 Health Completed 3 7.3% Previous financial year(s) 3 7.3% 2020/2021 Completed and handed over 1 2.4% Previous financial year(s) 1 2.4% 2020/2021 Incomplete 19 46 % Previous financial year(s) 13 32% 2020/2021 Not implemented 1 2.4% Not started Subtotal 41 100%", null, null, null, null, null], ["Grand Total 65", null, null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 59, "level": 3}}], "page": 59, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5"], "type": "table"}}, {"content": "Source: OAG analysis \nI further noted that out of the 53 incomplete projects, 36projects had exceeded their planned completion dates by an average of 11 months. \nThe Accounting Officers attributed the delays in project completion to; \na) The Covid-19 lockdown measures which limited the movement of materials and labour, \nb) The contractors abandoning the sites, \nc) Funds not being re-voted to the entities in time, \nd) Delayed hybrid procurements, \ne) Late release of funds, \nf) Poor terrain leading to impassable roads to some projects sites, \ng) Low capacity of the contractor in terms of manpower, machinery, and multiple projects. \nConsequently, the projects planned to be completed within the year were not completed, and as such the intended beneficiaries were denied services. \nI advised the Accounting Officers to liaise with the sector Ministries to ensure that the implementation bottlenecks identified above are addressed. \n47 \nb) Land Ownership \nThe Circular issued by the MoFPED in May 2018 requested all Local Governments to ensure that all Government projects are constructed on land with proof of ownership or a Memorandum of Understanding (MOU) with landowners; \nI observed 4 projects that did not have titles or MOUs for the land on which the seed schools and health centers were constructed as shown in the table below: \nTable 14: UgIFT projects without land titles", "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 59, "level": 3}}, [{"headings_0": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}], [{"headings_0": {"content": "a)", "page": 59, "level": 3}}]], "page": 59, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN", "District/", "Name of", "Contract price", "Amount spent", "Status"], ["", "Municipal", "project", "(UGX) Bn", "(UGX) Bn", null], [null, "Council", null, null, null, null], ["1", "Kamwenge", "Construction", "2.02", "1.92", "Completed"], ["", "DLG", "of Bwizi Seed", null, null, "and handed"], [null, "", "school", null, null, "over"], ["2 Mityana DLG Upgrade of Busunjju HC II to HC III 0.66 Incomplete", null, null, null, null, null], ["3", "Kyotera", "Upgrade of", "0.66", "0.28", "Incomplete"], ["", "DLG", "Nyangoma HC", null, null, null], [null, "", "II to HC III", null, null, null], ["4 Moroto DLG Construction of Rupa Seed secondary school 1.94 1.70 Incomplete", null, null, null, null, null], ["Total", null, null, "5.28", "3.90", ""]], "metadata": {"headings": [{"headings_0": {"content": "a)", "page": 59, "level": 3}}], "page": 60, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["SN.", "Sector", "Status of", "No. of", "%age", "Commencement period"], "type": "table"}}, {"content": "- Identify and assess the risks of material misstatement of the financial statements, whether due to fraud or error, design and perform audit procedures responsive to those risks, and obtain audit evidence that is sufficient and appropriate to provide a basis for my opinion. The risk of not detecting a material misstatement resulting from fraud is higher than for one resulting from error, as fraud may involve collusion, forgery, intentional omissions, misrepresentations, or the override of internal control.", "metadata": {"headings": [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}, [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}]], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Obtain an understanding of internal control relevant to the audit in order to design audit procedures that are appropriate in the circumstances, but not for the purpose of expressing an opinion on the effectiveness of the local governments\u2019 internal control.", "metadata": {"headings": [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Evaluate the appropriateness of accounting policies used and the reasonableness of accounting estimates and related disclosures made by the management.", "metadata": {"headings": [{"headings_0": {"content": "error and to issue an auditor\u2019s report that includes my opinion. Reasonable assurance is", "page": 61, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "basis of accounting and, based on the audit evidence obtained, whether a material uncertainty exists related to events or conditions that may cast significant doubt on the local government\u2019s ability to continue as a going concern. If I conclude that a material uncertainty exists, I am required to draw attention in my auditor\u2019s report to the related disclosures in the financial statements or, if such disclosures are inadequate, to modify my opinion. My conclusions are based on the audit evidence obtained up to the date of my auditor\u2019s report. However, future events or conditions may cause the local government to cease to continue as a going concern.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Evaluate the overall presentation, structure and content of the financial statements, including the disclosures, and whether the financial statements represent the underlying transactions and events in a manner that achieves fair presentation.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Conclude on the appropriateness of management\u2019s use of the going concern", "page": 62, "level": 2}}], "page": 62, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": [["S/N", "Enterprise", "Government Holding"], ["1.", "Uganda Air Cargo Corporation", "Not ascertained"], ["2\\. Uganda Refinery Holding Co Not ascertained", null, null]], "metadata": {"headings": [{"headings_0": {"content": "Treasury.", "page": 65, "level": 2}}], "page": 65, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "c) \nMissing Entities in the consolidated summary statement \nSection 52(1) c of PFMA 2015 as amended requires the Accountant General within three months after the end of each financial year to prepare and submit to the Minister and the Auditor General a consolidated summary statement of the financial performance of public corporations and state enterprises and Companies where Government has a controlling interest. \nI noted that three (3) entities were neither reported nor disclosed in the consolidated summary statement of performance. (Table 16 below refers). \nTable 16: Entities neither reported nor Disclosed in the consolidated summary statement", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, [{"headings_0": {"content": "c)", "page": 65, "level": 3}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}]], "page": 65, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["S/N", "Enterprise", "Remarks"], ["1", "Uganda National Oil Company Limited", "Not reported in the previous year"], ["2 Nakivubo War Memorial Stadium Not reported in the previous year", null, null], ["3", "Uganda Crane Industries Ltd.", "Not reported in the previous year"]], "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 65, "level": 3}}], "page": 65, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "This implies that the consolidated summary statement of financial performance of public corporations and state enterprises does not reflect the accurate status of government ownership and interest and as such I was unable to assess and conclude on their performance. \nI advised the Accountant General to issue comprehensive guidelines in respect of all Public Corporations and state Enterprises to be consolidated to enable assessment of financial performance. \n53 \n2.4.1 Review of Financial Performance of Public Corporations and State Enterprises \nThe Government of Uganda (GoU) owns shares in a number of Public Corporations and State Enterprises. These enterprises, which are independently managed, are supposed to operate efficiently, make profits and pay dividends to Government. Their financial performance is therefore of interest to Government. \nAs noted in my previous reports, the Government Consolidated Summary Statement of financial performance of public corporations and State enterprises only reports on; government shareholding, total income, total expenditure, dividends declared, retained earnings, and net worth of entities. However, key performance assessment parameters, such as; profitability, return on assets, liquidity assessment, long-term debt, and interest cover are not reported on. As a result, I computed these ratios using audited financial statements for further analysis of performance of Public Corporations and State Enterprises, where applicable. \nOut of the 46 Public Corporations and State Enterprises, seven (7) entities were not assessed because they had not submitted audited accounts at the time of writing my report. Table 17 below refers; \nTable 17: Entities not assessed", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, [{"headings_0": {"content": "c)", "page": 65, "level": 3}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}], [{"headings_0": {"content": "c)", "page": 65, "level": 3}}]], "page": 65, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["S/N", "Entity", "Government Stake"], ["1.", "Uganda National Oil Company Limited", "100%"], ["2\\. Nakivubo War Memorial Stadium 100%", null, null], ["3.", "National Housing and Construction Company Limited", "51%"], ["4\\. Uganda Telecom Limited Not known", null, null], ["5.", "The Micro Finance Support Centre Ltd", "100%"], ["6\\. Uganda Seeds Limited 100%", null, null], ["7.", "Uganda Livestock Industry", "100%"]], "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 65, "level": 3}}], "page": 66, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["S/N", "Enterprise", "Remarks"], "type": "table"}}, {"content": "From the financial performance analysis undertaken, I noted the following; \na) Profitability of Enterprises \nI noted that thirteen (13) out of the twenty-six (26) Public Corporation and State Enterprises analysed made profits/surplus in the year under review, with Uganda Electricity Transmission Company Limited (UETCL), Uganda Electricity Generation Company (UEGCL) and National Water and Sewerage Corporation (NWSC) posting profits of UGX 112Bn, UGX 91.9Bn and UGX 47.8Bn, respectively. Table 18 below refers. \n54 \nTable 18: Profitability of Public Corporation and State Enterprises", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 65, "level": 3}}, [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}], [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}], [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}], [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}]], "page": 66, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["No", "Entity", "Profit After Tax / Surplus", null, "Increase/"], ["", null, "for the year (UGX", null, "Decrease"], [null, null, "in Bn)", null, null], [null, null, "2020/21", "2019/20", ""], ["1\\. Uganda Electricity Transmission Company Limited (UETCL) 112.00 54.02 57.97", null, null, null, null], ["2.", "Uganda Electricity Generation Company", "91.93", "2.80", "89.14"], ["", "(UEGCL)", null, null, null], ["3\\. National Water and Sewerage Corporation (NWSC) 47.79 27.44 20.35", null, null, null, null], ["4.", "Kira Motors Corporation", "26.09", "", "26.10"], ["5\\. Uganda Development Bank Limited 22.11 10.14 11.97", null, null, null, null], ["6.", "Housing Finance Bank Limited", "20.69", "22.50", "(1.80)"], ["7\\. Pride Micro Finance (Dec 2020) 12.69 12.79 (0.98)", null, null, null, null], ["8.", "Post Bank Uganda Limited (Dec 2020)", "10.07", "8.38", "1.69"], ["9\\. Uganda Printing and Publishing Corporation 6.25 4.22 2.033", null, null, null, null], ["10.", "NEC Luwero", "3.68", "3.38", "0.30"], ["11\\. Insurance Training college 2.42 0.015 2.42", null, null, null, null], ["12.", "Uganda Wildlife Conservation education", "1.44", "1.74", "(0.30)"], ["", "Centre", null, null, null], ["13\\. Mandela National Stadium 1.08 (0.23) 1.38", null, null, null, null], ["14.", "Uganda Property Holdings Limited", "0.85", "", "0.85"], ["15\\. Uganda Development Corporation (Group) 0.63 (7.32) 7.95", null, null, null, null], ["16.", "NEC UZIMA", "0.15", "0.26", "(0.12)"], ["17\\. Nile Hotel International Limited 0.08 1.24 (1.16)", null, null, null, null], ["18.", "Uganda Energy Credit Capitalization Co.", "(0.87)", "(0.59)", "(0.28)"], ["", "Ltd", null, null, null], ["19\\. Kilembe Mines Limited (0.91) (2.81) (1.10)", null, null, null, null], ["20.", "New Vision Printing and Publishing", "(7.11)", "2.66", "(9.76)"], ["", "Company Limited", null, null, null], ["21\\. Uganda Electricity Distribution Company Limited (UEDCL) (10.90) (10.12) (0.78)", null, null, null, null], ["22.", "Uganda Broadcasting Corporation", "(19.32)", "(7.62)", "(11.71)"], ["23\\. Uganda Civil Aviation Authority (UCAA) (27.50) (13.74) (13.78)", null, null, null, null], ["24.", "Uganda Railways Corporation", "(37.78)", "(61.39)", "23.60"], ["25\\. Uganda Wildlife Authority (UWA) (45.05) 5.54 (50.59)", null, null, null, null], ["26.", "Uganda National Airlines Company Limited", "(164.60)", "(102.45)", "(62.12)"]], "metadata": {"headings": [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}], "page": 67, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "The general performance of some of the Public Corporations and State enterprises slightly improved compared to the previous year with companies such as Uganda Electricity Transmission Company Limited (UETCL), Uganda Electricity Generation Company (UEGCL) and National Water and Sewerage Corporation (NWSC) posting more than double the profits of the previous year. This was mainly attributed to government efforts to ease several COVID-19 restrictions, allowing certain businesses to reopen and government intervention of revamping the economy. \nI further noted that entities including Uganda Railways Corporation, Kilembe Mines Limited, Uganda Civil Aviation Authority (UCAA) and Uganda National Airlines Company Limited made losses as at the end of the financial year. However, it should be noted that this is the second year of operation of Uganda National Airlines in a highly competitive industry. \n55 \nI advised the entities to develop clear strategies to improve operations and adopt efficient financial management practices to lower operating costs and increase revenue generation. Government should also consider recapitalizing the most affected entities to revamp their operations. \nb) Return on Assets \nThe Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large \ninitial investments will generally have lower return on assets, ROAs below 5% are generally considered inadequate. \nApart from eleven (11) companies, which include; Uganda Wildlife Conservation education Centre, Uganda Electricity Transmission Company Limited, Kira Motors \nCorporation, Uganda Printing and Publishing Corporation, Insurance Training \nCollege, NEC Constructions Construction Works and Engineering Limited, NEC Uzima, NEC Luwero, Insurance Regulatory Authority of Uganda and National Drug Authority which posted a favourable ROA, the rest of the entities where the ratio is applicable, registered a poor performance on ROA of below 5%. \nTable 19: Returns on Assets", "metadata": {"headings": [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}, [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}], [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}], [{"headings_0": {"content": "a) Profitability of Enterprises", "page": 66, "level": 2}}], [{"headings_0": {"content": "b) Return on Assets", "page": 68, "level": 2}}], [{"headings_0": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}], [{"headings_0": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}], [{"headings_0": {"content": "The Return on Assets (ROA) shows the percentage of how a company\u2019s assets are generating revenue. It measures management\u2019s efficiency in using the enterprise\u2019s assets to generate earnings. Although companies that require large", "page": 68, "level": 2}}], [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}]], "page": 67, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["No.", "Entity", "Return on Asset (%)", null], [null, null, "2019/20", "2020/21"], ["1\\. Uganda Wildlife Conservation education Centre 49.9 48.1", null, null, null], ["2.", "Kira Motors Corporation", "41", "43"], ["3\\. NEC Constructions Construction Works and Engineering Limited 10.8 31", null, null, null], ["4.", "Uganda Electricity Transmission Company Limited", "26.2", "26.4"], ["5\\. Uganda Printing and Publishing Corporation 2.16 22.06", null, null, null], ["6.", "NEC UZIMA", "6.3", "12.1"], ["7\\. NEC Luwero 12.5 10", null, null, null], ["8.", "Pride Micro Finance (Dec 2020)", "4", "3.3"], ["9\\. Uganda Development Bank Limited 3.16 2.91", null, null, null], ["10.", "Housing Finance Bank Limited", "2.9", "2.5"], ["11\\. Post Bank Uganda Limited (Dec 2020) 2.57 2.25", null, null, null], ["12.", "Uganda Development Corporation (Group)", "-405.4", "1.8"], ["13\\. Uganda Post Limited 1 1", null, null, null], ["14.", "Uganda Electricity Generation Company", "0.69", "0.79"], ["15\\. Mandela National Stadium -0.16 0.6", null, null, null], ["16.", "Uganda Property Holdings Limited", "0.4", "0.33"], ["17\\. National Water and Sewerage Corporation 1.45 0.26", null, null, null], ["18.", "Nile Hotel International Limited", "0.67", "0.04"], ["19\\. New Vision Printing and Publishing Company Limited 5.28 -0.4", null, null, null], ["20.", "Uganda Electricity Distribution Company Limited", "-0.56", "-0.56"], ["21\\. Uganda Railways Corporation -1.66 -1.03", null, null, null], ["22.", "Uganda Civil Aviation Authority", "0.48", "-2.4"]], "metadata": {"headings": [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], "page": 68, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "56", "metadata": {"headings": [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], "page": 68, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["23\\. Uganda Broadcasting Corporation -2.5 -5.88", null, null, null], ["24.", "Kilembe Mines Limited", "-6.72", "-10"], ["25\\. Uganda National Airlines Company Limited -12.2 -13.1", null, null, null], ["26.", "Uganda Wildlife authority", "6.84", "-21.75"], ["27\\. Soroti Fruits Limited -1513 -1590.2", null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], "page": 69, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["No.", "Entity", "Return on Asset (%)", "None"], "type": "table"}}, {"content": "c) Dividends \nI noted that, only Uganda Property Holdings Limited and Housing Finance Bank Limited proposed a dividend pay-out of, UGX 400,000,000 and UGX 1,495,222,000, respectively, in the year under review, Nile Hotel International Limited, Uganda Development Corporation (Group) and Housing Finance Bank Limited paid out dividends declared for the previous year totalling UGX. \n2,269,944,381. \nI further noted that although some companies were making significant amount of profits, they were not paying dividends to Government. \nThe enterprises attributed the non-payment of dividends to the loss-making positions and retention of funds to fund planned investments/projects. \nI advised the Accountant General to ensure that profit making enterprises provide a share of government dividend. \nd) Liquidity Assessment \nI analysed the ability of Public Corporations and State enterprises to meet their short-term financial obligations by comparing the current assets and current liabilities using the Current Ratio analysis. Generally, the ratio of Current Assets to Current Liabilities between 1.5 and 2 is desirable, although acceptable current ratios vary between different industries or sectors. \nI noted that eighteen (18) entities were above the ideal threshold, implying that they are able to meet their liabilities as they fall due. three (3) entities had ratios below 1.0 and may have a challenge of paying their obligations as and when they fall due. The table 20 below refers. \nTable 20: Enterprise Liquidity", "metadata": {"headings": [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}, [{"headings_0": {"content": "Corporation, Uganda Printing and Publishing Corporation, Insurance Training", "page": 68, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}]], "page": 69, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "Current Ratio", null], ["No", "Entity", "2020/21 26.24", "2019/20 9.9"], ["1\\. Nile Hotel International Limited 26.24 9.9", null, null, null], ["2.", "Soroti Fruits Limited", "25.7", "122.38"], ["3\\. NEC Luwero 11.9 5.1", null, null, null], ["4.", "NEC AGRO", "11.4", "2.7"], ["5\\. Uganda Development Corporation (Group) 9.3 4.3", null, null, null], ["6.", "Uganda Electricity Distribution Company Limited", "6.9", "7.4"]], "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], "page": 69, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "57", "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], "page": 69, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["7\\. Uganda Property Holding 3.9 2.5", null, null, null], ["8.", "Uganda National Airlines Company Limited", "2.7", "6.2"], ["9\\. Uganda Printing and Publishing Corporation 2.64 1.77", null, null, null], ["10.", "New Vision Printing and Publishing Company Limited", "2.6", "2.68"], ["11\\. Uganda Railways Corporation 2.6 3.09", null, null, null], ["12.", "NEC UZIMA", "2.3", "0.8"], ["13\\. Uganda Electricity Transmission Company Limited 1.9 1.66", null, null, null], ["14.", "NEC Constructions Construction Works and", "1.4", "1.3"], ["", "Engineering Limited", null, null], ["15\\. National Water and Sewerage Corporation 1.37 1.18", null, null, null], ["16.", "Uganda Wildlife Conservation education Centre", "1.3", "1.12"], ["17\\. Uganda Post Limited 1.1 1.2", null, null, null], ["18.", "Uganda Wildlife authority", "1.09", "1.93"], ["19\\. Mandela National Stadium 0.73 0.49", null, null, null], ["20.", "Kilembe Mines Limited", "0.56", "1.3"], ["21\\. Uganda Electricity Generation Company 0.43 0.53", null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], "page": 70, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "", "Current Ratio", "None"], "type": "table"}}, {"content": "In addition, I noted that the customer deposits in the four banking institutions grew to an average of UGX.344Bn up from UGX.264 Bn in the prior year. Relatedly, the loan to deposit ratio averaged to 66% up from 64% which is still desirable at individual bank rating. The Table 21 below refers; \nTable 21: Liquidity assessment for financial institutions", "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}]], "page": 70, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Institution", "Liquidity assessment for banking institutions", null, null, null, null, null, null, null], ["SN 1.", "Bank", "Current ratio", null, "CustomerDeposits/loan", null, "Net liquid assets", null, "Loan to deposit", null], [null, "N Housing 1 Finance Bank 1.45 1.44", null, null, "s", null, null, null, null, null], [null, null, null, null, "654.1 559.8 35% 31% 84.10% 98%", null, null, null, null, null], ["2.", "Pride 2 Micro", "1.62", "1.56", "174.37", "140.82", "0", "0", "105%", "80%"], [null, "Finance", null, null, null, null, null, null, null, null], [null, "", null, null, null, null, null, null, null, null], ["3\\. Post 3 Bank 1.11 1.13 0 0 0 0 74.50% 77%", null, null, null, null, null, null, null, null, null], ["4.", "Uganda 4", "6.3", "4.42", "547", "354", "0", "0", "0", "0"], [null, "Development", null, null, null, null, null, null, null, null], [null, "Bank", null, null, null, null, null, null, null, null], ["Total 10 9 1375 1055 35% 31% 264% 255%", null, null, null, null, null, null, null, null, null], ["", "Average", "3", "2", "344", "264", "9%", "8%", "66%", "64%"]], "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], "page": 70, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5", "column_6", "column_7", "column_8", "column_9"], "type": "table"}}, {"content": "I further noted that despite the low activity during the COVID-19 period, Loans and advances to customers increased on average from UGX.336Bn to UGX.405Bn in the current year. \n58 \nTable 22 : Loans and Advances performance", "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}]], "page": 70, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN Bank Prior period (UGX- Billions) Current period (UGX-Billions)", null, null, null], ["1", "Housing finance bank", "550.60", "553.50"], ["2 Pride Micro Finance 171.76 183.39", null, null, null], ["3", "Postbank", "267.00", "334.70"], ["4 Uganda Development Bank 354.00 547.00", null, null, null], ["", "Average", "335.84", "404.65"]], "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], "page": 71, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "The performance of the 4 institutions was commendable. e) Interest cover \nI analysed the interest cover of Public Corporations and State enterprises that had taken loans to establish their ability to service the loans through payment of interest. Interest cover looks at how many times a Company\u2019s operating profits exceed its interest payable. A cover of two (2) times and above is usually considered to be safe, depending on the nature of industry. The implication is that a company is most likely to meet its interest payments. \nI noted that of the 3 companies/enterprises which were financing loans, two (2) (NWSC and the Insurance Training College) were better placed to meet their interest obligations, while the New Vision Printing and Publishing Company Limited was not. The Table 23 below refers. \nTable 23 : Enterprises' ability to service loan obligations", "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}, [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}]], "page": 71, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["No. Entity Profit Before Interest Interest (Financing cost) Interest Cover (No. of times) (2020/21 Interest Cover (No. of times) (2019/20", null, null, null, null, null], ["1", "National Water and", "18.68", "6.95", "2.7", "28.3"], ["", "Sewerage", null, null, null, null], [null, "Corporation", null, null, null, null], ["2 New Vision Printing and Publishing Company Limited (0.34) 0.59 -0.6 28.2", null, null, null, null, null], ["3", "Insurance Training", "2.42", "1.06", "2.30", "0.001"], ["", "college", null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "2,269,944,381.", "page": 69, "level": 2}}], "page": 71, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5"], "type": "table"}}, {"content": "- Some successful candidates did not take up the job offers because the contract period was limited to only 18 months as recommended by Ministry of Public Service.", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Ministry of Public Service and Solicitor General guided that recruitment of staff for the agencies affected by rationalization should only be for a period up to June 2023.", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}]], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The employment contracts should contain a disclaimer clause to the effect that the employment can be terminated any time without recourse.", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- There is no guarantee of retention of the workforce.", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "The above situation has affected the agencies also in other areas of planning, execution of activities and implementation of the new NDP III strategic plans. \n62 \nI advised Government to fast-track implementation of the policy with a view of ensuring that the on-going rationalization activities are finalized in the shortest time possible to avoid further disruptions in the operations. \n3.3.2. Over dependence on the Public Private Partnership in the Cotton sector \nSection 5 (i) of the Cotton Development Organisation Act, vests the duty to facilitate cotton production, cotton research and extension through the Ministry responsible for \nagriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and \nprocessing of cotton and represent all aspects of the cotton subsector. \nOver the last 11 years, the Private Sector (Ginners) under their umbrella body Uganda Ginners and Cotton Exporters Association (UGCEA), have been supporting cotton production activities under the Cotton Production Support Program through a Memorandum of Understanding that is signed annually between CDO and UGCEA. The Program, using funds pooled voluntarily by UGCEA members into the Cotton Development Fund (CDF), supports a variety of activities which aim to assist cotton farmers in Uganda to increase cotton production and productivity through; provision of inputs, farmer mobilization and sensitization, extension services and agricultural mechanization. \nIt was noted that UGX.19.649Bn was budgeted to cater for the cotton marketing season 2020/21 out of which, UGX.15.154Bn was budgeted towards provision of planting seed and production inputs. Government was able to contribute only UGX.8.6Bn leaving the balance for the private partner intervention. This is an indication that government is relying more on the ginners to fund the cotton sector. \nDespite the intervention by the private sector, there were shortages in provision of inputs to farmers. From table below, 866 Mt of planting seed, 374.6 Mt of fertilizers and 2,260 spray pumps were not provided as projected in the strategic plan despite the support from the Ginners which directly affected the performance of the sector in achieving the desired cotton production targets. \nTable 24 : Comparison of consolidated quantities of production inputs", "metadata": {"headings": [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}, [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}], [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}], [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}], [{"headings_0": {"content": "3.2.1.", "page": 74, "level": 2}}], [{"headings_0": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}], [{"headings_0": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}], [{"headings_0": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}], [{"headings_0": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}], [{"headings_0": {"content": "agriculture to CDO. CDO\u2019s mandate is to promote production, monitor marketing and", "page": 75, "level": 2}}], [{"headings_0": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}]], "page": 74, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Planting", "Pesticides", "Fertilizers", "Spray", "Herbicides"], ["", "seed", null, null, "pumps", null], ["Production inputs needed(Strategic Plan) A 3,200 Mt 222,000 liters 415 Mt 7,000 0", null, null, null, null, null], ["Planned Quantities (MOU-", "2,500Mt", "224,000", "746 Mt", "3,000", "7,500 liters"], ["Ginners) B", null, "liters", null, null, null], ["Actual Quantities provided (Reports) C 2,334 Mt 287,102 liters 40.4 Mt 4,740 6,616 liters", null, null, null, null, null], ["Difference A - C", "866 Mt", "(65,102)", "374.6 Mt", "2,260", "(6,616)"], ["", null, null, null, null, "Liters"]], "metadata": {"headings": [{"headings_0": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}], "page": 75, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4", "column_5"], "type": "table"}}, {"content": "Source: OAG analysis of CDO Strategic Plan 2020/21-20, MOU, quarterly reports \n63 \nDependency on the Private sector for a key production activity such as provision of seed for planting and production inputs, risks the sustainability of the sector and enables the private sector to exercise influence over farmers through paying of low prices for the \nfarmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in \nkey aspects such as targeted extension services for mobilizing farmers and training them on cotton agronomical practices using demonstration gardens established at village/parish level.", "metadata": {"headings": [{"headings_0": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}, [{"headings_0": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}], [{"headings_0": {"content": "Table 24 : Comparison of consolidated quantities of production inputs", "page": 75, "level": 3}}], [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}], [{"headings_0": {"content": "farmers\u2019 crops. Further, inadequate Government funding limits CDO\u2019s interventions in", "page": 76, "level": 2}}]], "page": 75, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SN", "Information system", "Purpose", "Entity", "Cost (Bn)"], ["1", "Prosecution Case", "Record and collect information", "ODPP", "26.188"], ["", "Management", "pertaining to cases, and rapidly transfer", null, null], [null, "Information System", "case details from law enforcement", null, null], [null, "(PROCAMIS)", "across the DPP offices.", null, null], ["2 Court Case Administration System (CCAS) Receiving and allocating cases to different Judicial officers for further management. Judiciary No information", null, null, null, null], ["3", "The Electronic Court", "Manage case records, e-filing. The", "Judiciary", "9.277"], ["", "Case Management", "system tracks all aspects of a case life", null, null], [null, "Information System", "cycle from initial filing through", null, null], [null, "(ECCMIS)", "disposition up to appeal.", null, null], ["4 Prisoners Management Information System(PMIS) Recording and classifying of all prisoner related information across all the prisons. Prisons 0.501", null, null, null, null], ["5", "Crime Records", "Automate all paper based processes of", "Uganda", "0.5"], ["", "Management System", "case management.", "Police Force", null], [null, "(CRMS)", null, null, null], ["6 Suspect profiling systems Capture profiles of suspects such as bio data, photographs, and thumbprints among other features, to help in quick identification of suspects. Uganda Police Force No information", null, null, null, null], ["", "TOTAL", "", "", "36.466"]], "metadata": {"headings": [{"headings_0": {"content": "3.4.1.", "page": 77, "level": 2}}], "page": 77, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "- Management of scholarships at the Ministry of Education and Sports is not supported by a Scholarship Policy, thus the country lacks policy direction in regard to sourcing, accepting, allocation and monitoring of scholarships.", "metadata": {"headings": [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}, [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}]], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Ministry of Education and Sports still holds the mandate of managing Government scholarships contrary to Section 42(1) of the", "metadata": {"headings": [{"headings_0": {"content": "Board.", "page": 89, "level": 2}}], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s \nmandate. \n", "metadata": {"headings": [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}, [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}], [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}]], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- Information on Scholarship offered at the different Missions and other Government organizations was not readily available at the Secretariat.", "metadata": {"headings": [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Low uptake of scholarships was noted whereby out of a total of 280 scholarships offered to government in the previous three years, only 162 were filled resulting into an under absorption of 118 (42%) scholarships.", "metadata": {"headings": [{"headings_0": {"content": "Higher Education Students Financing Act which revoked the Committee\u2019s", "page": 90, "level": 2}}], "page": 90, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "iii) I that out of the expected 16 monitoring reports in the four-year period ending 30 th June, 2020, only 4 (25%) were prepared in the entire four-year period. In addition, NFA budgeted to receive UGX.320m for monitoring in the four years under review, but only UGX.91.8million (29%) was released, and the entity spent UGX 88.8million over the period on monitoring activity. Furthermore, there were limitations in discussing and implementing monitoring report recommendations, and as a result, there were instances in which management did not demarcate the area as recommended by the M&E report before restoring the forest. This led to destruction of the newly restored forests by encroachers. \nI established that seventeen (17) MOUs were signed with different government agencies, out of the planned twenty (20), representing an 85% performance. Although these collaborations contributed to the restoration and establishment of new plantations, there were inadequacies in providing the planned quantity of seedlings. In addition, twenty (20) out twenty-eight (28) Collaborative Forest management (CFM) agreements were signed with forest edge communities. \n80 \nI advised the Accounting Officer to improve on the Planning, Budgeting, Coordination and Collaborations, Monitoring aspects, and prioritization of fixed resources required in the restoration and establishment of forest cover in the country. \n3.12. WORKS SECTOR \n3.12.1. Uganda National Roads Authority \na) \nLoss of funds in interest on delayed payment of contractors \nThe Authority incurred wasteful expenditure to a tune of UGX.17Bn in form of interest and penalties due to delayed settlement of invoices from contractors. This was a loss to Government. The Accounting Officer explained that interest costs arise due to inadequate funding for the road development and maintenance projects that UNRA is managing. I advised the Accounting Officer to enhance the Authority cash flow management by rationalizing available resources, especially reduction of advances \npayments to settle outstanding claims and to improve the Authority\u2019s budgeting process \nand liaison with relevant authorities such Parliament and Ministry of Finance for adequate financial resource allocation. \nb) \nDelayed road projects and accumulation of commitment fees", "metadata": {"headings": [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}, [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}], [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}], [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}], [{"headings_0": {"content": "Forest reserves. The country\u2019s forest cover reduced from 24% (4,933,271ha) in 1990 to", "page": 92, "level": 2}}], [{"headings_0": {"content": "3.12.1. Uganda National Roads Authority", "page": 93, "level": 4}}], [{"headings_0": {"content": "a)", "page": 93, "level": 2}}], [{"headings_0": {"content": "a)", "page": 93, "level": 2}}], [{"headings_0": {"content": "a)", "page": 93, "level": 2}}], [{"headings_0": {"content": "payments to settle outstanding claims and to improve the Authority\u2019s budgeting process", "page": 93, "level": 2}}], [{"headings_0": {"content": "payments to settle outstanding claims and to improve the Authority\u2019s budgeting process", "page": 93, "level": 2}}], [{"headings_0": {"content": "b)", "page": 93, "level": 2}}], [{"headings_0": {"content": "b)", "page": 93, "level": 2}}]], "page": 92, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "By 30 th June 2021, 35 road projects under UNRA with a total contract value of USD.398,427,063.99 and UGX.149,739,813,845 had been delayed. These 35 projects were to be completed during the year were behind schedule as per their work programme still on-going by the close of the year. The delays which ranged from 64 days (about two months) to 1,072 days (about two months three years) days were majorly attributed to: inadequate mobilization by some contractors, abnormal rains, delayed acquisition of Right of Way and the effects of COVID-19 that resulted into nationwide lockdown. I computed commitment fees on only two projects (Busega-Mpigi- UGX.7,1140,345,245) and RSSPV (UGX.3,079,241,588) and observed an accumulation of total commitment fees amounting to UGX.10,219,586,833 in only one year alone. \nThe Accounting Officer explained that the delay to complete the projects was due to a number of factors that included; inadequate mobilization by some contractors, abnormal rains, delayed acquisition of Right of Way and the effects of COVID-19 that resulted into nationwide lockdown. I advised the Accounting Officer to always ensure that projects are completed within the agreed timelines. \nc) \nDelayed compensation for Project Affected Persons and Acquisition of Right of Way for Road Projects (Projects- Kampala Jinja Expressway, Hoima Wanseko)", "metadata": {"headings": [{"headings_0": {"content": "b)", "page": 93, "level": 2}}, [{"headings_0": {"content": "b)", "page": 93, "level": 2}}], [{"headings_0": {"content": "c)", "page": 93, "level": 2}}], [{"headings_0": {"content": "c)", "page": 93, "level": 2}}]], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "I observed delays in compensation of Project Affected Persons and hence Acquisition of the Right of Way. The majority of Project Affected Persons are compensated beyond the stipulated six-month period after approval of the Valuation Reports by the Chief Government Valuer. For the KJE Project, the construction works are planned to commence in January 2022. However, 21% of the approved compensation amount worth UGX.92,571,144,970 has not yet been paid, with less than 6 months to the scheduled commencement date which is likely to impede timely handover of the project corridor and timely commencement of works. In addition, compensation for properties within volume 5 comprising Kasokoso area had not yet been assessed. \n81 \nThe Accounting Officer explained that a number of issues caused the delays for compensations, such as; lack of proper ownership documents, for example; sales agreements, letters of administration, ownership disputes especially for untitled interests like Kibanja or customary land, absentee landlords, and; rejection of compensation awards by PAPs that lead to review of the complaint to ascertain validity. I advised the Accounting Officer to consider using escrow accounts with district local governments for the absentee landlords and PAPs where funds may be deposited so as to aid fast land acquisition. \n3.12.2. Ministry of Works and Transport \na) Failure to maintain district road equipment", "metadata": {"headings": [{"headings_0": {"content": "c)", "page": 93, "level": 2}}, [{"headings_0": {"content": "c)", "page": 93, "level": 2}}], [{"headings_0": {"content": "c)", "page": 93, "level": 2}}], [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}], [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}]], "page": 93, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The inspection of the Ministry\u2019s Regional Mechanical Workshops during August and September 2021 revealed that 21 units of district road equipment which are key in opening and maintaining district roads were left unused in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. This means that the districts that own the said equipment could not maintain their roads and deliver such critical service to the country as planned. In addition, the cost of repair may escalate as other parts also become faulty when the equipment is grounded for a long time. \nThe Accounting Officer explained that the amount budgeted and received to maintain road equipment represents 30% of the total funds required for equipment maintenance. I advised the Accounting Officer to liaise with the responsible authorities to obtain the necessary funding for the full maintenance of the equipment so that the equipment operates and serves the Districts. \nb) Delayed acquisition of land for the Right of Way for the Standard Gauge Railway project (Ministry of Works and Transport) \nThe SGR project was to acquire 5,200 acres of land free of encumbrances at an estimated cost of UGX 534.6 bn for the Right of Way (ROW) for the construction of the Kampala \u2013 Malaba SGR route by October 2016. However, by September 2021 only 1,296 acres (25%) had been acquired at a cost of UGX 95.3 bn. Additionally, the project had not obtained titles for the acquired land. There are risks of subsequent compensation for the land already paid for and failure to acquire all the land needed for the full realization of the project. \nThe Accounting Officer explained that currently, land acquisition is one of the core activities of the project. He further explained that the releases however have been going down in comparison to the annual budgets. I advised the Accounting Officer to obtain and transfer land titles to Government for the land paid for and expedite the acquisition of all the land needed for the project. \n82 \n3.12.3. Uganda Railways Corporation \na) Procurement, supply, delivery, training and commissioning of four (4) used locomotives", "metadata": {"headings": [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}, [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}], [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}], [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}], [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}], [{"headings_0": {"content": "3.12.2. Ministry of Works and Transport", "page": 94, "level": 4}}], [{"headings_0": {"content": "3.12.3. Uganda Railways Corporation", "page": 95, "level": 2}}], [{"headings_0": {"content": "3.12.3. Uganda Railways Corporation", "page": 95, "level": 2}}]], "page": 94, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "URC contracted M/S GRP Leasing Africa for the supply, delivery, training and commissioning of four (4) used locomotives under procurement reference; URC/SUPLS/2020-11/0001 at UGX.41,323,768,935. However, I noted that the bidder did not comply with some requirements within the bid document which were supposed to be the basis of evaluation. Despite the non-compliance, the bid was evaluated without following the evaluation criteria for Technical stage contrary to the regulations. Non-compliance with the evaluation criteria may have led to delivery of unsuitable locomotives at an inflated cost. Important to note was that the locomotives could not turn at the existing turning points in the country. Therefore, the Corporation will incur un-planned costs of providing turning points for the locomotives.", "metadata": {"headings": [{"headings_0": {"content": "3.12.3. Uganda Railways Corporation", "page": 95, "level": 2}}], "page": 95, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "b) Ratio analysis and financial performance of Uganda Civil Aviation Authority \nThe Authority made a loss for the year under review amounting to UGX 29,321,645,000. On review of the operating margin, I observed that the costs before considering interest and taxes exceeded revenue for the year. I also observed that due to the loss incurred, the Authority generated a negative return on assets of 5%. Further, the Authority could not cover interest accrued on its long-term loans in view of its earnings. Along with the lack of potential to cover loan interest, the Authority had a significant long term liabilities portfolio on its balance sheet, which majorly comprised of the loan from Exim of China to finance the upgrading and expansion of Entebbe International Airport. \n84 \nThe Authority\u2019s loss and the ratios computed are an indication that Uganda Civil Aviation \nAuthority did not perform well in terms of profitability and ability to sustain provision of services without further Government intervention for funding and Management strategies to improve revenue generation. The Accounting Officer explained that the performance results during the period were severely impacted by the COVID-19 situation that affected the airport operations of the Authority. \nI advised the Accounting officer to ensure that strategies are devised to improve the revenue generating potential of the Authority, while putting in place cost cutting mechanisms. I also advised the Accounting Officer to engage Government on further financing including clearance of the debt held by Government agencies, to be able to cover the current operating costs as they devise strategies to improve the earning potential of the Authority. \n3.13. HEALTH SECTOR \n3.13.1. Mulago National Referral Hospital \na) \nStatus of key medical equipment", "metadata": {"headings": [{"headings_0": {"content": "UCAA\u2019s operations, and on the possibility of transferring the loan liability from UCAA\u2019s", "page": 96, "level": 2}}, [{"headings_0": {"content": "UCAA\u2019s operations, and on the possibility of transferring the loan liability from UCAA\u2019s", "page": 96, "level": 2}}], [{"headings_0": {"content": "The Authority\u2019s loss and the ratios computed are an indication that Uganda Civil Aviation", "page": 97, "level": 2}}], [{"headings_0": {"content": "The Authority\u2019s loss and the ratios computed are an indication that Uganda Civil Aviation", "page": 97, "level": 2}}], [{"headings_0": {"content": "The Authority\u2019s loss and the ratios computed are an indication that Uganda Civil Aviation", "page": 97, "level": 2}}], [{"headings_0": {"content": "The Authority\u2019s loss and the ratios computed are an indication that Uganda Civil Aviation", "page": 97, "level": 2}}], [{"headings_0": {"content": "3.13.1. Mulago National Referral Hospital", "page": 97, "level": 4}}], [{"headings_0": {"content": "a)", "page": 97, "level": 2}}], [{"headings_0": {"content": "a)", "page": 97, "level": 2}}]], "page": 96, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Only (3) three development projects were fully implemented, i.e., shareholder's loan to Atiak Sugar Factory; Acquisition of shares in Mabale Tea Factory; and Acquisition of shares in Bukoona Agro Processors Limited.\n- Five (5) development projects were partially implemented.\n- Eleven (11) projects were not implemented at all.", "metadata": {"headings": [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}], "page": 100, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "This was attributed to the conditional release of funds tied to specified development projects and inadequate institutional capacity to appraise and implement investment projects. \nUnder-absorption undermines government effort in attaining its goals. \n88 \n3.15.3. \nUNBS Inadequate Capacity in Testing and Enforcing Commodity Standards \nSection 3(1) of the UNBS Act spells out the functions of the Bureau which, among others, include providing for the testing of locally manufactured or imported commodities with a view to determining whether the commodities conform to the standard specification as well as making arrangements or provide facilities for the examination, testing or analysis of commodities and any material or substance from which or with which and how they may be manufactured, produced, processed or treated. However, I noted; \n", "metadata": {"headings": [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}, [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}], [{"headings_0": {"content": "3.15.2.", "page": 100, "level": 2}}], [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}], [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}], [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}], [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}]], "page": 100, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UNBS released 633 consignments due to the absence of standards to test these commodities for conformity.", "metadata": {"headings": [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The Bureau also released 366 consignments without testing product standards due to lack of capacity, which may lead to sub-standard products on the market.", "metadata": {"headings": [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}, [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}]], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Bureau had staff presence at only 27 out of the 170 border entry points. This was attributed to understaffing at the Bureau.", "metadata": {"headings": [{"headings_0": {"content": "3.15.3.", "page": 101, "level": 2}}], "page": 101, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": [["Financial Year", "Approved", "Filled up", "Shortage", "Percentage shortage"], ["", "positions", null, null, null], ["2018/2019", "3,847", "2,008", "1,842", "48%"], ["2019/2020 6,797 2,713 3,823 60%", null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}], "page": 102, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": "Source: OAG analysis \nUnderstaffing overstretches the available staff beyond their capacity, creates jobrelated stress to the fewer staff and negatively affects the level of public service delivery to the community. \nThe Accounting Officers explained that staffing at LLG level is a responsibility of the respective Districts and Municipal Councils. \nI advised the Accounting Officers to follow up on the matter with the relevant authorities and ensure that most of the vacancies are filled. \n90 \n3.17.2. \nBudget implementation in sample LLGs for FY 2018/2019 and 2019/2020 \nI sampled 627 LLGs for FY 2018/19 and 250 LLGs for FY 2019/20 to assess the implementation of the budget and noted the following significant audit findings: \n3.17.2.1. Performance of Central Government Grants \nThe LLGs sampled budgeted to receive UGX.146,160,919,043 for FY 2018/2019 and 2019/2010 (revised) as Central Government Grants). However, UGX.134,095,135,622(92%) was received resulting into a shortfall of UGX.12,065,783,421(8%) majorly attributed to budget cuts as shown in the table below. \nThis affected service delivery in Lower Local Governments Table 27 : Performance of Central Government Grant", "metadata": {"headings": [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}, [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}], [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}], [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}], [{"headings_0": {"content": "2019/2020", "page": 102, "level": 2}}], [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}], [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}]], "page": 102, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Financial Year", "Revised Budget", "Actual Receipts", "Variance", "Percentage"], ["", null, null, null, "Perfomance"], ["2018/2019", "92,214,094,491", "87,717,635,886", "4,496,458,605", "95%"], ["2019/2020 53,946,824,552 46,377,499,736 7,569,324,816 86%", null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "3.17.2.", "page": 103, "level": 2}}], "page": 103, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Financial Year", "Approved", "Filled up", "Shortage", "Percentage shortage"], "type": "table"}}, {"content": "- 41 LLGs in FY 2018/19 and 24 LLGs in FY 2019/20 respectively lacked land titles, including where their headquarters are located.\n- 41 LLGs in FY 2018/19 and 24 LLGs in FY 2019/20 respectively lacked Area Lands Committees or the committees were non-functional.\n- In the circumstances, there is risk of persons trespassing, disputes and litigation.", "metadata": {"headings": [{"headings_0": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}], "page": 104, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Majority of Accounting Officers explained that it was the responsibility of the Districts or Municipal Councils to obtain these land titles. A number of other Accounting Officers cited insufficient funding as a cause for failure to have fully functional land committees \nGovernment should consider taking deliberate steps to fund the survey and titling of all government land at the Local Governments. I also advised the Accounting Officers to constitute the Area land Committees. \n92 \n3.17.5. \nLack of Urban Physical Planning Committees \nI noted that 32 Town Councils in the two financial years had no Urban Physical Planning Committees in place or the Committees were not fully functional. \nConsequently, physical developments undertaken within the physical planning areas may not have been well determined and managed by the respective LLGs. This was mainly attributed to lack of sufficient funds to operationalize the physical planning committees. \nI advised Government to engage the relevant stakeholders to nominate members and ensure that the committees are fully instituted and are functional. \n93 \nPART 4: INFORMATION SYSTEMS, ENGINEERING, VALUE FOR MONEY AND SPECIAL \nAUDITS \nDuring the financial year 2020/2021, I undertook three Information Systems audits, three Engineering audits covering 90 projects, eight Value for money audits. In addition, I undertook special and forensic audits which are reported on separately. \nBelow is a summary of the key findings I noted in each category, the details of which are included in individual reports issued separately. \n4.0. \nHIGHLIGHTS FROM THE ENGINEERING AUDITS \n4.1. Value for Money Audit and Assessment of Urban Infrastructure projects implemented by 22 Municipal Councils under the USMID-AF Program for projects started in the Financial year 2018/2019", "metadata": {"headings": [{"headings_0": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}, [{"headings_0": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}], [{"headings_0": {"content": "3.17.4. Land Management in Local Governments", "page": 104, "level": 4}}], [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}], [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}], [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}], [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}], [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}], [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}], [{"headings_0": {"content": "3.17.5.", "page": 105, "level": 2}}], [{"headings_0": {"content": "AUDITS", "page": 106, "level": 2}}], [{"headings_0": {"content": "AUDITS", "page": 106, "level": 2}}], [{"headings_0": {"content": "AUDITS", "page": 106, "level": 2}}], [{"headings_0": {"content": "4.0.", "page": 106, "level": 3}}], [{"headings_0": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}], [{"headings_0": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}]], "page": 104, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "For the financial year 2020/21 a total of 14 infrastructure projects procured in 2018/2019 under the World Bank funded Uganda Support to Municipal Infrastructure Development-Additional Financing (USMID-AF) Program implemented by 22 Municipal Councils namely Arua, Gulu, Kitgum, Lira, Apac, Soroti, Moroto, Mbale, Tororo, Busia, Kamuli, Jinja, Lugazi, Entebbe, Hoima, Mubende, Fort Portal, Kasese, Mbarara, Ntungamo, Kabale and Masaka were audited and assessment of the performance of these projects across the 22 municipalities carried out including a selected sample of non-USMID i.e. Uganda Road Fund (URF) funded projects, and Schools Facilities Grant (SFG)/Transitional Development Grant (TDG)/Discretional Development Equalisation Grant (DDEG) funded projects implemented in the participating municipalities. \nThe total contract value of the projects assessed was UGX 192,742,021,942. Below is a summary of the Key findings I noted, the details of which are included in the consolidated audit report for the 22 Municipal Councils and the 22 Individual reports issued separately; \n", "metadata": {"headings": [{"headings_0": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}, [{"headings_0": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}], [{"headings_0": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}]], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Overpayments and irregular expenditure on USMID and Non USMID projects were noted during the audit. This comprised of overpayments of UGX. 214,862,488 and UGX 459,323,494 on USMID projects and Non-USMID projects respectively. The audit assessment also revealed various questionable expenditures, irregular payments, and potential financial losses attributable to different contractual irregularities totaling to UGX. 817,571,137 on the USMID funded projects in Arua, Jinja and Mbale", "metadata": {"headings": [{"headings_0": {"content": "HIGHLIGHTS FROM THE ENGINEERING AUDITS", "page": 106, "level": 2}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Municipalities. \n", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}]], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- All the municipalities had completed their projects by the time of the audit and the entire infrastructure in the municipalities was in use with the exception of Entebbe whose project was phased. Although the projects were finally completed there were delays in completion of the projects within the stipulated contract timelines.", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- During physical inspection of the municipalities of Mbale, Moroto and Lira, major defects were noted such as missing draining/emptying pipe on the", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "94 \nsoaking tank (leads to poor drainage), Clogged manholes and missing manhole covers, potholes on roads and poor drainage leading to ponding.", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}]], "page": 106, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- All the participating municipalities implemented environmental protection measures with the exception of Arua Municipality. Further, all the participating municipalities implemented social/safety measures except Soroti and Tororo Municipalities.", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}, [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}]], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Inadequate allocation of funds in the budget for operation and maintenance of USMID infrastructure was noted in the municipalities except for the municipalities of Lira, Hoima, Fort Portal, Masaka and Gulu.", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "I advised the Accounting officers of the Municipal Councils to ensure that;", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- All amounts overpaid are recovered by the respective municipalities.\n- Contractors have updated work programs and delays in delivery of projects within stipulated contract timelines should be penalized by invoking liquidated damages clauses\n- Inspections are carried out during the DLP as some defects can only surface while the structure is in use and report on the progress of the structure during the period and have all the identified major defects rectified.\n- All municipalities should plan, budget and implement operation and maintenance activities to avoid early deterioration of the facilities.", "metadata": {"headings": [{"headings_0": {"content": "Municipalities.", "page": 106, "level": 2}}], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Conclusion \nOwing to the challenges faced by the Municipal Councils during the delivery of USMID- AF Urban infrastructure as highlighted in this report, audit observed that these challenges notable improvements have been noted in planning, cost control enforcement of internal controls for certification, supervision and monitoring, and general contract management for the USMID Infrastructure projects, however these gains have not been translated to the Non USMID projects as URF, SFG,DDEG accordingly the Town Clerks must ensure that Non USMID projects are equally effectively monitored and supervised to ensure delivery of the works within the planned cost, quality and time requirements \n4.2. \nValue for Money audit and assessment of Infrastructure projects implemented by 60 Local Governments under the UgIFT Program for Construction of Seed Schools and Health Facilities in the Education and Health Sectors \nFor the financial year 2020/21 a total of 109 infrastructure projects implemented by 60 Local Governments involving the construction of seed schools and Health centre IIs under the World Bank funded Uganda Inter-Governmental Fiscal Transfer (UgIFT) Programme for Results was audited and assessment of the performance of these projects across the 60 Local Governments municipalities carried out for the Education Sector and Health Sector. \n95 \nUnder the UgIFT programme, the World Bank committed the total of US$500m over the period FY 2018/19 to FY 2023/24 to support decentralized services in Education, Health, Water and Environment, and Agriculture (micro-scale irrigation) as well as support I \nnterventions in Refugee host communities, With this financial support, Government committed to construct Seed Secondary Schools and Upgrade Health Centre IIs to IIIs in Sub-Counties, extend rural water to underserved communities including the newly constructed seed Secondary Schools and Health Centre IIIs, and also provide Small Scale Irrigation equipment to farmers to enhance their productivity. \nThe scope of the audit and assessment covered 53 seed secondary schools\u2019 construction projects with an overall total contract sum of UGX 111,860,803,846 and 57 health centre construction projects with an overall total contract sum of UGX 33,743,610,012. \nBelow is a summary of the Key findings noted, the details of which are included in the consolidated audit report for the 60 Local Governments and the 60 Individual reports issued separately; \n", "metadata": {"headings": [{"headings_0": {"content": "Conclusion", "page": 107, "level": 2}}, [{"headings_0": {"content": "Conclusion", "page": 107, "level": 2}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}]], "page": 107, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- In assessing the adequacy of the design process for the buildings, evidence of needs assessment, presence of geotechnical investigations report, design report, drawings and specifications were considered as key requirements, it was observed that detailed design reports were not availed to all local governments by the Ministry of Education.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Overpayments and irregular expenditure amounting to UGX 3,153,351,606 was noted during payment for construction works in some of the seed schools. Furthermore, UGX 3,588,640,939 were made without providing the breakdown of work items being certified.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- During physical inspection of the Seed school infrastructure works, the participating LGs with exception of 3 LGs had defects such as honeycombing in concrete, absence of anti-sag rods, cracks in the ceilings, absence of expansion joint in the ICT blocks, exposed steel reinforcement, inadequate painting in the roof structures.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "The observed defects, if not addressed, will result in increased maintenance costs for the local governments.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- In assessing the adequacy of the design process for the buildings, evidence of needs assessment, presence of geotechnical investigations report, design report, drawings and specifications were considered as key requirements. It was observed that 39 local governments did not carry out needs assessment, geotechnical investigations, produce design reports in addition work specifications were also omitted.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}]], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Overpayments and irregular expenditure totalling to UGX 920,905,442 were noted during payment for construction works of the Health Centre IIs in LGs and municipalities. Furthermore, UGX 209,175,652 were made without providing the breakdown of work items being certified.", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "96 \n\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under \nconstruction of HCs revealed that out of the 56 local governments, only the 4 local governments had evidence that the contractors mobilized all required equipment. Further, only 13 local governments had evidence that the contractors mobilized all required equipment under the construction of seed schools. \n", "metadata": {"headings": [{"headings_0": {"content": "4.2.", "page": 107, "level": 3}}, [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}]], "page": 108, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Review of land ownership revealed that 7 local governments did not avail any evidence of acquisition or ownership of the land on which the Seed schools and health centres were constructed.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "I advised the Accounting officers of the Local Governments to ensure that; \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}]], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Prior to implementation of any infrastructural projects of similar nature; all due design procedures such as needs assessment, geotechnical investigations are undertaken and documented by the local governments to facilitate adequate designs.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Overpayments in respect of quantities certified in excess of the actual works executed worth UGX. 3,153,351,606 in the Education Sector and UGX. 920,905,442 in the Health Sector should be recovered. In addition, the technical officers should review the other items that were not part of the audit sample and have additional checks in the certification process to minimise the errors in quantification.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Investigate the basis of payment of the questionable amounts totalling to UGX.3,588,640,939 in the Education Sector and UGX.209,175,652 in the Health Sector and take appropriate action.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- Enforce the requirement for contractors to fully mobilize adequate equipment to undertake the works. In addition, any demobilization during contract implementation should be with the written approval of the project manager/supervisor.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- All the defects/omissions observed should be corrected. Furthermore, additional inspection of the contractor\u2019s works should be undertaken and any defects identified remedied immediately.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}, [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}]], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Fast track the process of obtaining formal ownership of the land on which the infrastructure is being constructed. Going forward, Accounting Officers should ensure that projects of similar nature are constructed on land that is formally owned by the respective local government.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Review of the status of the contractors\u2019 equipment mobilization under", "page": 109, "level": 2}}], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Conclusion \nOwing to the challenges faced by the various local governments during the delivery of UgIFT infrastructure projects in the education and health sectors as highlighted in this report, audit observed that these challenges are a result of gaps/weaknesses in the planning and costing of works, enforcement of internal controls for certification, supervision and monitoring, and general contract management. \n97 \nAccordingly, the relevant stakeholders should enhance the capacities of the local governments through involvement of local governments in the planning for future projects of similar nature, organizing tailor made trainings for technical staff, review of the staff structure in the engineering department and ensure that it is adequate and appropriately staffed. The relevant ministries should develop standardized guidelines for costing of civil works and strengthen the monitoring and supervision role in local governments. \n4.3. \nEngineering Audit of Selected Road and Building Projects in Kampala Capital City Authority (KCCA) \nFor the financial year 2020/21, a total of 24 public works projects (Road upgrade/rehabilitation, signalization of road junctions, and building projects) with a total contract sum/value of UGX.333.72tn were implemented by KCCA. A sample of Eight (8) projects (road, signalization and building projects) with a contract value of UGX. 276.92tn. were selected for audit. This sample represents 82.98% of the value of the 24 projects. \nEight (8) of the KCCA projects were sampled for audit comprising of three (3) road projects funded by the World Bank under the Second Kampala Institutional and Infrastructure Development Project (KIIDP 2) and five (5) projects funded by the Government of Uganda (GoU). The five projects funded by GoU comprised of three (3) road upgrading/ rehabilitation projects and two (2) building projects, the following key observations were noted on these projects \ni. \nDelayed relocation of existing services", "metadata": {"headings": [{"headings_0": {"content": "Conclusion", "page": 109, "level": 2}}, [{"headings_0": {"content": "Conclusion", "page": 109, "level": 2}}], [{"headings_0": {"content": "Conclusion", "page": 109, "level": 2}}], [{"headings_0": {"content": "Conclusion", "page": 109, "level": 2}}], [{"headings_0": {"content": "4.3.", "page": 110, "level": 3}}], [{"headings_0": {"content": "4.3.", "page": 110, "level": 3}}], [{"headings_0": {"content": "4.3.", "page": 110, "level": 3}}], [{"headings_0": {"content": "4.3.", "page": 110, "level": 3}}], [{"headings_0": {"content": "i.", "page": 110, "level": 2}}], [{"headings_0": {"content": "i.", "page": 110, "level": 2}}]], "page": 109, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "Delayed relocation of existing utilities for water and power for the three KIIDP road projects of Kulambira ring road 4.82Km, spur to Najjera road 0.7Km, Nakawa Ntinda road 2.8Km, Kabuusu \u2013Bunamwaya \u2013 Lweza road 8.06Km and Lukuli road 7.71Km resulted in significant delays in execution of road works by up to 17 months. The Accounting Officer explained that public utility services by Statutory Undertakers (UMEME, NITA, UG POLICE, NWSC and UTL) in particular Kampala City are so complex that even the owners/operators do not know the exact location of their infrastructure, In addition, obtaining of shut-down permits from UMEME was always delayed as UMEME had to fit request within their planned shutdown programme. \nI advised the Accounting Officer to ensure that relocation of services is implemented in time, and works executed as per the approved work programme. \nii. \nUnjustified and overpayments amounting to UGX 1.355Bn \nIt was noted that on some of the projects, payments equivalent to UGX.1.355Bn had been made for quantities of works in excess of those executed, not backed up by the necessary payment supporting documentation or contrary to the contract conditions as follows; \n98 \nTable 29 : Unjustified Payments and Overpayments", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 110, "level": 2}}, [{"headings_0": {"content": "i.", "page": 110, "level": 2}}], [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}], [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}], [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}], [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}], [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}]], "page": 110, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["S/No", "Project Name", "Payment (UGX)", "Remarks"], ["1", "Upgrading to Paved Standards of", "80,849,062", "Payment of Unverified"], ["", "Kulambiro Ring Road (4.82km)", null, "NITA Relocations"], [null, "including Spur to Najjera Road 503,716,979.38 Unaccounted for Payments", null, null], [null, "(0.7km), Reconstruction and of for relocation of", null, null], [null, "Dualling of Nakawa Ntinda Road services", null, null], [null, "(2.8km) (Including Signalization of", "215,992,827.81", "Payments for quantities of"], [null, "Four Junctions) and Reconstruction", null, "works in excess of those"], [null, "and Widening of Acacia Avenue", null, "executed"], [null, "(1.45km) (including Signalization of", null, null], [null, "Six Junctions) \u2013 Lot 1", null, null], ["2 Upgrading to paved standard of Kabuusu \u2013Bunamwaya \u2013 Lweza road (8.06Km) \u2013 Lot 2 56,860,150 Irregular Payment for Costs due to Extension of Time 348,214,079.83 Payments for quantities of works in excess of those executed", null, null, null], ["3 Upgrading of Cecila Road (1.3Km) 14,074,910 Payments for quantities of works in excess of those executed", null, null, null], ["4", "Construction of Kitintale Market \u2013", "119,717,000", "Payments for quantities of"], ["", "Phase I", null, "steel reinforcement in"], [null, "", null, "excess of those in the bar"], [null, null, null, "bending schedule"], ["5 Reconstruction of Ntinda II Road 16,213,200 Payments for quantities of works in excess of those executed", null, null, null], ["TOTAL", null, "1,355,638,209", ""], ["", null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}], "page": 111, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "I advised the Accounting Officer to ensure that the amounts certified and paid in excess of the quantities executed, unaccounted for payments and irregular/unjustified payments are recovered from the contractors prior to concluding the contracts. \niii. \nDelayed Land Acquisitions for the KIIDP Road projects", "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 110, "level": 2}}, [{"headings_0": {"content": "iii.", "page": 111, "level": 2}}], [{"headings_0": {"content": "iii.", "page": 111, "level": 2}}]], "page": 111, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Has unlimited access to the application that is used to process the PUSATI information.\n- Has control over the AIMS database and operating system environment\n- Has the only Administrator privileges on the AIMS for all the PUSATIs.\n- Issues access rights to the AIMS system users.", "metadata": {"headings": [{"headings_0": {"content": "Data Ownership of the AIMS", "page": 115, "level": 2}}], "page": 116, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- Despite investing substantial amounts of money in the land system, the land registration processes are largely still manual and no transactions take place without a manual file.", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The system encourages rampant use of agents; sometimes, titles change hands four times before getting to the registrar.", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}, [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}]], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Currently, changes on land titles are effected using manual typewriters, which are prone to error and waste time due to a requirement of scanning out to capture the manual changes.", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- There is no mechanism of communication to clients whose titles are ready; I noted that there are a number of duplicate copies of titles that have not been picked by clients, some as far back as 1997.", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The system does not provide for functionality to perform electronic printing and sealing of land titles as a security feature in the certificate of titles.", "metadata": {"headings": [{"headings_0": {"content": "Implementation of the National Land Information System Infrastructure", "page": 117, "level": 2}}], "page": 118, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": [["SN", "Item", "Amount - UGX"], ["1", "Consolidated Tax Liability (PAYE, Local Exercise,", "9,786,780,845"], ["", "Withholding Tax, Value Added Tax)", null], ["2 UCC liability 62,469,304,749", null, null], ["3", "UCECPS liability", "2,353,904,321"], ["4 Verified Creditors Liability (Pre & Post Administration period) 63,079,412,417", null, null], ["5", "Un remitted NSSF Deductions", "15, 462, 575,874"], ["6 UTL Pension Liability for former UPTC employees 165,048,246,917", null, null], ["", "Total", "302,737,649,249"]], "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 120, "level": 3}}], "page": 120, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "I noted that creditors worth UGX. 28.74Bn were not verified due to insufficient information and creditors totalling to 336.3Bn were subject to court proceedings and therefore not verified. \n108 \nThe Government should explore ways of settling the above liabilities to avoid litigation and associated costs. \niii. Verification of Non-Current Assets \nThe current estimated value of UTL Non-Current Assets is UGX.184Bn which was computed based on independent valuers reports of M/s Bageine and Company (September 2017) and Elite Realty Limited (June 2018). Adjustments were made for depreciation and disposals since the valuation date to arrive at the current estimated value. There is need for re-valuation by the Chief Government Valuer to ascertain the current market values.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, [{"headings_0": {"content": "i.", "page": 120, "level": 3}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}]], "page": 120, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "In addition, UTL has a 9.13% shareholding in a company (i.e. WIOCC) which was valued between USD.146.2 \u2013 181.2 million, by an independent valuer commissioned by WIOCC in December 2020. The Administrator further informed me of an ongoing offer by an equity investor into WIOCC, who has valued the company at USD.171 million by the time of my verification. This would imply that the UTL shareholding of 9.13% in WIOCC, could be valued at USD.15.61 Million (i.e. approximately UGX.55.45Bn exchanged at UGX.3,551.71 for one USD), as of 30th June, 2021. This would significantly increase the value of total assets of UTL. \nThere are disputes on ownership of 11 Properties worth UGX.57.5Bn between Uganda Telecom Limited (UTL), POSTA (U) Ltd, Uganda Broadcasting Corporation (UBC), and other entities. \nGovernment should consider resolving the disputes before liquidating the company. iv. Verification of Receivables \nReceivables totalling to UGX.113.65Bn were presented for verification. Due to time limitations and sensitivity of the matter, I could not verify receivables, however the process of verification had commenced under the administrator. I await the outcome of the verification exercise. \n6.2. \nVerification of Terminal Benefits/Pension of former Employees UPTC in Respect of Civil Appeal No. 230 Of 2013 And No.10 Of 2014 Of The Court Of Appeal Of Uganda \nI undertook a country wide verification exercise of 1,837 former employees/ claimants of the defunct Uganda Posts and Telecommunications Corporation (UPTC) in accordance with the orders of the Court of Appeal in respect to Civil Appeal No. 230 of 2013 and No. 10 of 2014. \nBelow are my findings; \nThe claims presented for verification in the actuarial report as at 30 th June 2020 and are summarized in the Table 31 below; \n109 \nTable 31 : Summary of claims presented for Verification", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 120, "level": 3}}, [{"headings_0": {"content": "i.", "page": 120, "level": 3}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}], [{"headings_0": {"content": "i.", "page": 120, "level": 3}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}]], "page": 121, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["S/N", "Entity", "Total No. of Claimants", "Claim Amounts as at 30 th June"], ["", null, null, "2020 - UGX"], ["1", "UTL", "1,065", "200,444,057,531"], ["2 UPL 348 35,249,791,537", null, null, null], ["3", "PBUL", "8", "135,780,242"], ["4 UCC 11 691,361,961", null, null, null], ["5", "UPTC", "71", "9,638,276,645"], ["Total 1,503 246,159,267,916", null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}], "page": 122, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "I verified the claims presented and summarized the findings per entity as presented below; \ni. Verified Claims \u2013 UGX.213,026,888,318 \nThe total verified amount of UGX.213,026,888,318 is payable to 1,254 claimants under UTL (in-Administration), Uganda Posts Limited (UPL) and the defunct UPTC as summarised in the Table 35 below; \nTable 32 : Summary of Verified claims payable", "metadata": {"headings": [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}, [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}], [{"headings_0": {"content": "6.2.", "page": 121, "level": 2}}], [{"headings_0": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}]], "page": 122, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["S/N Entity Total No. of Claimants Total claimants verified Total Amount Verified Payable as at June 2021- UGX", null, null, null, null], ["1", "UTL", "1,065", "882", "165,048,246,917"], ["2 UPL 348 337 43,233,738,001", null, null, null, null], ["3", "UPTC", "71", "35", "4,744,903,400"], ["Total 1,484 1,254 213,026,888,318", null, null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "Table 32 : Summary of Verified claims payable", "page": 122, "level": 3}}], "page": 122, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3", "column_4"], "type": "table"}}, {"content": [["S/N", "Project Name", "Amount Invested as at 30 th June", "Challenge"], ["", null, "2020 (UGX in Bn)", null], ["01", "Soroti Fruit factory", "23.76", "Additional machinery was"], ["", null, null, "procured to cater for the user"], [null, null, null, "needs not identified at planning"], [null, null, null, "stage"], ["02 Kigezi Highland 14.03 Additional funds to support raw material uptake leading to project cost-overruns", null, null, null], ["03", "Mabale Tea Factory", "16.6", "Change of user needs during"], ["", null, null, "implementation"], ["04 Kayonza tea factory 14.06 Project performance is satisfactory however, the objective of the investment decision on the part of Government is yet to be realised.", null, null, null], ["05", "Atiak Sugar factory", "88.8", "Inadequate inputs to match the"], ["", null, null, "factory capacity"], ["Total 157.25", null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}], "page": 124, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2", "column_3"], "type": "table"}}, {"content": "Management should improve implementation processes by ensuring that guidelines are in place, and that sufficient staffing is deployed. Additionally, the institution should lobby for a \u2018Fund-based\u2019 financing approach of the institution, instead of \u2018projectised\u2019 financing where funds are sent to UDC already tagged to an investment project to be funded. This will allow flexibility during implementation of investment projects. \n112 \niii. Monitoring and Evaluation \nI noted that the oversight role in all the eight sampled investment projects had not been fully undertaken and thus, the projects were not operating at full capacity as expected. This was greatly attributed to weak governance structures and non-existing/inadequate Boards in those investment projects supported as partnership ventures. This ultimately caused delays in decision making, financing and signing of contractual agreements. \nUDC management should improve the monitoring and oversight role in the government investments by ensuring that the monitoring frameworks are established and followed- up at both management and Board levels. \nOverall Conclusion", "metadata": {"headings": [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}, [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}], [{"headings_0": {"content": "7.0. HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS", "page": 123, "level": 4}}]], "page": 124, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Engage all relevant stakeholders to ensure sustainable coordination and comprehensive planning initiatives to enhance mainstreaming efforts to increase forest cover in the country.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}], "page": 127, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}], "page": 127, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Improve on its collaboration and sensitization efforts with all stakeholders to protect all forest land and undertake a process of titling all gazetted forest reserves and national forests to curb illegal encroachment. The National Land Information System (NLIS) should include control measures to prevent illegal titling of gazetted forest land.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}], "page": 127, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- Continue engaging the relevant Government authorities to fast-track the revision and approval of the NFA organizational structure, to enhance the institutional capacity to manage national forests.", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}], "page": 127, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nOverall Conclusion \nWhereas the National Forestry Authority has undertaken specific interventions aimed at increasing forest cover through restoration and establishing new plantations; inadequate coordination, planning, monitoring, collaboration with communities have led to a limited increase in the NFA forest cover over the years. In some instances, increased encroachment, land encumbrances through issuance of title over the NFA land, limited community sensitization and involvement, inadequate prioritization of restoration and new forest establishment have contributed to the dismal 45.8% forest cover under NFA and national cover of 12.3%. \nIt is hoped that despite the increased population that is exerting pressure on the rather limited national forest cover, the lessons learnt and recommendations will be applied to fulfil the objectives of the NFA, forest sector and country. \n7.3. \nA Value for Money Audit on the Implementation of the Uganda Women Entrepreneurship Programme by the Ministry of Gender, Labour and Social Development (MGLSD) \nI undertook a Value for Money to assess the extent to which the Programme achieved its intended objectives. \nThe Uganda Women Entrepreneurship Programme (UWEP) is an initiative of the Government of Uganda that is aimed at empowering women to improve their income levels and their contribution to economic development; by improving their access to financial services and equipping them with skills for enterprise growth, value addition and marketing of their products and services. \nThe Programme has disbursed UGX.107 Bn to 11,256 women groups, benefitting over 135,000 women, over the five-year period (2015/16 to 2019/20) in the first Phase. The \n115 \nprogramme through its revolving fund recovered over UGX.16 billion from the loans disbursed to the women which funds were available for financing new women groups. \nDespite the achievements registered, the audit identified the following areas that need to be addressed by the Ministry;", "metadata": {"headings": [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}, [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 126, "level": 3}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}]], "page": 127, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that 4,185 women had benefited from the Programme under the capacity and skills development component, which translates into 42% of the desired target (10,000 women) according to the UWEP Programme document.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- There were delays in disbursement of funds to the women groups. In some cases, the delays were more than 12 months from time of approval of the applications to receipt of the funds which affected the performance and success of enterprises, specifically those in the agricultural sector, which depend on the rainy seasons for planting. The delays impact on agricultural yields.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}]], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted budget cuts for women groups at the MGLSD level (TSU) with some groups receiving less than budgeted funds to implement their enterprises; however, at the Local Government level, explanations for the budget revisions were not effectively communicated to the groups; which hindered implementation of activities of women groups.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Funds to the tune of UGX 16 Bn remained idle on the recovery account in Bank of Uganda over the five years. Only 6% (UGX 963 million) of the amount had been re- disbursed; which denied the other qualifying women groups access to funds.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The MGLSD through the UWEP Technical Support Unit did not effectively plan for and coordinate implementation of the activities to facilitate women groups to access markets for their products. In addition, access to appropriate technologies were not catered for in the project design and budgets for the entire 5-year period. The intended objective of the funds disbursed may not be fully realised.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- There was underfunding of monitoring and supervision activities at the Local Government level which affected the frequency of monitoring of beneficiary women groups. The programme gaps at enterprise level could not be adequately identified and corrected on time.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- At the National level, the Technical Support Unit (TSU) undertook only 13 (43%) of the planned 30 monitoring and supervision visits to the regions throughout the five- year period. This resulted in delayed identification of performance gaps and timely remedial actions.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nKey Recommendations \nI advised management to do the following; \n", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}]], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Prioritize the capacity and skills development component of the Programme through increased sensitization to ensure that women groups receive the required skills to", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "116 \neffectively implement selected enterprises. In addition, consider reviewing the funding programme requirements to make training a prerequisite for all groups venturing into value addition enterprises for the first time.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}]], "page": 128, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The programme implementation guidelines should be reviewed to reduce on the time taken between approval and disbursement to improve timely access to funding to the groups. All budgetary cuts should be communicated to beneficiary women groups in time.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 129, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}]], "page": 129, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The MGLSD should ensure that the funds recovered are revolved in a timely manner to benefit the intended women groups, and ensure sustainability of the Programme.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 129, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The MGLSD should liaise with MoFPED to mobilise funds to cater for value addition, and monitoring and evaluation activities within the programme.", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], "page": 129, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nOverall Concluion \nUWEP exceeded its target in attracting 100,000 women beneficiaries over the five year period and managed to put in place implementation guidelines and training of beneficiaries and implementing partners. \nHowever, utilization of funds from the programme\u2019 revolving fund and equipping beneficiaries with value addition and skills for enterprise growth was found to be \nunsatisfactory and merits Management\u2019s urgent intervention. \nThe overall prospects of the programme are promising if the challenges of rationalization of the programme funding; delayed funding of beneficiaries; limited focus on skills and capacity development; inadequate coordination of partnering institutions; are addressed. \n7.4. A Value for Money Audit Report on the Management of Research Grants by Public Universities in Uganda \nResearch is any type of systematic investigation, testing and evaluation whose objective is to discover new facts or information and increase the stock of knowledge. It generates new knowledge, which is critical for sustained economic growth and social transformation of Nations. \nAccording to Section 24(2)(a) of the Universities and other Tertiary Institutions Act, 2001 (as amended), a Public University has a function of provision of higher education, promotion of research and advancement of learning. Research is a costly activity and often relies on grants to supplement the existing financial resources. Research grants enable the research community within the Universities to thrive in knowledge sharing and to use research towards solving community-based problems. \nOwing to the different challenges in the management of research grants at public universities which is characterised by poor rankings of the universities at continental and world level, and less innovation products from the public universities, the Office of the \n117 \nAuditor General undertook an independent assessment of the management of research grants by Public Universities. \nThe overall audit objective was to assess the adequacy of management of research grants in achieving grant management objectives in Public Universities in Uganda. The audit adopted a case study approach whereby 4 out of the 9 Public Universities in Uganda were considered as cases for the study, these included; Makerere University, Mbarara University of Science and Technology (MUST), Kyambogo University and Busitema University. Below is a summary of key findings and recommendations, the details are found in the subsequent part of the report; \nKey Findings \ni. \nInstitutional framework for coordination of research grants activities", "metadata": {"headings": [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}, [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "7.3.", "page": 127, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], [{"headings_0": {"content": "unsatisfactory and merits Management\u2019s urgent intervention.", "page": 129, "level": 2}}], [{"headings_0": {"content": "i.", "page": 130, "level": 3}}], [{"headings_0": {"content": "i.", "page": 130, "level": 3}}]], "page": 129, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- It was noted that all the Public Universities through their respective Councils determine the research policies, research management structures and research direction of the respective Universities. There is no framework to ensure collective planning, coordination and follow-up of research efforts for the different Public Universities to ensure equitable allocation of resources, efficient utilization of academic staff, and that research results contribute to National development.", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 130, "level": 3}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 130, "level": 3}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- It was also established that key research and grant management policies/guidelines were missing at a number of Universities to guide on the efficient and effective management of research activities. Only MUST and Busitema had a grants management policy/manual to guide their grants management processes. Furthermore, the country lacks national regulations and guidelines for research and innovation activities including; sourcing of external grants, development and uptake of technologies and, management and commercialization of intellectual properties.\n- Furthermore, the research committees for MUK, MUST and Kyambogo which are responsible for strategic planning and research direction focused more on graduate", "metadata": {"headings": [{"headings_0": {"content": "i.", "page": 130, "level": 3}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "students\u2019 research with limited emphasis on university grants research.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- It was also noted that out of the 4 Universities, only MUST had a grants office under the DRGT with dedicated staff to support grant activities. It was further noted that Busitema and Kyambogo did not have grants administrators at college/faculty level while at MUK and MUST only the college of Health Sciences and the faculty of medicine respectively had grant administrators to undertake the tasks.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The most funded area of the research agenda for MUK was health and health systems which accounted for over 50% of the funding with other areas of research getting smaller contributions. In addition, no operational processes were in place to ensure that external grants sourced by MUK & KYU staff are in line with the university\u2019s research agenda. MUST and Busitema University did not have an approved research agenda at University level. Furthermore, the country does not have a clear research agenda to guide planning, implementation and policy making.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n118 \nii. Resource Mobilization Initiatives", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}]], "page": 130, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- It was found that MUK, KYU and Busitema have established processes to centrally award competitive research grants from internally generated funds or Government support as initiatives to promote research and innovation in public universities. These processes have in turn enabled staff to seek external grants through proposal writing. The processes however have challenges. MUST on the other hand has not established such processes.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the 4 universities, only MUK had a consolidated Research Innovation Fund (RIF) for research funds from government. Through continuous lobbying by MUK, government allocated UGX.30bn to the fund; the other universities have not explored this initiative. All the universities have not raised any resources internally into a separate fund for research. This was attributed to government policy of remitting all internally generated revenue into the consolidated fund and therefore appropriating funds through the annual budget process.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}]], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- It was noted that for all the 348 grants sampled from the four (4) universities, overheads/indirect costs were not deducted from the funds spent contrary to percentage requirements in the research and grant policies of the universities.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "iii. Monitoring and Evaluation", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- In all the four Universities, M&E was not carried out by the university management on external research grants for the period 2017/18-2019/20. 193 out of 348 (55.5%) sampled external grants were however monitored by the donors. For internal grants, only 222 grants under MUK RIF were monitored.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- It was noted that even where M&E was undertaken by donors, recommendations were not fully implemented by the Universities.\n- 450 out of 512 Government funded Grants from MUK, Kyambogo and Busitema, representing 87.9% were not completed in time during the period under review. Similarly, 218 out of 350 (62.3%) Donor funded Grants from the 4 universities were not completed in time.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Key Recommendations \n", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}]], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Ministry of Education and Sports should institute a committee with full representation from all public universities and supported with relevant legislation to collectively undertake strategic planning for university research in line with the National Development Plan and ensure adequate coordination between universities, follow-up of research activities, equitable allocation of resources and efficient utilization of academic staff on research.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The NCHE should introduce a standard legal framework for evaluation of management of research activities in the universities. The Universities should then take the responsibility for mainstreaming the instituted framework into their management system. Regular audits of planned university research activities vis a vis expected outputs should be undertaken.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "119", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 131, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The public universities should prioritize development of key research and grant management policies to guide the related processes. Benchmarking with leading universities in the region and at the continental level can be used to ease the process and ensure up-to-date policies with the changing environment.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Government and related institutions should fast track the development of policies, strategies and guidelines to promote research, technology development and, uptake and management & commercialization of Intellectual Properties (IPs) as provided for in the NDP III.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}, [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}]], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The public universities should have different Senate/Management committees for the different roles of governing graduate programs and students on one hand and research and innovations activities including grants management on the other hand. This would ensure adequate focus on strategic planning for research, management and follow-up of research activities at the university for timely achievement of university research objectives.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The public universities should engage with MoPS, MoFPED and MoES for support to fill the key staffing gaps for grants management and ensure that the necessary key roles such as grants administration and M&E are undertaken.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Government through the Ministry of Finance, Planning and Economic Development should prioritise funding/grants for research in public universities to enable focus on research which is in line with university research agendas and national priorities.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Government and related institutions should fast track the development of the national research agenda to guide planning, implementation and policy making as provided for in the NDP III.", "metadata": {"headings": [{"headings_0": {"content": "students\u2019 research with limited emphasis on university grants research.", "page": 130, "level": 2}}], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the \nimplementation of recommendations on project or grant monitoring and Evaluation for improvement in the management of research grants in the University. \nOverall Audit Conclusion", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}, [{"headings_0": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The Universities\u2019 management should institute Committees to follow up and review the", "page": 132, "level": 2}}]], "page": 132, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- The study revealed that the annual revenue budgets or targets of all the seven (7) markets were consistently below their revenue potential by 38%. Whereas the revenue potential for the markets was UGX.32.8Bn over the 6 years reviewed, the markets only budgeted to collect UGX.12.5Bn over the period. This was attributed to lack of a management information systems and the manner in which the municipalities develop the revenue budgets based on prior year collections instead of using actual market occupancy. Unrealistically low budgets imply that the revenue performance is likely to be below the market potential.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}], "page": 133, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}], "page": 133, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the budget of UGX.12.5Bn by these markets for the six-year period, only UGX.7.9Bn was collected representing a performance of 54%. This was due to lack of automated revenue management system, leaseholders who were not paying monthly market rents, unoccupied stalls and lockups, irregular subletting, and the failure to terminate tenancy of rent defaulters. Under collection of revenues has affected the", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}], "page": 133, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "121 \nability of these markets to meet their obligations which has resulted into accumulation of arrears totalling to UGX.1.41Bn in the seven (7) markets.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}]], "page": 133, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Four (4) markets of Mbale, Gulu, Lira and Jinja were overcrowded with the vendor- occupancy exceeding the markets\u2019 design capacity by 36% due to over allocation of market spaces, illegal traders and sub-lettees, inadequate enforcement by the municipality and design deficiencies such as poor lighting in some sections, and lack of accessibility. The overcrowding has caused congestion in the markets.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}]], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The majority of vendors all the seven (7) markets were not trading in the established zones due to insufficient space in zones, allocation of spaces to traders outside their designated zones, rejection of the stalls by vendors, and weak enforcement of zoning. This has resulted in a disorganised market environment which continues to present challenges for customers and traders.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- All the seven (7) markets had failed to maintain adequate sanitation within the markets due to overcrowding of the markets, weaknesses in the supervision of the cleaning staff and cleaning contracts, insufficient number of garbage trucks, skips, bins, garbage banks and landfills. The poor sanitation makes the markets unsightly for the customers and poses health risks for both the traders and customers such as food contamination and air pollution.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The market infrastructure was not well maintained for all the markets. There were cases of leaking roofs, walls with old peeling paint, cracked floors, non-functioning toilets, failed water pumps, un-serviced generators and firefighting equipment, and non-functioning CCTV security equipment. Inadequate maintenance of the market infrastructure was attributed to failure to prioritize this activity by the municipalities, and failure to set aside maintenance funds as recommended in the market maintenance guidelines. Failure to maintain infrastructure has resulted in accelerated deterioration of the newly constructed markets.", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nIn order to address the gaps identified, the municipalities should roll out automated revenue management systems in all the markets, enforce terms of tenancy agreements in relation to sub-letting, invoicing and payment of rent, modify the market structures to allow for better lighting and improved access. The municipalities should also address the issue of illegal occupants, and develop guidelines to regulate sub-letting. \nThe municipalities should review the current markets layout to address the challenges of zoning, and overcrowding. In addition, there is need to enhance supervision of market cleaning and prioritise the maintenance of the market structures. \n7.6. \nPrevention and Response to Incidents of Fire by Uganda Police Force. \nDirectorate of Fire Prevention and Emergency Rescue Services (DFPERS) is one of the directorates in the Uganda Police Force. Its major role is to enhance capacity for prevention of emergencies and delivery of rescue services in order to deliver on its functions of fire prevention, fire suppression and emergence rescue. The directorate operates eleven (11) fire stations in Kampala Metropolitan Area and thirty-four (34) others stations across the country. \n122 \nThis study assessed the extent to which DFPERS has put in place measures to prevent and respond to fire outbreaks. The Directorate of Fire and Rescue services has made notable achievements over its nine years of existence as illustrated below; \nFollowing the creation of DFPERS in 2012 the number of fire stations in the country has increased by thirty-one (31) which has improved access to fire services. In addition, coordination with stakeholders in preventing and responding to fire by DFPERS has improved and a total of 4,131 have been responded to in the last four years thus saving lives and property. Despite the achievements registered, the audit identified the following areas that need to be addressed. \n", "metadata": {"headings": [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}, [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}], [{"headings_0": {"content": "7.5.", "page": 133, "level": 2}}], [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}], [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}], [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}], [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}], [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}], [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}], [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}]], "page": 134, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Directorate of Fire and Rescue Services (DFPERS) undertakes activities aimed at preventing the outbreak of fire and incidents that require emergency response. The study observed that the Directorate faced challenges in preventing the occurrence of fire. These include;", "metadata": {"headings": [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}], "page": 135, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf076 DFPERS did not have fire and safety Act, regulations, and policies to aid the operations of the directorate in prevention. Because of this the Directorate was unable to effectively carry out risk assessment, sensitization of the public, inspection of buildings by DFPERS staff, and carry out post incident investigations as indicated below. \n\uf076 DFPERS has not undertaken any comprehensive assessment of risks relating to occurrence of fire incidents in order to develop appropriate prevention and response measures/strategies to control fire outbreaks which has affected the \ndirectorate\u2019s ability to develop appropriate fire prevention strategies. \n\uf076 DFPERS undertook only 873 (29%) out of the planned 3,020 sensitisations in the past four (4) years. This has continued to expose buildings and their occupants to fire outbreaks and limited the capacity of citizens to prevent the occurrence of such incidents. \n\uf076 DFPERS undertook only 527 (17%) out of the planned 3,080 inspections in the past four (4) years. This affects the level of compliance to fire standards which increases the probability of fire outbreaks which can lead to loss of life and damage to property. \nThe study also noted the following weaknesses on the side of the Fire department: \n", "metadata": {"headings": [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}, [{"headings_0": {"content": "7.6.", "page": 134, "level": 2}}], [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}]], "page": 135, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- DFPERS did not undertake post incident investigations to ascertain the cause, extent of damage or loss from the fires and lessons for prevention of re-occurrence of similar incidents on the 3,179 incidents of fire reported during the past three years due to lack of equipment and trained investigators and coordination with other government investigative bodies. This has resulted into non-conclusion of investigations hence continued public dissatisfaction on the way Uganda Police Force handles fire investigations.", "metadata": {"headings": [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], "page": 135, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "123 \n", "metadata": {"headings": [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}, [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}]], "page": 135, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- In addition to fire prevention, DFPERS responds to fire outbreaks to minimize the impact of fire on people\u2019s lives and property. The Directorate faced challenges in responding to fire outbreaks due to limited number of fire stations, inadequate staff, lack of enough equipment and non-automation of operations to respond to fires as indicated below;", "metadata": {"headings": [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- DFPERS is currently operating forty-five (45) fire stations in thirty-eight (38) districts to respond to cases of fire outbreaks across the country which is only 27% coverage of the total number of districts in the country due to the high cost of opening and", "metadata": {"headings": [{"headings_0": {"content": "directorate\u2019s ability to develop appropriate fire prevention strategies.", "page": 135, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding \nto incidents of fire across the country. \n", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}]], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- DFPERS currently has 599 fire staff against an approved establishment of 1,081 staff representing staffing levels of 55% implying that the current fireman to population ratio in Uganda is 1:75,000 compared to the recommended international ratio of 1:2,000. The existing staff were also not well trained and lacked adequate accommodation.", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The equipment at the fire stations were inadequate in terms of quantity and functionality (not well maintained) to support effective response in the event of fire incidents. DFPERS had only 78 out of 232 equipment required to handle fire incidents representing 34% level of required equipment capacity. In addition, it was noted that firemen lacked adequate PPEs for use during fire response.", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The fire stations inspected were not automated and information was recorded in manual books there were also no computers and communication systems which affected the efficiency and coherence of DFPERS response in the event of fire outbreak.\n- DFPERS coordinates with some stakeholders such as Local Governments, NWSC, DGAL, CIID, Hospital emergency units, Civil Aviation Authority and Uganda Red Cross Society however this coordination is informal and characterized by slow decision making which affects response time.", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Key Recommendations \nI advised DFPER to engage the Ministry of internal Affairs to develop a comprehensive fire and safety Act, policy and guidelines in consultation with key stakeholders to streamline risk assessment, sensitisation, inspection and post incident investigations. In addition, DFPERS should enhance coordination mechanisms with internal and external players to support its operations particularly post incident investigations. \nDFPERS should prioritize increasing coverage of fire stations to at least 50% of the districts and develop strategies to ensure the population fire man ratio of 1:75,000 is matched to internationally recommended ratio of 1: 2,000. In addition, UPF should undertake an assessment of the current accommodation needs with a view of developing strategies to address the current inadequacies in accommodation. UPF should prioritise the acquisition of equipment, PPEs and automation of the current communication and record management systems to ensure that there is an effective \n124 \nresponse to fire incidents enhance on the operational efficiency during responses to incidents of fire outbreaks \n7.7. \nValue for Money Audit on the Performance of the Performance of the Agriculture Cluster Development Project \nGovernment has implemented the Agriculture Cluster Development Project (ACDP) with an overall objective of raising on-farm productivity, production and marketable volumes of selected agricultural commodities (Maize, Beans, Cassava, Rice, and Coffee) in twelve (12) clusters in fifty-seven (57) districts across the country. The project is funded through IDA Credit worth UGX.540Bn and farmer contribution of UGX.352.8Bn and implemented through the e-voucher management system. \nThe intervention has resulted into distribution of 60,124 tonnes of beans, maize, and rice and 49,871 bags of cassava planting materials to 245,510 farmers/beneficiaries by the agro-dealers between 2018/2019 and 2020/2021. The intervention has also resulted into increased the marketable volumes from 11.94MT to 33.28MT in the past three years. \nDespite the achievements registered, the study identified areas that need to be addressed. The following key observations were noted; \n\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary \napprovals from cabinet and parliament (20 months) and delayed fulfilment of the project effectiveness conditions (26 months) which led to late implementation of project activities and service delivery. \n", "metadata": {"headings": [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}, [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], [{"headings_0": {"content": "operating fire stations. This has resulted into DFPERS\u2019 ineffectiveness in responding", "page": 136, "level": 2}}], [{"headings_0": {"content": "7.7.", "page": 137, "level": 2}}], [{"headings_0": {"content": "7.7.", "page": 137, "level": 2}}], [{"headings_0": {"content": "7.7.", "page": 137, "level": 2}}], [{"headings_0": {"content": "7.7.", "page": 137, "level": 2}}], [{"headings_0": {"content": "7.7.", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}]], "page": 136, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Despite the project achieving more than 70% in five (5) districts in training of Local Government Staff and farmers on system use and financial literacy, the project did not perform satisfactorily in twenty-three (23) districts where twenty-seven (27) trainings had been planned. As a consequence, a number of farmers were unable to transition from the first cropping cycle to the third cropping cycle.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the targeted 450,000 farmers, 204,490 (46%) farmers did not access inputs through the e-voucher system. With only one year left to the end of the project, the project may not achieve its intended objective.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The inputs that were distributed to the farmers were not verified by UNBS because of absence of a streamlined quality control process. As a result, farmers reported cases where seeds did not germinate and fertilizers that \u201cjust hardened the soils\u201d were distributed by the Agro-dealers. This has compromised the process of ensuring farmers get the best quality inputs since the department is limited in capacity to undertake this activity.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The project did not achieve the intended targets in the three areas below in the three years of implementation.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "125", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], "page": 137, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "o Only 207 Area Commodity Cooperative Enterprises (ACCEs) (69%) and 155 Rural Producer Organisations (RPOs) (5%) have been supported with value addition facilities out of the targeted 300 ACCEs and 3000 RPOs in the six-year project life span. \no \nOut of 1,835 farmers in the cooperatives that received matching grants for the value addition facilities, only 585 farmers (31.9%) were enrolled on the e-voucher system which made it difficult for the project to reach its targeted 450,000 farmers. \no The project had planned to rehabilitate a total of 2,827.7km planned road chokes however, only 228.1km (8%) had been rehabilitated representing 8% of the overall performance of the community access roads. \nGovernment should ensure that for future projects of a similar nature; The necessary loan documentation is submitted by the implementing entities and loan appraisal unit at MoFPED to the approving authorities in time, trainings activities are undertaken in a timely manner, farmers are mobilized into village savings and lending associations to increase access to funding and reviewing the e-voucher subsidy rates in order to make them more affordable to farmers. The role of other partner participating agencies (in this case UNBS) regarding quality is clearly defined in future project designs. \nIn addition, MAAIF should ensure that evaluation of business proposals for funding of ACCEs and RPOs are done in a timely manner for the farmer groups to access funds. MAAIF should also enhance supervision in the rollout districts so that works on the road chocks are completed in the remaining project life span. \n7.8. Follow up on the Value for Money Audit on the Compensation of Project Affected Persons under the Refinery Project by the Ministry of Energy and Mineral Development \nThe follow-up on the 2017 VFM audit on Compensation of Project Affected Persons (PAPs) under the Refinery Project by the Ministry of Energy and Mineral Development found that MEMD had made efforts to implement the Auditor General\u2019s recommendations made at the time, resulting in improved RAP implementation. \nOut of the 21 key audit recommendations made in the report of 2017, 12 (57%) were fully implemented and 4 (19%) were partially implemented. The status of implementation of 5 (24%) of the recommendations can only be verified in future projects through audit of subsequent RAPs. \nSpecifically, after the 2017 audit, MEMD had registered the following progress in RAP \nImplementation: \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}, [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], [{"headings_0": {"content": "\uf0b7 The project delayed to commence by 20 months\u2019 due delays in obtaining the necessary", "page": 137, "level": 2}}], [{"headings_0": {"content": "Implementation:", "page": 138, "level": 2}}], [{"headings_0": {"content": "Implementation:", "page": 138, "level": 2}}]], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- All PAPs houses had been occupied by the respective owners;\n- Electricity had been connected to all PAP houses;\n- Four boreholes were constructed for use by the PAPs and the Host Community;", "metadata": {"headings": [{"headings_0": {"content": "Implementation:", "page": 138, "level": 2}}], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were \nmotorable;", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}, [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}]], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- Construction of the places of worship and a Police Post had been completed and the structures handed over to the respective authorities;\n- Construction of the community centre and market stalls was on-going.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "126", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}], "page": 138, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- MEMD had acquired land titles for the land occupied by the PAPs and was processing the transfer of the individual land titles into the names of the PAPs.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}], "page": 139, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nSome outstanding issues noted included the following: A few pending compensation payments mostly due to failure to trace the PAPs; failure by the contractor to remedy most defects identified during the 2017 audit; reports of conflicts owing to changing social dynamics as people adapt to living in congregated settlements; and long distance from the resettlement area to the boreholes. Finally, the PAPs also reported that MEMD and other responsible players rarely conduct visits to sensitise or update them on progress of pending outputs or to explain delays. \nFurther recommendations were then made with the aim of addressing the outstanding issues noted. \n7.9. \nVFM Audit on the Implementation of the Uganda Reproductive Maternal and Child Health Services Improvement Project (URMCHSIP) \nURMCHSIP is a USD 180 million project fully donor funded and was approved in August 2016 and is expected to close in December 2022. The target group comprises women of childbearing age, adolescents, and children under-five in all the one-hundred and thrty five (135) districts in Uganda. The Project Development Objectives (PDOs) are to: (a) to scale up reproductive, maternal, newborn, child and adolescent health (RMNCAH) services in the whole country; (b) scale-up birth and death registration (BDR) services; and (c) to strengthen disease outbreak preparedness and response. \nThe audit covered twelve (12) Districts benefiting from this project in the three financial years of 2017/18, 2018/19 and 2019/20. Below are the key findings of the study; \ni. \nStatus of Implementation of the Project \nIt was noted that out of the 22 project performance indicators considered, 13 (i.e. 60%) achieved their target for the FY 2019/20. The remaining 9 indicators (i.e. 40%) were below their 2019/20 target. Amongst the 9 are two indicators: the number of health facilities constructed and equipped, which are not reflecting any progress due to delays in implementation. \nii.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}, [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}], [{"headings_0": {"content": "\uf0b7 Access roads constructed in the PAPs\u2019 settlement area were completed and were", "page": 138, "level": 2}}], [{"headings_0": {"content": "7.9.", "page": 139, "level": 2}}], [{"headings_0": {"content": "7.9.", "page": 139, "level": 2}}], [{"headings_0": {"content": "7.9.", "page": 139, "level": 2}}], [{"headings_0": {"content": "7.9.", "page": 139, "level": 2}}], [{"headings_0": {"content": "i.", "page": 139, "level": 3}}], [{"headings_0": {"content": "i.", "page": 139, "level": 3}}], [{"headings_0": {"content": "ii.", "page": 139, "level": 3}}]], "page": 139, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The Results-Based Financing (RBF) Program \nSince January 2019 to date, the URMCHSIP has rolled out the RBF program to 1,316 health facilities in one-hundred and thirty-five (135) districts across the country in three phases. However, review of timing of RBF payments made by the Ministry of Health-to- health facilities revealed delayed payments ranging from 83 to 154 days after the prescribed deadline. Consequently, timely implementation of Performance Improvement Plan (PIP) activities at these facilities was adversely impacted. The delayed payments were partly attributed to the delayed verification of health facility outputs by the District Health Management Teams (DHMTs) which was further constrained by the reliance on manual processes. \n127 \niii. \nProcurement of Essential RMNCAH Medicines and Supplies \nThe project intended to support the Ministry of Health (MoH), through National Medical Stores (NMS), to procure and distribute essential Reproductive, maternal, newborn, child and adolescent health (RMNCAH) commodities. However, there have been several delays in the procurement of these commodities under the project, leaving health facilities partly incapable of handling certain complications arising during delivery. This was partly attributed to failure by the MoH to retender certain procurements, there being no bidder that initially met the requirements. \niv. \nBirth and Death Notifications in Health Facilities \nThere were delays in implementation of various activities by National Identification and Registration Authority (NIRA) especially (i) scaling up the electronic vital records system \nfor birth registration through the supply of laptops, MiFi\u2019s and internet data bundles to \n285 HC IVs and High-volume Health centre IIIs. As a result, the project has made minimal improvement in capacity of these facilities to conduct birth and death notifications. \nv. \nMonitoring and Evaluation of Project Activities \nThe monitoring and evaluation (M&E) function was found to be inadequate and this was partly attributed to the fact that there were no annual M&E work plans and the M&E specialist was only recruited in December 2019, two and a half years after the project had commenced. \nOverall Audit Conclusion", "metadata": {"headings": [{"headings_0": {"content": "ii.", "page": 139, "level": 3}}, [{"headings_0": {"content": "ii.", "page": 139, "level": 3}}], [{"headings_0": {"content": "iii.", "page": 140, "level": 3}}], [{"headings_0": {"content": "Procurement of Essential RMNCAH Medicines and Supplies", "page": 140, "level": 2}}], [{"headings_0": {"content": "Procurement of Essential RMNCAH Medicines and Supplies", "page": 140, "level": 2}}], [{"headings_0": {"content": "iv.", "page": 140, "level": 3}}], [{"headings_0": {"content": "Birth and Death Notifications in Health Facilities", "page": 140, "level": 2}}], [{"headings_0": {"content": "Birth and Death Notifications in Health Facilities", "page": 140, "level": 2}}], [{"headings_0": {"content": "for birth registration through the supply of laptops, MiFi\u2019s and internet data bundles to", "page": 140, "level": 2}}], [{"headings_0": {"content": "for birth registration through the supply of laptops, MiFi\u2019s and internet data bundles to", "page": 140, "level": 2}}], [{"headings_0": {"content": "v.", "page": 140, "level": 3}}], [{"headings_0": {"content": "v.", "page": 140, "level": 3}}], [{"headings_0": {"content": "v.", "page": 140, "level": 3}}]], "page": 139, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "The MoH is advised to continue working closely with the National Identification and Registration Authority, the District Local Governments, National Medical Stores, and the World Bank to address any capacity gaps and implementation delays that are derailing project performance. The MoH is also advised to liaise with MoFPED and other key stakeholders to guarantee the continuity of the interventions set up under this project especially the RBF Program, the increased supply of key RMNCAH medicines and supplies, the recruitment of health workers trained under URMCHSIP, so as maintain the gains made in the Health sector as a result of this project. \n128 \nANNEXURES \nANNEXURE I: SUMMARY OF ENTITY FINDINGS AND OPINIONS FOR MDAs, COMMISSIONS, STATUTORY CORPORATIONS AND STATE ENTERPRISES AND PROJECTS", "metadata": {"headings": [{"headings_0": {"content": "v.", "page": 140, "level": 3}}, [{"headings_0": {"content": "v.", "page": 140, "level": 3}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 140, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Sn SECTOR AND ENTITY SUMMARY OF KEY FINDINGS", null, null], ["", "AGRICULTURE SECTOR", ""], ["1\\. Agriculture Cluster Development Project (ACDP). 2020/21 Opinion Unqualified \uf0b7 Delays in the implementation of some project activities were noted such as provision of E-Vouchers subsidies to beneficiaries in the 12 clusters, only a total of 208,827 of beneficiaries used E-Voucher out of the targeted 400,000 and only 18 road chokes have been worked on in the 7 pilot districts against the targeted 90. \uf0b7 The project budgeted to receive UGX 361.7Bn from development partners but only received UGX 254.8Bn, representing a performance of 70% of the budget. Similarly, the project budgeted to receive UGX 4Bn as GOU counterpart funding but only received UGX 2.6Bn (66%) resulting in a shortfall of UGX 1.4Bn which is 34% of the budget. \uf0b7 Out the releases of funds of UGX 254.8Bn, the project remained with unspent balance of UGX 99.1Bn representing an absorption level of 61%. \uf0b7 I sampled 12 outputs with a total of 25 activities worth UGX.324.1Bn representing 90% of the total budget and noted that 8 outputs with 17 activities worth UGX 53.7Bn were not quantified to enable measurement of performance. Furthermore, of the 4 outputs with a total of (8) quantified activities worth UGX 80.14Bn assessed; 1 output with 1 activity representing 25% was fully implemented while 3 outputs with a total of 7 activities representing 75% were partially implemented. \uf0b7 The budget for the financial year 2020/21 was approved on 13th August 2020 (2 months into the financial year). \uf0b7 Project funds to the tune of UGX 3.5Bn were disbursed significantly late to the districts. \uf0b7 National Project Steering Committee (NPSC) held only one meeting as opposed to two recommended in a year. \uf0b7 Procurements for rehabilitation of identified and approved road chokes/work in the last 29 roll-out districts had not commenced by the time of audit despite MAAIF budgeting for the activity at UGX 90Bn. \uf0b7 Shortcomings were observed with the E-Voucher Management Agency which included, frequent breakdown of the system, lesser enrolment of beneficiaries ie 64% of the target, only 44% of the project beneficiaries were trained in Financial Literacy and Input use, the system was at 78% of its functional requirement, system installation, configuration, optimisation and commissioning reports have not been submitted. \uf0b7 MAAIF budgeted UGX.104.9Bn to provide Electronic Voucher subsidies to 293,500 beneficiaries in 12 project clusters but only managed 118,933 (41%) beneficiaries. \uf0b7 Farmers still had challenges in transacting using the system, managing farmer savings and use of inputs via the system. During the financial years 2019/2020 and 2020/2021, 52,089 transactions were made by users who had never logged onto the system and were accessing inputs manually. Relatedly, 2,873 user IDs initiated 7,878 payment requests", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 141, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": [["Sn SECTOR AND ENTITY SUMMARY OF KEY FINDINGS", null, null], ["", "AGRICULTURE SECTOR", ""], ["1\\. Agriculture Cluster Development Project (ACDP). 2020/21 Opinion Unqualified \uf0b7 Delays in the implementation of some project activities were noted such as provision of E-Vouchers subsidies to beneficiaries in the 12 clusters, only a total of 208,827 of beneficiaries used E-Voucher out of the targeted 400,000 and only 18 road chokes have been worked on in the 7 pilot districts against the targeted 90. \uf0b7 The project budgeted to receive UGX 361.7Bn from development partners but only received UGX 254.8Bn, representing a performance of 70% of the budget. Similarly, the project budgeted to receive UGX 4Bn as GOU counterpart funding but only received UGX 2.6Bn (66%) resulting in a shortfall of UGX 1.4Bn which is 34% of the budget. \uf0b7 Out the releases of funds of UGX 254.8Bn, the project remained with unspent balance of UGX 99.1Bn representing an absorption level of 61%. \uf0b7 I sampled 12 outputs with a total of 25 activities worth UGX.324.1Bn representing 90% of the total budget and noted that 8 outputs with 17 activities worth UGX 53.7Bn were not quantified to enable measurement of performance. Furthermore, of the 4 outputs with a total of (8) quantified activities worth UGX 80.14Bn assessed; 1 output with 1 activity representing 25% was fully implemented while 3 outputs with a total of 7 activities representing 75% were partially implemented. \uf0b7 The budget for the financial year 2020/21 was approved on 13th August 2020 (2 months into the financial year). \uf0b7 Project funds to the tune of UGX 3.5Bn were disbursed significantly late to the districts. \uf0b7 National Project Steering Committee (NPSC) held only one meeting as opposed to two recommended in a year. \uf0b7 Procurements for rehabilitation of identified and approved road chokes/work in the last 29 roll-out districts had not commenced by the time of audit despite MAAIF budgeting for the activity at UGX 90Bn. \uf0b7 Shortcomings were observed with the E-Voucher Management Agency which included, frequent breakdown of the system, lesser enrolment of beneficiaries ie 64% of the target, only 44% of the project beneficiaries were trained in Financial Literacy and Input use, the system was at 78% of its functional requirement, system installation, configuration, optimisation and commissioning reports have not been submitted. \uf0b7 MAAIF budgeted UGX.104.9Bn to provide Electronic Voucher subsidies to 293,500 beneficiaries in 12 project clusters but only managed 118,933 (41%) beneficiaries. \uf0b7 Farmers still had challenges in transacting using the system, managing farmer savings and use of inputs via the system. During the financial years 2019/2020 and 2020/2021, 52,089 transactions were made by users who had never logged onto the system and were accessing inputs manually. Relatedly, 2,873 user IDs initiated 7,878 payment requests", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 141, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "129", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 141, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", null, null], ["2", "Agriculture Value Chain Development Programme (AVCP).", "\uf0b7 Out of the planned twelve (12) strategic targets/goals to be achieved by financial year 2020/2021; four (4) had been fully achieved, seven (7) were partially achieved while one (1) was not achieved at all."], [null, "2020/21 Opinion", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 142, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", null, null], ["2", "Agriculture Value Chain Development Programme (AVCP).", "\uf0b7 Out of the planned twelve (12) strategic targets/goals to be achieved by financial year 2020/2021; four (4) had been fully achieved, seven (7) were partially achieved while one (1) was not achieved at all."], [null, "2020/21 Opinion", null], [null, "Unqualified", ""], [null, null, "activities were fully quantified. Further, out of the 14 outputs that were"], [null, null, "fully quantified, I observed that; 0ne (01) output with four (04) activities"], [null, null, "and expenditure worth UGX.0.547Bn was fully implemented; ten (10)"], [null, null, "outputs with forty-two (42) activities worth UGX.10.1Bn were partially"], [null, null, "implemented i.e. out of the 42 activities, 17 activities (40%) were fully"], [null, null, "implemented, 16 activities (39%) were partially implemented while 9"], [null, null, "activities (21%) remained unimplemented. Three (03) outputs with four"], [null, null, "(04) activities were not implemented at all."], [null, null, "\uf0b7 Assessment of achievement of services from implemented outputs"], [null, null, "revealed that 60 artificial inseminations (AI) Kits were purchased at"], [null, null, "UGX.0.26Bn and delivered to NAGRC in June; however, management had"], [null, null, "not yet distributed them to beneficiary AIs by November 2021 implying"], [null, null, "that the equipment was not in use for more than five months."], [null, null, "\uf0b7 Relatedly, the project undertook the Purchase and Installation of Ultra-"], [null, null, "High Performance Liquid Chromatography (UHPLC) for analysis of various"], [null, null, "chemical food and environmental residues and related substances at"], [null, null, "UGX.0.39Bn which was delivered in June 2021 but was not functional by"], [null, null, "November due to incomplete components."], [null, null, "\uf0b7 There was no Steering committee sitting during the year to facilitate and"], [null, null, "ensure adherence to relevant strategies established by Government"], [null, null, "during project implementation."], ["3 Coordinating Office for Control of Trypanosomiasis in Uganda. 2020/21 Opinion Unqualified \uf0b7 The entity had an approved strategic plan, however the plan had not been certified by NPA contrary to Regulation 26 (1) of the NPA (development of plans). \uf0b7 All budgeted Donor revenue of UGX.0.783Bn for the financial year 2020/2021, was dully received representing performance of 100% of the target. \uf0b7 There was a shortfall in releases amounting to UGX.0.172Bn representing 4.1% of the budget. Furthermore, the entity remained with unspent balance of UGX.0.00037Bn representing an absorption level of 99.9%. \uf0b7 The entity received off-budget financing to a tune of UGX.0.783bn which was not appropriated as part of the entity budget contrary to the law. \uf0b7 4 outputs with 8 activities and expenditure worth UGX.0.324Bn were fully quantified while 5 outputs with 34 activities worth UGX.4.41Bn were", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 142, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "130", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 142, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["insufficiently quantified. Of the 4 outputs with all 8 quantified activities worth UGX.0.324Bn assessed; 3 outputs with 4 activities worth UGX.0.19Bn were fully implemented, while 1 output with 4 activities worth UGX.0.134 was partially implemented. \uf0b7 All 4 quarterly performance reports were submitted after the quarterly deadline and I did not obtain evidence to confirm that the Accounting Officer prepared monitoring plans and reports. \uf0b7 Out of the approved staff number of 37 employees, 19 (51%) have been filled leaving a 18 (49%) vacant among which are key posts of Deputy Director, Accountant, Medical Officer, Entomology Officer, M&E Officer etc. \uf0b7 Contrary to the COCTU Human Resource Manual that requires operation of a medical insurance scheme to benefit all its employees, the entity has not operationalized any Staff Medical Insurance Policy for its staff.", null, null], ["4", "Cotton Development Organization. 2020/21", "\uf0b7 The entity cotton sub sector strategic plan had been prepared and approved; however, it was not certified by NPA to evidence its alignment to the NDP-III."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 143, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None"], "type": "table"}}, {"content": "131", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 143, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "targets."], [null, "\uf0b7 Analysis of the domestic arrears showed an increase of 198% from"], [null, "UGX.7,925,963 in the prior year to UGX.23,659,951 in the year under"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 144, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": [["", "targets."], [null, "\uf0b7 Analysis of the domestic arrears showed an increase of 198% from"], [null, "UGX.7,925,963 in the prior year to UGX.23,659,951 in the year under"], [null, "review."], [null, "\uf0b7 CDO staff structure had thirty seven (37) positions dully filled leaving a"], [null, "staff vacancy of ten (10) positions (21%). The positions that have"], [null, "remained vacant over the years include key positions of two (2)"], [null, "Agronomy officers, a classifier and a Personnel & Administration Officer."], [null, "\uf0b7 Withholding tax to the tune of UGX.83,142,447 from payments worth"], [null, "UGX.839,194,850 was not recovered for onward remittance to URA"], [null, "contrary to section 120(1) and 120(4) of the Income tax Act."], ["5 National Agricultural Research Organization 2020/21 Opinion Unqualified \uf0b7 The entity\u2019s draft strategic plan had been aligned to the NDP-III at the time of audit and was awaiting certification from NPA due to delayed approval of the Programme Implementation Action Plans (PIAPs). \uf0b7 The entity budgeted to collect NTR of UGX.4.625Bn but collected UGX.3.053Bn representing a performance of 66% of the target. \uf0b7 There was a shortfall in GoU releases amounting to UGX.11.216Bn representing 10.1%. Further, the entity remained with unspent balance of UGX.0.085Bn representing an absorption level of 99.9%. \uf0b7 The entity received off-budget financing directly from development partners to a tune of UGX.49.77Bn out of which only UGX.38.19Bn was declared to the PSST and disclosed in the entity ministerial policy statement without a supplementary appropriation for the balance of UGX.11.58Bn. \uf0b7 I sampled 8 outputs with 35 activities and expenditure of UGX.99.59Bn and noted that 7 outputs with 18 activities and expenditure worth UGX.45.070Bn were fully quantified while 1 output with 17 activities and expenditure worth UGX.54.52Bn was insufficiently quantified, of which 5 activities (29%) were quantified while 12 activities (71%) were not clearly quantified to enable measurement of performance. Further, I observed that out of the seven (7) outputs that were fully quantified, two (2) outputs with five (5) activities and expenditure worth UGX.5.186Bn were fully implemented while Five (5) outputs with thirteen (13) activities worth UGX.39.884Bn were partially implemented i.e. four (4) activities were fully implemented, eight (8) activities were partially implemented, while one (1) activity remained unimplemented. \uf0b7 Submission of performance reports for all the quarters was made after the deadline dates. \uf0b7 Fourteen (14) slow progressing competitive grant scheme (CGS) projects initiated in 2018/19 with funding of UGX.1.158Bn during the financial year 2020/2021 were still on-going despite expected completion date of June 2021. \uf0b7 Civil works and Supplies Projects worth UGX.32,051,565,938 undertaken during the financial year were not yet handed over for use. Further, inspections of NARO facilities at institutes revealed poor road networks, broken down silos at the feed mill, non-functional water pump and abandoned works. \uf0b7 There was failure to achieve the intended service delivery for the additional Civil Works at Rwebitaba ZARDI that costed UGX.418,584,880. This was due to lack of equipment in the laboratory. \uf0b7 Review of 9 sample procurements worth UGX.27,606,866,233 revealed an", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 144, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": "132", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 144, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["average delay of 45 days in the procurement process due to late release of funds by MoFPED. \uf0b7 The entity received Covid 19 supplementary budget of UGX.0.0134Bn for settlement of arrears which was all spent by the entity representing an absorption level of 100%. It was noted that this was inadequate for settlement of domestic arrears brought forward from the previous year 2019/20 given leaving a deficit of UGX1.69Bn (98%). \uf0b7 Domestic arrears increased from UGX.1.72Bn in the previous year to UGX.2.875Bn in the year under review, an increase of 67%. The arrears remained unsettled at the close of the year. Further, NARO did not budget for domestic arrears amounting to UGX.1.687Bn during the year as a paltry provision of only UGX.0.033Bn was budgeted to settle arrears of UGX.1.72Bn. \uf0b7 A review of NARO\u2019s land portfolio revealed that the entity had surveyed 31 pieces of land with total coverage of 4097.20364 Hectares, however it was noted that 8 pieces (3172.937 Hectares) were titled, 20 pieces of land (706.75454 Hectares) were at deed plan stage and 3 pieces of land (217.5121 Hectares) were still at survey report stage. Further, 17 parcels of land located in NaFIRRI-Jinja, Bulindi-Kibaale district, NaLIRRI- Tororo, Namayingo, Nyakyesasa, Ngetta- Kitgum and Rwebitaba-Fort-portal still had cases of encroachement by both private and public developers. \uf0b7 A review of the NARO staff establishment revealed that out of the approved staff number of 995 employees, 851 positions have been filled leaving a staffing gap of 144 (14.5%) staff which indicates a further reduction in staff by about 2.5% compared to the previous financial year.", null, null], ["6", "National Animal Genetics and Data Bank (NAGRIC) 2020/21", "\uf0b7 The entity strategic plan had been aligned to the NDP-III at the time of audit but it was still in draft form awaiting certification from NPA before approval."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 145, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None"], "type": "table"}}, {"content": "133", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 145, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "expenditure of UGX.0.54Bn. By 30th June 2021, prior year LCs worth"], [null, "UGX.10.875Bn were still outstanding."], [null, "\uf0b7 12 project sites whose contracts total to UGX.20.055Bn out of which"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 146, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": [["", "expenditure of UGX.0.54Bn. By 30th June 2021, prior year LCs worth"], [null, "UGX.10.875Bn were still outstanding."], [null, "\uf0b7 12 project sites whose contracts total to UGX.20.055Bn out of which"], [null, "UGX.6.327Bn had been paid were abandoned while 8 delayed and"], [null, "remained incomplete by 30th June 2021."], [null, "\uf0b7 34 contracts for construction of structures, procurement of land and"], [null, "delivery of supplies worth UGX.34.4Bn out of which UGX.11.451Bn was"], [null, "paid had not started. Out of the 34 contracts, 3 service providers who"], [null, "had been fully paid a sum of UGX.7.45Bn had not delivered."], [null, "\uf0b7 640 acres of planted pasture/ fodder in Kasolwe ranch had dried up"], [null, "adversely affecting the quality and quantity of feeds for the animals."], [null, "\uf0b7 Domestic arrears increased by UGX.0.918Bn from UGX. 0.336Bn in the"], [null, "previous year to UGX.1.254Bn in the year under review. The arrears"], [null, "remained unsettled at the close of the year."], [null, "\uf0b7 Out of 12 ranches managed by NAGRC & DB, 6 had been encroached on"], [null, "while some of the NAGRC & DB land had no land titles in the names of"], [null, "NAGRIC 7DB."], [null, "\uf0b7 NAGRC & DB had an approved staff structure of 189 positions with only"], [null, "105 (56%) filled leaving 84 (44%) vacant and 17 positions were filled"], [null, "beyond the approved structure. Further, general support staff structure of"], [null, "128 positions had 310 staff resulting in an over staffing of 142 (185%)."], ["7 National Oil Palm Project 2020/21 Opinion Unqualified \uf0b7 Out of seven (7) strategic targets to be achieved by 30th June 2021, none had been fully achieved, two (2) were partially achieved while five (5) were not achieved at all. \uf0b7 The Project budgeted to receive IFAD funds to a tune of UGX.39.87bn, out of which UGX.25.584bn was available representing a performance of 64% of the budget. Further, there was a shortfall in GoU releases amounting to UGX.0.035Bn representing 0.46% of the budgeted UGX.7.597Bn. \uf0b7 Out of the total available funding of UGX.35.528Bn during the financial year, UGX.28.415Bn was spent by the entity resulting in an unspent balance of UGX.7.113Bn representing an absorption level of 80%. \uf0b7 I sampled Six (6) outputs with a total of eighty one (81) activities and expenditure of UGX.21.6231Bn and noted that all six (6) outputs with 81 activities were fully quantified to enable assessment of performance. Further, assessment of the implementation of all Six (6) outputs revealed that; all six (6) outputs with eighty one (81) activities were partially implemented i.e. out of the eighty one (81) activities, thirty two (32) activities (40%) were fully implemented; thirty (30) activities (37.5%) were partially implemented, while nineteen (19) activities (12.5%) remained unimplemented. \uf0b7 Two (2) contracts worth UGX.12.397Bn in relation to construction of landing sites were cancelled due to delayed implementation of projects beyond 12 months from the initial intended completion date. \uf0b7 I noted delayed titling of 883.92 hectares of the acquired nucleus estate Land exposing it to risks of encroachment by individuals. \uf0b7 Review of four (4) sample procurements worth UGX.1.47Bn revealed an average delay of 140 days in the procurement process majorly as a result of delayed approval process by IFAD, contracts committee and Solicitor General.", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 146, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": "134", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 146, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["8", "Strengthening National Seed Certification Service Project (SNSCS).", "\uf0b7 Out of the planned six (6) strategic targets/goals to be achieved, none was either fully or partially achieved and one target was not even quantified to enable assessment."], [null, "2019/2020 Opinion Unqualified", null], ["9 Strengthening National Seed Certification Service Project (SNSCS). 2020/21 Opinion Unqualified \uf0b7 Out of the planned six (6) strategic targets/goals to be achieved by 30th June 2021, one (1) target was fully achieved, three (3) targets had been partially achieved and two (2) were not achieved at all. \uf0b7 The Project budgeted to receive UGX.1.184bn out of which UGX.1.049bn was received resulting into a shortfall of UGX.0.135bn, which is 11% of the budget. Further, out of the total warrants of UGX.1.049Bn received during the financial year, only UGX.0.199Bn was spent by the entity resulting in an unspent balance of UGX.0.85Bn representing absorption level of 19%. \uf0b7 I sampled five (5) outputs with 15 activities worth UGX.0.199Bn and noted that three (3) outputs with a total of seven (7) activities and expenditure worth UGX.0.199Bn were fully quantified; Two (2) outputs with a total of eight (8) activities were not quantified at all. Further, of the three quantified outputs assessed, one (1) output with 3 activities worth UGX.199, 045,000 was partially implemented. Out of the 3 activities, one (1) activity was partially implemented, while two (2) activities remained unimplemented. Two (2) outputs with four (4) activities worth NIL expenditure were not implemented. \uf0b7 AGRA amended the disbursement of Grant due to low absorption and decided to de-obligate US$.571,167 being the total un-disbursed funds for the project thus necessity to restructure the budget and milestone delivery plan to fit within US$.323, 450 that had been disbursed. \uf0b7 Contrary to the grant guidelines, unspent or un-committed grant funds remained on the project bank account and were not invested in highly liquid investments to earn income. \uf0b7 A number of project milestones had not been achieved by the end of the financial year exposing the Grant to a risk of failure to achieve its objectives.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 147, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None"], "type": "table"}}, {"content": "135", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 147, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["10", "The Uganda Multi-Sectoral Food Security and Nutrition Project.", "\uf0b7 Out of the planned fourteen (14) strategic targets/goals to be achieved by financial year 2020/2021; ten (10) (71%) had been fully achieved while four (4) (29%) were partially achieved."], [null, "2020/21 Opinion Unqualified", null], ["11 The Regional Pastoral Livelihoods Resilience Project. 2020/21 Opinion Unqualified \uf0b7 Out of the planned fourteen (14) strategic targets/goals to be achieved by financial year 2020/2021; six (6) had been fully achieved, five (5) were partially achieved while three (3) were not achieved at all. \uf0b7 There was a shortfall in releases from the donor of UGX.13.788Bn which is 30% of the budget. The project budgeted to receive UGX.0.3Bn GOU funding all of which was availed. Further, the entity remained with unspent balance of UGX.15.172Bn representing an absorption level of 54%. \uf0b7 I reviewed all the eleven (11) outputs with a total of twenty six (26) activities and expenditure of UGX.17.71Bn and noted all were fully quantified. Further, assessment of the level of implementation for the 11 outputs revealed that five (5) outputs with nine (9) activities and expenditure worth UGX.0.765Bn were fully implemented while the six (6) outputs with seventeen (17) activities worth UGX.16.945Bn were partially implemented i.e. out of the seventeen (17) activities, the entity fully implemented seven (7) activities (41%); five (5) activities (29%) were partially implemented, while five (5) activities (29%) remained unimplemented. \uf0b7 Assessment of achievement of services from implemented outputs revealed that although the Livestock marketing Information System is in place, it lacks up to date information for the beneficiaries implying that it", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 148, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None"], "type": "table"}}, {"content": "136", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 148, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["may not be regularly used. \uf0b7 Contract works for the valley dams which are the critical infrastructure for the long term sustainability of the project are past the completion time and works are still significantly behind schedule despite contractors having been paid substantial percentages of the contract sums \uf0b7 Shortcomings were noted on reliability of the market information data system designed to track information such as prices, tradeable volumes, diseases concerning livestock for use by famers such as failure to input market information data into the system since October 2019, lack of a designated system administrator that is responsible for managing and updating the system at the Ministry and lack of a system manual that provides standard guideline for the system use. \uf0b7 There was no Steering committee sitting during the year to facilitate and to ensure adherence to relevant strategies established by Government during project implementation.", null, null], ["12", "Dairy Development Authority.", "\uf0b7 DDA\u2019s dairy strategic plan had been prepared, approved and certified by NPA to evidence its alignment to the NDP-III."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 149, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None"], "type": "table"}}, {"content": [["may not be regularly used. \uf0b7 Contract works for the valley dams which are the critical infrastructure for the long term sustainability of the project are past the completion time and works are still significantly behind schedule despite contractors having been paid substantial percentages of the contract sums \uf0b7 Shortcomings were noted on reliability of the market information data system designed to track information such as prices, tradeable volumes, diseases concerning livestock for use by famers such as failure to input market information data into the system since October 2019, lack of a designated system administrator that is responsible for managing and updating the system at the Ministry and lack of a system manual that provides standard guideline for the system use. \uf0b7 There was no Steering committee sitting during the year to facilitate and to ensure adherence to relevant strategies established by Government during project implementation.", null, null], ["12", "Dairy Development Authority.", "\uf0b7 DDA\u2019s dairy strategic plan had been prepared, approved and certified by NPA to evidence its alignment to the NDP-III."], [null, "2020/21 Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 DDA directly received off-budget financing to a tune of UGX.0.63Bn from"], [null, null, "Fleming fund country grant II but it was never declared to the PSST and"], [null, null, "as such not appropriated to the entity by parliament."], [null, null, "\uf0b7 I sampled 4 outputs for review with a total of twenty four (24) activities"], [null, null, "and expenditure of UGX.3.8Bn and noted that One (01) output with four"], [null, null, "(04) activities and expenditure worth UGX1.1Bn was insufficiently"], [null, null, "quantified, that is, one (01) activity (25%) was quantified while three"], [null, null, "(03) activities (75%) were not clearly quantified to enable assessment of"], [null, null, "performance. Three (03) outputs with a total of twenty (20) activities and"], [null, null, "expenditure worth UGX.2.7Bn were not quantified at all. Further, I"], [null, null, "assessed the implementation of one activity that was quantified and"], [null, null, "noted that the Rehabilitation of Kyegegwa and Katakwi Milk Collection"], [null, null, "Centres(MCCs) was partially implemented."], [null, null, "\uf0b7 Submission of performance reports for the four quarters was made after"], [null, null, "the deadline dates and there was no evidence to confirm that the"], [null, null, "Accounting Officer prepared Monitoring Plans and reports which affect"], [null, null, "timely tracking and evaluation of performance."], [null, null, "\uf0b7 Analysis of the domestic arrears showed new arrears incurred during the"], [null, null, "year under review to the tune of UGX.0.178Bn. Further, I noted that"], [null, null, "there was no budget provision for settlement of these arrears in the year"], [null, null, "under review."], [null, null, "\uf0b7 I noted that the entity lost fixed assets through theft which included"], [null, null, "fifteen (15) desktop computers, two (02) laptop computers, a projector, a"], [null, null, "router, and cameras but they were not disclosed in the financial"], [null, null, "statements."], [null, null, "\uf0b7 The Authority has failed to collect CESS revenue compensation from"], [null, null, "MoFPED contrary to the presidential directive requiring the same."], [null, null, "\uf0b7 DDA is understaffed by seventy seven (77) posts out of one hundred and"], [null, null, "forty (140) posts which is 55% understaffing. The unfilled posts include"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 149, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None"], "type": "table"}}, {"content": "137", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 149, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "key positions like Head of internal audit, Director Finance and"], [null, "Administration, Planner, Regional managers, Principal Dairy Development"], [null, "Officers and Dairy inspectors. Some posts have remained vacant since"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 150, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": [["", "key positions like Head of internal audit, Director Finance and"], [null, "Administration, Planner, Regional managers, Principal Dairy Development"], [null, "Officers and Dairy inspectors. Some posts have remained vacant since"], [null, "2003."], ["13 National Agricultural Advisory Services (NAADS). 2020/21 Opinion Unqualified \uf0b7 The entity had prepared the strategic plan; but there was no approval and certification of the same by NPA to evidence alignment to the NDP- III at the time of audit. \uf0b7 Out of the budgeted NTR of UGX.3.587Bn, the Authority collected only UGX.0.12Bn, representing a performance of 3.3% of the target. There was 100% performance in GoU releases amounting to UGX. 243.9Bn. Further, NAADS remained with unspent balance of UGX.0.06Bn representing an absorption level of 99.9%. \uf0b7 I sampled four (04) outputs with a total of twenty five (25) activities and expenditure of 184.4Bn and noted that two (02) outputs with a total of three (03) activities and expenditure worth UGX.43.19Bn were fully quantified while two (02) outputs with a total of twenty two (22) activities and expenditure worth UGX.141.19Bn were insufficiently quantified i.e. out of the twenty two (22) activities, fourteen (14) activities (64%) were quantified while the balance of eight (08) activities (36%) were not clearly quantified. Further, assessment of the implementation of the two (2) outputs that were fully quantified with a total of three (03) activities revealed that none was fully implemented. \uf0b7 Assessment of one partially implemented output revealed that out of 3,010,000 hand hoes, only 2,500,000 hand hoes were procured and distributed to the Northern parts of the country instead of the planned vulnerable rural small holder farming households across the country. \uf0b7 Submission of performance reports for all quarters was made after the deadline dates. Furthermore, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports. \uf0b7 NAADS incurred huge LC charges to a tune of UGX.1.053Bn as a result of opened LCs worth UGX.71.25Bn for contracts that failed to deliver within the year. Further, I noted LCs worth UGX.23.13Bn that failed to perform for a period of more than two (2) financial years with one of UGX.2.071Bn for milk coolers outstanding for more than 4 years. \uf0b7 Review of the Kasese industrial park Agri-LED intervention worth UGX.3.9Bn revealed allocation of land to a bus company contrary to the set objectives and delayed payment of NWSC to connect piped water. \uf0b7 Review of the sugarcane production project implementation with investments of UGX.85Bn revealed shortcomings i.e.lack of feasibility assessment, lack of accruing benefits to the beneficiaries, weaknesses in the MoU signed with beneficiaries, limited information on members of the cooperatives, delays in contract completions, pending liquidated damages, and stalled activities. \uf0b7 I noted failure to enter into MOU\u2019s with beneficiaries of milk coolers contrary to the selection criteria of the standing orders of procedure for operation wealth creation. \uf0b7 There was lack of clearly identified beneficiaries from the start in the transportation and distribution of hoes intervention, lack of MOU\u2019s with delegated DLGs on distribution modalities and nugatory storage costs. \uf0b7 Review of the tractor strategic intervention revealed lack of assessment of potential beneficiaries and non-adherence to the terms of the MoU thus risks of beneficiaries without the capacity to manage the tractor for", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 150, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": "138", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 150, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["farming practice or as an enterprise. \uf0b7 NAADS had a Covid 19 arrears supplementary budget of UGX.17.84Bn all of which was warranted and absorbed. Further, review of utilisation revealed failure to settle long outstanding payables, appropriation in excess of requirement and diversion of Covid 19 relief funds worth UGX.10.032Bn from the settlement of domestic arrears to settlement of current year bills without seeking and obtaining the necessary approvals \uf0b7 A trend analysis of the domestic arrears showed an increase of UGX.7.085Bn (53.6%) from UGX.13.23Bn in the previous year to UGX.20.31Bn that remained unsettled at close of the year with arrears of UGX.0.162Bn relating to previous financial years. \uf0b7 Funds worth UGX.2.15Bn were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals \uf0b7 I noted long outstanding receivables of UGX.2.38Bn relating to cash balances and accountabilities that remained at the DLG at the time of restructuring thus casting doubt on their recoverability. \uf0b7 Review of the procurement function revealed shortcomings such as delayed supplies and unjustified extensions and non execution of performance security. \uf0b7 I noted that NAADS has an approved staff structure of 56 positions out of which 53 (94.6%) positions are filled. Key among the vacant posts is Manager Finance and Administration and Zonal Agricultural Development Officer. Further, I noted temporary appointments of six (6) staff for the sugarcane field based team for 30 months contrary to the recommended 12 months as stipulated in the regulations.", null, null, null], ["14", "Ministry of Agriculture, Animal, Industry and Fisheries (MAAIF). 2020/21", null, "\uf0b7 I noted that the Ministry had prepared the Agro-Industrialization (AGI) Programme as a strategic plan for 2020/21-2024/25 that is aligned to the NDP-III and according to the certificate of compliance for the FY 2020/21"], [null, null, null, "annual budget, the overall Agro-industrialization programme budget was"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 151, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None", "None"], "type": "table"}}, {"content": [["farming practice or as an enterprise. \uf0b7 NAADS had a Covid 19 arrears supplementary budget of UGX.17.84Bn all of which was warranted and absorbed. Further, review of utilisation revealed failure to settle long outstanding payables, appropriation in excess of requirement and diversion of Covid 19 relief funds worth UGX.10.032Bn from the settlement of domestic arrears to settlement of current year bills without seeking and obtaining the necessary approvals \uf0b7 A trend analysis of the domestic arrears showed an increase of UGX.7.085Bn (53.6%) from UGX.13.23Bn in the previous year to UGX.20.31Bn that remained unsettled at close of the year with arrears of UGX.0.162Bn relating to previous financial years. \uf0b7 Funds worth UGX.2.15Bn were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals \uf0b7 I noted long outstanding receivables of UGX.2.38Bn relating to cash balances and accountabilities that remained at the DLG at the time of restructuring thus casting doubt on their recoverability. \uf0b7 Review of the procurement function revealed shortcomings such as delayed supplies and unjustified extensions and non execution of performance security. \uf0b7 I noted that NAADS has an approved staff structure of 56 positions out of which 53 (94.6%) positions are filled. Key among the vacant posts is Manager Finance and Administration and Zonal Agricultural Development Officer. Further, I noted temporary appointments of six (6) staff for the sugarcane field based team for 30 months contrary to the recommended 12 months as stipulated in the regulations.", null, null, null], ["14", "Ministry of Agriculture, Animal, Industry and Fisheries (MAAIF). 2020/21", null, "\uf0b7 I noted that the Ministry had prepared the Agro-Industrialization (AGI) Programme as a strategic plan for 2020/21-2024/25 that is aligned to the NDP-III and according to the certificate of compliance for the FY 2020/21"], [null, null, null, "annual budget, the overall Agro-industrialization programme budget was"], [null, "Opinion Unqualified", null, "scored at 63.5% compliance to the NDP-III."], [null, null, null, "\uf0b7 There was a shortfall in NTR collections amounting to UGX.6.82bn representing 76% and a shortfall in GOU releases amounting to"], [null, null, null, "UGX.24.1Bn representing 14%. Further, out of the total warrants of"], [null, null, null, "UGX.151.2Bn received, UGX.146.95Bn was spent by the entity resulting in an unspent balance of UGX.4.24Bn representing absorption of 97%."], [null, "", "", "\uf0b7 The Ministry received off-budget financing to a tune of UGX.1.78Bn that"], [null, "", "", "was not appropriated as part of the entity budget contrary to the law."], [null, "", "", "\uf0b7 I sampled sixty-five (65) outputs with a total of one hundred and sixty-"], [null, "", "", "seven (167) activities and expenditure of UGX.98.2Bn for assessment. I"], [null, "", "", "noted that; sixty-one (61) outputs with a total of one hundred and sixty"], [null, "", "", "(160) activities and expenditure worth UGX.89.6Bn were fully quantified"], [null, "", "", "while four (4) outputs with a total of seven (7) activities and expenditure"], [null, "", "", "worth UGX.8.6Bn were not quantified at all to enable assessment of"], [null, "", "", "performance. Further, I assessed all the quantified 61 outputs and noted"], [null, "", "", "that; 34 outputs with a total of 75 activities worth UGX.39.1Bn were fully"], [null, "", "", "implemented and 27 outputs with a total of 85 activities worth"], [null, "", "", "UGX.50.5Bn were partially implemented i.e. out of the 85 activities, the"], [null, "", "", "Ministry fully implemented 39 activities (46%), partially implemented 44"], [null, "", "", "activities (52%) while 2 activities (2%) remained unimplemented."], [null, "", "", "\uf0b7 I noted failure of timely interventions to combat the foot and mouth"], [null, "", "", "disease (FMD) outbreak as a result of challenges faced in the"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 151, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None", "None", "None"], "type": "table"}}, {"content": "139", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 151, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "procurement of vaccines despite the availability of funds. The Ministry"], [null, "faced challenges as only 500,000 doses were delivered out of the"], [null, "procured 700,000 doses from the prior year and these came 4 months"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 152, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": [["", "procurement of vaccines despite the availability of funds. The Ministry"], [null, "faced challenges as only 500,000 doses were delivered out of the"], [null, "procured 700,000 doses from the prior year and these came 4 months"], [null, "after expected delivery. Further, none of the procured 2,311,000 doses"], [null, "procured in May 2020 were delivered within the contract period despite"], [null, "the emergency situation and by the time of audit, the contract had not"], [null, "fully performed with 611,000 doses outstanding."], [null, "\uf0b7 Shortcomings were noted in the management of the Ministry Public"], [null, "Investment Plan (PIP) Projects in regard to compliance with the"], [null, "Development Committee Guidelines 2016 and the budget execution"], [null, "circular 2020/2021. I noted incomplete approvals for Projects, non-"], [null, "adherence of Projects with appraisal Guidelines, ongoing projects after"], [null, "expiry of project duration and irregular and excessive spending on"], [null, "recurrent Items"], [null, "\uf0b7 Domestic arrears decreased by 14% from UGX.12.96Bn in the prior year"], [null, "to UGX.11.13Bn in the year under review. Further, a paltry UGX.2.42Bn"], [null, "budget provision was provided for settlement of domestic arrears in the"], [null, "current year budget."], [null, "\uf0b7 All documents pertaining to Contingency fund activities and transfers to"], [null, "agricultural institutions during the year worth UGX 11.95Bn were"], [null, "submitted to the IGG for investigations and I was unable to confirm"], [null, "whether the amount involved was applied to the intended purpose."], [null, "\uf0b7 Management did not undertake monthly wage and pension performance"], [null, "analysis to reconcile the payroll generated through the IPPS with the"], [null, "payment information from the IFMS as required resulting into delays in"], [null, "granting clearance to recruit, inefficient wage and pension payroll"], [null, "management, accumulated arrears and non-absorption of pension and"], [null, "gratuity budget."], [null, "\uf0b7 Out of 919 approved staffing positions, only 595 had been filled and the"], [null, "rest of the positions (324) were vacant representing 35% staffing gap."], [null, "Among the vacant were key positions such as directors, commissioners,"], [null, "assistant commissioners and principals in core directorates and noticed"], [null, "management\u2019s failure to undertake timely recruitments despite availability"], [null, "of funds."], ["15 Uganda Coffee Development Authority (UCDA). 2020/21 Opinion Unqualified \uf0b7 The entity had prepared the coffee strategy; but there was no approval and certification of the strategic plan by NPA to evidence alignment to the NDP-III at the time of audit. \uf0b7 Out of the budgeted NTR of UGX.27.5Bn, the Authority collected only UGX.20.1Bn, representing a performance of 73% of the target. \uf0b7 There was a shortfall in GoU releases amounting to UGX.5.8Bn representing 3.1% of the budgeted UGX.186.3Bn. Further, the entity remained with unspent balance of UGX.9.391Bn representing an absorption level of 94.8%. \uf0b7 The Authority received off-budget financing worth UGX.443M which was never declared to the PSST and as such no supplementary appropriation was issued as guided by the PSST. \uf0b7 I sampled eight (08) outputs with a total of sixty two (62) activities and expenditure of UGX.150.6Bn and noted that one (01) output with a total of four (04) activities and expenditure worth UGX.2.1Bn was fully quantified; three (03) outputs with a total of fifty four (54) activities and expenditure worth UGX.67.1Bn were insufficiently quantified i.e. out of the fifty four (54) activities, forty nine (49) activities (91%) were quantified while the balance of five (05) activities (9%) were not clearly", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 152, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["without logging onto the system. \uf0b7 An analysis of E-Voucher Management Agency (EVMA) system revealed that 168,086 (99%) of the farmers that accessed inputs redeemed the inputs for only one cycle without transitioning to cycles 2 and 3, 2191 (1.3%) transitioned to cycle 2 without transitioning to cycle 3, while 47 (0.03%) transitioned to cycle 3. \uf0b7 In the year 2019/2020 and 2020/2021, 347 farmers ordered inputs during the financial year at amounts that were in excess of the recommended threshold of UGX.1,350,000 worth UGX.186,792,644.", "None"], "type": "table"}}, {"content": "140 \nquantified and four (04) outputs with a total of four (04) activities and expenditure worth UGX.81.3Bn were not quantified at all. Further, assessment of the implementation of the one (01) output that was fully quantified with a total of four (04) activities revealed that it was partially implemented i.e. out of the four (4) activities, the entity fully implemented three (03) activities (75%) while one (1) activity (25%) remained unimplemented.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 152, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Submission of performance reports for three quarters was made after the deadline dates. Furthermore, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Review of the distribution lists (form Bs) attached to the accountabilities for coffee seedlings supplied revealed that deliveries to a tune of UGX.0.213Bn were made either out of season or towards season end thus rendering the survival of the inputs nearly impossible.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Fertilizers worth UGX.2.25Bn distributed to the cooperatives were unacknowledged by the intended coffee farmers. The form F3\u2019s where the actual farmers who received the fertilisers were supposed to have acknowledged had not yet been received and verified by management and neither had the cooperatives returned the empty fertiliser bags and filled in form F4\u2019s.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- 65,445 and 1880 bags of fertilisers for the western and Elgon region respectively had not yet been distributed at the time of inspection in September 2021 contrary to section 7 (a) of the fertiliser distribution guidelines that required application of fertilisers to only be done in the rainy season.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Field inspection of the procured fertilizers and materials to support the establishment of CWDR nurseries revealed several anomalies i.e. bad warehousing storage (stacked high on the floor, instead of pallets), lack of aeration and non-adherence to first in first out (FIFO) policy. Further, the nurseries for CWDR had not been setup and materials were simply kept in stores by the beneficiaries and some had started using the implements such as hoes, pangas, wheel burrows; mother gardens were poorly maintained and no labels of the lines had been added to the mother gardens.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UCDA had a Covid 19 arrears supplementary budget of UGX.73Bn all of which was warranted and absorbed 100%. Review of utilisation revealed doubtful payments, duplicated arrears on verified list and witting down of invoice amounts without supplier consent which exposes the entity to litigation", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Domestic arrears showed a movement in arrears from UGX.120,383,249,500 in the previous year to UGX.23,036,904,150 by the close of the financial year 2019/20, representing a decrease of 80.8%. Out of this, amount UGX.16,699,179,350 was incurred during the year under review.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A total of UGX.80,373,239,334 (43.1% of the approved budget) was provided for settlement of domestic arrears, however, arrears worth UGX.125,407,367,170 were paid resulting in settlement of prior year domestic arrears worth UGX.45,034,127,836.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Review of the procurement function revealed several shortcomings such as delays in the procurement process with an average delay period of 2 and a half months, failure to deliver within contractual timelines, un- deducted liquidated damages, inconsistent liquidated damages clauses and deviation from Ministry of Works specifications for vehicle", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "141", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 153, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", null, null], ["16", "Uganda Seeds Limited. 2019/20", "\uf0b7 A receivable of UGX.1,147,910,181 (17% of the total assets) could not be supported as there was no evidence to confirm the accuracy, existence and completeness of the reported balance."], [null, "Opinion Qualified", null], ["JUSTICE, LAW AND ORDER SECTOR", null, null], ["1", "Directorate of Government Analytical Laboratory (DGAL).", "\uf0b7 Out the total receipts for the financial year of UGX.24.684Bn, only UGX.15.630Bn was spent by the entity resulting in an unspent balance of UGX.9.054Bn representing an absorption level of 63.3%."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 154, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "142", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 154, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "their contract obligations."], [null, "\uf0b7 In the financial year 2019/2020, DGAL procured digital forensic tools for"], [null, "use to recover data on mobile phones at an estimated cost of USD.82,000"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 155, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None"], "type": "table"}}, {"content": [["", "their contract obligations."], [null, "\uf0b7 In the financial year 2019/2020, DGAL procured digital forensic tools for"], [null, "use to recover data on mobile phones at an estimated cost of USD.82,000"], [null, "(equivalent to UGX.290,232,000). In the period since acquisition, the"], [null, "entity has only used the forensic tools and equipment to process and"], [null, "analyse just one (1) case raising the possibility that the equipment is"], [null, "under-utilised."], [null, "\uf0b7 Nine (9) staff positions for a Commissioner, Government Analysts and"], [null, "drivers in the Directorate were cleared by the Ministry of Public Service"], [null, "for recruitment, and the directorate received funding amounting to"], [null, "UGX.0.032Bn for the purpose. The recruitment process had not been"], [null, "finalised at the year end and the funds were returned to the consolidated"], [null, "fund."], [null, "\uf0b7"], ["2 Justice Law and Order Sector JLOS-SWAP. 2019/20 Opinion Unqualified \uf0b7 I noted that out of the budgeted revenue of UGX. 121,683,362,209 for the financial year 2019/2020 only UGX. 104,870,934,098 (86%) was released, resulting in a shortfall of UGX. 16,812,428,111 (14%) on the overall. The largest shortfall of UGX. 10,304,157,202 (8.4%) was in respect to the Development Partners funding, \uf0b7 A review of the JLOS SWAP disbursement of funds to implementing entities and the respective actual expenditure revealed that only UGX. 81,391,358,207 was spent out of the availed UGX.104,870,934,098, resulting in an unspent balance of UGX.31,080,004,792. The unspent balance excludes the JLOS House Project balance of UGX. 18,592,439,794, which commenced in the subsequent financial year 2020/21. \uf0b7 I reviewed all the 43 activities under the JLOS Secretariat with a budget of UGX.23.561Bn, out of which UGX.18.027Bn was released, resulting in a shortfall of UGX.5.534Bn, which is 23.5% of the budget \uf0b7 I further noted from the analysis of the annual performance report that some critical activities for which funds had been released had not been implemented. \uf0b7 Out of the 43 activities with a total budget of UGX.23.561Bn, I reviewed the extent of quantification of outputs and activities and noted that a total of three (3) activities and releases worth UGX.4.076Bn were not quantified at all to enable assessment of performance. A total of forty (40) activities and releases worth UGX.13.951Bn were fully quantified. That is, all the forty (40) activities (100%) were clearly quantified to enable assessment of performance. \uf0b7 I assessed the implementation of all the Forty (40) JLOS SWAP activities worth UGX.13.951Bn that were fully quantified and noted that Fourteen (14) activities worth UGX.12.507Bn were fully implemented. The entity implemented all the Fourteen (14) activities (100%) within the JLOS SWAP consolidated strategic outputs. Four (4) activities worth UGX.0.665Bn were partially implemented. All the Four (4) activities within the JLOS SWAP consolidated strategic outputs were not achieved 100%. Twenty-two (22) activities worth UGX0.779Bn were not implemented at all. \uf0b7 I observed that UGX.656,905,350 advanced to various beneficiaries by four implementing agencies to execute sector activities during the COVID- 19 lockdown period, i.e. between November 2019 and June 2020, lacked the necessary supporting documents such as payment vouchers, activity reports and receipts at the time of audit (November 2020) and were", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 155, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None"], "type": "table"}}, {"content": "143", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 155, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["submitted during the month of January 2021, implying that the funds had not been accounted for by 30th June 2020. \uf0b7 I noted from the review of financial statements that management did not disclose the outstanding balances as at 30th June 2019. Consequently, no provision was made to cater for domestic arrears in the financial year 2019/2020 budget. But I noted that UGX.9,145,799 was spent to settle outstanding bills in respect of conference facilities for JLOS and the supply and delivery of law reference books", null, null, null], ["3", "Office of the Director of Public Prosecutions. 2020/21 Opinion Unqualified", null, "\uf0b7 During the years under review, 666,620 cases were brought forward from the previous years, and 99,232 cases were registered during the year, giving a cumulative sum of 765,492 cases recorded. Of these cumulative"], [null, null, null, "cases, only 40,466 (5%) were cleared during the year. \uf0b7 Over the five years only 253,596 cases representing (33%) have been"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 156, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None", "None"], "type": "table"}}, {"content": [["submitted during the month of January 2021, implying that the funds had not been accounted for by 30th June 2020. \uf0b7 I noted from the review of financial statements that management did not disclose the outstanding balances as at 30th June 2019. Consequently, no provision was made to cater for domestic arrears in the financial year 2019/2020 budget. But I noted that UGX.9,145,799 was spent to settle outstanding bills in respect of conference facilities for JLOS and the supply and delivery of law reference books", null, null, null], ["3", "Office of the Director of Public Prosecutions. 2020/21 Opinion Unqualified", null, "\uf0b7 During the years under review, 666,620 cases were brought forward from the previous years, and 99,232 cases were registered during the year, giving a cumulative sum of 765,492 cases recorded. Of these cumulative"], [null, null, null, "cases, only 40,466 (5%) were cleared during the year. \uf0b7 Over the five years only 253,596 cases representing (33%) have been"], [null, null, null, "concluded through conviction, acquittal, withdrawal, dismissal and closed files. \uf0b7 ODPP continues to incur substantial annual maintenance costs of"], [null, "", "", "UGX.2,808,000,000 in spite of the low coverage of the system (only 41"], [null, "", "", "stations out of the planned 138) and some system components like the complaint handling and processing component are not fully operational."], [null, "", null, null], ["4 Uganda Human Rights Commission 2020/21 Opinion Unqualified \uf0b7 I noted that the Commission did not have an approved strategic plan that was aligned to NDP III by the time of audit. The draft plan prepared by the entity had not been certified by NPA. \uf0b7 The Commission collected over 100% of its NTR target for the year over and above the target. The Commission absorbed only 86.8% of the funds that were released by government. \uf0b7 The Commission received off-budget financing directly from development partners to a tune of UGX.2.187Bn, which was not declared to Treasury and, therefore, not appropriated to the entity by Parliament. \uf0b7 Management did not quantify 2 outputs with 6 activities and expenditure worth UGX 0.12Bn. \uf0b7 Out of (11) outputs that were fully quantified with 22 activities, 3 activities worth UGX.0.44Bn were fully implemented, 18 activities worth UGX.15.54Bn were partially implemented. 1 output with 1 activity worth UGX.0.17Bn was not implemented at all. \uf0b7 \uf0b7 The Commission neither prepared annual budget monitoring plans nor submitted quarterly budget monitoring reports. The Commission also failed to submit all its quarterly budget performance reports in time. \uf0b7 The UHRC had tribunal case backlog of 1,756 cases at the beginning of the financial year 2020/2021, and 71 additional cases were registered during the year, resulting in a total of 1,827 outstanding cases. Out of the 1,827 cases, only 326 (17.8%) were investigated and disposed of. The", null, null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 156, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None", "None"], "type": "table"}}, {"content": "144", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 156, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["un-cleared complaints at the tribunal level stood at 1,501 at the year-end, translating into underperformance of 82.2%. \uf0b7 Timeline errors continue to occur due to the limited interface between IPPS and IFMS in payroll processing. A review of the payroll register and IFMS payment file revealed that UGX.5.706 Bn was paid as per payroll register; while IFMS indicates that UGX.6.124Bn was paid, resulting in an overpayment of UGX. 0.417Bn.", null, null], ["5", "Uganda Law Reform Commission. 2020/21", "\uf0b7 I noted that the Commission did not have an approved strategic plan that was aligned to NDP III by the time of audit. The draft plan prepared by the entity had not been certified by NPA. \uf0b7 The Commission collected only 100% of its NTR target for the year which was commendable. The Commission also absorbed only 92.4% of the"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 157, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": [["un-cleared complaints at the tribunal level stood at 1,501 at the year-end, translating into underperformance of 82.2%. \uf0b7 Timeline errors continue to occur due to the limited interface between IPPS and IFMS in payroll processing. A review of the payroll register and IFMS payment file revealed that UGX.5.706 Bn was paid as per payroll register; while IFMS indicates that UGX.6.124Bn was paid, resulting in an overpayment of UGX. 0.417Bn.", null, null], ["5", "Uganda Law Reform Commission. 2020/21", "\uf0b7 I noted that the Commission did not have an approved strategic plan that was aligned to NDP III by the time of audit. The draft plan prepared by the entity had not been certified by NPA. \uf0b7 The Commission collected only 100% of its NTR target for the year which was commendable. The Commission also absorbed only 92.4% of the"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 Out of the 8 outputs assessed with 37 activities and expenditure of"], [null, null, "UGX.7.74Bn, 6 outputs with worth UGX.4.53Bn were fully quantified."], [null, null, "\uf0b7 I assessed the implementation of 6 outputs with 24 activities that were"], [null, null, "fully quantified and noted that 1 output with 3 activities and expenditure"], [null, null, "worth UGX 3.43Bn was fully implemented while 5 outputs with 21"], [null, null, "activities worth UGX.1.1Bn were partially implemented. Out of the 21"], [null, null, "activities, the entity fully implemented 9 activities, 4 activities were"], [null, null, "partially implemented, while 8 activities remained unimplemented."], [null, null, "\uf0b7 The Commission neither prepared annual budget monitoring plans nor"], [null, null, "submitted quarterly budget monitoring reports. The Commission also"], [null, null, "failed to submit all its quarterly budget performance reports in time."], [null, null, "\uf0b7 ULRC did not have any domestic arrears brought forward from the"], [null, null, "previous year; however, the entity recorded payables worth"], [null, null, "UGX.124,626,384 under court awards and compensations in the year"], [null, null, "under audit."], ["6 Judicial Service Commission 2020/21 Opinion Unqualified \uf0b7 I noted that the Commission submitted a draft strategic plan to NPA for approval. \uf0b7 The Commission budgeted for NTR of UGX.4.5bn for the financial year 2020/21, however only UGX. 788,000 was collected representing performance of 0.02% of the target. The Commission absorbed 95.7% of the funds that were released. \uf0b7 Out of the fifteen (15) outputs sampled, ten (10) were fully quantified, while one (1) was insufficiently quantified and two (2) were not quantified at all. \uf0b7 Out of the ten (10) outputs assessed, five (5) were fully implemented while five (5) were partially implemented. \uf0b7 The Commission neither prepared annual budget monitoring plans nor submitted quarterly budget monitoring reports. The Commission also failed to submit all its quarterly budget performance reports in time. \uf0b7 Out of the approved 143 staff positions, ninety-seven (97) positions were filled while forty-seven (47) positions were vacant. \uf0b7 The commission did not remit to URA PAYE of UGX.138,219,093.", null, null], ["7", "Ministry of Justice and Constitutional Affairs. 2020/21", "\uf0b7 At the time of audit, the entity strategic plan had not yet been submitted to NPA; management was awaiting the completion of revising"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 157, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "145", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 157, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Opinion", "the Governance and Security Programme. \uf0b7 The entity budgeted to collect NTR of UGX.0.112Bn but collected UGX.0.233Bn representing a performance of 208% of the target."], [null, "Unqualified", null], ["8 The Directorate of Citizenship and Immigration Control. 2020/21 Opinion Unqualified \uf0b7 The DCIC prepared a strategic plan for 2020-2025 that was approved by the National Planning Authority on 22nd November 2021. However, following the issuance of a Certificate of Approval, management had not approved the plan for implementation. \uf0b7 \uf0b7 Out of the total receipts for the financial year of UGX.104.9Bn, only UGX.103.9Bn was spent by the entity resulting in an unspent balance of UGX.1.0Bn representing an absorption level of 99%. \uf0b7 I sampled seventeen (17) outputs with a total of one hundred seventeen (117) activities and expenditure of UGX.101.8Bn for assessment and noted that eleven (11) outputs with expenditure worth UGX.26.95Bn were fully quantified. Five (5) outputs with worth UGX.74.09Bn were insufficiently quantified, and One (1) output with expenditure worth UGX.0.13Bn was not quantified at all \uf0b7 I noted that a sum of UGX.1.02Bn was released to DCIC to settle Domestic Arrears to a supplier under Covid-19 related funding. \uf0b7 An assessment of service delivery revealed that DCIC takes an average of 7.7 days to process a passport and a further 7.3 days from the date of printing to issue the passport to the citizens. I further observed that although the Directorate has several regional offices for processing of passports, 97% of the applications for passports and 92% of the issuances are done at the Central Office in Kampala. \uf0b7 A trend analysis of the Directorate domestic arrears over the past three", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 158, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "146", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 158, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["years showed a decreasing trend from UGX.4.19Bn in 2018/2019 to UGX.0.32Bn in 2020/2021. \uf0b7 A review of the approved budget estimates for the year revealed that only UGX.1,015,473,085 (11.4%) was budgeted and released to settle domestic arrears amounting to UGX.8,898,668,915, implying insufficient budgeting for domestic arrears. \uf0b7 The Directorate procured an e-visa and permit management system during the financial year. I observed a number of contract conditions, including final user acceptance testing, completion of the setup of the system workflow, training of end-users, and integration of the system to other government systems in NIRA, CAA, URSB, and URA had not yet to be achieved. \uf0b7 The Directorate procured a consultant for the configuration, installation and maintenance of an Integrated System for archived records and the maintenance of the electronic data management system. I observed delays in contract execution and that the entity did not have a Service Level Agreement to guide the support and maintenance of the system.", null, null], ["9", "The Court of Judicature (The Judiciary).", "\uf0b7 The Judiciary prepared a strategic plan and had it approved by NPA at the time of audit."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 159, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": [["years showed a decreasing trend from UGX.4.19Bn in 2018/2019 to UGX.0.32Bn in 2020/2021. \uf0b7 A review of the approved budget estimates for the year revealed that only UGX.1,015,473,085 (11.4%) was budgeted and released to settle domestic arrears amounting to UGX.8,898,668,915, implying insufficient budgeting for domestic arrears. \uf0b7 The Directorate procured an e-visa and permit management system during the financial year. I observed a number of contract conditions, including final user acceptance testing, completion of the setup of the system workflow, training of end-users, and integration of the system to other government systems in NIRA, CAA, URSB, and URA had not yet to be achieved. \uf0b7 The Directorate procured a consultant for the configuration, installation and maintenance of an Integrated System for archived records and the maintenance of the electronic data management system. I observed delays in contract execution and that the entity did not have a Service Level Agreement to guide the support and maintenance of the system.", null, null], ["9", "The Court of Judicature (The Judiciary).", "\uf0b7 The Judiciary prepared a strategic plan and had it approved by NPA at the time of audit."], [null, "2020/21 Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 Thirteen (13) outputs with a total of sixty-seven (67) activities were"], [null, null, "quantified, while seven (7) outputs with a total of twenty-seven (27)"], [null, null, "activities were insufficiently quantified, and six (6) outputs with a total of"], [null, null, "forty-five (45) activities were not quantified at all. Further, of the thirteen"], [null, null, "(13) quantified outputs/activities assessed, five (5) outputs with fourteen"], [null, null, "(14) activities were fully implemented; eight (8) outputs with fifty-three"], [null, null, "activities were partially implemented."], [null, null, "\uf0b7 Submission of all performance reports for all the quarters was made after"], [null, null, "the deadline dates."], [null, null, "\uf0b7 I noted the accumulation of case backlog due to delayed"], [null, null, "operationalisation of gazetted courts and a limited number of judicial"], [null, null, "officer\u2019s compared to the workload."], [null, null, "\uf0b7 Judiciary had a COVID 19 arrears supplementary budget of UGX.8.66Bn,"], [null, null, "all of which was warranted and spent representing 100% of the budget"], [null, null, "absorption."], [null, null, "\uf0b7 I noted an increase in receivables from UGX 661,164,656(2019/2020) to"], [null, null, "UGX 3,268,317,882 (2020/2021). This was partly due to UGX."], [null, null, "1,652,842,084 that was advanced to courts to undertake election"], [null, null, "petitions and remained unaccounted for at the end of the financial year"], [null, null, "under audit. Furthermore, the other receivables of UGX.320,947,170"], [null, null, "carried forward from previous years remained outstanding with no"], [null, null, "recoveries made."], [null, null, "\uf0b7 I noted that management accrued new domestic arrears totalling UGX."], [null, null, "4,171,245,048 during the financial year 2020/2021 compared to UGX."], [null, null, "2,641,109,446 new arrears accrued in 2019/2020, registering an"], [null, null, "increment of new arrears of UGX. 1,530,135,602 thus representing a"], [null, null, "58% growth rate."], [null, null, "\uf0b7 Judiciary did not budget for domestic arrears amounting to UGX.3.543Bn,"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 159, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "147", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 159, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "which remained outstanding in the FY 2019/20."], [null, "\uf0b7 I noted inconsistencies in statistics reported on both pending and cases"], [null, "handled by the Judiciary during the period."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 160, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None"], "type": "table"}}, {"content": [["", "which remained outstanding in the FY 2019/20."], [null, "\uf0b7 I noted inconsistencies in statistics reported on both pending and cases"], [null, "handled by the Judiciary during the period."], [null, "\uf0b7 I noted delays in the implementation of The Electronic Court Case"], [null, "Management Information System (ECCMIS); an overall average delay of"], [null, "3 months since the Go-live had been scheduled on 7th June 2021. But, as"], [null, "of 11th October 2021, this has not yet been done. Data migration of the"], [null, "Phase 1 stations from CCAS into the new integrated ECCMIS has not"], [null, "been performed; the project was still at the design and development"], [null, "stage at the time of audit; the Change management training is still"], [null, "ongoing as of 6th October 2021, yet the training had been scheduled for"], [null, "23rd October 2020, some planned activities were not implemented, like"], [null, "the migration of data for phase 1 entities from the court case"], [null, "administration system (CCAS) to ECCMIS."], ["10 The Uganda Prisons Service. 2020/21 Opinion Unqualified \uf0b7 The UPS prepared a strategic plan for the period 2020-2025 and was approved by the National Planning Authority on the 23rd of July 2021. \uf0b7 Out of the total receipts for the financial year of UGX.310.8Bn, only UGX.306.5Bn was spent by the entity resulting in an unspent balance of UGX.4.4Bn representing an absorption level of 98.6%. \uf0b7 I sampled fourteen (14) outputs with a total of eighty seven (87) activities and expenditure of UGX.316.2Bn for assessment and noted that ten (10) outputs with a total of fifty-seven (57) activities and expenditure worth UGX.293.82Bn were fully quantified and four (4) outputs with a total of thirty (30) activities and expenditure worth UGX 22.36Bn were insufficiently quantified \uf0b7 I noted that of the 57 quantified activities worth UGX293.82Bn assessed; 35 activities representing 61% were fully implemented, 20 activities representing 35% were partially implemented, while 2 activities representing 4% were not implemented. \uf0b7 I noted that a sum of UGX. 40,6Bn was released to UPS for the settlement of Domestic Arrears to suppliers under Covid-19 related funding with all funds spent for settlement of arrears. \uf0b7 A trend analysis of the Service\u2019s domestic arrears over the past three years showed a decreasing trend from UGX.65.97Bn in 2018/2019 to UGX.62.345Bn in 2020/2021. \uf0b7 I noted that UPS was only allocated UGX.40.6Bn (67.4%) for settlement of domestic arrears worth UGX.60.2Bn and paid for arrears worth UGX.54.8Bn with the additional funds worth UGX.14.2Bn diverted from planned activities to pay for the arrears \uf0b7 An assessment of service delivery revealed cases of overcrowding in prison cells with the congestion levels increasing from 291.5% in 2017/18 to 321.1% in 2020/2021. This compromises the welfare of the inmates and may result in a number of health risks such as the quick spread of diseases and compromising on sanitation. The existing congestion has proved a challenge for the prisons\u2019 service when implementing Standard Operating Procedures (SOPs) to reduce the spread of COVID-19. It has also posed a challenge in separating different categories of offenders to break the cyclic chain of crime and violence. \uf0b7 I noted that a total of 33 (12.7%) prisons stations are still using the bucket system of sanitation which may turn cells into a breeding centre for diseases, resulting in the violation of the prisoners\u2019 rights \uf0b7 I noted cases of over stay of prisoners on remand with the prisoners\u2019", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 160, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None"], "type": "table"}}, {"content": "148", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 160, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["length of stay on remand increasing from 10.5 to 18.8 months for capital offenders and from 2.6 months to 3.8 months for petty offenders from 2016/17 to 2020/2021 respectively. For example out of the 32,409 prisoners on remand, a total of 13,933 prisoners had overstayed on remand \uf0b7 I observed challenges of staff accommodation which currently stands at a deficit of 7,217 (65.1%) housing units with staff staying in temporary houses/shelters/not accommodated \uf0b7 The Service also faced challenges of under staffing where out of an approved organisation structure comprising of 49,470 staff, only 12,860 (26%) posts were filled, leaving a balance of 36,610 (74%) posts vacant. This leads to high staff prisoner ratio and causes fatigue among the few staff \uf0b7 I noted that sixty-seven (67) of the prison stations did not have buses to enable safe and secure transportation of prisoners to court which resulted into delayed delivery of prisoners to courts, transportation of high-risk inmates on open trucks, and prisoners and staff walking long distances to attend court. \uf0b7 I noted delays in completion of the Prisoners Management Information System (PMIS) which has delayed the enjoyment of anticipated benefits from the system. \uf0b7 I observed challenges in land management including encroachments, land disputes and encumbrances. Out of 158 pieces of land of different sizes in the different parts of the country, only 52 pieces were surveyed and titled, 17 pieces were surveyed but still not yet titled, while 89 pieces were not yet surveyed. Furthermore, the UPS did not have land surveying equipment", null, null], ["11", "The Law Development Centre.", "\uf0b7 LDC had prepared the Strategic Plan aligned to NDP III and approved by NPA."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 161, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "149", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 161, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 The entity submitted all performance reports after the deadline."], [null, null, "\uf0b7 LDC had outstanding commitments brought forward totaling UGX."], [null, null, "2,697,202,827 as at 30th June 2020. During the year under review, UGX."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 162, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": [["", null, "\uf0b7 The entity submitted all performance reports after the deadline."], [null, null, "\uf0b7 LDC had outstanding commitments brought forward totaling UGX."], [null, null, "2,697,202,827 as at 30th June 2020. During the year under review, UGX."], [null, null, "1,490,351,141 was paid, and UGX. 786,304,467 was accumulated,"], [null, null, "leaving an outstanding of UGX. 1,993,156,153 as at 30th June 2021."], ["12 The Uganda Registration Services Bureau \u2013 Liquidation. 2020/21 Opinion Unqualified \uf0b7 The entity had a court appropriation of UGX.1.162Bn for the financial year 2020/2021 and an appropriation by court brought forward from the previous year 2019/2020 of UGX.0.640Bn totaling up to UGX.1.802Bn receipts. \uf0b7 Out of the total funds available for expenditure of UGX.1.802Bn, UGX.1.277Bn was spent by the bureau resulting in an unspent balance of UGX.0.525, representing an absorption level of 70.9%. \uf0b7 I reviewed all the outputs and noted that the outputs were all adequately quantified. \uf0b7 Out of the six (6) outputs assessed, one (1) was fully implemented, while five (5) were partially implemented. Five (5) outputs with twenty-four (24) activities worth UGX1.061Bn were partially implemented. \uf0b7 URSB did not prepare performance reports for liquidation. \uf0b7 I observed that the bureau had receivables carried forward from the previous financial years amounting to UGX.6.243Bn that remained outstanding at the end of the financial year under audit.", null, null], ["13", "The Uganda Registration", "\uf0b7 The URSB strategic plan was prepared and approved by NPA."], ["", "Services Bureau - Operations. 2020/21 Opinion", null], [null, "Unqualified", ""], [null, "", ""], [null, null, "\uf0b7 Out of the seven (7) outputs sampled, five (5) were fully quantified, while"], [null, null, "one (1) was insufficiently quantified and one (1) was not quantified at all."], [null, null, "\uf0b7 Out of the five (5) outputs assessed, two (2) were fully implemented"], [null, null, "while three (3) were partially implemented."], [null, null, "\uf0b7 Submission of all the quarterly performance reports was made after the"], [null, null, "deadline date. Also, inconsistencies were noted in the annual"], [null, null, "performance report and the system-generated reports. For example,"], [null, null, "management reported four (4) and two (2) patents to have been granted"], [null, null, "in the financial years of June 2020 and June 2021, respectively. Yet the"], [null, null, "system report analysis showed that no patent had been granted in the"], [null, null, "last two financial years."], [null, null, "\uf0b7 Despite a positive increase in the number of searches on the system,"], [null, null, "there was a significant decline in the performance of industrial designs"], [null, null, "registered, Local Trademarks renewed, Patents granted, and foreign"], [null, null, "trademarks registered"], [null, null, "\uf0b7 I analysed the number of applications received and eventually registered"], [null, null, "for the Utility model, patents and industrial designs and noted a"], [null, null, "significant difference in the number of applications that materialised to"], [null, null, "actual registrations. For instance, three (3) out of nineteen (19) Utility"], [null, null, "model applications were granted, two (2) out of the fifteen (15) Patent"], [null, null, "applications were granted, seventeen (17) out of the seventy-six (76)"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 162, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "150", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 162, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "were granted."], [null, "\uf0b7 I noted a decline in performance for activities planned under Civil"], [null, "Registration; the number of churches registered declined by 38.8%."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 163, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None"], "type": "table"}}, {"content": [["", "were granted."], [null, "\uf0b7 I noted a decline in performance for activities planned under Civil"], [null, "Registration; the number of churches registered declined by 38.8%."], [null, "Similarly, the number of Marriage returns FBOs, and Districts registered a"], [null, "decline in the performance of 17.56%."], [null, "\uf0b7 I noted shortcomings in the performance of the National Marriage"], [null, "registration system such as; NMRS could not internally generate reports;"], [null, "few staff are trained, incomplete information on certificates generated"], [null, "through the system, the system does not allow bulky payments, resulting"], [null, "in multiple bank charges to the customer, other systems of the Bureau"], [null, "like on base are not integrated with NMRS."], [null, "\uf0b7 URSB received COVID 19 arrears supplementary budget of"], [null, "UGX.0.0318Bn, all of which was spent representing 100% of the budget"], [null, "absorption."], [null, "\uf0b7 The Bureau had UGX.4.516Bn in domestic arrears, but it budgeted and"], [null, "was warranted UGX.0.032Bn, leaving a balance of UGX.4.484Bn"], [null, "unbudgeted. URSB effected payments totaling UGX.1.216Bnresulting in"], [null, "excess of UGX.1.184Bn above the approved budget. Domestic arrears"], [null, "increased by UGX.3.055Bn (68%) from UGX.1.466Bn to UGX.4.516Bn as"], [null, "at June 2021. The arrears remained unsettled at the close of the year."], [null, "\uf0b7 I reviewed the business registration system and noted the absence of an"], [null, "inbuilt mechanism to track and trace the movement and clearance of"], [null, "queries raised regarding name reservations and applications. The entity"], [null, "still has some processes that use manual backup. There were delays in"], [null, "the development of the Quality Management system ISO 9001(QMS)"], ["14 The Ministry of Internal Affairs. 2020/21 Opinion Unqualified \uf0b7 The Ministry of Internal Affairs prepared a strategic plan for 2020-2025. However, it had not been approved by the National Planning Authority at the time of audit. \uf0b7 Out of the total receipts for the financial year of UGX.51.5Bn, only UGX.50.8Bn was spent by the entity resulting in an unspent balance of UGX.0.7Bn representing an absorption level of 99%. \uf0b7 I sampled forty-one (41) outputs with a total of one hundred and ninety- seven (197) activities and expenditure of UGX.37.7Bn for assessment and noted that fifty-nine (59) activities with expenditure worth UGX.11.30Bn were fully quantified. one hundred thirty-seven (137) activities with worth UGX.26.1Bn were insufficiently quantified, and one (1) activity with expenditure worth UGX.0.24Bn was not quantified at all \uf0b7 An assessment of service delivery revealed that in the financial year 2020/2021, the Ministry extended support to 299 victims of human trafficking, which is only 45% of the total victims of human trafficking as reported by the Uganda Police Force. An assessment of the Monitoring of NGOs revealed that although the Ministry had registered 2,249 NGOs, the Ministry could only carry out offsite inspections of just 145 NGOs or 1% of all registered NGOs. \uf0b7 A trend analysis of the Ministry domestic arrears over the past three years showed an increasing trend from UGX.0.078Bn in 2018/2019 to UGX.1.45Bn in 2020/2021. \uf0b7 The Ministry paid for repair services worth UGX.13,237,877 without being certified by the responsible technical officer to confirm receipt of the services. The Ministry also procured stores worth UGX.88,444,071, which were not recorded in the Ministry\u2019s stores records. \uf0b7 I noted that procurements worth UGX.88,844,071 were not recorded in", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 163, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None"], "type": "table"}}, {"content": "151", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 163, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["the stores\u2019 ledgers nor witnessed by internal audit, making it difficult to verify the deliveries. \uf0b7 The Ministry of Internal Affairs has an approved structure of 224 positions, out of which 105 are filled, resulting in a shortfall of 119 (representing 47%)., including critical positions such as Commissioner Compliance, Assistant Commissioner Compliance, Senior Internal Auditor, Commissioner and Assistant Commissioner for the Social Integration department were vacant.", null, null], ["15", "Uganda Police Force. 2020/21", "\uf0b7 Uganda Police Force prepared a strategic plan for the period 2020-2025. However, the plan had not yet been approved by the National Planning Authority at the time of audit ."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 164, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "152", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 164, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "surveyed nor titled."], ["16 National Identification and Registration Authority (NIRA). 2020/21 Opinion Unqualified \uf0b7 NIRA prepared a strategic plan for the period 2020-2025, which was approved by the National Planning Authority. However, the plan is yet to be approved by the Board of the Authority for implementation. \uf0b7 NIRA budgeted to collect NTR of UGX.15.0Bn during the year. However, by the end of the year, NIRA had collected a total of UGX.3.66Bn. \uf0b7 Out of the total GoU receipts for the financial year of UGX.55.2Bn, only UGX.53.3Bn was spent by the entity resulting in an unspent balance of UGX.1.7Bn representing an absorption level of 97%. As a result, I noted that of the twenty-four (24) fully quantified activities worth UGX.70.6Bn assessed; 10 activities representing 42% were fully implemented, 12 activities representing 50% were partially implemented, while 2 activities representing 8% were not implemented at all. \uf0b7 I assessed the extent of service delivery and noted that only 11% of the planned 1,712,880 citizens were registered during the year, while only 30% of the planned 2,000,000 National IDs were issued. \uf0b7 I assessed the progress on registration of births and deaths and observed that NIRA registered 90% of the planned 960,000 births and only 1.3% of the 960,000 deaths. \uf0b7 A review of the progress of registering citizens indicated that as of December 2021, 29,713,029 applications, or 69% of all Ugandans, had applied to NIRA for registration. Of these, only 25,557,448 or 86% of the applicants had been registered, and only 16,258,521 (63.6%) have been issued with National Identity cards. \uf0b7 Only 16.3 million cards out of the over 19 million national identity cards so far printed have been claimed, leaving over 2.7 million cards unissued or unclaimed. \uf0b7 At the time of audit (December 2021), the Authority had over 4.3 million applications yet to be processed. Of these, 3.2 million applications were still being processed, while 1.1 million applications have been rejected. \uf0b7 NIRA plans to register at least 28,000 aliens annually and issue them with the relevant identification cards. From 2015 to date, the entity has only received 16 applications for alien IDs, and no Alien ID has been issued. \uf0b7 A reviewed the outcome of the initiative to register learners (or school going children within their schools) undertaken in 2017/2018 to determine whether all registered learners had been issued with NINs. I noted that records of over 1.8 million (or 19%) learners\u2019 who registered during that exercise had been rejected and thus not processed for issuance of NINs and Identification Cards. \uf0b7 NIRA failed to procure over 4,500,000 million IDs from the Uganda Security Printing Company as the Joint Venture Agreement required. As a result, the entity has recognised a contingent liability of UGX.33.5Bn.", null, null], ["17", "Amnesty Commission 2020/21", "\uf0b7 The entity budgeted to receive UGX.4.016Bn, out of which UGX.3.868Bn was warranted, resulting in a shortfall of UGX.0.147Bn, which is 3.7% of the budget."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 165, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": [["", null, "surveyed nor titled."], ["16 National Identification and Registration Authority (NIRA). 2020/21 Opinion Unqualified \uf0b7 NIRA prepared a strategic plan for the period 2020-2025, which was approved by the National Planning Authority. However, the plan is yet to be approved by the Board of the Authority for implementation. \uf0b7 NIRA budgeted to collect NTR of UGX.15.0Bn during the year. However, by the end of the year, NIRA had collected a total of UGX.3.66Bn. \uf0b7 Out of the total GoU receipts for the financial year of UGX.55.2Bn, only UGX.53.3Bn was spent by the entity resulting in an unspent balance of UGX.1.7Bn representing an absorption level of 97%. As a result, I noted that of the twenty-four (24) fully quantified activities worth UGX.70.6Bn assessed; 10 activities representing 42% were fully implemented, 12 activities representing 50% were partially implemented, while 2 activities representing 8% were not implemented at all. \uf0b7 I assessed the extent of service delivery and noted that only 11% of the planned 1,712,880 citizens were registered during the year, while only 30% of the planned 2,000,000 National IDs were issued. \uf0b7 I assessed the progress on registration of births and deaths and observed that NIRA registered 90% of the planned 960,000 births and only 1.3% of the 960,000 deaths. \uf0b7 A review of the progress of registering citizens indicated that as of December 2021, 29,713,029 applications, or 69% of all Ugandans, had applied to NIRA for registration. Of these, only 25,557,448 or 86% of the applicants had been registered, and only 16,258,521 (63.6%) have been issued with National Identity cards. \uf0b7 Only 16.3 million cards out of the over 19 million national identity cards so far printed have been claimed, leaving over 2.7 million cards unissued or unclaimed. \uf0b7 At the time of audit (December 2021), the Authority had over 4.3 million applications yet to be processed. Of these, 3.2 million applications were still being processed, while 1.1 million applications have been rejected. \uf0b7 NIRA plans to register at least 28,000 aliens annually and issue them with the relevant identification cards. From 2015 to date, the entity has only received 16 applications for alien IDs, and no Alien ID has been issued. \uf0b7 A reviewed the outcome of the initiative to register learners (or school going children within their schools) undertaken in 2017/2018 to determine whether all registered learners had been issued with NINs. I noted that records of over 1.8 million (or 19%) learners\u2019 who registered during that exercise had been rejected and thus not processed for issuance of NINs and Identification Cards. \uf0b7 NIRA failed to procure over 4,500,000 million IDs from the Uganda Security Printing Company as the Joint Venture Agreement required. As a result, the entity has recognised a contingent liability of UGX.33.5Bn.", null, null], ["17", "Amnesty Commission 2020/21", "\uf0b7 The entity budgeted to receive UGX.4.016Bn, out of which UGX.3.868Bn was warranted, resulting in a shortfall of UGX.0.147Bn, which is 3.7% of the budget."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 165, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "153", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 165, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["SECURITY SECTOR", null, null], ["1", "NEC AGRO SMSC LTD 2019/2020 Opinion", "\uf0b7 Accounts receivables increased by 229% from UGX.3.080bn in the financial year 2018/19 to UGX.7.062bn in financial year 2019/20. Outstanding debtors represent idle resources which could be used in the implementation of planned activities."], [null, "Unqualified", null], ["2 NEC AGRO SMSC LTD 2020/2021 Opinion Unqualified \uf0b7 Receivables increased by 23.2% from UGX.6,671,059,244 in the F/Y 2019/20 to UGX.8,219,802,915 in the F/Y 2020/21 and a number of debtors had been outstanding since financial year 2018/19 to-date. \uf0b7 NEC AGRO SMC LTD has an operating margin of 8.5% which is below the desirable 15%. This implies that the subsidiary has a lower proportion of revenues covering expenses rather than profits or income. \uf0b7 The Corporation had a current ratio of 11.4 for the year under review which was way above the desirable ratio of 1.5. I further noted that the current ratio for the year increased by 322% from a ratio of 2.7 recorded in the previous year.", null, null], ["3", "(NEC) Farm Katonga Limited. 2019/2020", "\uf0b7 The Corporation had an operating margin of 2.1%, which is below 50% which implies that the Corporation is having a lower proportion of revenues covering expenses rather than profits or income."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 166, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "154", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 166, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "meet future contingencies or investments in growth."], [null, null, "\uf0b7 The return on assets for the Corporation increased by 0.01% from 0.55%"], [null, null, "recorded in the previous year, the return was still very low. This implies"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 167, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": [["", "", "meet future contingencies or investments in growth."], [null, null, "\uf0b7 The return on assets for the Corporation increased by 0.01% from 0.55%"], [null, null, "recorded in the previous year, the return was still very low. This implies"], [null, null, "that the Corporation is not making enough income from the use of its"], [null, null, "assets."], [null, null, "\uf0b7 The Corporation had a current ratio of 389 for the year under review"], [null, null, "which was far above the desirable range of 1.5 \u2013 2.0. It reduced by 59%"], [null, null, "from a ratio of 938 realized in the previous year."], ["4 (NEC) Farm Katonga Limited, 2020/2021 Opinion Unqualified \uf0b7 The Corporation has an operating margin of 1.2%, which is below the 50% compared to 2.1% realized in the previous year 2019/20 representing a reduction of 43% which implies that the Corporation is having a lower proportion of revenues covering expenses rather than profits or income. \uf0b7 The Corporation made profits of UGX.32,789,541 after tax in the year under review up from profits of UGX.30,230,727 realized in the previous year representing a rise in profits of 8.5%. However the Corporation had negative retained earnings of UGX.1,441,914,445 as at the end of the financial year which may affect the entity\u2019s ability to meet future contingencies or investments in growth. \uf0b7 The corporation posted a return on assets of only 0.4% down from 0.56% posted in the previous year, representing a reduction in ROA of 28.6%. This implies that the Corporation is not making enough income from the use of its assets. \uf0b7 The Corporation had a current ratio of 2,123 for the year under review which was far above the desirable range of 1.5 \u2013 2.0. The very high current ratio implies that the Corporation is not efficiently using its current assets or its short-term financing facilities. \uf0b7 A loan advances worth UGX.808,940,140 was extended to NEC AGRO SMC LTD on 10/03/2021 after committing to pay back the short term loan in 4 weeks. It was however observed that at the time of writing this report in December 2021, the loan advance had not been repaid. \uf0b7 It was established that NEC was involved in land disputes with various encroachers at NEC Farm Katonga which may result into loss of land if not promptly handled.", null, null], ["5", "NEC Headquarter 2019/2020 Opinion Unqualified", "\uf0b7 The Corporation had outstanding debtors amounting to UGX.1,796,916,916 some of which have been outstanding for a number of years. Continued reflection of the debtors\u2019 amount in the financial statements when their recovery seems to be remote misleads users of the accounts."], [null, "", null], ["6 NEC Headquarters 2020/2021 Opinion Qualified \uf0b7 I observed that NEC Pharmaceutical investment reduced to UGX.1,118,877,451 from UGX.2,460,326,736 by the end of the financial year 2020/2021 because machinery and furniture valued at UGX.1,341,449,285 was to be disposed of. The Ministry of Works expert put the value of the machinery and furniture to be disposed of at UGX.413,720,000 implying that value for sale was overstated by UGX.927,729,285. \uf0b7 In the FY 2017, NEC was allocated road construction and maintenance", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 167, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "155", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 167, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["equipment from Ministry of Works and Transport as one way of enhancing its competitiveness in the market. I however noted that the depreciation charge related to the road construction and maintenance equipment was not disclosed in the statement of profit and loss and other comprehensive income contrary to the existing financial reporting standards. \uf0b7 Debtors worth UGX.757,989,660 were reported among which are sundry debtors and prepayments worth UGX.142,254,800 which have been outstanding for a period of more than one year. \uf0b7 Payable amounting to UGX.10,010,447 have remained outstanding for over ten years. \uf0b7 In 2005, Iran Agro Industries was given a lease for 17 square miles of land at NEC Farm Katonga. The initial 5-year lease elapsed without fulfilment of the lease obligations by Iran Agro Industries and the lease was terminated but the land titles were not repossessed by NEC. \uf0b7 It was observed that there was no Annual General Meeting held in the last five years and the entity\u2019s draft strategic plan had not been reviewed by NPA to align to NDP III for onward approval by the Board of Directors.", null, null], ["7", "NEC Luwero Industries Limited, 2019/2020 Opinion Unqualified", "\uf0b7 The Corporation had outstanding trade debtors amounting to UGX.791,065,997 at the close of the financial year 2019/2020 some of which have been outstanding for over the past three financial years. Uncollected debtors represent an idle resource that would be put to use by the entity to enhance its operations."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 168, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "156", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 168, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "financed by debt. In comparison with the previous year, the debt ratio"], [null, null, "was 6.6% indicating a reduction of 1.3% in the debt over the one year"], [null, null, "period."], ["8 National Enterprise Corporation (NEC) Luwero Industries Limited. 2020/21 Opinion Unqualified \uf0b7 The entity had outstanding trade debtors amounting to UGX.491,697,278 at the close of the financial year 2020/2021, some of which have been outstanding for over the past three financial years. Uncollected debtors represent an idle resource that would be put to use by the entity to enhance its operations. \uf0b7 The Corporation had outstanding trade creditors amounting to UGX.744,085,592 some of which have been outstanding for over three financial years. Failure to settle creditors for such long periods could lead to expensive litigation costs for the entity and impact on the going concern as the creditors may cease doing business with the entity. \uf0b7 The Corporation had negative retained earnings of UGX.15,552,895,876 as at the end of the financial year. This may affect the entity\u2019s ability to meet future contingencies or investments in growth. \uf0b7 The corporation posted a return on assets of only 10% down from 12.5% posted in the previous year, representing a reduction in ROA of 20%. This implies that the Corporation is not making enough income from the use of its assets. \uf0b7 The Corporation had a current ratio of 11.9 for the year under review which was above the desirable ratio of 1.5. A very high current ratio implies that the Corporation is not efficiently using its current assets or its short-term financing facilities. \uf0b7 The Corporation had a debt ratio of 2.1% as at the end of the financial year under review implying that majority of Corporation assets are financed by debt.", null, null], ["9", "NEC UZIMA. 2019/2020 Opinion Unqualified", "\uf0b7 I noted that management procured major factory materials worth UGX.1,645,898,731 without adhering to neither the existing procurement processes nor applying for accreditation of an alternative system specifying existence of unique circumstances that could have prevented adherence to the requirements of PPDA Act."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 169, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "157", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 169, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["10 NATIONAL ENTERPRISE UZIMA LTD, 2020/2021 Opinion Unqualified \uf0b7 Payables increased from UGX.1,042,752,671 in the F/Y 18/19 to UGX.1,744,963,543 in 19/20 and further to UGX.2,052,449,538 in the year under review. The increasing trend of payables could result into an uncontrollable level of payables which greatly affects the credit worthiness of the entity. \uf0b7 The Corporation had negative retained earnings of UGX.88,435,269 as at the end of the financial year. This may affect the entity\u2019s ability to meet future contingencies or investments in growth. \uf0b7 The Corporation had a current ratio of 2.3 for the year under review which is above the desirable ratio of 1.5. The high current ratio implies that the Corporation is not efficiently using its current assets or its short term financing facilities. \uf0b7 The Corporation had a debt ratio of 53.5% as at the end of the financial year under review which is considered undesirable. This implies that the company does not have enough funds to meet its current debt obligations and may find it hard to pay a return on Government investment.", null, null], ["11", "NEC Construction Works and Engineering Limited, 2019/2020", "\uf0b7 NEC Works Ltd had outstanding trade debtors of UGX.10,074,717,689 as at the close of the financial year 2019/2020. Outstanding debtors represent an idle asset that would be put to use by the entity to enhance its operations."], [null, "Opinion Unqualified", null], ["12 National Enterprise Corporation - Construction, Works and Engineering Ltd 2020/21 \uf0b7 NEC Works Ltd had outstanding trade debtors of UGX.2,961,747,233 as at the close of the financial year 2020/2021 some of which have been outstanding for more than one year. I was not availed any recovery plans", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 170, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "158", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 170, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Unqualified nor any initiatives taken by management to recover the debts. \uf0b7 The Corporation had an operating margin of 11%, which is below 15% compared to 9% realized in the previous year 2019/20 representing an increase of 22%. This implies that the Corporation is having a lower proportion of revenues covering expenses rather than profits or income. \uf0b7 The Corporation had a current ratio of 1.4 for the year under review which was below the desirable ratio of 1.5. The low current ratio implies that the Corporation has limited ability to meet short-term obligations without raising external capital. \uf0b7 The Corporation had a debt ratio of 69% as at the end of the financial year under review implying that majority of Corporation assets are financed by debt.", null, null], ["13", "Uganda Air Cargo Corporation 2019/2020", "\uf0b7 The Corporation had outstanding debtors of UGX.8,174,344,548 as at 30th June, 2020. UGX.8,159,631,016 representing 99.8% of the debtors reported has been outstanding for a period of more than 5 years. The uncollected debtors constitute more than 65% of the total current assets."], [null, "Opinion Unqualified", null], ["14 Uganda Air Cargo Corporation, 2020/2021 Opinion Unqualified \uf0b7 MoFPED released UGX.46,048,485,223 through MoDVA for capitalisation of UACC but MoDVA transferred UGX.42,511,285,223 leaving a balance of UGX.3,537,200,000. It was observed that UACC with the approval of the Board of Directors agreed to reallocate UGX.28,647,537,490 to fund new priorities other than those for which the funds were appropriated. \uf0b7 A review of the ten (10) year Strategic Business and Investment Plan 2016 to 2027 revealed that out of the planned seven (7) targets/goals, one (1) had been fully achieved, three (3) were partially achieved while", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 171, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "159", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 171, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["three (3) were not achieved at all. \uf0b7 Management created an additional position of \u201cPrincipal Director\u201d to oversee the Directorates of Flight operations and Maintenance which is not in the established structure and is contrary to The Civil Aviation Regulations 2014, section 13. \uf0b7 UACC is a statutory corporation that is supposed to undertake procurements in accordance with PPDA Law and its Regulations. I observed that procurements are normally undertaken as and when the aircrafts breakdown and as such did not follow the formal procurement procedures. \uf0b7 UACC signed a contract on 20th April, 2021 with National Enterprise Corporation (NEC) for construction of the UACC HQ offices for a sum of UGX.1.097Bn and the expected project completion date was 19th October, 2021. I observed that unsecured advances of UGX.1.04Bn (95%) of the contract sum had been paid to NEC by closure of the financial year 30th June 2021. Audit inspection carried out on 18th October, 2021 observed that construction works were behind schedule. \uf0b7 UACC to-date does not have an operating Aircraft to do business since most of them had been grounded or not operational under different circumstances. \uf0b7 The Corporation had negative retained earnings/revenue reserves of UGX.24.03Bn as at the end of the financial year. This may affect the entity\u2019s ability to meet future contingencies or investments in growth.", null, null], ["15", "State House. 2020/21", "\uf0b7 There was a shortfall in NTR collections amounting to UGX.0.573.4bn representing 64%."], [null, "Opinion Unqualified", null], ["16 Office of the President Opinion Unqualified \uf0b7 The entity had prepared a draft strategic plan which was submitted to align the plan to NDP III upon which the certificate of compliance will be issued. \uf0b7 Out of the budgeted revenue of UGX.525,000,000 for the year 2020/21; UGX.423,827,920 was collected representing performance of 80% of the target. \uf0b7 Out of the total warrants for the financial year of UGX.202,499,917,566,", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 172, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "160", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 172, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["UGX.201,682,707,928 was spent by the entity resulting in an unspent balance of UGX.817,209,638 representing absorption level of 99.6%. \uf0b7 I assessed the implementation of all the 19 out puts that were fully quantified with a total of 100 activities worth UGX.92.2 bn. and noted the following: \uf0b7 Twelve (12) outputs with a total of seventy eight (78) activities worth UGX.62.1bn were fully implemented. \uf0b7 Four (4) outputs with a total of fifteen (15) activities worth UGX.16.0bn were partially implemented. \uf0b7 Three (3) outputs with a total of seven (7) activities worth UGX.14.7bn were not implemented at all. \uf0b7 \uf0b7 Out of the planned 27 strategic targets/goals, 23 targets had been fully achieved while 4 were not achieved at all. \uf0b7 Out of the budgeted revenue of UGX.0.52bn for the year 2019/20; only UGX.0.20bn was collected representing performance of only 3.8% of the target. \uf0b7 Out of the total receipts for the financial year of UGX.2.17bn, UGX.2.11bn was spent by the entity resulting in an unspent balance of UGX.5.633bn representing an absorption level of 97.4%. \uf0b7 I assessed a sampled of 19 outputs with a total of 175 activities and actual expenditure of UGX.94Bn which were fully quantified by management. I observed that; 11 outputs with a total of 69 activities worth UGX.77.2Bn were fully implemented. 2 outputs with a total of 21 activities worth UGX.18.5Bn were partially implemented. \uf0b7 I examined supplementary funding received by the Office for COVID 19 interventions and observed anomalies which included under absorption of the funds, failure to quantify activities implemented, inappropriate procurement methods and funds not accounted for. Specifically for management of quarantine centres, I observed that items were procured at varying prices and they were not taken on charge. \uf0b7 Arrears totalling to UGX 30,549,780,185 remained unsettled at close of the year. Further, UGX.28,431,892,310 was provided for settlement of domestic arrears yet domestic arrears brought forward from the prior year were UGX.58,981,672,495. \uf0b7 Shortcomings were observed in the Ministry\u2019s fleet management which included incomplete recording of motor vehicles in the assets register, failure to use motor vehicle logbooks, lack of motor vehicle annual inspections, lack of adequate vehicles for allocation to RDCs, gaps in drivers\u2019 competences and failure to implement board of survey recommendations for disposal of motor vehicles.", null, null], ["17", "Ministry of Defence and Veteran Affairs. 2020/21", "\uf0b7 Out of the budgeted revenue of UGX.1.735Bn for the year 2020/21; UGX.1.018Bn was collected representing performance of 59% of the target. \uf0b7 Out of the total warrants for the financial year of UGX.5.316Tn, UGX.5.315Tn was spent by the entity resulting in an unspent balance of"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 173, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": [["UGX.201,682,707,928 was spent by the entity resulting in an unspent balance of UGX.817,209,638 representing absorption level of 99.6%. \uf0b7 I assessed the implementation of all the 19 out puts that were fully quantified with a total of 100 activities worth UGX.92.2 bn. and noted the following: \uf0b7 Twelve (12) outputs with a total of seventy eight (78) activities worth UGX.62.1bn were fully implemented. \uf0b7 Four (4) outputs with a total of fifteen (15) activities worth UGX.16.0bn were partially implemented. \uf0b7 Three (3) outputs with a total of seven (7) activities worth UGX.14.7bn were not implemented at all. \uf0b7 \uf0b7 Out of the planned 27 strategic targets/goals, 23 targets had been fully achieved while 4 were not achieved at all. \uf0b7 Out of the budgeted revenue of UGX.0.52bn for the year 2019/20; only UGX.0.20bn was collected representing performance of only 3.8% of the target. \uf0b7 Out of the total receipts for the financial year of UGX.2.17bn, UGX.2.11bn was spent by the entity resulting in an unspent balance of UGX.5.633bn representing an absorption level of 97.4%. \uf0b7 I assessed a sampled of 19 outputs with a total of 175 activities and actual expenditure of UGX.94Bn which were fully quantified by management. I observed that; 11 outputs with a total of 69 activities worth UGX.77.2Bn were fully implemented. 2 outputs with a total of 21 activities worth UGX.18.5Bn were partially implemented. \uf0b7 I examined supplementary funding received by the Office for COVID 19 interventions and observed anomalies which included under absorption of the funds, failure to quantify activities implemented, inappropriate procurement methods and funds not accounted for. Specifically for management of quarantine centres, I observed that items were procured at varying prices and they were not taken on charge. \uf0b7 Arrears totalling to UGX 30,549,780,185 remained unsettled at close of the year. Further, UGX.28,431,892,310 was provided for settlement of domestic arrears yet domestic arrears brought forward from the prior year were UGX.58,981,672,495. \uf0b7 Shortcomings were observed in the Ministry\u2019s fleet management which included incomplete recording of motor vehicles in the assets register, failure to use motor vehicle logbooks, lack of motor vehicle annual inspections, lack of adequate vehicles for allocation to RDCs, gaps in drivers\u2019 competences and failure to implement board of survey recommendations for disposal of motor vehicles.", null, null], ["17", "Ministry of Defence and Veteran Affairs. 2020/21", "\uf0b7 Out of the budgeted revenue of UGX.1.735Bn for the year 2020/21; UGX.1.018Bn was collected representing performance of 59% of the target. \uf0b7 Out of the total warrants for the financial year of UGX.5.316Tn, UGX.5.315Tn was spent by the entity resulting in an unspent balance of"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 173, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["procurement leading to higher purchase and maintenance costs. \uf0b7 UCDA undertook new recruitments in the year which have increased staffing levels to only 147 (66%) positions leaving 77 (34%) positions vacant. Among the vacant posts are key positions i.e. Board Secretary/Director of Corporate Services, three (3) Regional managers, Accountants (2), one (1) procurement manager, thirty eight (38) regional coffee extension officers and three (3) Regional Coffee Technical officers among others. \uf0b7 I noted irregular extension of contracts for staff at managerial level without explicit board approval contrary to section 5.3(c) of the UCDA Human Resource manual (2018) and staffs in acting capacities longer than the stipulated time periods in the Human Resource Manual i.e. not more than two terms of six (6) months.", "None", "None"], "type": "table"}}, {"content": "161 \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 173, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A budgetary allocation on Court awards and compensations of UGX.279.12M was received during the year against the outstanding claim of UGX.3.537BN resulting into a shortfall of 99.92%.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Domestic arrears over the past three years have shown a declining trend with arrears reducing by UGX.284.868Bn from 2019 to 2021.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that trade creditors totalling to UGX.364.821Bn remained unsettled at close of the year with arrears totalling to UGX.194.297Bn relating to previous financial year(s).", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that UGX.19.711Bn paid to settle domestic arrears was diverted from the current budget.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- I observed that Batuma Ivan Mbabazi was paid UGX.1.085Bn out of UGX.3.056Bn in respect of compensation for Kibanja land situated in Kihumuro village without proof of ownership. I noted the compensation value of crops worth UGX.1.885Bn paid did not provide details of crops planted and the land coverage.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that a number of illegal activities were being carried out on UPDF 36 Sq Miles land in Kaweweta to include: Illegal acquisition and fencing of military land by veterans; Illegal leasehold registration; Land encroachment; Charcoal burning; Cattle grazing and construction of dams.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that UGX.47BN out of the contract sum of UGX.104.77BN had been paid in relation to the construction of UPDF National Referral Hospital at Lower Mbuya. I observed during my inspections that the no single structure was complete, agreed time frame had elapsed and the site looked abandoned.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted during my inspection that Kaweweta Recruit Training School construction project site had been abandoned and observed the following: Abandoned water supply project; pending works on phase 2 and phase 3 projects; un finished works on road opening of the security road; pending works on tarmacking of 3kms internal road network; Abandoned dormitory blocks for female trainees and aqua-privy toilets; abandoned construction of 2 range grounds and lack of adequate accommodation.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted an urgent need to repair the white house building at URDCC which was found to have a leaking roof in the mess and accommodation rooms.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that the UPDF Legal Training Centre which was started in 2014 funded by Netherlands Government had stalled and looked abandoned.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that out of the required 5.6km concrete perimeter wall fence for land forces headquarter Bombo, only 525 meters had been covered leaving 4.6kms outstanding to complete the perimeter wall.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that Land forces operation centre Bombo had been abandoned since September 2021 and the project had stalled at 75%. The pending works on the project included painting, electrical and water connections and finishing works on the toilets.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I inspected the General Military Hospital- Bombo (GMHB) and observed the following: a need for a centralised system of resource allocation at the hospital; Inadequate medical supplies; Underutilization of hospital equipment; Crowded hospital premises; Old hospital equipment and Parked staff bus.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- I observed that the Marine Pier at Ntokolo Landing site Magamaga was", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n162", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 174, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "affected with water levels on Lake Victoria dropping back to normal"], [null, null, "hence making it difficult for the marine boats to fully utilise the docking"], [null, null, "area due to shallow waters. I noted that only half of the docking area"], [null, null, "was utilised contrary to the original plan."], [null, null, "\uf0b7 I inspected Magamaga cantonment and observed the following issues:"], [null, null, "lack of sufficient storage space, land encroachments\u2019, inadequate water"], [null, null, "supply, poor road network, insufficient lighting system at the store"], [null, null, "premises, accommodation challenges, need to expand Health centre II to"], [null, null, "Health centre III and inadequate toilets at the store premises."], [null, null, "\uf0b7 I observed inadequate Fuel supply for Air Force training as Air Force is"], [null, null, "not allocated fuel for operations. but the same fuel allocation for training"], [null, null, "is used for other operations and yet the trainers have specific"], [null, null, "performance contracts."], [null, null, "\uf0b7 I noted that while there are reserve tanks in Nakasongola and Jinja that"], [null, null, "were constructed in past regimes, these have never been utilised"], [null, null, "subjecting management to buying Jet fuel from dealers at the open"], [null, null, "market pump prices and exorbitant prices."], [null, null, "\uf0b7 I inspected Special Forces Command (SFC) and observed creation of 206"], [null, null, "brigade SFC without sufficient funding. I noted lack of office furniture,"], [null, null, "storage space and CCTV cameras."], ["PUBLIC SECTOR MANAGEMENT SECTOR", null, null], ["1.", "The New Vision printing and Publishing company Limited 2020/21", "\uf0b7 Because the company\u2019s market capitalisation of UGX 23,715 million was significantly lower than the carrying amount of the company\u2019s net assets of UGX 65,039 million as at 30thJune 2021. In accordance with IAS 36"], [null, null, "Impairment of Assets, this impairment indicator triggered impairment"], [null, "Opinion", "testing of the non-current assets of the company. The recoverable cost of UGX 57,866 estimated to be the fair value of the company. \uf0b7 NVPPCL incurred costs relating to a one-off discretionary retirement"], [null, "Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 175, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "163", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 175, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "the following;"], [null, null, "\uf0b7 Absence of a defined information security management system"], [null, null, "\uf0b7 Absence of a cybersecurity incident response team"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 176, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": [["", null, "the following;"], [null, null, "\uf0b7 Absence of a defined information security management system"], [null, null, "\uf0b7 Absence of a cybersecurity incident response team"], [null, null, "\uf0b7 Inadequate security awareness"], [null, null, "\uf0b7 Vulnerability assessments not performed"], [null, null, "\uf0b7 Absence of data classification"], [null, null, "\uf0b7 Inadequate ICT vendor management"], ["2\\. Markets and Agricultural Trade Improvement Project (MATIP) II 2020/21 Opinion Unqualified \uf0b7 There was a shortfall in releases from GOU sources of UGX.0.23Bn and donors of UGX.19.763Bn. Furthermore, the project failed to absorb UGX.0.271Bn. \uf0b7 I reviewed 4 out-puts with a total of 16 activities worth UGX.57.7Bn representing 100% of the total expenditure and noted that two (2) outputs with six (6) activities worth UGX.38.6Bn were fully quantified. I further observed two (2) out-puts with ten (10) activities worth UGX.19.1Bn were insufficiently quantified. All the two (2) outputs that were fully quantified were partially implemented. \uf0b7 I observed that there was delayed completion of works on some of the markets and value addition facilities. Two (2) markets were completed by June 2021 however they had not been commissioned and operationalized by September 2021 thus affecting service delivery. \uf0b7 I observed that except for Entebbe market all the other markets lacked a revenue management information system to facilitate revenue management. This was also the case for the seven (7) MATIP 1 markets. I further observed that the allocation guidelines favor leaseholders who pay very little in terms of ground rent to the Municipalities. This affects revenue mobilization and impairs self-reliance and sustainability of these markets. \uf0b7 The beneficiary Municipalities have failed to put in place a market maintenance fund which would facilitate routine maintenance of the completed structures. This was also the case for the MATIP 1 markets. In addition, all the markets redeveloped under MATIP 1 and 2 are not insured against risks such as; fire outbreaks, electrical failures and unforeseen disasters.", null, null], ["3.", "Ministry of Public Service 2020/21", "\uf0b7 The Ministry\u2019s five (5) year strategic plan was certified by NPA, confirming that it is aligned to the NDP III. \uf0b7 The Ministry collected only 57.7% of its NTR target for the year and had a shortfall in government funding of UGX.9.7Bn, which is 32.4% of the"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 The Ministry had off-budget financing of UGX.0.529Bn, which was never"], [null, null, "declared to the PSST for re-voting."], [null, null, "\uf0b7 Out of the thirty-five (35) outputs assessed, eight (8) were fully"], [null, null, "quantified, while five (5) were insufficiently quantified to facilitate"], [null, null, "performance measurement. The balance of two (2) outputs were not"], [null, null, "included in the Ministerial Policy Statement submitted to Parliament."], [null, null, "\uf0b7 Out of the eight (8) outputs that were fully quantified, seven (7) outputs"], [null, null, "were partially implemented, while one (1) output was not implemented at"], [null, null, "all as a result of the disruptions caused by restrictions imposed due to"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 176, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "164", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 176, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Covid-19."], [null, "\uf0b7 The Ministry delayed submitting all its quarterly performance reports to"], [null, "MoFPED, and similarly, I did not find evidence to confirm that monitoring"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 177, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": [["", "Covid-19."], [null, "\uf0b7 The Ministry delayed submitting all its quarterly performance reports to"], [null, "MoFPED, and similarly, I did not find evidence to confirm that monitoring"], [null, "plans and reports were prepared."], [null, "\uf0b7 I observed that a number of government entities had not been filling"], [null, "positions of persons who had been granted leave without pay, which"], [null, "resulted in manpower gaps in these entities affecting their efficiency in"], [null, "delivering services to the citizens."], [null, "\uf0b7 The Ministry failed to utilise up to UGX.6.5Bn of the total salary budget of"], [null, "UGX.17.9Bn provided by MoFPED over the past four (4) years."], [null, "\uf0b7 The Ministry had outstanding domestic arrears of UGX 0.86Bn by the end"], [null, "of the financial year."], [null, "\uf0b7 The Ministry had not put in place adequate guidance regarding the"], [null, "number of boards on which a civil servant is allowed to serve at any one"], [null, "time. This resulted in some civil servants serving on more than three (3)"], [null, "boards, which affects the time they allocate to their substantive jobs."], [null, "\uf0b7 I noted some challenges in the management of recruitments into the"], [null, "service, such as; irregular employment of staff by Accounting Officers and"], [null, "the absence of a policy for the recruitment and selection of temporary"], [null, "staff."], [null, "\uf0b7 I noted irregularities in the management of leave without pay for civil"], [null, "servants, which included; absence of a complete register of all civil"], [null, "servants who were away on leave without pay and irregular grant of"], [null, "leave without pay."], [null, "\uf0b7 I noted irregularities in overseas training for civil servants, such as the"], [null, "absence of a register of all civil servants who were away on training and"], [null, "some Officers who went abroad for training programmes offered by the"], [null, "different local universities in Uganda."], ["3\\. Local Government Finance Commission 2020/21 Opinion Unqualified \uf0b7 I noted that the Commission did not have an approved strategic plan that was aligned to NDP III by the time of audit. The draft plan prepared by the entity had not been certified by NPA. \uf0b7 The Commission collected only 0.03% of its NTR target for the year and had a shortfall in government funding of 0.04Bn which is 0.75% of the budget. The Commission absorbed all the funds that were released. \uf0b7 Out of the five (5) out-puts assessed, one (1) output with 0.115 Bn was fully quantified, while four (4) outputs with 4.01Bn were insufficiently quantified. The one (1) output that was fully quantified was partially implemented. \uf0b7 The Commission neither prepared annual budget monitoring plans nor submitted quarterly budget monitoring reports. The Commission also failed to submit all its quarterly budget performance reports in time. \uf0b7 The Commission failed to coordinate the automation of revenue management systems. There are currently four (4) revenue management systems used by various Local Governments which are implemented in a disjointed and uncoordinated manner. This has resulted in duplication of activities associated with running these systems thus affecting service delivery. \uf0b7 The Commission received UGX.182,000,000 as budget support to undertake physical decentralization and service delivery. However only UGX.31,241,000 was absorbed by the Commission which significantly", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 177, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "165", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 177, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["affected service delivery. \uf0b7 I noted that by 30th June 2021 the Commission had accumulated domestic arrears of UGX.101,473,991.", null, null], ["4.", "City Wide Inclusive Sanitation (CWIS) 2020/21", "\uf0b7 I observed that the program work plans and budgets were not sent to parliament for formal approval through the KCCA Ministerial Policy Statements \uf0b7 The project budgeted to receive donor financing of USD 1.2M for the year under review; however, only USD 1M was received during the year. Also,"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 178, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": [["affected service delivery. \uf0b7 I noted that by 30th June 2021 the Commission had accumulated domestic arrears of UGX.101,473,991.", null, null], ["4.", "City Wide Inclusive Sanitation (CWIS) 2020/21", "\uf0b7 I observed that the program work plans and budgets were not sent to parliament for formal approval through the KCCA Ministerial Policy Statements \uf0b7 The project budgeted to receive donor financing of USD 1.2M for the year under review; however, only USD 1M was received during the year. Also,"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 The project under absorbed funds totaling USD 1,329,522, which is 62%"], [null, null, "of the funds that were available to the project for implementation of"], [null, null, "activities"], [null, null, "\uf0b7 Out of the sixty-seven (67) activities assessed, forty-seven activities"], [null, null, "worth USD 609,563 were fully quantified, while twenty (20) activities"], [null, null, "worth USD 199,314 were insufficiently quantified. Out of the forty-seven"], [null, null, "(47) activities that were quantified, twenty (20) 43% activities worth USD"], [null, null, "502,564 were fully implemented, seventeen (17) 36% activities worth"], [null, null, "USD 99,664 were partially implemented, while ten (10) 21% activities"], [null, null, "worth USD 7,335 were never implemented at all."], [null, null, "\uf0b7 The project accumulated arrears amounting to USD 583,742 during the"], [null, null, "year under review."], [null, null, "\uf0b7 The project's progress towards achieving project targets or outcomes was"], [null, null, "found unsatisfactory in some areas. The performance in some cases was"], [null, null, "below 50%, while in other areas, no activities had been implemented."], [null, null, "This affects service delivery."], [null, null, "\uf0b7 The project irregularly recruited providers that KCCA or NEMA had not"], [null, null, "licensed."], ["5 Development Response to Displacement Impacts Project 2020/21 Opinion Unqualified \uf0b7 The Project budgeted to receive UGX.233Bn out of which UGX.185Bn was received representing 79% of the budget leaving a balance of UGX.48.1Bn as unreleased. All the funds that were released were absorbed. \uf0b7 All the four (4) outputs with a total of thirteen (13) activities worth UGX.185Bn were fully quantified to enable assessment of performance. Out of this two (2) out puts with six (6) activities worth UGX.9.86Bn were fully implemented while the balance of two (2) out puts with seven (&) activities worth UGX.175Bn were partially implemented. \uf0b7 I noted that the project did not utilise grant funds totalling to UGX UGX.9.6Bn. \uf0b7 The project had not achieved its thre e(3) year targets in four (4) areas with performance in some cases being as low as 0% in some areas.", null, null], ["6", "National Planning Authority 2020/21", "\uf0b7 The Authority prepared a new five (5) year strategic plan which was certified as aligned to NDP III."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 178, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "166", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 178, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "appropriated to the entity by Parliament. These funds were received"], [null, null, "directly from development partners for undertaking activities not"], [null, null, "budgeted for."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 179, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": [["", null, "appropriated to the entity by Parliament. These funds were received"], [null, null, "directly from development partners for undertaking activities not"], [null, null, "budgeted for."], [null, null, "\uf0b7 I noted that out of the 12 out-puts sampled for review, 6 (50%) were"], [null, null, "fully quantified, 5 (41%) were insufficiently quantified and 1 (9%) was"], [null, null, "not quantified at all making it impossible to measure performance. Out of"], [null, null, "the 6 out puts that were fully quantified, none was fully implemented, 4"], [null, null, "(66%) were partially implemented while 2 (34%) were not implemented."], [null, null, "\uf0b7 All the quarterly budget performance reports were submitted late by the"], [null, null, "Authority."], [null, null, "\uf0b7 I noted cases of delays in approval of MDA and LG strategic plans. In"], [null, null, "addition to this seventy three (73) entities had not submitted their"], [null, null, "strategic plans for review and certification by the Authority."], [null, null, "\uf0b7 The Authority had not undertaken capacity building of planners at both"], [null, null, "local and national level which affected the capacity of the planners to"], [null, null, "implement, monitor and report on the performance of the budgets in"], [null, null, "their respective entities."], [null, null, "\uf0b7 I observed shortcomings in government\u2019s readiness to implement the"], [null, null, "new programme approach to planning and budgeting which included;"], [null, null, "non-alignment of the accounting and oversight processes to the new"], [null, null, "programme planning framework, non-alignment to the statistical and data"], [null, null, "collection systems to the new programme planning framework and non-"], [null, null, "functional programme working groups among others."], [null, null, "\uf0b7 I also noted that the Authority had not realigned the development"], [null, null, "planning regulations from the sector approach to planning and budgeting"], [null, null, "to the new programme approach of planning and budgeting."], ["7 Public Service Commission 2020/21 Opinion Unqualified \uf0b7 Although the Commission had come up with a strategic plan aligned to NDP III, this plan had not been approved and certified by NPA as required by the planning regulations. \uf0b7 The Commission did collect NTR for the year despite having an NTR budget of UGX.2.7Bn. The Commission received 99% of its budget from Treasury and absorbed all the funds. \uf0b7 Out of the thirteen out-puts assessed, two (2) outputs worth 0.88Bn were fully quantified, six (6) worth 6.72Bn were partially quantified while five (5) outputs worth 1.87Bn were not quantified at all. The two (2) out-puts that were quantified were all partially implemented. \uf0b7 All the quarterly performance reports were submitted late by the Commission and there were no budget monitoring reports prepared by the Accounting Officer. \uf0b7 The Commission does not participate in the recruitment of foreign service officers in Uganda\u2019s missions and embassies abroad. \uf0b7 The Commission had outstanding domestic arrears amounting to UGX.48.768,099. \uf0b7 The Commission did not deduct PAYE from gratuity payments amounting to UGX.1Bn for its Commission members.", null, null], ["8", "Office of The Prime Minister 2020/21", "\uf0b7 I noted that OPM strategic plan had not been approved by NPA as aligned to NDP III."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 179, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "167", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 179, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "government releases. OPM had unspent balances of UGX.2.5Bn, which"], [null, "were returned to the consolidated fund."], [null, "\uf0b7 OPM received off-budget financing amounting to UGX.53.452Bn, which"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 180, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": [["", "government releases. OPM had unspent balances of UGX.2.5Bn, which"], [null, "were returned to the consolidated fund."], [null, "\uf0b7 OPM received off-budget financing amounting to UGX.53.452Bn, which"], [null, "Parliament never appropriated."], [null, "\uf0b7 I noted that out of the thirty-two (32) outputs sampled for review,"], [null, "twenty-nine (29) (91%) were fully quantified, one (1) (3%) was partially"], [null, "quantified, and 2 (6%) were not quantified at all which made it"], [null, "impossible to measure performance. Out of the twenty-nine (29) outputs"], [null, "that were fully quantified, four (4) outputs (14%) were fully"], [null, "implemented, while twenty-five (25) outputs (86%) were partially"], [null, "implemented."], [null, "\uf0b7 OPM did not prepare and submit annual budget monitoring plans and"], [null, "reports while submission of all the quarterly performance reports were"], [null, "delayed."], [null, "\uf0b7 I observed service delivery challenges such as delayed completion of"], [null, "works, failure to fund micro-projects and non-functional District Disaster"], [null, "Management Committees."], [null, "\uf0b7 I noted that OPM received UGX.0.25Bn as part of the COVID-19 relief"], [null, "interventions budget. These funds were all absorbed and used for the"], [null, "intended purpose."], [null, "\uf0b7 I noted delayed resettlement of encroachers in the Apaa game reserve"], [null, "land."], [null, "\uf0b7 OPM did not have a complete database of all entitled beneficiaries and"], [null, "those paid since 2008 under the Akasiimo gratuity scheme."], ["9 Northern Uganda Social Action Fund (NUSAF 3) 2020/21 Opinion Unqualified \uf0b7 This was the last year of implementation of the NUSAF 3 Project. An independent impact evaluation undertaken by Makerere University Business School highlighted achievements by the project, which included; increased income for beneficiary households, improved resilience and vulnerability to shocks, improved household welfare and progress out of poverty, improved savings and investments, increased production and income earnings and increased household food security and consumption for a number of beneficiaries. \uf0b7 uring FY2020/2021, the project budgeted to receive UGX.38.7Bn, which was all received. Similarly, the project absorbed all this money representing 100% performance. \uf0b7 All the three (3) outputs with nine (9) activities worth UGX.38.8Bn sampled for verification were fully quantified. Out of these, two (2) outputs with five (5) activities worth UGX.26.72Bn were fully implemented while one (1) output with four (4) activities worth UGX.12.08Bn was partially implemented. \uf0b7 The project advanced funds for the construction of coffee shops in Arua, Gulu, Lira, Mbale and Tororo. At the time of audit, works were not complete in Lira, Arua and Gulu. The coffee shop in Mbale was not fully operational. \uf0b7 During my inspection, I noted that the beneficiary communities and districts were having sustainability challenges in maintaining project investments three (3) months after the closure of the project. These included poor maintenance of roads, low savings by farmers, among others. \uf0b7 Ownership of two (2) project vehicles had not reverted to government three (3) months after the closure of the project.", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 180, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "168", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 180, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["10", "Project for The Restoration of Livelihoods in the Northern Region (PRELNOR)", "\uf0b7 The project had a shortfall of UGX.26Bn, which is 52% and UGX.3.27Bn, which is 67% of the budget in external and government funding, respectively. The project absorbed UGX.25.65Bn, which is 88% of all the funds that were released."], [null, "2020/21 Opinion Unqualified", null], ["11 Ministry of Local Government 2020/21 Opinion Unqualified \uf0b7 The Ministry\u2019s strategic plan (2020/2021 to 2025/2026) had not been certified by NPA to confirm that it was well aligned to NDP III at the time of the audit. \uf0b7 There was a shortfall in NTR collection of up to 89.9% of the target, while government receipts were less than anticipated by UGX.3.64Bn. The Ministry had unspent balances of UGX.3.94Bn by year-end. \uf0b7 I noted that out of the thirty-nine (39) outputs sampled for review, fifteen (15) (38%) were fully quantified, twenty (20) (51%) were insufficiently quantified, and four (4) (10%) were not quantified at all. Out of the fifteen (15) outputs that were fully quantified, one (1) output was fully implemented, while fourteen (14) outputs were partially implemented. \uf0b7 All the quarterly performance reports were submitted after the deadline for submission. \uf0b7 2,127 motorcycles and 77,831 bicycles worth UGX.18.9Bn and UGX.24.6Bn respectively had not yet been delivered by the time of audit in November 2021, although they were due for delivery in September 2021. \uf0b7 The Ministry delayed disbursing funds for budget support to Local Governments. UGX.22.1Bn to various Local Governments was disbursed in the last two weeks of June 2021. \uf0b7 The Ministry delayed disbursing start-up costs of UGX.6.79Bn to 125 Local Governments. Most of the funds were transferred the last two weeks of June and, in some cases, as late as 29th June 2021. \uf0b7 The Ministry received UGX.2.86Bn for settlement of domestic arrears as part of the COVID 19 interventions, which was all absorbed and used to settle domestic arrears. \uf0b7 The Ministry had outstanding domestic arrears of UGX.33Bn as at June 2021.", null, null], ["12", "Kampala Capital City Authority (KCCA).", "\uf0b7 I noted that the Authority\u2019s strategic plan had not been certified by NPA by the time of audit, contrary to the Planning Regulations."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 181, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "169", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 181, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "UGX.18.97Bn, which Parliament never appropriated."], [null, null, "\uf0b7 I noted that out of the thirty-nine (39) outputs sampled for review, two"], [null, null, "(2) outputs (5%) were fully quantified, two (2) outputs (5%) were"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 182, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": [["", null, "UGX.18.97Bn, which Parliament never appropriated."], [null, null, "\uf0b7 I noted that out of the thirty-nine (39) outputs sampled for review, two"], [null, null, "(2) outputs (5%) were fully quantified, two (2) outputs (5%) were"], [null, null, "partially quantified, and thirty-five (35) outputs (90%) were not"], [null, null, "quantified at all which made it impossible to measure performance. The"], [null, null, "two (2) outputs that were fully quantified were all fully implemented."], [null, null, "\uf0b7 All performance reports were submitted after the deadline."], [null, null, "\uf0b7 I noted that the Authority had not developed regulations to guide the"], [null, null, "collection of outdoor advertising fees, which hindered the collection of"], [null, null, "NTR. I further noted that the Authority did not undertake regular updates"], [null, null, "of the valuation rolls."], [null, null, "\uf0b7 The Authority has an unserviceable long-term liability of"], [null, null, "UGX.42,570,448,999 in addition to accumulated domestic arrears of"], [null, null, "UGX.62,477,592,377 as at 30th June 2021."], [null, null, "\uf0b7 The Authority did not remit statutory deductions to URA and NSSF"], [null, null, "amounting to UGX.1.86Bn."], [null, null, "\uf0b7 The Authority incurred avoidable expenditure of UGX.7.8Bn as interest"], [null, null, "due to delayed site handover for civil works constructions."], [null, null, "\uf0b7 noted that the Authority had not adopted the Computerized Government"], [null, null, "Financial Management Information Systems (GFMIS) for management of"], [null, null, "its inventories as required by the Treasury Instructions."], ["13 Kampala Institutional and Infrastructure Development Project (KIIDP). 2020/21 Opinion Unqualified \uf0b7 The Project budgeted to receive UGX.8.7Bn from GOU out of which UGX.1.9Bn was released representing 21.8% of the budget leaving a balance of UGX.6.8Bn as unreleased. Similarly, the project budgeted to receive UGX.139.7Bn from World Bank however only UGX.125.2Bn (90%) was availed. \uf0b7 UGX.49.9Bn remained un-utilized at the end of the financial year. \uf0b7 Out of the four (4) outputs reviewed, only one (1) output (25%) was fully quantified. Three (3) outputs were not quantified at all. I observed that management did not prepare performance reports that show the status of implementation of planned outputs. \uf0b7 I noted that there was slow progress of works, delayed relocation of utilities and delayed land aquistion which resulted in delayed service delivery. \uf0b7 I also noted that UGX.1,323,171,260 that was garnished had not yet been refunded by Government through KCCA. \uf0b7 I noted that ownership of one hundred forty-seven (147) pieces of land on which project roads and drainages had been constructed had not yet been transferred to KCCA.", null, null], ["1.", "PUBLIC ADMINISTRATION SECTOR", "\uf0b7 \uf0b7 Out of the planned 10 strategic targets/goals, 4 targets were fully achieved, 5 targets were partially achieved and 1 was not achieved at all. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.544Bn representing 1.66% performance. \uf0b7 I sampled 4 outputs with a total of 8 activities and actual expenditure of UGX.5.376Bn and observed that 3 outputs with a total of 7 activities and expenditure worth UGX.5.31Bn were fully quantified while 1 output with 1 activity and expenditure worth UGX 0.06Bn was not quantified. I further"], [null, "Uganda Embassy in Abu Dhabi. 2019/20 Opinion \uf0b7 Out of the planned 10 strategic targets/goals, 4 targets were fully achieved, 5 targets were partially achieved and 1 was not achieved at all. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.544Bn representing 1.66% performance.", null], [null, "Unqualified \uf0b7 I sampled 4 outputs with a total of 8 activities and actual expenditure of UGX.5.376Bn and observed that 3 outputs with a total of 7 activities and expenditure worth UGX.5.31Bn were fully quantified while 1 output with 1 activity and expenditure worth UGX 0.06Bn was not quantified. I further", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 182, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "170", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 182, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["observed that none of the outputs were fully implemented. \uf0b7 The Mission did not prepare and submit the annual monitoring plans to MoFPED and NPA contrary to the requirement of paragraph 58 of the Budget Execution Circular for 2019/2020. I also noted that the Mission submitted performance reports for Q1, Q2, Q3 and Q4 after the elapse of the deadline given for submission of the reports. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.58,817,501 out of which UGX.37,898,755 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX. 20,918,746 not remitted. \uf0b7 The Mission paid 73,400.00 AED (equivalent to UGX.73,326,600) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission paid medical refunds to its staff amounting to 8,540.9 AED (equivalent to UGX.8,531,460) contrary to Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 The Mission has an approved staff structure of 4 staff positions out of which 3 (75%) were filled leaving 1 (25%) vacant.", null, null], ["2.", "Uganda Embassy in Abuja, 2019/20", "\uf0b7 Out of the planned 9 strategic targets/goals, no target was fully achieved, 4 targets were partially achieved and 5 targets were not achieved at all."], [null, "Opinion Qualified", null], ["3\\. Uganda Embassy in Algeria 2019/20 Opinion Unqualified \uf0b7 All the planned 7 strategic targets/goals in the Mission charter were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.078Bn representing 0.5% performance. \uf0b7 Out of the total receipts for the financial year of UGX.4.16Bn, UGX.3.81Bn", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 183, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "affected with water levels on Lake Victoria dropping back to normal"], "type": "table"}}, {"content": "171", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 183, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["was spent by the entity resulting in an unspent balance of UGX.0.35Bn representing an absorption level of 91.5%. \uf0b7 I sampled 5 outputs with a total of 16 activities and actual expenditure of UGX.3.89Bn and observed that 1 output with a total of 6 activities and expenditure worth UGX.1.14Bn was fully quantified, 2 outputs with a total of 8 activities and expenditure worth UGX.2.47Bn were insufficiently quantified while 2 outputs with 2 activities and expenditure worth UGX.0.28Bn were not quantified at all. \uf0b7 Out of 6 activities planned, only 2 were fully implemented (33%) while 1 activity was partially implemented (17%) and 3 activities were actually not implemented (50%). \uf0b7 Funds to the tune of \u00a3 890 (UGX.3,739,406) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The entity did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 A review of the cumulative performance reports revealed the subsequent quarterly performance reports did not include activities implemented in the previous quarter(s) and therefore, the cumulative activities reported in the fourth quarter performance report does not include all activities implemented in the first, second and third quarters. \uf0b7 The Mission paid Euros.45,314 (equivalent to UGX.190,390,396) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission had a fixed assets register detailing all of the Mission\u2019s assets but lacked some of the information such as date of purchase, estimated useful life, maintenance costs and the expected date of disposal making it incomplete. I further observed that a number of the entity\u2019s assets were old and due for boarding off but this had not been done.", null, null], ["4.", "Uganda Embassy in Ankara 2019/20", "\uf0b7 Out of the planned 10 strategic targets/goals in the Mission charter, seven (7) targets had been fully achieved, two (2) were partially achieved, while one (1) was not achieved."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 184, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "172", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 184, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "management of the Embassy procured office equipment, ICT equipment"], [null, null, "and furniture and fittings worth UGX.129,698,987 resulting into a"], [null, null, "diversion of UGX.39,698,987. Furthermore, the additions in the Statement"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 185, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was spent by the entity resulting in an unspent balance of UGX.0.35Bn representing an absorption level of 91.5%. \uf0b7 I sampled 5 outputs with a total of 16 activities and actual expenditure of UGX.3.89Bn and observed that 1 output with a total of 6 activities and expenditure worth UGX.1.14Bn was fully quantified, 2 outputs with a total of 8 activities and expenditure worth UGX.2.47Bn were insufficiently quantified while 2 outputs with 2 activities and expenditure worth UGX.0.28Bn were not quantified at all. \uf0b7 Out of 6 activities planned, only 2 were fully implemented (33%) while 1 activity was partially implemented (17%) and 3 activities were actually not implemented (50%). \uf0b7 Funds to the tune of \u00a3 890 (UGX.3,739,406) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The entity did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 A review of the cumulative performance reports revealed the subsequent quarterly performance reports did not include activities implemented in the previous quarter(s) and therefore, the cumulative activities reported in the fourth quarter performance report does not include all activities implemented in the first, second and third quarters. \uf0b7 The Mission paid Euros.45,314 (equivalent to UGX.190,390,396) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission had a fixed assets register detailing all of the Mission\u2019s assets but lacked some of the information such as date of purchase, estimated useful life, maintenance costs and the expected date of disposal making it incomplete. I further observed that a number of the entity\u2019s assets were old and due for boarding off but this had not been done.", "None", "None"], "type": "table"}}, {"content": [["", "", "management of the Embassy procured office equipment, ICT equipment"], [null, null, "and furniture and fittings worth UGX.129,698,987 resulting into a"], [null, null, "diversion of UGX.39,698,987. Furthermore, the additions in the Statement"], [null, null, "of Stores and Other Assets (physical assets) as at the end of the financial"], [null, null, "year 2019/2020 was UGX.129,698,987 but the payment file revealed that"], [null, null, "only office equipment, ICT equipment and furniture and fittings worth"], [null, null, "UGX.85,138,153 were procured implying that this statement is overstated"], [null, null, "by UGX.44,560,834."], [null, null, "\uf0b7 The Embassy made upfront payments for rent of USD.74,850 (equivalent"], [null, null, "to UGX.279,215,200) beyond the financial year but did not disclose the"], [null, null, "prepayments in the Statement of Financial Position for the year."], [null, null, "\uf0b7 The Mission paid USD.35,000 (equivalent to UGX.130,725,000) in respect"], [null, null, "of education allowances direct to its officials instead of their respective"], [null, null, "educational institutions or schools contrary to Section (E - e) Paragraphs"], [null, null, "19 and 20 of the Public Service Standing Orders 2010."], [null, null, "\uf0b7 The Embassy spent USD.53,627 (equivalent to UGX.200,296,400) on"], [null, null, "refunds for medical expenses to its officers contrary to Section M (m-a)"], [null, null, "(14) of the Public Service Standing Orders, 2010."], [null, null, "\uf0b7 The Mission has an approved staff structure of 8 staff positions out of"], [null, null, "which, 5 (63%) were filled leaving 3 (37%) vacant."], ["5", "Uganda Embassy in China, Beijing 2019/20 Opinion Qualified \uf0b7 Out of the planned 8 strategic targets/goals in the Mission charter, three (3) targets had been fully achieved, three (3) were partially achieved, while two (2) was not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.4.17Bn representing 0.05% performance. \uf0b7 Out of the total receipts for the financial year of UGX.5.031Bn, UGX.4.276Bn was spent by the entity resulting in an unspent balance of UGX.0.755Bn representing an absorption level of 84.99%. \uf0b7 The Embassy received off-budget financing from the Contingency Fund as a relief fund for students locked down in Wuhan to a tune of UGX.227,318,724 which was not appropriated by Parliament. \uf0b7 I sampled 5 outputs with a total of 20 activities and actual expenditure of UGX.4.28Bn and observed that 1 output with a total of 20 activities and expenditure worth UGX.4.23Bn was fully quantified while 2 outputs with a total of 2 activities and expenditure worth UGX.0.05Bn were not quantified. I further noted that for the quantified outputs, 3 outputs with 20 activities worth UGX.4.23Bn were partially implemented, 9 (45%) activities were fully implemented, 2 (10%) activities partially implemented and 9 (45%) activities remained unimplemented \uf0b7 Funds to the tune of UGX.20,000,000 were irregularly diverted from purchase of specialized machinery and equipment for which they were budgeted to purchase of curtains without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. \uf0b7 I noted 20 cases of activities that were not reported that were disclosed in quarter 2 and quarter 3 reports but not disclosed the cumulative 4th", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 185, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was spent by the entity resulting in an unspent balance of UGX.0.35Bn representing an absorption level of 91.5%. \uf0b7 I sampled 5 outputs with a total of 16 activities and actual expenditure of UGX.3.89Bn and observed that 1 output with a total of 6 activities and expenditure worth UGX.1.14Bn was fully quantified, 2 outputs with a total of 8 activities and expenditure worth UGX.2.47Bn were insufficiently quantified while 2 outputs with 2 activities and expenditure worth UGX.0.28Bn were not quantified at all. \uf0b7 Out of 6 activities planned, only 2 were fully implemented (33%) while 1 activity was partially implemented (17%) and 3 activities were actually not implemented (50%). \uf0b7 Funds to the tune of \u00a3 890 (UGX.3,739,406) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The entity did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 A review of the cumulative performance reports revealed the subsequent quarterly performance reports did not include activities implemented in the previous quarter(s) and therefore, the cumulative activities reported in the fourth quarter performance report does not include all activities implemented in the first, second and third quarters. \uf0b7 The Mission paid Euros.45,314 (equivalent to UGX.190,390,396) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission had a fixed assets register detailing all of the Mission\u2019s assets but lacked some of the information such as date of purchase, estimated useful life, maintenance costs and the expected date of disposal making it incomplete. I further observed that a number of the entity\u2019s assets were old and due for boarding off but this had not been done.", "None", "None"], "type": "table"}}, {"content": "173", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 185, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["quarter performance report of the Mission. \uf0b7 The Mission had outstanding commitments to a tune of UGX.7,720,207 from the previous year but no budget was provided for settlement of domestic arrears in the current budget but the arrears were paid. \uf0b7 For procurements, I observed that the Mission had one member for an Evaluation Committee and there was lack involvement of the Contracts Committee in the procurement processes. \uf0b7 I observed that the fixed assets register maintained by the entity was not updated and not maintained in the format prescribed in the Treasury Instructions. \uf0b7 The Embassy spent RMB.154,898 (equivalent to UGX.81,538,197) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Expenditure amounting to RMB.118,327 (equivalent to UGX.62,287,491) was incurred on staff telephone bills out of which RMB.78,885 (equivalent to UGX.41,524,994) representing 2/3 of the amount should have been recovered from staff but the recovery was not effected contrary to Section H (h-e) (12) of the Public service Standing Orders, 2010.", null, null], ["6.", "Uganda Embassy in Berlin 2019/20 Opinion", "\uf0b7 The cashbook closing balance revealed an amount of Eur.8,442.77 (equivalent to UGX.35,283,771) while the bank statement closing balance revealed Eur.53,180.48 (222,250,267) resulting into un-reconciled difference of Eur.44,737.71 (equivalent to UGX.186,966,496)."], [null, "Qualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 186, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was spent by the entity resulting in an unspent balance of UGX.0.35Bn representing an absorption level of 91.5%. \uf0b7 I sampled 5 outputs with a total of 16 activities and actual expenditure of UGX.3.89Bn and observed that 1 output with a total of 6 activities and expenditure worth UGX.1.14Bn was fully quantified, 2 outputs with a total of 8 activities and expenditure worth UGX.2.47Bn were insufficiently quantified while 2 outputs with 2 activities and expenditure worth UGX.0.28Bn were not quantified at all. \uf0b7 Out of 6 activities planned, only 2 were fully implemented (33%) while 1 activity was partially implemented (17%) and 3 activities were actually not implemented (50%). \uf0b7 Funds to the tune of \u00a3 890 (UGX.3,739,406) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The entity did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 A review of the cumulative performance reports revealed the subsequent quarterly performance reports did not include activities implemented in the previous quarter(s) and therefore, the cumulative activities reported in the fourth quarter performance report does not include all activities implemented in the first, second and third quarters. \uf0b7 The Mission paid Euros.45,314 (equivalent to UGX.190,390,396) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission had a fixed assets register detailing all of the Mission\u2019s assets but lacked some of the information such as date of purchase, estimated useful life, maintenance costs and the expected date of disposal making it incomplete. I further observed that a number of the entity\u2019s assets were old and due for boarding off but this had not been done.", "None", "None"], "type": "table"}}, {"content": "174", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 186, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], [null, null, "Germany was under lock down (March to June, 2020). I could not"], [null, null, "establish the genuineness of the expenditure."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 187, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", null, "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], [null, null, "Germany was under lock down (March to June, 2020). I could not"], [null, null, "establish the genuineness of the expenditure."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 187, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", null, "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], [null, null, "Germany was under lock down (March to June, 2020). I could not"], [null, null, "establish the genuineness of the expenditure."], [null, null, "\uf0b7 The Embassy has an approved staff structure of 8 positions out of which"], [null, null, "5 (62.5%) were filled leaving 3 (37.5%) vacant."], ["7\\. Uganda Embassy in Brussels 2019/20 Opinion Unqualified \uf0b7 Out of the planned 10 strategic targets/goals in the Mission charter, two (2) targets had been fully achieved while eight (8) were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.445Bn representing 7.9% performance. \uf0b7 I sampled 4 outputs with a total of 11 activities and actual expenditure of UGX.10.359Bn and observed that all the 4 outputs with a total of 11 activities and expenditure worth UGX.10.359Bn were fully quantified. I further observed that 1 output with 1 activity worth UGX.4.993Bn was fully implemented while 3 outputs with 10 activities worth UGX.5.336Bn were partially implemented. \uf0b7 Funds to the tune of USD.1,949.02 (equivalent to UGX.7,990,982) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The entity submitted performance reports for Q1, Q2, Q3 and Q4 but there was no evidence for submission before elapse of the deadline. I noted cases of material inaccuracies and inconsistencies in the annual cumulative performance reports. \uf0b7 The Embassy paid Euro.21,086.69 (equivalent to UGX.88,711,704) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 \uf0b7 The Embassy spent Embassy spent Euro.16,297.47 (equivalent to UGX.68,563,456) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Euro.15,364.80 (equivalent to UGX.64,639,713) was incurred on the payments for telephone bills out of which Euro.10,243.20 (UGX.43,093,142), equivalent to (2/3) should have been recovered from the respective staff during the period but the recovery was not effected contrary to Section H (h-e) (12) of the Public service Standing Orders, 2010. \uf0b7 The Embassy has an approved staff structure of 8 positions out of which 6 (75%) were filled leaving 2 (25%) vacant.", null, null], ["8.", "Uganda Embassy in Bujumbura 2019/20", "\uf0b7 Out of the planned 9 strategic targets/goals in the Mission charter, three (3) targets had been fully achieved, three (3) were partially achieved while three (3) were not achieved."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 187, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "175", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 187, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 I sampled 6 outputs with a total of 23 activities and actual expenditure of"], [null, "UGX.4.140Bn and observed that 4 outputs with a total of 21 activities and"], [null, "expenditure worth UGX.3.440Bn were fully quantified while 2 outputs"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 188, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", "\uf0b7 I sampled 6 outputs with a total of 23 activities and actual expenditure of"], [null, "UGX.4.140Bn and observed that 4 outputs with a total of 21 activities and"], [null, "expenditure worth UGX.3.440Bn were fully quantified while 2 outputs"], [null, "with a total of 2 activities and expenditure worth UGX.0.7Bn were"], [null, "insufficiently quantified. I further observed that all 4 outputs with 21"], [null, "activities were partially implemented."], [null, "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "MoFPED and NPA and also did not prepare and submit quarterly"], [null, "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, "\uf0b7 The entity submitted performance reports for Q1, Q2, Q3 and Q4 but"], [null, "there was no evidence for submission before elapse of the deadline."], [null, "\uf0b7 The Mission had total collections including balance brought forward from"], [null, "previous year of UGX.59,804,444 out of which UGX.17,626,729 had been"], [null, "transferred to the Treasury for onward transfer to the Consolidated Fund"], [null, "leaving a balance UGX.42,177,715 not remitted"], [null, "\uf0b7 The Embassy paid USD.16,000 (equivalent to UGX.59,685,280) in respect"], [null, "of education allowances direct to its officials instead of their respective"], [null, "education institutions or schools contrary to Section (E - e) Paragraphs 19"], [null, "and 20 of the Public Service Standing Orders, 2010."], [null, "\uf0b7 BIF.452,224,651 (equivalent to UGX.863,334,000) was withdrawn from"], [null, "the Mission\u2019s expenditure account as cash imprest but was not"], [null, "adequately accounted for."], [null, "\uf0b7 The Embassy maintains an asset register which is not in the format"], [null, "prescribed in the Treasury Instructions and has a number of assets that"], [null, "are unserviceable and need to be disposed of."], ["9\\. Uganda Embassy in Cairo, 2019/20 Opinion Unqualified \uf0b7 All the seven (7) targets/goals of the Mission Charter were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.999Bn representing 4.45% performance. \uf0b7 Out of the total receipts for the financial year of UGX.5.564Bn, UGX.4.952Bn was spent by the entity resulting in an unspent balance of UGX.0.612Bn representing an absorption level of 89%. \uf0b7 4 outputs with 14 activities and expenditure worth UGX.3.176Bn were not quantified to enable assessment of performance. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The entity submitted performance reports for Q1, Q2, Q3 and Q4 but there was no evidence for submission before elapse of the deadline. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.238,031,600 out of which UGX.183,216,635 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.54,814,965 not remitted. \uf0b7 UGX.90,391,294 was disclosed as unspent balances for the period 2018/19 but note 17, cash and cash equivalents indicates that the prior year closing balance was UGX.75,022,891. The variance amounting to UGX.15,368,403 was not explained. \uf0b7 EGP.1,015,780.00 (equivalent to UGX.229,058,390) was drawn as imprest", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 188, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "176", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 188, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["and spent on activities such as advances, transport and per diems which are not small incidental expenditures contrary to Instruction 17.22 of the Treasury Instructions 2017. \uf0b7 The Embassy paid USD.27,419.00 (equivalent to UGX.101,998,680) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 The Embassy spent Egyptian pounds.255,613 (equivalent to UGX.57,640,732) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010.", null, null, null], ["10", "Uganda High Commission in Canberra. 2019/20 Opinion Qualified", null, "\uf0b7 The High Commission made upfront payments for rent of AUD.43,096.67 (equivalent to UGX.109,469,851) beyond the financial year but did not disclose the same as prepayments in the Statement of Financial Position"], [null, null, null, "for the year. \uf0b7 The High Commission did not provide strategic performance reports and"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 189, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["and spent on activities such as advances, transport and per diems which are not small incidental expenditures contrary to Instruction 17.22 of the Treasury Instructions 2017. \uf0b7 The Embassy paid USD.27,419.00 (equivalent to UGX.101,998,680) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 The Embassy spent Egyptian pounds.255,613 (equivalent to UGX.57,640,732) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010.", null, null, null], ["10", "Uganda High Commission in Canberra. 2019/20 Opinion Qualified", null, "\uf0b7 The High Commission made upfront payments for rent of AUD.43,096.67 (equivalent to UGX.109,469,851) beyond the financial year but did not disclose the same as prepayments in the Statement of Financial Position"], [null, null, null, "for the year. \uf0b7 The High Commission did not provide strategic performance reports and"], [null, null, null, "therefore, I could not undertake an assessment of the achievements of the Mission charter targets/goals."], [null, "", "", "\uf0b7 There was a shortfall in NTR collections amounting to UGX.1.00Bn"], [null, "", "", "representing 0.05% performance."], [null, "", "", "\uf0b7 I sampled 3 outputs with a total of 9 activities and actual expenditure of"], [null, "", "", "UGX.4.84Bn and observed that the activities were not quantified. I was"], [null, "", "", "therefore unable to undertake assessment of the performance of the High"], [null, "", "", "Commission."], [null, "", "", "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "", "", "MoFPED and NPA and also did not prepare and submit quarterly"], [null, "", "", "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, "", "", "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, "", "", "\uf0b7 The entity submitted performance reports for Q1, Q2 and Q3 after the"], [null, "", "", "deadline given for submission. I noted cases of material inaccuracies and"], [null, "", "", "inconsistencies in the level of performance reported."], [null, "", "", "\uf0b7 Assets to the tune of AUD.25,060 (equivalent to UGX.63,654,906) were"], [null, "", "", "procured during the year which were not disclosed in the summary"], [null, "", "", "statement of stores and other assets (physical assets) at the end of the"], [null, "", "", "year."], [null, "", "", "\uf0b7 The High Commission had total collections including balance brought"], [null, "", "", "forward from previous year of UGX.59,002,072. At the closure of the"], [null, "", "", "period, no funds had been transferred to the Treasury for onward"], [null, "", "", "transfer to the Consolidated Fund thus implying UGX.59,002,072 was not"], [null, "", "", "remitted"], [null, "", "", "\uf0b7 The Embassy paid AUD.77,726 (equivalent to UGX.197,430,593) in"], [null, "", "", "respect of education allowances direct to its officials instead of their"], [null, "", "", "respective education institutions or schools contrary to Section (E - e)"], [null, "", "", "Paragraphs 19 and 20 of the Public Service Standing Orders, 2010."], [null, "", "", "\uf0b7 The Embassy spent AUD.77,726 (equivalent to UGX.197,430,593) on"], [null, "", "", "refunds for medical expenses to its officers contrary to the requirements"], [null, "", "", "of Section M (m-a) (14) of the Public Service Standing Orders, 2010."], [null, "", "", "\uf0b7 AUD.28,722 (equivalent to UGX.72,956,752) out of which AUD.19,148"], [null, "", "", "(equivalent to UGX.48,637,835) representing 2/3 of the amount should"], [null, "", "", "have been recovered from the respective staff was incurred on the"], [null, "", "", "payments for telephone bills during the period. The recovery was not"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 189, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "177", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 189, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, null, "effected."], [null, null, null, "\uf0b7 AUD.44,725.21 (equivalent to UGX.113,605973) was withdrawn from the"], [null, null, null, "High Commission\u2019s local expenditure account as cash imprest but was not"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 190, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", null, null, "effected."], [null, null, null, "\uf0b7 AUD.44,725.21 (equivalent to UGX.113,605973) was withdrawn from the"], [null, null, null, "High Commission\u2019s local expenditure account as cash imprest but was not"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 190, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", null, null, "effected."], [null, null, null, "\uf0b7 AUD.44,725.21 (equivalent to UGX.113,605973) was withdrawn from the"], [null, null, null, "High Commission\u2019s local expenditure account as cash imprest but was not"], [null, null, null, "adequately accounted for."], [null, null, null, "\uf0b7 Out of an approved staff structure of 7 staff positions for the Mission, six"], [null, null, null, "(86%) were filled leaving one (14%) vacant."], ["11\\. Uganda High Commission in Dar es Salaam. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 30 strategic targets/goals in the Mission charter, eight(8) outputs/targets had been fully achieved, twelve (12) were partially achieved, while ten (10) were not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.3.12Bn representing 0.01% performance. \uf0b7 I sampled 5 outputs with a total of 18 activities and actual expenditure of UGX.5.277Bn and observed that 1 output with 1 activity and expenditure worth UGX.0.173 was fully quantified, 1 output with 4 activities and expenditure worth UGX.0.674Bn was partially quantified at 50% quantification while 3 outputs with 13 activities and expenditure worth UGX.4.43Bn were not quantified. I further observed that 1 output with 1 activity and expenditure worth UGX.0.173Bn was partially implemented. \uf0b7 The entity submitted performance reports for Q1, Q2, Q3 and Q4 but there was no evidence for submission before elapse of the deadline. \uf0b7 Prepayments amounting to TSHS.1,130,500 (equivalent to UGX.1,818,975) were made to various suppliers for services but were not disclosed in the financial statements thereby understating the assets in the Statement of Financial Position and overstating expenditure in the Statement of Financial Performance. \uf0b7 The Embassy owns land in Dodoma on which the proposed Chancery building and official residence are to be constructed but the value of this land was not disclosed in the financial statements contrary to GOU accounting policy \u2018disclosure of land under non-produced assets. \uf0b7 The Embassy paid UGX.74,506,600 in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 The Embassy spent UGX.61,871,014 on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 UGX.15,954,192 out of which UGX.10,636,129 representing 2/3 of the amount should have been recovered from the respective staff was incurred on the payments for telephone bills during the period. The recovery was not effected. \uf0b7 Out of an approved staff structure of 7 staff positions for the Mission, 5 (71%) were filled leaving 2 (29%) vacant.", null, null, null], ["12.", "Uganda High Commission in Doha. 2019/20", null, "\uf0b7 Prepayments amounting to QR.424,000 (equivalent to UGX.431,046,880) were made to various suppliers for services but were not disclosed in the financial statements thereby understating the assets in the Statement of"], [null, null, null, "Financial Position and overstating expenditure in the Statement of"], [null, "Opinion Qualified", null, "Financial Performance."], [null, null, null, "\uf0b7 There was a shortfall in NTR collections amounting to UGX.1.547Bn representing 1.45% performance."], [null, "", "", "\uf0b7 Out of the total receipts for the financial year of UGX.3.293Bn,"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 190, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "178", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 190, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "UGX.2.64Bn was spent by the entity resulting in an unspent balance of"], [null, "UGX.0.653Bn representing an absorption level of 80.2%."], [null, "\uf0b7 I sampled 5 outputs with a total of 7 activities and actual expenditure of"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 191, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", "UGX.2.64Bn was spent by the entity resulting in an unspent balance of"], [null, "UGX.0.653Bn representing an absorption level of 80.2%."], [null, "\uf0b7 I sampled 5 outputs with a total of 7 activities and actual expenditure of"], [null, "UGX.2.64Bn and observed that 2 outputs of the 5 outputs with a total of"], [null, "2 activities and expenditure worth UGX.0.06Bn were not quantified. I"], [null, "further observed that 1 output out of the 3 outputs with 2 activities worth"], [null, "UGX.2.02Bn was fully implemented 2 outputs with 3 activities worth"], [null, "UGX.0.56Bn were partially implemented."], [null, "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "MoFPED and NPA and also did not prepare and submit quarterly"], [null, "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, "\uf0b7 The Embassy submitted performance reports for Q1, Q2, Q3 and Q4 after"], [null, "the deadline given for submission of the reports."], [null, "\uf0b7 The Embassy spent QR.11,481 (equivalent to UGX.11,671,814) on"], [null, "refunds for medical expenses to its officers contrary to the requirements"], [null, "of Section M (m-a) (14) of the Public Service Standing Orders, 2010."], [null, "\uf0b7 QR.43,652 (equivalent to UGX.44,377,496) out of which (2/3) amounting"], [null, "to QR.29,101 (equivalent to UGX.29,584,659) should have been"], [null, "recovered from the respective staff was incurred on the payments for"], [null, "telephone bills during the period. The recovery was not effected."], [null, "\uf0b7 I noted that all the three (3) sampled procurements were undertaken"], [null, "using direct procurement method but no justification was given and no"], [null, "contract manager was appointed to oversee these procurements."], [null, "\uf0b7 Out of an approved staff structure of 7 staff positions for the Mission, 9"], [null, "(60%) were filled leaving 6 (40%) vacant."], ["13 Uganda High Commission in Geneva. 2019/20 Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.3.045Bn representing 3% performance. \uf0b7 I sampled 3 outputs with a total of 7 activities and actual expenditure of UGX.7.66Bn and observed that all the 3 outputs were fully quantified and were partially implemented. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Embassy submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.345,130,819. At the closure of the period, UGX.146,139,671 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.198,991,148 not remitted. \uf0b7 UGX.27,296,608 was spent on procurements outside the approved procurement plan for the financial year 2019/2020 while procurements worth UGX.294,979,327 were acquired using the wrong procurement methods. \uf0b7 The fixed assets register maintained by the entity was not updated as it lacks details of exact month of purchase (only the year was mentioned), maintenance cost and estimated useful life of the asset. \uf0b7 The Embassy paid UGX.39,320,000 in respect of education allowances", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 191, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "179", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 191, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 CHF.12,623 (equivalent to UGX.49,602,836) out of which CHF.8,415 (equivalent to UGX.33,068,557) equivalent to 2/3 should have been recovered from the respective staff was incurred on the payments for telephone bills during the period. The recovery was not effected. \uf0b7 Out of an approved staff structure of 7 staff positions for the Mission, six (86%) were filled leaving one (14%) vacant.", null, null], ["14", "Uganda Consulate in Guangzhou, China 2019/20", "\uf0b7 Out of the planned 8 strategic targets/goals in the Mission charter, six (6) outputs/targets had been fully achieved while two (2) were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.037Bn representing 2.54% performance."], [null, "Opinion Unqualified", null], ["15\\. Uganda Embassy in South Sudan. 2019/20 \uf0b7 Prepayments amounting to UGX.399,145,310 were made to various suppliers for services but were not disclosed in the financial statements", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 192, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "180", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 192, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Qualified thereby understating the assets in the Statement of Financial Position and overstating expenditure in the Statement of Financial Performance. \uf0b7 Out of the planned 7 strategic targets/goals in the Mission charter, 2 outputs/targets had been fully achieved while 5 were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.56Bn representing 17.3% performance. \uf0b7 Out of the total receipts for the financial year of UGX.7.624Bn, UGX.9.11Bn was spent by the entity resulting into an over absorption of UGX.1.48Bn representing an absorption level of 119%. \uf0b7 I sampled 5 outputs with a total of 30 activities and actual expenditure of UGX.7.07Bn and observed that 4 outputs with a total of 18 activities and expenditure worth UGX.6.69Bn were fully quantified while 1 output with a total of 12 activities and expenditure worth UGX.0.39Bn was insufficiently quantified. For the 5 fully quantified outputs, 2 outputs with 2 activities worth UGX.2.55Bn were fully implemented while 3 outputs with 28 activities worth UGX.4.09Bn were partially implemented. \uf0b7 Funds to the tune of USD.17,382.29 (equivalent to UGX.64,841,678) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The entity submitted performance reports for Q1, Q2 and Q3 after the deadline given for submission. I noted some cases of material inaccuracies and inconsistencies in the level of performance reported. \uf0b7 UGX.328,779,539 reported as cash in transit has been in the books of the Embassy for more than three financial years and the funds have never been credited to the Consolidated Fund. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.884,552,695out of which UGX.180,503,771 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.704,048,924 not remitted. \uf0b7 The Embassy paid USD.25,000.00 (equivalent to UGX.93,258,250) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 USD.1,613.00 (equivalent to UGX.6,017,022) out of which USD.1,076.00 (equivalent to UGX.4,013,835) representing 2/3 of the amount should have been recovered from the respective staff was incurred on the payments for telephone bills during the period. The recovery was not effected. \uf0b7 Out of an approved staff structure of 6 staff positions for the Mission, 5 (83%) were filled leaving 1(17%) vacant.", null, null], ["16.", "Uganda Embassy in Khartoum.", "\uf0b7 Out of the planned 10 strategic targets/goals in the Mission charter, 5 outputs/targets had been fully achieved while 3 were partially achieved."], [null, "2019/20", null], [null, "Opinion", ""]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 193, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "181", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 193, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Unqualified", "UGX.4.169Bn and observed that 2 outputs with a total of 6 activities and expenditure worth UGX.0.95Bn were fully quantified, 1 output with a total"], [null, null, "of 4 activities and expenditure worth UGX.3.11Bn was insufficiently"], [null, null, "quantified while 1 output with 1 activity and expenditure worth UGX.0.11"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 194, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", "Unqualified", "UGX.4.169Bn and observed that 2 outputs with a total of 6 activities and expenditure worth UGX.0.95Bn were fully quantified, 1 output with a total"], [null, null, "of 4 activities and expenditure worth UGX.3.11Bn was insufficiently"], [null, null, "quantified while 1 output with 1 activity and expenditure worth UGX.0.11"], [null, null, "was totally not quantified. I further observed that no output was fully"], [null, null, "implemented while 3 outputs with 10 activities worth UGX.4.09Bn were"], [null, null, "partially implemented."], [null, null, "\uf0b7 Funds to the tune of USD.4,393.04 (equivalent to UGX.15,595,150) were"], [null, null, "irregularly diverted from the activities on which they were budgeted and"], [null, null, "spent on other activities without seeking and obtaining the necessary"], [null, null, "approvals."], [null, null, "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, null, "MoFPED and NPA and also did not prepare and submit quarterly"], [null, null, "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, null, "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, null, "\uf0b7 The entity submitted performance reports for Q1, Q2 and Q3 after the"], [null, null, "deadline given for submission."], [null, null, "\uf0b7 The Embassy paid USD.17,500.00 (equivalent to UGX.64,925,000) in"], [null, null, "respect of education allowances direct to its officials instead of their"], [null, null, "respective education institutions or schools contrary to Section (E - e)"], [null, null, "Paragraphs 19 and 20 of the Public Service Standing Orders, 2010."], [null, null, "\uf0b7 The Embassy spent USD.3,702.42 (equivalent to UGX.13,702,656.42) on"], [null, null, "refunds for medical expenses to its officer\u2019s contrary to the requirements"], [null, null, "of Section M (m-a) (14) of the Public Service Standing Orders, 2010."], [null, null, "\uf0b7 USD.7,979.94 (equivalent to UGX.29,605,577) out of which USD.5,319.96"], [null, null, "(equivalent to UGX.19,737,051) representing 2/3 of the amount should"], [null, null, "have been recovered from the respective staff was incurred on the"], [null, null, "payments for telephone bills during the period. The recovery was not"], [null, null, "affected."], [null, null, "\uf0b7 Out of an approved staff structure of 5 staff positions for the Mission, 4"], [null, null, "(80%) were filled leaving 1 (20%) vacant."], ["17 Uganda Embassy in Kigali. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 10 strategic targets/goals in the Mission charter, 2 outputs/targets had been fully achieved, 2 were partially achieved while 6 were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.3.07Bn representing 2.3% performance. \uf0b7 I sampled 4 outputs with a total of 13 activities and actual expenditure of UGX.3.325Bn and observed that all the 4 outputs were not quantified. Therefore, I was unable to undertake assessment of the performance of the Mission. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The entity submitted performance reports for Q1, Q2 and Q3 after the deadline given for submission. I noted that the cumulative activities reported in the fourth quarter performance report did not include all activities implemented in the first, second and third quarters. \uf0b7 I noted that the assets register maintained was not in the format prescribed in the Treasury Instructions and lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 194, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "182", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 194, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["useful life. \uf0b7 Out of an approved staff structure of 5 staff positions for the Mission, two (2) (40%) were filled leaving 3 (60%) vacant.", null, null], ["18", "Uganda Embassy in Kinshasa. 2019/20", "\uf0b7 UGX.241,949,940 was reported as the variance between the approved budget/warrants and the actual expenditure instead of UGX.3,564,587. The source of UGX.241,949,940 could not be established. \uf0b7 The statement of revenue collected in the financial statements in comparison with statement of performance and the NTR estimates for the"], [null, "Opinion Qualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 195, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "183", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 195, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "(85.7%) were filled leaving 3 (14.3%) vacant."], ["19 Uganda High Commission in Kuala Lumpur. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 10 (ten) strategic targets/goals in the Mission charter, one (1) target had been fully achieved, three (3) were partially achieved, while six (6) were not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.068Bn representing 1% performance. \uf0b7 I sampled 3 outputs with a total of 13 activities and actual expenditure of UGX.3.57Bn and observed that 2 outputs with a total of 9 activities and expenditure worth UGX.0.87Bn were fully quantified while 1 output with a total of 4 activities and expenditure worth UGX.2.6Bn was insufficiently quantified. Of the fully quantified outputs, 1 output with 5 activities worth UGX.0.21Bn was fully implemented while 1 output with 4 activities worth UGX.0.66Bn was partially implemented. \uf0b7 Funds to the tune of MYR.11,209 (equivalent to UGX.9,763,039) were irregularly diverted from purchase of specialized machinery and equipment for which they were budgeted to purchase of curtains without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q2 and Q3 after the deadline given for submission of the reports. \uf0b7 The Embassy paid MYR.136,000 (equivalent to UGX.118,456,000) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 The Mission has an approved staff structure of five (5) staff positions out of which, two (2) (40%) were filled leaving three (3) (60%) vacant. \uf0b7 Management of the Embassy paid salary and FSA advances to staff to the tune of MYR.185,950 (equivalent to UGX.160,995,510) which exceeded three (3) months gross pay and no authority was sought from Secretary to the Treasury. This is contrary to the Public Service Standing Orders, 2010.", null, null], ["20", "Uganda High Commission in London. 2019/20 Opinion Unqualified", "\uf0b7 Out of the planned 9 (nine) strategic targets/goals in the Mission charter, four (4) targets had been fully achieved, three (3) were partially"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 196, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", null, "(85.7%) were filled leaving 3 (14.3%) vacant."], ["19 Uganda High Commission in Kuala Lumpur. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 10 (ten) strategic targets/goals in the Mission charter, one (1) target had been fully achieved, three (3) were partially achieved, while six (6) were not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.068Bn representing 1% performance. \uf0b7 I sampled 3 outputs with a total of 13 activities and actual expenditure of UGX.3.57Bn and observed that 2 outputs with a total of 9 activities and expenditure worth UGX.0.87Bn were fully quantified while 1 output with a total of 4 activities and expenditure worth UGX.2.6Bn was insufficiently quantified. Of the fully quantified outputs, 1 output with 5 activities worth UGX.0.21Bn was fully implemented while 1 output with 4 activities worth UGX.0.66Bn was partially implemented. \uf0b7 Funds to the tune of MYR.11,209 (equivalent to UGX.9,763,039) were irregularly diverted from purchase of specialized machinery and equipment for which they were budgeted to purchase of curtains without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q2 and Q3 after the deadline given for submission of the reports. \uf0b7 The Embassy paid MYR.136,000 (equivalent to UGX.118,456,000) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 The Mission has an approved staff structure of five (5) staff positions out of which, two (2) (40%) were filled leaving three (3) (60%) vacant. \uf0b7 Management of the Embassy paid salary and FSA advances to staff to the tune of MYR.185,950 (equivalent to UGX.160,995,510) which exceeded three (3) months gross pay and no authority was sought from Secretary to the Treasury. This is contrary to the Public Service Standing Orders, 2010.", null, null], ["20", "Uganda High Commission in London. 2019/20 Opinion Unqualified", "\uf0b7 Out of the planned 9 (nine) strategic targets/goals in the Mission charter, four (4) targets had been fully achieved, three (3) were partially"], [null, null, "achieved, while two (2) were not achieved."], [null, null, "\uf0b7 There was a shortfall in NTR collections amounting to UGX.1.604Bn"], [null, null, "representing 31% performance."], [null, null, "\uf0b7 I sampled 4 outputs with a total of 7 activities and actual expenditure of UGX.7.32Bn and observed that all the 4 outputs with 7 activities and"], [null, null, "expenditure worth UGX.7.32Bn were not quantified to enable assessment"], [null, null, "of performance."], [null, null, "\uf0b7 Funds to the tune of GBP.2,598.56 (equivalent to UGX.11,756,583) were"], [null, null, "irregularly diverted from purchase of specialized machinery and"], [null, null, "equipment for which they were budgeted to purchase of curtains without"], [null, null, "seeking and obtaining the necessary approvals."], [null, null, "\uf0b7 Entities are supposed to report actual performance of the quarter as well"], [null, null, "as the cumulative activities of the previous quarter(s). I observed that"], [null, null, "cumulative performance reports did not include activities implemented in"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 196, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "184", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 196, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "the previous quarter(s)."], [null, "\uf0b7 The Mission had total collections including balance brought forward from"], [null, "previous year of UGX.1,606,177,645 out of which UGX.706,072,607 had"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 197, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": [["", "the previous quarter(s)."], [null, "\uf0b7 The Mission had total collections including balance brought forward from"], [null, "previous year of UGX.1,606,177,645 out of which UGX.706,072,607 had"], [null, "been transferred to the Treasury for onward transfer to the Consolidated"], [null, "Fund leaving a balance UGX.900,105,038 not remitted."], [null, "\uf0b7 Payables increased from UGX.130,550,604 in the previous year to"], [null, "UGX.161,515,890 in the year under review, an increase of 24%. The"], [null, "arrears remained unsettled at the close of the year."], [null, "\uf0b7 Management has accumulated receivable advances to the tune of"], [null, "UGX.105,435,937 of which UGX.79,896,783 (76%) relates to the prior"], [null, "year and remains unrecovered."], [null, "\uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end"], [null, "of the financial year 2019/2020 revealed that additions during the year"], [null, "relating to non-residential buildings were disclosed as UGX.465,161,335,"], [null, "however, the Embassy procured items amounting to GBP.107,661"], [null, "(equivalent to UGX.494,777,699) implying that items worth"], [null, "UGX.29,616,364 were not disclosed in this statement thus understating"], [null, "the Statement of Stores and Other Assets (physical assets)."], [null, "\uf0b7 The Embassy had a capital expenditure budget of UGX.275,000,000 but"], [null, "items worth UGX.494,777,699 were procured resulting into an over"], [null, "expenditure of UGX.224,777,699."], [null, "\uf0b7 The Embassy paid GBP.28,187.49 (equivalent UGX.129,541,258) in"], [null, "respect of education allowances direct to its officials instead of their"], [null, "respective education institutions or schools contrary to Section (E - e)"], [null, "Paragraphs 19 and 20 of the Public Service Standing Orders, 2010."], [null, "\uf0b7 The Embassy spent GBP.14,300.09 (equivalent to UGX.65,718,929) on"], [null, "refunds for medical expenses to its officers contrary to the requirements"], [null, "of Section M (m-a) (14) of the Public Service Standing Orders, 2010."], [null, "\uf0b7 The Mission has an approved staff structure of eight (8) staff positions"], [null, "out of which, 5 (63%) were filled leaving 3 (37%) vacant."], ["21\\. Uganda Embassy in Mogadishu. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 5 strategic targets/goals in the Mission charter, all the 5 were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.3.14Bn representing 0% performance. \uf0b7 Out of the total receipts of UGX.3.78Bn, UGX.2.87Bn was spent by the entity resulting in an unspent balance of UGX.0.91Bn representing an absorption level of 76%. \uf0b7 I sampled 3 outputs with a total of 6 activities and actual expenditure of UGX.2.87Bn and observed that all the 3 outputs with a total of 6 activities and expenditure worth UGX.2.87Bn were not quantified at all. I was therefore unable to assess the implementation of outputs/activities of the Mission. \uf0b7 Funds to the tune of UGX.16,835,000 were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, Q2, Q3 and Q4 after", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 197, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "EUR.37,847.45 (equivalent to UGX.158,170,928) during the period when"], "type": "table"}}, {"content": "185", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 197, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["the deadline given for submission. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.850,244,773 out of which UGX.7,829 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.850,236,944 not remitted. \uf0b7 USD.1,020,250 (equivalent to UGX.3,800,767,933) was withdrawn as petty cash during the year out of which USD.340,250.00 (equivalent to UGX.1,267,543,533) was withdrawn in the last quarter of the financial year (March, April, May and June), the period affected by COVID 19 lockdown which appears irregular. \uf0b7 The Embassy paid UGX.83,250,000 in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010.", null, null], ["22.", "Uganda Consulate in", "\uf0b7 Out of the planned 6 strategic targets/goals in the Mission charter, 2"], ["", "Mombasa. 2019/20", "outputs/targets had been fully achieved while 4 were partially achieved."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 198, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": [["the deadline given for submission. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.850,244,773 out of which UGX.7,829 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.850,236,944 not remitted. \uf0b7 USD.1,020,250 (equivalent to UGX.3,800,767,933) was withdrawn as petty cash during the year out of which USD.340,250.00 (equivalent to UGX.1,267,543,533) was withdrawn in the last quarter of the financial year (March, April, May and June), the period affected by COVID 19 lockdown which appears irregular. \uf0b7 The Embassy paid UGX.83,250,000 in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010.", null, null], ["22.", "Uganda Consulate in", "\uf0b7 Out of the planned 6 strategic targets/goals in the Mission charter, 2"], ["", "Mombasa. 2019/20", "outputs/targets had been fully achieved while 4 were partially achieved."], [null, null, "\uf0b7 There was a shortfall in NTR collections amounting to UGX.2.089Bn representing 0.01% performance. \uf0b7 Out of the total receipts for the financial year of UGX.1.996Bn,"], [null, "", "UGX.1.883Bn was spent by the entity resulting in an under expenditure of"], [null, "", "UGX.0.113Bn representing an absorption level of 94.34%."], [null, "", "\uf0b7 UGX.12,562,792 was received as off-budget financing for a symposium"], [null, "", "held in the financial year under review but the funds were not disclosed"], [null, "", "in the financial statements."], [null, "", "\uf0b7 I sampled 3 outputs with a total of 4 activities and actual expenditure of"], [null, "", "UGX.1.883Bn and observed that 1 output with a total of 2 activities and"], [null, "", "expenditure worth UGX.0.73Bn was fully quantified while 2 outputs with a"], [null, "", "total of 2 activities and expenditure worth UGX.1.15Bn were insufficiently"], [null, "", "quantified. The quantified output with all its activities with its activities"], [null, "", "and expenditure worth UGX.0.73Bn was partially implemented."], [null, "", "\uf0b7 Funds to the tune of UGX.5,205,620 were charged wrongly on other"], [null, "", "expenditure item codes without obtaining the necessary approvals."], [null, "", "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "", "MoFPED and NPA and also did not prepare and submit quarterly"], [null, "", "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, "", "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, "", "\uf0b7 Entities are supposed to report actual performance of the quarter as well"], [null, "", "as the cumulative activities of the previous quarter(s). I observed that"], [null, "", "cumulative performance reports did not include activities implemented in"], [null, "", "the previous quarter(s)."], [null, "", "\uf0b7 The Embassy paid UGX.44,763,960 in respect of education allowances"], [null, "", "direct to its officials instead of their respective education institutions or"], [null, "", "schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public"], [null, "", "Service Standing Orders, 2010."], [null, "", "\uf0b7 A number of the Consulate\u2019s assets were old and due for boarding off but"], [null, "", "were still at the Consulate resulting into loss of value and high"], [null, "", "maintenance costs."], ["23\\. Uganda Embassy in Moscow. 2019/20 \uf0b7 Out of the planned 24 (twenty-four) strategic targets/goals in the Mission charter, thirteen (13) targets had been fully achieved, eight (8) were partially achieved, while three (3) were not achieved.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 198, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "186", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 198, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", null, null], ["24.", "Uganda High Commission in Nairobi.", "\uf0b7 Out of the planned 10 (ten) strategic targets/goals in the Mission charter, 2 (two) were partially achieved while eight (8) were not achieved."], [null, "2019/20", null], [null, "Opinion Unqualified", ""], [null, null, "was spent by the entity resulting in an unspent balance of UGX.1.17Bn"], [null, null, "representing an absorption level of 76.3%."], [null, null, "\uf0b7 I sampled 4 outputs with a total of 7 activities and actual expenditure of"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 199, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "187", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 199, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "UGX.3.77Bn and observed that all the 4 outputs with a total of 7 activities"], [null, "and expenditure worth UGX.3.77Bn were fully quantified but were"], [null, "partially implemented."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 200, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None"], "type": "table"}}, {"content": [["", "UGX.3.77Bn and observed that all the 4 outputs with a total of 7 activities"], [null, "and expenditure worth UGX.3.77Bn were fully quantified but were"], [null, "partially implemented."], [null, "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "MoFPED and NPA and also did not prepare and submit quarterly"], [null, "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, "\uf0b7 The Mission submitted performance reports for all quarters after the"], [null, "deadline given for submission. I also observed that cumulative"], [null, "performance reports revealed that the subsequent quarterly performance"], [null, "reports did not include activities implemented in the previous quarter(s)."], [null, "\uf0b7 Accumulated arrears of revenue to the tune of UGX.181,948,023 most of"], [null, "which related to the prior year remained uncollected."], [null, "\uf0b7 The Embassy paid a sum of USD.46,950 (equivalent to UGX.174,513,150)"], [null, "to Toyota Kenya Limited for the acquisition of a Land Cruiser Prado but"], [null, "the procurement was undertaken by the High Commissioner instead of"], [null, "the Accounting Officer which resulted into usurping the powers of the"], [null, "Accounting Officer, over committing the Mission, non-compliance with"], [null, "Government ban on acquisition of motor vehicles, un-planned"], [null, "procurement, use of inappropriate procurement method and failure to"], [null, "involve the Contracts Committee."], [null, "\uf0b7 The Embassy paid KES.3,360,000 (equivalent to UGX.117,633,600) in"], [null, "respect of education allowances direct to its officials instead of their"], [null, "respective education institutions or schools contrary to Section (E - e)"], [null, "Paragraphs 19 and 20 of the Public Service Standing Orders, 2010."], [null, "\uf0b7 The Embassy spent KES.620,485 (equivalent to UGX.21,723,180)on"], [null, "refunds for medical expenses to its officers contrary to the requirements"], [null, "of Section M (m-a) (14) of the Public Service Standing Orders, 2010."], [null, "\uf0b7 The Mission did not have a fixed assets register in the format prescribed"], [null, "in the Treasury Instructions and therefore additions and disposals to the"], [null, "assets could not be verified. I further observed that a number of the"], [null, "entity\u2019s assets were old and due for boarding off exposing the assets to"], [null, "loss of value and high maintenance costs."], [null, "\uf0b7 The Mission has an approved staff structure of seven (7) staff positions"], [null, "out of which 5 (71.4%) were filled leaving 2 (28.5%) vacant."], ["25\\. Uganda Embassy in New Delhi. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 6 (six) strategic targets/goals in the Mission charter, 1 (one) was fully achieved while 2 (two) were partially achieved while three (3) were not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.62Bn representing 0.0015% performance. \uf0b7 Out of the total receipts for the financial year of UGX.4.554Bn, UGX.3.732Bn was spent by the entity resulting in an unspent balance of UGX.0.822Bn representing an absorption level of 81.9%. \uf0b7 I sampled 3 outputs with a total of 6 activities and actual expenditure of UGX.3.732Bn and observed that all the 3 outputs were fully quantified and none was fully implemented. \uf0b7 Funds to the tune of INR.42,262 (equivalent to UGX.2,062,385) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit annual monitoring plans to", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 200, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None"], "type": "table"}}, {"content": "188", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 200, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["MoFPED and NPA and contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 Cumulative performance reports did not include activities implemented in the previous quarter(s). \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.524,440,586 out of which UGX.160,671,521 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.1,284,723,792 not remitted. \uf0b7 INR.38,324.24 (equivalent to UGX.1,839,564) out of which 2/3 of the amount should have been recovered from the respective staff was incurred on the payments for telephone bills during the period. The recovery was not effected. \uf0b7 Salary advances to the tune of USD. 98,406.39 (equivalent to UGX.369,023,963) were paid to staff during the year which exceeded three (3) months gross contrary to the Public Service Standing Orders. \uf0b7 The Embassy spent INR.549,516.00 (equivalent to UGX.26,376,775) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010.", null, null], ["26.", "The Uganda Embassy in New York.", "\uf0b7 The Embassy had a capital expenditure budget of UGX.0 but items worth UGX.665,143,450 resulting into an over expenditure of UGX.665,143,450."], [null, "2019/20 Opinion Qualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 201, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": "189", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 201, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, null, "\uf0b7 The Embassy spent UGX.145,667,183 on refunds for medical expenses to"], [null, null, null, "its officers contrary to the requirements of Section M (m-a) (14) of the"], [null, null, null, "Public Service Standing Orders, 2010."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 202, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None", "None"], "type": "table"}}, {"content": [["", null, null, "\uf0b7 The Embassy spent UGX.145,667,183 on refunds for medical expenses to"], [null, null, null, "its officers contrary to the requirements of Section M (m-a) (14) of the"], [null, null, null, "Public Service Standing Orders, 2010."], [null, null, null, "\uf0b7 The Mission prepared an approved procurement plan for the financial"], [null, null, null, "year 2019/2020 but procurement reports and procurement files were not"], [null, null, null, "availed for audit."], [null, null, null, "\uf0b7 The Mission has an approved staff structure of 9 staff positions out of"], [null, null, null, "which 8 (88%) were filled leaving 01 (12%) vacant."], ["27\\. Uganda High Commission in Ottawa. 2019/20 Opinion Unqualified \uf0b7 Out of the planned 8 (eight) strategic targets/goals in the Mission charter, four (4) were fully achieved while 2 (two) were partially achieved while two (2) were not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.077Bn representing 0.62% performance. \uf0b7 I sampled 3 outputs with a total of 8 activities and actual expenditure of UGX.5.63Bn and observed that all the 3 outputs were fully quantified but none was fully implemented. \uf0b7 Funds to the tune of CAD.3,301.3 (equivalent to UGX.9,586,521) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The Mission did not prepare and submit the annual monitoring plans to MoFPED and NPA contrary Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.2,585,956,931 out of which UGX.39,588,787 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.2,546,368,144 not remitted. \uf0b7 The Mission paid CAD.35,000.00 (equivalent to UGX.101,605,000)in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Embassy spent CAD.114,255 (equivalent to UGX.331,693,168) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010.", null, null, null], ["28.", "Uganda Embassy in Paris. 2019/20 Opinion Unqualified", null, "\uf0b7 The Mission made upfront payments for rent of EUR.50,183 (equivalent to UGX.209,723,288) beyond the financial year but did not disclose the"], [null, null, null, "same as prepayments in the Statement of Financial Position for the year. \uf0b7 Funds to the tune of UGX.40,504,892 were irregularly diverted from the"], [null, null, null, "activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals."], [null, "", "", "\uf0b7 There was a shortfall in NTR collections amounting to UGX.2.61Bn"], [null, "", "", "representing 0.4% performance."], [null, "", "", "\uf0b7 Out of the total receipts for the financial year of UGX.9.59Bn, UGX.5.56Bn"], [null, "", "", "was spent by the entity resulting in an unspent balance of UGX.4.03Bn"], [null, "", "", "representing an absorption level of 58%."], [null, "", "", "\uf0b7 I sampled 4 outputs with a total of 19 activities and actual expenditure of"], [null, "", "", "UGX.5.56Bn and observed that 1 output (25%) with a total of 7 activities"], [null, "", "", "and expenditure worth UGX.1.61Bn was insufficiently quantified while 3"], [null, "", "", "outputs (75%) with a total of 12 activities and expenditure worth UGX"], [null, "", "", "3.95Bn were not quantified at all. I was therefore unable to undertake"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 202, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None", "None"], "type": "table"}}, {"content": "190", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 202, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "assessment of implementation of outputs by the Mission."], [null, "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "MoFPED and NPA and also did not prepare and submit quarterly"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 203, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None"], "type": "table"}}, {"content": [["", "assessment of implementation of outputs by the Mission."], [null, "\uf0b7 The Mission did not prepare and submit annual monitoring plans to"], [null, "MoFPED and NPA and also did not prepare and submit quarterly"], [null, "monitoring reports to the Office of the Prime Minister and MoFPED"], [null, "contrary to Paragraph 58 of the Budget Execution Circular for 2019/20."], [null, "\uf0b7 The Mission submitted performance reports for Q1, Q2, Q3 and Q4 after"], [null, "the deadline given for submission. Furthermore, entities are supposed to"], [null, "report actual performance of the quarter as well as the cumulative"], [null, "activities of the previous quarter(s) but the Mission quarterly performance"], [null, "reports did not include activities implemented in the previous quarter(s)."], [null, "\uf0b7 The Embassy paid EUROS.30,691 (equivalent to UGX.128,071,701) in"], [null, "respect of education allowances direct to its officials instead of their"], [null, "respective education institutions or schools contrary to Section (E - e)"], [null, "Paragraphs 19 and 20 of the Public Service Standing Orders, 2010."], [null, "\uf0b7 The Embassy spent EUROS.7,933 (equivalent to UGX.33,101,972) on"], [null, "refunds for medical expenses to its officers contrary to the requirements"], [null, "of Section M (m-a) (14) of the Public Service Standing Orders, 2010."], [null, "\uf0b7 UGX.3.75BN was released for renovation and modification of Uganda"], [null, "Chancery Building in Paris but the procurement was undertaken using the"], [null, "restricted bidding instead of open domestic bidding without proper"], [null, "justification. Furthermore, the implementation of the contract had not"], [null, "commenced by the end of the financial and the contactor is said to have"], [null, "had difficulty in obtaining a bank guarantee from banks because the"], [null, "Mission is a foreign entity which could pose challenges in contract"], [null, "performance."], [null, "\uf0b7 The Mission has an approved staff structure of 7 staff positions out of"], [null, "which positions, 6 (86%) were filled leaving 1 (14%) vacant."], [null, "\uf0b7 EUR.43,541.63 (equivalent to UGX.181,969,420) was paid from the"], [null, "Mission\u2019s imprest account to cater for official activities but EUR.15,851"], [null, "(equivalent to UGX.66,244,024) was spent on activities such as,"], [null, "allowances, purchase of computer and household items which cannot be"], [null, "categorised under imprest making it irregular."], ["29\\. Uganda Embassy in Pretoria. 2019/2020 Opinion Unqualified \uf0b7 Out of the planned 8 (eight) strategic targets/goals in the Mission charter, two (2) were fully achieved while 4 (four) were partially achieved while two (2) were not achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.2.49Bn representing 5% performance. \uf0b7 I sampled 4 outputs with a total of 8 activities and actual expenditure of UGX.3.62Bn and observed that three (3) outputs with a total of seven (7) activities and expenditure worth UGX.3.54Bn were fully quantified while one (1) output with one (1) activity and expenditure worth UGX.0.08Bn was not quantified. Of the quantified outputs, one (1) output with three (3) activities worth UGX.0.38Bn was fully implemented while two (2) outputs with four (4) activities worth UGX.3.16Bn were partially implemented. \uf0b7 Funds to the tune of RAND.35,774.08 (equivalent to UGX.7,697,509) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The entity submitted performance reports for Q1, Q2, Q3, and Q4, however they were submitted after the deadline. I also observed that cumulative performance reports did not include activities implemented in", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 203, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None"], "type": "table"}}, {"content": "191", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 203, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["the previous quarter(s) \uf0b7 The Embassy paid USD.18,000.009 (equivalent to UGX.66,785,973) in respect of education allowances direct to its officials instead of their respective education institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders, 2010. \uf0b7 The Embassy spent 162,579.25 RAND (equivalent to UGX.34,982,177) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 The Mission has an approved staff structure of 6 staff positions out of which, 5 (83%) were filled leaving 1 (17%) vacant.", null, null], ["30.", "Uganda Embassy in Riyadh 2019/2020", "\uf0b7 There was a shortfall in NTR collections amounting to UGX.2.088Bn representing 0.5% performance. \uf0b7 I sampled 3 outputs with a total of 13 activities and actual expenditure of UGX.4.156Bn and observed that all the 3 outputs were fully quantified. I"], [null, "Opinion Unqualified", null], ["31\\. Uganda Embassy in Rome 2019/20 Opinion Unqualified \uf0b7 Out of the planned 8 (eight) strategic targets/goals in the Mission charter, two (2) targets had been fully achieved and six (6) were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.503Bn representing 4.2% performance. \uf0b7 Of the total receipts for the financial year of UGX.5.564Bn, UGX.4.952Bn was spent by the entity resulting in an unspent balance of UGX.0.612Bn representing an absorption level of 89%. \uf0b7 I sampled 4 outputs with a total of 8 activities and actual expenditure of UGX.3.62Bn and observed that 3 outputs with a total of 7 activities and expenditure worth UGX.3.54Bn were fully quantified while 1 output with 1 activity and expenditure worth UGX.0.08Bn was not quantified. Of the quantified outputs, 1) output with 3) activities worth UGX.0.38Bn was fully implemented while 2 outputs with 4 activities worth UGX.3.16Bn", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 204, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": "192", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 204, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["were partially implemented. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.1,702,152,606 out of which UGX.67,884,170 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.1,634,268,436 not remitted. \uf0b7 The Mission reported cash in transit of UGX.32,102,340 which relates to over 10 years ago which may be difficult for the Mission to trace or recover. \uf0b7 The Statement of Contingent Liabilities in the financial statements for the year ended 30th June, 2020, indicated an opening balance of UGX.1,141,003,975.79 instead of UGX.542,522,152.97 resulting into an overstatement of UGX.598,481,822.82. \uf0b7 During the year 2019/2020, management of the Mission was availed a supplementary funding of UGX.433,360,086 to cater for settlement of four (4) court cases but the Mission still remained with outstanding liabilities for settlement of court cases amounting to UGX.542,522,152 at the end of the year. \uf0b7 The Embassy spent Euros.8,430.75 (equivalent to UGX.35,422,471) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 The Embassy has an approved staff structure of 6 staff positions out of which 5 (83%) were filled leaving 1 (15%) vacant.", null, null], ["32.", "Uganda Embassy in Tokyo", "\uf0b7 Out of the planned 17 (seventeen) strategic targets/goals in the Mission"], ["", "2019/20", "charter, nine (9) were fully achieved, 4 (four) were partially achieved while four (4) were not achieved at all. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.451Bn"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 205, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": "193", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 205, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 JPY.2,591,132 (equivalent to UGX.89,938,192) out of which 2/3 of the"], [null, null, "amount should have been recovered from the respective staff was"], [null, null, "incurred on the payments for telephone bills during the period. The"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 206, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": [["", null, "\uf0b7 JPY.2,591,132 (equivalent to UGX.89,938,192) out of which 2/3 of the"], [null, null, "amount should have been recovered from the respective staff was"], [null, null, "incurred on the payments for telephone bills during the period. The"], [null, null, "recovery was not effected."], [null, null, "\uf0b7 The fixed assets register maintained by the entity was not in the format"], [null, null, "prescribed in the Treasury Instructions and lacked details of: cost of"], [null, null, "some items, maintenance cost, estimated useful life, among others and"], [null, null, "assets which had already been disposed were still in the assets register."], ["33\\. Uganda Embassy in Washington. 2019/20 Opinion Unqualified \uf0b7 Funds to the tune of UGX.184,722,054 were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 Out of the planned 31 strategic targets/goals in the Mission charter, 13 were fully achieved while 18 were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.3.64Bn representing 0.7% performance. \uf0b7 Out of the total receipts for the financial year of UGX.8,039,710,935, UGX.7,707,884,006 was spent by the entity resulting in an unspent balance of UGX.331,826,929 representing an absorption level of 96%. \uf0b7 I sampled 6 outputs with a total of 17 activities and actual expenditure of UGX.7.67Bn and observed that all 6 outputs were not quantified. I was therefore unable to undertake assessment of performance. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 Performance reports for Q1, Q2 and Q3 were submitted after the deadline given for submission. \uf0b7 The Mission paid USD.27,500 (equivalent to UGX.103,134,075) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Embassy spent USD.21,764.99 (equivalent to UGX.81,625,894.95) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 USD.18,000 (equivalent to UGX.69,552,175) was paid to Embassy staff as Covid relief allowance during the financial year 2019/2020 in the last month of the financial year. This allowance is not provided for in the Public Service Standing Orders and neither was it budgeted for during the year. \uf0b7 JPY.2,591,132 (equivalent to UGX.89,938,192) out of which 2/3 of the amount should have been recovered from the respective staff was incurred on the payments for telephone bills during the period. The recovery was not effected. \uf0b7 The fixed assets register maintained by the entity was not in the format prescribed in the Treasury Instructions and lacked details of: cost of some items, maintenance cost, estimated useful life, among others and assets which had already been disposed were still in the assets register.", null, null], ["34.", "Uganda Embassy in Teheranc. 2019/2020", "\uf0b7 Out of the planned 11 (eleven) strategic targets/goals in the Mission charter, one (1) were fully achieved while 10 (ten) were partially"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 206, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": "194", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 206, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "achieved."], [null, "Opinion", "\uf0b7 There was a shortfall in NTR collections amounting to UGX.1.57Bn representing 0.1% performance. \uf0b7 I sampled 7 outputs with a total of 12 activities and actual expenditure of"], [null, "Unqualified", null], ["35\\. Uganda Embassy in Addis Ababa. 2019/2020 Opinion Unqualified \uf0b7 Out of the planned 7 strategic targets/goals, no target was fully achieved, 5 targets were fully achieved and 2 targets were partially achieved. \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.85Bn representing 11% performance. \uf0b7 Out of the total receipts for the financial year of UGX.4.16Bn, UGX.3.81Bn was spent by the entity resulting in an unspent balance of UGX.0.35Bn representing an absorption level of 91.5%. \uf0b7 I sampled 5 outputs with a total of 9 activities and actual expenditure of UGX.3.76Bn and observed that 3 outputs with a total of 7 activities and expenditure worth UGX.3.76Bn were fully quantified while 2 outputs with a total of 2 activities were not quantified. I further observed that 2 outputs with 5 activities worth UGX.3.22Bn were fully implemented while 1 output with 2 activities worth UGX.0.674Bn was partially implemented. \uf0b7 Funds to the tune of Birr.304,045.69 (equivalent to UGX.23,958,820) were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 A review of the 4 quarterly performance reports revealed that the supplementary release of UGX.0.653Bn was not captured at all making the reports inaccurate. \uf0b7 The Mission had total collections including balance brought forward from previous year of UGX.707,901,392 out of which UGX.236,256,209 had been transferred to the Treasury for onward transfer to the Consolidated Fund leaving a balance UGX.471,645,183 not remitted. \uf0b7 USD.48,129.83 and BIRR.94,144.96 (equivalent to UGX.183,940,336)", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 207, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": "195", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 207, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["was withdrawn from the Mission\u2019s local expenditure account as cash imprest but was not adequately accounted for. \uf0b7 The Mission paid USD.44,000.00 (equivalent to UGX.165,000,000) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission paid medical refunds to its staff amounting to Birr.298,287.38 (equivalent to UGX.582,793,607) contrary to Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 The Mission maintains an assets register that is not in the format prescribed by the Treasury Instructions.", null, null], ["36.", "Uganda Embassy in Copenhagen. 2019/2020", "\uf0b7 A sum of UGX.300,000,000 was approved by Parliament as supplementary budget for the Embassy for the financial year 2019/2020 out of which UGX.270,000,000 was subsequently released during the"], [null, null, "year. This amount was not accurately disclosed in the \u201cCommentary on"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 208, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": [["was withdrawn from the Mission\u2019s local expenditure account as cash imprest but was not adequately accounted for. \uf0b7 The Mission paid USD.44,000.00 (equivalent to UGX.165,000,000) in respect of education allowances direct to its officials instead of their respective educational institutions or schools contrary to Section (E - e) Paragraphs 19 and 20 of the Public Service Standing Orders 2010. \uf0b7 The Mission paid medical refunds to its staff amounting to Birr.298,287.38 (equivalent to UGX.582,793,607) contrary to Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 The Mission maintains an assets register that is not in the format prescribed by the Treasury Instructions.", null, null], ["36.", "Uganda Embassy in Copenhagen. 2019/2020", "\uf0b7 A sum of UGX.300,000,000 was approved by Parliament as supplementary budget for the Embassy for the financial year 2019/2020 out of which UGX.270,000,000 was subsequently released during the"], [null, null, "year. This amount was not accurately disclosed in the \u201cCommentary on"], [null, "Opinion Qualified", "the Financial Statements by the Head of Accounts\u201d."], [null, null, "\uf0b7 Receivables from security deposits reduced by UGX.53,375,046 from UGX.313,145,225 in the previous year to UGX.259,770,179 as at the end"], [null, null, "of the year 2019/2020. I was not availed with supporting records to"], [null, null, "confirm the movement."], [null, null, "\uf0b7 VAT claims increased from UGX.45,636,374 in the previous year to"], [null, null, "UGX.70,11,405 in the current year. I was not provided with a ledger"], [null, null, "showing the specific VAT claims, the VAT supplier numbers, and"], [null, null, "documents to support the claims for refunds from the tax authority"], [null, null, "among others."], [null, null, "\uf0b7 Monthly and end-of-year bank reconciliations were not carried out. In"], [null, null, "addition, a list of bank accounts operated by the Embassy during the year"], [null, null, "was not disclosed by the Head of Accounts in his commentary on the"], [null, null, "Financial Statements."], [null, null, "\uf0b7 The Embassy\u2019s approved budget for Non-Tax Revenue was"], [null, null, "UGX.1,570,000,000. I observed that the Non-Tax Revenue budget was"], [null, null, "not reflected in the Statements of Appropriation."], [null, null, "\uf0b7 The Mission paid advances to various suppliers amounting to"], [null, null, "DKK.861,578.82 (equivalent to UGX.479,037,824). Whereas the Financial"], [null, null, "Reporting Guide, 2018 requires that prepayments are reported separately"], [null, null, "in the Statement of Cash Flows \u2013 as net advances paid and in the"], [null, null, "Statement of Financial Position as receivables, I noted that these"], [null, null, "prepayments were missing in both statements."], [null, null, "\uf0b7 The Embassy lost a court case and subsequently a sum of"], [null, null, "UGX.27,965,384 (DKK.49,878.51) was awarded and paid in the year"], [null, null, "2019/2020. I noted that the Memorandum Statement of Outstanding"], [null, null, "Commitments did not disclose the details regarding this case and there"], [null, null, "was no evidence that the funds for settlement of this court case had been"], [null, null, "budgeted for during the year."], [null, null, "\uf0b7 Funds amounting to DKK.399,793.77 (equivalent to UGX.225,083,893)"], [null, null, "were irregularly diverted from the activities on which they were budgeted"], [null, null, "and spent on other activities for which money had not been appropriated"], [null, null, "without seeking and obtaining the necessary approval."], [null, null, "\uf0b7 Payments made to the tune of DKK.109,193.75 (equivalent to"], [null, null, "UGX.61,221,660) lacked adequate supporting documents. Consequently,"], [null, null, "I could not confirm that the amounts paid were commensurate to the"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 208, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["Opinion Unqualified \uf0b7 There was a shortfall in NTR collections amounting to UGX.1.462Bn representing 6.8% performance. \uf0b7 I sampled 4 outputs with a total of 12 activities and actual expenditure of UGX.4.32Bn and observed that 2 outputs with a total of 8 activities and expenditure worth UGX.4Bn were fully quantified while 2 outputs with a total of 4 activities and expenditure worth UGX.0.32Bn were not quantified. The quantified outputs were partially quantified. \uf0b7 The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. \uf0b7 The Mission submitted performance reports for Q1, and Q3, after the deadline given for submission \uf0b7 The Statement of Stores and Other Assets (physical assets) as at the end of the financial year 2019/2020 revealed that additions during the year relating to non-residential buildings were disclosed as UGX.149,778,932, however, the Embassy procured items amounting to UGX.333,509,897 implying that items worth UGX.183,730,965 were not disclosed in this statement thus understating the Statement of Stores and Other Assets (physical assets). \uf0b7 The Embassy had an approved budget of UGX.196,000,000 for procurement of furniture and fixtures but a sum of UGX.333,509,897 on this item resulting into an excess expenditure of UGX.137,509,987. \uf0b7 The Embassy procured furniture and fittings for furnishing six residencies and a Chancery worth RUB.6,795,232 (equivalent to UGX.333,509,897) but were not recorded in the Embassy asset register as well as the Board of Survey report, direct procurement method was used without justification, procurements did not undergo any evaluation of bids, contracts committee was not involved during the procurement process and contract managers were not appointed for all the procurements. \uf0b7 The Assets Register maintained by the Embassy was not in the format prescribed in the Treasury Instructions as it lacked details of date of purchase, cost of purchase, maintenance cost, asset code and estimated useful life. \uf0b7 The Embassy spent RUB.1,052,189.97 and EURO.370.37 (approximately UGX.53,187,249) on refunds for medical expenses to its officers contrary to the requirements of Section M (m-a) (14) of the Public Service Standing Orders, 2010. \uf0b7 Salary advances to the tune of Euro. 4,681.18 (equivalent to UGX.19,537,232) were paid to to staff which exceeded three (3) months gross and though authorised by the Accounting Officer of the Embassy, no authority was sought from Secretary to the Treasury contrary to the Public Service Standing Orders.", "None", "None"], "type": "table"}}, {"content": "196 \nworks or supplies made by the different payees. \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 208, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Embassy had planned to refurbish the official residence and UGX.300,000,000 was released by the Ministry of Finance Planning and Economic Development (MoFPED) through a supplementary budget for the purpose. However, the refurbishment did not take place and UGX.190,000,000 was returned to the consolidated fund as required by Section 17(2) of the PFMA 2015 while UGX.110,000,000 was diverted.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Payments to the tune of DKK.171,063.61 (equivalent to UGX.95,910,234) had contradicting supporting documentation attached, payments were unbudgeted for or were incurred for activities which are not the responsibility of the Embassy.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Salary payments to locally recruited staff at the Mission to the tune of DKK.141,940.00 (equivalent to UGX.79,581,500) were made to two staff but no contract appointment letters were availed to justify them.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- Out of the budgeted NTR of UGX.1,570,000,000 for the financial year 2019/2020 only UGX.33,780,671 was collected representing performance of 2.15% of the target. The entity did not remit the collected amounts to the consolidated fund by the 31st July following the closure of the financial year contrary to the requirements of the PFMA.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the total receipts for the financial year of UGX.5.642Bn, UGX.5.152Bn was spent by the Mission resulting in an unspent balance of UGX.0.490Bn representing an absorption level of 91.3%. The unspent balance at the end of the financial year was not returned to the consolidated fund account by the 31st July 2020 contrary to the law.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the 5 outputs with a total of 9 activities and expenditure of UGX.5.152Bn, 2 outputs with a total of 2 activities and expenditure worth UGX.0.467bn were fully quantified, 2 outputs with a total of 5 activities and expenditure worth UGX.4.828Bn were insufficiently quantified while 1 output with a total of 2 activities and expenditure worth UGX.0.372Bn was not quantified at all. Of the quantified outputs, 1 output with 1 activity worth UGX.0.167bn was fully implemented while 1 output with 1 activity worth UGX.0.300bn was partially implemented.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Mission did not prepare and submit annual monitoring plans to MoFPED and NPA and also did not prepare and submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED contrary to Paragraph 58 of the Budget Execution Circular for 2019/20. In addition, performance reports for Q1, Q2, Q3 and Q4 were submitted after the deadline for submission.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that the Head of Mission and the Accounting Officer were absent from the station from March 2020 to June 2020, a period that is critical for preparation and finalisation of the Embassy financial statements. The two officers were under lock-down restrictions in Uganda due to onset of the Covid-19 pandemic. In addition the Finance Attach\u00e9 was not in office for most of the financial year. This negatively impacted on the operations of the Mission during that period.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- During the month of June 2020, a sum of DKK.152,700 (equivalent to UGX.85,970,100) was paid to Embassy staff for claims for trips that had been undertaken in January and February 2020. I observed that the payments were not adequately supported to justify that the trips were undertaken.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- An officer of the Embassy was paid Foreign Service Allowance for the months of November and December amounting to DKK.23,375.85 (equivalent to UGX.13,160,604) and education allowance amounting to", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "197", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 209, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "DKK.37,500 (equivalent to UGX.21,112,500) while on interdiction."], [null, "Payment of employment benefits to staff on interdiction may be unlawful."], [null, "\uf0b7 The Embassy continued to pay rent for the Finance Attach\u00e9\u2019s residence"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 210, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", "DKK.37,500 (equivalent to UGX.21,112,500) while on interdiction."], [null, "Payment of employment benefits to staff on interdiction may be unlawful."], [null, "\uf0b7 The Embassy continued to pay rent for the Finance Attach\u00e9\u2019s residence"], [null, "from April 2020 to September 2020 amounting to DKK.133,800.00"], [null, "(equivalent to UGX.75,329,400), a period during which the residence was"], [null, "not occupied."], [null, "\uf0b7 The Embassy procured 64 items for use at the Chancery and Embassy"], [null, "staff residences involving a sum of DKK.433,707.00 (equivalent to"], [null, "UGX.244,177,283). The procurements were undertaken without"], [null, "adherence to the procurement procedures and were not adequately"], [null, "accounted for."], [null, "\uf0b7 Contrary to the provisions in the law, expenditure amounting to"], [null, "DKK.1,181,215.74 (equivalent to UGX.665,024,462) was irregularly"], [null, "incurred by the Embassy during the month of July out of the expired"], [null, "appropriation and before the first quarter release for the financial year"], [null, "2020/2021 was received."], [null, "\uf0b7 Prepayments amounting to DKK.566,960.83 (equivalent to"], [null, "UGX.319,198,947) were made to nine (9) suppliers for services including"], [null, "fuel, insurance, water, electricity and heating. The funds were paid"], [null, "before the services were received by the Embassy."], [null, "\uf0b7 Cash amounting to DKK.37,000 (equivalent to UGX.20,831,000) was"], [null, "irregularly withdrawn from the Mission\u2019s corporate bank account by Amb."], [null, "Elly Kamahungye Kafeero to pay for accounting work done by a non-"], [null, "member of staff living outside Copenhagen. The funds were re-deposited"], [null, "on the Embassy account on 12th June 2020 by Amb. Elly Kamahungye"], [null, "Kafeero after three months because the reasons for which the funds were"], [null, "withdrawn had been suspended. I found it unusual for an amount of"], [null, "money to be set aside for an activity without confirming the total cost of"], [null, "the activity or following procurement procedures to identify a supplier."], [null, "\uf0b7 During the year 2019/2020, the Finance Committee was comprised of the"], [null, "Head of Mission (chairperson), Deputy Head of Mission, Accounting"], [null, "Officer, Finance Attach\u00e9, Head of Chancery (Third Secretary) and the"], [null, "Administrative Attach\u00e9. I observed that the Committee did not perform its"], [null, "roles of reviewing and approving the budgets and work-plans, monitoring"], [null, "implementation of the annual work-plans and procurement plans,"], [null, "monitoring implementation of internal controls over financial"], [null, "management and ensuring that there is compliance with applicable laws"], [null, "and regulations."], ["37\\. Ministry of Foreign Affairs (MOFA). 2020/21 Opinion Unqualified \uf0b7 The Ministry has an approved strategic plan for FY 2020/21- 2024/25. NPA had issued a Certificate of Compliance (CoC) to the Ministry, and Ministry Top Management had approved the plan. It is now aligned to the NDPIII. \uf0b7 The Ministry collected only 5.7% of its NTR target for the year and had a shortfall in government funding of UGX.19.886Bn which is 30.9% of the budget. The Ministry absorbed 92.3% of the funds that were released. \uf0b7 Out of the thirty-two (32) outputs sampled, ten (10) were fully quantified, seventeen (17) were insufficiently quantified and five (5) were not quantified. \uf0b7 Out of the ten (10) outputs assessed, seven (7) were fully implemented while three (3) were partially implemented. \uf0b7 The Ministry prepared and submitted the annual budget implementation plans and reports as required but failed to accurately report and submit", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 210, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "198", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 210, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["its quarterly budget performance reports in time. \uf0b7 Analysis of the Ministry\u2019s domestic arrears over the past four years showed an increase by 34.2% from 2016/17 to 2020/21. \uf0b7 The Ministry had domestic arrears worth UGX.37,436,592,723 from the prior financial year but only budgeted for UGX.6,356,885,823 (17%) in the financial year under review, thus under budgeting. \uf0b7 The approved staff establishment of Ministry of Foreign Affairs revealed that out of the approved 362 staff positions, 344 positions representing 95% were filled while 18 positions representing 5% were vacant.", null, null], ["38", "Ministry of East African Community Affairs 2020/21", "\uf0b7 I noted that the Ministry only had a draft strategic plan. NPA had not issued a Certificate of Compliance (CoC) to prompt to management of the Ministry approve the strategic plan. \uf0b7 The Ministry budgeted for NTR of UGX.699,000,000 for the financial year 2020/21, however only UGX.12,100,000 was collected representing"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 211, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "DKK.37,500 (equivalent to UGX.21,112,500) while on interdiction."], "type": "table"}}, {"content": [["its quarterly budget performance reports in time. \uf0b7 Analysis of the Ministry\u2019s domestic arrears over the past four years showed an increase by 34.2% from 2016/17 to 2020/21. \uf0b7 The Ministry had domestic arrears worth UGX.37,436,592,723 from the prior financial year but only budgeted for UGX.6,356,885,823 (17%) in the financial year under review, thus under budgeting. \uf0b7 The approved staff establishment of Ministry of Foreign Affairs revealed that out of the approved 362 staff positions, 344 positions representing 95% were filled while 18 positions representing 5% were vacant.", null, null], ["38", "Ministry of East African Community Affairs 2020/21", "\uf0b7 I noted that the Ministry only had a draft strategic plan. NPA had not issued a Certificate of Compliance (CoC) to prompt to management of the Ministry approve the strategic plan. \uf0b7 The Ministry budgeted for NTR of UGX.699,000,000 for the financial year 2020/21, however only UGX.12,100,000 was collected representing"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 Out of the fourteen (14) outputs sampled, twelve (12) were fully"], [null, null, "quantified, while two (2) were insufficiently quantified."], [null, null, "\uf0b7 Out of the twelve (12) outputs assessed, eight (8) were fully"], [null, null, "implemented while four (4) were partially implemented."], [null, null, "\uf0b7 The Ministry neither prepared annual budget monitoring plans nor"], [null, null, "submitted quarterly budget monitoring reports. The Ministry also failed to"], [null, null, "submit all its quarterly budget performance reports in time."], [null, null, "\uf0b7 Analysis of the Ministry\u2019s domestic arrears over the past four years"], [null, null, "showed a downward trend from 2017 to 2021. As at the close of the"], [null, null, "financial year a sum of UGX.13,002,369,510 was outstanding."], [null, null, "\uf0b7 Out of the approved one hundred three (103) staff positions, seventy two"], [null, null, "(72) positions representing 70% were filled while thirty one (31) positions"], [null, null, "representing 30% were vacant."], [null, null, ""], ["39 The Independent Electoral Commission. 2020/21 Opinion Unqualified \uf0b7 The Commission had not finalised the preparation of the strategic plan for the period 2021-2025. \uf0b7 The entity budgeted to collect NTR of UGX.4.483Bn during the year under review. Out of this, UGX.31.1Bn was collected, representing a performance of 694% of the target. \uf0b7 Out of the total warrants of UGX.671.61Bn received during the financial year, UGX.649.15Bn was spent by the entity resulting in an unspent balance of UGX.21.906Bn representing absorption level of 96.1%. \uf0b7 Out of the 9 outputs with a total of 40 activities and expenditure of UGX.671.61Bn assessed, 4 outputs with a total of 10 activities and expenditure worth UGX.51.838Bn was fully quantified, 3 outputs with a total of 16 activities and expenditure worth UGX.499.639Bn were insufficiently quantified while 2 outputs with a total of 14 activities and expenditure worth UGX.97.675Bn were not quantified at all. \uf0b7 Of the 4 out puts that were fully quantified with a total of ten (10) activities worth UGX.51.8Bn, 3 outputs with a total of 9 activities worth UGX.50.9Bn were fully implemented, while 1 output with 1 activity worth UGX.0.846Bn was partially implemented.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 211, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "DKK.37,500 (equivalent to UGX.21,112,500) while on interdiction."], "type": "table"}}, {"content": "199", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 211, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 An assessment to establish if there has been service delivery from a sample of outputs that were implemented revealed that purchase of motor vehicles and other transport equipment was undertaken but not fully used for the purpose while the Commission continues to pay rent after fully acquiring warehousing space. \uf0b7 I noted inconsistencies in the reported performance where all vehicles were reported as received which was not true while reported balances in the financial statements were inconsistent with those reported in the performance reports. \uf0b7 I noted that funds to the tune of UGX.4,023,217,397 were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 I noted that the Commission has been accumulating arrears in past three years and during the year 2020/2021, UGX.6.959Bn in arrears remained outstanding. \uf0b7 The Commission has in the past won cases and was awarded costs to the tune of UGX.336,880,920 but management has not collected these receivables. \uf0b7 The Commission procured Biometric Voter Verification Kit and services for the 2021 general election at a cost of UGX.82,894,881,252 and I observed that available kits were not considered while the services were not fully delivered. \uf0b7 The Commission entered into two contract agreements with a company to supply 10 double cabin pick-up vehicles at a cost of UGX.1,564,563,350 and 40 double cabin pick-up vehicles at UGX.7,013,387,920 for nomination of the Presidential candidates but by the time of audit, whereas the Commission had paid the full amount, only 32 double cabin vehicles out of the total 50 vehicles procured had been delivered leaving a balance of 18 vehicles. \uf0b7 The Commission procured for printing of ballot papers for 2021 general elections at a total cost of UGX.83.855Bn. 248 out of expected 448 pallets were delivered but the Commission had assembled vehicles to carry the entire load which rendered the vehicles redundant and this caused a loss to the Commission in form of hire fees, fuel and allowances. \uf0b7 The Commission was required to vacate their current premises by 30th June, 2021 and was subsequently compensated with UGX.22.14Bn by the Uganda National Roads Authority which was transferred to the consolidated fund as non-tax revenue. As a result of the continued delay to implement this critical activity of finding a new home, the Commission is already incurring losses on property acquired and is also likely to cause government to incur litigation costs through UNRA\u2019s failure to completely hand over the construction sites for roads to the contractor. \uf0b7 The Commission contracted two law firms for provision of legal services for Presidential petition at a cost of UGX.3,748,550,000 which had been budgeted at UGX.800Million resulting into payment of UGX.2,948,550,000 over and above the budget. Even though the planning for the elections started 3 years back, the procurement was treated as an emergency and there was no basis for the fees charged or detail of how the Commission came up with the market price for the service.", null, null], ["", "WORKS AND TRANSPORT SECTOR", ""], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 212, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "200", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 212, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", null, null], ["2", "Report on Verification SGS Automotive Uganda Limited For", "\uf0b7 I was unable to obtain all documents relating to the procurement for my review. From the available records however, it was noted that there were significant delays in the procurement process arising from administrative"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 213, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "201", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 213, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Setting Up of Vehicle", "reviews and court processes. It is also important to note that the High"], [null, "Inspection Facilities Under the Contract for Provision of Mandatory Motor Vehicle Inspection", "Court had made a ruling in favour of award of the contract to SGS. \uf0b7 There were delays in formulation of the statutory instrument covering revision of chargeable rates, negatively impacting on compliance by the vehicle owning public."], [null, "Services (MVIS). Dec 2021", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 214, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None", "None"], "type": "table"}}, {"content": [["", "Setting Up of Vehicle", "reviews and court processes. It is also important to note that the High"], [null, "Inspection Facilities Under the Contract for Provision of Mandatory Motor Vehicle Inspection", "Court had made a ruling in favour of award of the contract to SGS. \uf0b7 There were delays in formulation of the statutory instrument covering revision of chargeable rates, negatively impacting on compliance by the vehicle owning public."], [null, "Services (MVIS). Dec 2021", null], ["3 Uganda Road Fund. Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 URF did not forecast the NTR to be collected during the year. However, the Fund collected a total of UGX7,078,800 during the year. \uf0b7 Out of the total warrants of UGX. 506.507bn received during the financial year, UGX. 506.296 Bn was spent by the entity resulting in an unspent balance of UGX. 0.211Bn representing an absorption level of 99.96%. The unspent funds were swept back to the consolidated fund as required by the PFMA \uf0b7 The Authority did not implement some of its planned activities during the year. Examples include: Production of quarterly reports on the status and functionality of District Road Committees; Recruitment and substantive appointment of staff and; Review and calibration of the funds allocation formula. \uf0b7 The Fund did not collect the funds provided for under section 21 of the URF Act 2008 which mandates the Fund on recommendation by the URF Board to charge road user charges which include fuel levies, international transit fees from vehicles entering the country, road license fees, axle load fees, and bridge and road toll fees. \uf0b7 I noted that the fund allocation formula was last reviewed by the Secretariat in 2019. In addition, during the year, the formula was not reviewed to provide for current situations such as budget cuts and Covid- 19 pandemic effects which led to disproportionate transfers to designated agencies. \uf0b7 Procurements worth UGX 642,234,236 had delays ranging between 1 and 93 working days. For example; the contract for provision of Motor Vehicle maintenance services under framework contract was delayed by 93 days and the contract for supply, delivery and installation of I-pads for URF Board members was delayed by 15 days. \uf0b7 There were inadequate monitoring Designated Agencies. Out of the 203 designated agencies supposed to be monitored, only twenty-seven (27) Agencies representing 13.3% of the total designated agencies and sub", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 214, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None", "None"], "type": "table"}}, {"content": "202", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 214, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["agencies were monitored during the year. \uf0b7 Whereas URF had central stores under the charge and control of the Administrative Officer, the entity did not have a proper stores management system that is recommended in the Treasury Instructions.", null, null], ["4", "Uganda National Roads Authority. 2020/21 Opinion", "\uf0b7 A total of UGX 124,367,095,163 representing 21.58% of the spent funds for the sampled planned outputs was diverted from the budgeted projects to other projects contrary to the above provision. There was no evidence that the reallocations/diversions of such magnitude were authorized either by Parliament or the relevant funders."], [null, "Qualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 215, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None", "None"], "type": "table"}}, {"content": "203", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 215, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "agreed resettlement houses was initially scheduled to be completed by"], [null, "December 2020, no contractor had been procured for this purpose by the"], [null, "time of the audit in September 2021, implying a delay of over 9 months."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 216, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None"], "type": "table"}}, {"content": [["", "agreed resettlement houses was initially scheduled to be completed by"], [null, "December 2020, no contractor had been procured for this purpose by the"], [null, "time of the audit in September 2021, implying a delay of over 9 months."], [null, "\uf0b7 Significant delays in subdivision, demarcation and transfer of titles for"], [null, "fully acquired plots were observed on the Kampala-Jinja Expressway and"], [null, "Hoima-Wanseko Road projects."], [null, "\uf0b7 The Authority had an outstanding balance of UGX 215,059,225,419 in"], [null, "terms of payables at the year end. This figure increased by UGX"], [null, "73,885,957,262 (52.3%) from the previous year\u2019s amount of UGX"], [null, "141,173,268,157. It was observed that the bulk of this amount is"], [null, "comprised of unpaid certificates to contractors which yield interest due to"], [null, "delayed payments."], [null, "\uf0b7 Authority made payments amounting to UGX 17,078,565,465 as a result"], [null, "of penalties for the court cases and interest on delayed payments of"], [null, "advances and IPCs invoices from various projects. This is a loss to"], [null, "Government."], [null, "\uf0b7 The value of the Authority\u2019s infrastructure assets at the end of the"], [null, "financial year was disclosed as UGX10,417,198,881,566. However,"], [null, "contrary to the policy requirement to revalue the assets every three"], [null, "years, I was not availed with any valuation report for the infrastructure"], [null, "assets to confirm that the assets had ever been valued."], [null, "\uf0b7 35 road projects with a total contract value of USD.398,427,063.99 and"], [null, "UGX. 149,739,813,845 that were to be completed during the year were"], [null, "still on \u2013 going by the close of the year."], [null, "\uf0b7 Three civil cases with claims totaling to UGX6.991bn were brought"], [null, "against UNRA due to its failure to return residue land titles to the"], [null, "registered proprietors."], ["5 Uganda Civil Aviation Authority. 2020/21 Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 UCAA budgeted to collect internal revenue of UGX 293bn during the year under review. Out of this, only UGX 114.991bn was collected, representing a performance of 39.2% of the target. \uf0b7 UCAA absorbed all its revenue collected, and accrued expenditure in unpaid bills that is. its actual expenditure was more than the revenue. \uf0b7 The Authority did not implement some of its planned activities during the year. Examples include: Capital projects for Regional Airports, KOICA Counterpart funding, and procurement of a fleet management system, updating the master plan and constructing the ground surface car park. \uf0b7 There was an increase in trade and other receivables of UGX. 12,279,645,000 (equivalent to 25%) from UGX. 48,854,526,000 to UGX.61,134,171,000. The delayed collection of the receivables may lead to bad debts. \uf0b7 Management reported an increase in trade payables of UGX 21,763,762,000 (equivalent to 47.9%) from UGX 45,470,736,000 to UGX 67,234,498,000. \uf0b7 The Authority had accumulated receivables of up to UGX 96,569,511,580 in the FY 2019/20 due from Government Agencies. In the year under review, there was no follow up of this debt to the Government agencies, and no amounts were cleared. \uf0b7 The Authority made a loss for the year under review amounting to UGX 29,321,645,000. Because of the loss, the Authority did not have capacity", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 216, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None"], "type": "table"}}, {"content": "204", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 216, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["to cover any potential interest accruing on its long term loans in view of its earnings. Along with the lack of potential to cover loan interest, the Authority had a significant long term liabilities portfolio on its balance sheet, which majorly comprised of the loan from Exim Bank of China. \uf0b7 Prime Media\u2019s contract ended with a debt of UGX 1,131,017,128 which was unpaid for the year before the expiry of the contract. \uf0b7 UCAA has multiple systems operating in different departments which are tailored for the operations in the respective departments. A review of these systems revealed that some were not functional, not interfaced with other complementary system(s) and/or some of their modules were not working. Further, the IT Point of Sale System bought for tracking of revenue from concessionaire shops was out of date. \uf0b7 The Exim Bank loan terms to UCAA were renegotiated and this was to be formalized into an addendum agreement, to ensure that they are manageable. However, the addendum to the contract terms had still not been made by the time of this audit.", null, null], ["6", "Uganda National Airlines Company Ltd (UNACL). 2020/21 Opinion Qualified", "\uf0b7 UGX 8,716,398,000 was disclosed as the value of the inventories in the statement of financial position. However there was no evidence that Management carried out end of year stock taking to get actual values of inventories. In addition, there were no stores ledgers for engineering stores, and although the general stores had manual ledgers, the ledgers were not capturing Goods Received Note reference numbers (GRN)"], [null, null, "against the receipts in the ledgers as a reference of the goods received."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 217, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None", "None"], "type": "table"}}, {"content": [["to cover any potential interest accruing on its long term loans in view of its earnings. Along with the lack of potential to cover loan interest, the Authority had a significant long term liabilities portfolio on its balance sheet, which majorly comprised of the loan from Exim Bank of China. \uf0b7 Prime Media\u2019s contract ended with a debt of UGX 1,131,017,128 which was unpaid for the year before the expiry of the contract. \uf0b7 UCAA has multiple systems operating in different departments which are tailored for the operations in the respective departments. A review of these systems revealed that some were not functional, not interfaced with other complementary system(s) and/or some of their modules were not working. Further, the IT Point of Sale System bought for tracking of revenue from concessionaire shops was out of date. \uf0b7 The Exim Bank loan terms to UCAA were renegotiated and this was to be formalized into an addendum agreement, to ensure that they are manageable. However, the addendum to the contract terms had still not been made by the time of this audit.", null, null], ["6", "Uganda National Airlines Company Ltd (UNACL). 2020/21 Opinion Qualified", "\uf0b7 UGX 8,716,398,000 was disclosed as the value of the inventories in the statement of financial position. However there was no evidence that Management carried out end of year stock taking to get actual values of inventories. In addition, there were no stores ledgers for engineering stores, and although the general stores had manual ledgers, the ledgers were not capturing Goods Received Note reference numbers (GRN)"], [null, null, "against the receipts in the ledgers as a reference of the goods received."], [null, null, "\uf0b7 I noted that the entity did not have a strategic / business plan aligned to"], [null, null, "NDPIII."], [null, null, "\uf0b7 UNACL budgeted to collect internal revenue of UGX 304.6bn during the"], [null, null, "year under review. Out of this, only UGX 48.6bn was collected,"], [null, null, "representing a performance of 16% of the target."], [null, null, "\uf0b7 The Company did not implement some of its planned activities during the"], [null, null, "year. Examples include: Procurement of spare parts for the Airbus fleet;"], [null, null, "supporting 32 pilots for A330-800 neo type training, and; supporting 60"], [null, null, "pilots in simulator training."], [null, null, "\uf0b7 The company had payables totaling UGX.47,032,043,000. All the"], [null, null, "outstanding invoices were payable to UCAA. Out of the amount, payables"], [null, null, "totaling UGX 16,065,309,363 had been due for more than 6 months."], [null, null, "\uf0b7 UGX 1,127,484,315 as the value of Property Plant and Equipment In the"], [null, null, "statement of financial position and the corresponding note (Note 12) as"], [null, null, "at the close of the financial year. However, it was noted that assets were"], [null, null, "not engraved to give them an identification number for easy of"], [null, null, "identification. It was also noted that the assets could not be traced in the"], [null, null, "assets\u2019 register due to lack of identification numbers."], [null, null, "\uf0b7 I carried out financial analysis of UNACL financial performance and"], [null, null, "observed that the Company had made losses for the year 2019/2020 and"], [null, null, "2020/2021 amounting to UGX102.442bn and UGX164.573bn respectively."], [null, null, "On review of the operating margin, I observed that the costs before"], [null, null, "considering interest and taxes exceeded company revenues for the two"], [null, null, "years. I also observed that due to the losses incurred, the Company"], [null, null, "generated negative return on assets of 12.2% for the year 2019/2020"], [null, null, "and 13.1% for the year 2020/2021. The Company\u2019s revenue is still far"], [null, null, "below its assets."], [null, null, "\uf0b7 UACL implemented twenty-five (25) procurements outside the approved"], [null, null, "procurement plan for the FY 2020/2021. The procurements were made in"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 217, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["1 Ministry of Works and Transport (MoWT) Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by NPA at the end of the year under review. \uf0b7 The Ministry did not forecast the NTR to be collected during the year. However, a total of UGX6,995,230,920 was collected during the year. \uf0b7 Out of the total warrants of UGX. 1,280.322Bn received during the financial year, UGX. 1,067.967Bn was spent by the entity resulting in an unspent balance of UGX. 212.355Bn representing absorption level of 83.4% \uf0b7 The Ministry did not implement some of its planned activities during the year. Examples include: bridge inventory Data for BMS not collected; bridge management System (BMS) Software not procured, and; upgrading to Bitumen Standard Sebbowa road. \uf0b7 The Ministry had receivables worth UGX.1,570,776,843 out of which those worth UGX.623,855,947 were outstanding at the end of the previous year. There is likelihood of failure to recover the receivables that have been outstanding for over a year \uf0b7 Twenty-one (21) units of district road equipment had been lying in the workshops\u2019 yards for more than a year without repair. The equipment included: thirteen (13) motor graders of different models; four (4) bulldozers; One (1) pickup; two (2) dump trucks, and one (1) wheel loader. \uf0b7 Three (3) out of the nine (9) training aircrafts of the East African Civil Aviation Academy in Soroti were grounded due to non-repair and maintenance. The aircrafts were (registration numbers): 5X-RWE grounded due to a defective fuel injector pump; 5X-UAN grounded for mandatory structural modification and 5X -YKM grounded for a propeller overhaul. \uf0b7 I observed delayed compensation of PAPs for the development of the New Kampala Port in Bukasa. The valuation report for 2,378 PAPs with a total compensation sum of UGX 29.2 billion was approved by the Chief Government Valuer in October 2018. A total of 1,253 PAPs with a total compensation value of UGX.19.5 billion had been paid by 30th June 2021. As a result a total of 1,125 PAPs with a total compensation value of UGX.9.7 billion have remained unpaid for about three years. \uf0b7 Procurements worth UGX 1,772,908,757 which were not planned were implemented by the Ministry, while procurements worth UGX.7,465,000,000 which were planned were not implemented. \uf0b7 I observed delayed completion of Kayunga - Nabuganyi and Nansana \u2013 Kireka - Bbira roads construction project contracted at UGX 45,349,361,632. The contract provided that the works were to be completed by 01/07/2020. However, by the time of the audit in October 2021, one year and four months after planned completion date, the project works were not yet completed. \uf0b7 The acquisition of land for the Right of Way (RoW) for the SGR project has been delayed. The project plan was to acquire 5200 acres of land free of encumbrances at an estimated cost of UGX 534,600,000,000 for the construction of Kampala \u2013 Malaba SGR route by October 2016. However, only 1,295.98 (24.9%) acres of land had been acquired at a cost of UGX.95,361,767,388 (18%) as of September 2021.", "None", "None"], "type": "table"}}, {"content": "205 \ndifferent currencies amounting to (for each currency); Euro 1150,854.06, Kenya Shillings 61,879.2, USD 65,441.36, Tanzania Shillings 7,752,600 and UGX 346,738,939. \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 217, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A purchase Order was made for the supply of inflight equipment at a price of USD 25,694.46 (VAT Exclusive) without the approval of the Contracts Committee.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Two companies submitted bids for specialized motorized equipment used in ground handling of aircraft. The companies failed the preliminary stage (compliance), however, the Evaluation Committee did not cancel the evaluation process. The contract manager was not appointed and the delivery was not witnessed.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- USD 8,620.7 vide payment voucher No PV07/21/072 was paid to DAS Air as rent for the month of April 2021. Further to the above a review of invoices revealed that DAS Air had billed Uganda Airlines a total of USD 43,103.5 for unpaid ground rent. However, Uganda Airlines had not made any tenancy agreement with the DAS air, and there was no handover report from Uganda Airlines to DAS Air.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UGX 103,532,800 (USD 28,000) was paid to the supplier vide payment voucher No. PV09/20/025 dated 4/9/2020. The vehicle was purchased through direct procurement without proper justification.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Uganda National Airlines Limited made a contract agreement with M/s Ninesun Manufacturing Limited for supply of inflight service equipment for airbus at a contract amount of USD 319,226.86. The items were said to have been delivered to DAS Air. I was not provided with evidence that the items were actually delivered, witnessed for quality and quantity and handed over to DAS Air stores.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- UNACL concluded the procurement of a contractor for the provision of an Enterprise Resource Planning (ERP) software solution at a contract sum of USD 1,066,910 (VAT Exclusive) as well as the provision of an integrated Passenger Service System at a contract sum of USD 1,234,441 (VAT Exclusive). The procurements were conducted and finalized without seeking the necessary approvals from NITA-U.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The company issued a purchase order on 27/01/2021 to M/s Stelia Aerospace for Supply of critical spare parts for business class seats for A330-800 NEO at a price of USD 146,230.72. I was however not provided with the contract for the supply.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- From the 20 procurements sampled, I noted that neither was there Accounting Officer\u2019s appointments of contract managers nor were there contract management files. The procurements were made in different currencies amounting to (for each currency); Euro 212,050.67, Kenya Shillings 12,253,905.74, USD 109,803,962.54 and UGX 347,242,879.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Company did not have a Board approved staff structure and establishment to assess staff recruitment needs and staffing status, and did not have approved staff salary grades. This affected proper planning and budgeting for staff costs. As a consequence, the Company incurred excess expenditure of UGX 4,919,238,464 (USD 1,333,008) on salaries and staff expenses.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- There has been delayed conclusion of suspension cases. On 21st of April 2021, some HoDs were suspended for a period of 3 months (effective 29th April, 2021) to enable the appointed committee to investigate and report on stated allegations. Review of the staff files revealed that there were no committee resolutions on the cases and as a result Management extended the suspension on 20th August 2021 for another 3 months.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n206", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 218, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Since the affected staff remained on the same terms of contract, the"], [null, "officers appointed to act in their positions receive extra pay implying"], [null, "double payment for the same position. As a consequence, the company"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 219, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", "Since the affected staff remained on the same terms of contract, the"], [null, "officers appointed to act in their positions receive extra pay implying"], [null, "double payment for the same position. As a consequence, the company"], [null, "has lost a total of UGX 2,319,017,267 in a seven months\u2019 period (May to"], [null, "November 2021)."], ["7 Uganda Railways Corporation. 2020/21 Opinion Qualified \uf0b7 The Corporation had Non-current assets worth UGX.3,525,540,249,000 as at 30th June 2021. However, this figure included a total of UGX.6,012,000,000 in respect of Kabalega ferry (UGX.5,760,000,000) and Barbus ferry (UGX.252,000,000) which sunk under water twenty five years and sixteen years respectively. Since the ferries have been out of use under water for a long time without retrieval and cannot be disposed of while under water, it cannot be determined whether they still hold the value indicated to the Corporation. \uf0b7 The Corporation had GoU equipment loans amounting to UGX.22,067,482,000 at the beginning and end of the year under review. Out of this loan amount, loans totalling UGX.16,511,595,000 (other than the Spanish Government loan) were not supported and did not show any movement over the last four (4) years. \uf0b7 Interest arising from loans that was yet to be cleared by URC amounted to UGX.9,511,880,000. However, this balance has been outstanding over several years without any movement. The status quo still remained the same by the close of the year under review. This interest payable was not supported by any original documentation. \uf0b7 Trade and Other Payables increased from UGX.17,937,602,000 at the beginning of the year to UGX.21,513,931,000 at the close of the year. Out of the amount, trade and other payables worth UGX.9,753,781,407 lacked supporting documents such as LPOs, contracts, inward invoices, claims and demand notes. \uf0b7 The Corporation had Trade and Other Receivables of UGX.75,637,890,000 as at 30th June 2021. The figure includes UGX.69,516,000,000 due from Government in respect of the Nsambya land. This amount has remained un-paid to URC for too long despite Government having disposed of the land to the public long ago implying that the Corporation may never be compensated for its land. \uf0b7 URC budgeted to collect internal revenue of UGX 120.49 during the year under review. Out of this, only UGX 54.6bn was collected, representing a performance of 45.3% of the target. \uf0b7 The Corporation did not implement some of its planned activities during the year. Examples include: Sleeper reconditioning; Kampala Station not fencing; Tororo Station Roof Repairs and; Rehabilitation of Steel Mill Jinja siding. \uf0b7 The Corporation made losses for the past two years; UGX 37,783,152,000 (2020/2021) and UGX 66,151,318,000 (2019/2020). The Corporation\u2019s losses and the ratios computed are an indication that Uganda Railways Corporation is not performing well in terms of profitability and ability to sustain provision of services without further Government intervention for funding and Management strategies to improve revenue generation. \uf0b7 Management did not assess impairment of assets despite existence of impairment indicators. For instance, rental properties were being charged below market value. \uf0b7 Uganda Railways Corporation land worth UGX.91,832,636,500 lacked land titles as evidence of URC\u2019s rights to own and use the property. Management\u2019s efforts to secure the land titles appear remote. Lack of", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 219, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "207", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 219, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["land titles has led to heavy encroachment and grabbing of the Corporation\u2019s land. \uf0b7 URC procured four (4) used locomotives at UGX.41,323,768,935. I noted that the bidder did not comply with some requirements within the bid document which were supposed to be the basis of evaluation. Despite the non-compliance at the preliminary stage, the bid was evaluated at the Technical stage without following procurement regulations. \uf0b7 Government signed an agreement with Mango Tree (U) Ltd for the rehabilitation and upgrade of the Pamba ferry. However, the vessel was still grounded after a year of signing the agreement. \uf0b7 An officer of URC irregularly signed to transfer land measuring 4.452 hectares in Lira (under FRV 220 Folio 13). The land was subdivided into plots 41-63, 52-62, 42-50 and the titles were being processed. \uf0b7 Jinja Municipal took part of URC land in Jinja (6.3 acres) and gave it out to 58 developers, without consultation with the Corporation.", null, null], ["8", "Busega-Mpigi Road Project (Uganda National Roads Authority) 2020 Opinion Unqualified", "\uf0b7 I observed slow progress in Construction works and accumulation of loan charges. As of June 30th 2020, the contractor had only achieved physical progress of 0.13% against 12.77% planned cumulative progress. The total time lapse since commencement of the construction works was 7 months constituting 24.26% of the total contract duration yet only 0.13% construction work had been achieved. Slow progress in Construction works has led to continued accumulation of both Commitment and"], [null, null, "Service Charges that amounted to UGX 2,921,803,802 and UGX"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 220, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": [["land titles has led to heavy encroachment and grabbing of the Corporation\u2019s land. \uf0b7 URC procured four (4) used locomotives at UGX.41,323,768,935. I noted that the bidder did not comply with some requirements within the bid document which were supposed to be the basis of evaluation. Despite the non-compliance at the preliminary stage, the bid was evaluated at the Technical stage without following procurement regulations. \uf0b7 Government signed an agreement with Mango Tree (U) Ltd for the rehabilitation and upgrade of the Pamba ferry. However, the vessel was still grounded after a year of signing the agreement. \uf0b7 An officer of URC irregularly signed to transfer land measuring 4.452 hectares in Lira (under FRV 220 Folio 13). The land was subdivided into plots 41-63, 52-62, 42-50 and the titles were being processed. \uf0b7 Jinja Municipal took part of URC land in Jinja (6.3 acres) and gave it out to 58 developers, without consultation with the Corporation.", null, null], ["8", "Busega-Mpigi Road Project (Uganda National Roads Authority) 2020 Opinion Unqualified", "\uf0b7 I observed slow progress in Construction works and accumulation of loan charges. As of June 30th 2020, the contractor had only achieved physical progress of 0.13% against 12.77% planned cumulative progress. The total time lapse since commencement of the construction works was 7 months constituting 24.26% of the total contract duration yet only 0.13% construction work had been achieved. Slow progress in Construction works has led to continued accumulation of both Commitment and"], [null, null, "Service Charges that amounted to UGX 2,921,803,802 and UGX"], [null, null, "5,802,593,707 respectively as at the reporting date."], [null, null, "\uf0b7 UNRA reallocated GOU counterpart funding to other projects for the year"], [null, null, "ended 30th June, 2020. A total of UGX 320,077,550 was reallocated from"], [null, null, "the project to other projects. The reallocations delay project progress."], ["9 Busega-Mpigi Road Project (Uganda National Roads Authority). 2021 Opinion Unqualified \uf0b7 I observed slow progress in Construction works and accumulation of loan charges. As of June 30th 2021, the contractor had only achieved 3.42% against 29.18% planned cumulative progress. The total time lapse since commencement of the construction works was 19 months constituting 64.01% of the total contract duration yet only 3.42% construction work had been achieved. Slow progress in Construction works has led to continued accumulation of both Commitment and Service Charges that amounted to UGX 3,224,867,623 and UGX 7,140,345,245 respectively as at the reporting date. \uf0b7 I observed failure to procure Prefabricated Pipe Culvert Units to the project which is delaying project progress. The contractor could not progress through pipe culvert installation due to lack the culverts. \uf0b7 There were delays in payments to the contractor that are likely to lead to interest charges. I observed that on 2nd June 2021, the contractor issued IPC No. 3 amounting to UGX 8,303,000,336 which was unpaid by 30th June, 2021 and interest on the late payment was due to commence on 28th July 2021. \uf0b7 I observed delayed possession of site and land take over by the contractor. By 30th June, 2021, land acquisition was at 54.8% or 14.605 km of the main expressway where access to and possession was granted. It is to be noted that 100% access to and possession should have been formally handed over after 18 months (that is; 22nd May 2021) from commencement. \uf0b7 UNRA reallocated GOU counterpart funding to other projects for the year ended 30th June, 2020. A total of UGX 1,956,237,995 was reallocated", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 220, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": "208", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 220, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["from the project to other projects. The reallocations delay project progress.", null, null], ["10", "Kapchorwa-Suam Road Project (Uganda National Roads Authority) 2021 Opinion Unqualified", "\uf0b7 I observed delayed access and possession of site by the contractor. The last section of the road (from km 48+000 to km 073+000) was granted to the contractor on the 14th of June 2021 which is after 888 days. Further, additional land acquisition is still under progress from Km33+000 to Km73+000. Civil works from Km 46 to Km 58 have been put on hold pending additional land take especially for slope protection. It was also noted that new structures were being erected in the road reserve at"], [null, null, "Km17+692 and KM5+430."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 221, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": [["from the project to other projects. The reallocations delay project progress.", null, null], ["10", "Kapchorwa-Suam Road Project (Uganda National Roads Authority) 2021 Opinion Unqualified", "\uf0b7 I observed delayed access and possession of site by the contractor. The last section of the road (from km 48+000 to km 073+000) was granted to the contractor on the 14th of June 2021 which is after 888 days. Further, additional land acquisition is still under progress from Km33+000 to Km73+000. Civil works from Km 46 to Km 58 have been put on hold pending additional land take especially for slope protection. It was also noted that new structures were being erected in the road reserve at"], [null, null, "Km17+692 and KM5+430."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 221, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": [["from the project to other projects. The reallocations delay project progress.", null, null], ["10", "Kapchorwa-Suam Road Project (Uganda National Roads Authority) 2021 Opinion Unqualified", "\uf0b7 I observed delayed access and possession of site by the contractor. The last section of the road (from km 48+000 to km 073+000) was granted to the contractor on the 14th of June 2021 which is after 888 days. Further, additional land acquisition is still under progress from Km33+000 to Km73+000. Civil works from Km 46 to Km 58 have been put on hold pending additional land take especially for slope protection. It was also noted that new structures were being erected in the road reserve at"], [null, null, "Km17+692 and KM5+430."], [null, null, "\uf0b7 I observed delays in execution of Project civil works. UNRA engaged M/S"], [null, null, "China State Construction Engineering Corporation Ltd on the 7th May"], [null, null, "2018 to upgrade Kapchorwa-Suam road for a period of 36 months, with"], [null, null, "effect from 1st October 2018. There was an extension of time of 4.5"], [null, null, "months up to 15th February 2022. Based on the extension of time, the"], [null, null, "time lapse as at 30th June 2021 was 33 months that is 81.40 %."], [null, null, "However the reported cumulative physical progress for civil works was"], [null, null, "43.14% with no active works from Km 55 to km 73."], ["11 Road Sector Support Project 4 \u2013 Kigumba-Masindi- Hoima-Kabwoya Road (2021) (Uganda National Roads Authority). 2021 Opinion Unqualified \uf0b7 I observed delayed completion of civil works on Upgrading of Bulima \u2013 Kabwoya Road (Lot2).The project commencement date was 1st December 2015, and the initial completion date was after 30 months on 31st May 2018. Successive revisions of completion dates extended the construction period by a further 22 months with the last revised completion date being 27th March 2021. A certificate of substantial completion was issued in January 2021, and the contractor allowed 12 months as the Defects Liability Period, expiring on 27th January 2022. The snag list included two main items; the construction of Hoima Town Roads and a way bridge. \uf0b7 I observed delayed completion of civil works on Upgrading of Kigumba \u2013 Bulima Road (Lot1). The construction period was for 30 months (after commencement in March 2018), elapsing on 31st August 2020. When the Audit Team visited the site in September 2021, (42 months after commencement), the attained level of completion was approximately 95%. However, the new proposed completion date of 31st August had passed and no new completion date had been communicated. \uf0b7 There were delays in payment of lot1 supervision fees. By the time of my audit, the Lot 1 Supervising Engineer\u2019s unpaid invoices had accumulated to Euros 661,605 for the foreign component of the contract and UGX 1.38bn for the local component. The delays are likely to impact on the Engineer\u2019s ability to perform the contractual obligations and in turn impact on the progress of the construction works.", null, null], ["12", "Albertine Regional Sustainable Development Project (ARSDP) (Uganda National Roads Authority). 2021 Opinion Unqualified", "\uf0b7 I observed delayed implementation of civil works (Upgrading of Kyenjojo- Kabwoya Raod \u2013 100km). The duration of the contract was 36 months (from 5th April 2016 to 4tth April 2019) excluding the Defects Liability Period. There were two extensions of time; the first one for 818 days i.e from 4th April 2019 up to 30th June 2021 and the second one for four months from 1st July 2021 to 31st October 2021. The right of way for the last section, Km 0 to Km 30 was handed over to the contractor on the 14th September 2018. However, as per the monthly report No. 63 for the"], [null, null, "month of June 2021, the progress of works was reported as 94.83%"], [null, null, "against planned of 96.27%. In addition to this, the contractor was"], [null, null, "supposed to substantially complete and hand over 30% of works within"], [null, null, "180 days of the commencement date. However, as at 30th June 2021"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 221, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": "209", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 221, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "(1,912 days) no section of the road was handed over and UNRA."], [null, "\uf0b7 There were significant defects on the road works. I observed failure of"], [null, "road shoulders, lined drain and a speed hump at KM88+678. It was also"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 222, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": [["", "(1,912 days) no section of the road was handed over and UNRA."], [null, "\uf0b7 There were significant defects on the road works. I observed failure of"], [null, "road shoulders, lined drain and a speed hump at KM88+678. It was also"], [null, "observed that the contractor continued to construct line drains on steep"], [null, "slopes without scour checks."], [null, "\uf0b7 I also observed poor quality works on some sections of the road"], [null, "construction. For example: poor visibility on the right-hand side of river"], [null, "Nguse bridge and also inadequate protection between the end of stone"], [null, "pitching and the stream at the bridge; noticeable bleeding at Km 52+511,"], [null, "failed line drain at Km71+200 RHS and damaged guard rail at km72+921"], [null, "RHS; maintenance of the completed sections was poor with overgrown"], [null, "grass and silted drainages especially from Km 51 to Km 100, and;"], [null, "pedestrian walkways were not provided for in the design of Kagadi town"], [null, "roads which were under construction at time of the audit."], [null, "\uf0b7 I noted lack of adherence to the insurance contract. The ICEA Workman\u2019s"], [null, "Compensation Policy No 110-A2506044-18 covering the period 18th"], [null, "January 2021 to 17th February 2022 indicated that the number of staff"], [null, "insured are 181 only with neither the names nor the number of staff"], [null, "under each category/designation indicated but the monthly progress"], [null, "reports, the PAYE and NSSF returns for the period under review indicated"], [null, "that the contractor has over 400 staff. Further, the contract required that"], [null, "the insurances are in the joint names of the parties that is; UNRA and the"], [null, "contractor. However, the UAP Old Mutual contractor\u2019s All Risk Policy No"], [null, "0000461578 and the ICEA Motor Commercial Policy No. 080-A2-105193-"], [null, "17 indicate that the insured was only the contractor."], [null, "\uf0b7 Work Permits for all the foreign consultant\u2019s and contractor\u2019s staff were"], [null, "not provided for review. In the absence of the work permits for the"], [null, "foreign staff, the implication is that the expatriate staff are working"], [null, "irregularly in Uganda irregularly and this may lead to deportation, which"], [null, "will in turn affect the progress of work."], ["13 Road Sector Support Project 5 (Upgrading of Rukungiri- Kihihi-Ishasha/Kanungu and Bumbobi-Lwakhakha Roads (Uganda National Roads Authority). 2020. Opinion Unqualified \uf0b7 I observed significant delays in Project implementation. During the FY 2019/20, Project disbursements from ADF amounted to UA 6,679,508.53. From the signed loan amount of UA 70,000,000, only UA 24,672,103.72 representing 35% of the signed loan amount had been cumulatively disbursed through direct payments for Project expenditures as at 30th June 2020. However, 91% of the original project implementation time had elapsed as at 30th June 2020. Civil works for the upgrade of Bumbobi-Lwakhakha 44.5km road had attained 84% physical progress as at 30th June 2020 versus time progress and planned physical progress of 91%. The financial progress stood at 83% against plan of 92% as at 30th June 2020. For the upgrade of Rukungiri-Kihihi-Ishasha/Kanungu (78.5km), 19.24% cumulative physical progress had been achieved as at 30th June 2020 although 33.4% was planned to be completed. \uf0b7 During the FY 2019/20, UGX 3,033,479,790 (28%) of GOU counterpart project funds were re-allocated to other Projects. Re-allocation of Project funds to other projects invalidates the approved plan for implementation of RSSP-V activities. \uf0b7 UGX 267,083,716 was paid as interest on delayed payments. Such costs are un-necessary and represent unbudgeted expenditures which affect funds ear-marked for implementation of planned Project activities. \uf0b7 UGX 226,500,820 had been paid to Government agencies (votes) including sub-counties and town councils during the FY 2019/20. These payments constitute revenue received for purpose of Government and", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 222, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": "210", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 222, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["should have been paid directly to the Uganda Consolidated Fund. \uf0b7 Financing charges were accumulating due to low utilization of the loan funds. Total charges of UGX 3,912,848,969 accrued on the disbursed and undisbursed loan balances during the FY 2019/2020. This is comprised of UGX 3,079,241,588 (79%) being charges on the undisbursed loan balances during the year and UGX 833,607,381 (21%) being charges on the disbursed loan amounts.", null, null], ["14", "Road Sector Support Project 5 (Upgrading of Rukungiri- Kihihi-Ishasha/Kanungu and Bumbobi-Lwakhakha Roads (Uganda National Roads Authority). 2021 Opinion Unqualified", "\uf0b7 I observed significant delays in Project implementation. During the FY 2020/21, Project disbursements from ADF amounted to UA 10,235,407.97 resulting into cumulative disbursements of UA 34,907,511.69 (representing 49.9% of the signed amount of UA 70,000,000). Whereas the upgrading of Bumbobi-Lwakhakha (Lot2) 44.5km road had been substantially completed and the road was handed over to UNRA by the Contractor on 21st December 2020, the upgrading of Rukungiri-Kihihi- Ishasha/Kanungu (Lot1) 78.5km stretch had attained cumulative physical progress of only 42.6% completion rate against planned progress of 55.1% as at 30th June 2021. As at 30th June 2021, only 18 months"], [null, null, "(19.6%) time were left to the end of the extended Project"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 223, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": [["should have been paid directly to the Uganda Consolidated Fund. \uf0b7 Financing charges were accumulating due to low utilization of the loan funds. Total charges of UGX 3,912,848,969 accrued on the disbursed and undisbursed loan balances during the FY 2019/2020. This is comprised of UGX 3,079,241,588 (79%) being charges on the undisbursed loan balances during the year and UGX 833,607,381 (21%) being charges on the disbursed loan amounts.", null, null], ["14", "Road Sector Support Project 5 (Upgrading of Rukungiri- Kihihi-Ishasha/Kanungu and Bumbobi-Lwakhakha Roads (Uganda National Roads Authority). 2021 Opinion Unqualified", "\uf0b7 I observed significant delays in Project implementation. During the FY 2020/21, Project disbursements from ADF amounted to UA 10,235,407.97 resulting into cumulative disbursements of UA 34,907,511.69 (representing 49.9% of the signed amount of UA 70,000,000). Whereas the upgrading of Bumbobi-Lwakhakha (Lot2) 44.5km road had been substantially completed and the road was handed over to UNRA by the Contractor on 21st December 2020, the upgrading of Rukungiri-Kihihi- Ishasha/Kanungu (Lot1) 78.5km stretch had attained cumulative physical progress of only 42.6% completion rate against planned progress of 55.1% as at 30th June 2021. As at 30th June 2021, only 18 months"], [null, null, "(19.6%) time were left to the end of the extended Project"], [null, null, "implementation time of 31st December 2022. It is unlikely that UNRA will"], [null, null, "complete the 57.4% works outstanding (planned) for the upgrade of"], [null, null, "Rukungiri-Kihihi-Ishasha/Kanungu road in the agreed timelines."], [null, null, "\uf0b7 During the FY 2019/20, UGX 3,822,002,388 (36%) of GOU counterpart"], [null, null, "project funds were re-allocated to other Projects. Re-allocation of Project"], [null, null, "funds to other projects invalidates the approved plan for implementation"], [null, null, "of RSSP-V activities."], [null, null, "\uf0b7 UGX 150,255,638 was paid as interest on delayed payments. Such costs"], [null, null, "are un-necessary and represent unbudgeted expenditures which affect"], [null, null, "funds ear-marked for implementation of planned Project activities."], [null, null, "\uf0b7 Financing charges were accumulating due to low utilization of the loan"], [null, null, "funds. UGX 3,770,851,261 was accrued on the disbursed and undisbursed"], [null, null, "loan balances with ADF during the FY 2020/2021. This is comprised of"], [null, null, "UGX 2,620,478,974 (69%) being charges on the undisbursed loan"], [null, null, "balances during the year and UGX 1,150,372,287 (31%) being charges"], [null, null, "on the disbursed loan amounts. For the last two financial years (FY"], [null, null, "2019/20 and 2020/21), total charges of UGX 7,683,700,230 had accrued"], [null, null, "on the loan balances with ADF. This is comprised of UGX 5,699,720,562"], [null, null, "(74%) being charges on the undisbursed loan balances and UGX"], [null, null, "1,983,979,668 (26%) being charges on the disbursed loan balances."], ["15 Upgrading of Tirinyi-Pallisa- Kumi and Pallisa-Kamonkoli Road project (Uganda National Roads Authority). 2020 \uf0b7 The Authority was made to pay interest as a result of delay to pay the contractor\u2019s approved interim payment certificates (IPCs). The contractor invoked clause 14.7 and 14.8 of GCC and charged interest of UGX 373,044,074.47 for IPCs 1-6. Another interest amount of UGX 166,845,192 was paid for IPCs 11,12,13,14. The total interest paid for the delayed settlement of the IPCs amounted to UGX 539,889,266. These interest payments could have been higher if the dollar amounts had not been negotiated downwards by USD 108,262.29 due to disagreements in computations. \uf0b7 During the FY 2019/20, UGX 892,920,000 of Project funds were re- allocated to other Projects. Re-allocation of Project funds to other projects overrides established budgeting procedures. \uf0b7 There were delays in recruitment of the Project consultant. In the period 15th March 2018 to 26th April 2021, there was no Project consultant procured to carry out supervisory roles for upgrading the Tirinyi-Kumi-", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 223, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "Since the affected staff remained on the same terms of contract, the"], "type": "table"}}, {"content": "211", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 223, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Pallisa-Kamonkoli Road Project. In this period, the Directorate of Roads and Bridges Development of UNRA stepped in to carry out design review and supervisory roles in addition to their other activities. Recruitment of the Consultant, AECO (Abuljebain Engineering Consulting Office) delayed until 15th March 2021 and they commenced work on 26th April 2021 four months when the project physical progress was already at 92.51% and in time progress was 37.3 months (103.6%) to completion. The Consultant\u2019s first report was in the month of May 2021. \uf0b7 I observed delays in payment of Project Affected Persons. As of 30th June 2021 payment of PAPs was still incomplete with a total of 156 PAPs not yet paid. Tirinyi Pallisa Kumi (Lot 1) had 100 PAPs for land measuring 80.06 acres while Pallisa Kamonkoli road (Lot 2) had 56 PAPs not paid for 27.318 acres of land (by May 2021)", null, null], ["16", "Upgrading of Tirinyi-Pallisa- Kumi and Pallisa-Kamonkoli Road project (Uganda National Roads Authority).", "\uf0b7 There were overpayments to the contractor in interim payment certificates numbers 25 and 26 amounting to UGX 8,613,048,720 (USD 2,556,164.89). These payments were meant for supervisors who had not been recruited."], [null, "2021", null], ["17 North Eastern Road- Corridor Asset Management Project (Uganda National Roads Authority) 2020/21 \uf0b7 The Project did not have an annual work plan and budget prepared for implementation of its activities. Also, quantification of Project outputs was not done for the financial year audited. \uf0b7 I observed delays in Project implementation. From the signed loan", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 224, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "212", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 224, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", null, null], ["18", "Masaka-Bukakata Road project (2021) (Uganda National Roads Authority)", "\uf0b7 Project funds to the tune of UGX 262,339,751 were reallocated from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals."], [null, "2020/21", null], ["LANDS SECTOR", null, null], ["1", "National Physical Planning Board 2020/21", "\uf0b7 Out of the budgeted revenue of UGX.6.0 Bn, UGX.5.29 Bn was realised, resulting in a shortfall of UGX 0.710 Bn, which is 12% of the budget, Out of the total receipts for the financial year of UGX 5.29, Bn, UGX 2.945 Bn was spent representing an absorption level of 56%."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 225, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "213", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 225, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "were not quantified at all."], [null, null, "\uf0b7 One (01) output with one (01) activity and expenditure worth UGX 0.452"], [null, null, "Bn was fully implemented., two (2) outputs with two (02) activities worth"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 226, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "were not quantified at all."], [null, null, "\uf0b7 One (01) output with one (01) activity and expenditure worth UGX 0.452"], [null, null, "Bn was fully implemented., two (2) outputs with two (02) activities worth"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 226, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "were not quantified at all."], [null, null, "\uf0b7 One (01) output with one (01) activity and expenditure worth UGX 0.452"], [null, null, "Bn was fully implemented., two (2) outputs with two (02) activities worth"], [null, null, "UGX.0.308 Bn were not implemented."], [null, null, "\uf0b7 I noted that out of the approved staff structure of thirty five (35)"], [null, null, "positions, no position was substantively filled. The Board had only three"], [null, null, "(3) staff on secondment and twenty six (26) on assignment of duties."], [null, null, "\uf0b7"], ["2 Ministry of Lands, Housing and Urban Development 2020/21 Opinion Unqualified \uf0b7 Out of the budgeted NTR of UGX.5.500Bn for the financial year 2019/2020 only UGX.5.480Bn was realized, representing a performance of 99.6 % above the target. \uf0b7 The Ministry budgeted for UGX.74.32Bn in Government receipts, out of which UGX.71.13Bn was warranted, resulting in a shortfall of UGX.3.19Bn which is 4.29% of the budget. \uf0b7 Out of the total receipts of UGX.71.12Bn, UGX.69.13Bn was spent resulting into an unspent balance of UGX.1.99Bn representing an absorption level of 97.2%. The balance unspent was subsequently swept back to the consolidated fund at the end of the financial year. \uf0b7 I sampled 34 outputs with a total of 175 activities and expenditure of UGX 57.908Bn and noted that 15 outputs with a total of 67 activities and expenditure of UGX.12.45Bn were fully quantified. Fifteen (15) outputs with a total of 92 activities and expenditure worth UGX.42.35Bn were insufficiently quantified. Four (4) outputs with a total of 16 activities and expenditure worth UGX.3.11Bn were not quantified. \uf0b7 I assessed the implementation of 15 fully quantified outputs with a sample of 67 activities worth UGX.12.45Bn and noted that three (3) outputs with a total of three (3) activities worth UGX.0.456 Bn were fully implemented. Twelve (12) outputs with a total of sixty-four (64) activities worth UGX.11.99Bn were partially implemented. \uf0b7 I noted that the Ministry\u2019s Payables amount increased by UGX.105,145,022,390 from UGX.144,329,975,873 in the previous year to UGX.249,474,998,263 in the current year. In addition, UGX.11,593,918,200 of the new compensations related to private persons that had been included among the ranchers to be compensated, but lacked ranch title number, area of land lost and other details recorded in the domestic arrears schedule. \uf0b7 I noted a recognized NTR amount of UGX.1.7billion relating to proceeds from the sale of government pool housed had no proper documentation. \uf0b7 I noted that Parliament approved a payment of UGX.3,802,500,000, as compensation for Ndeeba Land but the payment was halted by an interim court order. \uf0b7 I noted that the Ministry compensated the claimant of land at Block 237 plots 29,48,56,59 and 67 at Mutungo for a sum of UGX.26.4 Bn which had earlier been purchased by Uganda Land Commission which partly paid UGX 2.4Bn. The two entities have not agreed on the ownership of the land.", null, null], ["3", "Uganda Support to Municipal Infrastructure Development, Additional Financing (USMID-AF/II)", "\uf0b7 To-date, the program has made available USD 140,331,745 (UGX.514,740,787,823), out of which only USD.44,938,686 (UGX.477,249,316,165) had been made available to the LGs, leading to a"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 226, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "214", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 226, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Project. 2020/21", "funds availability to LG level of 32%. \uf0b7 Out of the budgeted disbursements/receipts of UGX.454,866,200,300 in the financial year, only UGX.301,529,104,089 (66.3%) was available to the project, leading to a shortfall of UGX. 153,337,096,211(33.7%)."], [null, "Opinion Unqualified", null], ["4 Albertine Region Sustainable Development Project (ARSDP) \u2013 MoLHUD 2020/21 Opinion Unqualified \uf0b7 Out of the budgeted IDA disbursement of UGX.19,514,012,776 for the year 2020/2021, only UGX.10,094,659,078 (52%) was realized leading to a shortfall of UGX.9,419,353,698 (48%). Revenue shortfall limits the implementation of planned activities which could affect the achievement of the project objectives. \uf0b7 Review of the Q4 Progress report revealed that many sub-projects worth USD 27.5million handed over to the Ministry of Lands, Housing and Urban Development for construction, will not be implemented due to lack of funding, yet, costs have already been incurred since all the sub- projects have been designed and Environment and Social Impact Assessment done. \uf0b7 The civil works for construction of three markets, namely: Biiso Market in Buliisa District, Kabaale Market in Hoima District and Buhuka Market in Kikuube District costed at UGX.9,963,228,048 were not complete despite the extension of the completion date to 31st August 2021, thus delaying service delivery to citizens.", null, null], ["5", "Competitiveness and Enterprise Development Project (CEDP) Component", "\uf0b7 It was noted that out of the UGX.12.73Bn budget allocated for the project activities during the fiscal year 2020/2021, UGX.11.86 Bn (93%) was spent, leaving a balance of UGX.0.87Bn."], [null, "1- Land Administration (IDA CREDIT AGREEMENT CR 52690-UG) PROJECT ID P130471. 2020/21 Opinion", null], [null, "Unqualified", null], [null, "", null], ["6 Uganda Land Commission. 2020/21 Opinion Qualified \uf0b7 Out of the approved budget of UGX. 71,868,574,709, only UGX. 65,793,286,529was warranted/released resulting into a budget shortfall of UGX.6,075,288,180 representing 91.5%. \uf0b7 Out of the total warrants of UGX.65.79Bn received during the financial year. UGX.64.94Bn was spent by the entity resulting in an unspent balance of UGX.0.85Bn representing an absorption level of 98.71%. \uf0b7 Out of the twenty-one (21) outputs with a total of sixty-one (61) activities and expenditure of UGX.64.86Bn sampled, Two (2) outputs with a total of Six (6) activities and expenditure worth UGX.0.71Bn were fully quantified, Eight (8) outputs with a total of thirty (30) activities and expenditure worth UGX.32.35Bn, was insufficiently quantified. Eleven (11) outputs with a total of twenty-five (25) activities and expenditure worth UGX", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 227, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "215", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 227, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["31.8Bn were not quantified at all. \uf0b7 Out of the two (2) fully quantified outputs, Two (2) outputs with six (6) activities worth UGX.0.71Bn were partially implemented. Out of the six (6) activities, the entity fully implemented one (1) activity; Four (4) activities were partially implemented, while one (1) activity remained unimplemented. \uf0b7 The balances for; payables of UGX 169,490,014,824 , Non-produced assets of UGX 212,279,181,177, and that of revenue receivables of UGX 24,760,000 as at 30th June, 2021, Could not be confirmed due to absence of adequate supporting documentation and reliable data by the commission. \uf0b7 A sum of UGX.1,237,717,474 was paid for outstanding arrears that related to the prior year, but were not recognized in the prior year financial statements as payables. In addition, withholding tax of UGX.22,020,000 was not deducted and paid to URA. \uf0b7 I noted that the court garnished the Commission\u2019s bank Account with a balance of UGX.244,184,480 leading to the delay to clear the outstanding obligations to third parties. \uf0b7 It was noted that the entity obtained a supplementary of UGX 10.62Bn was received by the entity but was not requisitioned by management. There were unsupported payments of domestic arrears amounting to UGX 14.4 Bn. Payments worth UGX 6.7Bn were paid to unverified arrears. \uf0b7 In addition, payables to Church of Uganda amounting to UGX 15Bn, and Receivables amounting to UGX 3.966 Bn relating to the overpayment to Kampala archdiocese in the prior year were not recognised. In addition, outstanding arrears of UGX 1.2Bn related to prior year but paid during the year have not been recognised in the current year. \uf0b7 The Commission does not have a land inventory and database for all government land and properties under its jurisdiction that are either occupied by tenants, vacant, acquired under compensation (but not yet re-distributed to the bona fide occupants), or acquired and owned by other government institutions and missions abroad. As such tracking of lease payments and revenue arrears related to ground rent and premium could not be supported.", null, null], ["", "ACCOUNTABILITY SECTOR", "\uf0b7"], ["1\\. Uganda Communication Employees Contributory Pension Scheme. 2019/20 Opinion Qualified \uf0b7 Reported in the Statement of Net Assets Available for Benefits are payables and accruals of UGX.2,679,752,000, of which UGX.2,022,412,000 and UGX.442,330,000 are administrative and actuarial fees respectively. However, these were not adequately supported to confirm existence. \uf0b7 Eleven (11) properties disclosed as part of the non-core assets were still not valued and therefore not included in the value of Non-current assets of the Scheme. \uf0b7 A review and comparison made between the audited financial statements for the period ending 30th June, 2019 and the financial statements for the period ending 30th June, 2020 revealed inconsistencies in the account balances of reserves. \uf0b7 Receivables were not supported with any documentation and schedule to confirm the amounts and authenticity. \uf0b7 The reported cash and cash equivalents is misstated.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 228, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["31.8Bn were not quantified at all. \uf0b7 Out of the two (2) fully quantified outputs, Two (2) outputs with six (6) activities worth UGX.0.71Bn were partially implemented. Out of the six (6) activities, the entity fully implemented one (1) activity; Four (4) activities were partially implemented, while one (1) activity remained unimplemented. \uf0b7 The balances for; payables of UGX 169,490,014,824 , Non-produced assets of UGX 212,279,181,177, and that of revenue receivables of UGX 24,760,000 as at 30th June, 2021, Could not be confirmed due to absence of adequate supporting documentation and reliable data by the commission. \uf0b7 A sum of UGX.1,237,717,474 was paid for outstanding arrears that related to the prior year, but were not recognized in the prior year financial statements as payables. In addition, withholding tax of UGX.22,020,000 was not deducted and paid to URA. \uf0b7 I noted that the court garnished the Commission\u2019s bank Account with a balance of UGX.244,184,480 leading to the delay to clear the outstanding obligations to third parties. \uf0b7 It was noted that the entity obtained a supplementary of UGX 10.62Bn was received by the entity but was not requisitioned by management. There were unsupported payments of domestic arrears amounting to UGX 14.4 Bn. Payments worth UGX 6.7Bn were paid to unverified arrears. \uf0b7 In addition, payables to Church of Uganda amounting to UGX 15Bn, and Receivables amounting to UGX 3.966 Bn relating to the overpayment to Kampala archdiocese in the prior year were not recognised. In addition, outstanding arrears of UGX 1.2Bn related to prior year but paid during the year have not been recognised in the current year. \uf0b7 The Commission does not have a land inventory and database for all government land and properties under its jurisdiction that are either occupied by tenants, vacant, acquired under compensation (but not yet re-distributed to the bona fide occupants), or acquired and owned by other government institutions and missions abroad. As such tracking of lease payments and revenue arrears related to ground rent and premium could not be supported.", null, null], ["", "ACCOUNTABILITY SECTOR", "\uf0b7"], ["1\\. Uganda Communication Employees Contributory Pension Scheme. 2019/20 Opinion Qualified \uf0b7 Reported in the Statement of Net Assets Available for Benefits are payables and accruals of UGX.2,679,752,000, of which UGX.2,022,412,000 and UGX.442,330,000 are administrative and actuarial fees respectively. However, these were not adequately supported to confirm existence. \uf0b7 Eleven (11) properties disclosed as part of the non-core assets were still not valued and therefore not included in the value of Non-current assets of the Scheme. \uf0b7 A review and comparison made between the audited financial statements for the period ending 30th June, 2019 and the financial statements for the period ending 30th June, 2020 revealed inconsistencies in the account balances of reserves. \uf0b7 Receivables were not supported with any documentation and schedule to confirm the amounts and authenticity. \uf0b7 The reported cash and cash equivalents is misstated.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 228, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "216", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 228, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 The Scheme recognized a retrenchment penalty worth UGX.11,320,160,000 as a receivable from UTL yet this amount had been written off. \uf0b7 I noted that out of the budgeted revenue of UGX.12,447,003,444 for the year 2019/2020, only UGX.2,264,969,444 was realised representing a performance of only 18.2% of the target. \uf0b7 I established that funds totaling to UGX.88,575,000 were never budgeted for, and no authority was sought from the Founder to use the current year\u2019s appropriated funds to meet this expenditure. \uf0b7 Diversion of members\u2019 contribution (DC) to pay defined benefits (DB) liabilities: UGX.4,550,343,000. \uf0b7 I noted that, whereas PAYE to a tune of UGX.35,427,298 was withheld from employees as required during the year, it was not remitted to URA in the timelines prescribed by the Income Tax Act.", null, null], ["2", "Uganda Bureau of Statistics (UBOS). 2020/21", "\uf0b7 I noted a number of issues in the implementation of the approved budget such: under absorption of funds; partial or non-implementation of activities, non-quantification of activities, under performance of the NTR and government releases. \uf0b7 There was delayed Implementation of a number of Projects such as:"], [null, "Opinion Unqualified", null], ["3 URA Corporate 2020/21 Opinion Unqualified \uf0b7 URA operated at least six operations bank accounts in commercial banks with an annual turnover of over UGX.1.1 Tn, in contravention of Section 33 (5), (6) and (7) of the Public Finance Management Act 2015. The action overrides the Government financial management controls and distorts the monetary policy. \uf0b7 UGX.9.6Bn was advanced to staff through their bank accounts to purchase goods, services, and other activities without following regulations. The practice is irregular and also exposes Government funds to a risk loss through misuse. \uf0b7 UGX.1.16Bn paid through mobile money to various suppliers for the provision of services were not adequately supported with accountability documents as required; as a result, I could not ascertain whether the funds were utilised correctly for the intended activities. \uf0b7 Management made cash withdrawals amounting to UGX.5.2Bn during the year, contrary to Section 11 of PFMA 2015, as well as Section 7 of the URA Cash Policy that sets the maximum insurable cash limit to UGX.20Mn. The practice has been recurring and exposes government funds to a risk of misuse of cash and loss.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 229, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "217", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 229, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 The Authority awarded multi-year contracts to the tune of UGX.18.7Bn without evidence of approval of these multi-year commitments by the Parliament. This was contrary to Section 23(1) of the PFMA 2015. \uf0b7 Planned procurements worth UGX.25.1Bn were not implemented by 30th June 2021. This adversely affects the realisation of critical government programs. Management explained that the delays were due to various reasons, some of which are beyond their control. \uf0b7 During the financial year 2020/21, the collaborating institutions under the Tax Registration and Expansion Programme (TREP) registered only 167,211 taxpayers against a target of 436,869 taxpayers representing a 38.27% registration success and a shortfall of 61.7%. In revenue terms, although TREP had a revenue target of UGX.124.58 Bn in FY 2020/21, it had only collected UGX.49.93Bn by 30th June 2021, representing a 40% performance rate. The paltry performance was attributed to COVID-19 effects, riots and the political environment, that hindered field activities. \uf0b7 The Ministry of Local Government had planned to implement activities worth UGX.4.4Bn under TREP activities but only implemented activities worth UGX.3.3Bn, leaving un-implemented activities worth UGX.1.1Bn despite receiving all funding. As a result, the e-LogRev objective of simplifying and strengthening the local revenue collection systems for Local Governments may not be achieved in time.", null, null], ["4", "URA Revenue Collection Account 2020/21", "\uf0b7 The Authority had a total revenue collection target of UGX.22.039Tn for the financial year 2020/21, and collected total gross revenue of UGX.19.649Tn, representing 89% hence a shortfall of UGX.2.39Tn"], [null, null, "(11%). Under collection of revenue affects cash flow performance of"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 230, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["\uf0b7 The Authority awarded multi-year contracts to the tune of UGX.18.7Bn without evidence of approval of these multi-year commitments by the Parliament. This was contrary to Section 23(1) of the PFMA 2015. \uf0b7 Planned procurements worth UGX.25.1Bn were not implemented by 30th June 2021. This adversely affects the realisation of critical government programs. Management explained that the delays were due to various reasons, some of which are beyond their control. \uf0b7 During the financial year 2020/21, the collaborating institutions under the Tax Registration and Expansion Programme (TREP) registered only 167,211 taxpayers against a target of 436,869 taxpayers representing a 38.27% registration success and a shortfall of 61.7%. In revenue terms, although TREP had a revenue target of UGX.124.58 Bn in FY 2020/21, it had only collected UGX.49.93Bn by 30th June 2021, representing a 40% performance rate. The paltry performance was attributed to COVID-19 effects, riots and the political environment, that hindered field activities. \uf0b7 The Ministry of Local Government had planned to implement activities worth UGX.4.4Bn under TREP activities but only implemented activities worth UGX.3.3Bn, leaving un-implemented activities worth UGX.1.1Bn despite receiving all funding. As a result, the e-LogRev objective of simplifying and strengthening the local revenue collection systems for Local Governments may not be achieved in time.", null, null], ["4", "URA Revenue Collection Account 2020/21", "\uf0b7 The Authority had a total revenue collection target of UGX.22.039Tn for the financial year 2020/21, and collected total gross revenue of UGX.19.649Tn, representing 89% hence a shortfall of UGX.2.39Tn"], [null, null, "(11%). Under collection of revenue affects cash flow performance of"], [null, "Opinion Unqualified", "Government and realisation of the planned service delivery targets. Management attributed the performance to the adverse impact of COVID-"], [null, null, "19 pandemic."], [null, null, "\uf0b7 I reviewed the statement of comparison of target and actual revenue"], [null, null, "collection by the tax head and noted that revenues from different sources"], [null, null, "worth UGX.86.979Bn were not budgeted for, despite collecting significant"], [null, null, "incomes on these tax heads for the past two years leading to under-"], [null, null, "budgeting. Lack of budget provisions of the tax heads conceals revenue"], [null, null, "potential, distorts revenue projections and may lead to un-appropriate"], [null, null, "performance assessments and related bonuses."], [null, null, "\uf0b7 Uganda Tax/GDP ratio remained low at 12.5% in 2020/21, compared to"], [null, null, "other countries in the region and globally. This performance was similar"], [null, null, "to last year's performance. This implies that tax bases have not widened"], [null, null, "or deepened enough to tax all potential sources."], [null, null, "\uf0b7 There was an increase in total Tax Arrears from UGX.3.009Tn in 2019/20"], [null, null, "to UGX.4.519Tn in the financial year 2020/21 representing a total"], [null, null, "increase of UGX.1.492Tn or percentage increase in total Tax Arrears of"], [null, null, "50%. The Increase denies Government the required resources to deliver"], [null, null, "more services."], [null, null, "\uf0b7 The contract between the Government of Uganda (GoU) and a private"], [null, null, "company had since expired even though the Company had continued to"], [null, null, "manufacture motor vehicle registration numbers for taxpayers. Expired"], [null, null, "contracts expose the Government to the risk of loss of revenue without a"], [null, null, "remedy."], [null, null, "\uf0b7 I noted that government had continued to engage only two private"], [null, null, "companies, making them monopolies in providing motor vehicle"], [null, null, "registration number plates for more than eight (8) years without opening"], [null, null, "it up for competition. The Monopoly exposes the taxpayer to high prices"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 230, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "218", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 230, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "for the services."], [null, null, "\uf0b7 URA received a sum of UGX.279.509Bn through Bank of Uganda from"], [null, null, "Government Ministries, Departments and Agencies and Local"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 231, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "for the services."], [null, null, "\uf0b7 URA received a sum of UGX.279.509Bn through Bank of Uganda from"], [null, null, "Government Ministries, Departments and Agencies and Local"], [null, null, "Governments. The amount was not reconciled and receipted due to the"], [null, null, "inability to identify the tax head and the lack of IFMS and BoU Systems"], [null, null, "interface with URA systems. Collection of Revenue without receipting and"], [null, null, "charging the correct tax heads results into misstatement of revenue"], [null, null, "collected per tax head."], ["5 Uganda Retirement Benefits Regulatory Authority. 2020/21 Opinion Unqualified \uf0b7 The entity budgeted to receive UGX.12.35Bn in the FY 2021/21. However, only UGX.11.25Bn was available for spending resulting into a shortfall of UGX.1.1Bn, which is 9% of the budget; this affected implementation of planned activities. \uf0b7 Assessment of implementation of planned outputs revealed that Nine (9) outputs with a total of forty (40) activities worth UGX.2.89Bn were partially implemented. Out of the forty (40) activities, the entity implemented twenty-eight (28) activities (70%), while twelve (12) activities (30%) remained unimplemented. In addition, planned procurements totaling UGX.309Mn were also not implemented. \uf0b7 Out of the approved staffing level of 61, the Authority has only 36 positions filled (59%), leaving a staffing gap of 25 positions (41%). Included in the unfilled positions are key positions of Director Finance and Accounting, Director Human Resource and Administration and the Director Research and Strategy. This affects the entity\u2019s capacity to effectively deliver its mandate.", null, null], ["6", "Bank of Uganda 2020", "\uf0b7 Uncertainties brought by Covid-19 could potentially led to delays by Government to refund/repay amounts due to the Bank. \uf0b7 Audit noted that the Government capital account included in the loans, advances and drawdowns to Government increased by UGX 1,087,811"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 The assessment of the possible outcome of the appeal (Crane Bank - Civil"], [null, null, "Appeal No. 252 of 201) and the amount of any resulting potential"], [null, null, "obligations, if any, involves significant judgement by the directors."], [null, null, "\uf0b7 I noted that, as at June 30, 2020, the core capital of the Bank was below"], [null, null, "the minimum required capital by UGX.453,331 million (2019:"], [null, null, "UGX.671,712 million)"], ["7 Housing Finance Bank Limited 2020 Opinion Unqualified \uf0b7 I noted that Management has estimated impairment provisions for loans and advances to customers collectively for homogenous loan portfolios using statistical methods on the basis of risk parameters using historical data taking into account forward looking information on expected macroeconomic conditions including considerations made for possible effects from the COVID-19 pandemic. \uf0b7 As at 31 December 2020, a total of 1184 customers with loans worth UGX. 159.8 billion had applied and been granted loan restructures of different forms. However, as at 31 December 2020, only 331 customers with loans worth UGX. 58.0 billion were still under repayment moratoriums with the rest having reverted to periodic repayments schedules following the initial restructures. \uf0b7 The COVID-19 pandemic containment measures increased economic uncertainty amongst the borrowers, prompting many to prematurely repay their loans during and after the lockdowns. These redemptions", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 231, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "219", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 231, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["involving as many as 901 customers affected the growth rate of the loan book by over UGX. 37.0 billion. \uf0b7 I noted that there was a disruption in the periodic repayments by the Bank\u2019s borrowing customers at the peak of the pandemic containment measures.", null, null], ["8", "Post Bank Uganda Limited. 2020", "\uf0b7 COVID-19 effects and corresponding bank measures impacted PBU loan portfolio in different ways including reduction in cash flows from loan"], [null, null, "repayments as a result of granting moratoriums, increase in customers"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 232, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["involving as many as 901 customers affected the growth rate of the loan book by over UGX. 37.0 billion. \uf0b7 I noted that there was a disruption in the periodic repayments by the Bank\u2019s borrowing customers at the peak of the pandemic containment measures.", null, null], ["8", "Post Bank Uganda Limited. 2020", "\uf0b7 COVID-19 effects and corresponding bank measures impacted PBU loan portfolio in different ways including reduction in cash flows from loan"], [null, null, "repayments as a result of granting moratoriums, increase in customers"], [null, "Opinion Unqualified", "demanding for Interest rate reduction, shrink in credit demand for some sectors and drop in disbursements due to cautious lending coupled with"], [null, null, "increase in default rates for some sectors."], ["9 Contigencies\u2019 Fund. 2020/21 Opinion Unqualified \uf0b7 Section 26(i) of the PFMA 2015 (as amended) provides that a Contingencies Fund shall every financial year be replenished with an amount equivalent to 0.5% of the appropriated annual budget of Government of the previous financial year. The approved budget for the previous financial year (FY2019/20) was UGX.40.49Trillion, which would have translated into UGX.202.43Bn funding for the Contingencies\u2019 Fund in the year under review. I noted however, that Parliament only appropriated UGX.62Bn to the Contingencies fund, causing a deficit of UGX.140.3Bn. Underfunding of the Contingencies Fund distorts implementation of the approved budget for the current year as evidenced by budget cuts and reallocations to fund supplementary budgets relating to natural disasters and emergencies that occurred during the year. \uf0b7 Audit of the withdrawals made off the Contingencies Fund revealed that a total of UGX.62,070,000,000 was transferred to the Fund bank account held at Bank of Uganda. The funds were consequently transferred to entity bank accounts and expensed off the IFMS, which makes it difficult to follow up and track to confirm the adherence to the approved budget guidelines and also confirm accuracy of the reports generated. Spending off the IFMS also exposes the funds to the risk of misuse due to lack of transparency.", null, null], ["10", "Financial Intelligence Authority. 2020/21", "\uf0b7 The Financial Intelligence Authority lacked an approved strategic plan aligned to the NDP III. Under the circumstances, there is a risk that activities implemented during the financial year 2020/2021 were not"], [null, null, "aligned to the NDP-III, which negatively affects the achievement of NDP-"], [null, "Opinion", "III objectives. I advised the Accounting Officer to follow up on the approval of the strategic plan urgently. \uf0b7 A review of the staffing structure for FIA revealed that out of the total"], [null, "Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 232, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "220", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 232, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["11 Insurance Training College (ITC). 2020/21 Opinion Unqualified \uf0b7 Section 63 of the Insurance Act requires the Insurance Training levy to be reconciled with Insurers within 60 days after the end of the calendar year. I however noted that a total of UGX.4.9Bn was collected based on basis of computed returns submitted by the Insurers and Health Member Organisations (HMO\u2019s), with no evidence of reconciliation of Training Levy returns, contrary to requirements under the Act. As a result, the returns may be understated to reduce remittances, which may lead to revenue loss.", null, null], ["12", "National Population Council.", "\uf0b7 Out of the ten (10) sampled outputs that NPC planned to implement"], ["", "Opinion", "during the period under review, five (5) outputs representing 50% of the planned sampled outputs were fully implemented, four (4) Outputs representing 40% were partially implemented, and one (1) Output"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 233, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["11 Insurance Training College (ITC). 2020/21 Opinion Unqualified \uf0b7 Section 63 of the Insurance Act requires the Insurance Training levy to be reconciled with Insurers within 60 days after the end of the calendar year. I however noted that a total of UGX.4.9Bn was collected based on basis of computed returns submitted by the Insurers and Health Member Organisations (HMO\u2019s), with no evidence of reconciliation of Training Levy returns, contrary to requirements under the Act. As a result, the returns may be understated to reduce remittances, which may lead to revenue loss.", null, null], ["12", "National Population Council.", "\uf0b7 Out of the ten (10) sampled outputs that NPC planned to implement"], ["", "Opinion", "during the period under review, five (5) outputs representing 50% of the planned sampled outputs were fully implemented, four (4) Outputs representing 40% were partially implemented, and one (1) Output"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 233, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["11 Insurance Training College (ITC). 2020/21 Opinion Unqualified \uf0b7 Section 63 of the Insurance Act requires the Insurance Training levy to be reconciled with Insurers within 60 days after the end of the calendar year. I however noted that a total of UGX.4.9Bn was collected based on basis of computed returns submitted by the Insurers and Health Member Organisations (HMO\u2019s), with no evidence of reconciliation of Training Levy returns, contrary to requirements under the Act. As a result, the returns may be understated to reduce remittances, which may lead to revenue loss.", null, null], ["12", "National Population Council.", "\uf0b7 Out of the ten (10) sampled outputs that NPC planned to implement"], ["", "Opinion", "during the period under review, five (5) outputs representing 50% of the planned sampled outputs were fully implemented, four (4) Outputs representing 40% were partially implemented, and one (1) Output"], [null, "Unqualified", "representing 10% was not implemented during the period under review."], [null, null, "\uf0b7 Gratuity payments totalling UGX.940Mn were not subjected to PAYE and"], [null, null, "the 5% NSSF employee deductions. I further noted that NPC did not"], [null, null, "provide for the 10% employer contribution for the staff resulting from the"], [null, null, "gratuity payment. This denied URA the much-needed revenue and the"], [null, null, "staff were disadvantaged due to failure to contribute to NSSF."], ["13 Tax Appeals Tribunal. 2020/21 Opinion Unqualified \uf0b7 Arising out of a supreme court decision, all tax disputes in Uganda must first commence in the Tax appeal Tribunal before they move to any other court. A review of the cases filed at the Tribunal, in the last three years, revealed that there was an increase of cases filed from 40 in 2017 to 176 in 2020. In spite of the increase in cases, there has been no increase in the number of members of the Tribunal which has necessitated that the members of the Tribunal sit every day not withstanding their regular involvement in the administrative aspects of the Tribunal. The current structure of the remuneration of the members indicates that each member will be paid a sitting allowance and a retainer. This has resulted into the Tribunal spending the bulk of its money on the payment of allowances to the Tribunal members. \uf0b7 During the reviews, I noted that there were instances in which a Tribunal member is an active partner of a Firm that has a case before the Tribunal. Whereas the said Tribunal Member does not form part of the panel of the committee adjudicating the disputes, this presents a potential conflict of interest for the members of the committee who work with him and have to decide the matters involving his Firm for which he is an active partner. \uf0b7 I noted that the approved organisation structure for the Tribunal, did not have a provision for internal audit function and indeed, this role has not been assigned to any staff. This is contravention with the PFMA 2015, and it also denies the Tribunal an early warning mechanism in cases of errors of omission or commission.", null, null], ["14", "Uganda Microfinance Regulatory Authority (UMRA) 2020/21", "\uf0b7 It was noted that, contrary to Section 17 of the PFMA 2015, the Authority had unspent funds totalling UGX.4.93Mn at the year-end that were never returned to Treasury. It should also be noted that the same was done in the preceding year where UGX.204Mn was never returned. Failure to"], [null, null, "return unspent funds contravenes Section 17 of the Public Finance and"], [null, "Opinion Unqualified", "Management Act 2015, and exposes the funds to a risk of diversion since they are spent in the subsequent financial year without appropriation by"], [null, null, "parliament."], [null, null, "\uf0b7 Section 11.2.4 of the Treasury Instructions 2017, requires the Head of"], [null, null, "Finance to ensure that commitments are not approved unless sufficient"], [null, null, "funds are available in the commitment item. However, in disregard to the"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 233, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "221", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 233, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "above provision, commitments to a tune of UGX.321Mn remained unpaid"], [null, "at the close of the year under review."], [null, "\uf0b7 Comparison of licensees per category (Moneyl enders and non-deposit"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 234, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None"], "type": "table"}}, {"content": [["", "above provision, commitments to a tune of UGX.321Mn remained unpaid"], [null, "at the close of the year under review."], [null, "\uf0b7 Comparison of licensees per category (Moneyl enders and non-deposit"], [null, "taking institutions) between the previous year 2019/2020 and those that"], [null, "renewed their licenses in the year under review 2020/2021 revealed that"], [null, "a total of 365 licensees had not submitted applications for renewal. In"], [null, "light of the occurrence, there is a risk that the licensees in issue could"], [null, "have operated for the whole year without having paid the requisite fees,"], [null, "which would lead to a loss in government revenue to a tune of"], [null, "UGX.200Mn."], [null, "\uf0b7 Section 36(1)(a & b) of the Tier 4 Microfinance Institutions Act and"], [null, "Moneylenders Act, 2016 states that a SACCO shall not carry on the"], [null, "business of financial services unless it is a registered society; and licensed"], [null, "under the Act. Audit noted that only 15 SACCOs were issued with"], [null, "operating licenses by Uganda Microfinance Regulatory Authority."], [null, "However, data obtained from Microfinance Support Centre (MSC)"], [null, "indicated that over 6,150 EMYOOGA SACCOs were by March, 2021 in"], [null, "operation without acquiring operating licenses."], [null, "\uf0b7 Audit of the Authority\u2019s payroll and other expenses revealed that during"], [null, "the financial year ended 30th June 2021, Pay as You Earn (PAYE) tax"], [null, "amounting to UGX.290Mn in respect of deductions from employees was"], [null, "never remitted to the Uganda Revenue Authority."], ["15 The Departed Asians Property Custodian Board (DAPCB). 2020/21 Opinion Unqualified \uf0b7 I noted that MDAs and LGs are still experiencing challenges in implementing the budgets approved by parliament and policy guidance\u2019s issued by PS/ST, which has continued to affect the performance and credibility of the budget negatively. \uf0b7 I reviewed the NTR estimates, revenue sources and rates charged for the financial year 2020/2021 and noted that the entity budgeted to collect NTR of UGX.2,572,820,000 during the year under review. Out of this, only UGX.1,410,970,500 was collected, representing a performance of 55% of the target, resulting into a shortfall of UGX.1,161,849,500. \uf0b7 The entity budgeted to receive UGX.2.572Bn during the period, out of which UGX.1.383Bn was warranted, resulting into a shortfall of UGX.1.189Bn which is 46.23% of the budget. \uf0b7 I observed that in cases where outputs were not quantified, management reported performance in generic ways such as tenants sensitised to pay rent, court attended etc, without specifying the number/quantities achieved. \uf0b7 All five (5) outputs with a total of thirteen (13) activities worth UGX.1.383Bn were partially implemented. \uf0b7 I noted that in a twist of events, the Board refunded the sum of UGX.0.860Bn that had been deposited in respect of the property, citing the fact that the property had been donated to the tenant, but this was not supported by a Board resolution. \uf0b7 I observed that according to a disclosure in note 19 of the accounts, receivables have increased from UGX.3.35Bn last year to UGX.8.21Bn this year. Of this amount, UGX.3,73Bn relates to uncollected rent from prior years and UGX.4.60Bn relates to unpaid proceeds from property sales. \uf0b7 I reviewed the portfolio of DAPCB court cases and noted that there was a continuous rise) in the number of court cases against the Board arising from disputes of properties. The cases rose by 18, making a total of 120, as at the end of the year.", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 234, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None"], "type": "table"}}, {"content": "222", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 234, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that the entity does not have a comprehensive asset register to date. The copy of the compendium/register availed to me for audit was still under verification by management and as such management could not vouch for its completeness. \uf0b7 I reviewed the compendium of assets presented for audit by management and noted that nearly all properties therein were not yet valued, and yet the Board of valuers has now been in place for nearly three financial years.", null, null], ["16", "The Danida (Upgrade) Project Under the Inspectorate of Government.", "\uf0b7 I noted that MDAs and LGs are still experiencing challenges in implementing the budgets approved by parliament and policy guidance's issued by PS/ST, which has continued to affect the performance and credibility of the budget negatively."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 235, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["\uf0b7 I noted that the entity does not have a comprehensive asset register to date. The copy of the compendium/register availed to me for audit was still under verification by management and as such management could not vouch for its completeness. \uf0b7 I reviewed the compendium of assets presented for audit by management and noted that nearly all properties therein were not yet valued, and yet the Board of valuers has now been in place for nearly three financial years.", null, null], ["16", "The Danida (Upgrade) Project Under the Inspectorate of Government.", "\uf0b7 I noted that MDAs and LGs are still experiencing challenges in implementing the budgets approved by parliament and policy guidance's issued by PS/ST, which has continued to affect the performance and credibility of the budget negatively."], [null, "2020/21 Opinion Unqualified", null], ["17 The Inspectorate of Government (IG). 2020/21 Opinion Unqualified \uf0b7 I noted that MDAs and LGs are still experiencing challenges in implementing the budgets approved by parliament and policy guidance\u2019s issued by PS/ST, which has continued to affect the performance and credibility of the budget negatively. \uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity budgeted to collect NTR of UGX.1,201,509,223 during the year under review. Out of this, a total of UGX.1,875,073,520 was collected, representing a performance of 156% of the target with an excess collection of UGX.673,564,297. \uf0b7 The entity budgeted to receive UGX.53.4Bn from GoU sources; however, only UGX.49.45Bn was released, resulting into a shortfall of UGX.3.95Bn, which is 7.4% of the budget. \uf0b7 Out of the total warrants for the financial year of UGX.49,446,960,793, UGX.45,655,225,893 was spent by the entity, leaving a balance of UGX.3,791,734,900 unutilised by the vote. \uf0b7 I noted that the approved work programme for the construction of headquarter building indicated planned progress of 32% compared to the actual work progress of 11.9%.", null, null], ["18", "The Northern Uganda Social Action Fund Project Under the Inspectorate of", "\uf0b7 The project had an approved budget of UGX.2,235,166,397 for the FY 2020/21. I noted that a total of UGX.2,235,166,397 was received for the period representing 100% of the appropriated amount."], [null, "Government (IG). 2020/21 Opinion", null], [null, "Unqualified", null], [null, "", null], ["19 Ministry of Finance Planning and Economic Development (MoFPED). 2020/21 \uf0b7 Analysis of domestic arrears showed an increase of UGX.139Bn from UGX.129Bn in the financial year 2019/20 to UGX.269Bn in the financial year 20/21 representing a jump of 108%. Overall, tax expenditure by government for private firms continues to account for the biggest portion of the arrears (at 78%) despite the write off of the tax arrears in the", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 235, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "223", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 235, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Unqualified previous financial year. I also noted that arrears relating to unsettled obligations to international organizations stood at UGX.49.49Bn with some dating as far back as financial year 2014/15. \uf0b7 GoU, through MOFPED, offered additional incentives of USD Cents 5/KWH to companies in the Cotton, Textile and Apparels (CTA) industry. During the financial year ended 30th June 2021, a total of UGX.3.36Bn was paid/refunded to two manufacturers while UGX.5.41Bn remained outstanding as at year end; However, I noted that; i) the concession was not time-bound, which exposes government to perpetual expenditure without value analysis. ii) none of the beneficiaries had furnished the Ministry with the required insurance bond despite the continued access to the benefit. iii) there was no evidence of publicizing the concession for the benefit of all eligible firms/persons. In this regard, the concession is only being enjoyed by two firms which creates competitive disadvantages to the other players in the industry. iv) there was no mechanism in place to monitor compliance with the set targets despite having reached the first milestone. v) the memorandum of understanding signed did not provide for reporting obligations for the beneficiaries. There was thus no justification for the continued incentive vi) all refunds effected so far are made from supplementary budgets implying none sustainability of the incentive. Indeed a total of UGX.5.41Bn remains outstanding as at 30th June 2021. \uf0b7 In line with the above, it is apparent that the subsidy is being implemented with irregularities. Government is exposed to continued expenditure without due regard to achievement of the intended objectives. \uf0b7 The Uganda Agriculture Insurance Scheme (UAIS) is a Public Private Partnership between GoU and the Private Sector represented by the Uganda Insurers Association and insurance companies under the agro- Consortium. The purpose of the scheme is to hedge Ugandan farmers against natural calamities beyond their control. However, review of implementation revealed that there was lack of a mutual agreement on Marketing of the scheme to the potential beneficiaries and a number of conditions in the MoU are not yet fulfilled. This has limited its access to potential beneficiaries and also raised transparency concerns in regard to how the current beneficiaries were identified. \uf0b7 The PPP Act 2015 provides that there is to be established a Project Development Fund to support public private partnerships initiatives. However, six years later, there is no evidence of operationalization of the Fund by the Minister. Failure to establish the fund may be a contributory factor to the slow uptake and limited feasibility studies of the Public Private Partnerships.", null, null], ["20", "PPDA Tribunal. 2020/21", "\uf0b7 I noted that the Tribunal was operating a strategic plan that is not aligned to the NDP III period. The Tribunal\u2019s planning period is 2017-"], [null, null, "2022 implying that activities implemented during the financial year"], [null, "Opinion", "2020/2021 may not have been aligned to the NDP-III, which negatively affects the achievement of NDP-III objectives."], [null, "Unqualified", null], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 236, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "224", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 236, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["21 Uganda Investment Authority. 2020/21 Opinion Unqualified \uf0b7 The Authority received off-budget financing to a tune of UGX.50.43Bn, which was not transferred to the consolidated fund as required by law. These funds were received directly from development partners to the EPC contractor for the Development of infrastructure at Kampala Industrial and Business Park, Namanve. Off-budget financing distorts planning, may result into duplication of activities and is contrary to the Public finance Management Act 2015. \uf0b7 The approved budget estimates for the Authority for the financial year 2020/2021 indicated that only UGX.22Mn out of UGX.2.411Bn was budgeted towards the settlement of domestic arrears. The arrears balance of UGX.2.389Bn was therefore not budgeted for settlement. Failure to provide resources for the accumulated arrears increases outstanding obligations. \uf0b7 The Authority continued to accumulate domestic arrears with a total of UGX.1.768Bn incurred in the financial year under review, without clearing outstanding arrears from the previous financial year 2019/2020 of UGX.2.411Bn. The total accumulated domestic arrears stood at UGX.4.18Bn at 30th June 2021. This is an indicator of non adherence with the commitment control system of government. \uf0b7 During inspections countrywide, I observed that the industrial parks lack or had inadequate infrastructures like roads, solid waste and sewage management systems, power supply, street lights etc. The Parks have been characterized by encroachment, farming and cattle grazing, degradation of nearby swamps, unallocated land, idle land allocated to unserious investors and misunderstandings between investors and park management staff. Most roads are impassable and with inadequate lighting which exposes the parks to thefts and insecurity. I observed that some factories in the parks have set up their own infrastructure which may not be sustainable, and to the desired standards. This may negatively affect the usage and utilization of the parks. \uf0b7 The Authority lacks regulations required under Section 38(1) of the Investment Code Act to operationalize the statute. This may hinder the smooth implementation of the Act which is meant to create an investment enabling environment. \uf0b7 Although the Authority has 124 approved positions, only 78 (i.e. 62.9%) are filled, leaving 46 (37.1%) vacant positions. Among the vacant positions include 24 unfilled positions that are from the core Directorate of Investment which is the backbone of UIA. Understaffing undermines service delivery.", null, null], ["22", "Treasury Operations. 2020/21", "\uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity had not budgeted to collect NTR during the year under review."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 237, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["21 Uganda Investment Authority. 2020/21 Opinion Unqualified \uf0b7 The Authority received off-budget financing to a tune of UGX.50.43Bn, which was not transferred to the consolidated fund as required by law. These funds were received directly from development partners to the EPC contractor for the Development of infrastructure at Kampala Industrial and Business Park, Namanve. Off-budget financing distorts planning, may result into duplication of activities and is contrary to the Public finance Management Act 2015. \uf0b7 The approved budget estimates for the Authority for the financial year 2020/2021 indicated that only UGX.22Mn out of UGX.2.411Bn was budgeted towards the settlement of domestic arrears. The arrears balance of UGX.2.389Bn was therefore not budgeted for settlement. Failure to provide resources for the accumulated arrears increases outstanding obligations. \uf0b7 The Authority continued to accumulate domestic arrears with a total of UGX.1.768Bn incurred in the financial year under review, without clearing outstanding arrears from the previous financial year 2019/2020 of UGX.2.411Bn. The total accumulated domestic arrears stood at UGX.4.18Bn at 30th June 2021. This is an indicator of non adherence with the commitment control system of government. \uf0b7 During inspections countrywide, I observed that the industrial parks lack or had inadequate infrastructures like roads, solid waste and sewage management systems, power supply, street lights etc. The Parks have been characterized by encroachment, farming and cattle grazing, degradation of nearby swamps, unallocated land, idle land allocated to unserious investors and misunderstandings between investors and park management staff. Most roads are impassable and with inadequate lighting which exposes the parks to thefts and insecurity. I observed that some factories in the parks have set up their own infrastructure which may not be sustainable, and to the desired standards. This may negatively affect the usage and utilization of the parks. \uf0b7 The Authority lacks regulations required under Section 38(1) of the Investment Code Act to operationalize the statute. This may hinder the smooth implementation of the Act which is meant to create an investment enabling environment. \uf0b7 Although the Authority has 124 approved positions, only 78 (i.e. 62.9%) are filled, leaving 46 (37.1%) vacant positions. Among the vacant positions include 24 unfilled positions that are from the core Directorate of Investment which is the backbone of UIA. Understaffing undermines service delivery.", null, null], ["22", "Treasury Operations. 2020/21", "\uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity had not budgeted to collect NTR during the year under review."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 237, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "225", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 237, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "government to private enterprises for which no recovery has been"], [null, null, "effected since 2013."], [null, null, "\uf0b7 Included in cash and cash equivalents is UGX.15.62Bn which was a"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 238, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "government to private enterprises for which no recovery has been"], [null, null, "effected since 2013."], [null, null, "\uf0b7 Included in cash and cash equivalents is UGX.15.62Bn which was a"], [null, null, "USAID grant for enhancing Livelihoods and Infrastructure of Northern"], [null, null, "Uganda under a project. The funds have remained utilized for more than"], [null, null, "two years and risk being refunded to the donor yet it was a grant."], [null, null, "\uf0b7 I noted that there is no clear method of identifying which claimants are"], [null, null, "considered for negotiations even in the instance of where the said"], [null, null, "claimants have mandamus orders."], [null, null, "\uf0b7 I have noted that over the years, budgets for mandamus payments are"], [null, null, "included in the original budget as notional amounts despite having a"], [null, null, "figure for outstanding payments at the beginning of the year, including"], [null, null, "those for which settlement plans have been drawn as per the signed"], [null, null, "MoUs and court variation orders with beneficiaries."], [null, null, "\uf0b7 Audit observed that, UGX.3.32Tn which was advanced by the Bank of"], [null, null, "Uganda to settle matured obligations relating to treasury bills and bonds"], [null, null, "(principal and interest) had not been refunded as at 30th June 2021"], [null, null, "contrary to the requirements under Section 36 of the PFMA."], [null, null, "\uf0b7 A review of the company files in which the GOU holds shares revealed"], [null, null, "that some companies were dormant, with no activities being undertaken"], [null, null, "on the said files. There was no evidence that the said companies were"], [null, null, "filing the mandatory annual returns, minutes of the Annual General"], [null, null, "Meetings or any information to indicate the activity of the companies."], [null, null, "\uf0b7 Audit established through a review of records at Uganda Registration"], [null, null, "Services Bureau that Government owns a number of investments that are"], [null, null, "not reported/ recognised in the financial statements of Treasury"], [null, null, "Operations."], [null, null, "\uf0b7 It was established that the Minister provided authorisations to nineteen"], [null, null, "(19) Public Institutions to borrow funds from financial institutions totalling"], [null, null, "to UGX.60.042Bn, but there was no evidence of any monitoring being"], [null, null, "undertaken by the Ministry to ensure adherence to the loan terms and"], [null, null, "conditions."], ["23 Insurance Regulatory Authority. 2020/21 Opinion Unqualified \uf0b7 Out of the budgeted NTR of UGX.26.874Bn, only UGX.19.818Bn was collected and a shortfall of UGX.7.056Bn, representing a performance of 73.7% of the target. Shortfalls in NTR collections affect the implementation of planned activities. \uf0b7 I noted that a number of planned procurements were not executed worth UGX.5.61Bn. Non implementation of all procurements leads to failure to attain the intended objectives during the financial year. \uf0b7 There were noted delays in the phase one construction of an ultra- modern 11 storeyed office building for Insurance Regulatory Authority located at plot 6, Lumumba Avenue, which was awarded to a contractor at an amended contract price of UGX.32.662Bn. By the time of reporting, although a total cumulative payment of UGX.29.943Bn (91%) had been made to the contractor, the project was at 80% completion and 46 months behind schedule.", null, null], ["24", "National Lottery & Gaming Board. Opinion", "\uf0b7 I noted that a number of Gaming houses had not filed the required quarterly returns contrary to the Lotteries and Gaming regulations. There was no evidence that the Board had conducted enforcement activities to ensure compliance by the operators."], [null, "Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 238, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "226", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 238, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "not making returns and having operational gaps going undetected which"], [null, null, "affects the revenue collections of Uganda Revenue Authority and exposes"], [null, null, "the Ugandan public to risk of unprofessional operators."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 239, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "not making returns and having operational gaps going undetected which"], [null, null, "affects the revenue collections of Uganda Revenue Authority and exposes"], [null, null, "the Ugandan public to risk of unprofessional operators."], [null, null, "\uf0b7 The Ministry of Finance, Planning and Economic Development on behalf"], [null, null, "of Lotteries and Gaming Regulatory Board awarded a UGX.10.833Bn"], [null, null, "contract to a foreign company to provide consultancy services for"], [null, null, "development of a National Central Electronic Monitoring system. The"], [null, null, "contract period was for 2 (two) years effective 23rd June, 2020. I noted"], [null, null, "that, two years later, the procurement has not been made. There is no"], [null, null, "provision for implementation of the system even in the current budget"], [null, null, "2021/22. The failure to procure the system, denies the Board the"], [null, null, "associated benefits like monitoring and revenue tracking. Beside this may"], [null, null, "result into litigation on grounds of breach of contract and expose"], [null, null, "Government to loss of funds in compensation."], [null, null, "\uf0b7 During the year under review, although the Board licensed 17 casinos,"], [null, null, "there was no evidence that the Board advertised the applications for the"], [null, null, "said casinos to invite the views of the public as is required by regulations."], [null, null, "Failure to publish the notices poses a risk of granting licenses to"], [null, null, "operators with some conflicts among the public and as such may result"], [null, null, "into litigation."], ["25 Public Procurment And Disposal of Public (PPDA) 2020/21 Opinion Unqualified \uf0b7 I noted at the time of the audit that out of the planned Four (4) strategic targets/goals, No targets had been fully achieved, while three (3) were partially achieved, and one (1) target had not been achieved at al \uf0b7 I noted that out of the budgeted revenue of UGX.28.4Bn for the year 2020/21, UGX.21.3Bn was realised representing a performance of only 75% of the target. \uf0b7 Out of the 5 outputs assessed, No output was fully implemented; 5 outputs representing 100% were partially implemented, while no output was not implemented at all. \uf0b7 I noted that although the budget for Domestic arrears was UGX.42,407,000, funds amounting to UGX.432,579,009 were spent on domestic arrears for the FY 2020/21, implying an over expenditure of UGX.390,172,009 on this item. \uf0b7 Out of the total receipts for the financial year of UGX.18.698Bn, UGX.18.59Bn was spent by the Authority, resulting into an unspent balance of UGX.0.108Bn representing an absorption level of 99%. \uf0b7 The audit reviewed the performance of the above project and noted that much as most of the key planned activities had been implemented, there were few that were still pending. \uf0b7 I observed that the entity has a staff establishment of 140 positions, out of which only 116 were filled, leaving 24 positions vacant, representing 17% of the workforce of the entity. In addition, seven staff exited the Authority during the year, due to various reasons.", null, null], ["26", "Bank of Uganda.", "\uf0b7 No significant findings."], ["", "2020/21", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["27 Capital Markets Authority. 2019/20 Opinion \uf0b7 No significant findings.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 239, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "227", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 239, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Unqualified", null, null], ["28", "Deposit Protection Fund (\"The Fund\") 2020/21 Opinion Unqualified", "\uf0b7 I noted that although effective 1st July 2020, DPF was exempt from withholding tax, Bank of Uganda erroneously deducted withholding tax (WHT) on the Fund\u2019s interest income on matured government securities during the period amounting to UGX.10.4Bn. However, directors have decided to make full provision against the WHT receivable based on the historical experience and expected future outcome of the claim from URA"], [null, null, "on a conservative basis, and this is in accordance with the requirement of"], [null, null, "IAS 36: Impairment of Assets."], ["29 Pride Microfinance Limited (MDI) 2020 Opinion Unqualified \uf0b7 No significant findings.", null, null], ["30", "Project for Financial Inclusion In Rural Areas (PROFIRA)", "\uf0b7 I noted that, as reported in my report for the year ended 30th June 2020, Government of Uganda has not yet honored its obligation of UGX.5.6Bn as co-funding for the Project."], [null, "Opinion Unqualified", null], ["31 The Resource Enhancement and Accountability Programme (REAP) 2020/21 Opinion Unqualified \uf0b7 No significant findings.", null, null], ["32", "Uganda Development Bank", "\uf0b7 No significant findings."], ["", "Limited (UDBL). 2020", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["33\\. Microfinance Support Centre Limted (MCSC) 2020 Opinion Unqualified \uf0b7 I noted that unresolved receipts in payables balance amounting to UGX. UGX.581 Million", null, null], ["", "INFORMATION COMMUNICATION SECTOR", ""], [null, null, ""], ["1\\. Ministry of ICT and National Guidance Opinion Unqualified \uf0b7 The entity budgeted to receive UGX.46.401Bn from Treasury; out of this amount, UGX.43.586 Bn was warranted, resulting into a shortfall of UGX.2.81Bn which was 6% of the budget. Of the released amount, the Ministry absorbed UGX.42Bn, resulting into an unspent balance of UGX.1.6Bn representing an absorption level of 96%. Unspent balances imply un implemented activities and which in turn hampers proper service", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 240, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "228", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 240, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["delivery. \uf0b7 Contrary to Regulation 18 (1) of the PPDA (Contracts) Regulations, 2014, the Ministry issued call off orders to two firms in three separate procurements of office furniture worth UGX.144.8Mn under a framework contract where the items and prices on the call off orders were different from what was agreed on in the signed framework contract. This erodes the benefits of framework contracts and may cause a loss to Government.", null, null], ["2", "Uganda Communications Commission. Opinion Unqualified", "\uf0b7 Assessment of the Commission\u2019s performance of Non Tax Revenue (NTR) revealed that out of the budgeted NTR of UGX.156.59Bn, a total of UGX.454.61 was collected, representing an increase of UGX.298Bn (190% of the target). Management attributed the overperformance to payment of the National Telecom Operator (NTO) license by two telecom"], [null, null, "companies which had not been budgeted for. The Accounting Officer was"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 241, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["delivery. \uf0b7 Contrary to Regulation 18 (1) of the PPDA (Contracts) Regulations, 2014, the Ministry issued call off orders to two firms in three separate procurements of office furniture worth UGX.144.8Mn under a framework contract where the items and prices on the call off orders were different from what was agreed on in the signed framework contract. This erodes the benefits of framework contracts and may cause a loss to Government.", null, null], ["2", "Uganda Communications Commission. Opinion Unqualified", "\uf0b7 Assessment of the Commission\u2019s performance of Non Tax Revenue (NTR) revealed that out of the budgeted NTR of UGX.156.59Bn, a total of UGX.454.61 was collected, representing an increase of UGX.298Bn (190% of the target). Management attributed the overperformance to payment of the National Telecom Operator (NTO) license by two telecom"], [null, null, "companies which had not been budgeted for. The Accounting Officer was"], [null, null, "advised to always conduct comprehensive research on all potential"], [null, null, "revenue sources for proper budgeting of NTR."], [null, null, "\uf0b7 Out of the total receipts for the financial year of UGX.454.61Bn, only"], [null, null, "UGX.451.98Bn was spent by the entity resulting into an unspent balance"], [null, null, "of UGX.2.63Bn representing an absorption level of 99.5%. I commended"], [null, null, "the Accounting Officer for absorbing most of the funds availed despite the"], [null, null, "challenges during the year."], [null, null, "\uf0b7 I noted that several procurements to the tune of UGX.4.51Bn were not"], [null, null, "implemented as of 30th June 2021. As a result, implementation of critical"], [null, null, "Commission programs was delayed. Management attributed the delays in"], [null, null, "these procurements to the COVID-19 pandemic that paralysed the entire"], [null, null, "procurement process."], [null, null, "\uf0b7 The Commission discontinued issuing invoices to Uganda Telecom Ltd,"], [null, null, "Posta Uganda and Uganda Broadcasting Corporation due to tax"], [null, null, "implications where, the Commission has to pay VAT to URA on every"], [null, null, "invoice raised, whether funds are received or not. As a result, UCC ledger"], [null, null, "balances of UGX.85.1Bn differed from the reported receivables of"], [null, null, "UGX.13.1Bn, by a total of UGX.72.0Bn. Furthermore, I noted that the"], [null, null, "reported receivables by UCC from the same entities differed from the"], [null, null, "reported payables to UCC by the same entities. The Accounting Officer"], [null, null, "was advised to engage management of the affected entities with a view"], [null, null, "of reconciling to the correct receivable figures."], [null, null, "\uf0b7 The Commission did not charge the 2% gross annual levy on the licensed"], [null, null, "Television and FM radio operators and no licensed Television and FM"], [null, null, "radio operator had submitted Audited financial statements to the"], [null, null, "Commission for assessment. This denied the Commission the revenue to"], [null, null, "implement development programs."], [null, null, "\uf0b7 The Commission lacks a Tribunal with the jurisdiction to hear and"], [null, null, "determine all matters relating to communications services arising from"], [null, null, "decisions made by the Commission or the Minister, contrary to Section"], [null, null, "60(1 & 2) and 64(1) of the Uganda Communications Act, 2013. The"], [null, null, "accounting officer explained that the responsibility to appoint the tribunal"], [null, null, "resides with the President on the recommendation of the Judicial Service"], [null, null, "Commission. I advised management and the Board of Directors to liaise"], [null, null, "with the relevant authorities with the view of constituting the"], [null, null, "Communications Tribunal."], ["3 Rural Communications Infrastructure Program, Phase 5 \u2013 Uganda Project, IDA LOAN NO.5635-UG \uf0b7 I noted that MDAs and LGs are still experiencing challenges in implementing the budgets approved by parliament and policy guidance\u2019s issued by PS/ST, which has continued to affect the performance and", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 241, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "229", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 241, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["2020/21 Opinion Unqualified credibility of the budget negatively. \uf0b7 I noted that RCIP was lagging behind in some activities that would not be completed at the project end. \uf0b7 I noted that all four components did not fully absorb the available funds. Out of the UGX.104.88Bn that was released to RCIP, the Project only utilised UGX.76.52Bn, thus failing to absorb funds to a tune of UGX.28.36Bn representing 27% of the released funds. \uf0b7 It was noted that RCIP set clear performance targets and indicators for some activities to facilitate performance measurement. \uf0b7 I noted that a total of USD.702,415 has so far been paid to the contractor for supply, installation and commissioning of the e-government procurement system, of which a total of USD.198,645 was paid during the year under audit. \uf0b7 Government lost USD.208,156 for receiving quality assurance services for a system that had already been discontinued by Government", null, null], ["4", "National Information Technology Authority \u2013 Uganda (NITA-U) 2020/21 Opinion Unqualified", "\uf0b7 Analysis of domestic arrears over the past three years has shown a steep upward trend over the period with a 123% growth. The outstanding amount currently is UGX.6Bn. Further analysis revealed that most of the arrears relate to costs of expanding the national backbone infrastructure. The domestic arrears at hand now account for 14% of the annual GoU budget of the Authority. Such a trend is not only unsustainable but may lead to erosion of the credit worthiness of the Authority and may attract"], [null, null, "interest and penalties."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 242, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["2020/21 Opinion Unqualified credibility of the budget negatively. \uf0b7 I noted that RCIP was lagging behind in some activities that would not be completed at the project end. \uf0b7 I noted that all four components did not fully absorb the available funds. Out of the UGX.104.88Bn that was released to RCIP, the Project only utilised UGX.76.52Bn, thus failing to absorb funds to a tune of UGX.28.36Bn representing 27% of the released funds. \uf0b7 It was noted that RCIP set clear performance targets and indicators for some activities to facilitate performance measurement. \uf0b7 I noted that a total of USD.702,415 has so far been paid to the contractor for supply, installation and commissioning of the e-government procurement system, of which a total of USD.198,645 was paid during the year under audit. \uf0b7 Government lost USD.208,156 for receiving quality assurance services for a system that had already been discontinued by Government", null, null], ["4", "National Information Technology Authority \u2013 Uganda (NITA-U) 2020/21 Opinion Unqualified", "\uf0b7 Analysis of domestic arrears over the past three years has shown a steep upward trend over the period with a 123% growth. The outstanding amount currently is UGX.6Bn. Further analysis revealed that most of the arrears relate to costs of expanding the national backbone infrastructure. The domestic arrears at hand now account for 14% of the annual GoU budget of the Authority. Such a trend is not only unsustainable but may lead to erosion of the credit worthiness of the Authority and may attract"], [null, null, "interest and penalties."], [null, null, "\uf0b7 Included in the Statement of Financial Position is a receivable of"], [null, null, "UGX.14.9Bn arising from the 1% levy on Telecoms due from Uganda"], [null, null, "Communications Commission (UCC) dating as far back as financial year"], [null, null, "2016/17, whose recoverability is doubtful following a policy directive from"], [null, null, "the Ministry of Information, Communication and National Guidance to the"], [null, null, "effect that NITA-U should stop recognizing its share of 1% levy on"], [null, null, "Telecoms."], [null, null, "\uf0b7 UGX.1,532,979,432 reflected as non-produced assets in the Statement of"], [null, null, "Financial Position relates to land leased to NITA-U by Uganda Investment"], [null, null, "Authority. The same land has been leased to a private company without"], [null, null, "the knowledge of NITA-U. Although NITA-U filed a case against UIA in"], [null, null, "the High Court seeking a permanent injunction restraining UIA, the case"], [null, null, "was dismissed noting that the matter could only be determined under"], [null, null, "land law. By the time of audit, a developer to whom UIA leased the"], [null, null, "property had taken possession of the land and started undertaking"], [null, null, "developments on it."], ["5 Uganda Broadcasting Corporation (UBC). 2020/21 Opinion Unqualified \uf0b7 Although the entity budgeted to receive UGX.45.83Bn only UGX.15.39Bn was collected and spent, resulting into a shortfall of UGX.30.43Bn which is 66.4% of the budget. The budget for the financial year 2020/2021 was developed on the assumption that UBC would receive the UGX.34.6 Billion approved by Parliament; however, the Corporation did not receive the funds as planned. This is an indication of unrealistic budgeting by the Corporation well aware of the effects of the Covid-19 pandemic \uf0b7 Comparison of the trade receivables balances for current year and prior year indicates that the receivables decreased by 28% from UGX.30.79Bn to UGX.22Bn. An ageing analysis revealed that receivables worth UGX.13.549Bn from 228 clients were at least 7 years old without any movements in their ledger accounts, thus casting doubt as to their existence and recoverability.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 242, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "230", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 242, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 The Corporation has outstanding NSSF amounting to UGX.46.38Bn as at 30th June 2021. As a result, the Corporation and the Managing Director have been sued for non-payment and imposition of interest and fines by the NSSF due to non-remittance is now likely. This is wasteful as it could have been avoided if remittances had been made in a timely manner.", null, null], ["6", "Uganda Post Limited.", "\uf0b7 I noted that despite this being the final year of the Strategic plan and"], ["", "2020/21", "collecting on average, over 86% of the budget, most objectives were not"], [null, "Opinion", "achieved, with some attaining between 21% and 39% of implementation. The key strategic objectives that were not met include Building a strong financial base to meet operational and project development budget,"], [null, "Unqualified", "Attracting, deploying, developing and retaining a productive and motivated Human Resource, Strengthening the ICT unit to raise efficiency"], [null, null, "and competitiveness of UPL products and Rationalizing existing business"], [null, "", "lines and diversifying into low hanging opportunities to improve profitability."], [null, "", null], ["7 Uganda Communication Employees Contributory Pension Scheme (UCECPS) 2020/21 Opinion Qualified \uf0b7 I noted unsurpported payables amounting to UGX.2,679,752,000. \uf0b7 I noted that eleven (11) properties disclosed as part of the non-core assets were not valued and therefore not included in the value of Non- current assets of the Scheme. \uf0b7 A review and comparison made between the audited financial statements for the period ending 30th June, 2019 and the financial statements for the period ending 30th June, 2020 revealed inconsistencies in the account balances of reserves. \uf0b7 Unsupported and un-reconciled receivables from Uganda Telecom LimiteD (UTL - IN ADMINISTRATION) \uf0b7 I noted that the cash flow statement was misstated. \uf0b7 I noted that out of the budgeted revenue of UGX.12,447,003,444 for the year 2019/2020, only UGX.2,264,969,444 was realised representing a performance of only 18.2% of the target which implied that the Scheme had a deficit of 81.8%. \uf0b7 I noted unbudgeted expenditure totaling to UGX.88,575,000 \uf0b7 I noted diversion of members\u2019 contribution (dc) to pay Defined Benefits", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 243, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "231", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 243, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["(DB) liabilities amounting to UGX.4,550,343,000 \uf0b7", null, null], ["8", "Agricultural Credit Facility (ACF) 2020/21", "\uf0b7 No significant findings."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 244, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["(DB) liabilities amounting to UGX.4,550,343,000 \uf0b7", null, null], ["8", "Agricultural Credit Facility (ACF) 2020/21", "\uf0b7 No significant findings."], [null, null, ""], ["TRADE SECTOR \uf0b7", null, null], ["1", "Quality Infrastructure and Standards Programme (QUISP). 2017/2018", "\uf0b7 I observed that a sum of UGX. 80,034,014 and USD. 14,040 was paid to various officers and companies. However, contrary to the guidelines, the expenditure vouchers together with the supporting documents were not availed for audit verification. \uf0b7 Payments amounting to UGX.28,798,048 were paid to officers to enable them carryout various QUISP activities. However, some of the"], [null, "Opinion Qualified", null], [null, "", ""], [null, null, "373,603,894 as at end of the financial year. According to a letter from"], [null, null, "the Embassy of Sweden to the Permanent Secretary Ministry of Trade,"], [null, null, "Industry and Cooperatives dated 27th April, 2017 activities to a tune of"], [null, null, "UGX. 147,264,493 were authorized to be charged on the QUISP"], [null, null, "Programme. The entity spent a sum of UGX. 147,468,378 leaving"], [null, null, "outstanding commitments of UGX. 226,135,516 as indicated in the"], [null, null, "schedule of outstanding commitments."], [null, null, "\uf0b7 I reviewed the Programme bank statements and noted that as at 31st"], [null, null, "March 2021, UGX. 10,426,029 and USD. 1,973.43 was still on account."], [null, null, "Failure to spend funds resulted in partial and non-implementation of"], [null, null, "planned activities."], [null, null, "\uf0b7 I observed that a sum of UGX. 4,038,651 was deducted from two (2)"], [null, null, "service providers in respect of 6% withholding tax for onward remittance"], [null, null, "to Uganda Revenue Authority"], [null, null, "\uf0b7 The project procured 79 assets over the Programme life time. In March"], [null, null, "2021, I carried out an inspection of the assets procured under the"], [null, null, "Programme and noted that 12 were functional, 2 (vehicles) were under"], [null, null, "repair, 16 were old and beyond repair, 12 were non-functional while 37"], [null, null, "were not availed for verification. I could not assess the status of the 37"], [null, null, "assets that were not availed."], ["2 Uganda Export Promotions Board 2020/21 Opinion Unqualified \uf0b7 The entity budgeted to receive UGX.5.813Bn. However, UGX.3.759Bn was warranted, resulting into a shortfall of UGX.2.054Bn, which is 35.4% of the budget. This affected implementation of planned activities. \uf0b7 It was observed that the term of office for the previous Board expired on 5th October 2019, and no replacement Board had been appointed by the time of issuance of my report. This is likely to affect the strategic direction of the entity. For example, I noted that at the time of the audit (June 2021), the entity\u2019s strategic plan was in draft form and was not approved due to the lack of a Board. \uf0b7 I noted that contracts worth UGX.192Mn were awarded to bidders who", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 244, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "232", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 244, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["did not submit the required documents to evidence the eligibility and administrative compliance as required by regulations and bid documents at the preliminary stage.", null, null], ["3", "Uganda Freezones Authority (UFZA) 2020/21", "\uf0b7 Contrary to Section 15 of the Public Finance Management Act 2015, the Authority overspent to the tune of UGX.635Mn on recruitment and personnel costs in excess of what was approved by the Board. \uf0b7 The entity budgeted to collect NTR amounting to UGX.2.101Bn but was only able to collect UGX.0.06Bn resulting into a shortfall of UGX.2.04Bn,"], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 245, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["did not submit the required documents to evidence the eligibility and administrative compliance as required by regulations and bid documents at the preliminary stage.", null, null], ["3", "Uganda Freezones Authority (UFZA) 2020/21", "\uf0b7 Contrary to Section 15 of the Public Finance Management Act 2015, the Authority overspent to the tune of UGX.635Mn on recruitment and personnel costs in excess of what was approved by the Board. \uf0b7 The entity budgeted to collect NTR amounting to UGX.2.101Bn but was only able to collect UGX.0.06Bn resulting into a shortfall of UGX.2.04Bn,"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 The development work on 5 acres of land at Entebbe International Airport"], [null, null, "commenced in September 2020 and works worth UGX.4.146Bn (27%)"], [null, null, "had been certified as completed as at 30th June 2021. However, the"], [null, null, "Authority had affected 89% advance payment to NEC as at 29th June"], [null, null, "2021, amounting to UGX.15.34Bn and all the advance guarantees staked"], [null, null, "had expired."], [null, null, "\uf0b7 Although the Authority has taken possession of 109 acres of land at"], [null, null, "Buwaya purchased at UGX.7.6Bn and 5 acres of land at Entebbe"], [null, null, "International Airport purchased at UGX.850Mn, it still lacks land titles to"], [null, null, "confirm legal ownership."], ["4 Uganda Warehouse Receipt System Authority (UWRSA) 2020/21 Opinion Unqualified \uf0b7 The Uganda Warehouse Receipt System Authority had an approved budget of UGX.8,904,499,400 for the year. A review of the entity\u2019s receipts, cashbook and bank statement for the period ending 30th June 2021 revealed that UGX.8,035,212,980 was received under the normal budget appropriation \uf0b7 Whereas the overall Government National Development Plan (NDP II1) 2020/2021-2024/2025 was commissioned in the year under review, UWRSA had no approved strategic plan for the period under review \uf0b7 I noted that the entity did not budget for any tax revenue despite collecting 84 million. Failure to budget for NTR conceals the entity\u2019s potential collect revenue and also complicates assessment of performance since there is no benchmark. \uf0b7 I noted that out of the budgeted revenue of UGX. 8.899Bn from the Central Government for 2020/2021, and only UGX. 8.035Bn was received, representing a performance of only 90 % of the release. \uf0b7 The entity had a cash balance brought forward of UGX.134,172,095 from FY 2019/2020 and received UGX.8,035,212,980 making total cash available for spending in FY 20/21 of UGX.8,169,385,075. Out of the total cash available to spend, only UGX.3,730,897,866 was actually spent by the entity, representing an absorption level of 46%. This resulted into a balance of UGX.4,438,487,209 (54%) as unspent funds. \uf0b7 I compared the consolidated procurement plan, monthly procurement reports and procurement files availed and established that a number of procurements worth UGX.2,621,000,000 were not completed as of 30th June 2021. \uf0b7 Failure to implement planned activities despite availability of funds. \uf0b7 I noted that the Board sat only once during the year under review on 16th September 2020. I also noted that the Chairperson of the meeting did not sign the minutes for the meeting. \uf0b7 I noted that the Board had not developed some governance policies, manuals and other documents that would help in the smooth running of", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 245, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "233", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 245, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["the Authority. \uf0b7 The Authority received from the Treasury UGX.13,237,853,910 for the last three financial years to deliver its mandate; however, no tangible results are indicating that it is effective. \uf0b7 I established that procurements worth UGX.62,390,000 were implemented during the year, and yet they were not in the Authority\u2019s consolidated procurement plan.", null, null, null], ["5", "Competitiveness and Enterprise Development Project (CEDP) Component 2-5 IDA Credit Agreement", null, "\uf0b7 Competitiveness Enterprise Development Project (CEDP) approved budget for the Financial Year 2020/2021 was UGX.24.18Bn Comprising: UGX.23.5Bn IDA funding and UGX.742.3Mn GoU contributions. Expenditure was UGX.17.4Bn, yielding a 72% budget performance."], [null, "CR 52690-UG PROJECT ID P130471. 2020/21", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 246, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None", "None"], "type": "table"}}, {"content": [["the Authority. \uf0b7 The Authority received from the Treasury UGX.13,237,853,910 for the last three financial years to deliver its mandate; however, no tangible results are indicating that it is effective. \uf0b7 I established that procurements worth UGX.62,390,000 were implemented during the year, and yet they were not in the Authority\u2019s consolidated procurement plan.", null, null, null], ["5", "Competitiveness and Enterprise Development Project (CEDP) Component 2-5 IDA Credit Agreement", null, "\uf0b7 Competitiveness Enterprise Development Project (CEDP) approved budget for the Financial Year 2020/2021 was UGX.24.18Bn Comprising: UGX.23.5Bn IDA funding and UGX.742.3Mn GoU contributions. Expenditure was UGX.17.4Bn, yielding a 72% budget performance."], [null, "CR 52690-UG PROJECT ID P130471. 2020/21", null, null], [null, "Opinion Unqualified", null, ""], [null, null, null, "completed by 25th April 2019, and several extensions were entered into"], [null, null, null, "up to 30th June 2021. By the time of my field inspection, construction"], [null, null, null, "was still ongoing."], ["6 Great Lakes Trade Facilitation Project (GLTFP). 2020/21 Opinion Unqualified \uf0b7 I noted that the project management had failed to achieve its objectives by the initial project closure date of 31st December 2020. \uf0b7 As at 30th June 2021, a total of UGX.6.862Bn representing 62% was available for spending as indicated in the Statement of Financial performance leaving a budget deficit of UGX.4.106Bn representing 38%. \uf0b7 Audit noted that out of UGX.6.862Bn total funds available for use during the year, the project managed to utilize UGX.4.423Bn in the implementation of various project activities, leaving an unspent balance of UGX.2.439Bn (25% of the available funding).", null, null, null], ["7", "Ministry of Trade, Industry and Cooperatives 2020/21", null, "\uf0b7 I reviewed the approved revenue estimates for the financial year 2020/2021 and noted that the Ministry budgeted to receive Revenue of UGX.233.147Bn during the year under review. The entity received"], [null, null, null, "UGX.230.417Bn as releases from the consolidated fund representing the"], [null, "Opinion Unqualified", null, "overall performance of 98%."], [null, null, null, "\uf0b7 The Ministry budgeted to collect UGX.0.072Bn but realised UGX.0.053Bn, hence a shortfall of UGX.0.019Bn representing 25.4% of the budget."], [null, "", "", "\uf0b7 Out of UGX.230.417Bn released for various activities, UGX.229.123Bn was"], [null, "", "", "spent by the entity resulting into an unspent balance of UGX.1.294Bn"], [null, "", "", "representing an absorption level of 99%."], [null, "", "", "\uf0b7 Analysis of the vote performance revealed that a number of programs"], [null, "", "", "remained outstanding at the year-end, leaving a total unspent balance of"], [null, "", "", "UGX.2.0726Bn."], [null, "", "", "\uf0b7 The entity charged different expenditure codes for several expenditure"], [null, "", "", "items from those stipulated in the chart of accounts. This resulted in"], [null, "", "", "mischarging of expenditures worth UGX.81,083,608."], [null, "", "", "\uf0b7 Analysis of domestic arrears over the past three years has shown an"], [null, "", "", "upward trend in arrears from UGX.10.4Bn in 2018/19 to UGX.19.4Bn in"], [null, "", "", "2020/21."], [null, "", "", "\uf0b7 I observed that the Ministry had not paid verified domestic arrears worth"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 246, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None", "None"], "type": "table"}}, {"content": "234", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 246, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "UGX.16.743Bn."], [null, "\uf0b7 I noted that the Ministry accrued domestic arrears worth UGX.242Mn"], [null, "during the financial year."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 247, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None"], "type": "table"}}, {"content": [["", "UGX.16.743Bn."], [null, "\uf0b7 I noted that the Ministry accrued domestic arrears worth UGX.242Mn"], [null, "during the financial year."], [null, "\uf0b7 I noted that a total of UGX.159,543,267 paid to service providers and"], [null, "advances to various staff was not adequately supported with"], [null, "accountabilities and supporting documents such as requisitions, receipts,"], [null, "activity reports, minutes of meetings."], [null, "\uf0b7 Payments amounting to UGX.73Mn were advanced to personal accounts"], [null, "of staff to make onward payments to suppliers for services like office"], [null, "internet, hotels, workshop related expenditure, among others."], [null, "\uf0b7 I noted that as of 30th June 2021, several compensations claim worth"], [null, "UGX.165Bn by some Cooperative Societies had not been verified. There"], [null, "was also no evidence that verification teams had been constituted to"], [null, "undertake the verification exercise."], [null, "\uf0b7 Examination of records revealed that for some Cooperatives, the amounts"], [null, "to be paid as compensation for war losses were in excess of the amounts"], [null, "originally claimed by the Cooperatives."], [null, "\uf0b7 I noted that payments amounting to UGX.14Bn were made to persons"], [null, "and law firms other than the beneficiary Cooperative Societies."], [null, "\uf0b7 review of the procurement processes revealed that, for eight (8)"], [null, "procurements valued at UGX.282,626,237, the estimated market prices"], [null, "approved by the Accounting Officer on Form 5, were the same as those"], [null, "quoted by the best-evaluated bidder and subsequently awarded. I"], [null, "observed that the evaluation committee and Contracts committees did"], [null, "not detect the questionable coincidence."], [null, "\uf0b7 The ministry acquired a lease on an already existing lease for land and"], [null, "subsequent loss of funds."], ["8 Uganda National Bureau of Standards. 2020/21 Opinion Unqualified \uf0b7 The Beareau was unable to activate the use of the Digital Tracking System (DTS) to enforce conformity to standards of selected items and claim the associated fees due to absence of an enabling regulation to operationalise the Service. As a result, the Buereau was unable to claim for a total of UGX.13Bn charged on goods and services for conformity stamps issued by the provider towards conformity enforcement. There is a risk of misuse of the amounts involced by the private provider. \uf0b7 The Bureau released 366 consignments without testing due to lack of capacity and another 633 consignments released due to the absence of standards to test these commodities for conformity. Lack of capacity may lead to the release of sub-standard products to the market. \uf0b7 I noted that out of the approved staff structure of 666 positions, the Bureau had only filled 439, leaving a staffing gap of 227 (34 %). As a result, there was staff presence at only 27 out of the 170 border entry points. There is a risk of sub-standard goods entering the country through border points where the Bureau staffs are not present. \uf0b7 It was noted that procurements to the tune of UGX.2.735Bn were not completed as of 30th June 2021. This was attributed to several reasons, including failure to attract competitive bidders for some procruements, delayed submission of clear specifications, especially for specialised equipment, late submissions/ initiations of procurement requisitions by the users, as well as delayed deliveries due to COVID-19 especially for specialised Equipment. Un implemented activities imply that the provision of critical government programs and associated services were delayed.", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 247, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None"], "type": "table"}}, {"content": "235", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 247, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["9", "Uganda Development Corporation (UDC). 2020/21", "\uf0b7 Out of the total funds received of UGX.137.27Bn only UGX.63.39Bn was spent by the entity during the year, resulting into an unspent balance of UGX.73.88Bn representing an absorption level of only 46%. I noted that"], [null, null, "out of the 17 development project activities planned to be implemented"], [null, "Opinion Unqualified", "during the period under review, only (3) three development projects were fully implemented, while Five (5) development projects were partially"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 248, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["9", "Uganda Development Corporation (UDC). 2020/21", "\uf0b7 Out of the total funds received of UGX.137.27Bn only UGX.63.39Bn was spent by the entity during the year, resulting into an unspent balance of UGX.73.88Bn representing an absorption level of only 46%. I noted that"], [null, null, "out of the 17 development project activities planned to be implemented"], [null, "Opinion Unqualified", "during the period under review, only (3) three development projects were fully implemented, while Five (5) development projects were partially"], [null, null, "implemented, Eleven (11) projects were not implemented at all. Failure to"], [null, "", "fully absorb funds by the Corporation, leads to non-achievement of"], [null, null, "development objectives."], [null, null, "\uf0b7 The UDC Act 2016 requires capitalisation of UDC to the tune of"], [null, null, "UGX.500Bn. The same Act also established an Industrial and Economic"], [null, null, "Development Fund which was to be run by the UDC. However, 5 years"], [null, null, "later, the company has never been capitalised to that tune; currently the"], [null, null, "capitalisation grants have accumulated to UGX.311Bn and the Industrial"], [null, null, "and Economic Development Fund has never been operationalized. The"], [null, null, "current funding model, is such that capitalisation grants over the years"], [null, null, "come assigned to specific projects which nullifies the investment appraisal"], [null, null, "process of UDC. This has the disadvantage of earmarking funds for"], [null, null, "investments that are not ready or even viable leading to the low"], [null, null, "absorption noted above."], [null, null, "\uf0b7 An amount of UGX.30.46Bn was invested in various companies by UDC"], [null, null, "during the year without valuation. Shareholding in these companies had"], [null, null, "not been secured by the time of reporting. There is a risk of loss of value."], [null, null, "\uf0b7 Although the UDC Act 2016 provides that the Corporation will take over"], [null, null, "the interest of government in seven entities specified in schedule 2 and to"], [null, null, "manage, promote and facilitate the interest of the government in those"], [null, null, "entities, 5 years later, this had not been done except for Nile Hotel"], [null, null, "Limited. The other entities include: Amber House Limited, Embassy"], [null, null, "House, Development House, Munyonyo Commonwealth Resort, Phoenix"], [null, null, "Logistics and Tri-Star Apparels Limited. There is a risk of loss of strategic"], [null, null, "direction and government may not be aware whether the national"], [null, null, "objectives of import substitution, employment and industrialization are"], [null, null, "being met by these entities."], ["10 Uganda Investment Authority. 2020/21 Opinion Unqualified \uf0b7 The Authority received off-budget financing to a tune of UGX.50.43Bn, which was not transferred to the consolidated fund as required by law. These funds were received directly from development partners to the EPC contractor for the Development of infrastructure at Kampala Industrial and Business Park, Namanve. Off-budget financing distorts planning, may result into duplication of activities and is contrary to the Public finance Management Act 2015. \uf0b7 The approved budget estimates for the Authority for the financial year 2020/2021 indicated that only UGX.22Mn out of UGX.2.411Bn was budgeted towards the settlement of domestic arrears. The arrears balance of UGX.2.389Bn was therefore not budgeted for settlement. Failure to provide resources for the accumulated arrears increases outstanding obligations. \uf0b7 The Authority continued to accumulate domestic arrears with a total of UGX.1.768Bn incurred in the financial year under review, without clearing outstanding arrears from the previous financial year 2019/2020 of UGX.2.411Bn. The total accumulated domestic arrears stood at UGX.4.18Bn at 30th June 2021. This is an indicator of non adherence with the commitment control system of government. \uf0b7 During inspections countrywide, I observed that the industrial parks lack or had inadequate infrastructures like roads, solid waste and sewage", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 248, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "236", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 248, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["management systems, power supply, street lights etc. The Parks have been characterized by encroachment, farming and cattle grazing, degradation of nearby swamps, unallocated land, idle land allocated to unserious investors and misunderstandings between investors and park management staff. Most roads are impassable and with inadequate lighting which exposes the parks to thefts and insecurity. I observed that some factories in the parks have set up their own infrastructure which may not be sustainable, and to the desired standards. This may negatively affect the usage and utilization of the parks. \uf0b7 The Authority lacks regulations required under Section 38(1) of the Investment Code Act to operationalize the statute. This may hinder the smooth implementation of the Act which is meant to create an investment enabling environment. \uf0b7 Although the Authority has 124 approved positions, only 78 (i.e. 62.9%) are filled, leaving 46 (37.1%) vacant positions. Among the vacant positions include 24 unfilled positions that are from the core Directorate of Investment which is the backbone of UIA. Understaffing undermines service delivery.", null, null], ["", "TOURISM SECTOR", "\uf0b7"], ["1 Uganda Hotel and Tourism Training Institute (UHTII) 2020/21 Opinion Unqualified \uf0b7 Management failed to collect tuition fees and accumulated receivables to the tune of UGX.460Mn by close of the financial year, with some debts dating as far back as 2014. I observed that some students who had not cleared fees had completed their studies, graduated and even obtained their certificates rendering such receivables uncollectible. \uf0b7 I noted that the entity had prepared a new strategic plan, but had no proof of certification and approval of its plan by NPA. Management explained that the exercise was interrupted by Covid-19 Lock down and closure of schools. \uf0b7 Out of 175 approved posts for the Institute, only 127 were filled, resulting into a staffing gap of forty-eight (48) positions. Furthermore, seven (7) positions were filled by staff in an acting capacity including the Position of the Principal. Staffing gaps limit the Institute\u2019s ability to effectively deliver the intended services.", null, null], ["2", "Uganda Hotel and Tourism Training Institute. 2019/20", "\uf0b7 I noted that the budget is not aligned to the specific outputs and therefore, I could not analyze the outputs achieved and planned in line with the approved budget."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 249, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "237", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 249, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "Stock cards and Goods Received Notes."], ["3 Uganda Wildlife Education Conservation Centre (UWEC). 2019/20 Opinion Unqualified \uf0b7 Out of the 29 quantified outputs/activities assessed, 20 outputs/activities representing 69% were fully implemented; 4 outputs/activities representing 14% were partially implemented while 5 outputs/activities representing 17% were not implemented at all. \uf0b7 I noted that out of the budgeted NTR of UGX.5,360,000,000; only UGX.3,737,222,734 was collected representing performance of only 70% of the target. \uf0b7 I noted that the construction of the floating restaurant stalled. To date, the project is still at the first-floor stage and has since not been opened to the public. \uf0b7 A review of UWEC records revealed that UGX.6.6million was spent for resurveying the land on which the Centre is located. However, by the time of audit, the title had not been transferred to the Centre\u2019s names.", null, null], ["4", "Uganda Wildlife Research and Training Institute (UWRTI).", "\uf0b7 I observed that out of the budgeted NTR of UGX.435,000,000, only UGX.328,287,026 was collected representing a performance of 75% of the target."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 250, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "Stock cards and Goods Received Notes."], ["3 Uganda Wildlife Education Conservation Centre (UWEC). 2019/20 Opinion Unqualified \uf0b7 Out of the 29 quantified outputs/activities assessed, 20 outputs/activities representing 69% were fully implemented; 4 outputs/activities representing 14% were partially implemented while 5 outputs/activities representing 17% were not implemented at all. \uf0b7 I noted that out of the budgeted NTR of UGX.5,360,000,000; only UGX.3,737,222,734 was collected representing performance of only 70% of the target. \uf0b7 I noted that the construction of the floating restaurant stalled. To date, the project is still at the first-floor stage and has since not been opened to the public. \uf0b7 A review of UWEC records revealed that UGX.6.6million was spent for resurveying the land on which the Centre is located. However, by the time of audit, the title had not been transferred to the Centre\u2019s names.", null, null], ["4", "Uganda Wildlife Research and Training Institute (UWRTI).", "\uf0b7 I observed that out of the budgeted NTR of UGX.435,000,000, only UGX.328,287,026 was collected representing a performance of 75% of the target."], [null, "2019/20 Opinion", null], [null, "Unqualified", ""], [null, null, "procure particular items or pay other staff members yet the funds in"], [null, null, "question, could have been paid directly to the intended final beneficiaries."], [null, null, "\uf0b7 A review of the staffing structures for the UWRTI revealed that, out of"], [null, null, "the total approved structure of 46 staff, only 23 (50%) positions were"], [null, null, "filled while 23 (50%) positions had not yet been filled."], [null, null, "\uf0b7 I noted that several direct procurements amounting to UGX.122,943,179"], [null, null, "were made by the entity without justification for use of the direct"], [null, null, "procurement method."], [null, null, "\uf0b7 I observed that the Governing Council is not fully constituted, since a"], [null, null, "representative of the Academic Board has not been nominated."], ["5 The Handicraft and Souvenir Development Project (HSDP) in Uganda for the year ended 31 st Dec 2020. Opinion Unqualified \uf0b7 I noted that cumulatively a total of USD.940,460.00 had been disbursed to the Project by 31st December 2020, out of which USD.430,916.94 had been utilized, leaving a closing balance of USD.509,543.06 as at 31st December 2020. \uf0b7 It was also noted that no activity had been fully implemented/completed as of the time of this audit as they all remained either partially achieved or not achieved at all.", null, null], ["6", "Nile Hotel 2020/21 Opinion Unqualified", "\uf0b7 I noted that out of the budgeted revenue of UGX.2.041Bn from Concession fees and Investment income from fixed deposits, only UGX.1.191Bn was received, representing a performance of only 58% of the target. Failure to realise all budgeted revenue affects the implementation of planned activities. This was attributed to the effects of"], [null, null, "the COVID19 pandemic on the Tourism sector."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity is not in possession and is not aware of the exact"], [null, null, "whereabouts of the land title to the land on which Serena Hotel Kampala,"], [null, null, "is seated. The land is located on Plot 16-20 Nile avenue measuring 19.3"], [null, null, "acres. The land is listed as part of the assets in the concession agreement"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 250, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "238", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 250, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "that was signed between the Government of Uganda and TPS Uganda"], [null, null, "Limited and was leased by ULC and Nile Hotel International Ltd (NHIL) in"], [null, null, "1995."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 251, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "that was signed between the Government of Uganda and TPS Uganda"], [null, null, "Limited and was leased by ULC and Nile Hotel International Ltd (NHIL) in"], [null, null, "1995."], ["7 Uganda Wildlife Authority. 2020/21 Opinion Unqualified \uf0b7 This being the first year of implementation of the NDP-III, the entity was expected to prepare a strategic plan aligned to NDP III and ensure that the plan was approved. \uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity budgeted to collect NTR of UGX.82.Bn (Exclusive of UGX.30Bn prior-year surplus approved for re-investment during the year under review). \uf0b7 The entity budgeted to receive UGX.6.24Bn from donors, however, UGX.5.74Bn was realized, resulting into a shortfall of UGX.501Mn (8%) of the budget. \uf0b7 The entity budgeted to receive UGX.0.72Bn, out of which UGX.0.762Bn was received, resulting into an excess receipt of UGX.0.042Bn, representing 5.8% of the budget \uf0b7 I noted that Management re-assessed its revenue performance and requested the Board to approve a contingency plan to limit the expenditure of the Authority to only UGX.72.595Bn in line with the reduced revenue collections to finance only priority activities in the original approved budget of UGX.119.469Bn for FY 2020-2021. \uf0b7 I noted that the Authority prepared and submitted all the quarterly reports to the line ministry. However, there were delays in submission of Q1, Q2 & Q4 performance reports due to the effect of the covid-19 pandemic. \uf0b7 I noted decreasing Tourism Revenues due to Covid-19 Effect. \uf0b7 It was observed that the Authority has a total outstanding receivables balance of UGX.3.303Bn in the statement of financial position, of which UGX.2.244Bn are unpaid overdue fees from concessionaires that have been outstanding for more than a year. \uf0b7 It was noted that the entity has outstanding payables of UGX.71.655Bn in the statement of financial position of which UGX.8.422Bn are accrued staff gratuity that becomes due at the end of each staff\u2019s four year contract. \uf0b7 UWA had only disbursed UGX.642,455,690 in respect of revenue sharing for the surrounding communities in Lake Mburo National Park, leaving a balance of UGX.9,697,730,137 un-disbursed. \uf0b7 The Accountabilities of the disbursed grants have not yet been availed by the beneficiary communities through to the district local governments by the time of audit on 3rd November 2021. \uf0b7 I noted that whereas the Human Resource unit is critical in managing staff-related affairs, it is only situated at the headquarters and comprises five (5) staff. \uf0b7 Non-integration of gorilla booking system to the accounting system. \uf0b7 It was noted that most of the Protected Areas in Uganda are currently undergoing ecosystem changes as rangeland infestation by invasive and exotic plant species.", null, null], ["8", "Wildlife Research and Training Institute 2020/21", "\uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity budgeted to collect NTR of UGX.0.495Bn during the year under review. Out of this,"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 251, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "239", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 251, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "only UGX.0.200Bn was collected, representing a performance of 40.6% of"], [null, "Opinion Unqualified", "the target. \uf0b7 The entity budgeted to receive UGX.3.931Bn during the period, out of"], [null, null, "which UGX.2.531Bn was warranted, resulting into a shortfall of"], [null, null, "UGX.1.4Bn, which is 36% of the budget."], [null, null, "\uf0b7 A review of the staffing structure for UWRTI revealed that out of the total"], [null, null, "approved structure of 47 staff, only 23 (49%) positions were filled and 24"], [null, null, "positions (51%) had not yet been filled."], [null, null, "\uf0b7 A review of the procurement files revealed that the Institute awarded"], [null, null, "contracts to various providers totalling UGX.519Mn without carrying out"], [null, null, "market assessments/surveys."], ["9 Uganda Wildlife Education Conservation Centre. 2020/21 Opinion Unqualified \uf0b7 I noted that UWEC is one of the entities affected by the Government rationalisation policy on mergers anticipated to be concluded in 2023. By the time of reporting, discussions on transitional arrangements were ongoing. However, I was not provided with the transitional plans for a smooth merger. Delayed decision making leads to costly mergers and uncertainity amonst the stakeholders. \uf0b7 Five (5) procurements with a total value of UGX.3.239Bn were not implemented as planned due to insufficient release of funds from GOU and the adverse effects of the covid-19 pandemic resulting into delayed service delivery. \uf0b7 Although some electronic equipment and motor vehicles at cost of UGX.331Mn had been fully depreciated as per the previous financial year, they were still in use. Under the circumstances, the benefits accruing from them are not matched with their usage/expenditure. Management explained that the revaluation of assets had started, but COVID \u2013 19 effects hindered the process.", null, null], ["10", "Ministry of Tourism, Wildlife and Antiquities. 2020/21. Opinion Unqualified", "\uf0b7 The entity budgeted to receive UGX.27.408Bn out of which UGX.22.934Bn was warranted, resulting into a shortfall of UGX.4.474Bn which is 16.3% of the budget. This affected implementation of planned activities. I further noted that the Ministry did not seek a revision of its budget and work plan, as provided for by Section 17 (3) of the PFMA 2015, following the revenue shortfall."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 252, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "240", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 252, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 Attention is drawn to Note 19 of the financial statements in which"], [null, null, "management made a provision to reduce the receivable amount from"], [null, null, "UGX.13Bn to UGX.3.2Bn given the preliminary findings by a company"], [null, null, "engaged to assess recoverability of the funds."], ["11 Uganda Tourism Board. 2020/21 Opinion Unqualified \uf0b7 Contrary to Section 45 (3) of the Public Finance and Management Act, 2015, the Board failed to implement procurements worth UGX.2.79Bn which had been indicated in their procurement plan. Unimplemented procurements signify unimplemented activities and therefore delayed service delivery. \uf0b7 Contrary to Section 26 (4) of the PPDA 2003, procurements for stationery worth UGX.1.67Bn were concluded without carrying out market assessments. As a result, I could not establish how the estimated unit cost for these procurements was arrived at, thus implying that the procurements may have been awarded at exorbitant costs. \uf0b7 A review of the Board's establishment structure revealed that 38 posts out of the approved 85 remained vacant during the year, indicating a 45% understaffing level. Most notable among the vacant positions are key staffs like the Director Marketing, Director Quality Assurance, Director Finance and planning, and Manager Human Resource. Inadequate staffing levels not only deprive the entity of the skills required to enhance service delivery but also frustrates segregation of duty.", null, null], ["", "WATER AND ENVIRONMENT SECTOR", "\uf0b7"], [null, null, ""], ["1 Kampala Sanitation Program (KSP) Closure 2020/21 Opinion Unqualified \uf0b7 Contingent Liabilities \uf0b7 A contractor\u2019s global claim of Euros 25,043,073 arising from the contractual obligation of extension of time and causation of delays in project completion which was approved; \uf0b7 A compensation claim of UGX220 Million which is now before the Land Division of the High Court Civil suit No.109 of 2019 and thus the outcome of the compensation claim will be determined by court; \uf0b7 A compensation of UGX1.15 Billion which is now before the Land Division of the High Court HCCS NO. 518 of 2016 and thus the outcome of the compensation claim will be determined by court.", null, null], ["2.", "National Forestry Authority 2020/21", "\uf0b7 The Authority prepared and had its strategic plan for the period 2020/2021 to 2024/2025 approved by the Board, however there was no certification from NPA."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 253, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "241", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 253, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "was not implemented at all."], [null, null, "\uf0b7 I noted a significant receivables balance of UGX 8,268,255,693 at close of"], [null, null, "the financial year which impacts the liquidity capacity of the Authority."], [null, null, "\uf0b7 There were irregularities in forest land utilization with four (4) unlicensed"], [null, null, "Central Forest Reserves (one in Kajansi and three in Lutoboka) and 24"], [null, null, "non-complying developers in CFRs."], [null, null, "\uf0b7 I noted irregularities in forest land utilization, inactive private tree"], [null, null, "planters in CFRs, non-operationalisation of the Tree Fund, Out-dated"], [null, null, "Forest Reserve Management Plans and major encroachment on CFRs."], ["3 Uganda National Meteorological Authority (UNMA). 2020/21 Opinion Unqualified \uf0b7 The Authority collected NTR of UGX 317,259,177 out of the estimated UGX 1,259,080,696 representing a performance of 25.2%. \uf0b7 Out of the budgeted revenue of UGX 26,675,604,875, only UGX 19,025,934,156 was realized representing performance level of 71.3% of the target. Out of UGX 19,025,934,156 warranted, UGX 17,970,307,440 was absorbed by the authority leaving unspent balance of UGX 1,295,279,000 representing 94.5% absorption level. \uf0b7 The Authority received off-budget financing of UGX. 668,042,740 \uf0b7 Five (5) outputs with a total of twenty-eight (28) activities and expenditure worth UGX 5,094,648,000 were fully quantified, while Three (3) outputs with a total of thirty-seven (37) activities and expenditure worth UGX 2,682,683,000 were insufficiently quantified. \uf0b7 Of the 5 outputs with 28 fully quantified activities, 7 activities (25%) were fully implemented, 10 activities (35.7%) were partially implemented, while 11 activities (39.3%) remained unimplemented. \uf0b7 There was delayed completion of the Radars in Mwizi-Rwampara and Lira due to the restrictions of Covid 19 lockdown. \uf0b7 The average functionality of all the weather stations is at 89% instead of the desired 100% resulting from the non-functional meteorological equipment.", null, null], ["4", "Investment plan preparation grant for the strategic plan for climate resilience.", "\uf0b7 Two out of the three (3) sub objectives of the Project, were fully achieved while the third objective of building capacity of both national and subnational stakeholders in the management of climate change disasters was partially achieved."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 254, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "242", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 254, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "were not remitted to the Uganda Revenue Authority."], ["5 Integrated Water Management and Development Project- NWSC 2020/21 Opinion Unqualified \uf0b7 No material findings to report.", null, null], ["6", "National Water and Sewerage Corporation- Kampala Water Lake Victoria Water and Sanitation (KW-LV WATSAN", "\uf0b7 I noted that NWSC delayed to pay the Contractor and as a result, the contractor claimed for interest of Euros 141,968 approximately UGX.610 Million. I also noted changes in the scope of the contract which resulted into a contract variation of Euros 612,000 (approximately UGX 1.4 Billion)."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 255, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "were not remitted to the Uganda Revenue Authority."], ["5 Integrated Water Management and Development Project- NWSC 2020/21 Opinion Unqualified \uf0b7 No material findings to report.", null, null], ["6", "National Water and Sewerage Corporation- Kampala Water Lake Victoria Water and Sanitation (KW-LV WATSAN", "\uf0b7 I noted that NWSC delayed to pay the Contractor and as a result, the contractor claimed for interest of Euros 141,968 approximately UGX.610 Million. I also noted changes in the scope of the contract which resulted into a contract variation of Euros 612,000 (approximately UGX 1.4 Billion)."], [null, "I) PROJECT 2020/21", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["7 NATIONAL ENVIRONMENT MANAGEMENT AUTHORITY Opinion Unqualified \uf0b7 The Authority collected NTR of UGX.8,084,594,955 (50.2%) against the estimated UGX.16,088,769,336 as projected by Ministry of MOFPED. However, there were no NTR estimates indicated in the statement of appropriation. \uf0b7 Out of the budgeted GoU revenue of UGX.25,555,655,669 by the Authority, only UGX 18,809,799,829 was warranted representing performance of 73.6% of the target. \uf0b7 I noted that out of the UGX.18,809,799,829 released to the Authority, only UGX.18,494,875,926 was spent representing an absorption level of 98.3%. Subsequently, the unspent funds amounting to UGX.314,923,903 were swept back to the Consolidated Fund. \uf0b7 The Authority received off-budget funding to the tune of UGX.1,963,413,072 and USD 2,805,651,484 which were not appropriated as required by the law. \uf0b7 9 (69%) of the 13 activities (against which UGX 9,707,487,720 was released) were fully implemented and 4 (31%) of the activities were partially implemented. \uf0b7 Contrary to the directive from the Ministry of Finance, during the financial year a total of UGX 441,857,268 was deposited directly into the National Environment Fund (NEF) account as NTR and this amount was not remitted to the consolidated fund. \uf0b7 The Authority does not have any legal provision to regulate the work of the Environment Police. In addition, the funds to facilitate the work of the force were not budgeted for in the annual work plan and budget. Financial records indicate that only UGX.21,280,000 was spent on the force during the year. \uf0b7 I noted that all the wetlands in Uganda are not gazetted, contrary to Section 2 of the National Environment Act 2019, although they are indicated on the maps. In addition, contrary to Instrument 2 of the Nation Environment Act, 2019 (Commencement) that empowers the Authority to enforce wetland gazetting, the Authority went ahead to collect NTR from wetland user permits amounting to UGX 8,800,000", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 255, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "243", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 255, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["during the financial year 2020/21.", null, null], ["8", "Strategic Towns Water Supply and Sanitation Project. 2020/21", "\uf0b7 Out of the total budget of UGX 40 Bn for the financial year, only UGX 19.24 Bn was received representing a performance level of 48%. Out of the amount received, UGX.18.88 Bn was spent during the year representing an absorption level of 98.13%."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 256, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["during the financial year 2020/21.", null, null], ["8", "Strategic Towns Water Supply and Sanitation Project. 2020/21", "\uf0b7 Out of the total budget of UGX 40 Bn for the financial year, only UGX 19.24 Bn was received representing a performance level of 48%. Out of the amount received, UGX.18.88 Bn was spent during the year representing an absorption level of 98.13%."], [null, "Opinion Unqualified", null], ["9 Irrigation for Climate Resilience Project 2020/21 Opinion Unqualified \uf0b7 Out of the budgeted revenue of USD 13,641,026, only USD 6,305,937 (46.2%) was realized representing performance level of 46.2% of the target. Out of USD 6,305,917, disbursed, there was no absorption by the project as at close of the financial year. \uf0b7 Twenty-two (22) outputs with a total of thirty three (33) activities and budget of USD 13,641,026 were fully quantified as required. Out of 22 outputs with a total of 33 activities, only 1 activity (3%) was fully achieved, 27 (82%) were partially achieved and 5 activities (15%) were not implemented at all.", null, null], ["10", "Enhancing Resilience of Communities to Climate Change (EURECCCA)", "\uf0b7 At the end of the initial project completion date of 30th April 2021, all the four project components had been partially achieved and thus, the project completion date was extended to 30th April 2022."], [null, "2020/21 Opinion Unqualified", null], [null, "", ""], [null, null, "quantified to enable assessment of performance and enhance"], [null, null, "accountability. Out of the 42 planned activities 19 (45.2%) were fully"], [null, null, "implemented, 22 (52.4%) were partially implemented and 1(2.4%) was"], [null, null, "not implemented at all."], ["11 Nyabyeya Forestry College (NFC) Opinion Unqualified \uf0b7 The College does not have an approved strategic plan for the period 2021-202 and lacks an enabling law that stipulates its mandate. There is a risk that activities implemented during the financial year 2020/2021 were not aligned to the NDP-III, which negatively affects the achievement of the National Development objectives \uf0b7 Out of the total receipts of UGX 2,753,839,117 for the financial year, UGX 2,911,962,444 was spent resulting into an over expenditure of UGX 158,123,327 representing an absorption level of 106%. The over absorption of funds was due to the opening balances for civil works executed even during the Covid-19 lockdown. \uf0b7 I noted a decline in students\u2019 enrolment from 431 students in 2016/17 to 256 students in 2020/21. Continued fall in enrolment may result in the College\u2019s failure to achieve its mandate of producing technical human resource in forestry and related natural resources through training.", null, null], ["12", "Farm Income Enhancement and Forestry Conservation Project Phase II (FIEFOC", "\uf0b7 The Project has not fully achieved the three project subcomponents of Agriculture Infrastructure Development, Agribusiness Development and"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 256, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "244", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 256, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "II).", "Integrated Natural resources Management which had been set to be"], [null, "2020/21", "achieved by 30/06/2021."], [null, null, "\uf0b7 The project had an approved annual budget of UGX 111,249,503,000 out"], [null, "Opinion", "of which UGX 63,414,586,000 (57%) was received leading to a shortfall of UGX 47,834,917,000. \uf0b7 Out of the total funds received of UGX 63,414,586,000, a total of UGX"], [null, "Unqualified", null], ["13 Integrated Water Management and Development Project (IWMDP) 2020/21 Opinion Unqualified \uf0b7 Out of the approved budget of UGX 70,327,857,900, UGX.52,949,933,856 (75.3%) was availed for spending leading to a shortfall of UGX.17,377,924,044. Out of the total funds available for the financial year of UGX.52,949,933,856, UGX.20,830,393,625 was spent representing an absorption level of only 39.3%. \uf0b7 Fifteen (15) outputs with a total of twenty-seven (27) activities and expenditure worth UGX.14,957,387,000 were fully quantified, while one (1) outputs with one (1) activity was inadequately quantified. \uf0b7 Of the 15 outputs with 27 fully quantified activities, 2 out puts (13%) were fully implemented, 6 out puts (40%) were partially implemented while 7 out puts (47%) were not implemented. \uf0b7 Review of the project appraisal document, the monitoring and results framework analysis report of October 2021 together with annual progress reports revealed that the rate of achievement of project targets is slow as a result of procurement delays.", null, null], ["14", "Northern Uganda Resilience Initiative Project 2020/21", "\uf0b7 Out of the total rolled over funds of UGX.1,520,434,217 from the previous financial year, the project spent UGX.1,055,516,512 (69%) leaving an unspent balance of UGX.464,917,705 (31%). \uf0b7 Out of the 17 planned activities for the financial year 2020/2021, only 2 activities were quantified as required leaving 15 activities unquantified."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 257, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "245", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 257, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["15 Third National Communication (TNC) 2020/21 Opinion Unqualified \uf0b7 Out of an approved budget of USD.173,474, USD.83,000 was disbursed representing a performance level of 47.8% of the target. \uf0b7 Out of the total available funds for the year of US$ 92,304.34, the project spent US$ 60,493.32 representing an absorption level of 65.6%. As a result some activities were not implemented. \uf0b7 All the 16 outputs with a total budget of USD.173,474 and actual expenditure of 60,555.97 were not quantified at all.", null, null], ["16", "Water Supply and Sanitation on Refugee Hosting Communities in", "\uf0b7 Out of the Project budget of UGX. 20,868,100,000, a sum of UGX 9,204,079,893 was disbursed by the donor, representing a performance level of 44.1% of the target."], [null, "Northern Uganda Funded By (Kfw) Project KfW 2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 258, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["15 Third National Communication (TNC) 2020/21 Opinion Unqualified \uf0b7 Out of an approved budget of USD.173,474, USD.83,000 was disbursed representing a performance level of 47.8% of the target. \uf0b7 Out of the total available funds for the year of US$ 92,304.34, the project spent US$ 60,493.32 representing an absorption level of 65.6%. As a result some activities were not implemented. \uf0b7 All the 16 outputs with a total budget of USD.173,474 and actual expenditure of 60,555.97 were not quantified at all.", null, null], ["16", "Water Supply and Sanitation on Refugee Hosting Communities in", "\uf0b7 Out of the Project budget of UGX. 20,868,100,000, a sum of UGX 9,204,079,893 was disbursed by the donor, representing a performance level of 44.1% of the target."], [null, "Northern Uganda Funded By (Kfw) Project KfW 2020/21 Opinion Unqualified", null], ["17 Uganda National Redd - Plus Support Project Opinion Unqualified \uf0b7 The project had 2 sub components which had not been fully achieved. \uf0b7 The project had an approved revenue budget of USD.644,500 for the year under review but only USD.250,000 (38.8%) was disbursed. \uf0b7 Out of the total funds available for spending of USD.475,919.18, only USD.249,763.51 (52.18%) was spent leaving an unspent balance of $ 226,155.67 (48.82%). As a result certain activities were not implemented. \uf0b7 All the 10 outputs comprising 57 activities with a total budget of USD.2,210,799 were properly quantified. \uf0b7 The draft progress report was not detailed to enable assessment of implementation of activities against planned.", null, null], ["18", "Ministry of Water, and Environment (MoWE) 2020/21", "\uf0b7 I noted that the entity had not prepared a specific strategic plan as required by the NDP III and was instead utilizing an Investment plan (2030). \uf0b7 I noted that out of the estimated NTR collection of UGX 8.97 billion, only UGX1.39 Bn was realized, representing a performance of 15.5%."], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 Out of the total receipts for the financial year of 452.01 Bn, a sum of"], [null, null, "UGX. 453.24 Bn was spent by the entity resulting in an unspent balance"], [null, null, "of UGX 5.58 Bn, representing an absorption level of 98.7%."], [null, null, "\uf0b7 As a result of the under absorption, I noted that of the 72 quantified"], [null, null, "activities worth UGX.388.26Bn assessed; 15 activities representing 27.3%"], [null, null, "were fully implemented, 38 activities representing 69.1% were partially"], [null, null, "implemented,2 activities representing 3.6% were not implemented .I"], [null, null, "further noted that there was delayed submission of performance reports."], [null, null, "\uf0b7 The Ministry incurred penal interest of UGX.103,632,504 (USD.32,218)"], [null, null, "arising from delayed payment to the contractor."], [null, null, "\uf0b7 I noted that the Ministry\u2019s Payables amount significantly increased from"], [null, null, "UGX.64.3 billion in the previous year to UGX.114.5 billion in the current"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 258, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "246", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 258, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "year due to the increasing number of multi-year projects in the ministry."], [null, null, "\uf0b7 I noted that the Ministry\u2019s Receivables amount significantly increased"], [null, null, "from UGX.1.3 million in the previous year to UGX.22.4 billion in the"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 259, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "year due to the increasing number of multi-year projects in the ministry."], [null, null, "\uf0b7 I noted that the Ministry\u2019s Receivables amount significantly increased"], [null, null, "from UGX.1.3 million in the previous year to UGX.22.4 billion in the"], [null, null, "current year. This was attributed to prepayments made to contractors"], [null, null, "(UGX.19.3 billion) and the outstanding letters of credit (UGX.3.1 billion)"], [null, null, "for on-going projects in the Ministry."], [null, null, "\uf0b7 From my audit and field inspection of facilities, regional centres and"], [null, null, "Umbrella Organisations, I observed several weaknesses in service delivery"], [null, null, "such as; untitled land for piped water systems and schemes; delayed"], [null, null, "execution of works; outstanding revenue arrears; unmetered water"], [null, null, "schemes, Lack and faulty bulk meters; among others."], ["19 Support to Priority Irrigation Investments in Uganda Grant 2020/21 Opinion Unqualified \uf0b7 All the budgeted revenue from Government of USD.949,422.62 was realised representing a performance of 100% of the target. \uf0b7 Out of the donar funds of USD.949,422.62 received, only USD 117,475.04 was absorbed by the project representing an absorption level of 12.4%. The Under absorption was attributed to Covid-19 effects. \uf0b7 All the Six (6) outputs with a total of six (6) activities and expenditure of USD.117,475.04 were fully quantified. \uf0b7 Four (4) out of six (6) outputs had not been achieved despite the fact that the initial Project completion period had been 30thJune 2020. This was later extended to 30/06/2021 and another extension to 31/3/2022.", null, null], ["20", "The Adapting to Climate Change In Lake Victoria", "\uf0b7 Out of the budgeted revenue of USD.249,377, only USD.194,645.56 was received representing performance level of 78% of the target."], [null, "Basin. 2020/21 Opinion", null], [null, "Unqualified", ""], [null, null, "were fully achieved, 2 activities (18.2%) were partially achieved and 4"], [null, null, "activities (36.3%) were not implemented at all."], ["21 South Western Cluster Water and Sanitation Project \u2013 NWSC 2020/21 Opinion Unqualified \uf0b7 No material issues to report on", null, null], ["22", "National Water and Sewerage Corporation (NWSC) 2020/21 Opinion Unqualified", "\uf0b7 The financial statements under Note 28 include a Financial Asset in form of Trade Receivables. Management has estimated the fair value of the net financial asset receivable to be UGX 133.7 billion as at 30th June 2021 of which, the net amount of receivables UGX38.2bn is owed from"], [null, null, "the government and its MDA (Ministries; Departments and Agencies). \uf0b7 I noted that NWSC leased vehicles, offices and land under operating lease"], [null, null, "contracts whose terms were more than twelve (12) months, which were classified as; Right of Use asset amortization (UGX 87.8m) Right of Use"], [null, null, "Lease Assets (UGX 12.4bn) and Obligations due to Right of Use Leased"], [null, null, "Assets (UGX 8.4bn). Liabilities were not amortised annually using"], [null, null, "effective interest method in order to arrive at the amortised costs for"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 259, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "247", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 259, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "profit and loss recognition although the necessary disclosures were made"], [null, null, "in the financial statements."], [null, null, "\uf0b7 I noted that freehold land (UGX. 176.5bn) and leasehold land (UGX. 4bn)"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 260, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "profit and loss recognition although the necessary disclosures were made"], [null, null, "in the financial statements."], [null, null, "\uf0b7 I noted that freehold land (UGX. 176.5bn) and leasehold land (UGX. 4bn)"], [null, null, "included some land that had expired lease periods, some titles were not"], [null, null, "yet transferred in the names of NWSC, and Katosi, which is a long term"], [null, null, "investment constructed on a short term leased land of ten (10) years."], [null, null, "\uf0b7 Some on-going water projects were significantly delayed by litigations"], [null, null, "and substantial amounts that are required to compensate the interested"], [null, null, "parties in note 24 of the financial statements."], ["23 Multinational Lakes Edward and Albert Integrated Fisheries and Water Resources Management Project (LEAF) II 2020/21 Opinion Unqualified \uf0b7 A total of six (6) strategic outputs (50%) were fully achieved, while 6 outputs were partially achieved and still on-going (50%). \uf0b7 Out of the approved budgeted revenue of USD 1,887,374, USD 603,588.93 was released representing performance of 32% of the target. \uf0b7 The project had a total available balance of USD 2,767,452.2, out of which USD 2,754,945.85 (99.5%) was spent leading to an unspent balance of only USD 12,506.35. \uf0b7 All the 10 planned outputs with 39 activities and a total budget of USD 3,119,412.9 were properly quantified to enable measurement of performance. \uf0b7 Out of the 39 planned activities under the 3 Project components, 19 (48.7%) were fully implemented, 10 (25.6 %) were partially implemented and 10 (25.6%) were not implemented at all. \uf0b7 I noted delays in construction of infrastructure projects resulting from the effects of the Covid pandemic and effects of the rising water level of Lakes Albert and Edward and inadequate GoU funding. The projects affected included the construction of the surveillance station, Kitebere Landing Site, Mbegu landing site, fish processing facility at Dei Landing site, and supply of a fisheries research vessel.", null, null], ["", "ENERGY SECTOR", "\uf0b7"], ["1 Electricity Regulatory Authority (ERA) 2020/21 Opinion Unqualified \uf0b7 I noted that out of the budgeted revenue of UGX 28.57Bn, a sum of UGX. 27.70Bn was realized representing a performance of 98%. \uf0b7 Out of the revenue realized of UGX. 27.70Bn for the financial year, UGX 24.55Bn was spent on recurrent expenditure and UGX.2.25Bn on capital expenditure, resulting into an unspent balance of UGX.0.9Bn, representing absorption level of 97%. \uf0b7 Out of the forty-six (46) key activities, sixteen (16) (35%) activities had been fully achieved, and thirty (30) (65%) were partially achieved. \uf0b7 Included in the receivables figure of UGX.7,566,003,960, under Note 7 of the Financial Statements is a sum of UGX.724, 185,509, relating to license fees and permit fees which have been outstanding for more than 90 days instead of the recommended 14 days. \uf0b7 I noted that the target of reduction of the end user tariff was not achieved across customers\u2019 categories, with a weighted average of UGX.485.7 per Kwh. The end user off \u2013peak tariff for extra- large industrial customers was achieved at UGX.223.7. \uf0b7 I noted that out of the total staff establishment of 92 positions, only 67 (73%) positions had been filled leaving a balance of 25 (27%) positions vacant.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 260, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "248", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 260, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted Non-compliance to Quality-of-Service Standards (QoS) by Distribution Licensees, with an average of 45% compliance. Non- compliance with QoS denies customers quality and reliable electricity supply.", null, null], ["2", "Energy for Rural Transformation III PSFU Project (ERT III). 2020/21", "\uf0b7 Out of the total Receipts for the financial year of USD. 636,993, only USD.382,224 was spent by the Project resulting in an unspent balance of USD. 254,769 representing absorption level of 60% for the year. As a result, activities such as training of certified wiremen was partially implemented."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 261, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["\uf0b7 I noted Non-compliance to Quality-of-Service Standards (QoS) by Distribution Licensees, with an average of 45% compliance. Non- compliance with QoS denies customers quality and reliable electricity supply.", null, null], ["2", "Energy for Rural Transformation III PSFU Project (ERT III). 2020/21", "\uf0b7 Out of the total Receipts for the financial year of USD. 636,993, only USD.382,224 was spent by the Project resulting in an unspent balance of USD. 254,769 representing absorption level of 60% for the year. As a result, activities such as training of certified wiremen was partially implemented."], [null, "Opinion Unqualified", null], ["3 Uganda Rural Electricity Access Project (UREAP). 2020/21 Opinion Unqualified \uf0b7 Out of the Budget of UGX.157.4Bn, only UGX.106Bn was disbursed representing a shortfall of 51,339,828,177, which is 32.6% of the Budget. I further noted that out of the total receipts for the financial year of UGX. 106.1Bn, UGX.105.5Bn was utilized on installation of Medium Voltage Networks and Last Mile consumer connections, leaving an unutilized balance of UGX.564,461,546 representing an absorption level of 99.5%. \uf0b7 As 30th June 2021, the Bank had disbursed USD.44.83Million and Euros 5.89Million against the Loan credit facility of USD.100 Million and Grant of Euros 11.205 Million representing 45% and 53%, respectively. \uf0b7 I noted delays in construction works under procurement of plants, design, supply and installation of medium voltage networks and last mile consumer connections. Notably, under Lots 6, Medium Voltage stringing, and Low Voltage (LV) stringing had not yet commenced. Under Lot 7 Medium Voltage Pole erection was at 31% and stringing at 47%. \uf0b7 Out of 1,686 Project Affected Persons (PAPs), with an approved compensation amount of UGX.1,240,502,500, only 1,209 PAPs have been paid an amount of UGX.863,758,500, leaving an outstanding amount of UGX.376,744,000 relating to 477 PAPs.", null, null], ["4", "Lira-Gulu-Agago 132KV transmission project 2020/21 Opinion", "\uf0b7 Out of the total Receipts for the financial Year of USD. 2,304,191, only USD.519,117 was utilized by the Project, resulting in an unspent balance of USD.1,785,074, representing an absorption rate of only 22.5%. As a result, activities such as compensation of Project Affected Persons and supervision of EPC works were not implemented."], [null, "Unqualified", null], ["5 Energy for Rural Transformation III (ERT III) \u2013REA Project. 2020/21 Opinion Unqualified \uf0b7 Out of the total receipts for the financial year of UGX.139.5Bn, only UGX.98.3Bn was utilized on installation of Medium Voltage Networks and Last Mile consumer connections, leaving an unutilized balance of UGX 41.2Bn representing an absorption level of 70%. As a result, activities such as Grid extensions, Line connections and Grid Intensification schemes under various Lines were partially implemented. \uf0b7 Out of the total credit amount of USD.116.1 Million, only USD.73.7 Million", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 261, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "249", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 261, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["had been disbursed by the Bank under ERT- REA representing 64% of the Total credit. \uf0b7 The overall Implementation of the Grid extension and associated connections is behind schedule especially under Lines 20-21 which are at 17% and 2% respectively. Progress of work under Grid Intensification, UMEME Batch 1 and 2 were at 55% and 20% respectively. \uf0b7 Out of 34,535 Project Affected Persons (PAPs), with an approved compensation amount of UGX. 22.6Bn, only 22,180 PAPs have been compensated with an amount of UGX.14.2Bn, leaving an outstanding amount of 8.3Bn relating to 12,355 PAPs.", null, null], ["6", "Hoima Kafu Transmission Line Project - Kafu Interconnection Project. 2020/21", "\uf0b7 Out of the total receipts for the financial year, of USD.1,903,946, only USD.41,960 was spent by the Project, resulting in an unspent balance of USD.1,861,986, representing absorption level of only 2.2%. As a result, activities such as compensation of Project Affected Persons were not implemented."], [null, "Opinion Unqualified", null], ["7 Kampala Metropolitan Transmission System Improvement Project. 2020/21 Opinion Unqualified \uf0b7 Out of the total receipts for the financial year of USD.9,259,009 for the financial year, only USD.2,465,150 was spent by the Project, leaving an unspent balance of USD.6,793,859, representing absorption of rate of 26.6%. As a result, I noted that Key activities such as consulting Services for Procurement of the EPC contractor was not implemented, while compensation of projected affected persons was partially implemented. \uf0b7 I noted that out of 130 PAPs, 109 (83%) were compensated. Disclosures made were 120 (91%), agreements obtained from disclosures were 117 (89%), and PAPs not yet compensated were 22 (16.7%).", null, null], ["8", "Petroleum Authority of Uganda (PAU). 2020/21", "\uf0b7 I noted that the Authority budgeted to receive UGX.63.61Bn out of which only UGX.52 Bn was warranted, resulting in a shortfall of UGX11.6Bn, which is 18% of the budget."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 262, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "250", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 262, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "sector. These include; the air quality standards, noise and vibration and"], [null, null, "the chemicals management standards."], ["9 Grid Expansion and Reinforcement Project (GERP)-UETCL. 2020/21 Opinion Unqualified \uf0b7 Out of the total Receipts for the financial year of USD.35,395,297, only USD.6,139,307 was spent by the project leaving an unspent balance of USD.29,255,991, representing absorption of rate of 17.3%. As a result, activities such as construction of Transmission Lines and compensation of Project affected Persons were partially implemented. \uf0b7 Out of the total amount of IDA credit for the Project of USD.100,000,000 only USD.29,457,000(29.4%) was disbursed, and out of USD.27.3M GoU counterpart funding, 7,945,423 (28.9%) was disbursed by the end of the financial Year. \uf0b7 Out of the annual target of 59% progress, under Lot 1; -Construction of 132kv Double Circuit Transmission Lines, only 39% was achieved. Out of a target of 47% progress under Lot 2- construction of Substations, only 20% was achieved. \uf0b7 I noted that out of 2,340 identified PAPs under Gulu-Nebbi-Arua Section, only 1,719 (73%) had been compensated. Out of 994 PAPs under Kole- Gulu Section 985 (99%) were compensated, leaving a total of 630 PAPs not compensated by the time of audit. In addition to the 3,334 PAPs with a total cash resettlement of USD. 1,463,955.41, USD.1,241,137 was paid to 2,704 PAPs resulting into an outstanding obligation of USD.222,818 relating to 630 PAPs", null, null], ["10", "Islamic Development Bank (IDB) III Grid Rural Electrification Project.", "\uf0b7 Out of the total Loan credit of USD.70,730,000 Million by the Islamic Development Bank, USD 69,764,722.91 was disbursed representing a performance of 99% of the total Loan facility."], [null, "2020/21 Opinion Unqualified", null], ["11 Uganda Petroleum Fund (UPF). Opinion Unqualified \uf0b7 I noted that for the year under review, the balance in the Petroleum Fund increased from UGX.87.79Bn as at 30th June 2020 to UGX. 228.79Bn as at 30th June 2021. However, there was no appropriation of UGX. UGX.87.79Bn by during the Financial Year 2020/21 to the Consolidated Fund and/or the Petroleum Revenue Investment Reserve for budget support and investment activities, respectively.", null, null], ["12", "Uganda Electricity Generation Company Limited (UEGCL)", "\uf0b7 Out of the budgeted revenue of UGX.173,191,277,000, for the year 2020/21, UGX.169,743,586,000 was realized representing performance of 98% of the target."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 263, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "251", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 263, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, null, "for Karuma Hydro Power Plant was outstanding as at 30th June, 2021."], [null, null, null, "\uf0b7 There has been delayed commissioning of Karuma Dam, whose"], [null, null, null, "completion date was extended to 15th June 2022, resulting in a delay of"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 264, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None", "None"], "type": "table"}}, {"content": [["", null, null, "for Karuma Hydro Power Plant was outstanding as at 30th June, 2021."], [null, null, null, "\uf0b7 There has been delayed commissioning of Karuma Dam, whose"], [null, null, null, "completion date was extended to 15th June 2022, resulting in a delay of"], [null, null, null, "3 years and 6 months from the initial planned completion date."], [null, null, null, "\uf0b7 Instances of non-conformances (NC) were noted in relation to electrical,"], [null, null, null, "mechanical and civil works components that required rectification before"], [null, null, null, "commissioning of the Karuma Dam."], [null, null, null, "\uf0b7 There has been continuous extension of the Isimba Dam Defects Liability"], [null, null, null, "Period (DLP), due to the various snags and defects that were detected"], [null, null, null, "after the Dam\\`s commissioning on March 2019."], [null, null, null, "\uf0b7 I noted delayed commencement of the Construction of Muzizi Hydro"], [null, null, null, "Power Project whose credit facility agreement with Agence Francaise De"], [null, null, null, "Development (AFD) and KFW was signed on 9th December 2016 and"], [null, null, null, "25th November, 2016, respectively, to finance the construction of Muzizi"], [null, null, null, "Hydro Power Project with expected completion date of December 2023."], [null, null, null, "\uf0b7 I noted delayed Compensation of Project Affected Persons (PAPs) for"], [null, null, null, "Muzizi HPP whereby a total of UGX.1,769,227,282 (36.41%) of the total"], [null, null, null, "compensation value UGX.4,858,711,140 has been paid to PAPs."], [null, null, null, "\uf0b7 I also note a failure to undertake remedial works on the plants being"], [null, null, null, "handled under the concession between GOU and ESKOM with less than"], [null, null, null, "50% of the remedial works that have been carried out currently, with a"], [null, null, null, "few months to end of the concession."], ["13 Strengthening the Management of Oil and Gas Programme (SMOGP) 2020/21 Opinion Unqualified \uf0b7 Out of the total receipts for the financial year of USD 790,580.38, only USD. 239,221.92 was spent by the Programme resulting in an unspent balance of USD 551,358.46, representing an absorption level of 30.2%. Under absorption of released funds results in non-implementation of planned activities. \uf0b7 I noted that the Planned Programme activities such as Development of Reservoir Modelling and Simulation, Review of the Tax Laws and the Model Production Sharing Agreement Training course for Component Managers and Program Secretariat among others were not implemented. There is a risk of failure to achieve intended Programme objectives and service delivery due to delayed implementation of activities.", null, null, null], ["14 15", "Mutundwe-Entebbe 132kv Double Circuit Transimssion Line Project - UETCL- June", null, "\uf0b7 I noted delays in transfer of titles, caused by the slow land titling process. Out of the expected 463 land titles, UETCL received 264, and 70 were handed over to the RAP Consultant."], [null, "2020", null, null], [null, "Opinion", null, ""], [null, "Unqualified", null, ""], [null, null, null, "consultant such as inclusion of forest reserves and wetlands as part of"], [null, null, null, "compensation to private individuals anddivergent surcey and valuation report for the same property."], [null, "", "", "\uf0b7 Out of the total receipts for the financial year of UGX. 64.97Bn, a sum of UGX 63.38Bn was spent by the entity resulting in an unspent balance of UGX 1.52Bn representing absorption level of 97.6 %. \uf0b7 I noted un-reconciled receivables amount of UGX.70.1Bn resulting from the withheld funds by UMEME from the Escrow Account in regard to unpaid government electricity bills by MDAs."], [null, "", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 264, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None", "None"], "type": "table"}}, {"content": "252", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 264, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Unqualified \uf0b7 I noted power evacuation liability of UGX.15.29Bn, payable to UETCL. This was due to power losses attributed to absence of transmission lines to evacuate electricity from PA Technical, Siti 1 and Arpe Power Plants, as a result of wheeling power over a lower capacity and weaker distribution lines operated by UEDCL. \uf0b7 The long outstanding receivable resulting from payment of former UEB pension costs of UGX.38.6Bn by UEDCL which has never been paid back to the Company by MoFPED. \uf0b7 Failed to meet its targeted annual connection 37,293 of customers whereby only 6,309 (16.9%) connections were made. \uf0b7 I noted that in the FY 2020/21, the approved energy loss target by the Electricity Regulatory Authority was at 20.1%. I however noted from the Grid Energy Reports submitted to ERA, that the Company was unable to meet its target energy losses and most of its service territories registered an average of 32.7% power losses. \uf0b7 I noted non -compliance by the WENRECO to the terms of the Operation and Maintenance Agreement, such as provision of semi-annual reports on status of the assets, safe storage of UEDCL connection materials, participation in the physical network inspection, submission of asset modifications register among others. \uf0b7 The 62,944 poles leased to UMEME by UEDCL were damaged and required replacement which was not done contrary to the provisions of the Lease Agreement.", null, null], ["16", "Uganda National Oil Company 2020/21", "\uf0b7 Out of the total receipts for the financial year of UGX.34.4bn only UGX 26.6bn was spent by the company, resulting in an unspent balance of UGX 7.8bn. This represents an absorption level of 77.3%."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 265, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["Unqualified \uf0b7 I noted power evacuation liability of UGX.15.29Bn, payable to UETCL. This was due to power losses attributed to absence of transmission lines to evacuate electricity from PA Technical, Siti 1 and Arpe Power Plants, as a result of wheeling power over a lower capacity and weaker distribution lines operated by UEDCL. \uf0b7 The long outstanding receivable resulting from payment of former UEB pension costs of UGX.38.6Bn by UEDCL which has never been paid back to the Company by MoFPED. \uf0b7 Failed to meet its targeted annual connection 37,293 of customers whereby only 6,309 (16.9%) connections were made. \uf0b7 I noted that in the FY 2020/21, the approved energy loss target by the Electricity Regulatory Authority was at 20.1%. I however noted from the Grid Energy Reports submitted to ERA, that the Company was unable to meet its target energy losses and most of its service territories registered an average of 32.7% power losses. \uf0b7 I noted non -compliance by the WENRECO to the terms of the Operation and Maintenance Agreement, such as provision of semi-annual reports on status of the assets, safe storage of UEDCL connection materials, participation in the physical network inspection, submission of asset modifications register among others. \uf0b7 The 62,944 poles leased to UMEME by UEDCL were damaged and required replacement which was not done contrary to the provisions of the Lease Agreement.", null, null], ["16", "Uganda National Oil Company 2020/21", "\uf0b7 Out of the total receipts for the financial year of UGX.34.4bn only UGX 26.6bn was spent by the company, resulting in an unspent balance of UGX 7.8bn. This represents an absorption level of 77.3%."], [null, "Opinion Unqualified", null], ["17 Uganda Refinery Holding Company Ltd 2020/21 Opinion Unqualified \uf0b7 Out of a total of UGX 2.9bn received during the financial year, UGX.2.9bn was spent by the Company. This represents an absorption level of 100%. \uf0b7 I noted delays in the development of the Kabaale Industrial Park. As at 30th June 2021, implementation of infrastructure such as roads, power supply, water supply and Information Communication Technology connection had not yet commenced. \uf0b7 I noted delays in the implementation of the Refinery Project. As at 30th June 2021, the refinery investor had not met the targets for some Project milestones. Preliminary activities such as the Front End Engineering Design were at 97%, Environmental Social Impact Assessment Study at 70%, and procurement for the consultancy services for the Resettlement Action Plan was on-going.", null, null], ["18", "Uganda Electricity Transmission Company Limited (UETCL) 2020/21", "\uf0b7 I noted that UETCL developed and approved a Corporate Business Plan without certification from the National Planning Authority. There is a risk that activities implemented during the financial year 2020/2021 were not aligned to the NDP-III, which negatively affects the achievement of NDP- III objectives."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 265, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "253", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 265, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "of UGX 86Bn. Domestic energy sales were 9.5 % below budget. Both"], [null, "sales to Rwanda and DRC 29% below the budget, and no sales were"], [null, "made to South Sudan despite the anticipated revenue of UGX.824 million."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 266, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None"], "type": "table"}}, {"content": [["", "of UGX 86Bn. Domestic energy sales were 9.5 % below budget. Both"], [null, "sales to Rwanda and DRC 29% below the budget, and no sales were"], [null, "made to South Sudan despite the anticipated revenue of UGX.824 million."], [null, "\uf0b7 UETCL budgeted to receive from Government, UGX.108.823Bn for"], [null, "capacity charges and deemed energy costs. However, only UGX 36.4Bn"], [null, "was released resulting in a shortfall of UGX 72.423Bn, which is 66% of"], [null, "the budget."], [null, "\uf0b7 I sampled 40 critical activities implemented under 7 sampled departments"], [null, "under UETCL and noted that 17(43%) tasks had been fully implemented,"], [null, "13 (32%) were partially implemented, while 10 (25%) were not"], [null, "implemented at all."], [null, "\uf0b7 A provision for bad and doubtful debts amounting to UGX 161.4bn was"], [null, "made under Trade and other receivables in the financial statements. This"], [null, "was an increment of 25% from the financial year 2019/20. The provision"], [null, "relates to customers with unpaid balances in contravention of the terms"], [null, "and conditions of the power sales agreement. I further noted that 74.7%"], [null, "of the provisions were attributable to only one Company."], [null, "\uf0b7 Analysis of the trade and other payables revealed an increment of 18.7Bn"], [null, "from UGX.740.8Bn in 2019/20. Included in these payables were amounts"], [null, "of UGX.71.2Bn and USD.4.7 million which have been outstanding for over"], [null, "10 years."], [null, "\uf0b7 M/s UMEME and M/s UEDCL withheld UETCL revenue of UGX 64Bn and"], [null, "10.31Bn, respectively on account of evacuation losses and non-payment"], [null, "of electricity bills by Government MDAs. Withholding revenue constrains"], [null, "UETCL\u2019s ability to pay electricity generators."], [null, "\uf0b7 The land titling process was not satisfactory on most of UETCL Projects."], [null, "UETCL takes an average of 3 years to conclude the titling process in"], [null, "contravention of the 6 months period warranted which exposes the"], [null, "company to a risk of litigation and potential encroachment."], [null, "\uf0b7 UETCL incurred deemed energy costs of UGX 87.7Bn on thirteen (13)"], [null, "PPAs, save for me HPP were directly financed through the tariff system,"], [null, "hence impacting on the electricity price to the final consumer."], [null, "\uf0b7 I noted that UETCL incurred about UGX 494,150,000 in replacing"], [null, "vandalized tower equipment during the year under review. I further noted"], [null, "that the company incurred UGX. 1.6Bn in replacement costs on assorted"], [null, "transmission line items vandalized between 2017 and 2021."], [null, "\uf0b7 I noted delays in concluding the procurement process for a sample of"], [null, "procurements with a total contract sum of UGX.17.8Bn with"], [null, "procurements lasting an average of 3 years and some cases going up to 5"], [null, "years. Prolonged procurement processes deny timely achievement of"], [null, "intended project objectives."], ["19 National Pipeline Company 2020/21 Opinion Unqualified \uf0b7 Out of the total receipts for the financial year of UGX.3.71Bn, UGX.3.71Bn was utilized. This represents an absorption level of 100%. \uf0b7 I noted that the Company failed to maintain National Strategic Reserves. In the period under review, the Consortium failed to meet the required National Strategic Reserve levels of 12 million litres per month. Failure to restock petroleum reserves exposes the Country to supply shocks and a risk of inflated prices in the event of disruptions in the petroleum supplies chain. \uf0b7 I noted that as at 30th June 2021, the consortium had not developed the facilities to enable lake transport to the Jinja Storage Tanks. The construction of an oil jetty and connecting pipeline to Jinja Storage Tanks", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 266, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None"], "type": "table"}}, {"content": "254", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 266, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["had not commenced. \uf0b7 I noted delays in implementation of Kampala Storage Terminal (KST). As at 30th June 2021, Preliminary activities such as the Power Reticulation Proposal and Environment Social Impact Assessment for the terminal were undertaken However, Construction activities under the Project had not commenced.", null, null], ["20", "Rural Electrification Agency 2020/21 Opinion", "\uf0b7 Out of the budgeted government receipts for the financial year of UGX.155.23Bn, a sum of UGX. 149.26Bn was spent by the entity resulting in an unspent balance of UGX.5.97Bn, representing an absorption level of 96%."], [null, "Unqualified", null], ["21 Uganda Energy Credit Capitalisation Company Limited 2020/21 Opinion Unqualified \uf0b7 No material issue reported. \uf0b7", null, null], ["22", "Grid Expansion and Reinforcement Project \u2013 MEMD", "\uf0b7 Out of the total receipts for the financial year of USD.1,698,907.88, only USD.1,030,144.30 was spent resulting into an unspent balance of USD.654,938.58, representing an absorption level of only 60.6%."], [null, "2020/21 Opinion Unqualified", null], ["23 The Fuel Marking and Quality Monitoring Program, Ministry of Energy and Mineral Development \uf0b7 Out of the total receipts for the financial year of UGX.9.62Bn, a sum of UGX. 8.71Bn was spent representing 91% absorption level by the program. As a result activities such as Stakeholders\u2019 awareness", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 267, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "255", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 267, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["2020/21 Opinion Unqualified workshops and Training on petroleum standard development were partially implemented. \uf0b7 \uf0b7 I noted non-compliance by fuel stations with the Standard that covers the siting, design and construction of service stations, installation and operation of equipment in service stations for handling, storage and dispensing of petroleum products and their derivatives. \uf0b7 I noted that the Program does not have in place a comprehensive system of monitoring and testing the quality of lubricants and engine oils based on the standards. This poses a risk to motorists who may purchase poor quality engine oils and lubricants.", null, null, null], ["24", "The Ministry of Energy and Mineral Development (MEMD) 2020/21 Opinion Unqualified", null, "\uf0b7 I noted in the year under review, that the entity did not have an approved sector development plan (strategic plan) 2020/21. The Accounting Officer explained that a strategic Plan was prepared and is aligned to the NDP III, a however the approval of management delayed"], [null, null, null, "due to management transition \uf0b7 The Ministry budgeted to collect NTR of UGX.19.9Bn during the year"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 268, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None", "None"], "type": "table"}}, {"content": [["2020/21 Opinion Unqualified workshops and Training on petroleum standard development were partially implemented. \uf0b7 \uf0b7 I noted non-compliance by fuel stations with the Standard that covers the siting, design and construction of service stations, installation and operation of equipment in service stations for handling, storage and dispensing of petroleum products and their derivatives. \uf0b7 I noted that the Program does not have in place a comprehensive system of monitoring and testing the quality of lubricants and engine oils based on the standards. This poses a risk to motorists who may purchase poor quality engine oils and lubricants.", null, null, null], ["24", "The Ministry of Energy and Mineral Development (MEMD) 2020/21 Opinion Unqualified", null, "\uf0b7 I noted in the year under review, that the entity did not have an approved sector development plan (strategic plan) 2020/21. The Accounting Officer explained that a strategic Plan was prepared and is aligned to the NDP III, a however the approval of management delayed"], [null, null, null, "due to management transition \uf0b7 The Ministry budgeted to collect NTR of UGX.19.9Bn during the year"], [null, null, null, "under review. Out of this, only UGX. 13Bn was realized, representing a performance of 65.3% of the target. This was attributed to COVID"], [null, null, null, "Pandemic that greatly affected businesses in the Country to extent that"], [null, null, null, "some companies wrote requested for either a reduction or waiving off their rent arrears."], [null, "", "", "\uf0b7 Out of the total warrants for the financial year of UGX.342.3Bn, a sum of"], [null, "", "", "UGX.336.9Bn was spent by the entity resulting in an unspent balance of"], [null, "", "", "UGX.5.4Bn representing an absorption level of 98%. As a result, I noted"], [null, "", "", "that of the 148 quantified activities worth UGX.99.3Bn assessed; 16"], [null, "", "", "activities representing 10.8% were fully implemented, 125 activities"], [null, "", "", "representing 84.5% were partially implemented, while 7 activities"], [null, "", "", "representing 4.7% were not implemented."], [null, "", "", "\uf0b7 A trend analysis of the domestic arrears reported in Note 24 to the"], [null, "", "", "financial statements showed movement of domestic arrears from"], [null, "", "", "UGX.18.29Bn in the previous year to UGX.17.13Bn in the year under"], [null, "", "", "review, a decrease of 7%. This unsustainable trend poses risks of"], [null, "", "", "litigation and related costs inform of interest penalty."], [null, "", "", "\uf0b7 The Ministry received UGX.1.39Bn into the Mineral Royalties Sharing Fund"], [null, "", "", "account during the period, in addition to the closing amount of"], [null, "", "", "UGX.442.07Mn from the previous period. However, only UGX.1.39Bn was"], [null, "", "", "paid leaving an outstanding balance of UGX.433.82Mn which has been"], [null, "", "", "correctly disclosed as payables as at year end."], [null, "", "", "\uf0b7 The receivables amount of UGX.14,287,738,002 in the statement of"], [null, "", "", "financial position and under Note 19, to the financial statements includes"], [null, "", "", "an amount UGX.4,494,005,610 receivables (UGX 4,288,550,000 and"], [null, "", "", "UGX.205,455,610 relating to annual mineral rent/royalties and sale of"], [null, "", "", "goods and services, respectively) which has been outstanding for over"], [null, "", "", "four years."], [null, "", "", "\uf0b7 The RAP implementation and land acquisition for the Karuma Reservoir"], [null, "", "", "Area project. The contract has been extended several times with the new"], [null, "", "", "completion date set for 23rd June 2022. I established that a RAP survey"], [null, "", "", "and valuation report was submitted by the Consultant on 31st April 2021,"], [null, "", "", "but, as at 30th June 2021, compensation of the PAPs had not yet"], [null, "", "", "commenced."], [null, "", "", "\uf0b7 A review of the Department of Geological Survey and Mines staff"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 268, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None", "None"], "type": "table"}}, {"content": "256", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 268, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "establishment revealed that out of 127 approved positions, only 85"], [null, null, "positions were filled leaving 42 positions vacant representing a staffing"], [null, null, "gap of 33%."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 269, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["", null, "establishment revealed that out of 127 approved positions, only 85"], [null, null, "positions were filled leaving 42 positions vacant representing a staffing"], [null, null, "gap of 33%."], ["25 Kilembe Mines Ltd (KML) 2020/21 Opinion Unqualified \uf0b7 The entity budgeted to receive UGX.3.574Bn out of which, UGX.857Mn was realised, resulting in a shortfall of UGX.2.717Bn which is 76% of the budget. As a result activities such as dewatering the Copper Mines and revamping of Hima Lime Works, were not been implemented. \uf0b7 \uf0b7 I noted that a number of assets had been damaged / impaired due to waters that broke the banks of River Nyamwamba on 7th and 10th of May, 2020. However, no formal estimate of the recoverable amount has been conducted. This may result into an overstatement of the total assets and understatement of operating loss. \uf0b7 I noted that the Company had an outstanding receivable of UGX.1.26Bn as at 30th June 2021, 54% of the amount relates to unpain rent from Tibet Hima Mining Co. Ltd. Delayed recovery of outstanding revenues affects the Company\u2019s liquidity position. \uf0b7 I noted that the Company had outstanding payables of UGX.2.28Bn. The amount increased from UGX.0.966 to UGX.2.286Bn resulting into an increase of UGX.1.321Bn (137%) as at 30th June 2021. \uf0b7 I noted delayed divesture of Kilembe Mines. Three (3) years have elapsed without an investor/operator being identified to take over Kilembe Mines operations, following the termination of the Tibet Hima Concession Agreement. \uf0b7 Emergency Funding of UGX 4.375bn was required to rehabilitate the damaged Company infrastructure following flooding of rivers Nyamambwa and Mubuku in May and August 2020. However, the requested funds were not availed. \uf0b7 Mubuku Hydro-Power Plant was designed to generate 5MW. I however noted that the plant was only generating 2MW from Unit 1. Units 2 to 4 were out of service for a number of years. \uf0b7 Review of the Annual Performance Report, 2021 revealed that the Company had a number of long outstanding court cases, relating to encroachment of Land belonging to the company. Three cases had been outstanding for over 7 years, three other cases for 5 but less than 7 years and six cases for less than 5 years.", null, null], ["26", "Uganda Electricty Generation Company Limited Capacity Building Program-Norwegian Grant", "\uf0b7 Out of UGX.6,475,227,265 received for project activities UGX.5,285,679,281 was utilized representing 82% absorption. The under absorption was attributed to postponement of commissioning of Karuma Hydro power plant."], [null, "Uga-16/0010 Initial Support to UEGCL \u2013 2019 2020/21", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], ["27 Atomic Energy Council 2020/21 Opinion \uf0b7 Out of the total receipts for the financial year of UGX. 13.98bn, UGX. 9.96bn was spent by the entity resulting in an unspent balance of UGX 4bn representing an absorption level of 71.2%. As a result, Six (6) outputs with thirty nine (39) activities worth UGX. 4.2Bn were partially", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 269, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "257", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 269, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Unqualified implemented. \uf0b7 I noted that the Council lacked of Radiation Protection and Safety Laboratories. There were no Laboratories in place for testing radioactivity levels in food stuffs, construction materials and other consumable products that contain natural radionuclides. This puts the lives of the community at risk. \uf0b7 I noted that the Council lacked adequate specialized inspection equipment required for various practices and activities that involved management of radiation sources. \uf0b7 Out of Staff the Council Establishment of 90 positions, only 49 positions filled leaving 21 positions vacant, representing a staff shortfall of 30%. This affects the efficient and effective execution of the Council mandate.", null, null], ["28", "Energy for Rural Transformation Project (ERT III)-PCU 2020/21", "\uf0b7 Out of the total available funds for the financial year of USD 6,346,771.03, only USD 5,585,830.71 was spent by the Project, resulting in an unspent balance of USD. 760,940.32, representing absorption level of 88%. \uf0b7 I noted low disbursements of loan funds over the Project Life. Out of the ERT III Project loan amount of USD 143.2 Million, only USD 94.5 Million"], [null, "Opinion Unqualified", null], ["29 Opuyo- Moroto 132kv Transmission Line Project - (UETCL) 2019 Opinion Unqualified \uf0b7 I noted that despite the project nearing completion, out of 1,300 PAPs, only 1,222 had been compensated leaving a balance of 78 (6%) by 30th June 2019. There is a risk that the outstanding compensation of PAPs may further delay project implementation. \uf0b7 I noted that despite the loan last disbursement date being 28th February 2021, only 21% of the total funds were disbursed to both UETCL and REA by 30th June 2019", null, null], ["30", "Opuyo- Moroto 132kv Transmission Line Project - (UETCL) 2020 Opinion Unqualified", "\uf0b7 I noted under Note 9.13 that the project payables increased from USD.1,169,371 (2019) to USD. 2,290,568 (2020) due to non payments of service providers at the end of the financial year for the services"], [null, null, "provided."], [null, null, ""], ["31 The 132kv Mirama-Kabale Transmission Line and Distribution Project-2019 Opinion Unqualified \uf0b7 No significant matters to report on.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 270, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "258", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 270, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["32", "The 132kv Mirama-Kabale Transmission Line And Distribution Project-2020", "\uf0b7 No significant matters to report on."], [null, null, ""], [null, null, ""], ["33 Energy for Rural Transformation III Implemented by Uganda Energy Credit Capitalization Company Limited (ERT III- UECCCL) Opinion Unqualified \uf0b7 No material issue reported.", null, null], ["34", "Energy for Rural Transformation III BOU Project (ERT III).", "\uf0b7 No material findings to report on"], [null, null, ""], ["EDUCATION SECTOR", null, null], ["1", "African Centre for Agro ecology and Livelihood Systems (ACALISE) Project \u2013 UMU", "\uf0b7 I noted in the statement of income and expenditure that out of budgeted total revenue of USD 1,807,602 for the financial year 2020/2021, only USD 610,980 (33.8%) was realized leading to a budget shortfall of USD 1,196,622."], [null, "2020/21 Opinion Unqualified", null], ["2 Soroti University. 2020/21 Opinion Unqualified \uf0b7 I noted that the University did not indicate NTR estimates in its statement of Appropriation. How out of the budgeted NTR of UGX.706,000,000 for the financial year 2020/2021, UGX.195,985,600 was collected representing a performance of 28% of the target. \uf0b7 The entity budgeted to receive UGX.20.229Bn out of which UGX.19.621Bn was warranted, resulting into a shortfall of UGX.0.608 Bn which is 3% of the budget. \uf0b7 I noted the University received off-budget financing to the tune of UGX.36,710,266 which was not transferred to the consolidated fund as required by the law. \uf0b7 Out of the total receipts (warrants) for the financial year of UGX.19.621Bn, UGX.17.484Bn was spent by the entity resulting into an under absorption of UGX.2.137Bn representing an absorption level of 89%. \uf0b7 Ten (10) outputs with a total of ninety-nine (99) activities and", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 271, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "259", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 271, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["expenditure worth UGX 10.251Bn were fully quantified while one (1) output with a total of four (4) activities and expenditure worth UGX 1.898Bn was not quantified to enable assessment of performance as there was no output that was insufficiently quantified. \uf0b7 Out of the ten (10) out puts that were fully quantified, one (1) output with a total of 6 (six) activities worth UGX.0.051Bn was fully implemented while 9(nine) outputs with a total of ninety-three (93) activities worth UGX.10.201Bn were partially implemented. \uf0b7 The University closed the financial year with an accumulated payable totaling to UGX.2,604,379,429 of which UGX.559,049,780 had been outstanding for more than one year. \uf0b7 The University paid a contractor UGX.996,389,960 in respect of outstanding debt that included UGX.188,055,690 relating to accrued interest charged by the contractor as a result of delayed payments. The interest expenditure was nugatory", null, null], ["3", "Busitema University.", "\uf0b7 Out of the budgeted Non tax revenue of UGX.6,517,061,618 for the year"], ["", "2020/21", "2020/21, only UGX.4,904,767,921 was collected representing a"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 272, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": [["expenditure worth UGX 10.251Bn were fully quantified while one (1) output with a total of four (4) activities and expenditure worth UGX 1.898Bn was not quantified to enable assessment of performance as there was no output that was insufficiently quantified. \uf0b7 Out of the ten (10) out puts that were fully quantified, one (1) output with a total of 6 (six) activities worth UGX.0.051Bn was fully implemented while 9(nine) outputs with a total of ninety-three (93) activities worth UGX.10.201Bn were partially implemented. \uf0b7 The University closed the financial year with an accumulated payable totaling to UGX.2,604,379,429 of which UGX.559,049,780 had been outstanding for more than one year. \uf0b7 The University paid a contractor UGX.996,389,960 in respect of outstanding debt that included UGX.188,055,690 relating to accrued interest charged by the contractor as a result of delayed payments. The interest expenditure was nugatory", null, null], ["3", "Busitema University.", "\uf0b7 Out of the budgeted Non tax revenue of UGX.6,517,061,618 for the year"], ["", "2020/21", "2020/21, only UGX.4,904,767,921 was collected representing a"], [null, "Opinion Unqualified", "performance of only 75% of the target."], [null, null, "\uf0b7 There was a shortfall in releases amounting to UGX4.63Bn which is 9% of the budget. Furthermore, the entity remained with unspent balance of"], [null, null, "UGX.1.60Bn representing an absorption level of 97%."], [null, null, "\uf0b7 The University received off-budget financing to the tune of"], [null, null, "UGX.1,462,363,950 which was not transferred to the consolidated fund as"], [null, null, "required by the law. These funds were received directly from"], [null, null, "development partners for undertaking activities which were not budgeted"], [null, null, "for."], [null, null, "\uf0b7 Nine (9) outputs with 73 activities worth UGX.33.34Bn were insufficiently"], [null, null, "quantified. That is out of the Seventy-three (73) activities, twelve (12)"], [null, null, "activities (16%) were not clearly quantified. Two (2) outputs with a total"], [null, null, "of eight (8) activities worth UGX.8.52Bn were fully implemented while"], [null, null, "two (2) outputs with a total of fifteen (15) activities worth UGX3.46Bn"], [null, null, "were partially implemented."], [null, null, "\uf0b7 I noted that the University closed the financial year with outstanding"], [null, null, "payables to the tune of UGX.1,504,842,864 of which UGX.1,421,201,933"], [null, null, "related to unpaid enhanced salaries for administrative and support staff"], [null, null, "that accrued in the financial year 2016/17."], ["4 Gulu University. 2020/21 Opinion Unqualified \uf0b7 I noted that the University\u2019s strategic plan was not certified by NPA and no feedback had been received by the time of concluding the audit. This was attributed to delays in the review and certification process by NPA. \uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity budgeted to collect NTR of UGX.12.75Bn during the year under review. Out of this, UGX.4.18Bn was collected, representing a performance of 32.8% of the target. The entity budgeted to receive UGX. 58.88Bn from treasury, out of which UGX.57.90Bn was warranted, resulting into a shortfall of UGX.0.98Bn which is 1.7% of the budget. \uf0b7 Out of the total warrants of UGX 58.11Bn received during the financial year, UGX. 57.90bn was spent by the entity resulting in an unspent balance of UGX 0.21Bn, representing an absorption level of 99.6%. The unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account as required by the PFMA.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 272, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "260", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 272, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 The University received off-budget financing to the tune of UGX.6,255,990,597 which was not declared to Treasury and, therefore, not appropriated to the entity by Parliament. These funds were received directly from development partners for undertaking activities not budgeted for. \uf0b7 I reviewed the extent of quantification of outputs and activities for a sample of the ten (10) outputs with a total of twenty (20) activities and expenditure of UGX.45.556Bn and noted that seven (7) outputs with a total of twelve (12) activities and expenditure worth 43.284bn were fully quantified while three (3) outputs with a total of eight (8) activities and expenditure worth UGX. 2.871bn were not quantified at all. \uf0b7 I assessed the implementation of seven (7) out puts that were fully quantified with a total of twelve (12) activities worth UGX.43.282Bn and noted that three (3) outputs with a total of six (6) activities worth UGX.37.054Bn were fully implemented. Two (2) outputs with a total of four (4) activities worth UGX,5.706Bn were partially implemented while two (2) outputs with a total of two (2) activities worth UGX. 0.522Bn were not implemented. \uf0b7 The University had outstanding domestic arrears of UGX.5,681,315,557 dating as far back as financial year 2015/16. There is a risk that the University could face litigation from the suppliers and other beneficiaries. \uf0b7 Gulu University is involved in several court cases and some of the cases remained pending at the financial year end. The cases are mostly between the University and its former staff, students and suppliers. The cases arose mainly from unlawful termination, breach of contracts, unfair treatment, land issues, Arrears/failure to pay suppliers. \uf0b7 Gulu University awarded a contract for the supply and installation of Network Equipment to the Faculty of Agriculture, Biometric Equipment for Staff attendance, Laptops and Desktops for Vice Chancellor, Director ICT and Director Planning & Development at a contract price of UGX.181,794,897 on the 25th June, 2021. However, as at the time of concluding the audit, installation was not undertaken. \uf0b7 Gulu University signed a contract for the construction of the Business and Development Centre on the 19th June, 2019 for a contract price of UGX.30,122,043,772. The construction start date was 1st August, 2019 and the expected completion date of 30th July, 2023. I noted that only UGX.2.1Bn out of UGX.6.0Bn was paid as advance for mobilization and this led to the temporary stoppage of works by the contractor which led to slow progress of the building works. At the time of concluding the audit, no major works were undergoing. \uf0b7 I noted that the following University pieces of land were not titled; forest land measuring 28 hectares, Pajengo Latoro; Agago and Agora Pader land. There is a risk that the land in question could be lost to unscrupulous individuals. \uf0b7 Out of the 1,606 approved positions in Gulu University; only 441 (27%) posts were filled, leaving 1,165 (73%) positions vacant.", null, null], ["5", "The Higher Education Students' Financing Board (HESFB)", "\uf0b7 I noted that the University\u2019s strategic plan was not certified by NPA and no feedback had been received by the time of concluding the audit. This was attributed to delays in the review and certification process by NPA."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 273, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["amount of XDR 157,600,000 (Equivalent to USD 243,800,000), only XDR 22,916,350.66 (USD 32,780,000) representing 14.5% of the signed loan amount had been cumulatively disbursed for implementation of the project activities as at 30th June 2021. It should be noted that 65% of the project implementation time had elapsed as at 30th June 2021. Implementation of civil works (road rehabilitation, improvement and routine maintenance works) under component 1 had hardly progressed. \uf0b7 There was under absorption of released project funds. Total IDA funds available during the year were USD 8,090,898.12 (being opening fund balance of USD 4,920,898.12 and additional disbursements of USD 3,170,000 on 23rd October 2020). However, only, USD 4,457,669.32 was spent on implementation of project activities representing funds absorption level of 55%. \uf0b7 Out of the GoU counterpart funds of UGX 3,034,260,000 released in the FY 2020/21, only UGX 765,831,419 (25%) was spent on implementation of the Project activities. The balance of UGX 2,268,428,581 (75%) was reallocated to other projects. Management did not avail the authorization used as basis to reallocate the funds to other projects. \uf0b7 There has been accumulation of higher financing charges due to the low utilization of the signed loan. Charges of UGX 4,703,471,276 (being service charges and commitment charges of UGX 840,691,467 and UGX 3,862,779,809 respectively) were accrued during the FY 2020/21. Cumulatively, total charges of UGX 27,201,439,219 (being service charges and commitment charges of UGX 2,734,784,077 and UGX 24,466,655,142 respectively) have been accrued since loan signature on 16th February 2015.", "None", "None"], "type": "table"}}, {"content": "261 \ntarget. The entity budgeted to receive UGX. 58.88Bn from treasury, out of which UGX.57.90Bn was warranted, resulting into a shortfall of UGX.0.98Bn which is 1.7% of the budget.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 273, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the total warrants of UGX 58.11Bn received during the financial year, UGX. 57.90bn was spent by the entity resulting in an unspent balance of UGX 0.21Bn, representing an absorption level of 99.6%. The unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account as required by the PFMA.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The University received off-budget financing to the tune of UGX.6,255,990,597 which was not declared to Treasury and, therefore, not appropriated to the entity by Parliament. These funds were received directly from development partners for undertaking activities not budgeted for.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I reviewed the extent of quantification of outputs and activities for a sample of the ten (10) outputs with a total of twenty (20) activities and expenditure of UGX.45.556Bn and noted that seven (7) outputs with a total of twelve (12) activities and expenditure worth 43.284bn were fully quantified while three (3) outputs with a total of eight (8) activities and expenditure worth UGX. 2.871bn were not quantified at all.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I assessed the implementation of seven (7) out puts that were fully quantified with a total of twelve (12) activities worth UGX.43.282Bn and noted that three (3) outputs with a total of six (6) activities worth UGX.37.054Bn were fully implemented. Two (2) outputs with a total of four (4) activities worth UGX,5.706Bn were partially implemented while two (2) outputs with a total of two (2) activities worth UGX. 0.522Bn were not implemented.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The University had outstanding domestic arrears of UGX.5,681,315,557 dating as far back as financial year 2015/16. There is a risk that the University could face litigation from the suppliers and other beneficiaries.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Gulu University is involved in several court cases and some of the cases remained pending at the financial year end. The cases are mostly between the University and its former staff, students and suppliers. The cases arose mainly from unlawful termination, breach of contracts, unfair treatment, land issues, Arrears/failure to pay suppliers.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Gulu University awarded a contract for the supply and installation of Network Equipment to the Faculty of Agriculture, Biometric Equipment for Staff attendance, Laptops and Desktops for Vice Chancellor, Director ICT and Director Planning & Development at a contract price of UGX.181,794,897 on the 25th June, 2021. However, as at the time of concluding the audit, installation was not undertaken.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Gulu University signed a contract for the construction of the Business and Development Centre on the 19th June, 2019 for a contract price of UGX.30,122,043,772. The construction start date was 1st August, 2019 and the expected completion date of 30th July, 2023. I noted that only UGX.2.1Bn out of UGX.6.0Bn was paid as advance for mobilization and this led to the temporary stoppage of works by the contractor which led to slow progress of the building works. At the time of concluding the audit, no major works were undergoing.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the following University pieces of land were not titled; forest land measuring 28 hectares, Pajengo Latoro; Agago and Agora Pader land. There is a risk that the land in question could be lost to unscrupulous individuals.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- Out of the 1,606 approved positions in Gulu University; only 441 (27%)", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n262", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 274, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "posts were filled, leaving 1,165 (73%) positions vacant."], ["6 Kabale University. 2020/21 Opinion Unqualified \uf0b7 I noted that the University prepared a strategic plan aligned to NDP III and the plan was approved by NPA and a certificate of approval issued. \uf0b7 Out of budgeted NTR collections of UGX.7.6 Bn, only UGX. 5.26Bn was realized, representing a performance of 74.6 % of the target. \uf0b7 There was a shortfall in government releases amounting to UGX.0.03Bn representing 0.08% of the budget. \uf0b7 Out of the total receipts for the financial year of UGX.40.95 Bn a sum of UGX. 40.5 Bn was spent by the entity resulting in an unspent balance of UGX 0.45Bn representing an absorption level of 99%. \uf0b7 I sampled 5 outputs of a total of Nine (9) outputs and expenditure worth 37.22.Bn and noted that two (2) outputs with a total of three (3) activities was fully quantified; three (3) outputs with thirteen (13) activities were partially quantified while two (2) activities were not implemented. \uf0b7 The university accumulated receivables totalling to UGX.3,114,950,156 as at 30/6/2021. Under collection of billed revenue cripples, the University\u2019s ability to meet its financial obligations and impacts negatively on service delivery. \uf0b7 I noted the University had outstanding payables of UGX.1,872,390,164 as at 30/6/2021. The failure to clear payables by the closure of the financial year may attract litigation resulting into wasteful expenditure in form of legal fees.", null, null], ["7", "Lira University. 2020/21 Opinion", "\uf0b7 The entity submitted its final copy of the strategic plan to National Planning Authority (NPA) for alignment and certification however, no feedback had been received by the entity at the time of audit (September 2021)."], [null, "Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 275, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "263", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 275, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "quantified with a total of six (6) activities worth UGX.5.3Bn and noted"], [null, null, "that two (2) outputs with two (2) activities worth UGX.0.3Bn were fully"], [null, null, "implemented while three (3) outputs with four (4) activities worth"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 276, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "posts were filled, leaving 1,165 (73%) positions vacant."], "type": "table"}}, {"content": [["", null, "quantified with a total of six (6) activities worth UGX.5.3Bn and noted"], [null, null, "that two (2) outputs with two (2) activities worth UGX.0.3Bn were fully"], [null, null, "implemented while three (3) outputs with four (4) activities worth"], [null, null, "UGX.5Bn were partially implemented."], [null, null, "\uf0b7 During the year, the University incurred nugatory expenditure totalling to"], [null, null, "UGX.25,752,041 being interest and penalties paid resulting from"], [null, null, "management\u2019s failure to deduct and remit NSSF deductions for the period"], [null, null, "August 2016 to June 2020."], [null, null, "\uf0b7 I noted that Lira University signed a tenancy agreement with the Law"], [null, null, "Development Centre letting out the first floor of the faculty of Education"], [null, null, "to LDC at a consideration of UGX.15,300,000 per month inclusive of taxes"], [null, null, "implying that the University is making a monthly financial loss of"], [null, null, "UGX.2,754,000 in form of VAT payable to URA. As a result, the university"], [null, null, "did not remit VAT totalling to UGX. UGX.33,048,000 being VAT payable"], [null, null, "on rental income to URA on the annual rental income of UGX.183,600,000"], [null, null, "(UGX.15,300,000 for 12 months) received by the University."], [null, null, "\uf0b7 I noted a delayed construction of the Administration Block following a"], [null, null, "contract award of UGX.16,664,107,531 to the construction contractor."], [null, null, "Despite the expiry of the contract duration of the three years to 11th"], [null, null, "September 2021, the construction works had not been completed, and"], [null, null, "the progress of works was estimated at 32% level. However, the"], [null, null, "supervising contractor had been paid 92% on his contract of"], [null, null, "UGX.749,885,000 ending 4th February 2022."], ["8 MAK Holdings. 2020/21 Opinion Unqualified \uf0b7 I noted that the Company management budgeted to receive and generate revenue of UGX.1,892,600,000 however, only UGX.809,760,761 (43%) was realized reflecting an underperformance of UGX.1,082,839,239 which is 57% of the expected revenue for the year. \uf0b7 The Makerere University Guest house had accumulated creditors to the tune of UGX.620,024,827 from UGX.405,138,535 in the financial year ended 30th June, 2020 representing a 53% increase in liabilities. Some of the outstanding liabilities include statutory payments worth UGX.240,026,071 \uf0b7 I noted an increase in receivables of UGX.299,307,621 from UGX.271,978,943 reported in the prior year.", null, null], ["9", "Mapronano World Bank Project. 2020/21 Opinion", "\uf0b7 I noted that out of the released USD 1,995,561, only USD 1,357,190 was spent by the Project resulting into unspent balance of USD 638,371 representing an under absorption level of 31.98%. The unspent balance at the end of the financial year was subsequently carried forward to the next financial year."], [null, "Unqualified", null], ["10 MaRCCI World bank Project. 2020/21 Opinion Unqualified \uf0b7 I assessed the implementation of the eight (8) out puts with 42 activities that were fully quantified worth US$ $907,282.93, and noted that one (1) output with two (2) activities worth US$ 27,600 was fully implemented while seven (7) outputs with a total of forty (40) activities worth US$ 879,681.93 were partially/not-implemented. The project management implemented sixteen (16) activities fully, eighteen (18) activities partially and six (6) activities were not implemented.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 276, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "posts were filled, leaving 1,165 (73%) positions vacant."], "type": "table"}}, {"content": "264", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 276, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that the project did not pay staff salaries to the tune of USD 13,596 (approximately UGX.50,305,2000. In addition, PAYE withheld from staff deductions for the months of October and November, 2020 totaling to USD. 11,764 (approximately UGX.43,526,800) was not remitted to Uganda Revenue Authority as per regulations.", null, null], ["11", "Management Training and Advisory Centre (MTAC).", "\uf0b7 The MTAC had not prepared the required 5-year strategic plan that is in line with the NDPIII"], [null, "2020/21 Opinion Unqualified", null], ["12 Makerere University. 2020/21 Opinion Unqualified \uf0b7 I noted that the University did not have the strategic plan annualized to indicate which outputs are expected for each year of implementation of the plan covering the period of 2021/21-2024/25. I also noted that whereas the University had prepared and submitted its strategic plan to NPA for approval, it had not yet been approved at the time of audit in October 2021. \uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2021/2021 and noted that the University budgeted to collect NTR of UGX.95.84Bn during the year under review. Out of this, only UGX.58.29Bn was collected, representing a performance of 60.82% of the target. I further noted that the University budgeted to receive UGX.363.74Bn out of which UGX.359.86Bn was warranted, resulting in a shortfall of UGX.3.88Bn which is 1.1% of the budget. Revenue shortfalls affect implementation of the planned activities. \uf0b7 Out of the total warrants of UGX.359.86Bn received during the financial year, UGX.357.04Bn was spent by the entity resulting in an unspent balance of UGX.2.82Bn representing an absorption level of 99.2%. The unspent funds were swept back to the consolidated fund as required by PFMA. \uf0b7 I noted that the University received off-budget financing to the tune of UGX.237,398,885,878 which was not declared to Treasury and, therefore, not appropriated to the entity by Parliament. These funds were received directly from both development partners and other stakeholders for undertaking activities not budgeted for. \uf0b7 I reviewed the extent of quantification of outputs and activities for a", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 277, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "posts were filled, leaving 1,165 (73%) positions vacant."], "type": "table"}}, {"content": "265 \nsample of ten (10) outputs with a total of forty two (42) activities and expenditure of UGX.356.85Bn and noted that two (2) outputs with a total of seven (7) activities and expenditure worth UGX.265.85Bn were fully quantified. Two (2) outputs with a total of twenty-five (25) activities and expenditure worth UGX.30.11Bn were insufficiently quantified while six (6) outputs with a total of ten (10) activities and expenditure worth UGX.60.89Bn were not quantified at all. I observed that in cases where outputs were either partially or not quantified, management reported performance in generic ways. \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 277, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I assessed implementation of two (2) out puts that were fully quantified with a sample of seven (7) activities worth UGX.265.85Bn and noted that one (1) output with a total of three (3) activities worth UGX 4.06Bn was fully implemented while one (1) output with a total of four (4) activities worth UGX.261.78Bn were partially implemented.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- During the financial year under review, the University lost its main administration building and other assets therein to a fire that gutted the main administration Block on the 20th day of September 2020. The fire caused substantial damage to the main building whose value was estimated at UGX.15,434,782,500 by the Chief Government Valuer.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The Statement of reported losses of Public moneys, stores and other assets during the year showed the reported losses of assets/property of total estimated value of UGX.16,457,577,500.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The University had a receivables balance of UGX.25,527,015,916 as at 30/6/2021 broken down as accrued income of UGX.23,372,851,776 and a prepayment of UGX.2,154,164,140 to UMEME for electricity bulk purchase. The accumulation of receivables may lead to under performance of the university on its planned activities.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The University has an outstanding pension liability of UGX.18,920,219,207, inclusive of interest as reported in the Statement of Financial Position for the year ended 30th June 2021 resulting from accumulation of In-House Retirement Benefits since 2010. Delayed payment of retirement benefits may result in nugatory expenditure if the retirees decide to take the University to court.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Statement of Financial Position showed accumulation of domestic arrears of UGX.7,819,385,752 as at 30th June 2021. I noted that majority of these arrears were from the prior years. There is a risk that the University could face litigation from the suppliers and other beneficiaries.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the main University installations/buildings such as the Senate, the Library, School of Women and Gender Studies and others are not comprehensibly insured. In case of a catastrophe, the University is at risk of huge financial obligations to the tenants.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that there are non-qualifying persons occupying the University buildings. These were identified to be former University staff (retirees), unknown persons and Uganda Police Officers whose services were transferred from Makerere University.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that water bills for the year under review were neither read nor submitted to the finance department for deductions. I noted that staff salaries were arbitrarily deducted to clear their water consumption without following one\u2019s monthly water consumption.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The University owns various pieces of land totalling to 102 Acres in prime locations around Kampala including Makerere, Mulago and Makindye. Inspection of the land revealed that the land is heavily encroached upon and a number of cases have been in court for more than five (5) years.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n266", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 278, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", null, null], ["13", "Muni University. 2020/21 Opinion Unqualified", "\uf0b7 I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that Muni University budgeted to collect NTR of UGX.1.18bn during the year under review. Out of this, only UGX.0.34bn was collected, representing a performance of 29% of the target."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 279, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "267", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 279, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "Latrine and Store have deteriorated and in dire need of renovation."], [null, null, "\uf0b7 The University\u2019s land in BidiBidi measuring about 439.58 acres valued at"], [null, null, "UGX.439,580,000 did not have a land title."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 280, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": [["", null, "Latrine and Store have deteriorated and in dire need of renovation."], [null, null, "\uf0b7 The University\u2019s land in BidiBidi measuring about 439.58 acres valued at"], [null, null, "UGX.439,580,000 did not have a land title."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 280, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": [["", null, "Latrine and Store have deteriorated and in dire need of renovation."], [null, null, "\uf0b7 The University\u2019s land in BidiBidi measuring about 439.58 acres valued at"], [null, null, "UGX.439,580,000 did not have a land title."], [null, null, "\uf0b7 Muni University entered into a contract for the Completion of the"], [null, null, "Construction of Health Science Laboratory Building at a contract price of"], [null, null, "UGX.9,393,202,823 inclusive of taxes. However, works were significantly"], [null, null, "behind schedule at an estimated 36% completion. There is a risk that the"], [null, null, "Project may not be completed within the projected time frame."], ["14 Mbarara University of Science & Technology. 2020/21 Opinion Unqualified \uf0b7 I noted that the University had NTR estimates of UGX.12.43Bn out of which UGX.9.28Bn was collected representing 75% of the budget. \uf0b7 I noted that out of the total receipts for the financial year of UGX.55.4Bn, only UGX.51.4Bn was spent by the entity resulting in an unspent balance of UGX.4Bn representing an absorption level of 92.9%. \uf0b7 I noted that the University received off-budget financing to the tune of UGX.9.2Bn which was not transferred to the consolidated fund as required by the law. \uf0b7 I noted that nine (9) outputs with a total of twenty-two (22) activities and expenditure worth 42.9Bn were fully quantified. That is, 99% of the activities within these out-puts were clearly quantified to enable assessment of performance. \uf0b7 I noted that one (1) output with a total of three (3) activities and expenditure worth UGX 0.47Bn was insufficiently quantified. That is, the two (2) activities of the three sampled (67%) of the output was not clearly quantified to enable assessment of performance. \uf0b7 I noted that one (1) output with one activity worth UGX.0.05Bn was fully implemented, while eight (8) outputs with a total of twenty-one (21) activities worth UGX.42.9Bn were partially implemented. Out of the twenty-one (21) activities, the entity fully implemented nine (9) activities (43%), 9 (43%) activities were partially implemented and three (3) activities (14%) remained unimplemented \uf0b7 I noted that the University accumulated receivables totalling to UGX.4,222,012,678 as at 30th June 2021, an increase of UGX.1,427,267,366 (51%) in the outstanding receivables of UGX.2,794,745,312 of the prior year ended 30th June 2020. \uf0b7 I noted that the leasehold land on Plot No. 6, lower circular Road, Mbarara expired on 31st March 2017 and has not been renewed four (4) years after its expiry. \uf0b7 I noted that MUST owns six (6) tourist camping sites (bandas) adjacent to Bwindi forest, in Kanungu district on approximately 2 acres of land which was leased to a service provider for a period of 10 years effective 12/04/2020 at contract sum of UGX.480,000,000 (UGX.48,000,000 annually). However, the service provider did not pay the first instalment of UGX.48,000,000 which was due on 12th April 2021, citing challenges of Covid-19 pandemic.", null, null], ["15", "National Council of Sports. 2020/21", "\uf0b7 Out of the budgeted NTR of UGX.1,185,394,990 for the financial year 2020/2021, UGX.515,782,750 was collected representing a performance of 44% of the target."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 280, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "268", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 280, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 Out of the total receipts for the financial year of UGX.22.165 Bn,"], [null, "UGX.22.160 Bn was spent by the entity resulting into an under absorption"], [null, "of UGX.0.006 Bn representing an absorption level of 99.97%."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 281, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None"], "type": "table"}}, {"content": [["", "\uf0b7 Out of the total receipts for the financial year of UGX.22.165 Bn,"], [null, "UGX.22.160 Bn was spent by the entity resulting into an under absorption"], [null, "of UGX.0.006 Bn representing an absorption level of 99.97%."], [null, "\uf0b7 Out of the eleven (11) outputs with a total of seventy-six (76) activities"], [null, "and expenditure of UGX.22.059 Bn taken for assessment, six (6) outputs"], [null, "with a total of thirteen (13) activities and expenditure worth UGX.18.708"], [null, "Bn were fully quantified."], [null, "\uf0b7 I assessed the implementation of six (6) out puts that were fully"], [null, "quantified with a total of thirteen (13) activities worth UGX.18.708Bn and"], [null, "noted that five (5) outputs with a total of twelve (12) activities worth"], [null, "UGX.18.708Bn were partially implemented. Out of the twelve (12)"], [null, "activities, the entity fully implemented five (5) activities (42%); partially"], [null, "implemented three (3) activities (25%) and four (4) activities (33%)"], [null, "remained unimplemented."], [null, "\uf0b7 A review of the strategic plan, budgets and other records revealed that"], [null, "Council does not have a policy in place for promoting sports. There was"], [null, "no evidence availed by management to show that there is any framework"], [null, "of relationship with Local authorities to provide sports facilities."], [null, "\uf0b7 Whereas Council approved funds transfer of UGX.1,431,284,198 to"], [null, "various Associations, there was no evidence to show that Council"], [null, "approved budgets of the individual Associations as required by NCS"], [null, "Regulations. I further noted that the approved funds transfers lacked a"], [null, "schedule supporting the allocation break down."], [null, "\uf0b7 Out of the 51 registered Associations, 49 submitted information about"], [null, "their other sources of funding. The remaining 2 Associations did not"], [null, "submit the required information for the period under review."], [null, "\uf0b7 I noted that some Associations did not deduct and remit WHT totalling to"], [null, "UGX.21,636,694 to the Uganda Revenue Authority."], ["16 Uganda Management Institute (UMI). 2020/21 Opinion Unqualified \uf0b7 I noted that the Institute budgeted to collect NTR of UGX.25.68Bn during the year under review. Out of this, only UGX.9.11Bn was collected, representing a performance of 35.5% of the target. In addition, the Institute budgeted to receive UGX.36.33Bn however, UGX.33.89Bn was availed, resulting in a deficit of UGX.2.44 Bn which is 6.7% of the budget. \uf0b7 Out of the total warrants of UGX.33.88Bn received during the financial year. UGX.29.25Bn was spent by the entity resulting in an unspent balance of UGX.4.63Bn, thus an absorption level of 86.33%. The unspent funds were swept back to the consolidated fund as required by the PFMA. I further noted that the entity did not seek a revision of its budget and work plan as provided for by section 17 (3) of the PFMA 2015. \uf0b7 I noted that the University received off-budget financing to the tune of UGX.185,595,654 which was not declared to treasury and, therefore, not appropriated to the entity by Parliament. These funds were received directly from development partners for undertaking activities not budgeted for. \uf0b7 I reviewed the extent of quantification of outputs and activities for a sample of twelve (12) outputs with a total of sixty-eight (68) activities and expenditure of UGX.35.32Bn and noted that all the twelve (12) outputs with a total of sixty-eight (68) activities and expenditure worth UGX 35.32Bn were not quantified at all. That is, all the sixty-eight (68) activities (100%) within these outputs were not clearly quantified to enable assessment of performance. \uf0b7 I noted that PAYE tax totaling to UGX.589,262,089 was not deducted", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 281, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None"], "type": "table"}}, {"content": "269", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 281, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["from staff gratuity payments on the basis of exemption from PAYE under the Pensions Act However, I noted that the gratuity of staff under contract terms is not regulated by the Pensions Act. \uf0b7 I noted that UMI did not transfer to the Consolidated Fund unspent balances of UGX. 555,953247 on ABSA Project Account at the end of the financial year as advised by the Accountant General.", null, null], ["17", "Uganda National Examinations Board (UNEB).", "\uf0b7 Out of the budgeted NTR of UGX.56.7Bn for the financial year 2020/2021, UGX.55.5 Bn was collected representing a performance of 97.9% of the target."], [null, "2020/21 Opinion Unqualified", null], ["18 BTVET SUPPORT PROJECT 2020/21 Opinion Unqualified \uf0b7 There were no reportable issues.", null, null], ["19", "Petroleum Geoscience Collaboration Programme (ENPE II PROJECT) 2020/21 Opinion", "\uf0b7 Makerere University main Building was gutted down by fire where vital documents got lost in the inferno. Consequently, payment vouchers and supporting documents in support of payments totaling to UGX.368,361,770 which is 65% of the total expenditure were not presented for examination. I was not able to confirm the authenticity of the expenditure."], [null, "Qualified", null], ["20 Makerere Institute of Social Research Beyond Criminal Justice Project Centre File 107453-001 for the Period 1 st January 2013 to 31 st December 2013 \uf0b7 No material issues to report on", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 282, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "270", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 282, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Unqualified", null, null], ["21", "Makerere Institute of Social", "\uf0b7 No material issues to report on"], ["", "Research Beyond Criminal Justice Project Centre File", null], [null, "107453-001 For The Period", null], [null, "1 st January 2014 to 31 st", null], [null, "December 2014", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["22 Makerere Institute Of Social Research Beyond Criminal Justice Project Centre File 107453-001 For The Period 1st January 2015 To 31st December 2015 Opinion Unqualified \uf0b7 No material issues to report on", null, null], ["23", "Makerere Institute of Social Research Beyond Criminal Justice Project Centre File", "\uf0b7 No material issues to report on"], [null, null, ""], ["24 MAKERERE INSTITUTE OF SOCIAL RESEARCH- HARRY FRANK GUGGENHEIM FOUNDATION GRANT FOR THE PERIOD 1st JANUARY 2014 TO 31ST DECEMBER 2014 Opinion Unqualified \uf0b7 No material issues to report on", null, null], ["25", "MAKERERE INSTITUTE OF SOCIAL RESEARCH- HARRY FRANK GUGGENHEIM", "\uf0b7 No material issues to report on"], [null, null, ""], ["26 MAKERERE INSTITUTE OF SOCIAL RESEARCH- HARRY FRANK GUGGENHEIM FOUNDATION GRANT FOR THE PERIOD 1 st JANUARY 2016 TO 31ST DECEMBER \uf0b7 No material issues to report on", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 283, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "271", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 283, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["2016 Opinion Unqualified", null, null], ["27", "Makerere Institute Of Social Research Internally Generated Funds For The Period 1st July 2012 To", "\uf0b7 No material issues to report on"], [null, null, "\uf0b7"], ["28 Makerere Institute of Social Research Internally Generated Funds for The Period 1st July 2013 To 30th June 2014 Opinion Unqualified \uf0b7 No material issues to report on \uf0b7", null, null], ["29", "Makerere Institute of Social Research Internally Generated Funds for The Period 1st July 2014 to 30th", "\uf0b7 No material issues to report on"], [null, null, "\uf0b7"], ["30 Makerere Institute of Social Research Internally Generated Funds for The Period 1st July 2015 to 30th June 2016 Opinion Unqualified \uf0b7 No material issues to report on \uf0b7", null, null], ["31", "Makerere Institute of Social Research- Norhed Project \u201cBuilding and Reflecting on Interdisciplinary Phd-", "\uf0b7 No material issues to report on"], [null, null, "\uf0b7"], ["32 Makerere Institute of Social Research- Norhed Project \u201cBuilding and Reflecting on Interdisciplinary Phd- \uf0b7 No material issues to report on \uf0b7", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 284, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "272", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 284, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Studies for Higher Education Transformation\u201d Grant Number: Uga- 13/0023 For the Period 1st January 2015 to 31st December 2015 Opinion Unqualified", null, null], ["33", "Makerere Institute of Social Research- Norhed Project \u201cBuilding and Reflecting On", "\uf0b7 No material issues to report on"], [null, null, ""], ["34 Makerere Institute of Social Research- Think Tank Initiative Phase 2 Institutional Support Centre File: 107906-001 For The Period 1st January 2014 To 31st December 2014 Opinion Unqualified \uf0b7 No material issues to report on \uf0b7", null, null], ["35", "Makerere Institute of Social Research- Think Tank Initiative Phase 2 Institutional Support Centre", "\uf0b7 No material issues to report on"], [null, null, ""], ["36 Makerere Institute of Social Research- Think Tank Initiative Phase 2 Institutional Support Centre File: 107906-001 For the Period 1st January 2016 to 31st December 2016 Opinion Unqualified \uf0b7 No material issues to report on", null, null], ["37", "Makerere Institute of Social Research- Carnegie", "\uf0b7 No material issues to report on"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 285, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "273", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 285, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Corporation Grant Number B 8741.Ro1 for the Period", "\uf0b7"], [null, "1st January 2014 to 31st", null], [null, "December 2014", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["38 Makerere Institute of Social Research Carnegie Corporation Grant Number B 8741.R01 for the Period 1 st January 2015 to 31 st December 2015 Opinion Unqualified \uf0b7 No material issues to report on \uf0b7", null, null], ["39", "Makerere Institute of Social Research-Carnegie Corporation Grant Number B 8741.Ro1 For the Period", "\uf0b7 No material issues to report on"], [null, null, "\uf0b7"], ["40 Kyambogo University Enable Report June 2020 Opinion Unqualified \uf0b7 No material issues to report on \uf0b7", null, null], ["41", "KYU University ENABLE Project Report Dec 2020 Opinion", "\uf0b7 No material issues to report on"], [null, null, "\uf0b7"], ["42 KYU NORHED-MVP Project Report June 2020 Opinion Unqualified \uf0b7 No material issues to report on \uf0b7", null, null], ["43", "KYU NORHED-MVP Project Report Dec 2020 Opinion", "\uf0b7 No material issues to report on"], [null, null, "\uf0b7"], ["44 Uganda Petroleum Institute Kigumba 2020/21 Opinion Unqualified \uf0b7 I noted that the Institute submitted its strategic plan for the period 2021- 2025 to NPA for review and approval but at the time of audit the certificate of approval had not been received. \uf0b7 Out of the budgeted NTR of UGX.0.67Bn for the year 2020/2021only UGX.0.073Bn was collected, representing a performance of 9% of the target. Similarly, the Institute budgeted to receive UGX.8.5bn from GOU", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 286, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "274", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 286, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["of which UGX.6.65bn was warranted, resulting in a shortfall of UGX. 1.85bn representing 21% of the budget. \uf0b7 I noted that the Institute spent all the funds that was available amounting to UGX.6.92bn representing 100% performance. \uf0b7 I noted that Seven (7) outputs with fifteen (15) activities and expenditure worth UGX.4Bn were fully quantified. That is, 100% of the activities within these out-puts were clearly quantified to enable assessment of performance. I further noted that Twelve (12) outputs with Twenty two (22) activities and expenditure worth UGX.2.49Bn was not quantified to enable assessment of performance. \uf0b7 Out of the Seven (7) quantified outputs three (3) outputs with seven (7) activities and expenditure worth UGX 4.39Bn were fully implemented while two (2) outputs with four (4) activities worth UGX.0.25Bn were partially implemented as two (2) outputs with four (4) activities worth UGX0.33Bn were not implemented. That is none of the four (4) activities was implemented at all. \uf0b7 The Institute had accumulated domestic arrears totalling to UGX. UGX.1.03Bn by the closure of the financial year under review (2020/2021) thereby being expressed to risk of litigation. \uf0b7 The Institute had outstanding receivables totalling to UGX.0.055Bn by the closure of the financial year under review. \uf0b7 Construction of Female hostel block, 2 Lecture halls, Library and an information Centre and Health Centre had delayed by 20months from the initial completion date of 27th March, 2020. \uf0b7 Out of the 103 approved staff established of the Institute, only 84 posts had been filled leaving 19 (18%) positions vacancies. I further noted that in spite of the vacant positions, the Institute had recruited an additional Forty-six (46) staff on contract terms outside the approved structure.", null, null], ["45", "Tb Preventive Therapy for Hiv-Infected Alcohol Users in Uganda: An Evaluation of Safety, Tolerability and Adherence (ADEPTT)", "\uf0b7 I noted that the closing balance of USD 12,178.00 was different from the balance brought forward as at 1st September 2017 of USD 9,615.58 creating a difference of USD 2,562.42. The difference could not be explained by management and was therefore disclosed in the Fund accountability statement as unaccounted for funds."], [null, "Project 2018 Opinion", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 287, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": [["of which UGX.6.65bn was warranted, resulting in a shortfall of UGX. 1.85bn representing 21% of the budget. \uf0b7 I noted that the Institute spent all the funds that was available amounting to UGX.6.92bn representing 100% performance. \uf0b7 I noted that Seven (7) outputs with fifteen (15) activities and expenditure worth UGX.4Bn were fully quantified. That is, 100% of the activities within these out-puts were clearly quantified to enable assessment of performance. I further noted that Twelve (12) outputs with Twenty two (22) activities and expenditure worth UGX.2.49Bn was not quantified to enable assessment of performance. \uf0b7 Out of the Seven (7) quantified outputs three (3) outputs with seven (7) activities and expenditure worth UGX 4.39Bn were fully implemented while two (2) outputs with four (4) activities worth UGX.0.25Bn were partially implemented as two (2) outputs with four (4) activities worth UGX0.33Bn were not implemented. That is none of the four (4) activities was implemented at all. \uf0b7 The Institute had accumulated domestic arrears totalling to UGX. UGX.1.03Bn by the closure of the financial year under review (2020/2021) thereby being expressed to risk of litigation. \uf0b7 The Institute had outstanding receivables totalling to UGX.0.055Bn by the closure of the financial year under review. \uf0b7 Construction of Female hostel block, 2 Lecture halls, Library and an information Centre and Health Centre had delayed by 20months from the initial completion date of 27th March, 2020. \uf0b7 Out of the 103 approved staff established of the Institute, only 84 posts had been filled leaving 19 (18%) positions vacancies. I further noted that in spite of the vacant positions, the Institute had recruited an additional Forty-six (46) staff on contract terms outside the approved structure.", null, null], ["45", "Tb Preventive Therapy for Hiv-Infected Alcohol Users in Uganda: An Evaluation of Safety, Tolerability and Adherence (ADEPTT)", "\uf0b7 I noted that the closing balance of USD 12,178.00 was different from the balance brought forward as at 1st September 2017 of USD 9,615.58 creating a difference of USD 2,562.42. The difference could not be explained by management and was therefore disclosed in the Fund accountability statement as unaccounted for funds."], [null, "Project 2018 Opinion", null], [null, "Unqualified", null], [null, "", null], ["46 MUST- Public Engagement Fund Grant, \u2018Unpacking Design Thinking Principles Through Biomedical Engineering Student\u2019s Innovation Cafes\u2019 Bmeic Project \u2013 2020 Opinion Unqualified \uf0b7 No Reportable issues. \uf0b7", null, null], ["47", "MUST- Serial Killers to Mosquitoes; The Spatial Targeting of Larval Habitats in Rural Uganda Using", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 287, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "275", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 287, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "(Breeding Sites) Project \u2013", null], [null, "2019", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["48 Epidemiology of Coronary Artery Disease Among People with Hiv In Rural Sub-Sahara Africa (CAD) Project 2019 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["49", "MUST- Interventions to Reduce Alcohol Use and Increase Adherence to TB Prevention Therapy Among", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"], ["50 MUST-Population Effectiveness of Dolutegravir Implementation in Sub- Saharan Africa: A Prospective Observational Cohort Study\u201d (DISCO), 2020 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["51", "MUST- Mobile Technology to Extend Clinic \u2013 Based Counseling For Hiv+ In Uganda (Extend), Project \u2013", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"], ["52 MUST- Mama Namtoto: Barriers and Enablers to Gender, Equity and Scale- Up in Tanzania Project Code 108547-002, 2018 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["53", "Must- Research Aimed at Developing Sustainable Low Field Magnetic Resonance Imaging (MRI-NIH) Project", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 288, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "276", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 288, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\u2013 2019", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["54 Advancing Hiv Research at MUST Through A Research Administration Training Project with the University of Virginia (RASA) -2020 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["55", "MUST- Resistance Testing Versus Adherence Support for Management of Patients with Virologic Failure on", "\uf0b7 I noted that the opening bank balance of USD 58,902 was different from the balance brought forward as at 1st July 2017 of USD 49,244, thus creating unexplained difference of USD 9,658. The difference was disclosed in the Fund accountability statement as unaccounted for funds."], [null, "First-Line Antiretroviral Therapy in Sub-Saharan Africa (Revamp) Project No. 04/05-16 \u2013 2018 Opinion", null], [null, "Unqualified", null], [null, "", null], ["56 MUST- Analysis of Past and Projected Future Land Use Change and Its Impact on Sediment Fluxes in The Rwizi Catchment (Vlir Rwizi) Project \u2013 2018 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["57", "MUST- Smart Discharge to Improve Post-Discharge Health Outcomes in Children: A Prospective", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"], ["58 Social Networks, Hiv Stigma, And the Hiv Care Cascade in Rural Uganda Project Of Mbarara Universisty Of Science and Technology- 2019 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["59", "MUST-The Virologic And Pharmacologic", "\uf0b7 No Material Reportable issues."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 289, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "277", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 289, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Determinants of Dolutegravir Failure in East", "\uf0b7"], [null, "Africa (Tld) Project 2019", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], [null, "", null], ["60 MUST- Voices of The Indigenous People Of Uganda Project 2020 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["61", "Education Service Commission", "\uf0b7 I noted the Commission closed the year with outstanding payables/domestic Arrears worth UGX.0.255Bn."], [null, "2020/21 Opinion Unqualified", null], ["62 Multinational Statistical Capacity Building Program for Managing for Development Results - Phase 4.2 (MSCB-AFDB) Project 2017 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null], ["63", "Multinational Statistical Capacity Building Program for Managing for Development Results -", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"], ["64 Multinational Statistical Capacity Building Program for Managing for Development Results - Phase 4.2 (MSCB-AFDB) Project 2019 Opinion Unqualified \uf0b7 No Material Reportable issues. \uf0b7", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 290, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "278", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 290, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, null], ["65", "Multinational Statistical Capacity Building Program for Managing for Development Results -", "\uf0b7 No Material Reportable issues."], [null, null, "\uf0b7"], ["66 Mandela National Stadium Limited 2020/21 Opinion Unqualified \uf0b7 I noted that the Company had no approved strategic plan that is aligned to NDPIII at the time of audit. \uf0b7 I noted that although the Company realized 101% of the budgeted, the original budget was revised from UGX.6.07Bn to UGX.2.63bn to match the expected revenue. \uf0b7 Out of the total receipts for the financial year of UGX.2.66bn, UGX. 1.36 Bn was resulting into an unspent balance of UGX.1.3bn representing an absorption level of 51%. \uf0b7 I noted that the Stadium quantified all its five (5) outputs and all the outputs were partially implemented whereby out of forty four (44) activities, the entity fully implemented seven (7) activities (16%), partially implemented five (5) activities (11%), while thirty two (32) activities (73%) remained unimplemented. \uf0b7 I noted that MNSL liabilities remained on a higher side despite a registered decrease from UGX.5.38Bn in the F/Y 2019/2020 to UGX.3.89Bn as at the end of the financial year under review representing a reduction of UGX.1.49 (28%). \uf0b7 I noted that Mandela National stadium closed the financial year with a receivables figure of UGX.2.42Bn, a reduction of only 7% from receivables of UGX.2.59 as at the end of the previous FYR: 2019/2020. \uf0b7 I noted that the Company did not implement its Staffing Strategy of the current running strategic plan 2018-2023. \uf0b7 I noted that stadium Land continues to have illegal occupants.", null, null], ["67", "The Albertine Region Sustainable Development Project (ARSDP) - MOES", "\uf0b7 Assessment of the Project\u2019s performance for the five year Project work plan implementation status revealed that one objective/goal had been achieved, while the remaining seven (7) were partially achieved."], [null, "Component 2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 291, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "279", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 291, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "UGX.25.18Bn were fully quantified."], [null, null, "\uf0b7 I noted One (1) output with two (2) activities and expenditure worth UGX"], [null, null, "14.53Bn was fully implemented. That is all the two (2) activities within"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 292, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": [["", null, "UGX.25.18Bn were fully quantified."], [null, null, "\uf0b7 I noted One (1) output with two (2) activities and expenditure worth UGX"], [null, null, "14.53Bn was fully implemented. That is all the two (2) activities within"], [null, null, "this output were fully implemented. I further noted that One (1) output"], [null, null, "with Five (5) activities worth UGX.3.60Bn was partially implemented. I"], [null, null, "also noted that One (1) output with one (1) activity worth UGX.0.68Bn"], [null, null, "was not implemented. That is; the one (1) activity was not implemented"], [null, null, "at all."], [null, null, "\uf0b7 Review of the Implementation status of the aide Memoir reports by the"], [null, null, "World bank for the Project monitoring mission activity for the period 27th"], [null, null, "July -3rdAugust 2020, 2nd-10th December 2020 Mission and 16th-25th"], [null, null, "March, 2021 revealed that some of the agreed upon"], [null, null, "actions/recommendations between the World Bank and MoES"], [null, null, "\uf0b7 Implementation status of aide Memoir reports indicated that some"], [null, null, "recommendations had either been partially implemented or not"], [null, null, "implemented."], [null, null, "\uf0b7 I noted that there was no internal audit review carried out on the"], [null, null, "operations of ARSDP during the period under review contrary to the"], [null, null, "requirement in Section II (B) of the ARSDP Financing agreement."], ["68 Kyambogo University 2020/21 Opinion Unqualified \uf0b7 I noted that the University prepared a strategic plan and obtained a certificate of compliance on the 27th of September 2021 from National planning Authority (NPA). \uf0b7 The University collected UGX.40.9Bn (53%) of its budgeted non-tax revenue of UGX.77.1Bn. I further noted that the university received UGX.130.07Bn (93%) out of the budgeted GOU receipts amount of UGX.140.6Bn. \uf0b7 Out of the total warrants for the financial year of UGX.130.07Bn, only UGX.124.5 was spent by the University resulting into unspent balance of UGX.5.53Bn representing an absorption level of 96%. \uf0b7 The University received Donor financing to the tune of UGX.3.11Bn of which only UGX.2.68Bn had been included in the budget reflecting off budget receipts of UGX.0.43Bn. \uf0b7 I noted that out of the 14 outputs sampled, 4 out puts (29%) were fully quantified, 8 out puts (57%) were insufficiently quantified while 2 out puts (14%) were not quantified at all. I also noted that the University did not fully implement any of the 4 fully quantified out puts. \uf0b7 The University had outstanding domestic arrears and outstanding receivables of UGX.13.6Bn and UGX.23.2Bn, respectively. \uf0b7 Some of the University land had illegal land occupants. I further noted that there were variations between the area on the Certificate of Tittle and actual Area on the ground for plot M902 of the University land. \uf0b7 Out of the 1,671 approved posts for the University, only 928 (55.5%) were filled leaving 743 (45.5%) posts vacant. This has a negative impact on education service delivery. \uf0b7 The University had MOUs for only 40 of the 112 affiliated Institutions. I further noted that of the 40 MOUs availed; MOUs for 9 Institutions had expired. \uf0b7", null, null], ["69", "The National Council for Higher Education", "\uf0b7 Out of budgeted NTR collections of UGX. 6.25bn, only UGX. 2.96Bn was"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 292, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "280", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 292, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "2020/21 Opinion Unqualified", "realized, representing a performance of 47.4%. \uf0b7 The Council budgeted to receive UGX.5.4Bn from Government out of which UGX.5.01Bn was availed, resulting in a shortfall of UGX0.39Bn, which is 7.2% of the budget."], [null, "", null], ["70 National Curriculum Development Centre 2020/21 Opinion Unqualified \uf0b7 I noted that whereas NCDC had prepared a strategic plan and whereas a notification of approval had been provided by NPA, a certificate of approval was yet to be obtained. \uf0b7 Out of the budgeted NTR of UGX.250,000,000 for the financial year under review, UGX.93,000,000 was collected representing a performance of 37.2% of the target. \uf0b7 The entity budgeted to receive UGX.40.163Bn from Treasury out of which UGX.37.138 Bn was warranted, resulting into a budget shortfall of UGX.3.025Bn which is 7.5% of the budget. \uf0b7 The Centre received off-budget financing to the tune of UGX.1,661,966,260 which was not transferred to the Consolidated Fund as required by the law and hence not appropriated. \uf0b7 Out of the total receipts for the financial year of UGX 37.137bn a sum of UGX. 36.929bn was spent by the entity resulting into an under absorption of UGX.0.208bn representing absorption level of 99.4%. \uf0b7 Out of the eleven (11) outputs with a total of seventy three (73) activities and expenditure of UGX.36.88 Bn, nine (9) outputs with a total of sixty eight (68) activities and expenditure worth UGX 35.95 Bn were fully quantified, one (1) output with a total of two (2) activities and expenditure worth UGX.0.16Bn were insufficiently quantified, and one (1) output with a total of one (1) activity and expenditure worth UGX 0.77Bn was not quantified to enable assessment of performance. \uf0b7 I assessed the implementation of nine (9) out puts that were fully quantified with a total of sixty eight (68) activities worth UGX.35.95Bn and noted the following; Two (2) outputs with 2 (two) activities worth UGX 0.75 Bn were fully implemented. The entity implemented the two (2) activities (100%) within the outputs. Secondly; seven (7) outputs with a total of sixty six (66) activities worth UGX.35.20Bn were partially implemented. Out of the sixty six (66) activities, the entity fully implemented forty one (41) activities (62%); partially implemented seven (7) activities (11%) and eighteen (18) activities (27%) remained unimplemented. \uf0b7 I noted that goods and services totalling to UGX.5,296,396,760 did not have corresponding WHT transactions totalling to UGX.317,783,806 on the IFMS payment file. I further noted that there was no evidence of exemptions. \uf0b7 Payments totalling to UGX.7,616,021 were made to staff of the Centre contrary to the e-cash guidelines. Similarly, funds totalling to UGX.31,448,969 were irregularly paid to payees who were already", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 293, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": [["", "2020/21 Opinion Unqualified", "realized, representing a performance of 47.4%. \uf0b7 The Council budgeted to receive UGX.5.4Bn from Government out of which UGX.5.01Bn was availed, resulting in a shortfall of UGX0.39Bn, which is 7.2% of the budget."], [null, "", null], ["70 National Curriculum Development Centre 2020/21 Opinion Unqualified \uf0b7 I noted that whereas NCDC had prepared a strategic plan and whereas a notification of approval had been provided by NPA, a certificate of approval was yet to be obtained. \uf0b7 Out of the budgeted NTR of UGX.250,000,000 for the financial year under review, UGX.93,000,000 was collected representing a performance of 37.2% of the target. \uf0b7 The entity budgeted to receive UGX.40.163Bn from Treasury out of which UGX.37.138 Bn was warranted, resulting into a budget shortfall of UGX.3.025Bn which is 7.5% of the budget. \uf0b7 The Centre received off-budget financing to the tune of UGX.1,661,966,260 which was not transferred to the Consolidated Fund as required by the law and hence not appropriated. \uf0b7 Out of the total receipts for the financial year of UGX 37.137bn a sum of UGX. 36.929bn was spent by the entity resulting into an under absorption of UGX.0.208bn representing absorption level of 99.4%. \uf0b7 Out of the eleven (11) outputs with a total of seventy three (73) activities and expenditure of UGX.36.88 Bn, nine (9) outputs with a total of sixty eight (68) activities and expenditure worth UGX 35.95 Bn were fully quantified, one (1) output with a total of two (2) activities and expenditure worth UGX.0.16Bn were insufficiently quantified, and one (1) output with a total of one (1) activity and expenditure worth UGX 0.77Bn was not quantified to enable assessment of performance. \uf0b7 I assessed the implementation of nine (9) out puts that were fully quantified with a total of sixty eight (68) activities worth UGX.35.95Bn and noted the following; Two (2) outputs with 2 (two) activities worth UGX 0.75 Bn were fully implemented. The entity implemented the two (2) activities (100%) within the outputs. Secondly; seven (7) outputs with a total of sixty six (66) activities worth UGX.35.20Bn were partially implemented. Out of the sixty six (66) activities, the entity fully implemented forty one (41) activities (62%); partially implemented seven (7) activities (11%) and eighteen (18) activities (27%) remained unimplemented. \uf0b7 I noted that goods and services totalling to UGX.5,296,396,760 did not have corresponding WHT transactions totalling to UGX.317,783,806 on the IFMS payment file. I further noted that there was no evidence of exemptions. \uf0b7 Payments totalling to UGX.7,616,021 were made to staff of the Centre contrary to the e-cash guidelines. Similarly, funds totalling to UGX.31,448,969 were irregularly paid to payees who were already", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 293, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "281", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 293, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["registered suppliers/vendors on IFMS. Also Funds to the tune of UGX.22,105,200, were utilized for expenses that were not provided for in the budget, to cater for COVID-19 SOPs.", null, null], ["71", "Makerere-Sida Bilateral Research Program 2020/21", "\uf0b7 No material Issues to report on"], [null, null, "\uf0b7"], ["72 Pharm-Biotechnology and Traditional Medicine (Pharmbiotrac) Centre Ace Ii Project 2020/21 Opinion Unqualified \uf0b7 I noted that a sum of USD.4,754,402 (88%) was disbursed in the 4 years period to 30th June 2021 against the planned cumulative expenditure of USD 5,404,514. \uf0b7 I noted that out of the total available financing for the financial year of USD.1,506,515 only USD.1,105,054 was spent by the Project resulting into an unspent balance of USD.401,461 representing an absorption level of 73%. \uf0b7 I noted that all the ten (10) outputs with a total of eighty seven (87) activities and expenditure of USD.1,105,054 were clearly quantified to enable assessment of performance. \uf0b7 I noted that all the ten (10) outputs with a total of eighty seven (87) activities worth USD. 1.1million were partially implemented. Out of eighty seven (87) activities, the entity fully implemented forty five (45) activities (52%), the entity partially implemented fifteen (15) activities (17%), while twenty seven (27) activities (31%) remained unimplemented. \uf0b7 \uf0b7 I noted that the Project had not obtained Patent rights over the various Products it had developed.", null, null], ["73", "Ministry of Education and Sports (MOES)", "\uf0b7 I noted that the Ministry\u2019s Strategic plan was not yet approved by National Planning Authority at the time of audit."], [null, "2020/21 Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 294, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "282", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 294, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 Out of a sum of UGX. 23.44Bn released to the ministry in respect of"], [null, "Covid-19 response related expenditure only UGX.9.62 (55.4%) remained"], [null, "unspent and was subsequently swept back to the Consolidated Fund"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 295, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None"], "type": "table"}}, {"content": [["", "\uf0b7 Out of a sum of UGX. 23.44Bn released to the ministry in respect of"], [null, "Covid-19 response related expenditure only UGX.9.62 (55.4%) remained"], [null, "unspent and was subsequently swept back to the Consolidated Fund"], [null, "Account."], [null, "\uf0b7 I noted under Note 18 to the financial statements and the statement of"], [null, "financial position that the ministry had receivables totaling to"], [null, "UGX.10.64Bn at the beginning of the financial year which increased to"], [null, "UGX.11,684,417,736 at closure of the year. The outstanding amounts"], [null, "relate to advances which were made to various educational institutions"], [null, "and District Local Government."], [null, "\uf0b7 The ministry had outstanding payables amounting to UGX.39.45 Bn at the"], [null, "closure of the financial year. This was a reduction of UGX.10.74Bn"], [null, "(21.4%) from UGX.50.19Bn in the FY 2019/20. I further noted that UGX."], [null, "29.79Bn (75.5%) of the outstanding amount has been outstanding for"], [null, "more than one year. I also noted that whereas the Ministry had"], [null, "outstanding obligations UGX.50.19Bn at the beginning of the financial"], [null, "year, only UGX.16.69Bn was provided for in the budget resulting into a"], [null, "funding gap of UGX.33.51Bn."], [null, "\uf0b7 Only UGX.18.81Bn of the appropriation for pensions of UGX.28.52Bn"], [null, "(66%) was absorbed leading to under absorption of funds by UGX.9.71Bn"], [null, "(34%). In addition, the Ministry had accumulated pension arrears"], [null, "totaling to UGX.1.47Bn due to delayed payment due to missing"], [null, "documents on pension files."], [null, "\uf0b7 Out of the total verified outstanding court awards of UGX.10.18 Bn, a"], [null, "sum of UGX.4.69Bn (46.1%) relates to accumulated interest costs arising"], [null, "from delayed settlement of court awards. I further noted that whereas"], [null, "the ministry had obligations to the tune of UGX. 15.98Bn and other on-"], [null, "going cases during the financial year, only UGX.1.66Bn was provided for"], [null, "court awards and compensations in the work plan for the financial year"], [null, "under review."], [null, "\uf0b7 Post closure audit inspection on Uganda Teacher School Effectiveness\u2019"], [null, "project (UTSEP) in the Ministry of Education revealed UGX.1.58Bn"], [null, "remained unutilized as at the closure of the F/Y (30th June 2021)."], [null, "\uf0b7 I noted that UGX.3.9Bn of the UGX.5.55Bn advanced to UBOS before"], [null, "project closure date (31st July 20) to carry out data collection"], [null, "(enumeration) for the comprehensive Education Institutions baseline,"], [null, "which was expected to be completed by 30th April 2020 remained"], [null, "outstanding."], [null, "\uf0b7 I noted that the Ministry of Education and Sports still holds the mandate"], [null, "of managing Government scholarships, however information on"], [null, "Scholarship offered at the different Missions and other Government"], [null, "organizations was not available at the Secretariat. In addition, there was"], [null, "no scholarship Policy. I also noted that out of a total of 280 scholarships"], [null, "offered in the previous three years, only 162 were utilized resulting into"], [null, "an under absorption of 118 (42%) scholarships."], ["74 Opec Fund for International Development (OFID)- Vocational Education Project Phase 11 2020/21 Opinion Unqualified \uf0b7 I noted that the 5 year project with total budget of UGX.59.43 Bn that started in June 2017 had only received a total of UGX 14.09 Bn by end of financial year 2020/2021. \uf0b7 Out of the total amount of UGX.14.09Bn availed for financing the Project for the four and a half years covered; only UGX.12.3 Bn (87%) had been absorbed while the unspent balance of UGX.1.7bn was swept back to the Consolidated Fund. \uf0b7 I noted that whereas the Project closing date was 31st December 2021,", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 295, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None"], "type": "table"}}, {"content": "283", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 295, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["two critical project Components 1 & 2 (civil works, supply of equipment and tools) that form 85% of the total project budget had not taken off by the time of concluding the audit (2nd December 2021. \uf0b7 I observed that out of the absorbed funds worth UGX.12.3Bn, UGX.6.6bn (54%) was spent on other Arab funded Projects other than OFID project. \uf0b7 I noted that a total amount of UGX. 6.6Bn of the UGX.12.3 Bn GOU component was irregularly spent on other Arab funded Projects of IDBI, IDBII, KFAED and BADEA without authority.", null, null], ["75", "Uganda Skills Development Project (USDP)- PSFU 2020/21", "\uf0b7 I noted that the Project has made cummulative disbursements of USD.15,345,592 against cummulative commitments of USD.17,617,457 representing 87% performance."], [null, "Opinion Unqualified", null], ["76 Uganda Skills Development Project (USDP) -MOES Opinion Unqualified \uf0b7 I noted that at the close of the financial year 2020/2021, out of the two (2) planned strategic targets/objectives, one objective/goal had been achieved, while the other one had been partially achieved. \uf0b7 Out of the budgeted amount of UGX.58.82Bn budgeted to be received from World Bank during the financial year 2020/2021; a sum of UGX.46.53Bn was received indicating performance of 79% of the target. Similarly, the project budgeted to receive UGX.1.25Bn, of which UGX.1.07Bn was warranted, resulting in a shortfall of UGX. 0.18 Bn (14.4%) of the budget. \uf0b7 I noted that all project outputs were fully quantified. I also noted that the project fully implemented one of the sampled outputs, partially implemented one and two outputs were not implemented. \uf0b7 I noted delayed Signing of Contract for Supply of a Spray track for UTC Lira valued at Euros 205,200 had delayed for 9 months by end of November 2021, following the contracts committee\u2019s approval on 23rd/02/2021. \uf0b7 I noted delayed Installation and testing of Equipment: USD. 8,304,848 by 5 months at the time of audit at the end of November. I further noted that furniture supplies and civil works had also delayed with the delayed period ranging from 1-7 months.", null, null], ["77", "Imagining Gender Futures in Uganda (IMAGENU) Project \u2013 DFC Project No. 17-07-AU- Gulu University -", "\uf0b7 There were no reportable issues."], [null, null, "\uf0b7"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 296, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 A review of the Land register revealed that the University owns land in Kibaale and Makerere Hill. It was however noted that the university had not secured certificate of titles confirming ownership of the two (2) pieces of land. \uf0b7 A review of the staff establishment at the directorates and Colleges revealed an overall staffing gap of 915 positions, which is 44.9 % of the approved establishment. The understaffing was mainly at the Associate Professor level and Professor level. It was further noted that most of the staff at lecturer and senior lecturer level had adequate qualifications but had not been promoted.", "None", "None"], "type": "table"}}, {"content": "284 \n78 Makerere University Busines School. \n2020/21 \nOpinion Unqualified \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 296, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the University had its plan approved and certified by NPA and the plan is aligned to the national development plan. This greatly supports the achievement of NDP-III objectives.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I reviewed the NTR estimates, revenue sources and rates charged at vote level for the financial year 2020/2021 and noted that the entity budgeted to collect NTR of 56.845Bn during the year under review. Out of this, only 33.589bn was collected, representing a performance of 59.1% of the target.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The University budgeted to receive UGX.102.629Bn out of which UGX.97.03Bn was availed, resulting in a shortfall of UGX5.59Bn, which is 5.5% of the budget.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the total warrants of UGX.97.03Bn received during the financial year. UGX.96.85Bn was spent by the entity resulting in an unspent balance of UGX.0.18Bn representing an absorption level of 99.8%. The unspent funds were swept back to the consolidated fund as required by the PFMA.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the School received off-budget financing to the tune of UGX. 549Bn from NOHRED/NORAD Project Support which was not declared to treasury and, therefore, not appropriated to the entity by Parliament.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I reviewed the extent of quantification of outputs and activities for a sample of twelve (12) outputs with a total of seventy three (73) activities and expenditure of UGX.91.667Bn and noted that five (5) outputs with a total of fourteen (14) activities and expenditure worth UGX.3.031Bn were fully quantified. One (1) output with a total of twenty four (24) activities and expenditure worth UGX.77.002Bn, was insufficiently quantified while six (6) outputs with a total of thirty five (35) activities and expenditure worth UGX 11.633Bn were not quantified at all.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I assessed the implementation of five (5) outputs that were fully quantified with a total of fourteen (14) activities worth UGX 3.031Bn and noted that; Three (3) outputs with eight (8) activities and expenditure worth UGX 1.694Bn were fully implemented. One (1) output with two (2) activities worth UGX.1.336Bn was partially implemented while one (1) output with four (4) activities with a budget of UGX.1.159Bn was not implemented.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The entity disclosed receivables to the tune of UGX.21,730,133,664. This reflected an increase in receivables by UGX.12,025,676,995 (124%) from the previous year\u2019s balance of UGX.9,704,456,669. The accumulation of receivables impacts negatively on the operations of the University and the education service delivery.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Statement of Financial Position showed accumulation of payables to the tune of UGX.1,215,592,931 as at 30th June 2021. I noted that these payables were accumulated in the current year and largely related to suppliers of goods and services. Accumulation of payables poses a risk of litigation and or loss of trust against the University from the suppliers of the goods and services.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The financial statements showed that MUBS was involved in several court cases/legal proceedings of a total value UGX.2,899,977,221 in various courts of law that remained pending as at the financial year end. There is a risk that in case of un-favourable rulings, the School may incur more financial losses.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- A review of the statement of cash flow revealed payment of domestic arrears of UGX.9,601,334,785 against UGX.330,708,964 that was budgeted and warranted for payment of domestic arrears. Payment of", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n285", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 297, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", null, null], ["79", "The Norwegian Programme for Capacity Development In Higher Education And", "\uf0b7 The Project ended, and as at the end of the six-month period ended 31st December, 2020, funds to the tune of USD. 272,213 (Nok2,054,787) remained unspent, and it was refunded to the Funders."], [null, "Research For Development (Norhed) 2020", null], [null, "", null], [null, "Opinion", null], [null, "Unqualified", null], ["80 Environment for Development Initiative (Efd- Mak Centre) Project Makerere University for The Period 1st January - 31st December 2020 Opinion Unqualified \uf0b7 No material Issues reported", null, null], ["82", "Nurture: Research Training and Mentoring Program for Career Development of", "\uf0b7 No material Issues reported"], [null, null, ""], ["SCIENCE AND INNOVATION SECTOR", null, null], ["1.", "Kiira Motors Corporation. 2019/2020", "\uf0b7 I noted that at the time of the audit (June 2020), out of the planned six (6) strategic targets/goals, three (3) targets had been fully achieved and three (3) were partially achieved"], [null, "Opinion Unqualified", null], ["2\\. Presidential Initiative on Banana Industrial Development (PIBID). \uf0b7 I noted that out of the 3 strategic targets, PIBID partially attained them, with the hope of fully attaining the targets by the end of the strategic", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 298, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "286", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 298, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["2019/2020 Opinion Unqualified plan period. \uf0b7 NTR of UGX.99 Million was collected but not remitted to the consolidated fund and was instead spent at source. \uf0b7 It was observed that the entity has not taken off full operations as it remains cash strapped with limited subventions from the Ministry of Science Technology and innovation. \uf0b7 There was no evidence of the establishment of the Institutional Framework and Governance Board and the renewal of the appointment of the Board and Management Committee Members. \uf0b7 During the financial year, a total of UGX.29,230,320 was paid to the Executive Director as man-day allowance for signing 12 contracts on behalf of the organization, yet this is one of her roles for which a monthly salary is paid. \uf0b7 A total of UGX.272,694,000 was paid to various staff as allowances for working over the weekend. \uf0b7 The internal audit department had only one draft internal audit report with no evidence that the report was submitted to the Accounting Officer and Internal Auditor General. \uf0b7 PIBID recruited staff during the year 2019/2020 without an approved recruitment plan for the period. \uf0b7 Audit noted that PIBID did not have an approved salary structure on which it bases to pay individual staff \uf0b7 I noted that the entity lacked land titles for its land at Sanga (approximately 50 acres) and land where the water source is located at Kyamugambira (approximately 4 acres). \uf0b7 Management deducted UGX.633,205,884, as PAYE, from employee\u2019s salaries but was not remitted to Uganda Revenue Authority. \uf0b7 It was observed that outstanding obligations to the National Security Fund at the end of the Financial Year 2019/2020 were UGX.829,409,254.", null, null], ["3.", "Uganda Institute of Communication Technology (UICT).", "\uf0b7 I noted that out of the budgeted revenue of UGX.3,359,386,101 for the year 2019/2020, only UGX.1,893,012,622 was collected representing a performance of only 56% of the target."], [null, "2019/2020 Opinion", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 299, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": [["2019/2020 Opinion Unqualified plan period. \uf0b7 NTR of UGX.99 Million was collected but not remitted to the consolidated fund and was instead spent at source. \uf0b7 It was observed that the entity has not taken off full operations as it remains cash strapped with limited subventions from the Ministry of Science Technology and innovation. \uf0b7 There was no evidence of the establishment of the Institutional Framework and Governance Board and the renewal of the appointment of the Board and Management Committee Members. \uf0b7 During the financial year, a total of UGX.29,230,320 was paid to the Executive Director as man-day allowance for signing 12 contracts on behalf of the organization, yet this is one of her roles for which a monthly salary is paid. \uf0b7 A total of UGX.272,694,000 was paid to various staff as allowances for working over the weekend. \uf0b7 The internal audit department had only one draft internal audit report with no evidence that the report was submitted to the Accounting Officer and Internal Auditor General. \uf0b7 PIBID recruited staff during the year 2019/2020 without an approved recruitment plan for the period. \uf0b7 Audit noted that PIBID did not have an approved salary structure on which it bases to pay individual staff \uf0b7 I noted that the entity lacked land titles for its land at Sanga (approximately 50 acres) and land where the water source is located at Kyamugambira (approximately 4 acres). \uf0b7 Management deducted UGX.633,205,884, as PAYE, from employee\u2019s salaries but was not remitted to Uganda Revenue Authority. \uf0b7 It was observed that outstanding obligations to the National Security Fund at the end of the Financial Year 2019/2020 were UGX.829,409,254.", null, null], ["3.", "Uganda Institute of Communication Technology (UICT).", "\uf0b7 I noted that out of the budgeted revenue of UGX.3,359,386,101 for the year 2019/2020, only UGX.1,893,012,622 was collected representing a performance of only 56% of the target."], [null, "2019/2020 Opinion", null], [null, "Unqualified", ""], [null, null, "budget lines."], [null, null, "\uf0b7 I noted that the entity had outstanding trade and other receivables"], [null, null, "amounting to UGX.384,635,852."], [null, null, "\uf0b7 I noted temporary staffs that have been working at the Institute for over"], [null, null, "10 years with continuous contract renewals."], [null, null, "\uf0b7 A review of the staff establishment showed that only 41 positions were"], [null, null, "filled out of the established 99 positions, leaving 58 positions vacant."], [null, null, "\uf0b7 I noted that there was neither staff training nor an annual training plan in"], [null, null, "place."], [null, null, "\uf0b7 Contrary to Section 34 (1) of the VAT Act 1996, I noted that"], [null, null, "UGX.4,534,592 worth of VAT remained outstanding as at 30th June 2020."], ["4\\. Ministry of Science and \uf0b7 The Ministry of Science Technology and Innovation was merged with the", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 299, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": "287", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 299, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Technology and Innovation. 2020/21 Opinion Unqualified President\u2019s Office effective July 2021. I however did not obtain evidence of a proper transition plan which has led to delayed disbursement of funding for subventions and independent projects. The merger further rendered 136 technical scientist staff redundant and were not paid emoluments by the end of November, 2021. I advised management to ensure that a smooth transition process is undertaken. \uf0b7 Out of the total budget for the financial year of UGX.150Bn, only UGX.144.6Bn was received by the Ministry resulting into a shortfall of UGX.5.737Bn (equivalent to 3.5% of the budget). Shortfalls in revenue result into non implementation of planned activities. \uf0b7 Out of 20 quantified activities worth UGX.105.9Bn that were assessed; 13 activities representing 65% were fully implemented, 5 activities representing 25% were partially implemented, while 2 activities representing 10% were not implemented. I advised management to roll over critical activities to subsequent years and ensure that they are implemented before the end of the National Development Plan III. \uf0b7 I noted that funds to the tune of UGX.834Mn were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. I advised management to always ensure that proper authorization is obtained before implementing any unbudgeted activities. \uf0b7 Most of the research projects that had received funds for COVID-19 Vaccines and Treatments had not made much progress. Delays were majorly attributed to the late disbursement of funds and delayed delivery of Equipment. I advised management to ensure thorough due diligence before funds are allocated to the projects.", null, null], ["5", "Kiira Motors Corporation. 2020/21 Opinion Unqualified", "\uf0b7 Cabinet approved the roadmap for the commercialisation of the Kiira Electric vehicle project with a seed fund of UGX.143.7Bn to be availed over a period of 4 years effective 2018/19. Only 59% of the seed fund had been released in the previous three financial years, casting doubt as to whether the balance of UGX.58.4Bn (41%) would be released in the"], [null, null, "remaining one year. Failure to promptly fund the project, may lead to"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 300, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": [["Technology and Innovation. 2020/21 Opinion Unqualified President\u2019s Office effective July 2021. I however did not obtain evidence of a proper transition plan which has led to delayed disbursement of funding for subventions and independent projects. The merger further rendered 136 technical scientist staff redundant and were not paid emoluments by the end of November, 2021. I advised management to ensure that a smooth transition process is undertaken. \uf0b7 Out of the total budget for the financial year of UGX.150Bn, only UGX.144.6Bn was received by the Ministry resulting into a shortfall of UGX.5.737Bn (equivalent to 3.5% of the budget). Shortfalls in revenue result into non implementation of planned activities. \uf0b7 Out of 20 quantified activities worth UGX.105.9Bn that were assessed; 13 activities representing 65% were fully implemented, 5 activities representing 25% were partially implemented, while 2 activities representing 10% were not implemented. I advised management to roll over critical activities to subsequent years and ensure that they are implemented before the end of the National Development Plan III. \uf0b7 I noted that funds to the tune of UGX.834Mn were irregularly diverted from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. I advised management to always ensure that proper authorization is obtained before implementing any unbudgeted activities. \uf0b7 Most of the research projects that had received funds for COVID-19 Vaccines and Treatments had not made much progress. Delays were majorly attributed to the late disbursement of funds and delayed delivery of Equipment. I advised management to ensure thorough due diligence before funds are allocated to the projects.", null, null], ["5", "Kiira Motors Corporation. 2020/21 Opinion Unqualified", "\uf0b7 Cabinet approved the roadmap for the commercialisation of the Kiira Electric vehicle project with a seed fund of UGX.143.7Bn to be availed over a period of 4 years effective 2018/19. Only 59% of the seed fund had been released in the previous three financial years, casting doubt as to whether the balance of UGX.58.4Bn (41%) would be released in the"], [null, null, "remaining one year. Failure to promptly fund the project, may lead to"], [null, null, "high-cost overruns and delays in realising the intended objectives. In"], [null, null, "addition, it may cast doubts on its sustainability."], [null, null, "\uf0b7 KMC signed a Memorandum of Understanding (MOU) with National"], [null, null, "Enterprise Corporation (NEC) on the 15th January 2019 for the"], [null, null, "construction of the Kiira Vehicle Plant start-up facilities at the cost of"], [null, null, "UGX.63.64Bn. I noted that of the civil works that were to be completed"], [null, null, "by June 2021 (a period of 2 years and six (6) months), only 82% of those"], [null, null, "works had been completed due to insufficient funding. Underfunding has"], [null, null, "affected the progress of the plant construction which further delays the"], [null, null, "realisation of the intended objectives."], [null, null, "\uf0b7 Ministry of Science, Technology and Innovation (represented by Kiira"], [null, null, "Motors Corporation) and Makerere University were collaborating in the"], [null, null, "Development of a Low-Cost Open Design Medical Ventilator named"], [null, null, "Bulamu, that could be manufactured locally. Although UGX.74Mn was"], [null, null, "received from Resilient Africa Network Ran Ltd towards the completion of"], [null, null, "the development of the Ventilator, the development was behind schedule."], [null, null, "The delays may affect the realisation of intended objectives."], [null, null, "\uf0b7 I noted that Makerere University received UGX.8.92Bn for the Kiira"], [null, null, "Motors Project between FY2012/13 and FY2015/16 for the construction of"], [null, null, "the Kiira Vehicle Plant Start-Up facilities in Jinja. However, the university"], [null, null, "had not released these funds for over eight years. I advised management"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 300, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": "288", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 300, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "to follow up on the matter with all responsible stakeholders."], ["6 Uganda National Council for Science and Technology. 2020/21 Opinion Unqualified \uf0b7 I noted that out of the budgeted revenue of UGX.20.53Bn for 2020/21; UGX.24.59Bn was collected, representing a performance of 120% of the target. \uf0b7 Out of the 41 outputs assessed, 34 outputs representing 83% were fully implemented; four (4) outputs representing 10% were partially implemented, while three (3), representing 7%, were not implemented. \uf0b7 I noted that there was no evidence that the Accounting Officer prepared or submitted the annual budget performance reports of the Council by 31st July 2021 as required by regulations. \uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to the line Ministry for consolidation and onward transmission to the Ministry of Finance Economic and Economic Planning. \uf0b7 I established that UGX.94Mn was directly paid to staff\u2019s personal bank accounts, yet this money could have been directly paid to the intended final recipients. \uf0b7 Out of the 85 planned activities assessed, 69 outputs/activities representing 81% were fully implemented; 9 outputs/activities representing 11% were partially implemented, while seven (7) outputs/activities representing 8% were not implemented at all. \uf0b7 I noted that the Council did not produce the annual report as required by the UNCST Act. \uf0b7 A review of the procurement file for the Supply of ICT Equipment under EDCTP-SCRECU Project revealed no evidence of any public bid opening session, which creates doubts as to whether the bidders attended the bid opening session. \uf0b7 Audit noted that the Council had outstanding Pay As You Earn (PAYE) payments relating to July 2019 and June 2020 amounting to UGX.45,457,013 as of 30th June 2021, which had not been remitted to Uganda Revenue Authority", null, null], ["7", "Uganda Industrial Research Institute (UIRI). 2020/21 Opinion", "\uf0b7 I noted that 3.2 million masks were tested, treated and packaged, but the contract for the distribution of the reusable face masks was terminated after only 1.5 million masks had been consumed. The stock of over 1.7 million face masks has remained unutilised at the time of reporting. Government is likely to incur nugatory expenditure of almost UGX.4.08Bn"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 301, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": [["", null, "to follow up on the matter with all responsible stakeholders."], ["6 Uganda National Council for Science and Technology. 2020/21 Opinion Unqualified \uf0b7 I noted that out of the budgeted revenue of UGX.20.53Bn for 2020/21; UGX.24.59Bn was collected, representing a performance of 120% of the target. \uf0b7 Out of the 41 outputs assessed, 34 outputs representing 83% were fully implemented; four (4) outputs representing 10% were partially implemented, while three (3), representing 7%, were not implemented. \uf0b7 I noted that there was no evidence that the Accounting Officer prepared or submitted the annual budget performance reports of the Council by 31st July 2021 as required by regulations. \uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to the line Ministry for consolidation and onward transmission to the Ministry of Finance Economic and Economic Planning. \uf0b7 I established that UGX.94Mn was directly paid to staff\u2019s personal bank accounts, yet this money could have been directly paid to the intended final recipients. \uf0b7 Out of the 85 planned activities assessed, 69 outputs/activities representing 81% were fully implemented; 9 outputs/activities representing 11% were partially implemented, while seven (7) outputs/activities representing 8% were not implemented at all. \uf0b7 I noted that the Council did not produce the annual report as required by the UNCST Act. \uf0b7 A review of the procurement file for the Supply of ICT Equipment under EDCTP-SCRECU Project revealed no evidence of any public bid opening session, which creates doubts as to whether the bidders attended the bid opening session. \uf0b7 Audit noted that the Council had outstanding Pay As You Earn (PAYE) payments relating to July 2019 and June 2020 amounting to UGX.45,457,013 as of 30th June 2021, which had not been remitted to Uganda Revenue Authority", null, null], ["7", "Uganda Industrial Research Institute (UIRI). 2020/21 Opinion", "\uf0b7 I noted that 3.2 million masks were tested, treated and packaged, but the contract for the distribution of the reusable face masks was terminated after only 1.5 million masks had been consumed. The stock of over 1.7 million face masks has remained unutilised at the time of reporting. Government is likely to incur nugatory expenditure of almost UGX.4.08Bn"], [null, "Unqualified", "in the event no market is obtained for the masks."], [null, null, "\uf0b7 I noted that a number of machinery at the UIRI Namanve campus had"], [null, null, "been procured ahead of the proposed contract on mask production in the"], [null, null, "textile section. I noted that some equipment has remained unused/idle or"], [null, null, "has not been put to use due to lack of technical support from the supplier"], [null, null, "to operationalize the equipment. Management attributed the failure to the"], [null, null, "restrictions on international travel for the supplier\u2019s technical staff to"], [null, null, "come."], [null, null, "\uf0b7 The absence of a Board Chairperson has resulted in the failure of the"], [null, null, "Board to be constituted to meet and handle its mandate as provided for"], [null, null, "under Section 7 of the UIRI Act 2003. There is no evidence that the"], [null, null, "Board has ever met. There is a risk that the entity will lose strategic"], [null, null, "focus, since there is no supervisory oversight over its operations."], [null, null, "\uf0b7 I observed that the Institute signed MoUs with the different incubatees in"], [null, null, "which funds have been spent to support the projects. However, the"], [null, null, "Institute has not signed any binding contracts with the participants, which"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 301, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": "289", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 301, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "makes dispute resolution difficult in case it arises. In addition, I noted"], [null, null, "that 50 of the 95 incubatees reviewed had expired MoUs at the time of"], [null, null, "reporting, while others were not paying NTR to the Institute as per"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 302, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": [["", null, "makes dispute resolution difficult in case it arises. In addition, I noted"], [null, null, "that 50 of the 95 incubatees reviewed had expired MoUs at the time of"], [null, null, "reporting, while others were not paying NTR to the Institute as per"], [null, null, "agreement."], [null, null, "\uf0b7 It was observed that UIRI paid a total of UGX.1.286Bn in gratuity, for"], [null, null, "which PAYE was wrongly computed, resulting into an overpayment of"], [null, null, "UGX.100,778,201 to staff. The staff over payments can lead to financial"], [null, null, "loss to government, in the event the Institute is unable to recover from"], [null, null, "the concerned staff."], ["GENDER AND SOCIAL DEVELOPMENT SECTOR \uf0b7", null, null], ["1", "Equal Opportunities Commission. 2020/21", "\uf0b7 Out of the approved budget of UGX.12,071,754,441, a sum of UGX.12,016,602,345 was realized resulting into a shortfall of UGX. 55,152,096.00, representing 0.46%. \uf0b7 Out of the warrants of UGX.12,016,602,345, a sum of UGX.11,874,386,080 was spent indicating an absorption rate of 98.8 %."], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "representing 91% of the total budget, and noted that 1 output (11%)"], [null, null, "with 04 activities and expenditure worth UGX. 1.05Bn were fully"], [null, null, "quantified. In addition, Four (4) outputs with twenty-five 25) activities"], [null, null, "worth UGX.9.47 Bn were partially implemented. Out of the twenty-five"], [null, null, "(25) activities, the entity fully implemented sixteen (16) activities, two (2)"], [null, null, "activities were partially implemented, while seven (7) activities remained"], [null, null, "unimplemented."], [null, null, "\uf0b7 I noted long outstanding receivables of UGX.211,105,359 from interdicted"], [null, null, "staff, and management has not yet instituted recovery measures due to"], [null, null, "the ongoing court cases."], [null, null, "\uf0b7 I noted that funds to the tune of UGX.63,568,761 were irregularly re-"], [null, null, "allocated from the activities on which they were budgeted and spent on"], [null, null, "other activities without seeking and obtaining the necessary approvals."], [null, null, "\uf0b7 I noted that 244 accumulated cases from 2017/18 are still pending as at"], [null, null, "30th June 2021. Over the last three years 48% of the registered cases"], [null, null, "have remained un-concluded during the year of registration. In addition,"], [null, null, "the legal department that handles petitions is at a 50% staffing level."], [null, null, "\uf0b7 I noted that the Commission has 81 approved staff positions, but only 50"], [null, null, "(62%) positions were filled leaving 31 (31%) posts vacant."], [null, null, "\uf0b7 I noted that the land and building on plot 7c, Luthuli close, Bugolobi"], [null, null, "where the EOC offices are located was transferred to the Commission by"], [null, null, "the Ministry of Gender, labour and Social Development. However, there"], [null, null, "was no trace of the original title, and there was no documentary evidence"], [null, null, "of handover of the title to EOC management."], [null, null, "\uf0b7 I noted that the report on gender and equity compliance of the budget"], [null, null, "framework papers was produced in December 2020, eleven (11) months"], [null, null, "later than the Parliamentary submission of the required certification and"], [null, null, "responsive measures of February 2020, contrary to the PFMA."], [null, null, "\uf0b7 I noted that the Commission lacked an independent Audit Committee,"], [null, null, "however, the functions of the Committee were being undertaken by the"], [null, null, "Commissioners who are part of the Commission management, thus"], [null, null, "posing serious challenges of conflict of interest."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 302, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["funds to un-appropriated budget lines leads to non-implementation of budgeted for activities. \uf0b7 I noted that the School had five (5) pieces of land recorded in the assets register that have never been valued to ascertain the monetary value. I also noted that the land in Kireka had squatters and the possibility of reclaiming it may prove to be challenging. The encroachment on the School land was attributed to failure to gazette and develop the land.", "None", "None"], "type": "table"}}, {"content": "290 \n2 Ministry of Gender, Labour and Social Development (MoGLSD) \n2020/21 \nOpinion \nUnqualified", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 302, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the approved budget of UGX. 153.01Bn, a sum of UGX.148.47Bn was warranted resulting into a shortfall of UGX.4.54Bn, representing 2.97% of the budget.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out UGX.148.47Bn warranted, a sum of UGX.147.63Bn was spent indicating an absorption rate of 99.4%.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Ministry received off-budget financing of UGX.11.598 Bn that was not appropriated by Parliament.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I sampled fifteen (15) outputs with a total of thirty (30) activities and expenditure worth UGX.105.44Bn, representing 87.76% of the total budget, and noted that 9 outputs (36%) with 11 activities worth UGX.79.33Bn were not quantified at all. In addition, out of the 16 quantified outputs with 20 activities assessed, 12 outputs (75%) were achieved, 15 activities (75%) were fully achieved/implemented, while 4 out puts with 5 activities representing 25% were partially achieved/implemented.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Ministry had payables of UGX 37,394,048,164. Of these, a sum of UGX 36,075,485,050 (96.5%) related to funds not remitted to older persons under the Social Assistance Grant and Empowerment Programme (SAGE).", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Ministry made a cumulative total disbursement of UGX.113.22Bn to the Youth Livelihood Programme (YLP) by 30th June 2021 to 13,095 Youth groups. However, out of the expected recoverable funds of UGX.78.10Bn, only UGX.40.14Bn was recovered, leaving an outstanding amount of UGX.37.96Bn.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "- The Ministry recovered UGX.40.14Bn YLP funds from Local Governments, but only UGX.37.59Bn was transferred to the recovery account in BOU, leaving a balance of UGX.2.54Bn.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that out of the total UGX. 37.59Bn received on the YLP revolving fund account in Bank of Uganda, only UGX.19.93Bn (53%) was revolved to other Youth Interest Groups, leaving a balance of UGX.17.65Bn (47%) not revolved.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the budgeted UGX.188Bn for the Women Entrepreneur Programme (UWEP) for the period of five years since financial year 2015/16, only 135Bn (72%) had been released over the same period leading to a programme budget shortfall of UGX.53Bn (28%).", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of UGX.27.61Bn due for recovery under UWEP by 30th June, 2021, a sum of UGX.20.19Bn was recovered leaving a balance of UGX.7.42Bn, thus indicating a recovery rate of 73%.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- A sum of UGX.2.64Bn recovered under the UWEP could not be tagged to specific Local Governments and individual women groups.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Labour advisory (LAB) Board did not function in the financial year under review to deliberate on matters affecting workers. This meant that no advisory services were extended to Government on matters of employment and industrial relations.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Medical Arbitration Board (MAB) met only in one quarter during the entire financial year (February 2021) despite having over 150 pending cases awaiting arbitration as at 30th June 2021. I further noted that some cases have been pending for over 9 years.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that Uganda has only three signed bilateral agreements in protection of migrant workers with Saudi Arabia, the Hashemite Kingdom of Jordan and the United Arab Emirates. Agreements with other", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "291", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 303, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", null, null], ["3", "National Council for People with Disabilities 2020/21", "\uf0b7 Out of the approved budget of UGX.1,236,047,430 expected through the MOGLSD a sum of UGX.921,555,246 was realized resulting into a shortfall of UGX. 314,492,184, which is 75% of the budget. The shortfall has since"], [null, null, "led to 43% increase in payables relating to mainly unpaid gratuities to"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 304, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", null, null], ["3", "National Council for People with Disabilities 2020/21", "\uf0b7 Out of the approved budget of UGX.1,236,047,430 expected through the MOGLSD a sum of UGX.921,555,246 was realized resulting into a shortfall of UGX. 314,492,184, which is 75% of the budget. The shortfall has since"], [null, null, "led to 43% increase in payables relating to mainly unpaid gratuities to"], [null, "Opinion Unqualified", "staff, totalling UGX 539,360,000 at year end."], [null, null, "\uf0b7"], [null, null, "\uf0b7 Out of the total funds available of UGX.922,507,816 a sum of UGX.896,409,230 was spent indicating an absorption level of 97.3 %."], [null, null, "The unspent balance of UGX. 26,098,586 related to the production of the"], [null, null, "disability status report activities that were not undertaken."], [null, null, "\uf0b7"], [null, null, "\uf0b7 I sampled eleven (11) outputs with thirteen (13) activities worth UGX."], [null, null, "877,320,000, representing 71% of the total budget, and noted that 10"], [null, null, "outputs (91%) with eleven (11) activities and expenditure worth UGX."], [null, null, "0.5899Bn were fully quantified. In addition, One (1) output with two (2)"], [null, null, "activities worth UGX.0.1221Bn was insufficiently quantified. Out of the"], [null, null, "ten (10) fully quantified outputs, three (3) outputs with three (3)"], [null, null, "activities worth UGX 0.0135Bn were fully implemented; six (6) outputs"], [null, null, "with seven (7) activities worth UGX 0.558Bnwere partially implemented"], [null, null, "and one (1) output with two (2) activities worth UGX 0.0184 were not"], [null, null, "implemented. The disability status report was not developed."], [null, null, "\uf0b7"], [null, null, "\uf0b7 To-date, council has not fully taken over the property of the Uganda"], [null, null, "Foundation for the blind, as such land located at Kireka and Mayuge has"], [null, null, "since been encroached upon by unknown persons. Council is at risk of"], [null, null, "losing these and other properties due to delays in taking possession and"], [null, null, "title."], ["4 National Council for Older Persons (NCOP) 2020/21 Opinion Unqualified \uf0b7 Out of the budgeted revenue of UGX. 726,000,000 for the financial year 2020/2021, UGX. 726,606,000 was received representing over 100% availability of funds for expenditure. This resulted in excess revenue of UGX. 606,000. \uf0b7 Out of the released funds amounting to UGX. 726,606,000 and unbudgeted Non-Tax revenue of UGX 1,198,590, only UGX.709,472,400 was spent by the entity resulting into an unspent balance of UGX. 18,332,190, representing absorption level of 97.5%.", null, null], ["5", "Uganda National Cultural Centre 2020/21", "\uf0b7 Out of the approved budget of UGX 15,407,572,000 a sum of UGX 13,245,324,701 was realized, resulting into a shortfall of UGX 2,162,247,299 representing 14% of the total budget. \uf0b7 Out of the total receipts of UGX 13,245,324,701, only UGX 10,700,171020 was spent by the entity resulting in an unspent balance of"], [null, "Opinion Unqualified", null], [null, "", ""], [null, null, "\uf0b7 Following parliament\u2019s pronouncement to collect UGX 1.6 Bn from a"], [null, null, "private company for the use of Nommo Gallery, Recovery measures have"], [null, null, "remained futile. UNCC has since stopped charging rent from the"], [null, null, "company."]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 304, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "292", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 304, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 Covid-19 stimulus funds amounting to UGX 6.8 Bn were paid in two"], [null, null, "batches to music/Arts promoters, without clearly documented criteria."], ["6 The National Children Authority (NCA) 2020/21 Opinion Unqualified \uf0b7 Out of the approved budget of UGX. 901,908,000 a sum of UGX. 826,112,357 was realized resulting into a shortfall of 104,143,334, representing 8.7%. \uf0b7 Out of the subvention receipts of UGX. 797,764,666 and non-tax revenue of UGX 28,347,691, a sum of UGX. 825,311,734 was spent indicating an absorption rate of 99.9%. \uf0b7 The Authority has no governing board and this has led to absence of policy and operational guidelines, and irregular short term employment contracts. \uf0b7 The report on the state of children under the lock down period revealed limited access of reading materials provided, increase in physical abuse, teenage pregnancies and in some instances death. This was due to inadequacies in law enforcement, capacity and resource constraints for extension works at district level and lack of community awareness on the child rights legal framework.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 305, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", null, "\uf0b7 Covid-19 stimulus funds amounting to UGX 6.8 Bn were paid in two"], [null, null, "batches to music/Arts promoters, without clearly documented criteria."], ["6 The National Children Authority (NCA) 2020/21 Opinion Unqualified \uf0b7 Out of the approved budget of UGX. 901,908,000 a sum of UGX. 826,112,357 was realized resulting into a shortfall of 104,143,334, representing 8.7%. \uf0b7 Out of the subvention receipts of UGX. 797,764,666 and non-tax revenue of UGX 28,347,691, a sum of UGX. 825,311,734 was spent indicating an absorption rate of 99.9%. \uf0b7 The Authority has no governing board and this has led to absence of policy and operational guidelines, and irregular short term employment contracts. \uf0b7 The report on the state of children under the lock down period revealed limited access of reading materials provided, increase in physical abuse, teenage pregnancies and in some instances death. This was due to inadequacies in law enforcement, capacity and resource constraints for extension works at district level and lack of community awareness on the child rights legal framework.", null, null], ["7", "National Library of Uganda 2020/21", "\uf0b7 Out of the approved budget of UGX.1,228,432,118 expected, a sum of UG.1,076,772,693 was realized resulting into a shortfall of UGX."], [null, null, "151,659,425, which is 87.6% of the budget. The shortfall has since led to"], [null, "Opinion Unqualified", "increased rental and gratuity arrears."], [null, null, "\uf0b7 Out of the total funds available of UGX. 1,076,772,693 a sum of UGX.1,041,279,372 was spent indicating an absorption level of 96.7%."], [null, null, "The unspent balance of UGX. 35,493,321 was meant for the clearance"], [null, null, "costs of the periodical book donations from Book Aid International"], [null, null, "\uf0b7 I sampled eleven (11) outputs with a total of twelve (12) activities worth"], [null, null, "UGX.852,906,000, representing 69.4% of the total budget, and noted"], [null, null, "that Ten (10) outputs with a total of eleven (11) activities and"], [null, null, "expenditure worth UGX.0.801Bn were fully quantified. In addition, One"], [null, null, "(01) output with One (01) activity and expenditure worth UGX.0.012 Bn"], [null, null, "was not quantified. Out of the ten (10) fully quantified outputs, One (1)"], [null, null, "output with one (1) activity and expenditure worth UGX 0.010Bn was fully"], [null, null, "implemented. Six (06) outputs with seven (7) activities worth"], [null, null, "UGX.0.775Bn were partially implemented. Three (3) outputs with two (3)"], [null, null, "activities worth UGX.0.028Bn were not implemented. Review of the entity"], [null, null, "strategic plan 2016-2021 and production of a new one, and Sensitization"], [null, null, "of publishers on ISBN requirements were some of the activities not"], [null, null, "undertaken."], [null, null, "\uf0b7 NLU has outstanding rental obligations of up to UGX.145,351,824 which"], [null, null, "only attract litigation."], [null, null, "\uf0b7 2 Acres of land initially allocated to the NLU has been re-allocated without"], [null, null, "compensation."], ["8 National Women\u2019s Council 2020/21 Opinion Unqualified \uf0b7 Out of the approved budget of UGX. UGX.3,589,554,501, a sum of UGX.3,644,076,229 was realized resulting into a shortfall of UGX.31,238,272, representing 99% performance. \uf0b7 Out of the total released funds for the financial year of UGX.3,644,076,229, only UGX.3,597,158,934 was spent by the entity resulting into an unspent balance of UGX.46,917,295 representing an absorption level of 99%. \uf0b7 I noted that NWC did not link its budget to the strategic plan with activities worth UGX.1,686,300,000 that were specified in the entity", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 305, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "293", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 305, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["strategic plan for implementation during the fourth year (20/21) of the plan not being included in the budget for FY 2020-2021. NWC strategic plan is not aligned to that of the MoGLSD and hence not aligned to the NDP III. \uf0b7 All nineteen (19) outputs with thirty-five (35) activities and expenditure of UGX.3,597,158,934 were not quantified to enable assessment extent of output and activity implementation. \uf0b7 No risk assessments or review of internal controls were undertaken on the council\u2019s operational processes during the year.", null, null], ["9", "National Youth Council 2020/21 Opinion Unqualified", "\uf0b7 The entity budgeted to receive UGX.3.075Bn out of which UGX.2080Bn was received, resulting in a shortfall of UGX.0.995 Bn which is 32% of the budget. I also noted that out of the total receipts for the financial year of UGX 2.080 Bn, UGX 2.079 Bn was spent by the entity representing absorption level of 100%."], [null, "", null], ["10 National Social Security Fund 2020/21 Opinion Unqualified \uf0b7 No significant matters to report on. \uf0b7", null, null], ["11", "UNFPA Funded Programme Ref; UGA08CMH/HIV/GBV/UFP/A YP/FGM implemented by", "\uf0b7 No significant matters to report on."], [null, null, ""], ["12 UNFPA Funded Programme Ref: UGA08CMH/HIV/GBV/UFP/A YP/FGM implemented by The Ministry of Health, 2020 Opinion Unqualified \uf0b7 No significant matters to report on.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 306, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "294", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 306, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, null], ["13", "UNFPA Funded Programme Ref; Uga08cmh/Hiv/Gbv/Ufp/Ayp /Fgm Implemented by The", "\uf0b7 No significant matters to report on."], [null, null, "\uf0b7"], ["14 UNFPA Country Programme Component of Data and Populationdynamics Implemented by Ministry of Gender, Labour & Social Development (Mglsd) 2020 Opinion Unqualified \uf0b7 No significant matters to report on.", null, null], ["15", "Unfpa Funded Programmeme Component of Data and Population Dynamics Implemented by", "\uf0b7 No significant matters to report on."], [null, null, ""], ["16 Unfpa Funded Programme Component of Data and Population Dynamics Implemented by National Population Council (Npc) 2020 Opinion Unqualified \uf0b7 No significant matters to report on.", null, null], ["17", "Unfpa Funded Programme Component of Data and Population Dynamics Implemented by Uganda", "\uf0b7 No significant matters to report on."], [null, null, ""], ["HEALTH SECTOR", null, null], ["1.", "Centre for Disease Control and Prevention (CDC) Opinion Unqualified", "\uf0b7 I noted a variance of US$.241,921 between the expenditure recorded in the accounting system and the expenditure reported in the quarterly financial reports for the year ended 30th September 2020. The expenditure reported per quarterly reports totaled US$.3,177,866 as opposed to the audited total expenditure of US$.2,935,945."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 307, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "295", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 307, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "Agreement Grant/ Notice of Award vs actual expenditures showed that"], [null, "", "management of CDC \u2013 UPS had executed most of the budgeted activities"], [null, null, "for the year ended 30th September 2020. The overall budget"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 308, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", "", "Agreement Grant/ Notice of Award vs actual expenditures showed that"], [null, "", "management of CDC \u2013 UPS had executed most of the budgeted activities"], [null, null, "for the year ended 30th September 2020. The overall budget"], [null, null, "performance was 97%."], [null, null, "\uf0b7 I further noted instances of budget over runs to a tune of US$.198,986"], [null, null, "on three budget lines, a practise not permitted under the Cooperative"], [null, null, "Agreement."], [null, null, "\uf0b7 From the tests conducted on a sample of non-payroll disbursements (i.e."], [null, null, "supplies contract costs, Fringe Benefits, travel and other direct costs), I"], [null, null, "noted that cost totalling to US $ 54,135 were inadequately supported."], [null, null, "\uf0b7"], [null, null, "\uf0b7 I noted that monthly financial returns are supposed to be submitted by"], [null, null, "the 15th day of the subsequent month, but this was not complied"], ["2 Centre for Disease Control Project (PEPFAR Grant No: 6NU2GGH002221-01-01) 30 th September 2020 Opinion Unqualified \uf0b7 I noted that there was low absorption of project funds. I noted that out of the total receipts; only USD 1,864,527 (UGX. 6,884,001,756) was utilized leaving a balance of USD. 868,756 (UGX. 3,207,525,075); representing an absorption level of 68.2%. \uf0b7 I observed that the Project Chart of Accounts was not aligned with the IFMS Accounting codes. \uf0b7 I noted significant delays in the approval and payment for most activities whereby the average lead time for processing a payment was over three (3) months", null, null], ["3.", "The Italian Support to the Ugandan Health Sector Strategic Plan III (HSSP III) and the Peace, Recovery", "\uf0b7 The entire budgeted revenue of UGX.10,543,205,000 in respect of external financing by the Government of the Italian Republic was not received during the year. As a result, no planned activity was implemented."], [null, "and Development Plan (PRDP) for Northern Uganda - Karamoja Region Staff Housing Project (KRSHP) \u2013 Ministry of Health Project. 2019/20", null], [null, "Opinion", ""], [null, "Unqualified", null], [null, "", null], ["4\\. The Rehabilitation and Expansion of Kayunga and Yumbe Hospitals Project (KAYUP) -BADEA No. 0761, OFID No. 1628P and SFD No. 6/620 - Ministry of Health Project. 2019/20 \uf0b7 The project experienced significant revenue shortfalls. Out of the expected receipts of USD 19,064,124.79, the project received funding totalling USD.8,252,401.61 constituting USD. 6,240,515.26 from external sources and USD.2,011,886.35 (UGX. 7,505,000,000) from GoU counterpart contribution. This translated into a budget shortfall of USD 10,811,723.18 (representing 56.71% of the approved budget). \uf0b7 There were delays in Project implementation. The project became effective on 16th April 2015 and was initially expected to be completed on 28th February 2020 which was later extended to 31st December 2021. However, the cumulative project progress was at 99.5% as at 30th June 2020\\. Major delays were identified in the procurement and installation of Medical equipment, Ambulances, mini-buses and Pick-ups.", null, null], ["5.", "Uganda National Health Research Organization (UNHRO).", "\uf0b7 UNHRO did not have an approved strategic plan for the period 2015/16 - 2019/20. The organization implemented a draft strategic plan for five years 2015/2016-2019/2020. I observed that the entity did not fully"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 308, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "296", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 308, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "2019/20", "achieve any of the 6 strategic objectives in its expired draft strategic plan"], [null, "Opinion Unqualified", "it has been implementing for the last five years. \uf0b7 I noted that the Organization did not have a governing Board during the year under review, after the term of office for all former members of the Board expired in 2016."], [null, "", null], ["6\\. Uganda Nurses and Midwives Council (UNMC). 2019/20 Opinion Qualified \uf0b7 The Council made payments worth UGX 1,465,751,440 in the year ended 30th June 2019 which did not have supporting documents such as invoices, payment request forms and payment vouchers. I noted that no action had been taken by Management to account for the funds in the year ended 30th June 2020. \uf0b7 Management reported a financial loss of UGX.444,400,000 during the year. The amount was transferred from UNMC\u2019s Stanbic Bank Account No. 9030005852950 to M/S RAM Engineering (U) Ltd under fraudulent circumstances. \uf0b7 Council failed to collect budgeted revenue amounting to UGX 557,669,951 during the year. \uf0b7 Council had a total of UGX. 7.77bn available for implementation of planned activities. The total receipts for the financial year under review were UGX 2.71 bn. However, only UGX 1.84bn was absorbed (representing 23.7%) leaving a balance of UGX. 5.93bn. \uf0b7 I observed that the Council partially implemented six (6) of its planned outputs with a total of Nineteen (19) activities worth UGX 268.41M. I also observed that seven (7) outputs with a total of twenty (20) activities were not implemented at all. \uf0b7 The entity did not prepare and submit the annual monitoring plans to MoFPED and NPA as required. Further, the entity did not prepare and submit quarterly monitoring reports to the MoFPED as required. \uf0b7 A review of the Organization\u2019s Annual cumulative performance report and", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 309, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "297", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 309, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["the entity work plan revealed cases where the reported set targets were not consistent with the set targets in the entity work plans. \uf0b7 I observed conflicting in the Council governing laws. Section 51(2) of the Public Finance Management Act, 2015 requires the Accounting Officer of a public corporation, within two months after the end of each financial year, to prepare and submit to the Accountant-General, a summary statement of financial performance of the public corporation and give a copy of the summary statement to the Secretary to the Treasury. On the contrary, Section 18 (1) Part IV of the Nurses and Midwives Act, 1996 requires the Council to keep proper books of accounts and prepare the annual financial statements of accounts for the immediately preceding financial year not later than three months in the following year. Conflict in the governing laws hampers effective execution of UNMC mandate. \uf0b7 Section 4 of the UNMC Act 1996, requires each Council member to be a seconded representative of a particular institution or body and must be appointed by the Minister. However, a review of Council Members records revealed that out of the seventeen (17) members, none of them were seconded representatives of their respective bodies. \uf0b7 Good Corporate Governance practices require separation of duties of board members to ensure their independence in the discharge of duties. On the contrary, a review of the composition of the Audit Committee revealed that Chairperson of the full council is also a member of the committee. \uf0b7 I noted that the Council had not been managed by a substantive Registrar since 2017. The current Registrar\u2019s initial appointment ran from November 2018 to March 2019. However, management did not provide a valid appointment letter to confirm her appointment after March 2019. \uf0b7 A review of the Governing council minute ref FC/08/14/06/2020 revealed that council members were concerned about the significant delays in issuing of Practicing Certificates that hindered the recruitment of nurses in the industry. Furthermore, Management did not avail status reports on certificates that were produced. \uf0b7 Payment files and PPDA monthly reports revealed that supplies and service worth UGX 46,183,800 were procured and paid without going through the procurement process given that there were no LPOs or procurement documents availed to confirm that the supplier went through the procurement process. \uf0b7 UNMC has three (3) operational vehicles. However, a detailed review of the fleet management revealed that there were no log books maintained to track the vehicle movements as required by the regulations. Further, there were no records being maintained to keep track of vehicle history, performance, servicing, overheads, repairs and maintenance.", null, null], ["7.", "Uganda Sanitation Fund (USF) \u2013 Ministry of Health Project. 2019/20 Opinion", "\uf0b7 A review of the annual work plan and the performance reports for the Uganda Sanitation Fund revealed that there were inconsistencies in planned targets and those reported upon. Furthermore, the planned targets/outputs in the work plan lacked sufficient detail (description of outputs) to facilitate a meaningful comparison with the targets in the performance reports."], [null, "Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 310, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "298", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 310, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "the quarterly district performance work plans and reports submitted to"], [null, null, "the Ministry, revealed that, the quarterly release of funds from MOFPED"], [null, null, "was not done on time. As a result, Quarter 1 funds were disbursed in"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 311, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", null, "the quarterly district performance work plans and reports submitted to"], [null, null, "the Ministry, revealed that, the quarterly release of funds from MOFPED"], [null, null, "was not done on time. As a result, Quarter 1 funds were disbursed in"], [null, null, "quarter 2, quarter 2 funds were disbursed in quarter 3, and quarter 3"], [null, null, "funds disbursed in quarter 4."], [null, null, "\uf0b7 Since the project\u2019s inception, only a total of UGX.1.3bn (USD 386,259)"], [null, null, "out of the agreed GOU counterpart funding commitment of USD"], [null, null, "2,000,000 had been disbursed to the districts resulting into a funding"], [null, null, "shortfall of USD 1,613,741."], [null, null, "\uf0b7 The program\u2019s average national progress on Open Defecation Free (ODF)"], [null, null, "target stood at 60.9% yet the project is in its last year of implementation."], [null, null, "An Assessment of the 9-year targets (July 2011 to June 2020) revealed"], [null, null, "that out of the targeted 11,354 villages, only 9,632 achieved ODF targets,"], [null, null, "representing 84.8%; a total of 140 of the 400 targeted parishes"], [null, null, "representing 35% achieved ODF; and only 27 of the targeted 360 sub"], [null, null, "counties achieved the ODF target representing 7.5% achieved ODF"], [null, null, "status."], ["8 Allied Health Professionals Council. 2019/20 Opinion Unqualified \uf0b7 The Governing Council stated that a material uncertainty existed regarding the continued operation of Allied Health Professionals Council in the foreseeable future. \uf0b7 Management\u2019s judgement was informed by a letter from the PS - Ministry of Public Service to all Accounting Officers in which guidance was provided on the modalities for management of Public Institutions during the implementation of recommendations on the rationalization of Agencies and Public Expenditure. \uf0b7 I noted that out of the ten (10) sampled outputs with a total of ten (10) activities and expenditure of UGX. 3.127bn, only five (5) outputs with five (5) activities and expenditure worth UGX 3.017Bn were fully quantified. The balance of five (5) outputs with five (5) activities and expenditure worth UGX.011Bn were insufficiently quantified which made it difficult to assess extent of their delivery. \uf0b7 I observed that out of the five (5) outputs that were fully quantified, three (3) outputs with three (3) activities worth UGX. 1.918Bn were fully implemented. However, the remaining two (2) outputs with two (2) activities worth UGX.1.099Bn were partially implemented. \uf0b7 The Council fleet of six (6) sampled vehicles was not annually inspected during the three (3) year period under review to assess their mechanical condition and road worthiness. \uf0b7 Whereas the Council designated a Transport Officer responsible for transport matters, fuel registers were not maintained for all the six (6) motor vehicles sampled out of nine (9) vehicles held by the Council. \uf0b7 I noted that nine (9) out of the ten (10) Regional Offices were not allocated vehicles to facilitate their operations.", null, null], ["9", "Joint Clinical Research Centre. 2019/20", "\uf0b7 The entity budgeted to receive UGX 20,906,339,925 from development partners out of which UGX 19,707,530,000 was received resulting in a shortfall of UGX 1,198,809,925. In addition, out of budgeted local revenue of UGX 4,366,651,934, only UGX 2,693,800,000 was generated resulting into a shortfall of UGX 1,672,851,934."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 311, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "299", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 311, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "activities (12%) were partially implemented while forty-four (44) activities"], [null, null, "(28%), were not implemented by the time of audit."], [null, null, "\uf0b7 I reviewed the balance of \u2018payables falling within one year\u2019 reported in"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 312, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", null, "activities (12%) were partially implemented while forty-four (44) activities"], [null, null, "(28%), were not implemented by the time of audit."], [null, null, "\uf0b7 I reviewed the balance of \u2018payables falling within one year\u2019 reported in"], [null, null, "the Statement of Financial Position and Note 21 and noted an increase of"], [null, null, "UGX 121,010,000 from UGX 1,138,910,000 (30th June 2019) to UGX"], [null, null, "1,259,920,000 (30th June 2020). I further reviewed the ageing of the"], [null, null, "payables and noted that included in the outstanding balance of UGX"], [null, null, "1,259,920,000 are payables worth UGX 357,139,495 that had remained"], [null, null, "outstanding for over 90 days."], [null, null, "\uf0b7 Seventeen (17) running motor vehicles which were fully depreciated"], [null, null, "according to the JCRC Fleet Management Policy and had zero net book"], [null, null, "value in the schedule of fixed assets were still in use. The entity did not"], [null, null, "revalue or make annual reviews of its expectations with regard to the"], [null, null, "residual values and useful lives of the vehicles in question resulting into"], [null, null, "under valuation/understatement of non-current assets in use in the"], [null, null, "statement of financial position."], [null, null, "\uf0b7 The Principal Private Secretary to His Excellency the President\u2019s letter ref:"], [null, null, "PO/1 dated 12th February 2019 directed the Hon. Minister of Finance,"], [null, null, "Planning & Economic Development to increase Government funding to"], [null, null, "the Centre from UGX.240 million to UGX.5 billion annually in the"], [null, null, "subsequent years, that is, with effect from the Financial Year 2019/20."], [null, null, "According to the various communications by the Centre\u2019s Executive"], [null, null, "Director, the increment in funding was necessitated by the declining"], [null, null, "donor support."], [null, null, "\uf0b7 However, the no-objection for the implementation of the directive was"], [null, null, "only granted to the PS/ST by the PS MOH through letter ref: 45/415/01"], [null, null, "dated 4th February 2020. This was when the financial year 2019/20"], [null, null, "budget was in the third quarter of implementation."], [null, null, "\uf0b7 Contrary to the PPDA requirements, the entity delayed to submit ten (10)"], [null, null, "out of twelve (12) monthly procurement and disposal reports to the"], [null, null, "Authority for the financial year under review."], [null, null, "\uf0b7 The Centre had a procurement plan worth for the year under review. I"], [null, null, "noted that out of the planned procurements worth UGX 6,956,028,077,"], [null, null, "procurements worth UGX 5,434,128,077 (78%) were implemented while"], [null, null, "those worth UGX 1,521,900,000 (22%) were not conducted."], ["10 Uganda Medical and Dental Practitioners Council. 2019/20 Opinion Unqualified \uf0b7 The Governing Council stated that a material uncertainty existed regarding the continued operation of Allied Health Professionals Council in the foreseeable future. \uf0b7 Management\u2019s judgement was informed by a letter from the PS - Ministry of Public Service to all Accounting Officers in which guidance was provided on the modalities for management of Public Institutions during the implementation of recommendations on the rationalization of Agencies and Public Expenditure. \uf0b7 I noted that out of the budgeted Non-Tax revenue UGX.2,891,430,000, only UGX.1,650,811,279 was realized during the year under review (representing 57% performance). This hampered effective service delivery. \uf0b7 Contrary to the statutory deadline of 31st day of March for the publication all up-to-date registers in the gazette, registers for 2020 had not been published in the gazette by the time of audit in November 2020.", null, null], ["11", "The Rehabilitation and Expansion of Kayunga and", "\uf0b7 The project experienced significant revenue shortfalls. Out of the expected receipts of USD 19,064,124.79, the project received funding"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 312, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "300", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 312, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Yumbe Hospitals Project", "totalling USD.8,252,401.61 constituting USD. 6,240,515.26 from external"], [null, "(KAYUP) -BADEA No. 0761,", "sources and USD.2,011,886.35 (UGX. 7,505,000,000) from GoU"], [null, "OFID No. 1628P and SFD", "counterpart contribution. This translated into a budget shortfall of USD"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 313, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", "Yumbe Hospitals Project", "totalling USD.8,252,401.61 constituting USD. 6,240,515.26 from external"], [null, "(KAYUP) -BADEA No. 0761,", "sources and USD.2,011,886.35 (UGX. 7,505,000,000) from GoU"], [null, "OFID No. 1628P and SFD", "counterpart contribution. This translated into a budget shortfall of USD"], [null, "No. 6/620 \u2013 Ministry of Health Project. 2019/20 Opinion Unqualified", "10,811,723.18 (representing 56.71% of the approved budget). \uf0b7 There were delays in Project implementation. The project became effective on 16th April 2015 and was initially expected to be completed on 28th February 2020 which was later extended to 31st December 2021. However, the cumulative project progress was at 99.5% as at 30th June 2020\\. Major delays were identified in the procurement and installation of"], [null, null, "Medical equipment, Ambulances, mini-buses and Pick-ups."], ["12 Uganda-Spain Debt Swap Project. 2019/20 Opinion Unqualified \uf0b7 I noted that out of the two (2) planned project outputs for the year, one (1) output was fully implemented while one (1) output was partially implemented. Management attributed the level of performance to delayed commencement of the preparation of the detailed designs for the refurbishment and equipping of Busolwe General Hospital which involved approval of extra charges for the consultant to revise the site survey report. According to management, the COVID-19 pandemic further affected the operations of the Consultant. \uf0b7 During the year under review, the Project received a sum of UGX 15.69Bn of which UGX.10.63Bn was spent resulting in an unspent balance of UGX.5.06Bn (representing an absorption level of 67.8%).", null, null], ["13", "Uganda Reproductive Health Voucher Project (URHVP) GPOBA Grant Number TF015995. 2019/20", "\uf0b7 A review of the project financial statements as at 30th June 2020 (Note 2 & Annex 6.0) together with underlying financial records revealed that the project had bank balances of USD 49.85 and UGX.792 in Bank of Uganda at the time of closure. However, Management did not avail documentary proof of closure of these Accounts at the end of the project when sought."], [null, "Opinion Unqualified", null], ["14 Butabika National Mental Referral Hospital. Opinion Unqualified \uf0b7 The entity budgeted to collect NTR of UGX 1.24bn during the year under review. However, the hospital collected UGX. 1.15bn thereby resulting into a shortfall of UGX 0.09bn. \uf0b7 The Hospital received the entire revised annual budget of UGX 17.023bn out of which UGX 16.551bn was spent resulting in unutilized funds of UGX 0.472bn. The unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account. \uf0b7 I noted that the entity submitted all the quarterly performance reports after the prescribed deadline. The Accounting Officer explained that due to COVID-19 restrictions, the support offices were operating at 10% which led to delays in preparation and submission of the quarterly performance reports. \uf0b7 According to the patient admission schedule and the strategic plan, the Hospital currently handles between 750 and 780 in-patients per month compared to its bed capacity of 550 patients. This implies that 200 to 230 admitted patients either share beds or sleep on the floor. \uf0b7 I noted that UGX.93,717,182 was utilized for repairs and service for vehicles during the year under review. However, there were no repair and service analysis registers for the 13 vehicles that were maintained. Furthermore, it was observed that the Hospital Transport Officer did not maintain service charts for all the 13 vehicles.", null, null], ["15", "Kawempe National Referral", "\uf0b7 The entity budgeted to collect NTR of UGX. 449m during the year under"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 313, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "301", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 313, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Hospital.", "review, and UGX. 451m was realized, representing a performance of"], [null, "Opinion Unqualified", "100.4% of the target. \uf0b7 Out of the total receipts for the financial year of UGX 11.723 bn, UGX. 11.385Bn was spent by the entity resulting in an unspent balance of UGX.0.337Bn (representing an absorption level of 97.1%). The unspent"], [null, null, "balance at the end of the financial year was subsequently swept back to"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 314, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", "Hospital.", "review, and UGX. 451m was realized, representing a performance of"], [null, "Opinion Unqualified", "100.4% of the target. \uf0b7 Out of the total receipts for the financial year of UGX 11.723 bn, UGX. 11.385Bn was spent by the entity resulting in an unspent balance of UGX.0.337Bn (representing an absorption level of 97.1%). The unspent"], [null, null, "balance at the end of the financial year was subsequently swept back to"], [null, null, "the consolidated fund account."], [null, null, "\uf0b7 I noted that all the eight (8) outputs selected for budget performance"], [null, null, "assessment with a total of eleven (11) activities and actual expenditure of"], [null, null, "UGX 4.6bn were fully quantified. This therefore enabled me to assess the"], [null, null, "Hospital\u2019s performance during the year under review."], [null, null, "\uf0b7 Out of the eight (8) sampled outputs, two (2) outputs were fully"], [null, null, "implemented while six (6) were partially implemented. I further noted"], [null, null, "that out of the planned eleven (11) activities under the sampled outputs,"], [null, null, "two (2) activities were fully achieved while nine (9) were partially"], [null, null, "achieved."], [null, null, "\uf0b7 A total of UGX 36,870,179 worth of expenditure was charged on other"], [null, null, "than the budget lines on which the funds were appropriated without"], [null, null, "seeking the necessary approval from the relevant authorities."], [null, null, "\uf0b7 I noted that the Hospital submitted all the quarterly performance reports"], [null, null, "beyond the prescribed deadlines."], [null, null, "\uf0b7 From my review of the annual performance reports and physical"], [null, null, "inspections/verification of outputs reported, I did not observe"], [null, null, "inconsistencies in the reported performance."], [null, null, "\uf0b7 I noted that the Hospital accumulated payables/domestic arrears to tune"], [null, null, "of UGX. 799,186,746 up from UGX. 365,151,250 as at 30th June 2020."], [null, null, "\uf0b7 I noted that whereas the Board of Survey Report for the year ended 30th"], [null, null, "June 2021 established that the Hospital had a closing inventory of various"], [null, null, "items; this state of affairs was not disclosed as part of the Financial"], [null, null, "Statements under Annex (ii)-Schedule of Inventory, thereby rendering"], [null, null, "the financial statements incomplete."], [null, null, "\uf0b7 It was noted that the Hospital stored expired medicines without disposing"], [null, null, "them as required by the law. Out of the seventy four (74) items of"], [null, null, "expired drugs, I observed that thirty six (36) had expired by end of"], [null, null, "December 2020 (representing 49%). Under the circumstances, lives of"], [null, null, "patients are threatened by the existence of expired medicines at the"], [null, null, "hospital premises."], [null, null, "\uf0b7 I noted that the Referral Hospital was heavily congested with patients"], [null, null, "crowded in the wards and some sleeping on the floors. This was further"], [null, null, "evidenced by the data collected on Bed Occupancy Rates which showed"], [null, null, "an average BOR of 113% for the year under review. Congestion was also"], [null, null, "observed in the stores where some items were placed directly on the"], [null, null, "floor exposing them to damage."], [null, null, "\uf0b7 From a review of payments and procurements made during the year, I"], [null, null, "noted that procurements of goods worth UGX 187,406,417 were not"], [null, null, "supported with ledgers in the stores to track delivery and utilization of the"], [null, null, "accountable inventories procured."], ["16 Kiruddu National Referral Hospital. Opinion Unqualified \uf0b7 I noted that the Hospital\u2019s 5-Year Strategic Plan (FY 2020/21-2024/25) had been approved by National Planning Authority (NPA) by the time of audit. \uf0b7 The entity budgeted to collect NTR of UGX. 1,520,000,000 during the", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 314, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "302", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 314, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["year under review, and UGX. 719,423,137 was realized, representing a performance of 46.9% of the target. \uf0b7 Out of the total warrants of UGX.18.8Bn received during the financial year, UGX. 18.3Bn was spent by the entity resulting in an unspent balance of UGX. 0.5Bn (representing an absorption level of 97.3%). The unspent funds were swept back to the consolidated fund as required by the PFMA. \uf0b7 Out of the ten (10) outputs selected for budget performance assessment with a total of twenty four (24) activities and expenditure of UGX 12.16bn, I noted that seven (7) outputs with a total of fourteen (14) activities and expenditure worth UGX 9.99bn were fully quantified. Two (2) outputs with a total of eight (8) activities and expenditure worth UGX 1.9Bn, was insufficiently quantified. One (1) output with a total of two (2) activities and expenditure worth UGX 0.27bn were not quantified at all to enable performance assessment. \uf0b7 Out of the seven (7) outputs that were fully quantified with a total of fourteen (14) activities, four (4) outputs with a total of six (6) activities were fully implemented. Three (3) outputs with a total of eight (8) activities worth UGX 8.45bn were partially implemented. Out of the eight (08) activities, the entity fully implemented two (02) activities (25%) while six (06) activities (75%) remained partially implemented. \uf0b7 I noted that the Hospital submitted three (3) out of four (4) quarterly performance reports to Treasury within the prescribed deadlines. However, there was no documentary proof of preparation and submission of annual monitoring plans and reports to MoFPED and NPA as required. I further noted inconsistences in the financial information reported in the performance reports when compared with the financial statements. \uf0b7 A review of drugs supply chain management revealed that on several occasions there were drug stock-outs which left Kiruddu Hospital without several essential, vital and necessary drugs. \uf0b7 Inspection of the hospital drug stores revealed that some drugs/chemicals had expired in the Hospital stores. This could have been due to low utilization rates, receipt of drugs with short shelf life or placement of orders that do not match the usage patterns. \uf0b7 I noted that 55 new recruits were not cleared by Ministry of Public Service as required. The Accounting Officer attributed the anomaly to the need to fill critical vacant positions in the hospital.", null, null], ["17", "National Drug Authority.", "\uf0b7 NDA had an approved five-year strategic plan FY 2020/21-2024/25 which was well aligned to the National Development Plan in terms of timelines."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 315, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["year under review, and UGX. 719,423,137 was realized, representing a performance of 46.9% of the target. \uf0b7 Out of the total warrants of UGX.18.8Bn received during the financial year, UGX. 18.3Bn was spent by the entity resulting in an unspent balance of UGX. 0.5Bn (representing an absorption level of 97.3%). The unspent funds were swept back to the consolidated fund as required by the PFMA. \uf0b7 Out of the ten (10) outputs selected for budget performance assessment with a total of twenty four (24) activities and expenditure of UGX 12.16bn, I noted that seven (7) outputs with a total of fourteen (14) activities and expenditure worth UGX 9.99bn were fully quantified. Two (2) outputs with a total of eight (8) activities and expenditure worth UGX 1.9Bn, was insufficiently quantified. One (1) output with a total of two (2) activities and expenditure worth UGX 0.27bn were not quantified at all to enable performance assessment. \uf0b7 Out of the seven (7) outputs that were fully quantified with a total of fourteen (14) activities, four (4) outputs with a total of six (6) activities were fully implemented. Three (3) outputs with a total of eight (8) activities worth UGX 8.45bn were partially implemented. Out of the eight (08) activities, the entity fully implemented two (02) activities (25%) while six (06) activities (75%) remained partially implemented. \uf0b7 I noted that the Hospital submitted three (3) out of four (4) quarterly performance reports to Treasury within the prescribed deadlines. However, there was no documentary proof of preparation and submission of annual monitoring plans and reports to MoFPED and NPA as required. I further noted inconsistences in the financial information reported in the performance reports when compared with the financial statements. \uf0b7 A review of drugs supply chain management revealed that on several occasions there were drug stock-outs which left Kiruddu Hospital without several essential, vital and necessary drugs. \uf0b7 Inspection of the hospital drug stores revealed that some drugs/chemicals had expired in the Hospital stores. This could have been due to low utilization rates, receipt of drugs with short shelf life or placement of orders that do not match the usage patterns. \uf0b7 I noted that 55 new recruits were not cleared by Ministry of Public Service as required. The Accounting Officer attributed the anomaly to the need to fill critical vacant positions in the hospital.", null, null], ["17", "National Drug Authority.", "\uf0b7 NDA had an approved five-year strategic plan FY 2020/21-2024/25 which was well aligned to the National Development Plan in terms of timelines."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 315, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "303", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 315, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "of non-recoverability, thus denying the Authority realization of revenue"], [null, null, "for achievement of its objectives."], [null, null, "\uf0b7 Seventeen (17) running motor vehicles were fully depreciated during the"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 316, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": [["", null, "of non-recoverability, thus denying the Authority realization of revenue"], [null, null, "for achievement of its objectives."], [null, null, "\uf0b7 Seventeen (17) running motor vehicles were fully depreciated during the"], [null, null, "previous year, reflected at zero book value and removed from the"], [null, null, "Statement of Financial Position. Removal from the statement of financial"], [null, null, "position of assets still in use and with no evidence that future economic"], [null, null, "benefits will not be expected from disposal of the same, misrepresents"], [null, null, "the entity\u2019s financial position."], [null, null, "\uf0b7 There was slow progress on the civil works NDA laboratory Tower."], [null, null, "Further, works for the amended building plans for the NDA laboratory"], [null, null, "Tower had commenced by the time of audit in August 2021 prior to"], [null, null, "approval by the Metropolitan Physical Planning Authority contrary to"], [null, null, "Section 22 (1f) of the KCCA Act 2010."], [null, null, "\uf0b7 The Authority fully paid UGX.343,694,683 in advance to providers"], [null, null, "awarded contracts for the supply of analytical equipment without"], [null, null, "obtaining appropriate advance payment security. I also noted that the"], [null, null, "Authority signed contracts to a tune of USD 14,872.8 with two domestic"], [null, null, "suppliers in foreign currency."], ["18 Uganda National Health Research Organization. Opinion Unqualified \uf0b7 The Sessional Parliamentary Committee on Social services recommended the granting of a vote status to the Organization. This was followed by issuance of statutory instruments and the gazetting and commencement of the Uganda National Health Research Organisation Act, 2011 on the 22nd day of January 2016. However, I noted that the Organization had not been granted a vote status by the time of audit. \uf0b7 I noted that the Organization did not have a governing Board during the year under review, after the term of office for all former members of the Board expired in 2016. \uf0b7 The employment contract on file for the Director General expired in April 2018 and had not been renewed by the time of audit. \uf0b7 Only 12 out of the approved 26 positions in the Organizational Structure had been filled resulting into a staffing gap of 14 positions. \uf0b7 The Organization was financed by a subvention of only UGX.240m out of which 94% was earmarked for wage leaving only 6% for operational costs.", null, null], ["19", "Uganda National Health Research Organization. Opinion Unqualified", "\uf0b7 The Sessional Parliamentary Committee on Social services recommended the granting of a vote status to the Organization. This was followed by issuance of statutory instruments and the gazetting and commencement of the Uganda National Health Research Organisation Act, 2011 on the 22nd day of January 2016. However, I noted that the Organization had"], [null, null, "not been granted a vote status by the time of audit."], [null, null, "\uf0b7 I noted that the Organization did not have a governing Board during the"], [null, null, "year under review, after the term of office for all former members of the"], [null, null, "Board expired in 2016."], [null, null, "\uf0b7 The employment contract on file for the Director General expired in April"], [null, null, "2018 and had not been renewed by the time of audit."], [null, null, "\uf0b7 Only 12 out of the approved 26 positions in the Organizational Structure"], [null, null, "had been filled resulting into a staffing gap of 14 positions."], [null, null, "\uf0b7 The Organization was financed by a subvention of only UGX.240m out of"], [null, null, "which 94% was earmarked for wage leaving only 6% for operational cos"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 316, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "304", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 316, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["20 Joint Clinical Research Centre (JCRC). Opinion Unqualified \uf0b7 JCRC reported trade and other receivables of UGX.4,210,400,000. Out of this UGX.95,254,972 related to the previous financial year. I noted that JCRC did not make any provision for bad debts as required by IFRS 9 and its Manual. Failure to make provisions may result into overstating reported receivables due to unaccounted for risks of non-recoverability. In addition, there was no evidence from the Finance Committee that a review of the bad debts position was annually done. Management explained that in addition to sending out constant reminders to the listed debtors, Management would review the list further for presentation to the Finance Committee of the Board. I advised the Accounting officer to make the required provisions for bad debts in accordance with Standards and the Manual \uf0b7 I noted that JCRC signed contracts with local service providers in foreign currency to a tune of USD 32,258.7. The contracts were for supply of Bone density kits (USD 25,515); supply of Hematology reagents (USD 2,060), and; for internet services (USD 4,683). I advised the Accounting Officer to take heed of the PS/ST recommendation and ensure that all local contracts are awarded in Uganda Shillings.", null, null], ["21", "Uganda Blood Transfusion Services (UBTS).", "\uf0b7 I noted that the entity had prepared and approved its plan. However, approval and certification had not yet been obtained from the National Planning Authority."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 317, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "305", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 317, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "reflected as Plot 27 instead of 2F on the cover page of the title deed for"], [null, "the land currently occupied by Nakasero Blood Bank. Management wrote"], [null, "to the Secretary Uganda Land Commission about the anomaly in a letter"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 318, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None"], "type": "table"}}, {"content": [["", "reflected as Plot 27 instead of 2F on the cover page of the title deed for"], [null, "the land currently occupied by Nakasero Blood Bank. Management wrote"], [null, "to the Secretary Uganda Land Commission about the anomaly in a letter"], [null, "dated 5/4/2012 Reference number UBTS/ADM/LT/01, no response had"], [null, "been received to date. Furthermore, 0.079 hectares of Nakasero Blood"], [null, "Bank were reported to have been encroached on by the fence of Pearl of"], [null, "Africa Hotel on plots 2E and 7A1-9A1 as per the boundary opening"], [null, "reports of 23rd November 2009 (S.M Geoteam ltd) and 2nd August 2013"], [null, "(Terrain Consult) who had been appointed by UBTS."], [null, "\uf0b7 I noted a one year\u2019s delayed execution of works for the completion of the"], [null, "remodelling of a store at Nakasero Blood Bank. A sum of UGX 2.86bn had"], [null, "so far been paid against the contract sum of UGX.3.77bn."], [null, "\uf0b7 I noted that a total of UGX.0.968Bn was spent on the Blood Safety"], [null, "Information System during the year. Whereas there was information on"], [null, "blood collected, stored and issued during the year, there was no"], [null, "information on how the 224,303 units of blood that had been issued to"], [null, "the different health facilities had been utilized."], ["22 Uganda Virus Research Institute. Opinion Unqualified \uf0b7 I noted that the entity had prepared and approved its plan. However, approval and certification had not yet been obtained from the National Planning Authority. \uf0b7 I noted that the entity did not budget or collect NTR during the year under review. \uf0b7 This was attributed to the breakdown of the Nitrogen plant three years ago which was the main source of revenue. However, the Institute received funds from GoU and was in the process of procuring a new Nitrogen plant. \uf0b7 The Institute received the entire budget of UGX.8.97bn out of which UGX.8.95bn was spent by the entity resulting in an unspent balance of UGX.20.76m (representing an absorption level of 98.8%). The unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account. \uf0b7 Two (2) outputs with a total of two (2) activities and expenditure of UGX 2.23bn were fully quantified out of the eight (8) outputs with a total of twenty-two (22) activities and expenditure of UGX 8.20bn sampled for assessment. None of the two (2) quantified activities under the two (2) outputs was implemented at all. \uf0b7 Two (2) outputs with a total of seven (7) activities and expenditure worth UGX.4.99Bn were insufficiently quantified. Out of the seven (7) activities, two (2) activities (29%) was quantified, while the balance of five (5) activities (71%) were not clearly quantified to enable the assessment of performance. \uf0b7 Four (4) outputs with a total of thirteen (13) activities and expenditure worth UGX 980m were not quantified at all. That is none of the thirteen (13) activities within these outputs was quantified at all. \uf0b7 I noted that funds to the tune of UGX 53,300,000 were irregularly reallocated from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 I noted that the entity submitted performance reports for Q1, Q2, Q3, Q4 after the prescribed deadline.", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 318, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None"], "type": "table"}}, {"content": "306", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 318, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 Payables worth UGX 0.409bn remained outstanding from financial year ended 30th June 2019 to-date. I noted that management did not provide for the settlement of domestic arears in the approved budget estimates for the year under review. \uf0b7 A review of the staff structure of Uganda Virus Research Institute revealed that out of the approved structure of 237, only 75 positions were filled leaving 162 staff positions vacant. \uf0b7 A review of a sample of 19 procurement files with a total value of UGX.1.61Bn revealed that the Institute did not require suppliers to provide any form of an acceptable performance guarantee for procurements worth UGX.1.42Bn. \uf0b7 Analysis of payment records and review of staff files revealed that 5 staff of the Institution had retired but had not yet accessed the pension payroll although the six months pensions processing period had elapsed.", null, null], ["23", "National Medical Stores.", "\uf0b7 I noted that the Corporation budgeted to collect NTR of UGX.56.37Bn during the year under review. Out of this, only UGX.39.80Bn was collected thereby resulting into a shortfall of UGX.16.57bn."], [null, "Opinion Unqualified", null], ["24 Uganda Heart Institute. Opinion Unqualified \uf0b7 I noted that the Hospital\u2019s 5-Year Strategic Plan (FY 2020/21 -2024/25) was approved by National Planning Authority (NPA) on 27th September 2021 vide certificate no. 26(3). \uf0b7 Out of eight (8) outputs with a total of forty eight (48) activities and expenditure of UGX.11.50Bn sampled for assessment, I noted that four", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 319, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "307", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 319, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["(4) outputs with a total of seventeen (17) activities and expenditure worth UGX 7.196Bn were fully quantified; four (4) outputs with a total of thirty one (31) activities and expenditure worth UGX 4.306Bn were insufficiently quantified. \uf0b7 I assessed the extent of delivery of the 4 outputs that were fully quantified and noted that one (1) output with a total of two (2) activities worth UGX 0.439Bn was fully implemented. \uf0b7 Two (2) outputs with a total of fourteen (14) activities worth UGX 6.606Bn were partially implemented. Out of the fourteen (14) activities, the entity fully implemented four (4) (29%) activities; seven (7) activities (50%) were partially implemented while three (3) (21%) activities remained unimplemented. One (1) output with only one (1) activity worth 0.15Bn was not implemented at all. \uf0b7 I noted that funds to the tune of UGX. 24.13m were irregularly re- allocated from the activities on which they were budgeted and spent on other activities without seeking and obtaining the necessary approvals. \uf0b7 The entity submitted performance reports for Q1, Q2, Q3, and Q4 after the prescribed deadline. In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which are important in ensuring that the budget performs as expected. \uf0b7 From my review of the annual cumulative performance reports and physical inspections/verification of performance, I did not observe any inconsistencies with the results of my verification. \uf0b7 I noted that insufficient budget provisions (UGX.73,885,634) were made towards settlement of domestic arrears yet the arrears brought forward from the previous year were UGX.1,429,802,685. \uf0b7 The Institute had NTR debtors to the tune of UGX. 282.97m at the end of the financial year under review. These were receivables from various insurance companies, MDAs and institutions for services rendered by the Institute. \uf0b7 The Land Commission received a presidential directive to allocate Uganda Heart Institute 10 acres of land in Nakawa Naguru to facilitate the setting up of a Cardiac Centre of Excellence with a 250 bed hospital. However, I noted that during the year there were encumbrances on part of the allocated land which resulted in the loss of 3 acres after consensual withdrawal of a law suit. \uf0b7 Whereas the total contract sum of UGX. 3.5bn had been paid out for the renovation of the Intensive Care Unit on Block 1C, the works remained incomplete at the time of writing this report. \uf0b7 A review of the staff structure of Uganda Heart Institute revealed that out of the approved structure of 189, only 160 positions were filled leaving 29 staff positions vacant.", null, null], ["25", "Mulago Specialized Women & Neonatal Hospital.", "\uf0b7 The entity budgeted to collect NTR of UGX. 7bn during the year under review, and UGX. 3.64bn was realized, representing a performance of 52% of the target."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 320, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "308", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 320, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "five (25) activities and expenditure of UGX 17.7bn, only eight (8) outputs"], [null, "with a total of fourteen (14) activities worth UGX 9.1bn were fully"], [null, "quantified. Two (2) outputs with a total of nine (9) activities and"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 321, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None"], "type": "table"}}, {"content": [["", "five (25) activities and expenditure of UGX 17.7bn, only eight (8) outputs"], [null, "with a total of fourteen (14) activities worth UGX 9.1bn were fully"], [null, "quantified. Two (2) outputs with a total of nine (9) activities and"], [null, "expenditure worth UGX.8Bn, was insufficiently quantified. I observed that"], [null, "out of the nine (9) activities, six (6) activities (66.7%) were quantified,"], [null, "while the balance of three (3) activities (33.3%) were not clearly"], [null, "quantified to enable the assessment of performance. Two (2) outputs"], [null, "with a total of two (2) activities and expenditure worth UGX 0.550Bn"], [null, "were not quantified at all. That is none of the two (2) activities within"], [null, "these outputs was quantified at all."], [null, "\uf0b7 Out of the eight (8) fully quantified outputs with a total of fourteen (14)"], [null, "activities and expenditure worth UGX.9.1Bn, seven (7) outputs with ten"], [null, "(10) activities and expenditure worth UGX 4.8Bn were fully implemented."], [null, "One (1) output with four (4) activities worth UGX.4.4Bn was partially"], [null, "implemented. Out of the four (4) activities, the entity fully implemented"], [null, "three (3) activities; one (1) activity was partially implemented, while no"], [null, "activity remained unimplemented."], [null, "\uf0b7 A well equipped kitchen with boilers, fridges, gas cookers, cabinets, a"], [null, "chimney and a full outer gas tank was constructed at the Hospital."], [null, "However, it was not yet in use at the time of audit."], [null, "\uf0b7 I noted that the Hospital submitted all the quarterly performance reports"], [null, "beyond the prescribed deadlines."], [null, "\uf0b7 From my review of the annual performance reports and physical"], [null, "inspections/verification of outputs reported, I did not observe"], [null, "inconsistencies in the reported performance."], [null, "\uf0b7 I noted that the hospital reported a payables figure of UGX.2,180,857,756"], [null, "of which UGX. 427,844,778 related to PAYE which was deducted but"], [null, "remained unremitted by close of the year under review."], ["26 Mulago National Referral Hospital. 2020/21 Opinion Qualified \uf0b7 Transfers of UGX.3,867,161,000 received from the Ministry of Health were not recognized in the Statement of Financial Performance. The receipts were also not reported in Note 5 to the Financial Statements. It was further noted that the funds which were received on the Hospital\u2019s Infrastructure Development Account were transfers from Ministry of Health meant for intern allowances. \uf0b7 The Hospital had liabilities of UGX 2,952,608,319 from the previous year (FY 2019/20) in respect of payables (UGX 2,304,366,476) and deposits (UGX 648,241,843). However, payments totalling to UGX3,775,748,845 in respect of the liabilities were made. The Hospital therefore made payments for non-existent liabilities amounting to UGX 1,471,382,369. \uf0b7 Management made an adjustment to the opening balance of payables amounting to UGX 2,097,368,767 (statement of outstanding commitments on Page 33 of the financial statements). However, there was no explanation provided on the cause of the adjustment or the composition of this figure. \uf0b7 The Hospital misstated transfers to the Treasury during the year by UGX 1,296,483,686 in its financial statements. \uf0b7 The entity did not have a strategic plan approved by NPA during the year. \uf0b7 The Hospital did not budget to collect NTR during the year under review. However, the financial statements indicated that NTR amounting to UGX. 1,808,626,491 was collected during the year. \uf0b7 Out of the total warrants of UGX.63,573,318,357 received during the financial year, UGX.59,379,356,427 was spent by the entity resulting in", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 321, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None"], "type": "table"}}, {"content": "309", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 321, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["an unspent balance of UGX.4,193,961,930 representing an absorption level of 93.4%. \uf0b7 The Hospital spent UGX. 474,479,100 on refurbishment of the MRI machine. It was noted that the MRI machine was delivered and installed in 2018 and has since never been put to use. \uf0b7 Works under the construction contract for 150 units of staff houses at the Hospital of UGX. 30,228,600,856 have been delayed. \uf0b7 I noted that vital medical equipment was in poor working condition, while others were fully not functional and required replacement. The equipment included: autoclaves in the central sterile service department; patient monitors in the accident and emergency surgical unit; blood coagulation machine in the clinical laboratory unit; ICU beds in the intensive care unit, and CT machine in the Radiology department.", null, null], ["27", "Allied Health Professionals Council (AHPC).", "\uf0b7 The Council did not have a strategic plan approved by NPA during the year."], [null, "2020/21", null], ["28 Health Service Commission. 2020/21 Opinion Unqualified \uf0b7 I noted that the entity had prepared a strategic plan. However, this had not been approved by the end of the year under review. \uf0b7 The Commission did not budget to collect NTR during the year under review. However, the financial statements indicated that NTR amounting to UGX.21,850,000 was collected during the year. \uf0b7 There was no evidence to show that the procurement method and the Evaluation Committee were approved by the Contracts Committee for six sampled procurements worth UGX48,310,800. Lack of approval contravenes the PPDA Regulations. In the circumstances, the Evaluation Committees executed the assignment without authority.", null, null], ["29", "Uganda AIDS Commission. 2020/21", "\uf0b7 I noted that the entity had prepared a strategic plan. However, this had"]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 322, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "310", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 322, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Opinion Unqualified", "not been approved by the end of the year under review. \uf0b7 The Commission did not budget to collect NTR during the year under review. However, the financial statements indicated that NTR amounting to UGX. 37,800,000 was collected during the year."], [null, "", null], ["30 Allied Health Professionals Council (AHPC). 2020/21 Opinion Unqualified \uf0b7 The Council did not have a strategic plan approved by NPA during the year. \uf0b7 The entity budgeted to collect internal revenue of UGX.4.771Bn during the year under review. Out of this, only UGX.3.783Bn was realized, representing a performance of 79% of the target. \uf0b7 AHPC planned to implement five (5) outputs in the year under review. I assessed the implementation of three (3) outputs which had 16 activities and noted that all the 3 outputs with their 16 activities were fully quantified. with a total of sixteen (16) activities worth UGX.1.380Bn and noted that; \uf0b7 Out of the sampled 3 outputs with a total of 16 activities, I noted that one (1) output with four (4) activities and expenditure worth UGX 0.515Bn was fully implemented that is all the four (4) activities within this output were fully implemented. Two (2) outputs with twelve (12) activities worth UGX.0.865Bn were partially implemented. Out of the twelve (12) activities, the entity fully implemented one (1) activity; seven (7) activities were partially implemented while four (4) activities were not implemented. \uf0b7 The Council did not implement some of its planned activities during the year. Examples include: Verification and publication of Allied Health Professionals in the Gazette; Licensing of private Allied Health units and training institutions, and; ICT support supervision in regions. \uf0b7 The Governing Council stated that a material uncertainty existed regarding the continued operation of Allied Health Professionals Council in", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 323, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "311", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 323, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["the foreseeable future. This was based on the communication by the Permanent Secretary Ministry of Public Service (PS/MoPS) to the Permanent Secretary Ministry of Health among others in which the PS/MoPS communicated a Cabinet decision of 22nd February 2021 that required the commencement of merging, rationalization and mainstreaming of Government Agencies between financial years 2021/2022 and 2022/2023. There is a high possibility that the Council may not remain a going concern beyond the stated period. \uf0b7 The Council did not make any publication in the Gazette during the year under review, contrary to The Allied Health Professionals\u2019 Act (cap 268). In the absence of such a publication, the unsuspecting public may not be protected from quack practitioners.", null, null], ["31", "Uganda Global Fund To Fight Tuberculosis And Malaria Project \u2013 HIV", "\uf0b7 No significant findings"], [null, null, ""], ["32 Uganda Global Fund to Fight Aids, Tuberculosis And Malaria Project \u2013 HIV Component. 2020 Opinion Unqualified \uf0b7 No significant findings", null, null], ["33", "Uganda Global Fund to Fight Aids, Tuberculosis and Malaria Project-Tuberculosis", "\uf0b7 No significant findings"], [null, null, ""], ["34 Ministry of Health. 2020/21 Opinion Unqualified \uf0b7 I noted that whereas the Ministry submitted a draft 5-Year Strategic plan (FYs 2020/21-2024/25) to National Planning Authority for approval on 29th July 2021, a certificate had not been issued by the Authority by the time of audit. \uf0b7 The entity did not budget for NTR during the year under review. However, UGX 7.205Bn was collected. \uf0b7 The Ministry budgeted to receive UGX 147.112Bn. This budget was later revised to UGX 376.884Bn, out of which UGX 376.837Bn was warranted, resulting into a shortfall of UGX 47m (representing 0.012% of the approved budget). \uf0b7 Out of the total UGX 1,029.646Bn received during the year under review, UGX 852.099Bn was spent by the entity resulting in an unspent balance of UGX. 177.547Bn (representing an absorption level of 82.8%). The unspent funds included; UGX 0.61Bn of NTR which was swept back to the Consolidated Fund as required by the PFMA, while UGX 5Bn remained on the MoH Contingency Fund and the balance of UGX 171.937Bn remained on project Accounts. \uf0b7 Out of a sample of forty nine (49) outputs with a total of one hundred ninety seven (197) activities and expenditure of UGX 777.8Bn, twenty", null, null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 324, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["destination countries such sa; Kuwaiti; Qatar; Bahrain; Afghanistan; Iraq; Somalia; Turkey and Oman are still under process.", "None", "None"], "type": "table"}}, {"content": "Aids, \n312 \nfour (24) 48.9% outputs with a total of fifty nine (59) activities and expenditure worth UGX 140.4Bn were fully quantified. Fifteen (15) 30.6% outputs with a total of one hundred twenty one (121) activities and expenditure worth UGX 373.5Bn were insufficiently quantified. I observed that out of the one hundred twenty one (121) activities, sixty nine(69) activities (57%) were quantified, while the balance of fifty two (52) activities (43%) were not clearly quantified to enable the assessment of performance. Ten (10) 20.4% outputs with a total of seventeen (17) activities and expenditure worth UGX 263.9Bn were not quantified at all.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 324, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of twenty four (24) outputs that were fully quantified with a total of fifty nine (59) activities worth UGX 140.4Bn, eight (8) (33.3%) outputs with eleven (11) activities and expenditure worth UGX 101.8Bn were fully implemented; ten (10) (41.7%) outputs with forty two (42) activities worth UGX 32.5Bn were partially implemented. Out of the forty two (42) activities, eleven (11) activities were fully implemented; thirteen (13) activities were partially implemented, while eighteen (18) activities remained unimplemented. Six (6) (25% )outputs with six (6) activities worth UGX 6.1Bn could not be assessed to establish their level of implementation because four (4) of these outputs were not reported on, while two (2) outputs were inaccurately reported on i.e. different activities were planned for but different activities were reported on.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Ministry of Health received off-budget financing from Development Partners to a tune of UGX 8.44Bn, which was not declared to Treasury and, therefore, not appropriated to the entity by Parliament.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The entity submitted performance reports for Q1, Q2, and Q3, Q4 after the prescribed deadlines. In addition, I did not obtain documentary proof of in the form of monitoring plans and reports which are important in ensuring that the budget performs as expected.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The task force reporting functionality planned to produce bi-weekly, monthly, quarterly, bi-annual and annual COVID-19 performance reports. However, these were not prepared and discussed in a timely manner.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the Ministry of Health did not prepare a COVID-19 activity work plan upon receipt of UGX 253,596,115,200 meant for management of COVID-19.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Out of the Supplementary release of UGX 223.596Bn, the Contingency Fund allocation of UGX 30Bn, and the unutilized balance from FY 2019/2020 of UGX 0.5Bn, a total of UGX.249.025bn (Supplementary UGX 223.596Bn, and Contingency Funding of UGX 25.429Bn) was spent leaving a balance of UGX 5.071Bn unspent as at 30th June 2021 (representing an absorption level of 98% of the total available funds)", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the entity conducted COVID-19 related procurements worth UGX 105,937,028,042 in the FY 2019/20 out of which UGX 92,960,878,888 had been paid by 30th June 2021. During the year under review (FY 2020/21), procurements worth UGX 191,254,414,946 were conducted out of which UGX 184,690,133,663 was paid by 30th June 2021.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that 37,501,136 masks that were delivered by various suppliers at a cost of UGX 90.2bn were not supported with documentary proof of certification by UNBS to ensure conformance with the desired technical quality specifications.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Whereas the first GoU allocation for procurement of vaccines amounting to UGX 18.5bn was transferred to National Medical Stores on 29th March 2021, vaccination doses procured by the Government of Uganda were yet to be delivered to NMS by 30th June 2021. Delayed delivery of the", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "313", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 325, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["vaccines is likely to hamper the timely attainment of the vaccination targets set by government. \uf0b7 The Ministry did not comply with PPDA Regulatory Framework with respect to COVID-19 related procurements valued at UGX. 13.7bn. \uf0b7 Whereas Mulago National Referral Hospital had running contracts for cleaning, waste disposal and security services with 3 suppliers prior to the COVID-19 pandemic, the Ministry of Health directly paid these suppliers a total of UGX 1,071,968,797 in respect of Cleaning & waste disposal Services (UGX 794,999,997) and Security services (UGX 276,968,800) rendered at Mulago COVID-19 Treatment Centre. Under the circumstances, there is a risk of double payment. \uf0b7 I noted that Pay As You Earn (PAYE) amounting to UGX 626,630,608 was not deducted from hardship allowances paid to various officials. Failure to deduct taxes may attract interest and penalties from the Tax Body.", null, null], ["", "LEGISLATURE", ""], ["", null, null], ["1\\. Parliamentary Pension Scheme. 2020/21 Opinion Unqualified \uf0b7 A total of UGX.5,557,452,584 was utilized during the year against the approved budgeted t of UGX.6,601,744,660. The Under absorption of resources implies that the scheme did not carry out all the year\u2019s intended activities, hence not meeting its intended objectives. Some of the activities that were not or partially implemented were; \uf0b7 Recruitment of staff \uf0b7 IT Annual Maintenance Plans \uf0b7 Strategic Partnership Meetings \uf0b7 As observed last financial year 2019/2020, some members on the Board of Trustees are still signatories to the Bank Accounts of the Scheme. The Board\u2019s involvement in the day-to-day operations of the scheme erodes its oversight role. For instance, the Board cannot hold management to account for failure, to implement. agreed activities when the Board is actively participating in the daily operations of the scheme.", null, null], ["2.", "Parliamentary Commission. 2020/21", "\uf0b7 I noted that the Authority\u2019s strategic plan had not been certified by NPA by the time of audit, contrary to the Planning Regulations."], [null, "Opinion Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 326, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "314 \nUGX.62,477,592,377 as at 30th June 2021. \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}]], "page": 326, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Authority did not remit statutory deductions to URA and NSSF amounting to UGX.1.86Bn.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 327, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 327, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The Authority incurred avoidable expenditure of UGX.7.8Bn as interest due to delayed site handover for civil works constructions.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 327, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 327, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that the Authority had not adopted the Computerized Government Financial Management Information Systems (GFMIS) for management of its inventories as required by the Treasury Instructions.", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], "page": 327, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "315 \nANNEXURE II: SUMMARY OF ENTITY FINDINGS AND OPINIONS FOR LOCAL GOVERNMENTS \nS/N Fort Portal Branch \n", "metadata": {"headings": [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}, [{"headings_0": {"content": "ANNEXURES", "page": 141, "level": 2}}], [{"headings_0": {"content": "S/N Fort Portal Branch", "page": 328, "level": 3}}], [{"headings_0": {"content": "S/N Fort Portal Branch", "page": 328, "level": 3}}]], "page": 327, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "1. Bundibugyo DLG", "metadata": {"headings": [{"headings_0": {"content": "S/N Fort Portal Branch", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Opinion Unqualified \n", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified", "page": 328, "level": 3}}, [{"headings_0": {"content": "Opinion Unqualified", "page": 328, "level": 3}}]], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "2. Kabarole DLG", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified", "page": 328, "level": 3}}], "page": 328, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": [["\uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; under absorption of funds worth UGX.5,185,210,873 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.768,125,595; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines.", null, null], ["03.", "Kamwenge DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; over payment of pension"]], "metadata": {"headings": [{"headings_0": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}], "page": 329, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["\uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; under absorption of funds worth UGX.5,185,210,873 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.768,125,595; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines.", null, null], ["03.", "Kamwenge DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; over payment of pension"], [null, "Opinion Unqualified", "worth UGX.18,610,306; Underpayment of pension worth UGX."], [null, null, "20,537,350; Wrong computation of gratuity worth net"], [null, "", "overpayment of UGX. 126, 160257; payment of salaries worth"], [null, null, "UGX. 3,042,398 to six (6) staffs that was no longer in service;"], [null, null, "irregular deduction of loan instalments worth UGX.9,912,197 and"], [null, null, "failure to remit payroll deductions worth UGX.1,206,334,606"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by eleven (11) new employees; failure to utilize wage funds of"], [null, null, "UGX.2.32Bn; un-deducted PAYE from political leaders\u2019 gratuity"], [null, null, "resulting in unpaid tax of UGX.9,904,129; payment of forty three"], [null, null, "(43) staffs worth UGX.73,835,431 off the IPPS and failure to"], [null, null, "prepare monthly wage, pension and gratuity performance"], [null, null, "analysis report on payroll to MoPS"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.446,776,818 on"], [null, null, "wrong budget lines other than those prescribed for salary,"], [null, null, "pension and gratuity"], [null, null, ""], [null, null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds worth"], [null, null, "UGX.9, 615,375,142 that was eventually swept back to"], [null, null, "consolidated fund account at end of financial year; combined"], [null, null, "under performance worth UGX. 18,033,399,211 from planned"], [null, null, "donor funds, NTR, releases from Government & other"], [null, null, "Government units ; delayed submission of quarterly monitoring"], [null, null, "reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I observed that a total sum of UGX.792, 482,750 due from the"], [null, null, "groups that were funded in 2014/15, 2015/16, 2016/17, 2017/18"], [null, null, "and 2018/19 were still outstanding and therefore reported as"], [null, null, "revenue arrears at the year end."], [null, null, ""], [null, null, "\uf0b7 The district lacks evidence of ownership in form of titles for its"], [null, null, "land at Kabuga-Rubaba measuring 1,321 hectares."], [null, null, ""], [null, null, "\uf0b7 During a physical inspection of the Constructions, I noted a"]], "metadata": {"headings": [{"headings_0": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}], "page": 329, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "317", "metadata": {"headings": [{"headings_0": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}], "page": 329, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "number of shoddy works in Bwizi Seed School and upgrade"], [null, null, "Kabingo Health Centre II to Health Centre III."], ["04\\. Kasese DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, over payment of Salary and gratuity worth UGX. UGX.3, 574,714; Underpayment of pension worth UGX. 705,886; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.21, 251,680; payment of salaries worth UGX. 990,729 to two (2) staffs that was no longer in service and irregular deduction of loan instalments worth UGX.11, 312,968. \uf0b7 Additionally, I observed that there was delayed access to payroll by four (04) new employees and five (5) pensioners; failure to utilize wage funds of UGX.0.01Bn; over remittance UGX.14,857,510 was made to UNATU and UBA, and an under remittance of UGX.162,609,619 to URA and LST respectively; and payment of twenty nine (29) staffs & two (2) pensioners a total of UGX.35,824,742 off the IPPS \uf0b7 The district mischarged expenditure worth UGX.99,558,770 on wrong budget lines other than those prescribed for gratuity \uf0b7 The district\u2019s strategic plan was not certified by National Planning Authority. \uf0b7 I noted that the verification forms and copies of the verification cards for 150 new employees and 8 pensioners/beneficiaries were not on the respective personal files. \uf0b7 The district has uncollected Non Tax Revenue arrears to the tune of UGX.702, 009,983 that has remained outstanding for more than a year. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX. 6,349,941,923 that were eventually swept back to consolidated fund account at end of financial year; combined under performance worth UGX. 11,758,099,498 from planned donor funds, NTR, releases from Government & other Government units ; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Ninety one (91) pieces of land owned by the District lacked evidence of ownership in form of titles. \uf0b7 Out of the total funds of UGX.822, 539,506 UgIFT funds received, the district only utilized UGX.314,732,415 (38.26%) resulting into unspent balance of UGX.507,807,091.", null, null], ["05.", "Kyegegwa DLG", "\uf0b7 I noted a number of issues during the review of the district"], ["", "", null], [null, "Opinion", "pension and payroll such as;"], [null, "Unqualified", null]], "metadata": {"headings": [{"headings_0": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}], "page": 330, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["\uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; under absorption of funds worth UGX.5,185,210,873 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.768,125,595; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines.", "None", "None"], "type": "table"}}, {"content": "318 \n\uf0b7 The district delayed to submit wage estimates to MoPs by the 30 th of September of the previous year as required. This may \nlead to wage shortfalls/over provision due to lack of clarity and analysis of wage estimates by MoPS. \n\uf0b7 Unpaid accrued gratuity worth UGX.92,701,695 by year end and Under absorption of wage funds worth UGX.1.13Bn that meant \nsome employees and pensioners were unpaid \n\uf0b7 The verification forms and copies of the verification cards for 50 \nemployees were not on the respective personal files \n\uf0b7 The District did not prepare monthly wage, pension and gratuity \nperformance analysis and thus did not submit quarterly returns \non payroll to MoPS, contrary to Paragraph 2.1 of Establishment \nNotice No. 1 of 2020. This led to under absorption of wage, pension and gratuity budgets \n\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed \npay change reports", "metadata": {"headings": [{"headings_0": {"content": "UGX.35,678,772 off the IPPS", "page": 328, "level": 3}}, [{"headings_0": {"content": "\uf0b7 The district delayed to submit wage estimates to MoPs by the 30 th of September of the previous year as required. This may", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The district delayed to submit wage estimates to MoPs by the 30 th of September of the previous year as required. This may", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Unpaid accrued gratuity worth UGX.92,701,695 by year end and Under absorption of wage funds worth UGX.1.13Bn that meant", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Unpaid accrued gratuity worth UGX.92,701,695 by year end and Under absorption of wage funds worth UGX.1.13Bn that meant", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The verification forms and copies of the verification cards for 50", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The verification forms and copies of the verification cards for 50", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The District did not prepare monthly wage, pension and gratuity", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The District did not prepare monthly wage, pension and gratuity", "page": 331, "level": 3}}], [{"headings_0": {"content": "on payroll to MoPS, contrary to Paragraph 2.1 of Establishment", "page": 331, "level": 3}}], [{"headings_0": {"content": "on payroll to MoPS, contrary to Paragraph 2.1 of Establishment", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "page": 331, "level": 3}}]], "page": 330, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- 37 newly recruited/ transferred employees and 6 pensioners delayed to access payroll this affects staff moral and", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \naccumulation of domestic arrears and paid UGX.1,446,726 was \npaid to 2 former staff who had either retired or died \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 6 employees were paid a total of UGX.2,852,917 without signed", "page": 331, "level": 3}}, [{"headings_0": {"content": "accumulation of domestic arrears and paid UGX.1,446,726 was", "page": 331, "level": 3}}], [{"headings_0": {"content": "accumulation of domestic arrears and paid UGX.1,446,726 was", "page": 331, "level": 3}}], [{"headings_0": {"content": "accumulation of domestic arrears and paid UGX.1,446,726 was", "page": 331, "level": 3}}]], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The district did not subject political leaders\u2019 gratuity totalling to", "metadata": {"headings": [{"headings_0": {"content": "accumulation of domestic arrears and paid UGX.1,446,726 was", "page": 331, "level": 3}}], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "UGX.43,741,660 to the computation of PAYE in IPPS, leading to \nan under deduction of UGX.13,224,798, contrary to section 19(1) \n(a) of the Income Tax Act \n\uf0b7 The district made unauthorised loan deductions totalling UGX.157,604,005. The deductions were from 84 employees that \nneither had letters of undertaking nor existed in the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll \nDeduction Management System, operated by PCA-Payroll Consults Africa \n\uf0b7 I noted unrecovered overdue YLP and UWEP receivables worth \n541,572,633 and 196,364,405 from beneficiary groups that has affected the revolution of the funds among other groups in the queue \n\uf0b7 I noted a number of issues in the implementation of approved \nbudget such as delayed submission of quarterly reports; underperformance of revenue worth 9,414,937,826; under absorption of funds worth UGX.3,780,702,017 that affected \nimplementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works \n319", "metadata": {"headings": [{"headings_0": {"content": "UGX.43,741,660 to the computation of PAYE in IPPS, leading to", "page": 331, "level": 3}}, [{"headings_0": {"content": "an under deduction of UGX.13,224,798, contrary to section 19(1)", "page": 331, "level": 3}}], [{"headings_0": {"content": "an under deduction of UGX.13,224,798, contrary to section 19(1)", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The district made unauthorised loan deductions totalling UGX.157,604,005. The deductions were from 84 employees that", "page": 331, "level": 3}}], [{"headings_0": {"content": "neither had letters of undertaking nor existed in the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll", "page": 331, "level": 2}}], [{"headings_0": {"content": "neither had letters of undertaking nor existed in the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll", "page": 331, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I noted unrecovered overdue YLP and UWEP receivables worth", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted unrecovered overdue YLP and UWEP receivables worth", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 331, "level": 3}}], [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}]], "page": 331, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["", "at Kitayunjwa Seed School , ICT and science equipment for"], [null, "Kitayunjwa Seed School, Upgrading of Kagumba HC II to HC III"], [null, "and Procurement of medical equipment for Kagumba HC I and"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 332, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", "at Kitayunjwa Seed School , ICT and science equipment for"], [null, "Kitayunjwa Seed School, Upgrading of Kagumba HC II to HC III"], [null, "and Procurement of medical equipment for Kagumba HC I and"], [null, "Bubago HCII"], [null, "\uf0b7 I noted that the management had not prepared and approved a"], [null, "strategic plan that is aligned to the NDP-III at the time of audit"], [null, "\uf0b7 I noted ddelayed works for Construction of Karwenyi Health"], [null, "Center III under UgIFT. The contract was awarded to M/s.Nicole"], [null, "Associates Ltd at a contact sum of UGX.529, 682,320 and should"], [null, "have been completed on 07.09.19 but was still having pending"], [null, "works"], [null, "\uf0b7 I noted incomplete construction works on Rwentuuha seed"], [null, "school for works that should have ended by 07.04.2020"], [null, "\uf0b7 I noted funds shortfall of UGX.91, 745,203 for funds meant for"], [null, "road maintenance from URF that affected the implementation of"], [null, "planned works"], ["06\\. Kyenjojo DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, over payment of Gratuity worth UGX. UGX.4, 503,576; Underpayment of pension worth UGX. 10,233,398; payment of salaries worth UGX. 13, 121,357 to nine (9) staffs that was no longer in service and unauthorized deduction of loan instalments worth UGX. 21,809,702. \uf0b7 Additionally, I observed that there was delayed access to payroll by ten (10) new employees and two (2) pensioners; failure to utilize wage funds of UGX.0.96Bn; unremitted payroll deductions of UGX. 6,025,083 and failure to prepare monthly wage, pension and gratuity performance analysis report on payroll to MoPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX.3, 847,060,490 that was eventually swept back to consolidated fund account at end of financial year; combined under performance worth UGX. 22,372,196,592 from planned donor funds, NTR, releases from Government & other Government units; \uf0b7 Out of UGX.1, 300,000,000 received for Upgrading of Kigoyera HC II to HC III only UGX.480, 191,731 was utilized and the balance was swept back to the Treasury at the end of the financial year. \uf0b7 I noted shoddy works for M/s Build line Contractors Uganda LTD at a contract sum of UGX.2, 050,045,030. Although the end date was extended to 30th August 2020 and the contract sum revised to UGX.2, 150,170,030 to cater for variations", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 332, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "320", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 332, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 The districts strategic plan was not certified by National Planning Authority therefore I could not confirm that it is aligned to NDP- III.", null, null], ["07.", "Ntoroko DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 333, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_5"], "type": "table"}}, {"content": [["\uf0b7 The districts strategic plan was not certified by National Planning Authority therefore I could not confirm that it is aligned to NDP- III.", null, null], ["07.", "Ntoroko DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs; Underpayment of in payroll worth UGX."], [null, "Unqualified", "5,813,601; un-deducted PAYE from political leaders\u2019 gratuity"], [null, "", "resulting in unpaid tax of UGX.8, 062,325; Loan deductions"], [null, null, "relating to all the 279 employees did not have letters of"], [null, null, "undertaking and evidence of consent on file; One hundred five"], [null, null, "(105) staffs were paid using wrong salary scales, leading to over"], [null, null, "payments of UGX.9,200,722."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by thirty seven (37) new employees and one (01) pensioner;"], [null, null, "failure to utilize wage funds of UGX.0.026Bn; unremitted PAYE"], [null, null, "deductions of UGX.58,118,104, to URA; failure to prepare"], [null, null, "monthly wage, pension and gratuity performance analysis report"], [null, null, "on payroll to MoPS"], [null, null, ""], [null, null, "\uf0b7 I noted that the verification forms and copies of the verification"], [null, null, "cards for 50 employees were not on the respective personal files"], [null, null, ""], [null, null, "\uf0b7 The district\u2019s strategic plan was not certified by National Planning"], [null, null, "Authority therefore I could not confirm that it is aligned to NDP-"], [null, null, "III."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds worth"], [null, null, "UGX.824, 523,482 that was eventually swept back to"], [null, null, "consolidated fund account at end of financial year and a"], [null, null, "combined revenue under performance worth UGX. 1,971,531,402"], [null, null, "from planned donor funds, NTR, releases from other Government"], [null, null, "units"], [null, null, ""], [null, null, "\uf0b7 I noted that the Upgrade of Butungama HCIII under UgiFT works"], [null, null, "had stalled and behind schedule by 14 months."], ["08\\. Fort portal MC Unqualified Opinion \uf0b7 I noted a number of anomalies during review of the Municipal pension & salary payrolls such as; Failure to submit wage estimates to MoPs; Overpayment of UGX.1,547,570 Underpayment of in payroll worth UGX.674,289; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.3,015,540; failure to utilize wage funds of UGX.0.655Bn; Payment of 4 employees who were no longer in service; Under remittance of salary deductions worth UGX. UGX.68,499,107; Delayed remittance of deductions to UCLA/UBA of 5 to 90 days \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX.9, 264,101,819 that was eventually swept back to consolidated fund account at end of financial year; combined under performance worth UGX. 22,372,196,592 from planned", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 333, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_5"], "type": "table"}}, {"content": "321", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 333, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", null, null], ["", "Branch Jinja", "Summary of Key Findings"], ["01\\. Namutumba DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, over payment of Gratuity worth UGX. 6,699,263; Underpayment of salaries worth UGX 3,970,280; payment of salaries worth UGX. 34,532,950 to eighteen (18) staffs who were no longer in service; under remittance of payroll deduction of UGX. 42,851,131; unauthorized excess loan deductions worth UGX. 336,561,515 for one hundred seventy four (174) employees \uf0b7 Additionally, I observed that there was delayed access to payroll by ninety one (91) newly recruited/ transferred employees and nineteen (19) pensioners; eight (8) pensioners failed to access the pension payroll; failure to utilize wage funds of UGX.0.70Bn; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.9, 275,220; failure to prepare monthly wage, pension and gratuity performance analysis report on payroll to MoPS and overpayment of pensioners due to wrong computation worth UGX. 66,739,381 and payment of 05 employees worth UGX. 3,371,913 without authorization of pay change report. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX. 1,074,919,818 that were eventually swept back to consolidated fund account at end of financial year; under performance worth UGX. 183,402,134 from planned donor funds, NTR and releases from Government.; partial implementation of planned activities \uf0b7 The district mischarged expenditure worth UGX.41,963,816 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 09 staff and 10 pensioners were paid a total of UGX 461,890,255 off the IPPS.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 334, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "322", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 334, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that the District had uncovered funds (receivables) of UGX. 1,400,354,319 that affected the budget implementation of planned activities \uf0b7 The District\u2019s strategic plan is in place but no evidence of approval by the National Planning Authority was availed at the time of audit. \uf0b7 I noted that the construction works of a seed secondary school at Nabweyo did not take off in the financial year under review and the funds amounting to UGX. 344,284,000 were swept back to treasury. \uf0b7 The district lacked land titles for 17 pieces measuring approximately 299.3 acres which exposed the land to loss and encroachment. \uf0b7 The District received a sum of UGX. 223,381,891 for (06) secondary schools and (109) primary schools meant for the procurement of learning materials. However, the bank statements had not been availed for review at the time of audit.", null, null], ["02.", "Buyende DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 335, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["\uf0b7 I noted that the District had uncovered funds (receivables) of UGX. 1,400,354,319 that affected the budget implementation of planned activities \uf0b7 The District\u2019s strategic plan is in place but no evidence of approval by the National Planning Authority was availed at the time of audit. \uf0b7 I noted that the construction works of a seed secondary school at Nabweyo did not take off in the financial year under review and the funds amounting to UGX. 344,284,000 were swept back to treasury. \uf0b7 The district lacked land titles for 17 pieces measuring approximately 299.3 acres which exposed the land to loss and encroachment. \uf0b7 The District received a sum of UGX. 223,381,891 for (06) secondary schools and (109) primary schools meant for the procurement of learning materials. However, the bank statements had not been availed for review at the time of audit.", null, null], ["02.", "Buyende DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion: Unqualified", "estimates to MoPs, unpaid salaries of UGX 5,941,021 to nine (9)"], [null, null, "employees; Underpayment of salaries to staff worth UGX"], [null, null, "205,153,235; under payment of UGX 6,386,999 to pensioners;"], [null, null, "over payment of UGX 9,607,227; payment of salaries worth UGX."], [null, null, "11,313,061 to six (06) staffs who were no longer in service;"], [null, null, "under remittance of payroll deduction of UGX.205,612,209;"], [null, null, "unauthorized excess loan deductions worth UGX. 17,355,601 for"], [null, null, "168 employees"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by twenty nine (29) newly recruited/ transferred employees and"], [null, null, "seven (07) pensioners; un-deducted PAYE from political leaders\u2019"], [null, null, "gratuity resulting in unpaid tax of UGX. 12,019,045; failure to"], [null, null, "prepare monthly wage, pension and gratuity performance"], [null, null, "analysis report on payroll to MoPS and overpayment of"], [null, null, "pensioners due to wrong computation worth UGX. 20,650,780"], [null, null, "and payment of funds worth UGX. 8,205,747 off the IPPS system"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds worth UGX."], [null, null, "2,000,000,000,000 that were eventually swept back to"], [null, null, "consolidated fund account at end of financial year; under"], [null, null, "performance worth UGX. 2,097,035,126 from planned donor"], [null, null, "funds, NTR and releases from Government.; partial"], [null, null, "implementation of planned activities"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX. 71,513,039 on"], [null, null, "wrong budget lines other than those prescribed for salary,"], [null, null, "pension or gratuity"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 335, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "323", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 335, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", ""], [null, "\uf0b7 I noted that the entity had prepared a strategic plan but the"], [null, "National Planning Authority had not yet approved it at the time of"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 336, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": [["", ""], [null, "\uf0b7 I noted that the entity had prepared a strategic plan but the"], [null, "National Planning Authority had not yet approved it at the time of"], [null, "audit."], [null, ""], [null, "\uf0b7 Failure to quantify outputs, partial and non-implementation of"], [null, "planned activities, late submission of quarterly reports"], [null, ""], [null, "\uf0b7 I noted that funds to the tune of UGX. 571,677,701 were"], [null, "irregularly diverted from the activities on which they were"], [null, "budgeted and spent on other activities without seeking and"], [null, "obtaining the necessary approvals."], [null, ""], [null, "\uf0b7 Of the 9 road equipments at the district, 03 were grounded and"], [null, "in need of major repairs and I also observed lack of vital road"], [null, "equipment such as an excavator, a backhoe, supervision double"], [null, "cabin pickup and 02 supervision motor cycles."], [null, ""], [null, "\uf0b7 Delayed construction works on Buyende Seed School and expired"], [null, "performance security for the contract from the contractor was"], [null, "also noted"], [null, ""], [null, "\uf0b7 I note that there undelivered ICT Equipments worth UGX."], [null, "148,842,899 to Buyende Seed Secondary School; unutilized"], [null, "funds worth UGX. 178,400,391 meant for procurement of"], [null, "learning materials for (05) secondary schools and (91) primary"], [null, "schools."], [null, ""], [null, "\uf0b7 I noted that accountability amounting to UGX. 61,788,892 were"], [null, "not presented for verification by the time of audit."], [null, ""], [null, "\uf0b7 The district lacked land titles for 48 pieces measuring"], [null, "approximately 1,942 hectares which exposed the land to loss and"], [null, "encroachment."], ["03\\. Jinja DLG Opinion: Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, unpaid salaries and pension arrears of UGX 484,546,138; Underpayment of salaries to staff worth UGX. 40,243,749; under payment of UGX 6,386,999 to pensioners; over payment of UGX 9,607,227; payment of salaries worth UGX. 2,763,055 to six (06) staffs who were no longer in service \uf0b7 Additionally, I observed that there was delayed access to payroll by Fifteen (15) newly recruited/ transferred employees and three (03) pensioners; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 10,866,949; failure to prepare monthly wage, pension and gratuity performance analysis report on payroll to MoPS and payment to 06 staff and 09 pensioners of funds worth UGX. 62,763,120 off the IPPS system \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to Quantify outputs; partial &", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 336, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": "324", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 336, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["non-implementation of planned activities and delayed submission of performance reports; under absorption of funds worth UGX. 1,890,511,130 that were eventually swept back to consolidated fund account at end of financial year; under performance of NTR worth UGX. 341,038,789 \uf0b7 The district has outstanding unrecovered YLP and UWEP advances worth UGX. 1,164,605,343", null, null], ["04.", "Jinja MC", "\uf0b7 I noted a number of anomalies during review of the municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 337, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["non-implementation of planned activities and delayed submission of performance reports; under absorption of funds worth UGX. 1,890,511,130 that were eventually swept back to consolidated fund account at end of financial year; under performance of NTR worth UGX. 341,038,789 \uf0b7 The district has outstanding unrecovered YLP and UWEP advances worth UGX. 1,164,605,343", null, null], ["04.", "Jinja MC", "\uf0b7 I noted a number of anomalies during review of the municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion: Unqualified", "estimates to MoPs, failure to utilize wage funds of UGX.0.5Bn;"], [null, null, "unpaid salaries and pension arrears of UGX 484,546,138;"], [null, null, "Underpayment of salaries to staff worth UGX 2,179,634; under"], [null, null, "payment of UGX.54,373,901 to pensioners; over payment of"], [null, null, "gratuity worth UGX 34,302,808 to one pensioner arising from"], [null, null, "wrong computation; Underpayment of pensions worth UGX"], [null, null, "49,155,207; nonpayment of a pensioner worth UGX 10,907,334"], [null, null, "and payment of salaries worth UGX. 1,158,981 to two (02) staffs"], [null, null, "who were no longer in service"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by eight (08) newly recruited/ transferred employees and thirty"], [null, null, "five (35) pensioners; failure to prepare monthly wage, pension"], [null, null, "and gratuity performance analysis report on payroll to MoPS; Net"], [null, null, "under remittance of payroll deductions worth UGX. 42,851,131;"], [null, null, "payment of a staff and a pensioner worth UGX 13,515,274 off"], [null, null, "the IPPS and payment to 03 employees worth UGX. 6,202,537"], [null, null, "without signed pay change reports."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to Quantify outputs; delayed"], [null, null, "submission of performance reports; under absorption of funds"], [null, null, "worth UGX 2,361,255,255 that were eventually swept back to"], [null, null, "consolidated fund account at end of financial year; under"], [null, null, "performance of NTR & transfers from other Government Units"], [null, null, "worth UGX. 6,353,273,753"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had prepared a strategic plan but the"], [null, null, "National Planning Authority had not yet approved it at the time of"], [null, null, "audit"], [null, null, ""], [null, null, "\uf0b7 The Municipal Council had outstanding payables of UGX"], [null, null, "894,801,904 by the end of the year"], [null, null, ""], [null, null, "\uf0b7 The Municipality mischarged UGX. 132,864,963 on wrong"], [null, null, "account codes other than those prescribed for salary, pension or"], [null, null, "gratuity."], [null, null, ""], [null, null, "\uf0b7 I noted underfunding of UGX. 41,469,000 from URF that affected"], [null, null, "the routine manual, mechanized and periodic road maintenance"], [null, null, "under force account mechanism."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 337, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "325", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 337, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 I noted that the Municipal Council had 12-road equipment of"], [null, null, "which two (02) were grounded and in need of major repairs."], [null, null, "Additionally, I also observed that the Municipal lacked vital road"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 338, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["", null, "\uf0b7 I noted that the Municipal Council had 12-road equipment of"], [null, null, "which two (02) were grounded and in need of major repairs."], [null, null, "Additionally, I also observed that the Municipal lacked vital road"], [null, null, "equipment like a water bowser, a roller, chips spreader and a"], [null, null, "jet/pothole patcher."], [null, null, ""], [null, null, "\uf0b7 Under USMID, the Municipal Council had unspent balance of UGX"], [null, null, "1,701,586,908, meant for road construction works and"], [null, null, "incomplete road works by the year end"], [null, null, ""], [null, null, "\uf0b7 Under UgIFT, I noted that the construction works on Kimaka"], [null, null, "Health Centre III at a cost of UGX. 493,924,741 had stalled for"], [null, null, "over a year and the contractor had abandoned the site."], [null, null, ""], [null, null, "\uf0b7 The Municipal Council lacked land titles for 16 pieces measuring"], [null, null, "approximately over 34.265 hectares which exposed the land to"], [null, null, "possible loss and encroachment."], [null, null, ""], [null, null, "\uf0b7 I noted that Council was involved in 13 ongoing court cases"], [null, null, "which could lead to possible loss of funds."], ["05\\. Kaliro DLG Opinion: Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.0.4Bn; Underpayment of salaries to staff worth UGX. 24,360,137; under payment of UGX. 44,242,332 to pensioners and payment of salaries worth UGX. 2,246,579 to 5 staffs who were no longer in service \uf0b7 Additionally, I observed that there was delayed access to payroll by fifty-one (51) newly recruited/transferred employees and 03 pensioners; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 8,194,860. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to Quantify outputs; delayed submission of performance reports; under absorption of funds worth UGX. 1,575,930,542 that were eventually swept back to consolidated fund account at end of financial year; under performance of NTR & transfers from other Government Units worth UGX. 288,478,184. \uf0b7 I noted that the district had outstanding receivables of UGX. 1,240,015,837 at year end that had not been collected \uf0b7 There was delayed physical progress of the works at Buyinda health centre, Kasokwe Health Centre and Bukamba Seed Secondary School. This was attributed to effects of Covid-19 pandemic. \uf0b7 I noted that Kaliro DLG did not have land titles for 38 pieces of land measuring approximately 283.25 acres.", null, null], ["06.", "Kamuli MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 338, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "326", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 338, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion: Unqualified", "estimates to MoPs, failure to utilize wage funds of UGX.0.4Bn;"], [null, null, "Underpayment of salaries to staff worth UGX 17,301,287;"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 339, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion: Unqualified", "estimates to MoPs, failure to utilize wage funds of UGX.0.4Bn;"], [null, null, "Underpayment of salaries to staff worth UGX 17,301,287;"], [null, "", "overpayment to 239 staff worth UGX 12,549,285 under payment"], [null, null, "of gratuity worth UGX. 8,102,108 to pensioners; payment of"], [null, null, "salaries worth UGX. 5,528,605 to 2 staffs who were no longer in"], [null, null, "service; over and under remittance of salary deductions"], [null, null, "amounting to UGX 1,392,544 and UGX 30,126,523"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by 25 newly recruited/ transferred employees and 05 pensioners;"], [null, null, "un-deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX. 2,026,660; Unauthorized payroll deductions"], [null, null, "worth UGX 156,349,689 relating to 84 without letters of"], [null, null, "undertaking; over deductions payments worth UGX. 2,876,352"], [null, null, "and paid 03 staff and 07 politicians were worth UGX 14,156,592"], [null, null, "off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to Quantify outputs; delayed"], [null, null, "submission of performance reports; inaccurate reporting of"], [null, null, "performance; under absorption of funds worth UGX"], [null, null, "9,850,625,641 that were eventually swept back to consolidated"], [null, null, "fund account at end of financial year; under performance of NTR"], [null, null, "& transfers from other Government Units worth UGX."], [null, null, "609,177,435"], [null, null, ""], [null, null, "\uf0b7 I noted that the Municipal Council had outstanding receivables of"], [null, null, "UGX 592,620,187 that had not been recovered by year end."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had prepared a strategic plan but the"], [null, null, "National Planning Authority had not yet approved it at the time of"], [null, null, "audit."], [null, null, ""], [null, null, "\uf0b7 Failure to quantify outputs, partial or non-implementation of"], [null, null, "activities not quantified late submission of quarterly reports and."], [null, null, ""], [null, null, "\uf0b7 The Municipal Council had unspent funds under the USMID grant"], [null, null, "worth UGX. 9,421,230,865, which was subsequently swept back"], [null, null, "to the Consolidated Fund. Additionally, that the road construction"], [null, null, "works did not take off in the financial year under review."], [null, null, ""], [null, null, "\uf0b7 I noted that the construction works of two classroom blocks and"], [null, null, "water borne toilet at Busoga High School at UGX. 309,872,760"], [null, null, "were incomplete."], [null, null, ""], [null, null, "\uf0b7 The Municipal Council lacked land titles for 11 pieces which"], [null, null, "exposed the land to loss and encroachment."], [null, null, ""], ["07\\. Mayuge DLG Opinion: Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.1.2Bn; I also noted that there was an under payment of salaries and", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 339, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "327", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 339, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["pensions worth UGX. 1,193,840,180; Unpaid salaries worth UGX. 14,134,729; over payments of UGX. 17,722,575 to pensioners; 71 staff were paid using wrong salary scales, leading to monthly over payments of UGX. 1,177,702 and under payments of UGX. 1,257,209 respectively; nine (09) employees and fifteen (15) pensioners failed to access the payroll during the year; under remittance of salary deductions worth UGX. 45,320,114 \uf0b7 Additionally, I observed that there was delayed access to payroll by one hundred nine (109) newly recruited/ transferred employees and sixteen (16) pensioners; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 13,865,233; Unauthorized loan deductions worth UGX. 52,171,779 relating to 59 employees due to absence of Letters of undertaking; over deductions payments worth UGX. 2,876,352 and Paid 07 employees and 09 pensioners worth UGX. 89,285,252 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to Quantify outputs; delayed submission of performance reports; inaccurate reporting of performance; under absorption of funds worth UGX 2,017,223,134 that were eventually swept back to consolidated fund account at end of financial year; under performance of NTR & transfers from other Government Units worth UGX. 1,017,773,209 and delayed completion for the construction of Bukatube health and Nkombe Health Centre III \uf0b7 I noted that the district had outstanding receivables of UGX. 1,559,419,200 by year end \uf0b7 The Mayuge District had outstanding pension liabilities of UGX. 1,251,580,052 by the end of the year. \uf0b7 I noted that Mayuge District received off-budget financing to a tune of UGX 58,291,066 directly from Ministry of Local Governments for undertaking activities which were never declared to the PS/ST. \uf0b7 I noted that there is illegal mining of sand being carried out at the district lakeshores. The Accounting Officer explained that management had written to the prospective stakeholders in the sand mining activities giving guidance on the sustainable way of carrying out the activity including closure of some of the sand mines. \uf0b7 I noted that Mayuge DLG did not have land titles for 33 pieces of land measuring approximately 1430.761 Ha.", null, null], ["08.", "Lugazi MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 340, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["pensions worth UGX. 1,193,840,180; Unpaid salaries worth UGX. 14,134,729; over payments of UGX. 17,722,575 to pensioners; 71 staff were paid using wrong salary scales, leading to monthly over payments of UGX. 1,177,702 and under payments of UGX. 1,257,209 respectively; nine (09) employees and fifteen (15) pensioners failed to access the payroll during the year; under remittance of salary deductions worth UGX. 45,320,114 \uf0b7 Additionally, I observed that there was delayed access to payroll by one hundred nine (109) newly recruited/ transferred employees and sixteen (16) pensioners; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 13,865,233; Unauthorized loan deductions worth UGX. 52,171,779 relating to 59 employees due to absence of Letters of undertaking; over deductions payments worth UGX. 2,876,352 and Paid 07 employees and 09 pensioners worth UGX. 89,285,252 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to Quantify outputs; delayed submission of performance reports; inaccurate reporting of performance; under absorption of funds worth UGX 2,017,223,134 that were eventually swept back to consolidated fund account at end of financial year; under performance of NTR & transfers from other Government Units worth UGX. 1,017,773,209 and delayed completion for the construction of Bukatube health and Nkombe Health Centre III \uf0b7 I noted that the district had outstanding receivables of UGX. 1,559,419,200 by year end \uf0b7 The Mayuge District had outstanding pension liabilities of UGX. 1,251,580,052 by the end of the year. \uf0b7 I noted that Mayuge District received off-budget financing to a tune of UGX 58,291,066 directly from Ministry of Local Governments for undertaking activities which were never declared to the PS/ST. \uf0b7 I noted that there is illegal mining of sand being carried out at the district lakeshores. The Accounting Officer explained that management had written to the prospective stakeholders in the sand mining activities giving guidance on the sustainable way of carrying out the activity including closure of some of the sand mines. \uf0b7 I noted that Mayuge DLG did not have land titles for 33 pieces of land measuring approximately 1430.761 Ha.", null, null], ["08.", "Lugazi MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs, failure to utilize wage funds of UGX.0.4Bn; I"], [null, null, "also noted that there was an under payment of salaries worth"], [null, "", "UGX. 8,183,158; Unpaid salaries worth UGX. 34,305,160; Under"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 340, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "328", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 340, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "payments of UGX. 321,560,027 to pensioners; over payments of"], [null, "UGX. 7,263,946 and under payments of UGX. 1,360,106 arising"], [null, "from use of wrong bands; over and under remittance of salary"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 341, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": [["", "payments of UGX. 321,560,027 to pensioners; over payments of"], [null, "UGX. 7,263,946 and under payments of UGX. 1,360,106 arising"], [null, "from use of wrong bands; over and under remittance of salary"], [null, "deduction worth UGX. 2,697,535 and UGX. 35,487,023"], [null, "respectively"], [null, ""], [null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, "by 14 newly recruited/ transferred employees and thirteen (13)"], [null, "pensioners; un-deducted PAYE from political leaders\u2019 gratuity"], [null, "resulting in unpaid tax of UGX. 3,289,681; Unauthorized loan"], [null, "deductions worth UGX. 565,433,218 relating to 500 employees"], [null, "due to absence of Letters of undertaking; over deductions"], [null, "payments worth UGX. 2,876,352 and paid 15 staff and 10"], [null, "pensioners a total of UGX. 27,696,793 off the IPPS"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; Failure to Quantify outputs; delayed"], [null, "submission of performance reports; under absorption of funds"], [null, "worth UGX 14,415,862,633 that were eventually swept back to"], [null, "consolidated fund account at end of financial year"], [null, ""], [null, "\uf0b7 I noted that the Municipal Council had outstanding receivables of"], [null, "UGX. 1,973,054,521 by the year end that remained unrecovered"], [null, ""], [null, ""], [null, "\uf0b7 Under absorption of funds worth UGX. 14,177,800,402 under the"], [null, "USMID program that was eventually swept back to the"], [null, "consolidated fund."], [null, ""], [null, "\uf0b7 I noted under performance of funds worth UGX 17,916,865 from"], [null, "Uganda Road Fund meant for road maintenance in the"], [null, "municipality."], [null, ""], [null, "\uf0b7 I noted that Council was involved in 06 ongoing court cases"], ["09\\. Namayingo DLG Opinion: Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.0.72Bn; Unpaid salaries and pensions worth UGX. 49,235,421; under payments of UGX. 129,040,476 to pensioners; over and under payment of salaries worth UGX. 14,206,136 and UGX. 4,684,855 respectively due to use of wrong salary scales \uf0b7 Additionally, I noted there was un-deduction of PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 9,992,741; Unauthorized loan deductions worth UGX. 702,716,508 relating to 458 employees due to absence of Letters of undertaking; paid 33 staff and 16 pensioners a total of UGX. 38,434,320 off the IPPS \uf0b7 I observed that twenty-four (24) newly recruited/transferred employees and ten (10) pensioners delayed to access payroll; four (04) employees & seventeen (17) pensioners had not yet accessed the payroll by the close of the financial year and", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 341, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": "329", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 341, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["payment of 5 employees who were no longer in service \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 1,299,253,676 that were eventually swept back to consolidated fund account at end of financial year and under performance of revenues worth UGX. 896,645,767 \uf0b7 The District mischarged funds worth UGX. 5,057,686 on account codes other than those prescribed for salary, pension and gratuity. \uf0b7 Further, the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS, \uf0b7 I noted that the district had outstanding receivables of UGX. 1,063,954,752 that had not been recovered. \uf0b7 There was a delay in the physical progress of works at Bukana health centre III and Syanyonja Health centre. \uf0b7 I noted that Namayingo DLG did not have land titles for 113 pieces of land measuring approximately 357.3 hectares and 09 pieces of land were in the process of being titled.", null, null], ["10.", "Bugweri DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 342, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["payment of 5 employees who were no longer in service \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 1,299,253,676 that were eventually swept back to consolidated fund account at end of financial year and under performance of revenues worth UGX. 896,645,767 \uf0b7 The District mischarged funds worth UGX. 5,057,686 on account codes other than those prescribed for salary, pension and gratuity. \uf0b7 Further, the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS, \uf0b7 I noted that the district had outstanding receivables of UGX. 1,063,954,752 that had not been recovered. \uf0b7 There was a delay in the physical progress of works at Bukana health centre III and Syanyonja Health centre. \uf0b7 I noted that Namayingo DLG did not have land titles for 113 pieces of land measuring approximately 357.3 hectares and 09 pieces of land were in the process of being titled.", null, null], ["10.", "Bugweri DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.38Bn;"], [null, "Unqualified", "Unpaid pensions worth UGX. 110,127,127; Over payments of"], [null, "", "UGX. 3,000,000 to pensioners; over and under payment of"], [null, null, "salaries worth 9,273,543 and UGX. 4,410,477 respectively due to"], [null, null, "use of wrong bands"], [null, null, ""], [null, null, "\uf0b7 Additionally, I noted there was un-deduction of PAYE from"], [null, null, "political leaders\u2019 gratuity resulting in unpaid tax of UGX."], [null, null, "1,040,880; paid 23 staff and 15 pensioners were paid a total of"], [null, null, "UGX. 33,868,147 and UGX. 190,371,130 off the IPPS; over and"], [null, null, "under remittances of pay roll deductions of UGX. 532,326,787"], [null, null, "and UGX. 31,529,271 respectively; Payment of UGX.35,780,089"], [null, null, "to 09 employees who were no longer in service; wrong"], [null, null, "computation of gratuity benefits of 01 pensioner (TAJJUBA"], [null, null, "STEPHEN 417573) that resulted into an over payment of gratuity"], [null, null, "by UGX. 26, 936,170."], [null, null, ""], [null, null, "\uf0b7 I observed that 22 newly recruited employees and 15 pensioners"], [null, null, "delayed to access the pension payroll and the district did not"], [null, null, "prepare monthly wage, pension and gratuity performance"], [null, null, "analysis and thus did not submit quarterly returns on payroll to"], [null, null, "MoPS"], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 342, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "330", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 342, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; Failure to quantify outputs; partial and"], [null, "non-implementation of planned activities delayed submission of"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 343, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": [["", "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; Failure to quantify outputs; partial and"], [null, "non-implementation of planned activities delayed submission of"], [null, "performance reports; under absorption of funds worth UGX."], [null, "944,877,155 that were eventually swept back to consolidated"], [null, "fund account at end of financial year and under performance of"], [null, "revenues worth UGX. 6,114,158,151"], [null, ""], [null, "\uf0b7 I noted that the District had outstanding receivables worth UGX."], [null, "499,741,444 that was not yet recovered."], [null, ""], [null, "\uf0b7 I noted that the district had prepared a draft strategic plan but it"], [null, "had not yet been approved by the National Planning Authority."], [null, ""], [null, "\uf0b7 I noted that Bugweri District received off-budget financing to a"], [null, "tune of UGX. 860,199,000 without seeking approval."], [null, ""], [null, "\uf0b7 I noted that funds to the tune of UGX. 129,996,921 were"], [null, "misclassified."], [null, ""], [null, "\uf0b7 I noted that the District lacked land titles for 31 pieces of land"], [null, "measuring approximately 179 acres including schools, sub"], [null, "counties and health centers."], [null, ""], [null, "\uf0b7 Bugweri district received a sum of UGX. 155,136,081 for (06)"], [null, "secondary schools and (54) primary schools meant for the"], [null, "procurement of learning materials in March, 2021 but disbursed"], [null, "only UGX. 136,182,515 to the respective schools on 4 th June,"], [null, "2021 leaving an outstanding amount of UGX. 18,953,562 which"], [null, "remained unaccounted for."], [null, ""], [null, "\uf0b7 I noted that expenditure totaling UGX. 374,878,394 lacked"], [null, "adequate supporting documentation at the close of the financial"], [null, "year"], ["11\\. Bugiri Municipal Council Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.0.53Bn and over payment of salaries worth UGX. 4,618,049 due to use of wrong bands \uf0b7 Additionally, I observed that there was delayed access to payroll by 11 employees on the salary payroll and 03 pensioners on the pension pay roll; over and underpayment of salaries worth UGX. 5,020,000 UGX. 1,353,000; paid 15 staff and 03 pensioners were paid a total of UGX. 58,059,084 off the IPPS and paid five (5) employees a total of UGX. 29,073,390 without signed pay change reports \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 568,033,989 that were eventually swept back to consolidated", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 343, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": "331", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 343, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["fund account at end of financial year and under performance of revenues worth UGX. 334,420,647. \uf0b7 I noted that funds to the tune of UGX. 33,234,682 were paid on the wrong account codes. \uf0b7 I noted that the Council had outstanding receivables of UGX. 585,573,492. That remained unrecovered by year end \uf0b7 I noted that the entity\u2019s NDP-III was still in draft form and had not had its Strategic plan approved by NPA at the time of audit. \uf0b7 Road maintenance works was affected by budget shortfalls for funds worth GX 63,409,282 from URF. \uf0b7 I noted that expenditure totaling UGX. 37,580,848 advanced to staff and various suppliers to carry out activities lacked adequate supporting documents. \uf0b7 I noted that the Council lacked land titles for 07 pieces of its land.", null, null], ["12.", "Kamuli DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 344, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": [["fund account at end of financial year and under performance of revenues worth UGX. 334,420,647. \uf0b7 I noted that funds to the tune of UGX. 33,234,682 were paid on the wrong account codes. \uf0b7 I noted that the Council had outstanding receivables of UGX. 585,573,492. That remained unrecovered by year end \uf0b7 I noted that the entity\u2019s NDP-III was still in draft form and had not had its Strategic plan approved by NPA at the time of audit. \uf0b7 Road maintenance works was affected by budget shortfalls for funds worth GX 63,409,282 from URF. \uf0b7 I noted that expenditure totaling UGX. 37,580,848 advanced to staff and various suppliers to carry out activities lacked adequate supporting documents. \uf0b7 I noted that the Council lacked land titles for 07 pieces of its land.", null, null], ["12.", "Kamuli DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs, failure to utilize wage funds of UGX.1.3Bn;"], [null, null, "Unpaid pensions worth UGX. 129,711,499; Under payments of"], [null, "", "UGX. 789,022,349 to pensioners; under payment of salaries"], [null, null, "worth UGX. 16,604,611 and nonpayment of salaries worth UGX."], [null, null, "13,045,994"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by 25 newly recruited/ transferred employees and 14 pensioners;"], [null, null, "un-deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX.13,801,906; Unauthorized loan deductions"], [null, null, "worth UGX. 179,141,809 due to absence of Letters of"], [null, null, "undertaking; over/ under remittance of salary deductions worth"], [null, null, "UGX. 2,758,277 and paid UGX.5, 049,620 to 13 staff who had"], [null, null, "retired, transferred, absconded or died."], [null, null, ""], [null, null, "\uf0b7 I noted that Kamuli District had outstanding receivables figure of"], [null, null, "UGX. 1,309,756,172 that remained unrecovered by year end."], [null, null, ""], [null, null, "\uf0b7 I noted, the entity did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to quantify outputs; partial and"], [null, null, "non-implementation of planned activities delayed submission of"], [null, null, "performance reports; under absorption of funds worth UGX."], [null, null, "3,884,528,244 that was eventually swept back to consolidated"], [null, null, "fund account at end of financial year and under performance of"], [null, null, "revenues worth UGX. 1,734,443,308"], [null, null, ""], [null, null, "\uf0b7 I noted that Kamuli District received off-budget financing to a"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 344, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None", "None"], "type": "table"}}, {"content": "332", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 344, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "tune of UGX. 185,243,153 directly from Ministry of Health (MoH)"], [null, "and Marie topes for undertaking activities which was never"], [null, "declared to the PSST and as such no supplementary"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 345, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": [["", "tune of UGX. 185,243,153 directly from Ministry of Health (MoH)"], [null, "and Marie topes for undertaking activities which was never"], [null, "declared to the PSST and as such no supplementary"], [null, "appropriation was issued as guided by the PSST."], [null, ""], [null, "\uf0b7 I noted that the District lacked land titles for 194 pieces of land"], [null, "measuring approximately 546 acres including schools and health"], [null, "centers."], [null, ""], [null, "\uf0b7 I noted delays in the construction works on Kitayunjwa seed"], [null, "secondary school and construction works of seed secondary"], [null, "schools at Nabwigulu and Kagumba did not take off in the"], [null, "financial year under review and the funds were swept back to"], [null, "treasury."], [null, ""], [null, "\uf0b7 I noted at the time of inspection on 25th August, 2021 that"], [null, "science kits and chemicals that were delivered for Kitayunjwa"], [null, "Seed School were still in the district stores."], [null, ""], [null, "\uf0b7 I observed that works at Kagumba HC II were still ongoing and"], [null, "the works progress was behind"], [null, ""], [null, "\uf0b7 Under URF, There was underfunding of UGX 49,538,044 under"], [null, "URF for road maintenance"], ["13\\. Jinja RRH Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the Hospital pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.1.7Bn; over payment of gratuity worth UGX. 12,702,466 resulting from wrong computations; under payments of pension and gratuity of UGX. 393,563,387; under payment of salaries worth UGX. 43,160,618 and nonpayment of salaries worth UGX. 5,193,740 to eight employees; 14 pensioners were paid a total of UGX. 622,229,852 off the IPPS; twenty two (22) pensioners delayed to access the pension payroll; paid 4 employees who had retired worth UGX. 6,149,095 and under remittance of pay roll deductions amounting to UGX. 39,740,732 \uf0b7 The Hospital had payables of UGX. 1,184,835,800 for payment of utilities, pension and gratuity. \uf0b7 I noted that the entity did not have an approved strategic plan that was aligned to the NDP-III at the time of audit. \uf0b7 I noted that the Referral Hospital received off-budget financing to a tune of UGX.1,482,640,867, which was not declared to treasury. \uf0b7 Expenditure totaling UGX. 154,045,146 was misclassified through wrong coding \uf0b7 The referral hospital received UGX. 581,089,500 as covid 19 funds. Out of which UGX. 385,881,400 was utilized but UGX.30, 585,000 lacked adequate supporting documentation at the close", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 345, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["donor funds, NTR, releases from Government & other Government units \uf0b7 The Municipality mischarged expenditure worth UGX.5,244,093 on wrong budget lines other than those prescribed for salary, pension or gratuity \uf0b7 The Municipal\u2019s strategic plan was not approved by the National Planning Authority at the time of audit and therefore I could not confirm that it is aligned to NDP-III. \uf0b7 The Municipality lacked certificates of title for 13 pieces of land. \uf0b7 I noted that the MC did not have sufficient waste receptacles and solid waste collection vehicles which have led to piling of garbage on the Municipality streets resulting into a public health nuisance.", "None"], "type": "table"}}, {"content": "333", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 345, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["of the financial year. Further, I observed there was unspent balance of UGX. 195,208,100 \uf0b7 I noted that NTR totaling to UGX.74, 272,140 was spent at source contrary to regulations \uf0b7 Jinja RRH made Payments totaling UGX.41, 914,100 for clearing domestic arrears lacked appropriate supporting documents, UGX.76, 523,500 paid to M/S Rodek Enterprises Ltd towards settlement of outstanding bills for cleaning services of the hospital had not been cleared by Ernst and Young. \uf0b7 The hospital received off-budget financing from the Ministry of health amounting to UGX. 1,482,640,867. \uf0b7 I noted that the hospital commenced construction of a storey staff house on 15 th /04/2019 with an intended completion date of 14 th /10/2021 at a contract price of UGX. 3,205,111,734 but was noted to be incomplete to date, with outstanding advance payment of UGX. 73,337,302 to the contractor. \uf0b7 Expenditures worth UGX. 166,012,755 lacked adequate supporting documents \uf0b7 The Hospital had stock outs of Essential medicines for supportive treatment of Covid-19 during the year with an average stock out period of more than a month. Several drugs that expired during the year had not yet been removed from the shelves as required. \uf0b7 I observed that the hospital did not carry out regular maintenance of the available medical equipment. \uf0b7 I noted that the Hospital did not have land titles for 5 pieces of land measuring approximately 46.7 acres. \uf0b7 I noted that some of the buildings in the hospital were in a dilapidated state while other blocks accommodating nurses were not fit for accommodation due to their dilapidated state and there was lack of hygiene facilities such as latrines and bathrooms.", null, null], ["14.", "Bugiri DA", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 346, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": [["of the financial year. Further, I observed there was unspent balance of UGX. 195,208,100 \uf0b7 I noted that NTR totaling to UGX.74, 272,140 was spent at source contrary to regulations \uf0b7 Jinja RRH made Payments totaling UGX.41, 914,100 for clearing domestic arrears lacked appropriate supporting documents, UGX.76, 523,500 paid to M/S Rodek Enterprises Ltd towards settlement of outstanding bills for cleaning services of the hospital had not been cleared by Ernst and Young. \uf0b7 The hospital received off-budget financing from the Ministry of health amounting to UGX. 1,482,640,867. \uf0b7 I noted that the hospital commenced construction of a storey staff house on 15 th /04/2019 with an intended completion date of 14 th /10/2021 at a contract price of UGX. 3,205,111,734 but was noted to be incomplete to date, with outstanding advance payment of UGX. 73,337,302 to the contractor. \uf0b7 Expenditures worth UGX. 166,012,755 lacked adequate supporting documents \uf0b7 The Hospital had stock outs of Essential medicines for supportive treatment of Covid-19 during the year with an average stock out period of more than a month. Several drugs that expired during the year had not yet been removed from the shelves as required. \uf0b7 I observed that the hospital did not carry out regular maintenance of the available medical equipment. \uf0b7 I noted that the Hospital did not have land titles for 5 pieces of land measuring approximately 46.7 acres. \uf0b7 I noted that some of the buildings in the hospital were in a dilapidated state while other blocks accommodating nurses were not fit for accommodation due to their dilapidated state and there was lack of hygiene facilities such as latrines and bathrooms.", null, null], ["14.", "Bugiri DA", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Unqualified Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.017Bn;"], [null, null, "un-deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX.13,100,078"], [null, null, ""], [null, null, "\uf0b7 Additionally, 68 newly recruited/ transferred employees and 04"], [null, null, "pensioners delayed to access the payroll; paid 7 employees who"], [null, null, "were no longer in service worth UGX. 4,090,197; Unpaid salaries"], [null, null, "worth UGX. 6,074,121; underpayment and overpayment of"], [null, null, "pensions & gratuity worth UGX. 26,897,618 and UGX. 13,600,648"], [null, null, "respectively and the district made unauthorized loan deductions"], [null, null, "from 49 employees worth UGX. 150,566,095"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 346, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": "334", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 346, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", ""], [null, "\uf0b7 I noted that Bugiri District had outstanding receivables of UGX."], [null, "1,140,326,136 that had remained unrecovered"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 347, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", ""], [null, "\uf0b7 I noted that Bugiri District had outstanding receivables of UGX."], [null, "1,140,326,136 that had remained unrecovered"], [null, ""], [null, "\uf0b7 Payables of UGX. 30,517,114 remained unsettled by year end"], [null, ""], [null, "\uf0b7 I noted that the entity had prepared a draft Strategic plan but"], [null, "had not yet been approved by NPA at the time of audit."], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; Failure to quantify outputs; partial and"], [null, "non-implementation of planned activities delayed submission of"], [null, "performance reports; under absorption of funds worth UGX. UGX."], [null, "422,963,116 that was eventually swept back to consolidated fund"], [null, "account at end of financial year and under performance of"], [null, "revenues worth UGX. 3,550,589,111"], [null, ""], [null, "\uf0b7 I noted that funds to the tune of UGX. 172,737,949 were"], [null, "irregularly diverted from the activities on which they were"], [null, "budgeted and spent on other activities without seeking and"], [null, "obtaining the necessary approvals."], [null, ""], [null, "\uf0b7 I noted that construction works for Budhaya Seed secondary"], [null, "school did not take off"], [null, ""], [null, "\uf0b7 Underfunding worth UGX 24,751,000 was noted for URF meant"], [null, "for road maintenance"], [null, ""], [null, "\uf0b7 I noted that the District lacked land titles for 16 pieces of land"], [null, "measuring approximately 106.7 acres including schools, sub"], [null, "counties and health centers."], [null, ""], [null, "\uf0b7 Bugiri district received a sum of UGX. 204,224,148 for (08)"], [null, "secondary schools and (140) primary schools meant for the"], [null, "procurement of learning materials. I noted that (47) schools had"], [null, "irregularly utilized the funds totaling to UGX. 50,639,930 without"], [null, "proper guidance, (58) schools had not utilized the funds, while"], [null, "bank statements as at end of October 2021 for (43) schools were"], [null, "not presented to enable establishment of whether the funds had"], [null, "been utilized without proper guidance or not."], ["15\\. Njeru MC Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the Municipal pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.0.31Bn; Under and overpayment of salaries worth UGX. 8,321,986 and UGX. 31,890,939 respectively; under payments of pensions worth UGX. 4,693,227; paid 12 staff a total of UGX. 13,933,412 off the IPPS; the Municipal Council did not prepare monthly wage, pension and gratuity performance analysis for submission to MoPS and Paid UGX. 6,413,424 to 05 staff who were no longer in service \uf0b7 Additionally, I noted that 18 newly recruited/ transferred employees and 08 pensioners delayed to access the pension", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 347, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "335", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 347, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["payroll and 01 pensioner had never accessed the payroll; 15 employees were paid a total of UGX. 16,677,139 without signed pay change reports; over and under payment of thirteen (13) pensioners worth UGX. 34,733,352 and UGX. 24,197,298 respectively arising from wrong computation of gratuity benefits \uf0b7 The municipality paid 322 employees using the wrong bands, leading to monthly over payments of UGX. 7,147,390 and under payments of UGX. 2,837,275 \uf0b7 The Municipal Council made unauthorized loan deductions totaling UGX. 14,734,700 from 19 employees that lacked evidence of signing letters of undertaking \uf0b7 The Municipal Council had outstanding unrecovered funds (receivables) of UGX. 891,306,154 by close of financial year \uf0b7 I noted that the Municipal Council had prepared but had not had the strategic plan approved and aligned to the NDP-III at the time of audit \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 1,815,926,807 that was eventually swept back to consolidated fund account at end of financial year and under performance of revenues worth UGX. 2,234,326,614 \uf0b7 URF underfunding of UGX. 86,246,400 meant for road maintenance was noted \uf0b7 Njeru MC received a sum of UGX. 84,619,384 for (48) primary and secondary schools meant for the procurement of learning materials in March, 2021 and disbursed UGX. 84,619,384 (100%) to (48) schools on 28th June, 2021. However, the various school\u2019s bank statements had not been availed for review at the time of audit \uf0b7 I noted that the Municipal Council did not have land titles for 12 out of 22 pieces of land including schools and health centers", null, null], ["16.", "Iganga DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 348, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", ""], "type": "table"}}, {"content": [["payroll and 01 pensioner had never accessed the payroll; 15 employees were paid a total of UGX. 16,677,139 without signed pay change reports; over and under payment of thirteen (13) pensioners worth UGX. 34,733,352 and UGX. 24,197,298 respectively arising from wrong computation of gratuity benefits \uf0b7 The municipality paid 322 employees using the wrong bands, leading to monthly over payments of UGX. 7,147,390 and under payments of UGX. 2,837,275 \uf0b7 The Municipal Council made unauthorized loan deductions totaling UGX. 14,734,700 from 19 employees that lacked evidence of signing letters of undertaking \uf0b7 The Municipal Council had outstanding unrecovered funds (receivables) of UGX. 891,306,154 by close of financial year \uf0b7 I noted that the Municipal Council had prepared but had not had the strategic plan approved and aligned to the NDP-III at the time of audit \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 1,815,926,807 that was eventually swept back to consolidated fund account at end of financial year and under performance of revenues worth UGX. 2,234,326,614 \uf0b7 URF underfunding of UGX. 86,246,400 meant for road maintenance was noted \uf0b7 Njeru MC received a sum of UGX. 84,619,384 for (48) primary and secondary schools meant for the procurement of learning materials in March, 2021 and disbursed UGX. 84,619,384 (100%) to (48) schools on 28th June, 2021. However, the various school\u2019s bank statements had not been availed for review at the time of audit \uf0b7 I noted that the Municipal Council did not have land titles for 12 out of 22 pieces of land including schools and health centers", null, null], ["16.", "Iganga DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.1.07Bn;"], [null, "Unqualified", "under payment of salaries worth UGX. 32,546,140; non-"], [null, "", "payments of pensioners worth UGX. 80,485,339; paid 16 staff"], [null, null, "using wrong bands, leading to monthly over payments of UGX."], [null, null, "287,429 and under payments of UGX. 526,840; paid UGX."], [null, null, "4,349,175 to 07 staff who had retired, transferred or absconded;"], [null, null, "over and under remittance of salary deductions worth UGX."], [null, null, "7,428,040 and UGX. 42,133,941 respectively"], [null, null, ""], [null, null, "\uf0b7 Additionally, I noted that there was Un-deducted PAYE from"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 348, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", ""], "type": "table"}}, {"content": "336", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 348, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "political leaders\u2019 gratuity resulting in unpaid tax of"], [null, "UGX.10,059,827; 32 pensioners delayed to access the pension"], [null, "payroll and 19 pensioners had never accessed the payroll and"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 349, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", ""], "type": "table"}}, {"content": [["", "political leaders\u2019 gratuity resulting in unpaid tax of"], [null, "UGX.10,059,827; 32 pensioners delayed to access the pension"], [null, "payroll and 19 pensioners had never accessed the payroll and"], [null, "therefore not paid; 55 employees were paid a total of UGX. 30"], [null, "million without signed pay change reports and 73 employees and"], [null, "34 pensioners were paid a total of UGX. 1,166,247,120 off the"], [null, "IPPS"], [null, ""], [null, "\uf0b7 The district had outstanding unrecovered funds (receivables) of"], [null, "UGX. 1,705,945,185 by the end of the period"], [null, ""], [null, "\uf0b7 I noted that the district was engrossed in a number of court"], [null, "cases estimated at UGX. 3,832,685,041"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; Failure to quantify outputs; partial and"], [null, "non-implementation of planned activities delayed submission of"], [null, "performance reports; under absorption of funds worth UGX."], [null, "2,137,465,419 that was eventually swept back to consolidated"], [null, "fund account at end of financial year and under performance of"], [null, "revenues worth UGX. 9,278,908,203"], [null, ""], [null, "\uf0b7 I noted that the entity had not prepared and approved a"], [null, "strategic plan that is aligned to the NDP-III"], [null, ""], [null, "\uf0b7 I noted that the District had 04 pieces of land that were not titled"], [null, "as well as 33 pieces of land under its supervision that were also"], [null, "not titled"], [null, ""], [null, "\uf0b7 There was URF underfunding of UGX 57,904,000 meant for road"], [null, "maintenance that affected road roads in the district."], ["17\\. Luuka DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, failure to utilize wage funds of UGX.1.60Bn; under payment of salaries UGX. 33,624,349 \uf0b7 The District had with payments leading to over and over payments of UGX. 188,313272 due to wrong computation; underpayments of UGX. 39,314,543 to 32 pensioners resulting from wrong computation of gratuity benefits; made over and under payments of UGX. 16,741,697 and UGX. 8,347,743 respectively due to use of wrong salary bands \uf0b7 Paid UGX. 21,149,890 to 10 staff, who had retired, transferred, absconded or died; under remitted salary deductions worth UGX. 319,599,269; the District made unauthorized loan deductions totaling UGX. 158,654,625 from 115 employees; Un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 2,659,020 and under payment of pensioners worth UGX. 485,724,648 \uf0b7 Additionally, I noted that 41 newly recruited/ transferred employees and 19 pensioners delayed to access payroll; 47", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 349, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", ""], "type": "table"}}, {"content": "337", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 349, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["employees were paid a total of UGX. 215,642,700 without signed pay change reports; the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS; I noted that 21 staff and 01 pensioner were paid a total of UGX. 37,733,743 off the IPPS \uf0b7 The district mischarged funds worth UGX. 40,695,963 on account codes other than those prescribed for salary, pension and gratuity \uf0b7 I noted the district had outstanding unrecovered receivables of UGX. 885,992,084 by the year end. \uf0b7 I noted that the Council was engrossed in 03 court cases with individuals which could lead to possible loss of funds \uf0b7 I noted that the entity had prepared but not had the strategic plan approved and aligned to the NDP-III at the time of audit \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 652,127,207 that was eventually swept back to consolidated fund account at end of financial year and under performance of revenues worth UGX.673,814,209 \uf0b7 The District commenced construction works on Ikumbya seed secondary school under the Education Sector in the FY 2018/2019. At the time of inspection on 28th October, 2021, I observed that works were still ongoing at 87% progress, with all structures yet to be properly floored, with partial painting, no glasses, no roofing of latrine and the compound yet to be cleared and set \uf0b7 Luuka DLG budgeted for and received UGX. 344,284,000 for the initial stages of the construction of Buwanda Seed Secondary in the FY 2020/2021. However, construction works did not take off in the financial year under review and the funds were swept back to treasury \uf0b7 Luuka DLG received a sum of UGX. 217,156,943 for 89 primary schools and 8 secondary schools meant for the procurement of learning materials on 1st April, 2021 and disbursed UGX. 136,640,827 (63%) to 53 primary schools and 5 secondary schools on 28th June, 2021. UGX. 80,516,116 was not disbursed by the district. However, the respective school bank statement and receipts had not been availed for review at the time of audit, and as such, I could not establish whether the funds were still on the accounts", null, null], ["18.", "Iganga MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 350, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": [["employees were paid a total of UGX. 215,642,700 without signed pay change reports; the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS; I noted that 21 staff and 01 pensioner were paid a total of UGX. 37,733,743 off the IPPS \uf0b7 The district mischarged funds worth UGX. 40,695,963 on account codes other than those prescribed for salary, pension and gratuity \uf0b7 I noted the district had outstanding unrecovered receivables of UGX. 885,992,084 by the year end. \uf0b7 I noted that the Council was engrossed in 03 court cases with individuals which could lead to possible loss of funds \uf0b7 I noted that the entity had prepared but not had the strategic plan approved and aligned to the NDP-III at the time of audit \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under absorption of funds worth UGX. 652,127,207 that was eventually swept back to consolidated fund account at end of financial year and under performance of revenues worth UGX.673,814,209 \uf0b7 The District commenced construction works on Ikumbya seed secondary school under the Education Sector in the FY 2018/2019. At the time of inspection on 28th October, 2021, I observed that works were still ongoing at 87% progress, with all structures yet to be properly floored, with partial painting, no glasses, no roofing of latrine and the compound yet to be cleared and set \uf0b7 Luuka DLG budgeted for and received UGX. 344,284,000 for the initial stages of the construction of Buwanda Seed Secondary in the FY 2020/2021. However, construction works did not take off in the financial year under review and the funds were swept back to treasury \uf0b7 Luuka DLG received a sum of UGX. 217,156,943 for 89 primary schools and 8 secondary schools meant for the procurement of learning materials on 1st April, 2021 and disbursed UGX. 136,640,827 (63%) to 53 primary schools and 5 secondary schools on 28th June, 2021. UGX. 80,516,116 was not disbursed by the district. However, the respective school bank statement and receipts had not been availed for review at the time of audit, and as such, I could not establish whether the funds were still on the accounts", null, null], ["18.", "Iganga MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 350, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "338", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 350, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], [null, "Unqualified", "under payment of salaries worth UGX. 119,289,474; irregularly"], [null, "", "paid one staff who had retired UGX. 1,971,915; over remittance"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 351, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], [null, "Unqualified", "under payment of salaries worth UGX. 119,289,474; irregularly"], [null, "", "paid one staff who had retired UGX. 1,971,915; over remittance"], [null, null, "of payroll deductions worth UGX.10,164,672"], [null, null, ""], [null, null, "\uf0b7 Additionally, the Municipal Council did not prepare monthly wage,"], [null, null, "pension and gratuity performance analysis and thus did not"], [null, null, "submit quarterly returns on payroll to MoPS; 22 staff were paid a"], [null, null, "total of UGX. 37,734,317 off the IPPS; 15 employees were paid a"], [null, null, "total of UGX.7.9 million without signed pay change reports; 03"], [null, null, "newly recruited/transferred employees and 6 pensioners delayed"], [null, null, "to access payroll; Un-deducted PAYE from political leaders\u2019"], [null, null, "gratuity resulting in unpaid tax of UGX. 2,607,660"], [null, null, ""], [null, null, "\uf0b7 I noted that the verification forms and copies of the verification"], [null, null, "cards for all employees and pensioners/beneficiaries were not on"], [null, null, "the respective personal files"], [null, null, ""], [null, null, "\uf0b7 The Municipal Council had outstanding receivables of UGX."], [null, null, "1,705,945,185 that had not been recovered by year end."], [null, null, ""], [null, null, "\uf0b7 Municipal Council had outstanding payables of UGX. 650,570,897"], [null, null, "unsettled by year"], [null, null, ""], [null, null, "\uf0b7 I noted that the Municipal Council had not prepared and"], [null, null, "approved a strategic plan that is aligned to the NDP-III at the"], [null, null, "time of audit"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to quantify outputs; partial and"], [null, null, "non-implementation of planned activities delayed submission of"], [null, null, "performance reports; under performance of revenues worth UGX."], [null, null, "801,240,396"], [null, null, ""], [null, null, "\uf0b7 Noted URF underfunding of UGX 24,821,498 that affected road"], [null, null, "maintenance at the Municipality"], [null, null, ""], [null, null, "\uf0b7 Iganga Municipal Council did not have land titles for 15 of the 25"], [null, null, "pieces of land with some land files deemed missing (Bupala"], [null, null, "land)."], ["Branch Kampala Summary of Key Findings", null, null], ["01.", "Buikwe DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Over payment of salary to 7"], [null, "Opinion Unqualified", "staffs worth UGX. 6,542,796; Underpayment of salaries to 24"], [null, null, "employees worth UGX. 20,560,692; payment of salaries worth"], [null, "", "UGX 4,697,808 to two (2) staffs that was no longer in service and irregular deduction of loan instalments worth UGX."], [null, null, "56,120,313 for 23 employees."], [null, "", "\uf0b7 Additionally, I observed that there was delayed access to payroll by ten (10) new employees; un-deducted PAYE from political"], [null, null, "leaders\u2019 gratuity resulting in unpaid tax of UGX. 10,214,875; and"], [null, null, "unpaid pension and gratuity worth UGX. 95,481,460"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 351, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "339", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 351, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds worth"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 352, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds worth"], [null, null, "UGX.1.11Bn that was swept back to consolidated fund account"], [null, null, "and under performance of the releases from government worth"], [null, null, "UGX.2,590,769,685;"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX. 55,352,971 on"], [null, null, "wrong budget lines"], [null, null, ""], [null, null, "\uf0b7 The district had unrecovered funds worth UGX. 597,864,391 from"], [null, null, "YLP and UWEP groups."], [null, null, ""], [null, null, "\uf0b7 I noted off budget funding worth UGX.1,460,725,115 received for"], [null, null, "Result Based Financing (RBF) from the ministry of Finance."], [null, null, ""], [null, null, "\uf0b7 I also noted that the original copy of the title for Plot 18"], [null, null, "Kyaggwe block 564, land at Nansagazi landing site measuring"], [null, null, "7.06 hectares was missing from the safe."], ["02\\. Buvuma DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Over payment of salaries worth UGX. UGX.1,243,832; Underpayment of salaries worth UGX. UGX.1,667,474; Wrong computation of gratuity for four (4) pensioners worth UGX.2,382,045 and UGX.1,325,359 respectively; under remittance of employee\u2019s salary deductions worth UGX.139,719,468; unpaid salaries worth UGX. 0.883 Bn and delayed remittance of deductions to UCLA/UBA worth UGX.224 million \uf0b7 Additionally, I observed that there was delayed access to payroll by twenty (20) new employees and two (2) pensioners; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.18,624,938 and payment of one (1) pensioner worth UGX.10,519,628 off the IPPS. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial implementation of planned activities; under absorption of funds worth UGX. 0.888 Bn; under performance of the releases from other government units worth UGX.1,004,434; delayed submission of quarterly monitoring reports to OPM & MoFPED and late submission of performance reports \uf0b7 The district mischarged expenditure worth UGX.31,344,359 on wrong budget \uf0b7 I noted unrecovered funds of YLP and UWEP worth UGX.426,197,440 and UGX.161,592,376 respectively", null, null], ["03.", "ENTEBBE MC", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the Municipal"], [null, "Opinion", "pension & salary payrolls such as; Over payment of salaries"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 352, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "340", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 352, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Unqualified", "worth UGX.5,237,820; payment of salaries worth UGX.2,734,481"], [null, "", "to three (03) staffs that were no longer in service; over and"], [null, null, "under remittance of salaries worth UGX17,579,629 and"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 353, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", "Unqualified", "worth UGX.5,237,820; payment of salaries worth UGX.2,734,481"], [null, "", "to three (03) staffs that were no longer in service; over and"], [null, null, "under remittance of salaries worth UGX17,579,629 and"], [null, null, "UGX,8,495,808 respectively"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by ten (10) pensioners and un-deducted PAYE from political"], [null, null, "leaders\u2019 gratuity resulting in unpaid tax of UGX,2,607,660"], [null, null, ""], [null, null, "\uf0b7 The MC had outstanding receivables totaling to UGX.1,"], [null, null, "280,357,120 for YLP, UWEP and uncollected local revenue."], [null, null, ""], [null, null, "\uf0b7 Municipal Council outstanding commitments of UGX 170,801,502"], [null, null, "by close of the financial year"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds worth UGX."], [null, null, "5,594,339,871; under performance of the donor worth UGX"], [null, null, "80,040,000 & shortfalls in local revenue worth"], [null, null, "UGX.3,507,045,896;"], [null, null, ""], [null, null, "\uf0b7 I noted that there was an over commitment by the Municipal"], [null, null, "council of funds worth UGX. 6,503,237,230 under the USMID"], [null, null, "project through and agreement signed with M/s China Wu Yi Co."], [null, null, "Ltd on the 21 st April 2021."], [null, null, ""], ["04\\. Luwero DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salary worth UGX.150 million; unpaid salaries worth UGX.1.254 Bn and under/over remittance of employee salaries worth UGX.165,627,734 and UGX.37,026,373 respectively \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit. \uf0b7 Additionally, I observed that there was delayed access to payroll by thirty-eight (38) new/transferred employees and twenty- two (22) pensioners and un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.15,523,074 \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under performance worth UGX. 1,317,898,459; incomplete works at Katikamu Seed Secondary School and under absorption of funds worth UGX.1.256 Bn \uf0b7 The district received off-budget financing worth UGX.1,002,619,377 directly from Ministry of Health under Result Based Financing Programme (RBF) \uf0b7 The district mischarged expenditure worth UGX.8,575,441 on wrong budget lines. \uf0b7", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 353, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "341", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 353, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["05.", "MITYANA DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Over payment of salaries"], [null, "Opinion Unqualified", "worth UGX.2,992,554; Wrong computation of gratuity worth net"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 354, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["05.", "MITYANA DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Over payment of salaries"], [null, "Opinion Unqualified", "worth UGX.2,992,554; Wrong computation of gratuity worth net"], [null, null, "overpayment of UGX. 2,271,141; payment of salaries worth"], [null, null, "UGX.4,057,892 to ten (10) staffs that were no longer in service;"], [null, null, "irregular deduction of loan instalments for three (3) staff worth"], [null, null, "UGX. 1,085,168; over and under remittance of employees\u2019"], [null, null, "salaries worth UGX. 9,347,419 and UGX.52,480,527 respectively"], [null, null, "and payroll deductions to UCLA/UBA worth UGX. 10,193,805"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by thirty (30) new employees and sixteen (16) pensioners; un-"], [null, null, "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid"], [null, null, "tax of UGX. 12,460, 278 and unremitted PAYE worth"], [null, null, "UGX.41,763,487"], [null, null, ""], [null, null, "\uf0b7 Failure to remit local government revenue worth UGX.49,502,388"], [null, null, "to LLGs"], [null, null, ""], [null, null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 I noted issues such as incomplete works and under absorption of"], [null, null, "funds worth UGX.0.7 Bn in the implementation of the approved"], [null, null, "budget."], [null, null, ""], [null, null, "\uf0b7 The district lacked a title of land where the health Centre is being"], [null, null, "constructed."], [null, null, ""], ["06\\. Mukono DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of pensioners/employees worth UGX2,503,100 and UGX. 5,442,660 respectively. Underpayment worth UGX. 4,860,118; payment of salaries worth UGX.6,175,829 to nine (9) staffs that was no longer in service and irregular deduction of loan instalments for five (5) staff worth 3,165,094 \uf0b7 Additionally, I observed that there was delayed access to payroll by fourteen (14) new employees and fourteen (14) pensioners; failure to utilize wage funds of UGX.0.1 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 12,104,504 and payment of five (5) staffs and three (3) pensioners worth UGX.9,195,665 off the IPPS; over/ under remittance of employee\u2019s salary deductions worth UGX. 2,345,800 and UGX. 97,808,530 respectively. \uf0b7 I noted that 14 employees were paid a total of UGX. 2,875,407 without signed pay change reports. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete works at Mukono General", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 354, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "342", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 354, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Hospital and Kimenyedde Seed Secondary School; under absorption of funds worth UGX.0.4bn that was swept back to consolidated fund account and under performance worth UGX.1, 909251149;", null, null], ["07.", "MUKONO MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 355, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["Hospital and Kimenyedde Seed Secondary School; under absorption of funds worth UGX.0.4bn that was swept back to consolidated fund account and under performance worth UGX.1, 909251149;", null, null], ["07.", "MUKONO MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, payment of salaries worth UGX 11.1M to nine"], [null, "Unqualified", "(9) staffs that was no longer in service and unpaid pension worth"], [null, "", "UGX.106.9M"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by four (4) new employees and seven (7) pensioners; un-"], [null, null, "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid"], [null, null, "tax of UGX 2.6M and payment of fifty-four (54) staffs and one"], [null, null, "(1) pensioner worth UGX 60.5M off the IPPS"], [null, null, ""], [null, null, "\uf0b7 The Municipal Council did not have an approved strategic plan"], [null, null, "that is aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 I noted an issue of under performance of the releases from other"], [null, null, "government units worth UGX.2,529,600,000; in the"], [null, null, "implementation of the approved budget"], ["08\\. Nakaseke DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit pension and gratuity estimates to MoPs, Underpayment of pension/gratuity worth UGX.104,392,407; irregular deduction of loan instalments of seven (7) employees worth UGX.7, 853,306; unpaid pension and gratuity worth UGX.77, 373,425; over and under remittance of employee salaries deductions worth UGX.51, 659,500 and UGX.3, 303,310 respectively and unpaid pension arrears worth UGX.245,882,164 \uf0b7 The district had outstanding Payables worth UGX.467,701,993 and Receivables worth UGX.1,660,675,633 by close of financial year \uf0b7 Additionally, I observed that there was delayed access to payroll by twenty-two (22) employees and twenty-five (25) pensioners; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of 14, 265,549 and payment of two (2) pensioners worth UGX.6,199,129 and 1 staff worth UGX.26,750,870 off the IPPS \uf0b7 I noted that Butalangu HCIII lacked laboratory, th\u00e9\u00e2tre and maternity ward equipment \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works on roads- Kinyogoga- Kyabalongo- Kitindo 18.0Km and Kalagala- Kyamaweno- Kinyogoga 34km; incomplete works at Kalenge HC III and under absorption of funds worth UGX.0.3 billion that was swept back to consolidated fund account.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 355, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "343", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 355, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["09.", "Nakasongola District", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; under payment of pension"], [null, "Opinion Unqualified", "worth UGX. UGX.1,510,120; Underpayment of salary worth"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 356, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["09.", "Nakasongola District", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; under payment of pension"], [null, "Opinion Unqualified", "worth UGX. UGX.1,510,120; Underpayment of salary worth"], [null, null, "UGX.13million; Wrong computation of gratuity worth net"], [null, "", "overpayment of two (2) pensioners worth UGX.20,784,707;"], [null, null, "payment of salaries worth UGX. 23,149,880 to eighteen (18)"], [null, null, "staffs that were no longer in service and irregular deduction of"], [null, null, "loan instalments worth UGX.307,637,65."], [null, null, ""], [null, null, "\uf0b7 Under remittance of salary deductions worth UGX.132,371,427"], [null, null, ""], [null, null, "\uf0b7 I noted that the district made payroll deductions of UGX.16"], [null, null, "million, but did not remit to UCLA/UBA."], [null, null, ""], [null, null, "\uf0b7 I noted outstanding UWEP and YLP advances worth"], [null, null, "UGX.665,481,500 by year end"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by eighteen (18) new employees and thirteen (13) pensioners"], [null, null, "and un-deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX.12,011,160"], [null, null, ""], [null, null, "\uf0b7 The district had outstanding pension and gratuity arrears worth"], [null, null, "UGX.234,272,456 at year end."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; un implemented works at a Seed"], [null, null, "School; under absorption of funds worth UGX.0.6 billion and"], [null, null, "under performance of the releases from other government units"], [null, null, "worth 169 Mn;"], [null, null, "\uf0b7"], ["10\\. Nansana MC Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the Municipal pension & salary payrolls such as; Over payment of salaries/pension worth UGX. 2,494,859 and UGX.24,488,037 respectively; Underpayment of pension worth UGX.11,791,871; and irregular deduction of loan instalments worth UGX.18,027,312. \uf0b7 Un recovered UWEP/YLP funds of UGX.899,208,480 \uf0b7 The Municipal Council did not have an approved strategic plan that is aligned to the NDP-III at the time of audit. \uf0b7 Additionally, I observed that there was delayed access to payroll by three (3) new employees and nineteen (19) pensioners; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 3,122,640 \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works on the road construction; under absorption of funds worth UGX.0.278 billion that was swept back to consolidated fund account and under performance of the releases from other government units worth", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 356, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "344", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 356, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["UGX.534,603,597; \uf0b7 Failure to prepare monthly wage, pension and gratuity performance analysis \uf0b7 The Municipal Council reported receivables balance of UGX.1,780,766,221 \uf0b7 The Municipal Council had outstanding payables of UGX. 87,603,199 by close of the financial year \uf0b7 I noted that UGX.1,131,374,846 (103%) was spent on 2km reflecting over expenditure of UGX.51,408,546. The cost variations in projects planned works affects implementation of other maintenance activities.", null, null], ["11.", "Wakiso District", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as Underpayment of pension"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 357, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["UGX.534,603,597; \uf0b7 Failure to prepare monthly wage, pension and gratuity performance analysis \uf0b7 The Municipal Council reported receivables balance of UGX.1,780,766,221 \uf0b7 The Municipal Council had outstanding payables of UGX. 87,603,199 by close of the financial year \uf0b7 I noted that UGX.1,131,374,846 (103%) was spent on 2km reflecting over expenditure of UGX.51,408,546. The cost variations in projects planned works affects implementation of other maintenance activities.", null, null], ["11.", "Wakiso District", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as Underpayment of pension"], [null, "Opinion", "worth UGX.2, 010,117,938; payment of salaries worth UGX.5,"], [null, "Unqualified", "278,315 to five (5) staffs that was no longer in service; unpaid"], [null, "", "salaries UGX.8, 379,873 and accrued pension worth"], [null, null, "UGX.265,144,965"], [null, null, ""], [null, null, "\uf0b7 The outstanding payables for pension and gratuity worth UGX.2,"], [null, null, "405,604,903"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by seventeen (17) pensioners; failure to utilize wage funds of"], [null, null, "UGX.0.7 Bn; un-deducted PAYE from political leaders\u2019 gratuity"], [null, null, "resulting in unpaid tax of 14, 993,898 and payment eleven (11)"], [null, null, "pensioners worth UGX.303, 639,396 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; shoddy works at Nakitokolo HCIII;"], [null, null, "delayed works at Kasoozo HCIII; incomplete works at Wakiso"], [null, null, "Seed School; under absorption of funds worth"], [null, null, "UGX.1,108,628,816 that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX.6,616,905,830;"], [null, null, ""], ["12\\. KIRA MC Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the Municipal pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salary worth UGX. 12,367,380; Underpayment of salary worth UGX. 1,513,296; Wrong computation of gratuity worth net overpayment of UGX.23,863,854 and payment of salaries worth UGX 9,760,420 to nine (09) staffs that were no longer in service \uf0b7 I noted Over remittance of salary deductions worth UGX. 36,961,624 \uf0b7 I noted outstanding receivables worth of UGX. 3,171,846,861 \uf0b7 Additionally, I observed that there was delayed access to payroll", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 357, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "345", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 357, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["by three (3) new employees and sixteen (16) pensioners; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 3,015,540 and payment worth UGX. 435,546,906 off the IPPS \uf0b7 failure to prepare monthly wage, pension and gratuity performance analysis \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete construction works; under absorption of funds worth UGX.0.16Bn that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.3,402,046,314 and failure to submit quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the Municipal Council received off-budget financing worth UGX135,974,720 for Result Based Financing (RBF) from the Ministry of Health \uf0b7 The district mischarged expenditure worth UGX. 20,821,532 on wrong budget lines.", null, null], ["13.", "MAKINDYE SABAGABO", "\uf0b7 I noted a number of anomalies during review of the municipal"], ["", "MC", "pension & salary payrolls such as, Over payment of salary worth"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 358, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["by three (3) new employees and sixteen (16) pensioners; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 3,015,540 and payment worth UGX. 435,546,906 off the IPPS \uf0b7 failure to prepare monthly wage, pension and gratuity performance analysis \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete construction works; under absorption of funds worth UGX.0.16Bn that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.3,402,046,314 and failure to submit quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the Municipal Council received off-budget financing worth UGX135,974,720 for Result Based Financing (RBF) from the Ministry of Health \uf0b7 The district mischarged expenditure worth UGX. 20,821,532 on wrong budget lines.", null, null], ["13.", "MAKINDYE SABAGABO", "\uf0b7 I noted a number of anomalies during review of the municipal"], ["", "MC", "pension & salary payrolls such as, Over payment of salary worth"], [null, "", "UGX. 8,992,140; Wrong computation of gratuity worth net"], [null, "Opinion Unqualified", "underpayment of UGX. 9,709,876; payment of salaries worth"], [null, null, "UGX 20,892,893 to staffs that was no longer in service and"], [null, "", "irregular deduction of loan instalments worth UGX. 29,407,510."], [null, null, ""], [null, null, "\uf0b7 The Municipal Council reported payables worth UGX.532,235,004"], [null, null, "at end the financial year"], [null, null, ""], [null, null, "\uf0b7 The Municipal Council reported receivables worth"], [null, null, "UGX.750,391,890"], [null, null, ""], [null, null, "\uf0b7 The Municipal Council did not have an approved strategic plan"], [null, null, "that is aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by four (4) new employees and four (4) pensioners and un-"], [null, null, "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid"], [null, null, "tax of UGX.3,015,540"], [null, null, ""], [null, null, "\uf0b7 Un recovered UWEP/YLP funds worth UGX.459,332,075"], [null, null, ""], [null, null, "\uf0b7 I noted issues in the implementation of the approved budget"], [null, null, "such as; incomplete works on Mutundwe-Kisugula-Bunamwaya"], [null, null, "road; under absorption of funds worth UGX. 0.421 billion. and"], [null, null, "under performance of the releases from other government units"], [null, null, "worth UGX.6,801,993,716"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX. 304,575,692 on"], [null, null, "wrong budget lines."]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 358, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "346", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 358, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, ""], [null, null, "\uf0b7 A total of 19.1km at an estimated cost of UGX.70, 200,000 was"], [null, null, "planned to be undertaken. The audit revealed that 19.1 km were"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 359, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", null, ""], [null, null, "\uf0b7 A total of 19.1km at an estimated cost of UGX.70, 200,000 was"], [null, null, "planned to be undertaken. The audit revealed that 19.1 km were"], [null, null, "actually undertaken at a cost of UGX.152, 254,000 leading to an"], [null, null, "over expenditure of UGX. 82,054,000."], [null, null, ""], [null, null, "\uf0b7 I noted unrecovered funds from groups worth UGX.459,332,075"], ["Masaka Branch \uf0b7 Summary of Key Findings", null, null], ["01.", "Bukomansimbi DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, Underpayment of salary worth"], [null, "Unqualified", "UGX.13,134,104; payment of salaries worth UGX.5,195,665 to"], [null, "", "one (1) staff that was no longer in service; unpaid salary worth"], [null, null, "UGX.20,579,078; under payments of 5 pensioners worth"], [null, null, "UGX.1,133,789; under remittance of payroll deduction worth"], [null, null, "UGX.185,012,274; Amount worth UGX.10,081,159 wasn\u2019t"], [null, null, "remitted to UCLA/UBA and amount worth UGX.175,148,725 had"], [null, null, "not been remitted to URA"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by Sixteen (16) newly recruited/ transferred employees and Ten"], [null, null, "(10) pensioners; un-deducted PAYE from political leaders\u2019"], [null, null, "gratuity worth UGX.33,045,600, leading to an under deduction"], [null, null, "worth UGX.26,510,404 and payment of twenty (20) staffs worth"], [null, null, "UGX.4, 725,034 off the IPPS."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had prepared a strategic plan but the"], [null, null, "National Planning Authority had not yet approved it at the time of"], [null, null, "audit."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; the shortfalls in local revenue"], [null, null, "collections of UGX 9,848,129; Donor financing worth UGX."], [null, null, "759,350,373; under absorption of funds worth UGX.340,000,000"], [null, null, "that was swept back to consolidated fund account; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, "and Shoddy works in construction of classroom blocks"], [null, null, ""], [null, null, "\uf0b7 The district lacked land title for land on which Bukango Seed"], [null, null, "Secondary School is situated."], [null, null, ""], ["02\\. Kalangala DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district payroll such as; an unabsorbed balance of UGX 1.08 billion; an Over payment of salaries worth UGX 1,265,254, Underpayment of salaries of UGX.37, 719,627; Payment of salaries worth UGX. 1,480,155 to one (1) staff who had retired; under remittance of salary deductions worth UGX. 73,649,208 from employees\u2019 salaries; Deductions worth UGX. 100,753,524 relating to 57 employees without letters of under taking; unremitted deduction to UCLA/UBA worth UGX.2, 210, 654. \uf0b7 Additionally, I observed that the district did not remit deductions worth UGX.51,366,809 to URA; un-deducted PAYE from political", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 359, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "347", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 359, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["leaders\u2019 gratuity worth UGX.51,416,102, leading to an under deduction worth UGX UGX.11,323,785; Delays in accessing pay roll and pension payroll; payment of salaries worth UGX.14,222,733 to Nine (9) staffs who were off IPPS; \uf0b7 I noted that the entity had not prepared and approved its strategic plan by NPA and thus could not confirm if the plan is aligned to NDP 111 \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under performance of revenues worth UGX.867,111,016 and under absorption of funds worth UGX.675,040,597 that was swept back to consolidated fund account at the year end. \uf0b7 Mischarged funds worth UGX.357,586,292 on inappropriate budget codes", null, null], ["03.", "Kyotera DLG", "\uf0b7 I noted a number of anomalies during review of Kyotera district"], ["", "", "payroll such as; Failure to submit wage estimates to MoPs;"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 360, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["leaders\u2019 gratuity worth UGX.51,416,102, leading to an under deduction worth UGX UGX.11,323,785; Delays in accessing pay roll and pension payroll; payment of salaries worth UGX.14,222,733 to Nine (9) staffs who were off IPPS; \uf0b7 I noted that the entity had not prepared and approved its strategic plan by NPA and thus could not confirm if the plan is aligned to NDP 111 \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under performance of revenues worth UGX.867,111,016 and under absorption of funds worth UGX.675,040,597 that was swept back to consolidated fund account at the year end. \uf0b7 Mischarged funds worth UGX.357,586,292 on inappropriate budget codes", null, null], ["03.", "Kyotera DLG", "\uf0b7 I noted a number of anomalies during review of Kyotera district"], ["", "", "payroll such as; Failure to submit wage estimates to MoPs;"], [null, "Opinion Unqualified", "unabsorbed wage fund balance of UGX. 0.32 billion; Over"], [null, null, "payment of salaries worth UGX.29, 467,392; Unauthorized loan"], [null, "", "deductions worth UGX.148 million from 100 employees with no"], [null, null, "undertaking letters; un-deducted PAYE from political leaders\u2019"], [null, null, "gratuity worth UGX 57,855,806, leading to an under deduction"], [null, null, "worth UGX.13, 730,838."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there were delays in accessing"], [null, null, "salary and pension payroll; Failed to prepare monthly wage,"], [null, null, "pension and gratuity performance analysis for submission to"], [null, null, "MoPS and Payment of salaries worth UGX.7, 166,620 to Three"], [null, null, "(3) staffs who were off the IPPS."], [null, null, ""], [null, null, "\uf0b7 The district mischarged UGX.4, 876,514 on inappropriate budget"], [null, null, "codes other than those budget for"], [null, null, ""], [null, null, "\uf0b7 I noted that the district had prepared a draft strategic plan"], [null, null, "pending approval by NPA at the time of audit;"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to quantify outputs; partial and"], [null, null, "non-implementation of planned activities delayed submission of"], [null, null, "performance reports; delay commencement of work by"], [null, null, "contractor under the UGIFT program; under performance of"], [null, null, "revenues worth UGX.725,450,031 and under absorption of"], [null, null, "UGX.993, 780,260"], [null, null, ""], [null, null, "\uf0b7 Received off budget financing worth UGX.319,540,631 from"], [null, null, "Ministry of Health (MOH)"], [null, null, ""], [null, null, "\uf0b7 Not secured ownership of the land where the seed school and"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 360, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "348", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 360, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "health Center are being constructed"], [null, null, ""], ["04\\. Lwengo DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district payroll such as; Delay to submit wage estimates to MoPs; An unabsorbed wage funds worth UGX.1.5 billion; an under payment of salaries worth UGX 8,075,359; Accrued Pensions worth UGX.90,656,783 not yet paid; Over payment of gratuity worth UGX. 11,742,937 and under payment of gratuity amounting to UGX. 15,885,858; Payment of salaries worth UGX. 8,620,432 to Eighteen (18) staffs who had retired. \uf0b7 Additionally, I noted unauthorized loan deduction worth UGX.8 million to International Medical Link (IML); un-deducted PAYE from political leaders\u2019 gratuity worth UGX.87,948,356, leading to an under deduction worth UGX.12,070,409; Delays in accessing pay roll and pension payroll. \uf0b7 I noted that the entity had prepared a strategic plan which had not yet been approved by NPA in respect to alignment to the NDP-III; \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under performance of revenues worth UGX. UGX.541,868,161 and under absorption of UGX.1,952,031,565 \uf0b7 Received off budget financing worth UGX.223,549,580 from Ministry of Health without informing the PSST", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 361, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", null, "health Center are being constructed"], [null, null, ""], ["04\\. Lwengo DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district payroll such as; Delay to submit wage estimates to MoPs; An unabsorbed wage funds worth UGX.1.5 billion; an under payment of salaries worth UGX 8,075,359; Accrued Pensions worth UGX.90,656,783 not yet paid; Over payment of gratuity worth UGX. 11,742,937 and under payment of gratuity amounting to UGX. 15,885,858; Payment of salaries worth UGX. 8,620,432 to Eighteen (18) staffs who had retired. \uf0b7 Additionally, I noted unauthorized loan deduction worth UGX.8 million to International Medical Link (IML); un-deducted PAYE from political leaders\u2019 gratuity worth UGX.87,948,356, leading to an under deduction worth UGX.12,070,409; Delays in accessing pay roll and pension payroll. \uf0b7 I noted that the entity had prepared a strategic plan which had not yet been approved by NPA in respect to alignment to the NDP-III; \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs; partial and non-implementation of planned activities delayed submission of performance reports; under performance of revenues worth UGX. UGX.541,868,161 and under absorption of UGX.1,952,031,565 \uf0b7 Received off budget financing worth UGX.223,549,580 from Ministry of Health without informing the PSST", null, null], ["05.", "Masaka", "\uf0b7 I noted that Masaka District submitted wage estimates to MoPs"], ["", "DLG", "on 30th March 2020, which was a delay of 182 days; an"], [null, "", "unabsorbed balance of UGX 0.85 billion; under payment of UGX"], [null, "Opinion Unqualified", "of salaries worth 58,950,820; under payment pension worth UGX"], [null, null, "198,728,097 and unpaid pension of UGX 53,041,554; The District"], [null, null, "wrongly computed the gratuity benefit of 21"], [null, null, "pensioner/beneficiary leading to over payment of UGX 1,431,442"], [null, null, "and under payment of UGX 37,726,688; UGX. 82,631,676 was"], [null, null, "paid to 38 staff who had retired, transferred, absconded or died;"], [null, null, "an over and under remittance amounting to UGX. 14,013,953"], [null, null, "and UGX. 12,619,869 of payroll deduction."], [null, null, ""], [null, null, "\uf0b7 Additionally, the District made payroll loan deductions of UGX.1,"], [null, null, "064,546,679, but did not remit UGX.10, 874,315 to UCLA/UBA;"], [null, null, "under deduction of PAYE worth UGX. 8,988,018 from payments"], [null, null, "to political leaders; noted that 30 newly recruited/ transferred"], [null, null, "employees and 41 pensioners delayed to access payroll; I noted"], [null, null, "that 24 employees were paid a total of UGX. 263,080,952"], [null, null, "without signed pay change reports; 07 staffs and 19 pensioners"], [null, null, "were paid a total of UGX.20, 688,721 and UGX.85, 258,552"], [null, null, "respectively off the IPPS."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 361, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "349", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 361, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 The district mischarged funds worth UGX. 15,255,772 on account"], [null, null, "codes other than those prescribed for either salary, pension or"], [null, null, "gratuity"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 362, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", null, "\uf0b7 The district mischarged funds worth UGX. 15,255,772 on account"], [null, null, "codes other than those prescribed for either salary, pension or"], [null, null, "gratuity"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had had not prepared and approved the"], [null, null, "strategic plan at the time of audit;"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to quantify outputs; partial and"], [null, null, "non-implementation of planned activities delayed submission of"], [null, null, "performance reports; under performance of revenues worth UGX."], [null, null, "11,296,979,720 and under absorption of UGX. 1,258,107,623;"], [null, null, "Incomplete works at Bukakata seed Secondary School"], [null, null, ""], ["06\\. Sembabule DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; an unabsorbed balance of UGX.0.73billion; an under payment of salaries worth UGX.9, 696,016; Delays in accessing pension payroll; Failure to prepare monthly wage, pension and gratuity performance analysis; 72 staffs and 14 pensioners were paid a total of UGX.76,444,546 off the IPPS. \uf0b7 I noted that the management had prepared a strategic plan which had not yet been approved by NPA to confirm its alignment with NDP-III; \uf0b7 underperformance 275,905,089; under absorption of funds worth UGX.1,229,179,117; Partial Implantation of One (1) output with a total of two (2) activities worth UGX.0.89Bn; Late submission of performance reports; \uf0b7 I noted underfunding from URF for road maintenance worth UGX.27,517,358 that affected implementation of planned activities", null, null], ["07.", "Lyantonde DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, Underpayment of pension worth"], [null, "Unqualified", "UGX.27,094,530; Overpayment of Salary worth UGX.29,716,471;"], [null, "", "an unabsorbed balance of UGX.0.26 billion that was subsequently"], [null, null, "swept back to the consolidated fund account and wrong"], [null, null, "computation of gratuity benefit for four (04) pensioner worth net"], [null, null, "overpayment of UGX.4,437,740"], [null, null, ""], [null, null, "\uf0b7 Further, the district made payment of salaries worth"], [null, null, "UGX.3,279,528 to four (4) staffs that who had either retired,"], [null, null, "transferred, absconded or died; an over and over remittance of"], [null, null, "payroll deductions worth UGX.6,685,000 and UGX.8,713,886"], [null, null, "respectively; made unauthorized loan deductions worth"], [null, null, "UGX.736,802,204 from 400 employees that never had letters of"], [null, null, "undertaking"], [null, null, ""], [null, null, "\uf0b7 Additionally, Tax deductions worth UGX.7,073,772 had not been"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 362, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "350", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 362, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "remitted to URA; un-deducted PAYE from political leaders\u2019"], [null, "gratuity resulting in unpaid tax of A UGX.8,109,728; Twenty-"], [null, "Seven (27) employees recruited did not access the payroll and"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 363, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", "remitted to URA; un-deducted PAYE from political leaders\u2019"], [null, "gratuity resulting in unpaid tax of A UGX.8,109,728; Twenty-"], [null, "Seven (27) employees recruited did not access the payroll and"], [null, "delays in accessing payroll and pension payroll."], [null, ""], [null, "\uf0b7 The district mischarged funds worth UGX.5,870,000 on account"], [null, "code other than those prescribed salary, pension and gratuity;"], [null, ""], [null, "\uf0b7 The District paid Seventeen (17) employees worth UGX.22,"], [null, "846,471 without signed pay change reports; failed to prepare"], [null, "monthly wage, pension and gratuity performance analysis and"], [null, "salaries payment worth UGX.85, 678,850 was paid to Seven (7)"], [null, "staffs off the IPPS."], [null, ""], [null, "\uf0b7 I noted that the entity had prepared its strategic plan but it was"], [null, "not yet approved by NPA"], [null, ""], [null, "\uf0b7 Under performance worth; under absorption worth; Late"], [null, "submission of Reports;"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; Failure to quantify outputs; partial and"], [null, "non-implementation of planned activities delayed submission of"], [null, "performance reports; under performance of revenues worth UGX."], [null, "68,650,450 and under absorption of UGX.773,177,804"], [null, ""], ["08\\. Kassanda DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, an unabsorbed balance of UGX.0.20 billion; unpaid accrued pensions worth UGX.89,374,764;Payment of salaries worth UGX.29,042,083 to Eighteen (18) staffs who had either retired, transferred, absconded or died; an over and under remittance of deductions worth UGX.80,614,103 and UGX.11,056,051 respectively; made unauthorized loan deductions worth UGX.684,121,646 from 271 employees that neither had letters of undertaking nor letters of consent. \uf0b7 Additionally, I observed a deduction of worth UGX.31,937,764 from 26 employees who were not in approval and deduction report and a deductions of UGX.63,539,341 from 51 employees who were not in active deduction report but were in approval report; 15 employees had irregular loan end dates; Delays in accessing payroll and pension payroll; Payment of Sixteen (16) staffs and Six (06) pensioners worth UGX.205,954,862 off the IPPS; and payments worth UGX.47,984,473 off the payroll to 33 employees. \uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit; \uf0b7 I noted a number issues in the budget performance such as", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 363, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "351", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 363, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Underperformance of funds worth UGX.243,523,703; Under absorption of funds worth UGX.744,143,791; Failure to quantify outputs; partial and non-implementation and late submission of performance reports.", null, null], ["09.", "Mubende DLG", "\uf0b7 I noted that the District delayed to submit wage estimates to"], ["", "", "MoPs; An under absorption worth UGX.1.36 Billion and was"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 364, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["Underperformance of funds worth UGX.243,523,703; Under absorption of funds worth UGX.744,143,791; Failure to quantify outputs; partial and non-implementation and late submission of performance reports.", null, null], ["09.", "Mubende DLG", "\uf0b7 I noted that the District delayed to submit wage estimates to"], ["", "", "MoPs; An under absorption worth UGX.1.36 Billion and was"], [null, "Opinion", "subsequently swept back to the consolidated fund account;"], [null, "Unqualified", "unpaid salaries worth UGX.9,974,064; Over payment of one (1)"], [null, "", "pensioner worth UGX.2,420,407; Unpaid salaries & pension worth"], [null, null, "UGX.163,350,521; Under payments worth UGX.765,835 to"], [null, null, "Twenty (20) staffs using wrong salary scale; Payment of salaries"], [null, null, "worth UGX.17,448,575 to Fourteen (14) staffs who had either"], [null, null, "retired, transferred, absconded or died;"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed an under remittance of salary deduction"], [null, null, "worth UGX.246,546,709; Made unauthorized loan deductions"], [null, null, "worth UGX.123,209,904 from 30 employees that neither had"], [null, null, "letters of undertaking nor evidence of consent; Delays in"], [null, null, "accessing payroll and pension payroll; Residual Arrear payments"], [null, null, "worth UGX.380,760,596 paid to 17 staffs who were not part of"], [null, null, "MOFPED approved schedule; Unpaid pension to Six (6)"], [null, null, "pensioners worth UGX.118,064,322; Failed to prepare monthly"], [null, null, "wage, pension and gratuity performance analysis for submission"], [null, null, "to MoPS; Payment of Five (5) staffs worth UGX.4,831,538 off the"], [null, null, "IPPS;"], [null, null, ""], [null, null, "\uf0b7 I noted that the district had prepared its strategic plan but had"], [null, null, "not had its plan approved by NPA at the time of audit;"], [null, null, ""], [null, null, "\uf0b7 I noted a number issues in the budget performance such as"], [null, null, "Underperformance of funds worth UGX.117,978,419; Under"], [null, null, "absorption of funds worth UGX.1,625,514,838; Failure to quantify"], [null, null, "outputs; partial and non-implementation and late submission of"], [null, null, "performance reports."], ["10. Gomba Opinion Unqualified \uf0b7 I noted that the District delayed to submit wage estimates to MoPS; an unabsorbed balance of UGX.0.8 billion; over payment of UGX.649, 200 to Mujabi James; an under payment of UGX.1, 764,651; Unpaid salaries worth UGX.1, 176,393; noted that the District had an outstanding Accrual worth UGX.17, 271,309 at the end of the year; the District made unauthorized loan deductions worth UGX.7, 592,724 from 4 employees that neither had letters of undertaking nor existed in the reports. \uf0b7 Additionally, I observed delays in accessing payroll and pension payroll; I noted that five (05) ineligible persons accessed the payroll using forged Education Service Commission (ESC) minutes; Twenty Seven (27) staffs were paid worth UGX.31, 972,130 off the IPPS. \uf0b7 I noted that the entity had not had the strategic plan approved at the time of audit \uf0b7 I noted a number of issues in the implementation of budget such", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 364, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "352", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 364, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["as; Underperformance worth UGX.113,179,395; under absorption of funds worth UGX.1,088,912,187 that was subsequently swept back to the consolidated fund account; Late submission of reports.", null, null], ["", "Hoima Branch", "Summary of Key Findings"], ["01 Buliisa DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salary worth UGX.516,940 to one (1) employee; payment of salaries worth UGX.962,591 to two (2) staffs that was no longer in service; unauthorized loan deductions worth UGX.19,720,463 from 20 employees and net under payment of payroll deductions worth UGX.218,852,589 \uf0b7 Additionally, I observed that there was delayed access to payroll by twelve (12) new employees and three (3) pensioners; failure to utilize wage funds of UGX.1.39Bn; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.8,971,020 and payment of worth UGX.1,646,800 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs that affected measurement of performance, partial or non- implementation of planned activities, late submission of quarterly reports; under absorption of funds worth UGX.721,028,206 that was swept back to consolidated fund account; under performance of the donor & releases from the government worth UGX.1,359,130,302 \uf0b7 I noted that the district had prepared and submitted the Strategic plan to NPA but was still pending approval. \uf0b7 In regards to Covid-19 funds, I noted that out of the total receipts of UGX.81, 933,334, the district absorbed UGX.81, 933,334, representing absorption level of 100%. Additionally, I noted that the distribution of many of non-cash items delayed.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 365, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["as; Underperformance worth UGX.113,179,395; under absorption of funds worth UGX.1,088,912,187 that was subsequently swept back to the consolidated fund account; Late submission of reports.", null, null], ["", "Hoima Branch", "Summary of Key Findings"], ["01 Buliisa DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salary worth UGX.516,940 to one (1) employee; payment of salaries worth UGX.962,591 to two (2) staffs that was no longer in service; unauthorized loan deductions worth UGX.19,720,463 from 20 employees and net under payment of payroll deductions worth UGX.218,852,589 \uf0b7 Additionally, I observed that there was delayed access to payroll by twelve (12) new employees and three (3) pensioners; failure to utilize wage funds of UGX.1.39Bn; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.8,971,020 and payment of worth UGX.1,646,800 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify outputs that affected measurement of performance, partial or non- implementation of planned activities, late submission of quarterly reports; under absorption of funds worth UGX.721,028,206 that was swept back to consolidated fund account; under performance of the donor & releases from the government worth UGX.1,359,130,302 \uf0b7 I noted that the district had prepared and submitted the Strategic plan to NPA but was still pending approval. \uf0b7 In regards to Covid-19 funds, I noted that out of the total receipts of UGX.81, 933,334, the district absorbed UGX.81, 933,334, representing absorption level of 100%. Additionally, I noted that the distribution of many of non-cash items delayed.", null, null], ["02.", "Hoima MC", "\uf0b7 I noted a number of anomalies during review of the Municipal"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs, Over payment of salary worth UGX"], [null, null, "UGX.7,453,884 to (3) staffs; under payment of funds worth"], [null, "", "UGX.29,604,189 and unauthorized loan deductions worth"], [null, null, "UGX.37,990,205 from 35 employees"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to"], [null, null, "payroll by seven (7) new employees and ten (10) pensioners;"], [null, null, "failure to utilize wage funds of UGX.0.28Bn; un-deducted PAYE"], [null, null, "from political leaders\u2019 gratuity resulting in unpaid tax of"], [null, null, "UGX.12,771,000 and payment of two (2) staffs & seven(7)"], [null, null, "pensioners a total of UGX.368,827,383 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 365, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "353", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 365, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "approved budget such as; Failure to quantify outputs that"], [null, "affected measurement of performance, partial or non-"], [null, "implementation of planned activities; Incomplete road works"], [null, "under absorption of funds worth UGX.29,660,979,614 that was"], [null, "swept back to consolidated fund account; under performance"], [null, "of the donor & releases from the government worth"], [null, "UGX.2,515,468,499"], [null, ""], [null, "\uf0b7 The district mischarged expenditure worth UGX.45, 235,346 on"], [null, "wrong budget lines."], [null, ""], [null, "\uf0b7 I noted that UGX.5,060,453 was paid as residual salary arrears"], [null, "to 5 employees who had not missed salaries in the previous"], [null, "financial year(s)"], [null, ""], [null, "\uf0b7 Payment of funds worth UGX.33,792,884 without authorization"], [null, "of the pay change reports"], [null, ""], [null, "\uf0b7 I noted that the entity\u2019s strategic plan was still in draft form"], [null, "and not approved to confirm that is aligned to the NDP-III at"], [null, "the time of audit."], [null, ""], [null, "\uf0b7 UGX.19,240,000 remained unaccounted for at the close of the"], [null, "financial year"], [null, ""], ["03\\. Hoima DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, over payment of salary worth UGX. 1,380,792 to staffs; under payment of funds worth UGX.; payment of salaries worth UGX.27,668,323 were paid to twenty (20) staffs and eleven (11) pensioners were paid a total of UGX.251,898,925 off the IPPS that was no longer in service unauthorized loan deductions worth UGX.721,600,940 from 432 employees \uf0b7 Additionally, I observed that there was delayed access to payroll by ten (10) new employees and eleven (11) pensioners; failure to utilize wage funds of UGX 16.16Bn; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.7,763,400 \uf0b7 The district mischarged expenditure worth UGX.180, 754,659 on wrong budget lines. \uf0b7 I noted that the verification forms and copies of the verification cards for 126 employees and 43 pensioners were not on the respective personal files \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial implementation of planned activities; partially implemented ; late submission of quarterly reports; under absorption of funds worth UGX.1.9Bn that was", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 366, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "354", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 366, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["swept back to consolidated fund account; \uf0b7 Delayed submission of regular reports \uf0b7 I noted that the Hoima district did not have an approved strategic plan that is aligned to NDP-III and therefore lacks a certificate of compliance issued by National Planning Authority. \uf0b7 Regarding Covid-19 funds, Out of the total receipts of UGX.111, 450,000, the District absorbed UGX.111, 450,000 representing an absorption level of 100%.", null, null], ["04.", "Hoima RRH", "\uf0b7 I noted a number of anomalies during review of the hospital"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 367, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["swept back to consolidated fund account; \uf0b7 Delayed submission of regular reports \uf0b7 I noted that the Hoima district did not have an approved strategic plan that is aligned to NDP-III and therefore lacks a certificate of compliance issued by National Planning Authority. \uf0b7 Regarding Covid-19 funds, Out of the total receipts of UGX.111, 450,000, the District absorbed UGX.111, 450,000 representing an absorption level of 100%.", null, null], ["04.", "Hoima RRH", "\uf0b7 I noted a number of anomalies during review of the hospital"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates by the hospital to MoPs, over payment of pension"], [null, null, "worth UGX.3, 138,332. ; Underpayment of worth 2,282,632; The"], [null, "", "deductions were from nine (9) employees\u2019 salaries worth"], [null, null, "UGX18,438,987"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by twenty (20) new employees and four (4) pensioners;;un paid"], [null, null, "pensioners worth UGX 13372393.un-deducted PAYE from political"], [null, null, "leaders\u2019 gratuity resulting in unpaid tax of UGX.13372393 Failure"], [null, null, "to quantify outputs,"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; failure to quantify outputs, partial"], [null, null, "implementation or non-implementation of planned activities"], [null, null, "under absorption of funds worth UGX.1.78Bn that was swept"], [null, null, "back to consolidated fund account; under performance of the"], [null, null, "donor & releases from other government units worth"], [null, null, "UGX.0.03Bn; delayed submission of quarterly monitoring reports"], [null, null, "to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 The hospital mischarged expenditure worth UGX.38 million on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and"], [null, null, "not approved to confirm that is aligned to the NDP-III at the time"], [null, null, "of audit."], [null, null, ""], [null, null, "\uf0b7 Failure to quantify outputs, partial implementation or non-"], [null, null, "implementation of planned activities"], ["05\\. Kagadi DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Wrong computation of gratuity worth net overpayment of UGX. 1,8273,030; payment of salaries to three(3) staffs that was no longer in service and under remittance worth UGX. 35,519,020; and payment of two (2) staffs worth UGX. 3450720 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; unabsorbed balance worth UGX 1.5Bn partial implementation of funds worth UGX 0.155Bn under", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 367, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "355", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 367, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["absorption of funds worth UGX. 12,314,490,181 that was swept back to consolidated fund account; under performance of the donor & releases from other government units 3,329,413,255; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and not approved to confirm that is aligned to the NDP-III at the time of audit. \uf0b7 I noted a delay of 9 days for the month of July in the remittance of PAYE deductions to URA", null, null], ["06.", "Kakumiro DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 368, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["absorption of funds worth UGX. 12,314,490,181 that was swept back to consolidated fund account; under performance of the donor & releases from other government units 3,329,413,255; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and not approved to confirm that is aligned to the NDP-III at the time of audit. \uf0b7 I noted a delay of 9 days for the month of July in the remittance of PAYE deductions to URA", null, null], ["06.", "Kakumiro DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs; Underpayment of salaries worth UGX."], [null, null, "10,643,039 to employees underpayment pension worth UGX.4,"], [null, "", "511,350; under remittance worth UGX.146, 308,447 and"], [null, null, "payment of three (3) staffs worth UGX.8,763,215 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; unspent balance worth UGX"], [null, null, "2275637090 ; under absorption of funds worth"], [null, null, "UGX.9,191,378,616 that was swept back to consolidated fund"], [null, null, "account; partial or non-implementation of planned activities"], [null, null, "worth 0.37Bn under performance of the donor & releases from"], [null, null, "other government units worth UGX.0.4Bn; delayed submission of"], [null, null, "quarterly monitoring reports to OPM & MoFPED unabsorbed"], [null, null, "funds worth UGX.138,823,634; delayed completion of"], [null, null, "construction works at St Matia Mulumba seed secondary school."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and"], [null, null, "not approved to confirm that is aligned to the NDP-III at the time"], [null, null, "of audit."], [null, null, ""], [null, null, "\uf0b7 I noted that the District did not remit PAYE deductions for the"], [null, null, "month of May worth UGX.138, 823,634 to URA."], [null, null, ""], [null, null, "\uf0b7 I noted that the district had ongoing service delivery"], [null, null, ""], ["07 Kibaale DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of pension worth UGX.288, 866,531; Underpayment of pension worth UGX.4,082,68 underpayment of pensioners UGX.387,086,804; payment of salaries worth UGX.20,837,768 to fifteen (15) staffs that was no longer in service \uf0b7 I noted a number of issues in the implementation of the approved budget such as unspent balance worth UGX.1,861,400,617; underperformance of budgets worth UGX.14,350,250,339; delayed submission of quarterly monitoring reports to OPM & MoFPED; delayed completion of construction works at Nyamarwa Seed School secondary school;", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 368, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "356", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 368, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["under deduction of PAYE to URA worth 20,837,768 \uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and not approved to confirm that is aligned to the NDP-III at the time of audit. \uf0b7 I noted a number of issues in the implementation of the approved budget such as unspent balance worthUGX.1;861;400,617;unabsorbed funds worth UG.1.35 billion; delayed completion of construction works at Nyamarwa Seed School secondary school; under deduction of PAYE to URA worth 20,837,768 \uf0b7 I noted that funds amounting to UGX.24, 910,982 related to gratuity expense but were charged on pension arrears code. \uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification interface and noted in- adequate sensitization and training in the use and navigation of the system, System was not reliable and effective and operational challenges were encountered; such as delayed update of changes in employee details by NIRA, NID interface does not show facial images for some employees and network challenges.", null, null], ["08", "Kikuube DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 369, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["under deduction of PAYE to URA worth 20,837,768 \uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and not approved to confirm that is aligned to the NDP-III at the time of audit. \uf0b7 I noted a number of issues in the implementation of the approved budget such as unspent balance worthUGX.1;861;400,617;unabsorbed funds worth UG.1.35 billion; delayed completion of construction works at Nyamarwa Seed School secondary school; under deduction of PAYE to URA worth 20,837,768 \uf0b7 I noted that funds amounting to UGX.24, 910,982 related to gratuity expense but were charged on pension arrears code. \uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification interface and noted in- adequate sensitization and training in the use and navigation of the system, System was not reliable and effective and operational challenges were encountered; such as delayed update of changes in employee details by NIRA, NID interface does not show facial images for some employees and network challenges.", null, null], ["08", "Kikuube DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs, Over payment of salaries worth"], [null, null, "UGX.4,919,860; Salaries worth UGX. 5,747,552 to six (6) staffs"], [null, "", "that was no longer in service and payment of twenty two (22)"], [null, null, "staffs worth UGX.198,611,180 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; under absorption of funds; under"], [null, null, "performance of the donor & releases from other government"], [null, null, "units worth UGX.9.19Bn; partial implementation of funds worth"], [null, null, "UGX. o.95 delayed submission of quarterly monitoring reports to"], [null, null, "OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted that whereas UGX.756,788,804 was deducted from"], [null, null, "employees\u2019 salaries to be remitted to different beneficiaries,"], [null, null, "UGX.758,906,480 was remitted leading to an over and under"], [null, null, "remittance of UGX.2,117,676"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity\u2019s strategic plan was still in draft form and"], [null, null, "not approved to confirm that is aligned to the NDP-III at the time"], [null, null, "of audit."], [null, null, "\uf0b7 Payments to ten (10) employees worth 1457195 without signed a"], [null, null, "pay change report"], [null, null, ""], [null, null, "\uf0b7 I noted that UGX.68, 527,000 remained unaccounted for at the"], [null, null, "close of the financial year."], [null, null, ""], [null, null, "\uf0b7 I noted delayed completion of Nyairongo Seed Secondary School"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 369, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "357", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 369, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, ""], [null, null, "\uf0b7 Under Development Response to Displacement Impacts Project"], [null, null, "(DRDIP), I noted that Procurements worth UGX.2,524,177,097"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 370, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", null, ""], [null, null, "\uf0b7 Under Development Response to Displacement Impacts Project"], [null, null, "(DRDIP), I noted that Procurements worth UGX.2,524,177,097"], [null, null, "were undertaken using community procurement method which"], [null, null, "were not reported in quarterly reports submitted to the Authority."], [null, null, "Besides, they were not included in the approved integrated"], [null, null, "annual work plan of the District."], [null, null, ""], ["09 Kyankwanzi Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Underpayment of pension worth UGX.2,819,483 and payment of eight (8) staffs worth UGX.8,810,706 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; failure to quantify outputs, partial and non-implementation of planned activities; unabsorbed wage fund balance worth UGX.0.84Bn; under deduction of PAYE worth UGX.8, 593, 471; unabsorbed balance worth UGX. 69,083,003; under absorption of funds worth UGX.198,251,670 that was swept back to consolidated fund account; under performance under performance worth UGX 1.11Bn. \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines. \uf0b7 The district mischarged expenditure worth UGX.50, 174,102 on wrong budget lines. \uf0b7 I noted outstanding pensioners arrears worth UGX.40,454,541 \uf0b7 I noted that the entity did not prepare monthly wage, pension and gratuity performance analysis and did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted that the entity had prepared and approved the strategic plan but it was not certified by National Planning Authority.", null, null], ["10.", "Masindi DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs, Over and under payment of salaries;"], [null, null, "Overpayment of pension worth UG.37, 427,367 and under"], [null, "", "payment of pension worth UGX.870,105,650; payment of"], [null, null, "salaries to nine (9) staffs but were no longer in service."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; unabsorbed balance worth"], [null, null, "1,240,110,296; under performance of the donor & releases from"], [null, null, "other government units worth UGX.164Bn that was swept back"], [null, null, "to consolidated fund account; partial and non-implementation of"], [null, null, "planned activities; delayed submission of quarterly monitoring"], [null, null, "reports to OPM & MoFPED and payment of worth 208,659,885"], [null, null, "eleven staff(11) off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted that whereas UGX.3,312,092,285 was deducted from"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 370, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "358", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 370, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "employees\u2019 salaries to be remitted to different beneficiaries, only"], [null, null, "UGX.3,309,501,072 was remitted leading to a variance"], [null, null, "amounting to UGX.19,992,521."]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 371, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", null, "employees\u2019 salaries to be remitted to different beneficiaries, only"], [null, null, "UGX.3,309,501,072 was remitted leading to a variance"], [null, null, "amounting to UGX.19,992,521."], [null, null, ""], [null, null, "\uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2"], [null, null, "months the months"], [null, null, ""], [null, null, "\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID"], [null, null, "staff/pensioner/beneficiaries\u2019 verification interface and noted in-"], [null, null, "adequate sensitization and training in the use and navigation of"], [null, null, "the system, system was not reliable and effective and operational"], [null, null, "challenges were encountered; such as delays to capture changes"], [null, null, "on NIRA by IPPS."], [null, null, ""], [null, null, "\uf0b7 I noted that the District prepared a work plan to guide the"], [null, null, "utilization of funds that were received."], [null, null, ""], ["11\\. Masindi MC Opinion Qualified \uf0b7 I noted a number of anomalies during review of the municipal pension & salary payrolls such as; Failure to submit wage estimates to MoPs; over and underpayment of salaries worth UGX.33,863,477 to seventeen (17) staffs that was no longer in service and irregular deduction of loan instalments worth UGX.9, 061,174; under deduction of PAYE amounting to 11,411,400 and 19 staff and 13 pensioners were paid a total of UGX.315,332,447 off IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX.1, 362,275,792 that was swept back to consolidated fund account; partial or non-implementation of planned activities; under performance of the donor & releases from other government units worth UGX. 282,855,823; delayed submission of quarterly monitoring reports to OPM & MoFPED; \uf0b7 I noted that the entity had prepared and approved the strategic plan but it was not certified by National Planning Authority. \uf0b7 I noted that whereas UGX.1,427,190,853 was deducted from employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,149,993,408 was remitted leading to an under remittance amounting to UGX.280,237,640 and over remittance of UGX.3,040,195 \uf0b7 I noted that funds amounting to UGX.195,443,591 in relation to pension and gratuity were charged on wrong account codes \uf0b7 I noted that 73 employees were paid a total of UGX.UGX.61, 299,481 without signed pay change reports.", null, null], ["12.", "Kiboga DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, over payment of salaries worth UGX3,"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 371, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "359", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 371, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Unqualified", "632,888; Underpayment of salaries worth UGX.6,345,609;"], [null, "", "overpayment of pension UGX.1, 338,228 and under payment of"], [null, null, "pension of UGX.3, 404,504; salaries worth UGX. 3,051,636 to"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 372, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", "Unqualified", "632,888; Underpayment of salaries worth UGX.6,345,609;"], [null, "", "overpayment of pension UGX.1, 338,228 and under payment of"], [null, null, "pension of UGX.3, 404,504; salaries worth UGX. 3,051,636 to"], [null, null, "two (2) staffs that was no longer in service"], [null, null, ""], [null, null, "\uf0b7 I further noted under deduction of PAYE of UGX.5,724,180 to"], [null, null, "URA and two pensioners were paid a total of UGX.69,008,452 off"], [null, null, "the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; unabsorbed wage fund of"], [null, null, "UGX.0.41Bn; under performance of the donor & releases from"], [null, null, "other government units worth UGX.1,037,635,628; failure to"], [null, null, "quantify outputs, partial and non-implementation of planned"], [null, null, "activities; under absorption of government grants and Non"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had prepared and approved the strategic"], [null, null, "plan but it was not certified by National Planning Authority."], [null, null, ""], [null, null, "\uf0b7 I noted that funds amounting to UGX.40, 000,000 in relation to"], [null, null, "COVID funds returned by the area Members of Parliament had"], [null, null, "properly been accounted for."], [null, null, ""], [null, null, "\uf0b7 I noted that different departments at Kiboga district Hospital"], [null, null, "lacked the required personal protective gear to aid staff execute"], [null, null, "their duties during the pandemic"], ["13\\. Kiryandongo DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of pension salaries worth UGX.1,935,272; overpayment of pension UGX.1,423,052 and under payments of pension UGX.3,591,459; payment of salaries worth UGX. 7,153,511 three (3) staffs that was no longer in service and irregular deduction of loan worth UGX.45, 559,753. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; un absorbed balance wage funds worth UGX 0.28Bn; un quantified outputs; under absorption of funds worth UGX.2,939,664,455 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.4,624,951,481; staff payment worth 4,070,605 off the IPPS ;partial and non-implementation of planned activities delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the entity had prepared and approved the strategic plan but it was not certified by National Planning Authority. \uf0b7 Deduction Management System, operated by PCA-Payroll Consults Africa. \uf0b7 I noted that 23 employees were paid a total of UGX.46,112,214 without signed pay change reports", null, null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 372, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "360", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 372, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted lack of evidence of formal appointment for the contract committee members of the district", null, null], ["", "Gulu Branch", "Summary of Key Findings"], ["01 Agago DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, over payment of salaries worth UGX. 25,241,289; Underpayment of salaries worth UGX. 164,307,857; Underpayment of pension worth UGX 93,335,963; payment of salaries worth UGX. 28,901,916 to seventeen(17) staffs that was no longer in service \uf0b7 Additionally, I observed that there was delayed access to payroll by five (05) new employees and sixteen (16) pensioners; failure to utilize wage funds of UGX.0.3Bn; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 13,352,540 and payment of twenty two (22) staffs worth of UGX 642,221,799 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; under absorption of funds worth UGX. 484,346,069 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.1.994Bn. \uf0b7 I noted that UGX.13.7 million was paid as residual salary arrears to eleven (11) employees who had not missed salaries in the previous financial year(s). \uf0b7 I noted that the verification forms and copies of the verification cards for 04 employees and 16 pensioners/beneficiaries were not on the respective personal files \uf0b7 The district had outstanding unrecovered receivables of UGX. 1,376,134,925 at year end. \uf0b7 I noted that the entity had not prepared a strategic plan at the time of audit. \uf0b7 I noted that Agago District received off-budget financing to a tune of UGX. 90.5 million. \uf0b7 I noted that funds to the tune of UGX .237,168,404 were irregularly diverted from the activities", null, null], ["02", "Alebtong DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs, Over payment of salaries worth"], [null, null, "UGX.20,617,118; Underpayment of salaries worth"], [null, "", "UGX.21,081,264, payment of salaries worth UGX. 26,612,830 to"], [null, null, "twenty(20) staffs that was no longer in service"], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 373, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "Opinion", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "361", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 373, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, "by thirty three (33) new employees and twenty three(23)"], [null, "pensioners; failure to utilize wage funds of UGX.0.8Bn; un-"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 374, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": [["", "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, "by thirty three (33) new employees and twenty three(23)"], [null, "pensioners; failure to utilize wage funds of UGX.0.8Bn; un-"], [null, "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid"], [null, "tax of UGX. 9,060,528"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as;;"], [null, "Partial implementation, late submission of quarterly reports;"], [null, "Under absorption of UGX.1,493,165,616 that was swept back to"], [null, "consolidated fund account; under performance of the donor &"], [null, "releases from other government units worth UGX.1.994Bn"], [null, ""], [null, "\uf0b7 The district mischarged UGX. 198, 594,102 charged on account"], [null, "codes other than those prescribed for either salary, pension or"], [null, "gratuity."], [null, ""], [null, "\uf0b7 I noted that the district paid unverified residual arrears worth"], [null, "UGX. 119,498,458 to 12 pensioners"], [null, "\uf0b7 I noted that the District had outstanding receivables amounting"], [null, "to UGX.2,175,996,458 arising from Contractor\u2019s Prepayment YLP"], [null, "& UWEP"], [null, ""], [null, "\uf0b7 I noted that the district had outstanding payables of"], [null, "UGX.1,732,017,300 (Deposits received UGX.1,689,530,652,"], [null, "Sundry creditors of UGX.25,650,000 and Pension liabilities"], [null, "UGX.16,836,648) amounted to UGX. 3,464,034,600."], [null, ""], [null, "\uf0b7 I noted that the entity had prepared a strategic plan but the"], [null, "National Planning Authority had not yet approved it at the time of"], [null, "audit."], [null, ""], [null, "\uf0b7 I noted that UGX.580, 701,955 was charged on items which did"], [null, "not reflect the nature of the expenditure."], [null, ""], [null, "\uf0b7 I noted during the review of expenditure that the district received"], [null, "UGX.183,961,496 to be transferred to schools for printing"], [null, "materials. These funds were never transferred to the schools."], [null, ""], [null, "\uf0b7 Over/ under remittance of pays amounted to UGX. 6,239,435 and"], [null, "UGX. 180,339,880 respectively"], ["03 Amuru DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salaries worth UGX 9,787,296, Underpayment of salaries and pensioners worth UGX 122,296,566 and UGX 157,253,083 respectively ; payment of salaries worth UGX. 129,399,583 to twenty two (22) staffs that was no longer in service. Under remittance of employees\u2019 salaries deductions worth UGX. 11,492,067. \uf0b7 Additionally, I observed that there was delayed access to payroll by sixty six (66) new employees and thirteen (13) pensioners;", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 374, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "estimates to MoPs, failure to utilize wage funds of UGX.0.23Bn;"], "type": "table"}}, {"content": "362", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 374, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["failure to utilize wage funds of UGX.1,094,631,066; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 2,140,892 and payment of two (02) pensioners worth UGX. 45,794,020 off the IPPS. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial and non-implementation of outputs and activities; non-submission of quarterly wage returns to MoPS; incomplete works such as; Amuru Seed School, Otwee HC III, Giragira-Guruguru and Gotgweno-Maroawobi road and culvert installation under Periodic maintenance of Lakang- Kidimon-Atoro road; under absorption of funds worth UGX.1,854,436,151 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX. 13,266,132,540; \uf0b7 The district mischarged expenditure worth UGX. 122,058,859 on wrong budget lines. \uf0b7 I noted that UGX. 75,499,557 was paid as residual arrears to 8 pensioners who had not been verified (and thus not part of schedule) by MoFPED \uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 The district has payables worth UGX. 1,560,778,573 and receivables worth UGX. 1682,711,064", null, null], ["04", "APAC DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 375, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": [["failure to utilize wage funds of UGX.1,094,631,066; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 2,140,892 and payment of two (02) pensioners worth UGX. 45,794,020 off the IPPS. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial and non-implementation of outputs and activities; non-submission of quarterly wage returns to MoPS; incomplete works such as; Amuru Seed School, Otwee HC III, Giragira-Guruguru and Gotgweno-Maroawobi road and culvert installation under Periodic maintenance of Lakang- Kidimon-Atoro road; under absorption of funds worth UGX.1,854,436,151 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX. 13,266,132,540; \uf0b7 The district mischarged expenditure worth UGX. 122,058,859 on wrong budget lines. \uf0b7 I noted that UGX. 75,499,557 was paid as residual arrears to 8 pensioners who had not been verified (and thus not part of schedule) by MoFPED \uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 The district has payables worth UGX. 1,560,778,573 and receivables worth UGX. 1682,711,064", null, null], ["04", "APAC DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Qualified Opinion", "estimates to MoPs, Over payment of salaries worth UGX"], [null, null, "170,469,321 and over payment of pension worth UGX."], [null, null, "764,207,203; Underpayment of salaries worth UGX. 43,539,065;"], [null, null, "Wrong computation of gratuity worth net overpayment of UGX."], [null, null, "7650,338, 704; payment of salaries worth UGX. 2,257,209 to"], [null, null, "two (2) staffs who were no longer in service; unpaid salaries"], [null, null, "worth UGX. 29,321,020"], [null, null, ""], [null, null, "\uf0b7 I noted over and/or under remittance of salary deductions worth"], [null, null, "UGX.906, 079,942 and UGX.10, 641,906 respectively."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by eleven (11) new employees and one (1) pensioners; failure to"], [null, null, "utilize wage funds of UGX. 364,298,971; un-deducted PAYE from"], [null, null, "political leaders\u2019 gratuity resulting in unpaid tax of UGX."], [null, null, "7,747,080. and payment of staff off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; partial implantation of out puts;"], [null, null, "incomplete works ; under absorption of funds worth UGX. 1.7 Bn"], [null, null, "that was swept back to consolidated fund account; under"], [null, null, "performance of the donor & releases from other government"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 375, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": "363", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 375, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "units worth UGX.622,073,000; non submission of quarterly"], [null, null, "monitoring reports to OPM & MoFPED"], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 376, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", null, "units worth UGX.622,073,000; non submission of quarterly"], [null, null, "monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 I noted that Apac DLG had revenue arrears worth UGX."], [null, null, "715,864,939 by year end"], [null, null, ""], [null, null, "\uf0b7 Outstanding unpaid pension arrears worth UGX. 702,052,938 by"], [null, null, "year end"], [null, null, ""], [null, null, "\uf0b7 I noted that no funds were paid as residual arrears to pensioners"], [null, null, "and staff that had not been verified and were not part of"], [null, null, "schedule provided by MoFPED for payment."], [null, null, ""], [null, null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit."], ["05 Gulu District Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs; Underpayment of pension worth UGX 299,950,406; Wrong computation of gratuity worth net overpayment of UGX. 1,249,233 and under remittance of salary deductions worth UGX. 8,451,617. \uf0b7 Additionally, I observed that there was delayed access to payroll by two (02) new employees and five (05) pensioners; failure to utilize wage funds of UGX 4.97 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 11,003,344.and payment of sixteen (16) staffs and five (05) pensioners worth UGX 114,877,542 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as;; incomplete works; partial implantation of outputs; under absorption of funds worth UGX 4,900,216,339 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.4,034,373,129; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 I noted that the district has outstanding receivables worth UGX. 2,063,196,780 by the year end", null, null], ["06", "Gulu RRH", "\uf0b7 I noted a number of anomalies during review of the"], ["", "", "Hospitalpension & salary payrolls such as; Failure to submit wage"], [null, "Opinion Unqualified", "estimates to MoPs; Underpayment of salaries worth UGX. UGX"], [null, null, "8,236,293. Under remittance of salaries worth UGX.197, 476,295."], [null, "", ""]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 376, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "364", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 376, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, "by thirty one (31) new employees and seven (7) pensioners;"], [null, "failure to utilize wage funds of UGX. 1.87 billion.; un-deducted"]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 377, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "units worth UGX.622,073,000; non submission of quarterly"], "type": "table"}}, {"content": [["", "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, "by thirty one (31) new employees and seven (7) pensioners;"], [null, "failure to utilize wage funds of UGX. 1.87 billion.; un-deducted"], [null, "PAYE from political leaders\u2019 gratuity resulting in unpaid tax of"], [null, "UGX.10,746,540 and payment of nine (9) staffs and ten (10)"], [null, "pensioners worth UGX. 461,890,255 off the IPPS"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; shoddy works in construction of"], [null, "classrooms; incomplete works, I noted there was noted delayed"], [null, "completion of the construction of 54 staff houses; partial"], [null, "implementation of actives; under absorption of funds worth UGX."], [null, "1,939,617,659 that was swept back to consolidated fund"], [null, "account"], [null, ""], [null, "\uf0b7 The district mischarged expenditure worth UGX. 34,589,597 on"], [null, "wrong budget lines."], [null, ""], [null, "\uf0b7 I noted that 24 employees were paid worth UGX. 118,822,759"], [null, "without signed any way."], [null, ""], [null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, "aligned to the NDP-III at the time of audit"], [null, ""], [null, "\uf0b7 I reviewed the approved Local revenue estimates for the financial"], [null, "year 2020/2021 and noted that the Hospital did not budget for"], [null, "NTR during the year but collected UGX. 206,100,000."], [null, ""], [null, "\uf0b7 I noted that the hospital had an off budget financing worth UGX."], [null, "1,092,948,429 during the financial year."], [null, ""], ["07 Kole DLG Opinion Qualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs; Over payment of pension worth UGX.288, 866,531; Underpayment of pension worth UGX.271, 215,401; Wrong computation of gratuity worth net overpayment of UGX. 54,578,592; payment of salaries two (2) staffs who were no longer in service and irregular deduction of loan instalments worth UGX.9, 061,174. \uf0b7 Additionally, I observed that there was delayed access to payroll by twenty three (23) new employees and fourteen (14) pensioners; failure to utilize wage funds of UGX. 0.4 Billion; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 6,473,220 and payment of twenty two (22) staffs worth UGX.35,678,772 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; Failure to quantify out puts; partial and non-implementation of planned activities, inaccurate reporting, and delayed submission of quarterly reports; under absorption of funds worth UGX. 1,095,317,475 that was swept", null]], "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], "page": 377, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "units worth UGX.622,073,000; non submission of quarterly"], "type": "table"}}, {"content": "365 \nback to consolidated fund account; under performance of the donor & releases from other government units worth \n8,664,323,677 \n\uf0b7 The district mischarged expenditure worth UGX.639, 863,720 \non wrong budget lines. \n\uf0b7 I noted that UGX.349,542,400 in respect of staff advances and \nfuel deposits was not accounted for \n\uf0b7 I noted wrong recognition of deposits received figure of UGX.269, 970,000 in relation to Youth Livelihood Programme \n(YLP) and Uganda Women Entrepreneur Project (UWEP). \n\uf0b7 I noted that UGX.43, 200,000 was paid to one (1) purported pensioner who was neither on the IPPS payroll register nor \npossessed the necessary documentation to support their existence. \n\uf0b7 I noted that the district did not submit loan deductions worth UGX. 3,800,833 to UCLA/UBA. \n\uf0b7 I noted that the District failed to remit tax worth UGX.407, \n791,480 to URA. \n\uf0b7 I noted that UGX.34,062,213 was paid as residual arrears to one \n(1) staff and two (2) pensioners who had not been verified (and thus not part of schedule) by MoFPED.", "metadata": {"headings": [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}, [{"headings_0": {"content": "implementation of Construction of Kagumba & Nabiwugulu Seed Schools, upgrading of Bubago HCII to HC III, Construction works", "page": 331, "level": 3}}], [{"headings_0": {"content": "8,664,323,677", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The district mischarged expenditure worth UGX.639, 863,720", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The district mischarged expenditure worth UGX.639, 863,720", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.349,542,400 in respect of staff advances and", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.349,542,400 in respect of staff advances and", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted wrong recognition of deposits received figure of UGX.269, 970,000 in relation to Youth Livelihood Programme", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted wrong recognition of deposits received figure of UGX.269, 970,000 in relation to Youth Livelihood Programme", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.43, 200,000 was paid to one (1) purported pensioner who was neither on the IPPS payroll register nor", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.43, 200,000 was paid to one (1) purported pensioner who was neither on the IPPS payroll register nor", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district did not submit loan deductions worth UGX. 3,800,833 to UCLA/UBA.", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District failed to remit tax worth UGX.407,", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District failed to remit tax worth UGX.407,", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.34,062,213 was paid as residual arrears to one", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.34,062,213 was paid as residual arrears to one", "page": 378, "level": 3}}]], "page": 377, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted over remittance of payroll deductions worth", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.34,062,213 was paid as residual arrears to one", "page": 378, "level": 3}}], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nUGX.450,413,838 \n\uf0b7 I noted that UGX. 34,062,213 were charged on account codes \nother than those prescribed for salary, pension or gratuity. \n\uf0b7 I noted that the District had a receivables figure of UGX.1, 072,183,415 as presented in the Statement of Financial Position \nand disclosed in note 19 to the financial statements. \n\uf0b7 I further noted that the District had a payables worth UGX.1,244,267,887 \n\uf0b7 I noted a number of misstatements in the financial statements of the districts such as; un-reconciling balances for PPE, treatment \nof revenue surpluses, omission of domestic arrears paid during \nthe year of UGX.74,024,139, \n\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit. \n\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was \n366", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.34,062,213 was paid as residual arrears to one", "page": 378, "level": 3}}, [{"headings_0": {"content": "UGX.450,413,838", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX. 34,062,213 were charged on account codes", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX. 34,062,213 were charged on account codes", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District had a receivables figure of UGX.1, 072,183,415 as presented in the Statement of Financial Position", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District had a receivables figure of UGX.1, 072,183,415 as presented in the Statement of Financial Position", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I further noted that the District had a payables worth UGX.1,244,267,887", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted a number of misstatements in the financial statements of the districts such as; un-reconciling balances for PPE, treatment", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted a number of misstatements in the financial statements of the districts such as; un-reconciling balances for PPE, treatment", "page": 378, "level": 3}}], [{"headings_0": {"content": "the year of UGX.74,024,139,", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit.", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}]], "page": 378, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["never declared to the PS/ST. \uf0b7 Under UGIFT, I noted delayed completion of construction of Okwerodot Seed Secondary School, Okole HCII and Ayer HCIII upgrade.", null, null], ["08", "Lira Municipal", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 379, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["never declared to the PS/ST. \uf0b7 Under UGIFT, I noted delayed completion of construction of Okwerodot Seed Secondary School, Okole HCII and Ayer HCIII upgrade.", null, null], ["08", "Lira Municipal", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, over payment of pension worth"], [null, "Unqualified", "UGX.438,769,830 , underpayment of salaries worth"], [null, "", "UGX.14,238,411; Underpayment of pension worth UGX."], [null, null, "390,304,000;"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by five (5) pensioners; four (04) pensionaries do not have"], [null, null, "access to payroll; failure to utilize wage funds of UGX.0.6 billion;"], [null, null, "un-deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX.3, 734,640 and payment of nine (09)"], [null, null, "pensionaries worth UGX. 217,577,695 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete works; non implantation of"], [null, null, "municipal activities; under absorption of funds worth UGX."], [null, null, "UGX.12, 094,641,795 that were swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX. 236,796,670; late submission of"], [null, null, "quarterly reports"], [null, null, ""], [null, null, "\uf0b7 The municipal mischarged expenditure worth UGX. 63,933,741"], [null, null, "on wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 Under remitted payroll deductions worth UGX.4,119,401"], [null, null, ""], [null, null, "\uf0b7 I noted that the municipal paid unverified residual arrears worth"], [null, null, "UGX. 320,216,040 to 39 pensioners"], [null, null, ""], [null, null, "\uf0b7 I noted that 08 employees were paid a total of UGX.20, 975,837"], [null, null, "without signed pay change reports."], [null, null, ""], [null, null, "\uf0b7 I noted that the Municipal Council has an outstanding payables"], [null, null, "balance of UGX.383, 550,743 by year end as recognized in the"], [null, null, "statement of financial position on page 8 of the financial"], [null, null, "statements."], [null, null, ""], [null, null, "\uf0b7 I noted that municipal council has outstanding payables worth"], [null, null, "UGX. 383,550,743 and outstanding debtors worth UGX."], [null, null, "634,438,200"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had not had their prepared strategic plan"], [null, null, "approved as aligned to the NDP-III at the time of audit."], [null, null, ""], ["09 Lira RRH \uf0b7 I noted a number of anomalies during review of Lira RR Hospital pension & salary payrolls such as; Failure to submit wage", null, null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 379, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "367", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 379, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Unqualified estimates to MoPs, over payment of salaries worth UGX. UGX.10, 939,040; Underpayment of salaries worth UGX. UGX 19,371,873. Over payment of pension worth UGX 222,915,780. \uf0b7 Additionally, I observed that there was delayed access to payroll by three (3) pensioners; failure to utilize wage funds of UGX.1.50 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of one (01) pensioner worth UGX 48,955,200 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete works partial and implementation of activities; under absorption of funds worth UGX.1,866,855,791 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.13,220,968,441; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX. 53,750,617 on wrong budget lines. \uf0b7 Under remittance of salary deductions worth UGX. 115,855,754 \uf0b7 I noted that UGX. 18,767,338 was paid as residual arrears to 13 staff who had not been verified by MoFPED \uf0b7 I observed that a sum of UGX.339,276,432 had been paid to a contractor as advance payments", null, null], ["10", "Gulu MC", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the municipal"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 380, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["never declared to the PS/ST. \uf0b7 Under UGIFT, I noted delayed completion of construction of Okwerodot Seed Secondary School, Okole HCII and Ayer HCIII upgrade.", "None", "None"], "type": "table"}}, {"content": [["Opinion Unqualified estimates to MoPs, over payment of salaries worth UGX. UGX.10, 939,040; Underpayment of salaries worth UGX. UGX 19,371,873. Over payment of pension worth UGX 222,915,780. \uf0b7 Additionally, I observed that there was delayed access to payroll by three (3) pensioners; failure to utilize wage funds of UGX.1.50 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,746,540 and payment of one (01) pensioner worth UGX 48,955,200 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete works partial and implementation of activities; under absorption of funds worth UGX.1,866,855,791 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.13,220,968,441; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX. 53,750,617 on wrong budget lines. \uf0b7 Under remittance of salary deductions worth UGX. 115,855,754 \uf0b7 I noted that UGX. 18,767,338 was paid as residual arrears to 13 staff who had not been verified by MoFPED \uf0b7 I observed that a sum of UGX.339,276,432 had been paid to a contractor as advance payments", null, null], ["10", "Gulu MC", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the municipal"], [null, "Opinion", "council pension & salary payrolls such as; Failure to submit wage"], [null, "Unqualified", "estimates to MoPs, Underpayment of salaries worth"], [null, "", "UGX.26,212,810; payment of salaries worth UGX.64,323,258 to"], [null, null, "twenty nine (29) staffs that was no longer in service"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by one (01) new employee and twenty four (24) pensioners;"], [null, null, "failure to utilize wage funds of UGX. 0.33 billion; un-deducted"], [null, null, "PAYE from political leaders\u2019 gratuity resulting in unpaid tax of"], [null, null, "UGX. 4,415,984 and payment of seven (07) staffs and 08"], [null, null, "pensioners worth UGX. 73,991,598 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete work; partial and non-"], [null, null, "implementation of activities; under absorption of funds worth"], [null, null, "UGX. 37,873,163,059 that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX.5,244,627,728; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.313, 804,373 on"], [null, null, "wrong budget lines."]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 380, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["never declared to the PS/ST. \uf0b7 Under UGIFT, I noted delayed completion of construction of Okwerodot Seed Secondary School, Okole HCII and Ayer HCIII upgrade.", "None", "None"], "type": "table"}}, {"content": "368", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 380, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", ""], [null, "\uf0b7 A review of the pension payroll data and IFMS payments,"], [null, "revealed variances between amounts on the payroll and"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 381, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["never declared to the PS/ST. \uf0b7 Under UGIFT, I noted delayed completion of construction of Okwerodot Seed Secondary School, Okole HCII and Ayer HCIII upgrade.", "None"], "type": "table"}}, {"content": [["", ""], [null, "\uf0b7 A review of the pension payroll data and IFMS payments,"], [null, "revealed variances between amounts on the payroll and"], [null, "payments to individual pensioners, leading to an over and under"], [null, "payment of UGX.108,837,902 and UGX.1,323,647,325"], [null, "respectively."], [null, ""], [null, "\uf0b7 I noted that the entity had not had their prepared strategic plan"], [null, "approved as aligned to the NDP-III at the time of audit."], [null, ""], [null, "\uf0b7 I noted that 58 employees were paid a total of UGX."], [null, "UGX.48,537,458 without Unauthorized pay changed reports"], [null, ""], [null, "\uf0b7 I also noted that UGX.163, 186,521 accrued within the year and"], [null, "had not yet been paid to pensioners by the end of the year."], [null, ""], [null, "\uf0b7 Over and under payments of UGX 2,050,016 and UGX.625, 974"], [null, "respectively of 59 staff arising from the use a wrong salary scale."], [null, ""], [null, "\uf0b7 Overpayment of pension of arrears worth UGX.48,674,235 to"], [null, "nine (09) pensioners"], [null, ""], [null, "\uf0b7 I noted that Municipal Council paid out a total of UGX.6.3 million"], [null, "to 07 non-existent staff."], [null, ""], [null, "\uf0b7 I noted that UGX.75, 010,130 was paid to 08 purported"], [null, "pensioners that were neither on the IPPS payroll register nor"], [null, "possessed the necessary documentation to support their"], [null, "existence."], [null, ""], [null, "\uf0b7 I noted that the Municipal Council made PAYE deductions of"], [null, "UGX. 1,439,481,558, but did not remit UGX.2, 162,681 to URA."], [null, ""], [null, "\uf0b7 I noted that UGX.82, 533,859 was paid as residual arrears to 14"], [null, "pensioners who had not been verified."], [null, ""], [null, "\uf0b7 I noted that the council has receivables worth U GX.3,"], [null, "153,612,053 at end of the financial year."], [null, ""], [null, "\uf0b7 I noted that expenditure amounting to UGX.113,162,472"], [null, "remained unaccounted for."], [null, ""], ["11 Lira DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs,; payment of salaries worth UGX.14,683,834 to eight (8) staffs that was no longer in service . \uf0b7 Additionally, I observed that there was delayed access to payroll by fourteen (14) new employees and eight (8) pensioners; failure to utilize wage funds of UGX.0.5 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,794,810; Over and under payment salaries worth of", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 381, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["never declared to the PS/ST. \uf0b7 Under UGIFT, I noted delayed completion of construction of Okwerodot Seed Secondary School, Okole HCII and Ayer HCIII upgrade.", "None"], "type": "table"}}, {"content": "369", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 381, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["UGX.115,309,480 and UGX.131,175,021 respectively; under payments of salaries worth UGX.530,320 of 18 staff arising from the use a wrong salary scale \uf0b7 Over and under payment of pension worth of UGX.30, 707,444 and UGX.598, 762,255 respectively. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; the District failed to achieve the intended services from the implemented 02 outputs; under absorption of funds worth UGX. 1,005,249,173 that were swept back to consolidated fund account; over performance and under performance of the donor & releases from other government units worth UGX. 8,559,440,754 delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines. \uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit. \uf0b7 I noted that the district had an off budget financing worth UGX.220, 983,855 during the financial year. \uf0b7 I noted that 21 employees were paid a total of UGX. 9,941,845 without signed pay change reports. \uf0b7 I noted that the District had outstanding receivables worth UGX. 898,553,933 and outstanding payables worth UGX.920,018,518", null, null], ["12", "Oyam DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 382, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": [["UGX.115,309,480 and UGX.131,175,021 respectively; under payments of salaries worth UGX.530,320 of 18 staff arising from the use a wrong salary scale \uf0b7 Over and under payment of pension worth of UGX.30, 707,444 and UGX.598, 762,255 respectively. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; the District failed to achieve the intended services from the implemented 02 outputs; under absorption of funds worth UGX. 1,005,249,173 that were swept back to consolidated fund account; over performance and under performance of the donor & releases from other government units worth UGX. 8,559,440,754 delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines. \uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit. \uf0b7 I noted that the district had an off budget financing worth UGX.220, 983,855 during the financial year. \uf0b7 I noted that 21 employees were paid a total of UGX. 9,941,845 without signed pay change reports. \uf0b7 I noted that the District had outstanding receivables worth UGX. 898,553,933 and outstanding payables worth UGX.920,018,518", null, null], ["12", "Oyam DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Qualified Opinion", "estimates to MoPs, over payment of salaries worth UGX."], [null, null, "81,486,802; Underpayment of salaries worth UGX. 54,366,065;"], [null, null, "payment of salaries worth UGX.74, 935,902 to thirty three (33)"], [null, null, "staffs that was no longer in service .unpaid salary worth UGX.91,"], [null, null, "771,432."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by thirteen (13) new employees and sixteen (16) pensioners;"], [null, null, "failure to utilize wage funds of UGX. UGX.0.58 billion; un-"], [null, null, "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid"], [null, null, "tax of UGX.12, 437,406."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had not had their prepared strategic plan"], [null, null, "approved as aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 The District did not recognize as a receivable an advance"], [null, null, "payment of UGX.414,149,184 made on 28 th June 2021 for the"], [null, null, "supply and installation of medical equipment to 64 Health Center"], [null, null, "IIIs under Uganda Intergovernmental Fiscal Transfer Program"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 382, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": "370", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 382, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "(UgIFT) (LOT 3)."], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX. 609,529,053 on"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 383, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["UGX.115,309,480 and UGX.131,175,021 respectively; under payments of salaries worth UGX.530,320 of 18 staff arising from the use a wrong salary scale \uf0b7 Over and under payment of pension worth of UGX.30, 707,444 and UGX.598, 762,255 respectively. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; the District failed to achieve the intended services from the implemented 02 outputs; under absorption of funds worth UGX. 1,005,249,173 that were swept back to consolidated fund account; over performance and under performance of the donor & releases from other government units worth UGX. 8,559,440,754 delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines. \uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit. \uf0b7 I noted that the district had an off budget financing worth UGX.220, 983,855 during the financial year. \uf0b7 I noted that 21 employees were paid a total of UGX. 9,941,845 without signed pay change reports. \uf0b7 I noted that the District had outstanding receivables worth UGX. 898,553,933 and outstanding payables worth UGX.920,018,518", "None", "None"], "type": "table"}}, {"content": [["", "", "(UgIFT) (LOT 3)."], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX. 609,529,053 on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 Over payments of UGX.1, 104,810 respectively of 27 staff arising"], [null, null, "from the use of wrong salary scales."], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete works; partial and non-"], [null, null, "implementation of activities; under absorption of funds worth"], [null, null, "UGX. 972,008,324 that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX. 1,163,405,949; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 Over and under payment of pension to pensionaries worth"], [null, null, "UGX.34, 619,402, and UGX.126, 248,570 respectively."], [null, null, ""], [null, null, "\uf0b7 I noted that the District has unauthorized loan deductions worth"], [null, null, "UGX.178,342,254."], [null, null, ""], [null, null, "\uf0b7 Payment of pension arrears worth UGX.22,125,006 to ineligible"], [null, null, "pensioners"], [null, null, ""], [null, null, "\uf0b7 I noted 700 vacant staff position at the district that affected"], [null, null, "service delivery"], [null, null, ""], [null, null, "\uf0b7 The district had outstanding payables worth UGX.2, 865,939,536"], [null, null, "and Overdue receivables worth UGX.2, 865,939,536 by the end"], [null, null, "of the financial year."], [null, null, ""], [null, null, "\uf0b7 UGX.590, 863,502 paid to the contractor on the 28 th June 2021"], [null, null, "was not supported by certificates of works done."], [null, null, ""], [null, null, "\uf0b7 I noted that expenditure amounting to UGX.31, 252,804"], [null, null, "remained unaccounted."], [null, null, ""], [null, null, "\uf0b7 I noted that management irregularly paid out UGX.411, 867,050"], [null, null, "to individual staff personal bank accounts to purportedly"], [null, null, "implement several council activities instead of directly paying the"], [null, null, "eligible suppliers and service providers. In addition, these"], [null, null, "individuals were neither imprest holders nor cashiers who are"], [null, null, "mandated to hold cash among other duties."], ["13", "Pader DLG Un Qualified Opinion \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salaries worth UGX.42,537,857payment of pension worth UGX.288, 866,531; Underpayment of pension worth UGX.910,301,025.; payment of", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 383, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["UGX.115,309,480 and UGX.131,175,021 respectively; under payments of salaries worth UGX.530,320 of 18 staff arising from the use a wrong salary scale \uf0b7 Over and under payment of pension worth of UGX.30, 707,444 and UGX.598, 762,255 respectively. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; the District failed to achieve the intended services from the implemented 02 outputs; under absorption of funds worth UGX. 1,005,249,173 that were swept back to consolidated fund account; over performance and under performance of the donor & releases from other government units worth UGX. 8,559,440,754 delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines. \uf0b7 I noted that the entity had not had their prepared strategic plan approved as aligned to the NDP-III at the time of audit. \uf0b7 I noted that the district had an off budget financing worth UGX.220, 983,855 during the financial year. \uf0b7 I noted that 21 employees were paid a total of UGX. 9,941,845 without signed pay change reports. \uf0b7 I noted that the District had outstanding receivables worth UGX. 898,553,933 and outstanding payables worth UGX.920,018,518", "None", "None"], "type": "table"}}, {"content": "371", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 383, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["salaries worth UGX.7,410,931 to seven (07) staffs that was no longer in service \uf0b7 Additionally, I observed that there was delayed access to payroll by twenty three (23) new employees and two (2) pensioners; failure to utilize wage funds of UGX.2.38Bn; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.310,309,590 and payment of twenty two (22) staffs worth UGX.35,678,772 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; shoddy works in construction of classrooms; incomplete works; under absorption of funds that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.2,942,949,626; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Over payment of salary worth UGX.608,719 arising from use of wrong scale \uf0b7 I noted that the District made unauthorized loan deductions worth UGX. 45,223,516. \uf0b7 I noted that UGX.113, 671,178 was charged on account codes other than those prescribed for salary, pension and gratuity. \uf0b7 The District had an outstanding payables balance of UGX.1,365,231,670 as reported in the statement of financial position \uf0b7 The District had in its statement of financial position, long outstanding debtors (Advances) amounting to UGX.927, 029,154, which relate to the previous financial years. \uf0b7 I noted that the entity had prepared a strategic plan but the National Planning Authority had not yet approved it at the time of audit. \uf0b7 I undertook an assessment to establish if there has been service delivery from a sample of outputs that were implemented and noted that the upgrade of Lapul\u2013Ocwida Health Center II to III had not been completed because the contractor abandoned the site. \uf0b7 I noted that UGX.42, 534,087 was charged on items which did not reflect the nature of the expenditure. \uf0b7 The district has an approved staff structure of 2,215 positions. Out of the approved staff structure, 1,229 (55%) are filled leaving 986 (45%) vacant.", null, null], ["", "Soroti Branch", "Summary of Key Findings"], ["01 Amolatar DLG \uf0b7 I noted a number of anomalies during review of the district", null, null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}], "page": 384, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "372 \npension & salary payrolls such as; Failure to submit wage Opinion estimates to MoPs, over payment of pension worth UGX. Unqualified 3,624,783; Underpayment of pension worth UGX. 5,353,736 w; payment of salaries worth UGX. 12,633,711 fourteen (14) staffs \nthat was no longer in service \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Kole District received off-budget financing to a tune of UGX.27, 329,000 directly from the Development Initiative for Northern Uganda (DINU) for undertaking activities which was", "page": 378, "level": 3}}, [{"headings_0": {"content": "pension & salary payrolls such as; Failure to submit wage Opinion estimates to MoPs, over payment of pension worth UGX. Unqualified 3,624,783; Underpayment of pension worth UGX. 5,353,736 w; payment of salaries worth UGX. 12,633,711 fourteen (14) staffs", "page": 385, "level": 3}}], [{"headings_0": {"content": "pension & salary payrolls such as; Failure to submit wage Opinion estimates to MoPs, over payment of pension worth UGX. Unqualified 3,624,783; Underpayment of pension worth UGX. 5,353,736 w; payment of salaries worth UGX. 12,633,711 fourteen (14) staffs", "page": 385, "level": 3}}], [{"headings_0": {"content": "pension & salary payrolls such as; Failure to submit wage Opinion estimates to MoPs, over payment of pension worth UGX. Unqualified 3,624,783; Underpayment of pension worth UGX. 5,353,736 w; payment of salaries worth UGX. 12,633,711 fourteen (14) staffs", "page": 385, "level": 3}}]], "page": 384, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 13,781,047 and payment of 32 staffs and 02", "metadata": {"headings": [{"headings_0": {"content": "pension & salary payrolls such as; Failure to submit wage Opinion estimates to MoPs, over payment of pension worth UGX. Unqualified 3,624,783; Underpayment of pension worth UGX. 5,353,736 w; payment of salaries worth UGX. 12,633,711 fourteen (14) staffs", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "pensioners worth UGX. 34,292,421 off the IPPS and delayed \nsubmission of remittances of PAYE to URA \n\uf0b7 I noted a number of issues in the implementation of the \napproved budget such as; partial and non-implementation of \nplanned activities; unabsorbed wage fund of UGX0.95 billion; under absorption of funds worth UGX.3,620,479,221 that was \nswept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.2,409,034,822; non submission of quarterly monitoring reports to OPM & MoFPED; \n\uf0b7 I noted that whereas UGX. 2,463,002,481 was deducted from \nemployees\u2019 salaries to be remitted to different beneficiaries, \nUGX.2,451,377,682.was remitted, leading to an over and under \nremittance amounting to UGX.1,529,715 and UGX.13,154,514 respectively. \n\uf0b7 The district mischarged UGX. 30,489,944 for pension arrears on \naccount code for gratuity. \n\uf0b7 I noted that the district had not paid pension arrears of UGX.121,391,408 by the end of the financial year and the total \nliabilities of UGX.1,794,377,044 \n", "metadata": {"headings": [{"headings_0": {"content": "pensioners worth UGX. 34,292,421 off the IPPS and delayed", "page": 385, "level": 3}}, [{"headings_0": {"content": "pensioners worth UGX. 34,292,421 off the IPPS and delayed", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of the", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of the", "page": 385, "level": 3}}], [{"headings_0": {"content": "planned activities; unabsorbed wage fund of UGX0.95 billion; under absorption of funds worth UGX.3,620,479,221 that was", "page": 385, "level": 3}}], [{"headings_0": {"content": "planned activities; unabsorbed wage fund of UGX0.95 billion; under absorption of funds worth UGX.3,620,479,221 that was", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that whereas UGX. 2,463,002,481 was deducted from", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that whereas UGX. 2,463,002,481 was deducted from", "page": 385, "level": 3}}], [{"headings_0": {"content": "UGX.2,451,377,682.was remitted, leading to an over and under", "page": 385, "level": 3}}], [{"headings_0": {"content": "UGX.2,451,377,682.was remitted, leading to an over and under", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The district mischarged UGX. 30,489,944 for pension arrears on", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The district mischarged UGX. 30,489,944 for pension arrears on", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district had not paid pension arrears of UGX.121,391,408 by the end of the financial year and the total", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district had not paid pension arrears of UGX.121,391,408 by the end of the financial year and the total", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district had not paid pension arrears of UGX.121,391,408 by the end of the financial year and the total", "page": 385, "level": 3}}]], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- I noted that expenditure of UGX.10, 037,020 remained unaccounted for by the close of the financial year.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the district had not paid pension arrears of UGX.121,391,408 by the end of the financial year and the total", "page": 385, "level": 3}}], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 I noted that the entity did not prepare and have an approved \nstrategic plan aligned to NDP-III. \n\uf0b7 I noted that Amolatar District received off-budget financing to a tune of UGX.29, 056,000 directly from United Nations Development Fund (UNCDF) for local revenue enhancement and \nconstruction of Development Initiative for Northern Uganda \n(DINU) centre which was never declared to the PS/ST and as \nsuch no supplementary appropriation was issued as guided by the PS/ST. \n\uf0b7 I noted that despite recommendations by the board of survey, \nthe district had not disposed of assets. \n\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount \n373", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity did not prepare and have an approved", "page": 385, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that the entity did not prepare and have an approved", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that Amolatar District received off-budget financing to a tune of UGX.29, 056,000 directly from United Nations Development Fund (UNCDF) for local revenue enhancement and", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that Amolatar District received off-budget financing to a tune of UGX.29, 056,000 directly from United Nations Development Fund (UNCDF) for local revenue enhancement and", "page": 385, "level": 3}}], [{"headings_0": {"content": "(DINU) centre which was never declared to the PS/ST and as", "page": 385, "level": 3}}], [{"headings_0": {"content": "(DINU) centre which was never declared to the PS/ST and as", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that despite recommendations by the board of survey,", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}]], "page": 385, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", null, null], ["01.", "Bukedea 0 DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "2", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 386, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", null, null], ["01.", "Bukedea 0 DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "2", "pension & salary payrolls such as; Failure to submit wage"], ["", "Opinion", "estimates to MoPs,; Underpayment of pension worth"], [null, "Unqualified", "UGX.4,244,574. ; Wrong computation of gratuity worth net"], [null, "", "overpayment of UGX 4,368,548; delayed remittance of payroll"], [null, null, "deductions to URA and one staff was paid a total of"], [null, null, "UGX.14.8million off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as;partial implementation of planned"], [null, null, "activities; an absorbed wage fund balance 0.6Bn; under"], [null, null, "absorption of funds worth UGX.2.93Bn that was swept back to"], [null, null, "consolidated fund account; under performance of the donor &"], [null, null, "releases from other government units worth UGX.0.6Bn; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity did not prepare and have an approved"], [null, null, "strategic plan aligned to NDP-III."], [null, null, ""], [null, null, "\uf0b7 I noted that whereas UGX.4,007,788,020 was deducted from"], [null, null, "employees\u2019 salaries to be remitted to different beneficiaries,"], [null, null, "UGX.3,853,954,791 was remitted, leading to an over/ under"], [null, null, "remittance of UGX.116,697,024/UGX.270,530,253 respectively"], [null, null, "\uf0b7"], [null, null, "\uf0b7 I also noted that within total liabilities are deposits of UGX.994,"], [null, null, "994,899 regarding to YLP and UWEP."], [null, null, ""], [null, null, "\uf0b7 Bukedea HCIV experienced drug stock outs for several essential"], [null, null, "medicines during the year"], [null, null, ""], [null, null, "\uf0b7 The district awarded contracts and made payment of UGX."], [null, null, "47,362,136 without proof of active VAT registration. As a result,"], [null, null, "VAT amounting of UGX. 7,222,726 was paid to non-registered"], [null, null, "company/deregistered due to non-compliance."], [null, null, ""], [null, null, "\uf0b7 The district had received unbudgeted for funding worth UGX."], [null, null, "254,695,138 for printing of home study materials but this was"], [null, null, "not even approved as a supplementary budget by the council."], [null, null, ""], [null, null, "\uf0b7 An outstanding receivables balance of UGX. 303,281,690 during"], [null, null, "the financial year that remained unrecovered"], ["02\\. 0 3 Dokolo DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over Underpayment of salaries worth UGX.169,757,747 and several staff were paid a total of UGX.6.4million off the IPPS. \uf0b7 I noted a number of issues in the implementation of the approved budget such as;partial implementation of planned activities; unabsorbed wage funds of UGX.0.128Bn; under", null, null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 386, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "374", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 386, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["performance of the donor & releases from other government units worth UGX.6.258Bn; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the entity did not prepare and have an approved strategic plan aligned to NDP-III. \uf0b7 I noted delays in the remittance of PAYE deductions to URA in 2 out of 12 months, with an average delay. \uf0b7 I noted that the district did not subject political leaders\u2019 gratuity totaling to UGX.33, 217,800 to the computation of PAYE in IPPS, leading to revenue loss of UGX.10, 036,690. \uf0b7 Outstanding payables during the year worth UGX.7,108,292 remained unsettled by year end \uf0b7 Uncounted for funds at the close of the financial year amounted to UGX.13,212,000 \uf0b7 It was noted that two (2) contracts worth UGX.36,371,630 were awarded to contractors VAT inclusive to a tune of UGX.5,548,214 yet the individual contractors were either not VAT registered or had been de-registered by the tax authority. \uf0b7 An outstanding receivables balance of UGX.346,165,052 due from UWEP and YLP groups", null, null], ["03.", "Kaberamaido 0 DLG", ""], ["", "4", "\uf0b7 I noted a number of anomalies during review of the district"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 387, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["performance of the donor & releases from other government units worth UGX.6.258Bn; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the entity did not prepare and have an approved strategic plan aligned to NDP-III. \uf0b7 I noted delays in the remittance of PAYE deductions to URA in 2 out of 12 months, with an average delay. \uf0b7 I noted that the district did not subject political leaders\u2019 gratuity totaling to UGX.33, 217,800 to the computation of PAYE in IPPS, leading to revenue loss of UGX.10, 036,690. \uf0b7 Outstanding payables during the year worth UGX.7,108,292 remained unsettled by year end \uf0b7 Uncounted for funds at the close of the financial year amounted to UGX.13,212,000 \uf0b7 It was noted that two (2) contracts worth UGX.36,371,630 were awarded to contractors VAT inclusive to a tune of UGX.5,548,214 yet the individual contractors were either not VAT registered or had been de-registered by the tax authority. \uf0b7 An outstanding receivables balance of UGX.346,165,052 due from UWEP and YLP groups", null, null], ["03.", "Kaberamaido 0 DLG", ""], ["", "4", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "Opinion.", "pension & salary payrolls such as; Failure to submit wage"], [null, "Unqualified", "estimates to MoPs, over payment of salaries worth UGX.1,"], [null, "", "255,265; Underpayment of salaries worth UGX. 1, 222,507;"], [null, null, "salaries worth UGX.1,960,136 was paid to 1 staff who had retired"], [null, null, "and Paid UGX.3,300,000 and UGX.54,988,606 to 2 employees"], [null, null, "and 2 pensioners respectively off IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; unabsorbed wage funds worth UGX"], [null, null, "0.4Bn; under payment UGX. 37,655,834 under absorption of"], [null, null, "other received funds worth UGX.26, 816,534 that was swept"], [null, null, "back to consolidated fund account; under performance of the"], [null, null, "donor & releases from other government units worth"], [null, null, "UGX.464,763,581; delayed submission of quarterly monitoring"], [null, null, "reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity did not prepare and have an approved"], [null, null, "strategic plan aligned to NDP-III."], [null, null, "\uf0b7"], [null, null, "\uf0b7 I noted that the District made PAYE deductions of UGX.1,"], [null, null, "260,530,351 and remitted to URA and delays in the remittance of"], [null, null, "PAYE deductions to URA ranging from 1\u201313 days."], [null, null, ""], [null, null, "\uf0b7 I noted that Kaberamaido District did not subject political leaders\u2019"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 387, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "375", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 387, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "gratuity totaling to UGX. 37,211,942 to the computation of PAYE"], [null, null, "in IPPS, leading to an under deduction of UGX. 11,183,595."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 388, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["", null, "gratuity totaling to UGX. 37,211,942 to the computation of PAYE"], [null, null, "in IPPS, leading to an under deduction of UGX. 11,183,595."], [null, null, ""], [null, null, "\uf0b7 I observed a number of issues during my inspection of"], [null, null, "Kaberamaido Hospital such as; equipment such as Ultra sound"], [null, null, "machines and Scanners were idle due to lack of specialized"], [null, null, "human resources to operate them and the hospital has (4) small"], [null, null, "oxygen concentrators which are obsolete; Poor infrastructural"], [null, null, "development of kaberamido hospital"], [null, null, ""], [null, null, "\uf0b7 A review of the approved work plan and budget revealed that the"], [null, null, "district made budget provisions for vehicle maintenance during"], [null, null, "the period under review amounting to UGX.98, 812,000."], [null, null, "However, almost all the district vehicles were not functional due"], [null, null, "to failure to maintain and repair them and the approximated cost"], [null, null, "amounted to UGX.298, 400,000."], [null, null, ""], ["04\\. 0 5 Kalaki DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs; Underpayment of pension worth UGX.13,901,641; payment of salaries worth UGX. 1,573,970 to five (5) staffs that was no longer in service and payment of UGX 19.29 million to five (5) employees off the IPPS \uf0b7 I noted a number of issues in implementation of approved budget such as; under absorption of funds worth UGX.1,197,062,675 that was swept back to consolidated fund account;. un absorbed funds worth UGX.2.385Bn under performance of the donor & releases from other government units worth UGX.2,685,815,492 and non-submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 I noted that the entity did not prepare and have an approved strategic plan aligned to NDP-III. \uf0b7 I observed that whereas UGX.1,565,039,555 was deducted from employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,487,680,407 was remitted, leading to an over/under remittance of UGX.6,339,201 and UGX.83,698,349 respectively. \uf0b7 Disclosed in the statement of financial position on page (15) are receivables of UGX.752,701,227 as supported by Note (19) relating to UWEP and YLP funds which remained due to the revolving fund and close of the financial year", null, null], ["06", "Katakwi DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, over and under payment of salaries worth"], [null, "Unqualified", "UGX. 1,541,478 and UGX. 24,265,506 respectively; under"], [null, "", "remittance salary deductions worth UGX. 10,723,784;"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed failure to utilize wage funds of"], [null, null, "UGX.0.1Bn; un-deducted PAYE from political leaders\u2019 gratuity"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 388, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "376", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 388, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "resulting in unpaid tax of UGX. 13,353,316; I noted that 4 newly"], [null, "recruited/ transferred employees and 24 pensioners delayed to"], [null, "access payroll; the Katakwi District did not prepare monthly"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 389, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None"], "type": "table"}}, {"content": [["", "resulting in unpaid tax of UGX. 13,353,316; I noted that 4 newly"], [null, "recruited/ transferred employees and 24 pensioners delayed to"], [null, "access payroll; the Katakwi District did not prepare monthly"], [null, "wage, pension and gratuity performance analysis and thus did"], [null, "not submit quarterly returns on payroll to MoPS; paid 32 staff"], [null, "and 02 pensioners worth UGX. 34,292,421 off the IPPS"], [null, ""], [null, "\uf0b7 I noted that the district had not paid salary and pension arrears"], [null, "of UGX.176,136,812 and UGX.210,481,886 respectively and"], [null, "deposits under total liabilities of UGX.1,469,427,540, comprising"], [null, "of YLP and UWEP amounts due to the revolving fund"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; shoddy works in construction of"], [null, "classrooms; incomplete works; under absorption of funds worth"], [null, "UGX. 360,155,363 that was swept back to consolidated fund"], [null, "account; under performance of the donor & releases from other"], [null, "government units worth UGX.1,868,819,492; delayed"], [null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, ""], [null, "\uf0b7 A total of 37 km at an estimated cost of UGX.220, 000,000 was"], [null, "worked on, however on physical inspection it was noted that"], [null, "some road sections were not well graded with poor road shaping,"], [null, "spot gravelling while others lacked access roads to the"], [null, "community."], [null, ""], [null, "\uf0b7 The district had received unbudgeted funding worth"], [null, "UGX.186,033,984 on 20 th January 2021 for printing of home"], [null, "study materials which was not approved as a supplementary"], [null, "budget by the council, remained un-transferred to schools until"], [null, "23 rd June 2021 and had not been utilized by the beneficiary"], [null, "schools at the time of audit.(August 2021)."], [null, ""], [null, "\uf0b7 An audit of Katakwi district hospital revealed instances of drug"], [null, "stock outs, failure to keep records of essential medicines such as"], [null, "oxygen and blood, expiry of drugs and staffing gaps at the"], [null, "district hospital."], [null, ""], [null, "\uf0b7 The district signed a contract with UK General Services Limited"], [null, "for Upgrade of Palam HC III to III funded under Transitional"], [null, "Development Grant (TDG) (KATA522/WRKS/20-21/00032) at a"], [null, "contract price of UGX.296, 838,010, UGX.265, 076,343 (89%) of"], [null, "the contract sum had been paid leaving only 10% retention due"], [null, "to the contractor but on inspection it was noted that the works"], [null, "were in complete and the contractor was not found on site."], ["07 KUMI DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs; Underpayment of pension worth UGX 40,603,995; payment of salaries worth UGX. 41,743,339 to fourteen (14) staffs that was no longer in service \uf0b7 Additionally, I observed that there was delayed access to payroll", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 389, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None"], "type": "table"}}, {"content": "377", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 389, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["by seventy eigth (78) new employees and six (06) pensioners and 15 pensioners did not access the pension payroll by the end of FY 2020/21; failure to utilize wage funds of UGX 0.7 billion.; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 8,722,103.and payment of seven (07) staffs worth UGX 8,054,219 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial implementation of activities, under absorption of funds worth UGX. 1,189,642,702 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.9,484,212,313; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Over and under remittance amounting to UGX. 1,447,689 and UGX. 27,903,716 respectively. \uf0b7 I noted that the District has receivables worth UGX 207,343,250. \uf0b7 I noted that the District had payables of worth UGX. 1,061,619,255 \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit. \uf0b7 The district lacked land titles for 58 pieces measuring 948.809 acres which exposed the land to loss and encroachment. \uf0b7 The district received a sum of UGX 202,441,411 for primary and secondary for procurement of learning materials. I noted that the above funds were still on the schools accounts. \uf0b7 Vacant staff position of 82 was noted at the district \uf0b7 The district mischarged expenditure worth of UGX.23,818,896 on wrong budget lines.", null, null], ["08", "Soroti CITY", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the district"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 390, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["by seventy eigth (78) new employees and six (06) pensioners and 15 pensioners did not access the pension payroll by the end of FY 2020/21; failure to utilize wage funds of UGX 0.7 billion.; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 8,722,103.and payment of seven (07) staffs worth UGX 8,054,219 off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial implementation of activities, under absorption of funds worth UGX. 1,189,642,702 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.9,484,212,313; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Over and under remittance amounting to UGX. 1,447,689 and UGX. 27,903,716 respectively. \uf0b7 I noted that the District has receivables worth UGX 207,343,250. \uf0b7 I noted that the District had payables of worth UGX. 1,061,619,255 \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit. \uf0b7 The district lacked land titles for 58 pieces measuring 948.809 acres which exposed the land to loss and encroachment. \uf0b7 The district received a sum of UGX 202,441,411 for primary and secondary for procurement of learning materials. I noted that the above funds were still on the schools accounts. \uf0b7 Vacant staff position of 82 was noted at the district \uf0b7 The district mischarged expenditure worth of UGX.23,818,896 on wrong budget lines.", null, null], ["08", "Soroti CITY", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the district"], [null, "Opinion", "pension & salary payrolls such as; Failure to submit wage"], [null, "Unqualified", "estimates to MoPs worth 0.20Bn; Underpayment of pension"], [null, "", "worth UGX 17,693,503; payment of salaries worth UGX."], [null, null, "4,422,604 to two (2) staffs that was no longer in service"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by twenty three (2) new employees and nine (2) pensioners;"], [null, null, ""], [null, null, "\uf0b7 I noted under absorption of funds worth UGX.569,370,362 that"], [null, null, "was swept back to consolidated fund account; under"], [null, null, "performance of the donor & releases from other government"], [null, null, "units worth UGX.3,241,130,000; delayed submission of quarterly"], [null, null, "monitoring reports to OPM & MoFPED partial implementation of"], [null, null, "planned activities unquantified output 2 pensioners delayed to"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 390, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "378", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 390, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "access the pension payroll, with delays of 2 months."], [null, ""], [null, "\uf0b7 The district did not have an approved strategic plan that is"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 391, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None"], "type": "table"}}, {"content": [["", "access the pension payroll, with delays of 2 months."], [null, ""], [null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, "aligned to the NDP-III at the time of audit."], [null, ""], [null, "\uf0b7 I noted that whereas UGX.1,672,354,754 was deducted from"], [null, "employees\u2019 salaries to be remitted to different beneficiaries,"], [null, "UGX.1,720,244,218 was remitted, leading to an over remittance"], [null, "of UGX.47,889,464."], [null, ""], [null, "\uf0b7 I noted that the City did not subject political leaders\u2019 gratuity"], [null, "totaling to UGX.10, 718,400 to the computation of PAYE in IPPS,"], [null, "leading to a revenue loss of UGX.3,212,520."], [null, "."], [null, "\uf0b7 I noted that UGX.16, 952,389 was charged on account codes"], [null, "other than those prescribed for salary, pension and gratuity."], [null, "\uf0b7 9 staff and 1 pensioner were paid a total of UGX.9, 175,032 off"], [null, "the IPPS."], [null, "\uf0b7"], [null, "\uf0b7 It was noted that the health centre experienced expiry of several"], [null, "essential medicines."], [null, "\uf0b7 An audit of a sample of essential drugs revealed that there were"], [null, "discrepancies between quantities ordered and those actually"], [null, "delivered by National Medical Stores."], [null, ""], [null, "\uf0b7 I noted that from the financial year 2015/16 to 2018/19 the City"], [null, "had disbursed a total of UGX.213,350,031 out of which a sum of"], [null, "only UGX.48,137,000(23%) was recovered leaving an"], [null, "outstanding balance of UGX.173,473,68"], [null, "\uf0b7 AN outstanding balance of UGX.84,288,225 ."], ["09 Soroti DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; delayed to submit wage estimates to MoPs; an unabsorbed balance of UGX.0.1Bn; an over payment of UGX.2,539,634; Unpaid Salaries worth UGX.39,755,425; an under payment of UGX.40,539,361; payment of salaries worth UGX.2,618,034 to two (2) staffs that had retired and the other died; an over/under remittance of UGX.24,004,085 and UGX.70,000 respectively; loan deduction worth UGX.1,025,336,368 from 643 employees that had no letters of undertaking but exist in the reports. \uf0b7 I further un-deducted PAYE from political leaders\u2019 gratuity resulting to an under deduction of UGX.10,594,893; delay in accessing payroll and pension payroll; the district mischarged expenditure worth UGX.23,558,053 on wrong budget lines; Paid residual arrears worth UGX.361,354,056 to 15 pensioners who had not been verified; Failed to prepare monthly wage, pension and gratuity performance analysis; Failed also to submit quarterly returns on payroll to MoPS; Payment worth UGX.1,109,575,875 was paid to 26 pensioners off the IPPS; \uf0b7 I noted that the entity prepared and submitted the Strategic Plan to National Planning Authority but had not been approved by the", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 391, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None"], "type": "table"}}, {"content": "379", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 391, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["time of audit; the district had an Outstanding total liabilities worth UGX.1,315,447,223; Underperformance worth UGX.1,770,722,988; Under absorption worth UGX.620,661,204 which was subsequently swept back to the consolidated fund account; Failed to prepare annual monitoring plans. \uf0b7 The district received Amount worth UGX.51,440,000 under covid 19 response; the district had several pieces of land whose titles had not been secured; an outstanding balance worth UGX.1,028,188,380 from groups; shoddy works in construction of roads; Un utilized amount of money worth UGX.176,968,673 meant for the procurement of learning materials for primary and secondary schools", null, null], ["10", "Kapelebyong DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 392, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["time of audit; the district had an Outstanding total liabilities worth UGX.1,315,447,223; Underperformance worth UGX.1,770,722,988; Under absorption worth UGX.620,661,204 which was subsequently swept back to the consolidated fund account; Failed to prepare annual monitoring plans. \uf0b7 The district received Amount worth UGX.51,440,000 under covid 19 response; the district had several pieces of land whose titles had not been secured; an outstanding balance worth UGX.1,028,188,380 from groups; shoddy works in construction of roads; Un utilized amount of money worth UGX.176,968,673 meant for the procurement of learning materials for primary and secondary schools", null, null], ["10", "Kapelebyong DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, under payment of pension worth UGX."], [null, "Unqualified", "13,840,658; Underpayment of salaries worth UGX. 23,446,654.."], [null, "", "Accrued payment of pension worth UGX. 1,623,473. under"], [null, null, "remittance of salaries worth UGX. 35,257,436."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by two (2) pensioners; failure to utilize wage funds of UGX."], [null, null, "1,030,154,088.; un-deducted PAYE from political leaders\u2019 gratuity"], [null, null, "resulting in unpaid tax of UGX.6,156,000 and payment of six"], [null, null, "(06) staffs worth UGX. 19,428,658 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete works; partial"], [null, null, "implementation of activities, under absorption of funds worth"], [null, null, "UGX. 1,089, 751 811, that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX.537,701,164; delayed submission"], [null, null, "of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 Outstanding liabilities worth UGX.912,708,330"], [null, null, ""], [null, null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 A total of UGX.20, 000,000 was received as COVID 19"], [null, null, "supplementary funding"], [null, null, ""], [null, null, "\uf0b7 I noted that the district has funds worth UGX. 589,150,272"], [null, null, "relating to YLP and UWEP"], [null, null, ""], [null, null, "\uf0b7 The district received unbudgeted funding worth UGX. 76,174,518"], [null, null, ""], [null, null, "\uf0b7 I noted that the district has outstanding payables (YLP)/ UWEP"], [null, null, "worth UGX. 331,343,011 and UGX. 251,879,775 respectively"], [null, null, "."], [null, null, "\uf0b7 The district awarded contracts and made payments amounting to"], [null, null, "UGX.97, 981,512 without proof of active VAT registration, as a"], [null, null, "result, VAT amounting of UGX.14, 946,332 was paid to non-"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 392, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "380", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 392, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "registered or de-registered companies."], ["11 SERERE DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salaries worth UGX.5,681,385; Underpayment of salaries worth UGX.7,111,988; under remittance of salaries worth UGX.32,910,176 \uf0b7 I further noted failure to utilize wage funds of UGX.0.6 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,721, UGX.416million off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as;; under absorption of funds worth UGX.1.18Bn that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.7.721Bn; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Un recovered YLP and UWEP deposits worth UGX.1,086,363,675 \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit. \uf0b7 I noted that the district had received unbudgeted for funding worth UGX. 254,695,138 \uf0b7 Unrecovered YLP and UWEP fund worth UGX. 873,681,064", null, null], ["12", "Amuria DLG", ""]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 393, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["", null, "registered or de-registered companies."], ["11 SERERE DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salaries worth UGX.5,681,385; Underpayment of salaries worth UGX.7,111,988; under remittance of salaries worth UGX.32,910,176 \uf0b7 I further noted failure to utilize wage funds of UGX.0.6 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.10,721, UGX.416million off the IPPS \uf0b7 I noted a number of issues in the implementation of the approved budget such as;; under absorption of funds worth UGX.1.18Bn that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.7.721Bn; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Un recovered YLP and UWEP deposits worth UGX.1,086,363,675 \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit. \uf0b7 I noted that the district had received unbudgeted for funding worth UGX. 254,695,138 \uf0b7 Unrecovered YLP and UWEP fund worth UGX. 873,681,064", null, null], ["12", "Amuria DLG", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the district"], [null, "Opinion", "pension & salary payrolls such as; Failure to submit wage"], [null, "Un-Qualified", "estimates to MoPs, over payment of salaries worth"], [null, "", "UGX.467,333, under payment of salaries worth UGX.607,250"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by seven (07) new employees and fourteen (14) pensioners;"], [null, null, "failure to utilize wage funds of UGX.1,303,509,217.; un-deducted"], [null, null, "PAYE from political leaders\u2019 gratuity resulting in unpaid tax of"], [null, null, "UGX.12,243,797 and payment of one (01) staffs worth of"], [null, null, "UGX.5,393,465 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as;; under absorption of funds worth"], [null, null, "UGX.1,872,205,072 that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX.2,531,940,210; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted that the District has unauthorized loan deductions worth"], [null, null, "UGX.694,591,280."]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 393, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "381", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 393, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "at the time of audit"], [null, ""], [null, "\uf0b7 The district received off-budget financing to a tune of UGX. .46,"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 394, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None"], "type": "table"}}, {"content": [["", "at the time of audit"], [null, ""], [null, "\uf0b7 The district received off-budget financing to a tune of UGX. .46,"], [null, "449,000 directly from UNFPA for undertaking activities which was"], [null, "never declared to the PSST and as such no supplementary"], [null, "appropriation was issued as guided by the PSST."], [null, ""], [null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, "aligned to the NDP-III at the time of audit."], [null, ""], [null, "\uf0b7 I noted that Note 19, Net Receivables, to the financial"], [null, "Statements, Amuria District had receivables of UGX.808,524,096"], [null, "relating to UWEP and YLP funds at the beginning of the current"], [null, "financial year. Further review revealed that the receivables"], [null, "increased to UGX.1, 003,497,681."], [null, ""], [null, "\uf0b7 I noted that funds totaling UGX.7,747,000 were irregularly"], [null, "diverted from the activities on which they were budgeted and"], [null, "spent on other activities without seeking or obtaining the"], [null, "necessary approvals."], [null, ""], [null, "\uf0b7 I noted that that tracer medicines like Oxytocin, Coatem"], [null, "(Artemether + Lumefantrine) 24 Tablets 30 strips, Gloves,"], [null, "Determine test kit and Mama kits worth UGX.4,615,129 was not"], [null, "accounted for by the Hospital Management."], [null, "\uf0b7 I noted that out of 154 pieces of land, only 8 (5%) had titles."], ["13 Kumi MC Opinion Un-qualified \uf0b7 I noted a number of anomalies during review of the Municipal pension & salary payrolls such as; Under absorption worth UGX.212,168,628; under payment worth UGX.35,246,285; Outstanding payment worth UGX.2,256,948 meant for 5 employees; an under payment of Pension, Gratuity worth UGX.33,299; Accrued payment worth UGX.13,261,366; payment of salaries worth UGX.5,189,355 to Nine (9) staffs who had either retired, transferred, absconded or died. \uf0b7 Additionally, I observed an over remittance of UGX.13, 281,172; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.3, 889,440; delayed in accessing payroll and pension payroll; Failed to prepare monthly wage, pension and gratuity performance analysis; Failed to submit quarterly returns on payroll to MoPS; Salary payment worth UGX.5, 582,676 was paid to 12 staffs off the IPPS. Receivables worth UGX.1, 132,227,490 relating to UWEP and YLP funds. \uf0b7 I noted that the entity does not have an approved strategic plan that is aligned to the NDP-III at the time of audit; Underperformance worth UGX.389,604,927; under Absorption UGX.297,497,115. \uf0b7 I noted that UGX.9, 350,000 was charged on items which did not reflect the nature of the expenditure. \uf0b7 I noted that all the pieces of land owned by the municipality", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 394, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None"], "type": "table"}}, {"content": "382", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 394, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["lacked Titles; the entity Lacked approved Physical Development Plan and detailed Plans; Underperformance of the public Health and Hygiene Promotion worth UGX.2,996,879; an outstanding balance worth UGX.256,828,714 and UGX.148,878,891 from YLP groups and UWEP groups respectively", null, null], ["14", "Ngora DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as Underpayment of salary worth"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 395, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["lacked Titles; the entity Lacked approved Physical Development Plan and detailed Plans; Underperformance of the public Health and Hygiene Promotion worth UGX.2,996,879; an outstanding balance worth UGX.256,828,714 and UGX.148,878,891 from YLP groups and UWEP groups respectively", null, null], ["14", "Ngora DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as Underpayment of salary worth"], [null, "Opinion", "UGX.39,027,007; irregular deduction of loan instalments worth"], [null, "Un-Qualified", "UGX.834,880,411; pension and gratuity under/Non-payments of"], [null, "", "UGX.155,180,697; over remittance of salary deductions worth"], [null, null, "UGX.100,096,201 and eighty-seven (87) vacant staff positions"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed failure to utilize wage funds of UGX.0.4"], [null, null, "Bn; un-deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX.10,637,490 and payment of one (1) staff"], [null, null, "worth UGX.1,776,726 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted outstanding receivables of UGX.1,131,962,894 relating to"], [null, null, "UWEP and YLP"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete works; under absorption of"], [null, null, "funds worth UGX.652,569,804 that was swept back to"], [null, null, "consolidated fund account; under performance of the donor &"], [null, null, "releases from other government units worth UGX 2,214,950,254;"], [null, null, ""], [null, null, "\uf0b7 The DLG did not have an approved strategic plan that is aligned"], [null, null, "to the NDP-III at the time of audit"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.44, 007,809 on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity did not prepare monthly wage, pension"], [null, null, "and gratuity performance analysis and did not submit quarterly"], [null, null, "returns on payroll to MoPS."], [null, null, ""], [null, null, "\uf0b7 I noted that out of the total receipts/ Warrants for Covid-relief"], [null, null, "funds UGX.39,990,000 the entity did not absorb any Funds."], [null, null, ""], [null, null, "\uf0b7 I noted Drug Stock Outs and Expired medicines in Ngora HC. IV"], [null, null, ""], [null, null, "\uf0b7 I noted Lack of land titles for the district land"], [null, null, ""], [null, null, "\uf0b7 I noted un recovered youth group funds worth UGX.930,137,986."], [null, null, ""], ["15 Soroti Regional Referral Hospital Opinion Un-Qualified \uf0b7 I noted a number of anomalies during review of the hospital pension & salary payrolls such as; Failure to submit wage estimates to MoPs, over payment of salary worth UGX 8,16,582; Underpayment of salary worth UGX.1,039,133payment of salaries worth UGX 15,516,178 to seven (7) staffs that was no longer in service and irregular deduction of loan instalments worth UGX.61,946,480.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 395, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "383", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 395, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted an over/under payment for gratuity worth UGX8,109,089 and UGX.28,338,806 respectively \uf0b7 I noted under/over remittance of salary deductions worth UGX.6,037,243,966 and UGX.30,277 respectively \uf0b7 Additionally, I observed that there was delayed access to payroll by thirteen (13) new employees \uf0b7 I noted under remittance of PAYE deductions worth5.2Mn \uf0b7 I noted under remittance of salary deductions to UCLA/UBA worth 0.84Mn \uf0b7 I noted issues in the implementation of the approved budget such as; under absorption of funds worth UGX.0.33 that was swept back to consolidated fund account and partially quantified and un quantified planned output \uf0b7 The hospital did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 The district mischarged expenditure worth UGX.105Mn on wrong budget lines. \uf0b7 I noted that 03 employees were paid a total of UGX.27.8 million without signed pay change reports. \uf0b7 I noted that the Hospital did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted that the RRH received off-budget financing of UGX.1,652,793,876. \uf0b7 I noted. under absorption of COVID-19 relief funds worth UGX.6,068,828 \uf0b7 I noted that the Hospital had stock outs of Essential medicines for supportive treatment of Covid-19 during the year", null, null], ["16", "Otuke DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; delay to submit wage"], [null, "Opinion Un-Qualified", "estimates to MoPs, accrued pension worth UGX.10,251,154;"], [null, null, "under payments of pension and gratuity of UGX.5,374,525.; an"], [null, "", "under remittance of salary deductions worth UGX.122,929,219."], [null, null, ""], [null, null, "\uf0b7 I noted Pension, Salary and retentions arears worth"], [null, null, "UGX.440,155,588"], [null, null, ""], [null, null, "\uf0b7 I noted un recovered youth group funds worth"], [null, null, "UGX.898,559,384"], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 396, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "384", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 396, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 Additionally, I observed failure to utilize wage funds of"], [null, null, "UGX.0.97Bn; un-deducted PAYE from political leaders\u2019 gratuity"], [null, null, "resulting in unpaid tax of UGX.9,454,537 and payment of two (2)"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 397, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": [["", null, "\uf0b7 Additionally, I observed failure to utilize wage funds of"], [null, null, "UGX.0.97Bn; un-deducted PAYE from political leaders\u2019 gratuity"], [null, null, "resulting in unpaid tax of UGX.9,454,537 and payment of two (2)"], [null, null, "staffs worth UGX.13,339,271 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted issues in the implementation of the approved budget"], [null, null, "such as; absorption of funds worth UGX.0.58Bn that was swept"], [null, null, "back to consolidated fund account; under performance of the"], [null, null, "donor & releases from other government units worth UGX"], [null, null, "1.452Bn"], [null, null, ""], [null, null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 I noted that the district did not prepare monthly wage, pension"], [null, null, "and gratuity performance analysis and thus did not submit"], [null, null, "quarterly returns on payroll to MoPS."], [null, null, ""], [null, null, "\uf0b7 I noted that one employee was paid a total of UGX.18 million"], [null, null, "without signed pay change reports."], [null, null, ""], [null, null, "\uf0b7 I also noted un recovered YLP and UWEP funds worth"], [null, null, "UGX.1,514,330,911"], [null, null, ""], [null, null, "\uf0b7 I noted that the district received off-budget financing from"], [null, null, "donors"], [null, null, ""], [null, null, "\uf0b7 I noted that the district only recovered UGX.185,893,762 (31%)"], [null, null, "out of disbursed amount of UGX.597,983,600 (Interest Inclusive)"], [null, null, "leaving an outstanding amount of UGX.412,089,838 disbursed in"], [null, null, "financial Years 2016/2017,2017/2018, 2018/2019 and"], [null, null, "2020/2021."], ["Moroto Branch \uf0b7 Summary of Key Findings", null, null], ["01", "Moroto DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs; payment of salaries worth UGX. 944,615 to"], [null, "Unqualified", "two (2) staffs that was no longer in service"], [null, "", ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by two (02) new employees and nine (9) pensioners; failure to"], [null, null, "utilize wage funds UGX.1.9 Bn; un-deducted PAYE from political"], [null, null, "leaders\u2019 gratuity resulting in unpaid tax of UGX. 16,712,548 and"], [null, null, "payment of one hundred twenty six (126) staffs worth UGX."], [null, null, "113,636,936 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted Under payment of pension/ gratuity worth UGX 969,963"], [null, null, ""], [null, null, "\uf0b7 Over remittance of salaries worth UGX. 42,443,292."], [null, null, ""], [null, null, "\uf0b7 I noted that loan deductions amounting to UGX. 444 million"], [null, null, "relating to 236 employees lacked letters of undertaking."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 397, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["due (Interest Exclusive) of UGX. 559,850,500 representing 18%, leaving an outstanding balance of UGX. 478, 531,250 under the Uganda Women Entrepreneurship Program (UWEP).", "None", "None"], "type": "table"}}, {"content": "385", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 397, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete works; partial and non-"], [null, null, "implementation of activities worth UGX. 0.842Bn under"], [null, null, "absorption of funds worth UGX. 2.173 Bn that was swept back to"], [null, null, "consolidated fund account; under performance of the donor &"], [null, null, "releases from other government units worth UGX.4,318,906,529"], [null, null, "delayed submission of quarterly monitoring reports to OPM &"], [null, null, "MoFPED"], [null, null, "Under performance of the URF fund worth UGX 9,622,000"], [null, null, ""], [null, null, "\uf0b7 I noted Failure to maintain a repayments ledger for all YIG\u2019s"], [null, null, "(Youth Interest Groups)"], [null, null, "I noted Failure to maintain a repayments ledger for all UWEP"], [null, null, "Groups."], [null, null, ""], ["02 Napak DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salaries worth UGX.25,677,705 \uf0b7 Additionally, I observed that there was delayed access to payroll by fifteen (15) new employees and one (01) pensioners; failure to utilize wage funds of UGX. 0.7 Billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. UGX 9,299,652. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete works; partial implementation; under absorption of funds worth UGX. 2.406 Bn that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.88,076,485; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 Overpayment of salaries to 04 staff worth UGX. 263,929 arising from wrong scale. \uf0b7 I noted Under payment of pension/ gratuity worth UGX 274,445,221 \uf0b7 Over remittance of salaries worth 212,895,556. \uf0b7 I noted that the entity\u2019s strategic plan was prepared but not yet approved by NDP \uf0b7 I noted mischarges worth UGX. 23,485,083 by the district", null, null], ["03", "Abim DLG", ""], ["", "Qualified Opinion", "\uf0b7 I noted a number of anomalies during review of the district"], [null, null, "pension & salary payrolls such as; Failure to submit wage"], [null, null, "estimates to MoPs; Overpayments of salaries worth UGX."], [null, null, "2,172,750."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}], "page": 398, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_4"], "type": "table"}}, {"content": "386 \n\uf0b7 Additionally, I observed that there was delayed access to payroll \nby twenty one hundred two (102) new employees and six (06) \npensioners; failure to utilize wage funds of UGX.0.8 billion; un- \ndeducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 8,922,417and payment of nineteen(19) staffs worth \nUGX 46,305,014 off the IPPS \n\uf0b7 I noted a number of issues in the implementation of the \napproved budget such as; incomplete works; partial implementation of activities under absorption of funds worth \nUGX.1.3Bn that was swept back to consolidated fund account; \nunder performance of the donor & releases from other \ngovernment units worth UGX. 5.87Bn; delayed submission of \nquarterly monitoring reports to OPM & MoFPED \n\uf0b7 I noted that the district has an outstanding payables worth UGX. 43,702,393 by the end of the year \n\uf0b7 Over payment of pension to 11 pensionaries worth UGX. \n2,318,376 arising from wrong scale. \n\uf0b7 I noted Misclassification of Expenditure worth UGX.296,881,279 \n\uf0b7 I noted that UGX 130,582,400 accrued within the year and had \nnot yet been paid to pensioners by the year end. \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that for the financial year 2016/17 to 202021/ the district had recovered UGX. 99,542,500 out of the expected total amount", "page": 385, "level": 3}}, [{"headings_0": {"content": "\uf0b7 Additionally, I observed that there was delayed access to payroll", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Additionally, I observed that there was delayed access to payroll", "page": 399, "level": 3}}], [{"headings_0": {"content": "pensioners; failure to utilize wage funds of UGX.0.8 billion; un-", "page": 399, "level": 3}}], [{"headings_0": {"content": "deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 8,922,417and payment of nineteen(19) staffs worth", "page": 399, "level": 2}}], [{"headings_0": {"content": "UGX 46,305,014 off the IPPS", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of the", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of the", "page": 399, "level": 3}}], [{"headings_0": {"content": "UGX.1.3Bn that was swept back to consolidated fund account;", "page": 399, "level": 3}}], [{"headings_0": {"content": "UGX.1.3Bn that was swept back to consolidated fund account;", "page": 399, "level": 3}}], [{"headings_0": {"content": "government units worth UGX. 5.87Bn; delayed submission of", "page": 399, "level": 3}}], [{"headings_0": {"content": "government units worth UGX. 5.87Bn; delayed submission of", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district has an outstanding payables worth UGX. 43,702,393 by the end of the year", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Over payment of pension to 11 pensionaries worth UGX.", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Over payment of pension to 11 pensionaries worth UGX.", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted Misclassification of Expenditure worth UGX.296,881,279", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX 130,582,400 accrued within the year and had", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX 130,582,400 accrued within the year and had", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX 130,582,400 accrued within the year and had", "page": 399, "level": 3}}]], "page": 398, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Under remittance of salaries deduction worth to UGX.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX 130,582,400 accrued within the year and had", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "352,211,360. \n\uf0b7 I noted that funds amounting to 2 million relating to pension and \ngratuity were incorrectly charged on salaries and pension codes. \n\uf0b7 I noted that the Abim district did not have an approved strategic \nplan that is aligned to NDP-III and therefore lacks a certificate of compliance issued by National Planning Authority.. \n\uf0b7 I noted misclassification of expenditure UGX.296,881,279 by \nAbim DLG \n\uf0b7 I noted Lack of land title for Nyakwae Seed Secondary School. \n\uf0b7 I noted Irregular disbursement of UGX 175,113,737 for NUSAF \nfunds \n\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount \nUGX. 109,898,354 \n", "metadata": {"headings": [{"headings_0": {"content": "352,211,360.", "page": 399, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that funds amounting to 2 million relating to pension and", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that funds amounting to 2 million relating to pension and", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the Abim district did not have an approved strategic", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the Abim district did not have an approved strategic", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted misclassification of expenditure UGX.296,881,279 by", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted misclassification of expenditure UGX.296,881,279 by", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted Lack of land title for Nyakwae Seed Secondary School.", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted Irregular disbursement of UGX 175,113,737 for NUSAF", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted Irregular disbursement of UGX 175,113,737 for NUSAF", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}]], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- Unaccounted for funds worth 1,412,507,436 at year end", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted Transfer from other Government units indicates", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted Award of a VAT inclusive contract to a non-VAT registered supplier worth UGX. 610,546,414 with a VAT amount", "page": 399, "level": 3}}], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5 \n387", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}]], "page": 399, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["", null, "of UGX. 1,073,044,082 more than the amount warrantied by"], [null, null, "Ugx. 224,945,899. The trial balance also indicate a figure of"], [null, null, "Ugx.1,194,065"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 400, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", null, "of UGX. 1,073,044,082 more than the amount warrantied by"], [null, null, "Ugx. 224,945,899. The trial balance also indicate a figure of"], [null, null, "Ugx.1,194,065"], [null, null, ""], [null, null, "\uf0b7 I noted Statement of Cash Flow indicates a total amount from"], [null, null, "operating, investing and financing activities as"], [null, null, "Ugx.17,850,462,341 while the payment file indicates it as"], [null, null, "Ugx.17,808,775,851 leading to an overstatement of Ugx."], [null, null, "41,686,490."], [null, null, ""], [null, null, "\uf0b7 I noted Unsupported receivables figure in the Statement Of"], [null, null, "Financial Position of UGX. 1,683,003,314 as there is no schedule"], [null, null, "of receivables attached to the financial statement."], [null, null, ""], ["04 Kaboong DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salaries worth UGX.12,181,796; failure to utilize wage funds of UGX. UGX.1.9billion.; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 9,870,780 I noted a number of issues in the implementation of the approved budget such; incomplete works; partial implementation of activities, under absorption of funds worth UGX.2.042Bn that was swept back to consolidated fund account; delayed submission of quarterly monitoring reports to OPM & MoFPED \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines. \uf0b7 I noted under remittance of salaries worth UGX. 55,693,284 \uf0b7 The district mischarged expenditure worth UGX. 551,346,221 on wrong budget lines. \uf0b7 I noted 93 vacant positions at the district \uf0b7 I noted unbudgeted Funds from Ministry of Education and Sports to Kaabong DLG UGX.42,343,319 \uf0b7 I noted Irregular disbursement of NUSAF 3 Funds to M/S Agromax (U) Limited UGX.717,390,988", null, null], ["05", "Amudat DLG", ""], ["", "", "\uf0b7 I noted a number of anomalies during review of the district"], [null, "Opinion Unqualified", "pension & salary payrolls such as; Failure to submit wage"], [null, null, "estimates to MoPs, irregular deduction of loan instalments worth"], [null, "", "UGX.1,036,328; failure to utilize wage funds of UGX.0.851 billion"], [null, null, "un -deducted PAYE from political leaders\u2019 gratuity resulting in"], [null, null, "unpaid tax of UGX.6,432,420. and payment of two hundred two"], [null, null, "(222) staffs worth UGX.161,371,533 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; incomplete works; partial"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 400, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "388", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 400, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "implementation and quantified under absorption of funds worth"], [null, null, "UGX.4.3Bn that was swept back to consolidated fund account;"], [null, null, "under performance of the donor & releases from other"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 401, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["", null, "implementation and quantified under absorption of funds worth"], [null, null, "UGX.4.3Bn that was swept back to consolidated fund account;"], [null, null, "under performance of the donor & releases from other"], [null, null, "government units worth UGX.1,744,210,000; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 Over remittance of salaries worth UGX. 36,510,817"], [null, null, ""], [null, null, "\uf0b7 I further noted that all loan deductions relating to 7 employees"], [null, null, "did not have evidence of consent by the employees"], [null, null, "\uf0b7 UGX.101,273,688 was paid as residual arrears to 2 pensioners"], [null, null, "who had not been verified (and thus not part of schedule) by"], [null, null, "MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had not prepared and approved a"], [null, null, "strategic plan that is aligned to the NDP-III at the time of audit."], [null, null, ""], [null, null, "\uf0b7 I noted that district failed to recover worth UGX.390,319,125 of"], [null, null, "YLP funds"], [null, null, ""], [null, null, "\uf0b7 I noted that the district has outstanding balance worth"], [null, null, "UGX.390,319,125 from UWEP"], ["06 Kotido DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs; payment of salaries worth UGX.1,395,233 to two (2) staffs that was no longer in service. \uf0b7 Additionally, I observed that there was delayed access to payroll by thirty nine (39) new employees; failure to utilize wage funds of UGX.4.127billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.8, 766,597. \uf0b7 Under remittance of salary deduction worth UGX.18, 888,478. \uf0b7 I noted that the district has unauthorized loan deductions worth UGX.196,780,103 \uf0b7 I noted that the Kotido district did not have an approved strategic plan that is aligned to NDP-III by the time of audit. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete works; partial implementation and no quantified activities under absorption of funds worth UGX.1,291,391,337that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.1,603,270,000; delayed submission of quarterly monitoring reports to OPM & MoFPED", null, null], ["07", "Kotido MC", "\uf0b7 I noted a number of anomalies during review of the municipal"], ["", "", "council pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 401, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "389", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 401, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "Opinion", "estimates to MoPs,; payment of salaries worth UGX.1,819,248 to"], [null, "Unqualified", "two (2) staffs that was no longer in service ; failure to utilize"], [null, "", "wage funds of UGX.0.8 billion.; un-deducted PAYE from political"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 402, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["", "Opinion", "estimates to MoPs,; payment of salaries worth UGX.1,819,248 to"], [null, "Unqualified", "two (2) staffs that was no longer in service ; failure to utilize"], [null, "", "wage funds of UGX.0.8 billion.; un-deducted PAYE from political"], [null, null, "leaders\u2019 gratuity resulting in unpaid tax of UGX.12,448,800 and"], [null, null, "payment of sixteen (16) staffs worth UGX.68,011,511 off the"], [null, null, "IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as;; incomplete works; partial"], [null, null, "implantation non quantified under absorption of funds worth"], [null, null, "UGX.211,565,285 873 that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX.1,089,757,389; delayed"], [null, null, "submission of quarterly monitoring reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 I noted Over payment of salaries worth UGX.882,243 to 25 staff"], [null, null, "arising from wrong scale"], [null, null, ""], [null, null, "\uf0b7 I noted under remittance of salaries worth UGX. 43,787,620"], [null, null, ""], [null, null, "\uf0b7 I noted that the Municipal Council has unauthorized loan"], [null, null, "deductions worth UGX.14.77 million"], [null, null, ""], [null, null, "\uf0b7 I noted that the municipal council had not prepared and"], [null, null, "approved a strategic plan that is aligned to the NDP-III at the"], [null, null, "time of audit."], [null, null, "\uf0b7 The municipal has un recovered UWEP funds worth"], [null, null, "UGX.277,734,805."], [null, null, ""], ["08 Karenga DLG Opinion Unqualified \uf0b7 I noted anomalies during review of the district pension & salary payrolls such as; seventy-three (73) vacant positions; failure to utilize wage funds of UGX.1.089Bn.; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.5,294,160 and payment of eight (8) staffs worth UGX. 28,433,650 off the IPPS; under remittance of employee salary deductions worth UGX.361,889,043 \uf0b7 I noted issues in the implementation of the approved budget such as; under absorption of funds worth UGX.636,616,391 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.4,959,037,208 \uf0b7 The DLG did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 The district mischarged expenditure worth UGX.275, 847,736 on wrong budget lines \uf0b7 I noted that Karenga district did not include IPPS recurrent costs in its budget.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 402, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "390", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 402, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that the entity did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted un quantified, partially implemented and un implemented planned output \uf0b7 I noted underperformance of maintenance funds worth UGX.35,851,027 \uf0b7 I noted that administrative advances worth UGX.36,367,220 remained unaccounted for at year end", null, null], ["09", "Nakapiripirit DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 403, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["\uf0b7 I noted that the entity did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted un quantified, partially implemented and un implemented planned output \uf0b7 I noted underperformance of maintenance funds worth UGX.35,851,027 \uf0b7 I noted that administrative advances worth UGX.36,367,220 remained unaccounted for at year end", null, null], ["09", "Nakapiripirit DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, Over payment of salary worth"], [null, "Unqualified", "UGX.6,225,884; Underpayment of salary worth UGX."], [null, "", "120,957,229; pension worth UGX.102,547,496 and payment of"], [null, null, "residual arrears to 17 pensioners (not part of schedule) worth"], [null, null, "UGX.228,354,584"], [null, null, ""], [null, null, "\uf0b7 I noted outstanding receivables worth UGX.748,268,485 by year"], [null, null, "end"], [null, null, "\uf0b7 I noted outstanding payables worth UGX.204,060,122 by year"], [null, null, "end"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by four (4) new employees and five (5) pensioners; failure to"], [null, null, "utilize wage funds of UGX.0.8 Bn, un-deducted PAYE from"], [null, null, "political leaders\u2019 gratuity resulting in unpaid tax of"], [null, null, "UGX.11,064,133and payment of twenty-six (6) staff and two (2)"], [null, null, "pensioners worth UGX.67,526,067 off the IPPS; over/under"], [null, null, "remittance of employee salary deductions worth UGX.12,510,739"], [null, null, "and UGX.30,390,380 respectively"], [null, null, ""], [null, null, "\uf0b7 The DLG did not have an approved strategic plan that is aligned"], [null, null, "to the NDP-III at the time of audit"], [null, null, "\uf0b7 I noted partially quantified, partially implemented and un"], [null, null, "implemented planned output"], [null, null, ""], [null, null, "\uf0b7 I noted issues in the implementation of the approved budget"], [null, null, "such as; under absorption of funds worth UGX.387,179,529 that"], [null, null, "was swept back to consolidated fund account; under"], [null, null, "performance of the donor & releases from other government"], [null, null, "units worth UGX.3,798,701,446;"], [null, null, ""], [null, null, "\uf0b7 I noted that the district did not prepare monthly wage, pension"], [null, null, "and gratuity performance analysis and thus did not submit"], [null, null, "quarterly returns on payroll to MoPS"], [null, null, "\uf0b7 ."], [null, null, "\uf0b7 I noted that funds to the tune of UGX.37,212,320 were"], [null, null, "irregularly diverted from the activities on which they were"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 403, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "391", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 403, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "budgeted and spent on other activities without seeking and"], [null, null, "obtaining the necessary approvals."], [null, null, ""]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 404, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["", null, "budgeted and spent on other activities without seeking and"], [null, null, "obtaining the necessary approvals."], [null, null, ""], [null, null, "\uf0b7 Irregularities in evaluation and award of contract to Ramiram"], [null, null, "Company Ltd for the construction of a teachers\u2019 house in Doo"], [null, null, "Primary under procurement reference NAKP543/WRKS/20-"], [null, null, "21/00003"], [null, null, "\uf0b7 The district entered into a VAT exclusive contract with Bole"], [null, null, "Engineering Ltd (TIN:) vide NAKP543/WRKS/20-21/00005 worth"], [null, null, "UGX.55,000,000 despite the company being registered for VAT"], ["10 Moroto MC Opinion Unqualified \uf0b7 I noted anomalies during review of the Municipal pension & salary payrolls such as; Failure to submit wage estimates to MoPs Underpayment of salary worth UGX. 359,225; \uf0b7 Additionally, I observed that there was delayed access to payroll by two (2) pensioners; failure to utilize wage funds of UGX.0.32 Bn; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.3,314,340 over/under remittance of employee salary deductions worth UGX.5,297,009 and under UGX.1,329,429 respectively \uf0b7 The MC did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 I noted issues in the implementation of the approved budget such as; under performance of the donor & releases from other government units worth UGX. 439,621,456; un quantified planned output \uf0b7 I noted that the Municipal Council did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS . \uf0b7 I noted that Expenditure amounting to UGX.40,544,000 remained unsupported as at the close of the financial year", null, null], ["11", "Nabilatuk DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, Over payment of salary worth"], [null, "Unqualified", "UGX.41,886,731; Underpayment of salary worth UGX.88,251,765"], [null, "", "irregular deduction of loan instalments of twenty-seven (27)"], [null, null, "employees worth UGX.32,111,398 and excess loan deductions for"], [null, null, "eighteen (18) employees worth UGX.23,960,268"], [null, null, ""], [null, null, "\uf0b7 I noted payments to non-existent staff worth UGX.12,263,143"], [null, null, ""], [null, null, "\uf0b7 I noted over/under remittance of employee salary deductions"], [null, null, "worth UGX.22,136,522 and UGX.28,681,822 respectively"], [null, null, ""], [null, null, "\uf0b7 I noted outstanding receivables worth UGX.306,557,669."], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by twenty-seven (27) new employees; failure to utilize wage"], [null, null, "funds of UGX.0.766 Bn; un-deducted PAYE from political leaders\u2019"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 404, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "392", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 404, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, "gratuity resulting in unpaid tax of UGX.111,240 and payment of"], [null, null, "thirty-five (35) staff pensioners worth UGX.52,863,034 off the"], [null, null, "IPPS and residual arrears to two (2) staff UGX.3,128,128"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 405, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["", null, "gratuity resulting in unpaid tax of UGX.111,240 and payment of"], [null, null, "thirty-five (35) staff pensioners worth UGX.52,863,034 off the"], [null, null, "IPPS and residual arrears to two (2) staff UGX.3,128,128"], [null, null, ""], [null, null, "\uf0b7 The district did not have an approved strategic plan that is"], [null, null, "aligned to the NDP-III at the time of audit"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; un implemented works on construction"], [null, null, "of Nataparengan piped water system and rehabilitation of"], [null, null, "Lorukumo piped water system; under absorption of funds worth"], [null, null, "UGX.353,461,659 that was swept back to consolidated fund"], [null, null, "account; under performance of the donor & releases from other"], [null, null, "government units worth UGX.686,812,859;"], [null, null, ""], [null, null, "\uf0b7 I noted partially quantified and partially implemented planned"], [null, null, "output"], [null, null, ""], [null, null, "\uf0b7 I noted that the district did not prepare monthly wage, pension"], [null, null, "and gratuity performance analysis and thus did not submit"], [null, null, "quarterly returns on payroll to MoPS"], [null, null, ""], [null, null, "\uf0b7 I noted that Nabilatuk District received off-budget financing to a"], [null, null, "tune of UGX.12,464,800 directly from the Drylands Projects"], ["Mbale Branch Summary of Key Findings", null, null], ["01", "Bulambuli DLG", "\uf0b7 I noted a number of anomalies during review of the DLG pension"], ["", "", "& salary payrolls such as; delay to submit wage estimates to"], [null, "Opinion Unqualified", "MoPs; Underpayment of payroll worth UGX.53, 413,352; Wrong"], [null, null, "computation of gratuity worth net overpayment of UGX."], [null, "", "4,908,163 and payment of salaries worth UGX.799, 094 to one"], [null, null, "(1) staff that was no longer in service."], [null, null, ""], [null, null, "\uf0b7 I noted that the entity had receivables worth UGX 865,908,605"], [null, null, "and had Payables worth UGX.5,000,000 at close of financial year"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was failure to utilize wage"], [null, null, "funds of UGX.1.6Bn; un-deducted PAYE from political leaders\u2019"], [null, null, "gratuity resulting in unpaid tax of UGX.16,798,690and payment"], [null, null, "of nine (9) pensioners worth UGX.170,017,059 off the IPPS;"], [null, null, "partially implemented output worth UGX. 0.863Bn and un"], [null, null, "implemented output worth UGX.0.558Bn"], [null, null, ""], [null, null, "\uf0b7 I noted that the District LG did not prepare monthly wage,"], [null, null, "pension and gratuity performance analysis report for submission"], [null, null, "to MoPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; shoddy works at Bumugusha - Sisiyi"], [null, null, "Road, Gimayote - Malama Road, the boreholes; incomplete works"], [null, null, "on Buyaga-Muyembe road, Bulaago and Bwikhonge Health"], [null, null, "Centre IIs to IIIs; under absorption of funds worth"], [null, null, "UGX.2,653,035,652 that was swept back to consolidated fund"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 405, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "393", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 405, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "account; under performance of the donor & releases from other"], [null, "government units worth UGX.234,118787; non submission of"], [null, "quarterly monitoring reports to OPM & MoFPED; delayed"], [null, "submission of performance reports and unremitted lower local"], [null, "government revenue worth UGX 47,216,000"], [null, ""], [null, "\uf0b7 The District mischarged expenditure worth UGX 103,936,059 on"], [null, "wrong budget lines."], [null, ""], [null, "\uf0b7 I observed that key positions, including that of District engineer,"], [null, "District production officer, District education officer, and District"], [null, "planner had remained vacant by end of year."], [null, ""], [null, "\uf0b7 I noted drug stock out at Bulaago Health Centre"], [null, ""], [null, "\uf0b7 I observed that the district lacked vital road equipment such as:"], [null, "Motor Grader, Wheel Loader, Bulldozer, Excavator and Cargo"], [null, "Truck"], [null, ""], [null, "\uf0b7 I noted an Under-deduction of LST worth UGX 214,800,000 and"], [null, "PAYE worth UGX 32,139,829."], [null, ""], ["02 Manafwa DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the DLG pension & salary payrolls such as; failure to submit wage estimates to MoPs, over payment of salaries worth UGX. 14,044,594; Underpayment of salaries worth UGX. 10,735,580; Wrong computation of gratuity worth net overpayment of UGX. 14,474,704 \uf0b7 I noted an over and under remittance of employee salary deductions worth UGX 129,973,902 \uf0b7 I observed that there was failure to utilize wage funds worth UGX.0.890 billion \uf0b7 I noted under deduction of PAYE from employee salary worth UGX. 20,600,350. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; under absorption of funds worth UGX. 2,423,640,138 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.2,041,524,555; delayed submission of quarterly monitoring reports to OPM & MoFPED; partial implementation of planned activities and under performance of funds meant for maintenance worth UGX. 7,252,593 \uf0b7 The DLG mischarged expenditure worth UGX. 476,473,064 on wrong budget lines \uf0b7 I however noted that UGX. 2,521,572 was paid as residual arrears to 10 staff and 2 pensioners who had not been verified (and thus not part of schedule) by MoFPED.", null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 406, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "394", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 406, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that 2 employees were paid a total of UGX. 7,461,459 without signed pay change reports. \uf0b7 I noted that the DLG did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted outstanding payables worth UGX. 1,239,952,064.", null, null], ["03", "TORORO DLG", "\uf0b7 I noted a number of anomalies during review of the DLG pension"], ["", "", "& salary payrolls such as; Failure to submit wage estimates to"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 407, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["\uf0b7 I noted that 2 employees were paid a total of UGX. 7,461,459 without signed pay change reports. \uf0b7 I noted that the DLG did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted outstanding payables worth UGX. 1,239,952,064.", null, null], ["03", "TORORO DLG", "\uf0b7 I noted a number of anomalies during review of the DLG pension"], ["", "", "& salary payrolls such as; Failure to submit wage estimates to"], [null, "OPINION: UNQUALIFIED", "MoPs, over payment of salaries worth UGX.4,068,031;"], [null, null, "Underpayment of salaries worth UGX.15,716,191 and payment of"], [null, "", "salaries worth UGX.57,446,500 to staffs that was no longer in"], [null, null, "service accrued pension worth UGX.47,240,461"], [null, null, ""], [null, null, "\uf0b7 I noted an over and under remittance of employee salary"], [null, null, "deductions worth UGX.6,208,787"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by one hundred seventeen (117) new employees; failure to"], [null, null, "utilize wage funds of UGX.2.18 Bn, un-deducted PAYE from"], [null, null, "political leaders\u2019 gratuity resulting in unpaid tax of UGX."], [null, null, "11,370,060 and payment of four (4) staffs worth UGX 3,683,801"], [null, null, "off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; failure to quantify planned output;"], [null, null, "partial and non- implementation of planned activities; under"], [null, null, "absorption of funds worth UGX. 2,597,410,656 that was swept"], [null, null, "back to consolidated fund account; under performance of the"], [null, null, "donor & releases from other government units worth UGX."], [null, null, "11.87Bn."], [null, null, ""], [null, null, "\uf0b7 The DLG mischarged expenditure worth UGX.45,068,279 on"], [null, null, "wrong budget lines."], [null, null, ""], [null, null, "\uf0b7 I noted that the DLG did not prepare monthly wage, pension and"], [null, null, "gratuity performance analysis reports and did not submit"], [null, null, "quarterly returns on payroll to MoPS"], [null, null, ""], [null, null, "\uf0b7 I noted payables worth UGX.335, 571,661 outstanding at year"], [null, null, "end."], ["04 MBALE CITY OPINION: Unqualified \uf0b7 I noted a number of anomalies during review of the city pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salary and pension worth UGX.810,144,208; Underpayment of salary and pension worth UGX.915,374,687; Wrong computation of salaries worth net overpayment of UGX.91,569,052; payment of salaries worth UGX 30,376,995 to twenty six (26) staffs that were no longer in service and irregular deduction of loan instalments of one hundred seventeen (117) worth UGX. 159,385,584. \uf0b7 I noted receivables from other UWEP, YLP and other debtors", null, null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 407, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "395", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 407, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["worth UGX. 2,239,688,779 by the close of the financial year under review. \uf0b7 I noted outstanding payables worth UGX 545,408,158 at the end of the financial year. \uf0b7 The city did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 Additionally, I observed failure to utilize wage funds of UGX. 1,235,588,920; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.3,015,540and payment of staffs and pensioners worth UGX.161,000,660 off the IPPS; unpaid salaries worth UGX.161,000,660; payment of consolidated health lunch allowance to ineligible staff worth UGX.2,170,750 and a net over payment of arrears of UGX.64,535,832 \uf0b7 I noted an over and under deduction of loans worth UGX.13,477,848 and UGX.14,453,773 respectively \uf0b7 I noted that the city did not prepare monthly wage, pension and gratuity performance analysis and did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial and unquantified planned output, partial and non-implemented planned output ; shoddy works on Nambozo road incomplete works on Nambozo road; under absorption of funds worth UGX.1,600,759,501 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.3.17Bn; over absorption of funds worth UGX 73,268,000 \uf0b7 The city mischarged expenditure worth UGX 65,785,703 on wrong budget line \uf0b7 I noted non regular maintenance of street lights", null, null], ["05", "Bukwo DLG", "\uf0b7 I noted a number of anomalies during review of the DLG pension"], ["", "", "& salary payrolls such as; Failure to submit wage estimates to"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 408, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["worth UGX. 2,239,688,779 by the close of the financial year under review. \uf0b7 I noted outstanding payables worth UGX 545,408,158 at the end of the financial year. \uf0b7 The city did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 Additionally, I observed failure to utilize wage funds of UGX. 1,235,588,920; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.3,015,540and payment of staffs and pensioners worth UGX.161,000,660 off the IPPS; unpaid salaries worth UGX.161,000,660; payment of consolidated health lunch allowance to ineligible staff worth UGX.2,170,750 and a net over payment of arrears of UGX.64,535,832 \uf0b7 I noted an over and under deduction of loans worth UGX.13,477,848 and UGX.14,453,773 respectively \uf0b7 I noted that the city did not prepare monthly wage, pension and gratuity performance analysis and did not submit quarterly returns on payroll to MoPS. \uf0b7 I noted a number of issues in the implementation of the approved budget such as; partial and unquantified planned output, partial and non-implemented planned output ; shoddy works on Nambozo road incomplete works on Nambozo road; under absorption of funds worth UGX.1,600,759,501 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.3.17Bn; over absorption of funds worth UGX 73,268,000 \uf0b7 The city mischarged expenditure worth UGX 65,785,703 on wrong budget line \uf0b7 I noted non regular maintenance of street lights", null, null], ["05", "Bukwo DLG", "\uf0b7 I noted a number of anomalies during review of the DLG pension"], ["", "", "& salary payrolls such as; Failure to submit wage estimates to"], [null, "Opinion", "MoPs, Over payment of salary worth UGX.4,296,996;"], [null, "Unqualified", "Underpayment of salary, gratuity and pension worth"], [null, "", "UGX.16,337,404 and delayed deletion of 4 staff from the payroll"], [null, null, "worth UGX.9,328,845"], [null, null, ""], [null, null, "\uf0b7 I noted that the district did not prepare monthly wage, pension"], [null, null, "and gratuity performance analysis and thus did not submit"], [null, null, "quarterly returns on payroll to MoPS"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by 0ne (1) new employee and nine (2) pensioners; failure to"], [null, null, "utilize wage funds of UGX.0.568 billion; un-deducted PAYE from"], [null, null, "political leaders\u2019 gratuity resulting in unpaid tax of"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 408, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "396", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 408, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "UGX.11,064,570 over and under remittance of employee salary"], [null, "deductions worth UGX.1,789,798 and UGX.14,974,441"], [null, "respectively"], [null, ""], [null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, "approved budget such as; delayed works at the HCIIs; under"], [null, "absorption of funds worth UGX.2,421,073,740 that was swept"], [null, "back to consolidated fund account; under performance of the"], [null, "donor & releases from other government units worth"], [null, "UGX.6,333,457,050; partial and un quantified planned output"], [null, "and partial and un implemented planned output"], [null, ""], [null, "\uf0b7 The district did not prepare annual monitoring plans neither were"], [null, "quarterly monitoring reports prepared and submitted."], [null, ""], [null, "\uf0b7 I noted underperformance of budgeted funds for NUSAF-3"], [null, "projects worth UGX.183,000,000 and URF funds worth"], [null, "UGX.10,265,009 that affected implementation of the programs"], [null, ""], [null, "\uf0b7 I observed that the district lacked vital road equipment like an"], [null, "excavator, a bulldozer, a pedestrian roller and tampers/rammers."], [null, ""], [null, "\uf0b7 I noted an under absorption of funds worth UGX 1,005,458,204"], [null, "relating to construction of the college, secondary school and"], [null, "upgrading of HCIIs"], [null, ""], [null, "\uf0b7 The district lacked titles for 36 pieces of its land."], ["06 Sironko DLG Opinion Unqualified \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage estimates to MoPs, Over payment of salary worth UGX.3,937,076; Underpayment of salary worth UGX.9,336,463 delayed deletion of 3 staff from the payroll worth UGX.2,418,531 and 365 positions vacant \uf0b7 I noted residual arrear payments to one (1) pensioner who was not on the schedule worth UGX.25,856,920 \uf0b7 I noted outstanding receivables worth UGX.1, 395,021,574 and payables worth UGX.1, 271,747,912 by the end of the year. \uf0b7 Additionally, I observed that there was delayed access to payroll by nineteen (19) new employees and two (2) pensioners; un- deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX.13,980,570 over/under remittance of employee salary deductions worth UGX.12,620,619 and UGX.18,207,521 respectively \uf0b7 The district did not have an approved strategic plan that is aligned to the NDP-III at the time of audit \uf0b7 I noted partial and unquantified planned output, partial and non- implemented planned output", null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 409, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "397", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 409, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted issues in the implementation of the approved budget such as; delayed works at Buyobo Health Centre, Buteeza/Bumirisa Seed Secondary School; under performance of the donor & releases from other government units worth UGX.31,073,887; \uf0b7 The district lacked land tittles for 14 of its properties \uf0b7 I noted that the district did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted Un recovered YLP/Women groups funds worth UGX 1,076,861,319", null, null], ["07", "Namisidwa DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 410, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["\uf0b7 I noted issues in the implementation of the approved budget such as; delayed works at Buyobo Health Centre, Buteeza/Bumirisa Seed Secondary School; under performance of the donor & releases from other government units worth UGX.31,073,887; \uf0b7 The district lacked land tittles for 14 of its properties \uf0b7 I noted that the district did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted Un recovered YLP/Women groups funds worth UGX 1,076,861,319", null, null], ["07", "Namisidwa DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Failure to submit wage"], [null, "Opinion", "estimates to MoPs, payment of salaries worth UGX.9,737,931 to"], [null, "UnQualified", "twelve (12) staffs that were no longer in service over/under"], [null, "", "remittances of employee salary deductions worth"], [null, null, "UGX.15,456,000 and UGX.9,368,000 respectively"], [null, null, ""], [null, null, "\uf0b7 Additionally, I observed that there was delayed access to payroll"], [null, null, "by eleven (11) pensioners; failure to utilize wage funds of"], [null, null, "UGX.1.8 billion; un-deducted PAYE from political leaders\u2019 gratuity"], [null, null, "resulting in unpaid tax of UGX.10,343,040 and payment of"], [null, null, "twenty twelve (12) staffs worth UGX.44,528,289 off the IPPS"], [null, null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; Failure to Construct Namboko Seed"], [null, null, "Secondary School ; delayed works of Mukoto Seed Secondary"], [null, null, "School ; under absorption of funds worth UGX.1,965,728,111"], [null, null, "that was swept back to consolidated fund account; under"], [null, null, "performance of the donor & releases from other government"], [null, null, "units worth UGX.639,520,961; delayed submission of quarterly"], [null, null, "monitoring reports to OPM & MoFPED; Un implemented"], [null, null, "procurement plan worth UGX 2,601,160,000 and"], [null, null, "Underperformance of maintenance funds worth UGX.27,667,500."], [null, null, ""], [null, null, "\uf0b7 District received off-budget financing worth UGX.153,248,760"], [null, null, "directly from Ministry of Health (MoH)"], [null, null, ""], [null, null, "\uf0b7 I noted outstanding receivables worth UGX 1,380,786,175"], [null, null, ""], [null, null, "\uf0b7"], [null, null, "\uf0b7 The entity did not prepare and submit the annual monitoring"], [null, null, "plans to Moped, MoLG and NPA as required."], [null, null, "\uf0b7 I noted Underperformance of UWEP/YLP funds worth of"], [null, null, "UGX.170,000,000"], [null, null, "\uf0b7 I noted district land lacked titles"], ["08 Bududa DLG \uf0b7 I noted a number of anomalies during review of the district pension & salary payrolls such as; Failure to submit wage", null, null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 410, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "398", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 410, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["Opinion Unqualified estimates to MoPs, over payment of salary worth UGX. 40,955,029 Underpayment of salary due to wrong salary scales worth UGX 1,770,196 and Wrong computation of gratuity worth net overpayment of UGX. 16,342,974; \uf0b7 I noted payment to twelve (12) employees without signed pay change reports worth UGX. 33,563,249 \uf0b7 Additionally, I observed that there was; failure to utilize wage funds of UGX.0.386 billion; un-deducted PAYE from political leaders\u2019 gratuity resulting in unpaid tax of UGX. 25,271,520; over/under remittance of employee salary deductions wort UGX. 374,322,700 and UGX. 2,544,986 respectively and residual arrears to 10 staff and 5 pensioners (not part of schedule) worth UGX. 53,269,453 \uf0b7 I noted a number of issues in the implementation of the approved budget such as; incomplete works on five Community Access Roads (CARs); under absorption of funds worth UGX. 3,358,629,901 that was swept back to consolidated fund account; under performance of the donor & releases from other government units worth UGX.12,509,500; Under performance of maintenance funds worth UGX. 2,807,020 and un implemented procurement plan worth UGX.357,489,000 \uf0b7 I noted an under absorption of preliminary expenditures worth UGX 327,911,000 \uf0b7 I noted partial and non-implemented planned output \uf0b7 The district mischarged expenditure worth UGX. 53,269,453 on wrong budget lines. \uf0b7 It was noted that the district did not conduct revenue assessment. \uf0b7 I noted that the lacked District signed MOUs for Donor funds received during the year worth UGX. 25,203,300 from United Nations Children Fund (UNICEF) and World Health Organization (WHO).", null, null], ["09", "KIBUKU DLG", "\uf0b7 I noted a number of anomalies during review of the district"], ["", "", "pension & salary payrolls such as; Underpayment of pension"], [null, "Opinion", "worth UGX.97,316,845.; payment of salaries worth"], [null, "Unqualified", "UGX.7,336,993 to fourteen (14) staffs that was no longer in"], [null, "", "service and over remittance of employee salary deductions"], [null, null, "UGX.430,578,979"], [null, null, ""], [null, null, "\uf0b7 I noted outstanding payables worth UGX 128,739,122 at year"], [null, null, "end."], [null, null, ""], [null, null, "\uf0b7 I observed that there was delayed access to payroll by twenty-"], [null, null, "seven (27) new employees and nineteen (19) pensioners and"], [null, null, "420 vacant staff positions"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 411, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "399", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 411, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", null, ""], [null, null, "\uf0b7 I noted a number of issues in the implementation of the"], [null, null, "approved budget such as; I noted partial and unquantified"], [null, null, "planned output, partial and non-implemented planned output;"], [null, null, "under absorption of funds worth UGX 5,639,972,053 that was"], [null, null, "swept back to consolidated fund account; under performance of"], [null, null, "the donor & releases from other government units worth"], [null, null, "UGX.789,212,932 and failed submission of quarterly monitoring"], [null, null, "reports to OPM & MoFPED"], [null, null, ""], [null, null, "\uf0b7 The district mischarged expenditure worth UGX.47,252,328 on"], [null, null, "wrong budget lines"], [null, null, ""], [null, null, "\uf0b7 I noted that Kibuku Health Centre IV experienced drug stock outs"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity failed to procure assorted medical"], [null, null, "equipment for upgraded HCs worth UGX.210,937,500"], [null, null, ""], [null, null, "\uf0b7 I noted that the entity failed to conduct pre-bid meetings for 23"], [null, null, "contracts as provided for in the tender documents"], [null, null, "\uf0b7 I noted unrecovered funds from Women groups worth"], [null, null, "UGX.522,692,690"], ["ARUA BRANCH Summary of Key Findings", null, null], ["01.", "Obongi DLG", "\uf0b7 I reviewed funds absorption and noted that UGX.4.6 billion (100%) was spent out of the total receipts of UGX.5.9 billion,"], ["", "", null], [null, "Opinion", null], [null, "Unqualified", "resulting in an unabsorbed balance of UGX.1.3 billion. The unabsorbed balance was subsequently swept back to the"], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 412, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "400", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 412, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "following;"], [null, "\uf0b7 The Entity budgeted to receive UGX.17,548,360,000 as transfers"], [null, "from other Government Units. However, only"]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 413, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": [["", "following;"], [null, "\uf0b7 The Entity budgeted to receive UGX.17,548,360,000 as transfers"], [null, "from other Government Units. However, only"], [null, "UGX.14,007,769,263 (80%) was received. The Accounting Officer"], [null, "explained that low Local Revenue performance was due to the"], [null, "effects of COVID 19 lockdown that affected the performance of"], [null, "markets and secondly the disaster of floods impacted negatively"], [null, "on our major source of revenue, fisheries where most landing"], [null, "sites were flooded."], [null, "\uf0b7 The Entity budgeted to receive UGX.17,548,360,000 as transfers"], [null, "from other Government Units. However, only"], [null, "UGX.14,007,769,263 (80%) was received. The Accounting Officer"], [null, "explained that The under-performance of other government"], [null, "transfers was due to low performance of DRDIP. The funding for"], [null, "DRDIP was only for approved sub projects which were generated"], [null, "by the beneficiary groups."], [null, "\uf0b7 The District budgeted to receive UGX. 655,424,300 as"], [null, "external/donor financing out of which UGX.630,174,440 (96 %),"], [null, "was receivedThe Accounting Officer explained that External"], [null, "Financing performed very well up to 96% and all planned"], [null, "activities were implemented as planned. The difference of only"], [null, "4% has had no impact the implementation of the planned"], [null, "activities"], [null, "\uf0b7 Out of the total receipts for the financial year of"], [null, "UGX.27,315,767,447, UGX.42,423,071,166 (92%) was spent by"], [null, "the entity resulting in an unspent balance of UGX."], [null, "22,056,617,661 (81%). The unspent balance at the end of the"], [null, "financial year was subsequently swept back to the consolidated"], [null, "fund account. I advised the Accounting Officer to ensure that"], [null, "funds for these activities are in subsequent year un implemented"], [null, "activities rolled over and subsequently ensure the speedy"], [null, "implementation."], [null, "\uf0b7 I noted that the District received a total of UGX.22,103,714 as"], [null, "capitation grant. I reviewed the bank statements sampled"], [null, "schools and noted that the funds were still on the school"], [null, "accounts by 30th September, 2021 and had hence not been"], [null, "utilized. I advised the Accounting Officer to liaise with relevant"], [null, "authorities and ensure that these funds are put to productive"], [null, "usage."], ["02\\. ZOMBO DLG Opinion Unqualified \uf0b7 I reviewed funds absorption and noted that UGX.12.35 billion (81.78%) was spent out of the total receipts of UGX.15.1 billion, resulting in an unabsorbed balance of UGX.2.75 billion. The unabsorbed balance was subsequently swept back to the consolidated fund account. \uf0b7 A comparison of base pay in the IPPS payroll registers with the salary structure for 2020/21, revealed that 23 staff were paid", null]], "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}], "page": 413, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "of UGX. 1,073,044,082 more than the amount warrantied by"], "type": "table"}}, {"content": "401 \nusing wrong salary scales, leading to under payments of UGX \n0.932 million, contrary to Section B\u2013a (6) & (7) of the Uganda \nPublic Service Standing Orders, 2010. \n\uf0b7 I noted that UGX.20,116,483 was paid to 12 staff who had either retired, transferred, absconded or died. I advised the Accounting Officer to ensure prompt removal of staff from the \npayroll.", "metadata": {"headings": [{"headings_0": {"content": "warranties in the statement of appropriation of Ugx. 848,098,183, Actual in the statement of appropriation and note 5", "page": 399, "level": 3}}, [{"headings_0": {"content": "using wrong salary scales, leading to under payments of UGX", "page": 414, "level": 3}}], [{"headings_0": {"content": "using wrong salary scales, leading to under payments of UGX", "page": 414, "level": 3}}], [{"headings_0": {"content": "Public Service Standing Orders, 2010.", "page": 414, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.20,116,483 was paid to 12 staff who had either retired, transferred, absconded or died. I advised the Accounting Officer to ensure prompt removal of staff from the", "page": 414, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.20,116,483 was paid to 12 staff who had either retired, transferred, absconded or died. I advised the Accounting Officer to ensure prompt removal of staff from the", "page": 414, "level": 3}}]], "page": 413, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.3,328,551,409 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.20,116,483 was paid to 12 staff who had either retired, transferred, absconded or died. I advised the Accounting Officer to ensure prompt removal of staff from the", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nemployees\u2019 salaries to be remitted to different beneficiaries, UGX.3,319,064,736 was remitted, leading to an over and/or \nunder remittance amounting to UGX.7,357,520 and UGX \n6,415,791 respectively. The Accounting Officer explained that the \nunderpayment would be paid during subsequent remittances. \n\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX 680 million. The deductions were from 461 \nemployees that neither had letters of undertaking nor existed in \nthe \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the \nPDMS-Payroll Deduction Management System, operated by PCA- Payroll Consults Africa. \n\uf0b7 I noted that 13 newly recruited/ transferred employees delayed \nto access payroll, with delays ranging between 1-2 months. \nDelayed access to payroll leads to demotivation of the affected \nstaff and accumulation of salary arrears. \n\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to \nthe pension payroll leads to poor wellbeing of the affected retirees as well as accumulation of pension arrears. \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.20,116,483 was paid to 12 staff who had either retired, transferred, absconded or died. I advised the Accounting Officer to ensure prompt removal of staff from the", "page": 414, "level": 3}}, [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.3,319,064,736 was remitted, leading to an over and/or", "page": 414, "level": 2}}], [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.3,319,064,736 was remitted, leading to an over and/or", "page": 414, "level": 2}}], [{"headings_0": {"content": "6,415,791 respectively. The Accounting Officer explained that the", "page": 414, "level": 3}}], [{"headings_0": {"content": "6,415,791 respectively. The Accounting Officer explained that the", "page": 414, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX 680 million. The deductions were from 461", "page": 414, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX 680 million. The deductions were from 461", "page": 414, "level": 3}}], [{"headings_0": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 414, "level": 2}}], [{"headings_0": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 414, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I noted that 13 newly recruited/ transferred employees delayed", "page": 414, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 13 newly recruited/ transferred employees delayed", "page": 414, "level": 3}}], [{"headings_0": {"content": "Delayed access to payroll leads to demotivation of the affected", "page": 414, "level": 3}}], [{"headings_0": {"content": "Delayed access to payroll leads to demotivation of the affected", "page": 414, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "page": 414, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "page": 414, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "page": 414, "level": 3}}]], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that there were variances of UGX.263,261,431", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that one pensioner; Okenga Abedican delayed to access the pension payroll, with delays of 31 days. Delayed access to", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "between the figures in the MoPS IPPS and district payroll registers. I advised the Accounting Officer to ensure that the district IPPS payroll registers are consistent with MoPS payroll \ndata. \n", "metadata": {"headings": [{"headings_0": {"content": "between the figures in the MoPS IPPS and district payroll registers. I advised the Accounting Officer to ensure that the district IPPS payroll registers are consistent with MoPS payroll", "page": 414, "level": 3}}, [{"headings_0": {"content": "between the figures in the MoPS IPPS and district payroll registers. I advised the Accounting Officer to ensure that the district IPPS payroll registers are consistent with MoPS payroll", "page": 414, "level": 3}}], [{"headings_0": {"content": "between the figures in the MoPS IPPS and district payroll registers. I advised the Accounting Officer to ensure that the district IPPS payroll registers are consistent with MoPS payroll", "page": 414, "level": 3}}]], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- Included in the Statement of Financial Position on page 7 of the Financial Statements are receivables worth UGX.485,694,634 as", "metadata": {"headings": [{"headings_0": {"content": "between the figures in the MoPS IPPS and district payroll registers. I advised the Accounting Officer to ensure that the district IPPS payroll registers are consistent with MoPS payroll", "page": 414, "level": 3}}], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "supported by Note 19 to the financial statements. The amount for the previous financial year was UGX.193,836,559. The amounts relate to advances to Youth and Women Interest groups. I advised the Accounting Officer to continue sensitizing Youth Interest Groups and women groups to recover the funds. \n\uf0b7 I noted that the District had deposits worth UGX.396,301,510 presented in the Statement of Financial Position and disclosed in note 25 to the financial statements. The figure increased by \nUGX.4,000,000 from UGX.394,301,510 which were recoveries of \nthe Youth Livelihood Programme (YLP) as recommended by \nInspectorate of Government. \n\uf0b7 I noted that though the district had prepared the Strategic plan, \n402 \nit was still in draft form at the time of audit and certification from \nNPA had not been obtained. I advised the Accounting Officer to liaise with NPA to expedite the process of reviewing and approval \nthe Strategic Plan of the District. \n\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect \nUGX.1,040,800,000 during the year but collected UGX.296,535,563 representing (29%) performance. The \nshortfalls in Local Revenue collections of UGX.744,264,437 (71%) were recorded in Local Service Tax, Land Fees , Business Licence, other tax revenues, administrative fees and Application Fees.", "metadata": {"headings": [{"headings_0": {"content": "supported by Note 19 to the financial statements. The amount for the previous financial year was UGX.193,836,559. The amounts relate to advances to Youth and Women Interest groups. I advised the Accounting Officer to continue sensitizing Youth Interest Groups and women groups to recover the funds.", "page": 414, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that the District had deposits worth UGX.396,301,510 presented in the Statement of Financial Position and disclosed in note 25 to the financial statements. The figure increased by", "page": 414, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District had deposits worth UGX.396,301,510 presented in the Statement of Financial Position and disclosed in note 25 to the financial statements. The figure increased by", "page": 414, "level": 3}}], [{"headings_0": {"content": "the Youth Livelihood Programme (YLP) as recommended by", "page": 414, "level": 3}}], [{"headings_0": {"content": "the Youth Livelihood Programme (YLP) as recommended by", "page": 414, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that though the district had prepared the Strategic plan,", "page": 414, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that though the district had prepared the Strategic plan,", "page": 414, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that though the district had prepared the Strategic plan,", "page": 414, "level": 3}}], [{"headings_0": {"content": "NPA had not been obtained. I advised the Accounting Officer to liaise with NPA to expedite the process of reviewing and approval", "page": 415, "level": 3}}], [{"headings_0": {"content": "NPA had not been obtained. I advised the Accounting Officer to liaise with NPA to expedite the process of reviewing and approval", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 415, "level": 3}}], [{"headings_0": {"content": "shortfalls in Local Revenue collections of UGX.744,264,437 (71%) were recorded in Local Service Tax, Land Fees , Business Licence, other tax revenues, administrative fees and Application Fees.", "page": 415, "level": 3}}]], "page": 414, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- The District budgeted to receive UGX. 1,426,989,000 as external/donor financing out of which UGX.1,304,944 (0.09%), was received.", "metadata": {"headings": [{"headings_0": {"content": "shortfalls in Local Revenue collections of UGX.744,264,437 (71%) were recorded in Local Service Tax, Land Fees , Business Licence, other tax revenues, administrative fees and Application Fees.", "page": 415, "level": 3}}], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n\uf0b7 Out of the total receipts for the financial year of \nUGX.28,843,895,403, UGX.25,055,771,226 (97%) was spent by the district resulting in an unspent balance of \nUGX.3,788,124,204. The unspent balance at the end of the \nfinancial year was subsequently swept back to the consolidated fund account. \n\uf0b7 I noted that the district prepared annual monitoring plans dated 02/08/2021, but had not been submitted to MoFPED, MoLG and NPA as required by the time of audit (10/09/2021). Further, the \ndistrict had not also submitted quarterly monitoring reports to the Office of the Prime Minister and MoFPED as required by the \ntime of audit (10/09/2021). This practice is not only in \ncontravention of the circular instructions but also hinders efforts of timely monitoring of the implementation of the budget. \n\uf0b7 I noted that management submitted performance reports for Q1 \nand Q2 in time while performance reports for Q3 and Q4 were submitted after deadline given for submission of the reports. \n\uf0b7 In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which \nare important in ensuring that the budget performs as expected. \n\uf0b7 I noted delayed completion of Construction of Atyak Seed Secondary School under the UGIFT project, A joint supervision \nreport dated 18/5/2021 was reviewed and put the work so far done at only 66% and cumulative total payments had been made \nof UGX 1,365,729,024 ( representing 65% of the contract sum) by end of year. By the time of the audit in September 2021, \nabout 5% of the works were still incomplete yet the contract had long expired. \n\uf0b7 I noted that the District received a total of UGX.154,269,648. I \nreviewed the bank statements for sampled schools and noted that the funds were still on the schools\u2019 accounts by 30th \n403", "metadata": {"headings": [{"headings_0": {"content": "shortfalls in Local Revenue collections of UGX.744,264,437 (71%) were recorded in Local Service Tax, Land Fees , Business Licence, other tax revenues, administrative fees and Application Fees.", "page": 415, "level": 3}}, [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 415, "level": 3}}], [{"headings_0": {"content": "UGX.3,788,124,204. The unspent balance at the end of the", "page": 415, "level": 3}}], [{"headings_0": {"content": "UGX.3,788,124,204. The unspent balance at the end of the", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district prepared annual monitoring plans dated 02/08/2021, but had not been submitted to MoFPED, MoLG and NPA as required by the time of audit (10/09/2021). Further, the", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district prepared annual monitoring plans dated 02/08/2021, but had not been submitted to MoFPED, MoLG and NPA as required by the time of audit (10/09/2021). Further, the", "page": 415, "level": 3}}], [{"headings_0": {"content": "time of audit (10/09/2021). This practice is not only in", "page": 415, "level": 3}}], [{"headings_0": {"content": "time of audit (10/09/2021). This practice is not only in", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that management submitted performance reports for Q1", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that management submitted performance reports for Q1", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted delayed completion of Construction of Atyak Seed Secondary School under the UGIFT project, A joint supervision", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted delayed completion of Construction of Atyak Seed Secondary School under the UGIFT project, A joint supervision", "page": 415, "level": 3}}], [{"headings_0": {"content": "of UGX 1,365,729,024 ( representing 65% of the contract sum) by end of year. By the time of the audit in September 2021,", "page": 415, "level": 3}}], [{"headings_0": {"content": "of UGX 1,365,729,024 ( representing 65% of the contract sum) by end of year. By the time of the audit in September 2021,", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}]], "page": 415, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["September, 2021 and had hence not been utilised.", null, null], ["03.", "YUMBE DLG", "\uf0b7 I reviewed payroll funds absorption and noted that UGX.22 billion (94%) was spent out of the total receipts of UGX.23.5 billion,"], ["", "", null], [null, "Opinion", null], [null, "Unqualified", "resulting in an unabsorbed balance of UGX.1.44 billion. The unabsorbed balance was subsequently swept back to the"], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}], "page": 416, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "404 \ncomputing PAYE. \n\uf0b7 I noted that 20 pensioners delayed to access the pension payroll, with delays ranging between 4.5 months. I advised the Accounting Officer to ensure that pensioners promptly access the \npayroll and are subsequently paid. \n\uf0b7 I noted that 16 employees were paid a total of UGX.52 million without signed pay change reports. This affects the \nintegrity/credibility of the payroll and creates an avenue for payroll abuse. \n\uf0b7 I noted that the District did not prepare monthly wage, pension \nand gratuity performance analysis and thus did not submit \nquarterly returns on payroll to MoPS, contrary to Paragraph 2.1 \nof Establishment Notice No. 1 of 2020. The Accounting Officer took note of the observation and stated that action has been initiated during Q1 of the FY 2021/22. \n\uf0b7 A comparison of the payroll register and IFMS payment file, I noted that 3 pensioners were paid a total of UGX.75,420,453 off the IPPS. The Accounting Officer explained that Pension and \ngratuity arrears had their schedule of payment; therefore, they would not be paid through IPPS. \n\uf0b7 I noted that the district had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit. I advise Management to urgently prepare and have approved a strategic plan that is aligned to NDP-III to facilitate the \nachievement of the NDP objectives. \n\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect \nUGX. 663,494,100 during the year but collected UGX.445,457,586 representing (67%) performance. I advised the \nAccounting Officer to always ensure that NTR is collected as \nbudgeted. \n\uf0b7 The District budgeted to receive UGX.54,077,677,212 (revised) as grants from the Treasury. I noted that, UGX.48,328,375,344 \nwas warranted/ received representing 89% performance. \n\uf0b7 The District budgeted to receive UGX.38,231,319,640 as \ntransfers from other Government Units. However, only UGX.23,692,222,658 (62%) was received. \n\uf0b7 The District budgeted to receive UGX.5,980,183,220 as \nexternal/donor financing out of which UGX.2,031,658,591 (34%), was received. \n\uf0b7 Out of the total receipts for the financial year of \nUGX.74,531,220,778, UGX.57,130,020,926 (76.6%) was spent by the district resulting in an unspent balance of \nUGX.17,401,199,852 (23.4%). The unspent balance at the end of \nthe financial year was subsequently swept back to the \n405", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that the District received a total of UGX.154,269,648. I", "page": 415, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 20 pensioners delayed to access the pension payroll, with delays ranging between 4.5 months. I advised the Accounting Officer to ensure that pensioners promptly access the", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 20 pensioners delayed to access the pension payroll, with delays ranging between 4.5 months. I advised the Accounting Officer to ensure that pensioners promptly access the", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 16 employees were paid a total of UGX.52 million without signed pay change reports. This affects the", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 16 employees were paid a total of UGX.52 million without signed pay change reports. This affects the", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 417, "level": 3}}], [{"headings_0": {"content": "quarterly returns on payroll to MoPS, contrary to Paragraph 2.1", "page": 417, "level": 3}}], [{"headings_0": {"content": "quarterly returns on payroll to MoPS, contrary to Paragraph 2.1", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 A comparison of the payroll register and IFMS payment file, I noted that 3 pensioners were paid a total of UGX.75,420,453 off the IPPS. The Accounting Officer explained that Pension and", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 A comparison of the payroll register and IFMS payment file, I noted that 3 pensioners were paid a total of UGX.75,420,453 off the IPPS. The Accounting Officer explained that Pension and", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit. I advise Management to urgently prepare and have approved a strategic plan that is aligned to NDP-III to facilitate the", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district had not prepared and approved a strategic plan that is aligned to the NDP-III at the time of audit. I advise Management to urgently prepare and have approved a strategic plan that is aligned to NDP-III to facilitate the", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 417, "level": 3}}], [{"headings_0": {"content": "Accounting Officer to always ensure that NTR is collected as", "page": 417, "level": 3}}], [{"headings_0": {"content": "Accounting Officer to always ensure that NTR is collected as", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.54,077,677,212 (revised) as grants from the Treasury. I noted that, UGX.48,328,375,344", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.54,077,677,212 (revised) as grants from the Treasury. I noted that, UGX.48,328,375,344", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.38,231,319,640 as", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.38,231,319,640 as", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.5,980,183,220 as", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.5,980,183,220 as", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 417, "level": 3}}], [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}], [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}], [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}]], "page": 416, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "consolidated fund account. I advised the Accounting Officer to"], [null, "ensure that the rolled over activities are given priority during"], [null, "implementation."]], "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}], "page": 418, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", "consolidated fund account. I advised the Accounting Officer to"], [null, "ensure that the rolled over activities are given priority during"], [null, "implementation."], [null, "\uf0b7 I noted that Management submitted performance reports for Q2,"], [null, "Q3 and Q4 after the deadline. In addition, I did not obtain"], [null, "evidence to confirm that the Accounting Officer Prepared"], [null, "Monitoring Plans and reports which are important in ensuring"], [null, "that the budget performs as expected."], [null, "\uf0b7 Contrary to Section 34 (1) of the Public Finance Management Act"], [null, "2015, I observed the District constructed two (2) operating"], [null, "theaterstheatres worth UGX.666,903,480 at Ariwa Health Centre"], [null, "(HC) III and Baraka HC III in the financial year 2017/18 and"], [null, "were not functional and without operating equipment by close of"], [null, "audit. The unutilized operating theatre denies services to the"], [null, "community"], ["04\\. TEREGO DLG Opinion Unqualified \uf0b7 Terego District Local Government (DLG), being a newly created District curved out of Arua District, I noted that the payroll for the year under review was managed by Arua DLG. As a result, the pay roll analysis for Terego District was made under the audit of Arua DLG. \uf0b7 I, noted that although the district aligned its targets for the F/Y 2020/2021 with the DDPIII and NDPIII, the District strategic plan had not been approved. I advised the Accounting Officer to urgently prepare and approved a strategic plan that is aligned to NDP-III to facilitate the achievement of the NDP objectives \uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect UGX. 116,717,055 during the year but collected UGX.89,153,132 representing (76%) performance. The shortfalls in Local Revenue collections of UGX. UGX.27,563,923(24%) were recorded in Local Service Tax, Land Fees , Business Licence, other tax revenues, administrative fees and Application Fees. \uf0b7 The District budgeted to receive UGX. 23,749,241,508 (revised) as grants from the Treasury. I noted that, UGX. 1,894,332.444 was warranted/ received representing 8% performance. Revenue shortfalls affect the implementation of planned activities. \uf0b7 The Entity budgeted to receive UGX.4,406,498,162 as transfers from other Government Units. However, only UGX.4,006,498,162 (90%) was received. Revenue shortfalls affected the implementation of planned activities. \uf0b7 The District budgeted to receive UGX. 0.8Bn as external/donor financing out of which UGX. 0.4Bn (50%), was received. Revenue shortfalls affect the implementation of planned activities. The Accounting Officer explained that, for external financing the key donor projects funded by UNHCR and UNICEF use the calendar year for Budgeting and reporting as at the close", null]], "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}], "page": 418, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "406", "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}], "page": 418, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["of the financial year 2020/2021 their Budget release was only for the six months thus explaining the poor performance. \uf0b7 Out of the total receipts for the financial year of UGX. 6.5Bn, UGX. 5.9Bn (91%) was spent by the entity resulting in an unspent balance of UGX. 0.6 Bn (91%). The unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account. The funds were meant for activities that were not fully implemented by the end of the financial year and these include Salaries worth UGX.475,796,820. \uf0b7 During field Inspection carried out on service delivery areas at Yinga HC III, I observed the following; \uf0d8 Fridge for storage of blood donated by IRC and UNICEF was not installed consequently, cases of anaemia are referred to other facilities; \uf0d8 Motorised borehole that was installed by OXFAM had been disconnected for six months; \uf0d8 the piped water system installed at the facility had broken down for the period of six months; \uf0d8 As per interview of in-charge of the facility, the facility had not been supplied drugs for two quarters leading to drug stock-outs. This led to the referral of cases that would have been handled at the facility; \uf0d8 The generator that was donated to the HC has never been installed during the two years it has been at the facility \uf0b7 I reviewed of the governance structures of Terego DLG and noted that the district did not have a District Land Board in place. Consequently, the institutional land of the district was not titled. Further, there were reports of land disputes as seen in the Council Minutes dated 21st May 2021. \uf0b7 I reviewed the execution of the annual procurement plan of Terego district for the year under review revealed that projects worth UGX.740,372,862 were not executed in the year, hence hindering service delivery to the intended beneficiaries. \uf0b7 I reviewed the implementation of the DRDIP project in the district and observed that 16 beneficiary projects funded to the tune of UGX.1,620,066,939 had not yet been implemented. The Accounting Officer promised immediate action. I await the outcome of the Accounting Officers action.", null, null], ["05.", "NEBBI DLG", "\uf0b7 I noted that the District did not submit wage estimates to MoPS,"], ["", "", "as required. I advised the Accounting Officer to always submit"]], "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}], "page": 419, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "consolidated fund account. I advised the Accounting Officer to"], "type": "table"}}, {"content": [["of the financial year 2020/2021 their Budget release was only for the six months thus explaining the poor performance. \uf0b7 Out of the total receipts for the financial year of UGX. 6.5Bn, UGX. 5.9Bn (91%) was spent by the entity resulting in an unspent balance of UGX. 0.6 Bn (91%). The unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account. The funds were meant for activities that were not fully implemented by the end of the financial year and these include Salaries worth UGX.475,796,820. \uf0b7 During field Inspection carried out on service delivery areas at Yinga HC III, I observed the following; \uf0d8 Fridge for storage of blood donated by IRC and UNICEF was not installed consequently, cases of anaemia are referred to other facilities; \uf0d8 Motorised borehole that was installed by OXFAM had been disconnected for six months; \uf0d8 the piped water system installed at the facility had broken down for the period of six months; \uf0d8 As per interview of in-charge of the facility, the facility had not been supplied drugs for two quarters leading to drug stock-outs. This led to the referral of cases that would have been handled at the facility; \uf0d8 The generator that was donated to the HC has never been installed during the two years it has been at the facility \uf0b7 I reviewed of the governance structures of Terego DLG and noted that the district did not have a District Land Board in place. Consequently, the institutional land of the district was not titled. Further, there were reports of land disputes as seen in the Council Minutes dated 21st May 2021. \uf0b7 I reviewed the execution of the annual procurement plan of Terego district for the year under review revealed that projects worth UGX.740,372,862 were not executed in the year, hence hindering service delivery to the intended beneficiaries. \uf0b7 I reviewed the implementation of the DRDIP project in the district and observed that 16 beneficiary projects funded to the tune of UGX.1,620,066,939 had not yet been implemented. The Accounting Officer promised immediate action. I await the outcome of the Accounting Officers action.", null, null], ["05.", "NEBBI DLG", "\uf0b7 I noted that the District did not submit wage estimates to MoPS,"], ["", "", "as required. I advised the Accounting Officer to always submit"], [null, "Opinion", "wage estimates to MoPs by 30th September of the preceding"], [null, "Unqualified", "year."], [null, "", ""], [null, null, "\uf0b7 I reviewed funds absorption and noted that UGX.19,924,679,353"], [null, null, "(92%) was spent out of the total receipts of UGX."], [null, null, "21,572,885,359, resulting in an unabsorbed balance of UGX."], [null, null, "1,648,206,006. The unabsorbed balance was subsequently swept"]], "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}], "page": 419, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "consolidated fund account. I advised the Accounting Officer to"], "type": "table"}}, {"content": "407 \nback to the consolidated fund account hence denying the use of funds for other deserving service delivery areas. \n", "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}, [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}], [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}]], "page": 419, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.4,339,048,878 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "UGX.17,401,199,852 (23.4%). The unspent balance at the end of", "page": 417, "level": 3}}], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "employees\u2019 salaries to be remitted to different beneficiaries only, UGX.4,333,222,745 was remitted, leading to an over remittance \nof UGX.4,849,344 and under remittance of UGX.10,675,477. \n\uf0b7 I noted that the District made unauthorized loan deductions \ntotaling UGX.87,617,577. The deductions were from 78 employees that neither had letters of undertaking nor existed in \nthe \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the \nPDMS-Payroll Deduction Management System, operated by PCA- Payroll Consults Africa. \n\uf0b7 I compared the loan deductions in June 2021 on the IPPS payroll against the active deductions amounts on the Payroll Consults Africa (PCA) system and discovered that there were 160 instances where the amount on IPPS being deducted is either \nmore or less than the amount on the active deductions implying that there is a weakness in the system of loan deductions where many employees are either over paying for loans they picked or are underpaying. \n\uf0b7 In a sample of 14 teachers selected, I noted that the \ndistrict/votes were not affecting annual salary increments on \nemployee salaries. This may lead to demotivation of staff. \n\uf0b7 I noted that the district had not yet prepared a strategic plan at \nthe time of audit, I advised the Accounting Officer to ensure that the strategic plan is implemented upon approval. \n\uf0b7 I advised the Accounting Officer to ensure that the strategic plan is implemented upon approval. I advised the Accounting Officer to always ensure that NTR is collected as budgeted. The district budgeted to receive UGX.6, 748,502,080 as transfers from other Government Units. However, only UGX.1,325,146,185 (20%) was \nreceived. Revenue shortfalls affected the implementation of planned activities. \n\uf0b7 The district budgeted to receive UGX.2,213,127,500 as \nexternal/donor financing, out of which UGX.261,434,917 (12%), \nwas received. Revenue shortfalls affect the implementation of \nplanned activities. \n\uf0b7 District failed spent fund balance of UGX.681, 679,315 meant for Start of construction of Ndhew Seed Secondary School, Drilling of \nboreholes, and Payment of gratuity. \n\uf0b7 I noted that the district submitted performance reports for all the \nquarters after the deadlines given for submission of the reports, \nIn addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which \n408", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries only, UGX.4,333,222,745 was remitted, leading to an over remittance", "page": 420, "level": 2}}, [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries only, UGX.4,333,222,745 was remitted, leading to an over remittance", "page": 420, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "page": 420, "level": 3}}], [{"headings_0": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 420, "level": 2}}], [{"headings_0": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 420, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I compared the loan deductions in June 2021 on the IPPS payroll against the active deductions amounts on the Payroll Consults Africa (PCA) system and discovered that there were 160 instances where the amount on IPPS being deducted is either", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I compared the loan deductions in June 2021 on the IPPS payroll against the active deductions amounts on the Payroll Consults Africa (PCA) system and discovered that there were 160 instances where the amount on IPPS being deducted is either", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 In a sample of 14 teachers selected, I noted that the", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 In a sample of 14 teachers selected, I noted that the", "page": 420, "level": 3}}], [{"headings_0": {"content": "employee salaries. This may lead to demotivation of staff.", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district had not yet prepared a strategic plan at", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district had not yet prepared a strategic plan at", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I advised the Accounting Officer to ensure that the strategic plan is implemented upon approval. I advised the Accounting Officer to always ensure that NTR is collected as budgeted. The district budgeted to receive UGX.6, 748,502,080 as transfers from other Government Units. However, only UGX.1,325,146,185 (20%) was", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I advised the Accounting Officer to ensure that the strategic plan is implemented upon approval. I advised the Accounting Officer to always ensure that NTR is collected as budgeted. The district budgeted to receive UGX.6, 748,502,080 as transfers from other Government Units. However, only UGX.1,325,146,185 (20%) was", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The district budgeted to receive UGX.2,213,127,500 as", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The district budgeted to receive UGX.2,213,127,500 as", "page": 420, "level": 3}}], [{"headings_0": {"content": "was received. Revenue shortfalls affect the implementation of", "page": 420, "level": 3}}], [{"headings_0": {"content": "was received. Revenue shortfalls affect the implementation of", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 District failed spent fund balance of UGX.681, 679,315 meant for Start of construction of Ndhew Seed Secondary School, Drilling of", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 District failed spent fund balance of UGX.681, 679,315 meant for Start of construction of Ndhew Seed Secondary School, Drilling of", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district submitted performance reports for all the", "page": 420, "level": 3}}], [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}], [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}]], "page": 420, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["", "are essential in ensuring that the budget performs as expected."], [null, ""], [null, "\uf0b7 From my review of the annual performance report, I noted that"]], "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}], "page": 421, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", "are essential in ensuring that the budget performs as expected."], [null, ""], [null, "\uf0b7 From my review of the annual performance report, I noted that"], [null, "some outputs were not captured in the performance report,"], [null, "these included Purchase and supply of ICT Equipment for Atego"], [null, "Seed Secondary, and Purchase and supply of laboratory"], [null, "equipment to Atego Seed Secondary School."], [null, ""], [null, "\uf0b7 I noted that the District received a total of UGX.48,565,353. I"], [null, "reviewed the bank statements sampled schools and noted that"], [null, "the funds were still on the school accounts by 30th September,"], [null, "2021 and had hence not been utilized."], [null, ""], ["06\\. NEBBI MC Opinion Unqualified \uf0b7 I noted that the Municipal Council did not submit wage estimates to MoPs, as required. I advised the Accounting Officer to always submit wage estimates to MoPs by 30th September of the preceding year. \uf0b7 A review of the pension payroll data and IFMS payments, revealed variances between amounts on the payroll and payments to individual pensioners, leading to over payments of UGX. 4,584,882 contrary to article 254 (1) & (3) of the 1995 constitution (as amended). I further noted that there was an under payment of UGX.32,297,600 as well. The Accounting Officer acknowledged the shortcoming and promised future action. \uf0b7 A comparison of base pay in the Integrated Personnel and Payroll System (IPPS) payroll registers with the salary structure for 2020/21, revealed that 6 staff were paid using wrong salary scales, leading to over payments of UGX.3,190,260 contrary to Section B\u2013a (6) & (7) of the Uganda Public Service Standing Orders, 2010. \uf0b7 I noted that whereas UGX.722,140,725 was deducted from employees\u2019 salaries to be remitted to different beneficiaries, UGX.703,333,159 was remitted, leading to an under remittance of UGX.18,807,566. \uf0b7 I noted that the Municipal Council made unauthorized loan deductions totaling UGX.38,493,134. The deductions were from 24 employees that neither had letters of undertaking nor existed in the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll Deduction Management System, operated by Payroll Consults Africa (PCA). \uf0b7 I noted that the Municipal Council did not subject political leaders\u2019 gratuity totaling to UGX.10,962,600 to the computation of PAYE in IPPS, leading to an under deduction of UGX.3,288,780 contrary to section 19 (1) (a) of the Income Tax Act. \uf0b7 I noted that, there was minimal movement in receivables as only", null]], "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}], "page": 421, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "409", "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}], "page": 421, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["UGX.4,156,000 was recovered from the reported amount of UGX.528,709,420 previously, implying no significant effort was put into recovery. \uf0b7 I noted that the Municipal Council had not prepared and approved a strategic plan that is aligned to the NDP-III. \uf0b7 I noted budget underperformance of UGX.2,132,255,571 from government grants and local revenue which affected activity implementation \uf0b7 The municipality failed to spent funds worth UGX.522,335,106 and the unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account. \uf0b7 I noted that UGX.20,661,647 was charged on items which did not reflect the nature of the expenditure. I advised the Accounting Officer to always ensure that the correct codes are charged and seek approvals for any virement or reallocations", null, null], ["07.", "MARACHA DLG", "\uf0b7 I noted that the District did not submit wage estimates to MoPS,"], ["", "", "as required. I advised the Accounting Officer to always submit"]], "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}], "page": 422, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "are essential in ensuring that the budget performs as expected."], "type": "table"}}, {"content": [["UGX.4,156,000 was recovered from the reported amount of UGX.528,709,420 previously, implying no significant effort was put into recovery. \uf0b7 I noted that the Municipal Council had not prepared and approved a strategic plan that is aligned to the NDP-III. \uf0b7 I noted budget underperformance of UGX.2,132,255,571 from government grants and local revenue which affected activity implementation \uf0b7 The municipality failed to spent funds worth UGX.522,335,106 and the unspent balance at the end of the financial year was subsequently swept back to the consolidated fund account. \uf0b7 I noted that UGX.20,661,647 was charged on items which did not reflect the nature of the expenditure. I advised the Accounting Officer to always ensure that the correct codes are charged and seek approvals for any virement or reallocations", null, null], ["07.", "MARACHA DLG", "\uf0b7 I noted that the District did not submit wage estimates to MoPS,"], ["", "", "as required. I advised the Accounting Officer to always submit"], [null, "Opinion Unqualified", "wage estimates to MoPs by 30th September of the preceding"], [null, null, "year."], [null, "", ""], [null, null, "\uf0b7 I reviewed funds absorption and noted unabsorbed balance of"], [null, null, "UGX. 1.2 billion meant for payment mostly pensioners due to"], [null, null, "slow processing of pension benefits by the beneficiaries"], [null, null, ""], [null, null, "\uf0b7 A comparison of base pay in the IPPS payroll registers with the"], [null, null, "salary structure for 2020/21, revealed that 4 staff were paid"], [null, null, "using wrong salary scales, leading to over payments of"], [null, null, "UGX.25,197,900, and under payment of UGX.544,068 contrary to"], [null, null, "Section B\u2013a (6) & (7) of the Uganda Public Service Standing"], [null, null, "Orders, 2010. The Accounting Officer acknowledged the audit"], [null, null, "observation and promised to follow the audit recommendation."], [null, null, ""], [null, null, "\uf0b7 I noted that UGX.11, 634,613 was paid to 32 staff who had"], [null, null, "either retired, transferred, absconded or died. I advised the"], [null, null, "Accounting Officer to ensure prompt removal of staff from the"], [null, null, "payroll and recover payments of salaries to staff who have left"], [null, null, "active employment."], [null, null, ""], [null, null, "\uf0b7 I noted that whereas UGX3,361,569,932 was deducted from"], [null, null, "employees\u2019 salaries to be remitted to different beneficiaries,"], [null, null, "UGX3,358,721,257 was remitted, leading to an over remittance"], [null, null, "of UGX.6,609,552 and under remittance of UGX.9,458,227, I"], [null, null, "advised the Accounting Officer to reconcile IPPS deductions"], [null, null, "against IFMS remittances and recover the over remittances and"], [null, null, "pay the under remittances."], [null, null, ""], [null, null, "\uf0b7 I noted that the District made unauthorized loan deductions"], [null, null, "totaling UGX.100.4 million. The deductions were from 93"], [null, null, "employees that neither had letters of undertaking nor existed in"]], "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}], "page": 422, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "are essential in ensuring that the budget performs as expected."], "type": "table"}}, {"content": "410", "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}], "page": 422, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "", "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the"], [null, null, "PDMS-Payroll Deduction Management System, operated by PCA-"], [null, null, "Payroll Consults Africa."]], "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}], "page": 423, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": [["", "", "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the"], [null, null, "PDMS-Payroll Deduction Management System, operated by PCA-"], [null, null, "Payroll Consults Africa."], [null, null, ""], [null, null, "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity"], [null, null, "totaling to UGX.37,848,204 to the computation of PAYE in IPPS,"], [null, null, "leading to an under deduction of UGX.11,377,861, contrary to"], [null, null, "section 19(1) (a) of the Income Tax Act."], [null, null, ""], [null, null, "\uf0b7 I noted that the District did not prepare monthly wage, pension"], [null, null, "and gratuity performance analysis and thus did not submit"], [null, null, "quarterly returns on payroll to MoPS, contrary to Paragraph 2.1"], [null, null, "of Establishment Notice No. 1 of 2020."], [null, null, ""], [null, null, "\uf0b7 I noted that 3 staff were paid a total of UGX.15 Million off the"], [null, null, "IPPS. I advised the Accounting Officer to ensure that salaries,"], [null, null, "pension and gratuity is processed and paid through the IPPS."], [null, null, ""], [null, null, "\uf0b7 I noted that the strategic plan of Maracha District was still not"], [null, null, "approved and therefore it was still in draft form."], [null, null, ""], [null, null, "\uf0b7 I reviewed the approved Local revenue estimates for the financial"], [null, null, "year 2020/2021 and noted that the District budgeted to collect"], [null, null, "UGX.215,093,000 during the year but collected UGX.143,"], [null, null, "183,859 representing (66.6%) performance. The shortfalls in"], [null, null, "Local Revenue collections of UGX.71,909,141 (33.4%) were"], [null, null, "recorded in Land fees, business licenses, other tax revenues and"], [null, null, "Administrative fees and licenses. Revenue shortfalls affected the"], [null, null, "implementation of planned activities."], [null, null, ""], [null, null, "\uf0b7 The Entity budgeted to receive UGX. 8, 429,617,471 as transfers"], [null, null, "from other Government Units. However, only UGX. 139, 292,268"], [null, null, "(1.7%) was received, Revenue shortfalls affected the"], [null, null, "implementation of planned activities."], [null, null, ""], [null, null, "\uf0b7 The Entity did not also submit quarterly monitoring reports to the"], [null, null, "Office of the Prime Minister and MoFPED as required. I advised"], [null, null, "the Accounting Officer to ensure that monitoring plans and"], [null, null, "reports are timely submitted accordingly."], [null, null, ""], [null, null, "\uf0b7 Contrary to Regulation 47 of the PPDA (Contract) Regulations,"], [null, null, "2014, the entity on 29th June 2021 paid UGX.178, 391,142 to"], [null, null, "the contractor upgrading Odupiri HC II to HC III without an"], [null, null, "interim payment certificate. On inspection in September 2021,"], [null, null, "On physical inspection, I noted that the construction was still at"], [null, null, "ring beam stage hence severely delayed and the contractor was"], [null, null, "not on site and therefore there was no construction works."], [null, null, ""], [null, null, "\uf0b7 I noted that the District received a total of UGX.166,590,846 I"], [null, null, "reviewed the bank statements sampled schools and noted that"], [null, null, "the funds were still on the school accounts by 30 th September,"], [null, null, "2021 and had hence not been utilised."], ["08.", "MADI-OKOLLO DLG \uf0b7 I noted that the District did not submit wage estimates to MoPs,", null]], "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}], "page": 423, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_2"], "type": "table"}}, {"content": "411 \nas required. The submission was made late. The Accounting Opinion Officer promised to handle this issue as per the requirement in Unqualified \nthe subsequent years. \n\uf0b7 I reviewed payroll funds absorption and noted that UGX.7.4 billion (73%) was spent out of the total receipts of UGX.10.18 billion, resulting in an unabsorbed balance of UGX.2.78 billion. I advised the Accounting Officer to consider the unimplemented \nactivities in the next work plan. \n\uf0b7 A comparison of base pay in the IPPS payroll registers with the \nsalary structure for 2020/21, revealed that 17 staff were paid \nusing wrong salary scales, leading to under payments of UGX. \n2.1 million, contrary to Section B\u2013a (6) & (7) of the Uganda \nPublic Service Standing Orders, 2010. \n", "metadata": {"headings": [{"headings_0": {"content": "In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which", "page": 420, "level": 3}}, [{"headings_0": {"content": "as required. The submission was made late. The Accounting Opinion Officer promised to handle this issue as per the requirement in Unqualified", "page": 424, "level": 3}}], [{"headings_0": {"content": "as required. The submission was made late. The Accounting Opinion Officer promised to handle this issue as per the requirement in Unqualified", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.7.4 billion (73%) was spent out of the total receipts of UGX.10.18 billion, resulting in an unabsorbed balance of UGX.2.78 billion. I advised the Accounting Officer to consider the unimplemented", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.7.4 billion (73%) was spent out of the total receipts of UGX.10.18 billion, resulting in an unabsorbed balance of UGX.2.78 billion. I advised the Accounting Officer to consider the unimplemented", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 424, "level": 3}}], [{"headings_0": {"content": "using wrong salary scales, leading to under payments of UGX.", "page": 424, "level": 3}}], [{"headings_0": {"content": "using wrong salary scales, leading to under payments of UGX.", "page": 424, "level": 3}}], [{"headings_0": {"content": "Public Service Standing Orders, 2010.", "page": 424, "level": 3}}], [{"headings_0": {"content": "Public Service Standing Orders, 2010.", "page": 424, "level": 3}}]], "page": 423, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.1,901,582,442 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "Public Service Standing Orders, 2010.", "page": 424, "level": 3}}], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,868,292,549 was remitted, leading to an over and under \nremittance of UGX.28,854,515 and UGX.62,144,408 respectively \n\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX.108million from 55 employees that neither had \nletters of undertaking nor existed in the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll Deduction Management System, operated by PCA-Payroll Consults Africa \n\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity \ntotalling to UGX 40,202,400 to the computation of PAYE in IPPS, leading to an under deduction of UGX 12,439,426, contrary to section 19 (1) (a) of the Income Tax Act. The \n\uf0b7 I noted that 32 newly recruited/ transferred employees and 5 \npensioners delayed to access payroll, delayed access to payroll leads to demotivation of the affected staff and accumulation of salary arrears. \n\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 14 staff and were paid a total of UGX 19,228,208 off the IPPS. This control weakness creates an opportunity for \npayment of salaries and pension to non-eligible persons, hence loss of funds to Government. \n\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III. \n\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect \nUGX. 302,248,400 during the year but collected UGX.209,081,450 representing (69%) performance. The \n412", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,868,292,549 was remitted, leading to an over and under", "page": 424, "level": 3}}, [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,868,292,549 was remitted, leading to an over and under", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX.108million from 55 employees that neither had", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totaling UGX.108million from 55 employees that neither had", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 424, "level": 2}}], [{"headings_0": {"content": "totalling to UGX 40,202,400 to the computation of PAYE in IPPS, leading to an under deduction of UGX 12,439,426, contrary to section 19 (1) (a) of the Income Tax Act. The", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 32 newly recruited/ transferred employees and 5", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 32 newly recruited/ transferred employees and 5", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 14 staff and were paid a total of UGX 19,228,208 off the IPPS. This control weakness creates an opportunity for", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 14 staff and were paid a total of UGX 19,228,208 off the IPPS. This control weakness creates an opportunity for", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity had not prepared and approved a strategic plan that is aligned to the NDP-III.", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}]], "page": 424, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["shortfalls in Local Revenue collections of UGX. UGX. 93,166,950 (31%) were recorded in Land fees, business licenses, other tax revenues and Administrative fees and licenses. \uf0b7 I noted that Management submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which are important in ensuring that the budget performs as expected. The Accounting Officer admitted the shortcoming and promised to address the matter. \uf0b7 I noted that there was a general delay in the implementation of NUSAF 3 sub- projects without any justification. \uf0b7 Madi-Okollo District contracted M/s TIC Lokere Enterprises Ltd for the rehabilitation of Inde mile 10 Yoro base camp feeder road under DRDIP programme at a cost of UGX.1, 238,943,750. However, I noted that there was delayed Completion of the contract, Failure to install culverts at critical points of the road and Poorly installed culverts. \uf0b7 I noted that advances of UGX. 52,332,500 remained not accounted for, at year end. The funds were advanced to staff to carry out various activities. In the absence of the relevant accountability documents, it was not possible to confirm that the funds were used for the intended purposes. \uf0b7 I noted that there were un-utilized Market at Rhino Camp. The Market was constructed at an estimated cost of UGX.700,000,000. The market lock ups had been turned into residential apartments instead and the market stalls have been abandoned and now only used for drying cassava.4", null, null], ["09.", "KOBOKO MC", "\uf0b7 I noted that the Municipal Council did not submit wage estimates"], ["", "", "to MoPs by 30th September of the preceding year as required."]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}], "page": 425, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["shortfalls in Local Revenue collections of UGX. UGX. 93,166,950 (31%) were recorded in Land fees, business licenses, other tax revenues and Administrative fees and licenses. \uf0b7 I noted that Management submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which are important in ensuring that the budget performs as expected. The Accounting Officer admitted the shortcoming and promised to address the matter. \uf0b7 I noted that there was a general delay in the implementation of NUSAF 3 sub- projects without any justification. \uf0b7 Madi-Okollo District contracted M/s TIC Lokere Enterprises Ltd for the rehabilitation of Inde mile 10 Yoro base camp feeder road under DRDIP programme at a cost of UGX.1, 238,943,750. However, I noted that there was delayed Completion of the contract, Failure to install culverts at critical points of the road and Poorly installed culverts. \uf0b7 I noted that advances of UGX. 52,332,500 remained not accounted for, at year end. The funds were advanced to staff to carry out various activities. In the absence of the relevant accountability documents, it was not possible to confirm that the funds were used for the intended purposes. \uf0b7 I noted that there were un-utilized Market at Rhino Camp. The Market was constructed at an estimated cost of UGX.700,000,000. The market lock ups had been turned into residential apartments instead and the market stalls have been abandoned and now only used for drying cassava.4", null, null], ["09.", "KOBOKO MC", "\uf0b7 I noted that the Municipal Council did not submit wage estimates"], ["", "", "to MoPs by 30th September of the preceding year as required."], [null, "Opinion Unqualified", ""], [null, null, "\uf0b7 The Municipal did not absorb wage funds worth UGX.0.33 billion."], [null, "", ""], [null, null, "\uf0b7 The Council had outstanding domestic arrears worth UGX"], [null, null, "113,354,578 that accrued within the year"], [null, null, ""], [null, null, "\uf0b7 I noted that the Municipal Council made unauthorized loan"], [null, null, "deductions totaling UGX. 18,148,668. from 16 employees that"], [null, null, "neither had letters of undertaking nor existed in the \u201cactive"], [null, null, "deduction\u201d or the \u201cmy approval\u201d reports on the PDMS-Payroll"], [null, null, "Deduction Management System, operated by PCA-Payroll"], [null, null, "Consults Africa."], [null, null, ""], [null, null, "\uf0b7 I noted that 6 pensioners delayed to access the pension payroll"], [null, null, ""], [null, null, "\uf0b7 I noted that 5 staff was paid a total of UGX. 6,488,549 off the"], [null, null, "IPPS."], [null, null, ""], [null, null, "\uf0b7 I noted that the Municipal Council did not have an approved plan"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}], "page": 425, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "413", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}], "page": 425, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "neither did it have certification of the plan by NPA."], [null, ""], [null, "\uf0b7 I noted underperformance in all revenue sources totaling UGX."], [null, "4,384,175,589 that affected implementation of planned activities"], [null, "at the council I further noted delayed submission of quarterly"], [null, "performance reports to OPM and MoFPED"], [null, ""], ["10\\. ARUA REGIONAL REFERRAL HOSPITAL Opinion Unqualified \uf0b7 Through re-computation of gratuity benefits, I noted that there were variances of over payments of UGX.21,706,000 and under payment of UGX.19,700,433. I also re-computed pension benefits, and I further noted that there were variances of over payment of UGX.5, 798,629 and under payments of UGX.10, 401,528. The Accounting Officer explained that gratuity payments are automatically computed through the IPPS system. Consultations with system officers in MOPS were underway to have the error rectified. \uf0b7 I noted that UGX.6,659,448 was paid to 03 staff who had been transferred to other entities. These were payment for services not rendered to the Hospital, resulting in loss of funds to Government. \uf0b7 I noted that deductions to UCLA/UBA were concurrently remitted as salary was paid except for the month of April, 2021 where there was no remittance at all yet UGX.16,434,444 was deducted \uf0b7 I noted that the Hospital did not include Hospital Management Board Member\u2019s retainer fees of UGX.33,600,000 in the computation of PAYE leading to under deduction of PAYE of UGX.10,080,000 contrary to section 19(1) (a) of the Income Tax Act. \uf0b7 I noted that the Hospital did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS, contrary to Paragraph 2.1 of Establishment Notice No. 1 of 2020. \uf0b7 The Hospital had outstanding (unsettled) domestic arrears worth UGX. 1,255,228,566 by close of financial year \uf0b7 I noted that the Hospital had not prepared and approved a strategic plan that is aligned to the NDP-III. \uf0b7 I noted the Hospital received off-budget financing from Ministry of Health and development partners for undertaking various activities not budgeted to a tune of UGX.1,925,620,637 which was not transferred to the consolidated fund as required by the law. \uf0b7 The Hospital Ambulance number UG6812M had been stolen from the hospital yard. By close of the audit, the ambulance had not been recovered by management. Also the value of the ambulance had not been updated in the assets register as", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}], "page": 426, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["shortfalls in Local Revenue collections of UGX. UGX. 93,166,950 (31%) were recorded in Land fees, business licenses, other tax revenues and Administrative fees and licenses. \uf0b7 I noted that Management submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which are important in ensuring that the budget performs as expected. The Accounting Officer admitted the shortcoming and promised to address the matter. \uf0b7 I noted that there was a general delay in the implementation of NUSAF 3 sub- projects without any justification. \uf0b7 Madi-Okollo District contracted M/s TIC Lokere Enterprises Ltd for the rehabilitation of Inde mile 10 Yoro base camp feeder road under DRDIP programme at a cost of UGX.1, 238,943,750. However, I noted that there was delayed Completion of the contract, Failure to install culverts at critical points of the road and Poorly installed culverts. \uf0b7 I noted that advances of UGX. 52,332,500 remained not accounted for, at year end. The funds were advanced to staff to carry out various activities. In the absence of the relevant accountability documents, it was not possible to confirm that the funds were used for the intended purposes. \uf0b7 I noted that there were un-utilized Market at Rhino Camp. The Market was constructed at an estimated cost of UGX.700,000,000. The market lock ups had been turned into residential apartments instead and the market stalls have been abandoned and now only used for drying cassava.4", "None"], "type": "table"}}, {"content": "414", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}], "page": 426, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["required. \uf0b7 I noted that the Hospital did not have a land title for Hospital land plot 43 \u2013 Hospital cell with an estimated size of 13.478 acres which it currently occupied. There was no evidence of ownership of property and there was no guarantee that the land was free from encroachment.", null, null], ["11.", "MOYO DLG", ""], ["", "", "\uf0b7 I noted that UGX.12,035,376 was paid to 8 staff who had either"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}], "page": 427, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["shortfalls in Local Revenue collections of UGX. UGX. 93,166,950 (31%) were recorded in Land fees, business licenses, other tax revenues and Administrative fees and licenses. \uf0b7 I noted that Management submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which are important in ensuring that the budget performs as expected. The Accounting Officer admitted the shortcoming and promised to address the matter. \uf0b7 I noted that there was a general delay in the implementation of NUSAF 3 sub- projects without any justification. \uf0b7 Madi-Okollo District contracted M/s TIC Lokere Enterprises Ltd for the rehabilitation of Inde mile 10 Yoro base camp feeder road under DRDIP programme at a cost of UGX.1, 238,943,750. However, I noted that there was delayed Completion of the contract, Failure to install culverts at critical points of the road and Poorly installed culverts. \uf0b7 I noted that advances of UGX. 52,332,500 remained not accounted for, at year end. The funds were advanced to staff to carry out various activities. In the absence of the relevant accountability documents, it was not possible to confirm that the funds were used for the intended purposes. \uf0b7 I noted that there were un-utilized Market at Rhino Camp. The Market was constructed at an estimated cost of UGX.700,000,000. The market lock ups had been turned into residential apartments instead and the market stalls have been abandoned and now only used for drying cassava.4", "None", "None"], "type": "table"}}, {"content": [["required. \uf0b7 I noted that the Hospital did not have a land title for Hospital land plot 43 \u2013 Hospital cell with an estimated size of 13.478 acres which it currently occupied. There was no evidence of ownership of property and there was no guarantee that the land was free from encroachment.", null, null], ["11.", "MOYO DLG", ""], ["", "", "\uf0b7 I noted that UGX.12,035,376 was paid to 8 staff who had either"], [null, "", "retired, transferred, absconded or died. I advised the Accounting"], [null, "Opinion Unqualified", "Officer to ensure prompt removal of staff from the payroll."], [null, null, ""], [null, "", "\uf0b7 I noted that whereas UGX.2,467,253,134 was deducted from"], [null, null, "employees\u2019 salaries to be remitted to different beneficiaries,"], [null, null, "UGX.2,499,884,543 was remitted, leading to an under remittance"], [null, null, "amounting to UGX.519,984 and over remittance of"], [null, null, "UGX.33,151,393. I advised the Accounting Officer to ensure"], [null, null, "prompt removal of staff from the payroll."], [null, null, ""], [null, null, "\uf0b7 I noted that whereas UGX.2,467,253,134 was deducted from"], [null, null, "employees\u2019 salaries to be remitted to different beneficiaries,"], [null, null, "UGX.2,499,884,543 was remitted, leading to an under remittance"], [null, null, "amounting to UGX.519,984 and over remittance of"], [null, null, "UGX.33,151,393."], [null, null, ""], [null, null, "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity"], [null, null, "totalling to UGX.28,087,200 to the computation of PAYE in IPPS,"], [null, null, "leading to an under deduction of UGX.8,520,960 contrary to"], [null, null, "section 19(1) (a) of the Income Tax Act."], [null, null, ""], [null, null, "\uf0b7 I noted that 6 pensioners delayed to access the pension payroll,"], [null, null, "with delays ranging between 1-2 months. Delayed access to the"], [null, null, "pension payroll leads to poor wellbeing of the affected retirees as"], [null, null, "well as accumulation of pension arrears."], [null, null, ""], [null, null, "\uf0b7 I noted that the District/Municipal Council did not prepare"], [null, null, "monthly wage, pension and gratuity performance analysis and"], [null, null, "thus did not submit quarterly returns on payroll to MoPS,"], [null, null, "contrary to Paragraph 2.1 of Establishment Notice No. 1 of 2020."], [null, null, ""], [null, null, "\uf0b7 Revenue underperformance of UGX.9,484,876,432 due to"], [null, null, "shortfall in NTR, government transfers and donor funding"], [null, null, ""], [null, null, "\uf0b7 The district did not absorb funds worth of UGX.940, 729,263 and"], [null, null, "these funds were subsequently swept back to the consolidated"], [null, null, "fund account."], [null, null, ""], [null, null, "\uf0b7 I further noted that funds received under USMID totaling to"], [null, null, "UGX.1,342,227,081 were not absorbed and as such swept back"], [null, null, "to the consolidated fund"], ["12\\. KOBOKO DLG \uf0b7 I noted that there was an under payment of UGX 83,675,196 of pension and gratuity", null, null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}], "page": 427, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["shortfalls in Local Revenue collections of UGX. UGX. 93,166,950 (31%) were recorded in Land fees, business licenses, other tax revenues and Administrative fees and licenses. \uf0b7 I noted that Management submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports. In addition, I did not obtain evidence to confirm that the Accounting Officer Prepared Monitoring Plans and reports which are important in ensuring that the budget performs as expected. The Accounting Officer admitted the shortcoming and promised to address the matter. \uf0b7 I noted that there was a general delay in the implementation of NUSAF 3 sub- projects without any justification. \uf0b7 Madi-Okollo District contracted M/s TIC Lokere Enterprises Ltd for the rehabilitation of Inde mile 10 Yoro base camp feeder road under DRDIP programme at a cost of UGX.1, 238,943,750. However, I noted that there was delayed Completion of the contract, Failure to install culverts at critical points of the road and Poorly installed culverts. \uf0b7 I noted that advances of UGX. 52,332,500 remained not accounted for, at year end. The funds were advanced to staff to carry out various activities. In the absence of the relevant accountability documents, it was not possible to confirm that the funds were used for the intended purposes. \uf0b7 I noted that there were un-utilized Market at Rhino Camp. The Market was constructed at an estimated cost of UGX.700,000,000. The market lock ups had been turned into residential apartments instead and the market stalls have been abandoned and now only used for drying cassava.4", "None", "None"], "type": "table"}}, {"content": "415 \nOpinion Unqualified \uf0b7 I noted that UGX 5,703,084 was paid to 2 staff who had either \nretired or died \n\uf0b7 I noted that whereas UGX. 2,007,415,658 was deducted from \nemployees\u2019 salaries to be remitted to different beneficiaries, UGX. \n1,866,468,850 was remitted, leading to an under remittance of \nUGX.140,946,808 \n\uf0b7 I noted that the District made unauthorized loan deductions \ntotaling UGX. 111,107,631 \n\uf0b7 I noted that 14 newly recruited/ transferred employees and 6 \npensioners \n\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 25 staff were paid a total of UGX. 27,346,176 off the IPPS", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 424, "level": 3}}, [{"headings_0": {"content": "Opinion Unqualified \uf0b7 I noted that UGX 5,703,084 was paid to 2 staff who had either", "page": 428, "level": 3}}], [{"headings_0": {"content": "Opinion Unqualified \uf0b7 I noted that UGX 5,703,084 was paid to 2 staff who had either", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that whereas UGX. 2,007,415,658 was deducted from", "page": 428, "level": 3}}], [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.", "page": 428, "level": 2}}], [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.", "page": 428, "level": 2}}], [{"headings_0": {"content": "UGX.140,946,808", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 14 newly recruited/ transferred employees and 6", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 14 newly recruited/ transferred employees and 6", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 25 staff were paid a total of UGX. 27,346,176 off the IPPS", "page": 428, "level": 3}}]], "page": 427, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The district has outstanding payables worth UGX.736,710,419 in the current financial year", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 25 staff were paid a total of UGX. 27,346,176 off the IPPS", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n\uf0b7 I noted that the entity had not prepared and approved its \nstrategic plan at the time of audit \n\uf0b7 I noted a number of issues in the implementation of approved \nbudget such as partial or non-implementation of planned \nactivities and budget shortfall of UGX.8,706,420,377 that affected \nimplementation of planned activities; late submission of quarterly \nreports to Office of the Prime Minister and MoFPED \n\uf0b7 Construction of Multipurpose Hall, ICT, Library Block , teachers houses, pay ground and water installation at Padrombu \nSeedSchool UGX.1,234,362,772 has delayed and is incomplete \nand the Contractor was not on site", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 25 staff were paid a total of UGX. 27,346,176 off the IPPS", "page": 428, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that the entity had not prepared and approved its", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity had not prepared and approved its", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted a number of issues in the implementation of approved", "page": 428, "level": 3}}], [{"headings_0": {"content": "activities and budget shortfall of UGX.8,706,420,377 that affected", "page": 428, "level": 3}}], [{"headings_0": {"content": "activities and budget shortfall of UGX.8,706,420,377 that affected", "page": 428, "level": 3}}], [{"headings_0": {"content": "reports to Office of the Prime Minister and MoFPED", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Construction of Multipurpose Hall, ICT, Library Block , teachers houses, pay ground and water installation at Padrombu", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Construction of Multipurpose Hall, ICT, Library Block , teachers houses, pay ground and water installation at Padrombu", "page": 428, "level": 3}}], [{"headings_0": {"content": "and the Contractor was not on site", "page": 428, "level": 3}}]], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Nyangilia Ps briquette making sub project was advanced", "metadata": {"headings": [{"headings_0": {"content": "and the Contractor was not on site", "page": 428, "level": 3}}], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nUGX.51,257,476 on Voucher No/EFT number 36222842 for the purpose of making fuel energy through briquettes. During field inspections undertaken on 24/11/2021, I noted that sub project \nhad not yet taken off and the group members could not be traced \n\uf0b7 I noted that Koboko District received a total of UGX. 113,097,405 for supply of additional learning materials. I reviewed the bank \nstatements for sampled schools and noted that the funds were \nstill on the schools\u2019 accounts by 30 th September, 2021 and had \nhence not been utilised \n\uf0b7 I noted that management ignored the element of competition in \nthe procurement of some items worth UGX.1,236,462,077 \n\uf0b7 I noted that although the Bamure HC III General ward facility \n416", "metadata": {"headings": [{"headings_0": {"content": "and the Contractor was not on site", "page": 428, "level": 3}}, [{"headings_0": {"content": "UGX.51,257,476 on Voucher No/EFT number 36222842 for the purpose of making fuel energy through briquettes. During field inspections undertaken on 24/11/2021, I noted that sub project", "page": 428, "level": 3}}], [{"headings_0": {"content": "UGX.51,257,476 on Voucher No/EFT number 36222842 for the purpose of making fuel energy through briquettes. During field inspections undertaken on 24/11/2021, I noted that sub project", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that Koboko District received a total of UGX. 113,097,405 for supply of additional learning materials. I reviewed the bank", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that Koboko District received a total of UGX. 113,097,405 for supply of additional learning materials. I reviewed the bank", "page": 428, "level": 3}}], [{"headings_0": {"content": "still on the schools\u2019 accounts by 30 th September, 2021 and had", "page": 428, "level": 2}}], [{"headings_0": {"content": "still on the schools\u2019 accounts by 30 th September, 2021 and had", "page": 428, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that management ignored the element of competition in", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}]], "page": 428, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", null, null], ["13.", "ARUA DLG", "\uf0b7 I was not availed with evidence that the district submitted wage"], ["", "", "estimates to MoPs as required."]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 429, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", null, null], ["13.", "ARUA DLG", "\uf0b7 I was not availed with evidence that the district submitted wage"], ["", "", "estimates to MoPs as required."], [null, "Opinions", ""], [null, "Unqualified", "\uf0b7 The district failed to absorb wage funds worth UGX.2.14 billion"], [null, "", "and the funds were swept back into the consolidated fund"], [null, null, "account at year end."], [null, null, ""], [null, null, "\uf0b7 The district made over payments of UGX.17, 088,304 various"], [null, null, "pensioners."], [null, null, ""], [null, null, "\uf0b7 I noted that UGX.10, 115,392 was paid to 15 staffs that neither"], [null, null, "appeared on the IPPS payroll register nor had the necessary"], [null, null, "documentation in their personal files to support their existence."], [null, null, ""], [null, null, "\uf0b7 I noted that 58 employees were paid salaries above their"], [null, null, "applicable salary band resulting in overpayments totalling"], [null, null, "UGX.37,427,696 while 6 employees were paid salaries below"], [null, null, "their applicable salary band resulting in underpayments totalling"], [null, null, "UGX.2,441,988."], [null, null, ""], [null, null, "\uf0b7 The District wrongly computed gratuity benefits for 01 pensioner"], [null, null, "that resulted in an overpayment of UGX.17,088,304."], [null, null, ""], [null, null, "\uf0b7 I noted that UGX.66,918,755 was paid to 49 staff who had either"], [null, null, "retired, transferred, absconded or died."], [null, null, ""], [null, null, "\uf0b7 The district over and under remitted payroll deductions worth"], [null, null, "UGX.246,912,350 and UGX.201,704,458 due to wrong coding in"], [null, null, "the system"], [null, null, ""], [null, null, "\uf0b7 I noted that the District made unauthorized loan deductions"], [null, null, "totaling UGX.386, 522,646. The deductions were from 419"], [null, null, "employees that neither had letters of undertaking nor existed in"], [null, null, "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports"], [null, null, ""], [null, null, "\uf0b7 I further noted that loan deductions relating to 16 (sixteen)"], [null, null, "employees did not have evidence of consent by the employees."], [null, null, ""], [null, null, "\uf0b7 The District made PAYE deductions of UGX UGX.314, 021,935 for"], [null, null, "the month of February 2021, but did not remit to URA as"], [null, null, "required"], [null, null, ""], [null, null, "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity"], [null, null, "totalling to UGX.105,792,166 to the computation of PAYE in IPPS,"], [null, null, "leading to an under deduction of UGX.33,858,520, contrary to"], [null, null, "section 19(1) (a) of the Income Tax Act and also noted tha t 58"], [null, null, "pensioners delayed to access the pension payroll during the year."], [null, null, ""], [null, null, "\uf0b7 I noted that unqualifying funds amounting to UGX.52, 328,174"], [null, null, "were charged on account codes prescribed for salary, pension"], [null, null, "and gratuity."]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 429, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "417", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 429, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", ""], [null, "\uf0b7 I noted that 29 employees were paid a total of UGX.51,348,377"], [null, "without signed pay change reports."]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 430, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None"], "type": "table"}}, {"content": [["", ""], [null, "\uf0b7 I noted that 29 employees were paid a total of UGX.51,348,377"], [null, "without signed pay change reports."], [null, ""], [null, "\uf0b7 I noted that 1,302 staff was paid a total of UGX. 3,048,993,948"], [null, "off the IPPS that arose from wrong coding of Arua DLG staff"], [null, "under Madi-Okollo DLG payroll arising from the separation of the"], [null, "payroll following the creation of Madi-Okollo district."], [null, ""], [null, "\uf0b7 The budget of Arua DLG was not adjusted/collapsed following"], [null, "the issuance of the supplementary budgets to the new local"], [null, "governments. Consequently, the budget of Arua DLG for the year"], [null, "under review is unrealistic. Further, activities meant to be"], [null, "undertaken by the new local governments were undertaken by"], [null, "Arua DLG for example the payment of general staff salaries"], [null, "totaling UGX.6,397,754,797 for Terego DLG staff and"], [null, "UGX.8,348,159,119 for Arua city staff. This distorts the budget"], [null, "performance measurement for the local governments involved."], [null, ""], [null, "\uf0b7 I noted underperformance of revenues from NTR, transfer from"], [null, "government units and donor funding worth UGX.30.7Bn that"], [null, "affected budget implementation"], [null, ""], [null, "\uf0b7 The district failed to absorb funds worth UGX.9.3Bn and these"], [null, "funds were subsequently swept back to the consolidated fund"], [null, "account."], [null, ""], [null, "\uf0b7 The district mischarged funds worth UGX.373, 406,160 on"], [null, "various codes other those budgeted for. Further, I noted that"], [null, "funds to the tune of UGX.93, 269,685 were spent on other"], [null, "activities without seeking and obtaining the necessary approvals."], [null, ""], [null, "\uf0b7 I noted outstanding recoveries of funds from YLP and UWEP"], [null, "groups worth UGX.1, 793,009,954 by the year end."], [null, ""], [null, "\uf0b7 I noted that Arua District received a total of UGX.490,472,016. I"], [null, "reviewed the bank statements sampled schools and noted that"], [null, "the funds were still on the school accounts by 30th September,"], [null, "2021 and had hence not been utilized."], ["14\\. ADJUMANI DLG Opinion Unqualified \uf0b7 I reviewed funds absorption for salary and pension payments and noted under absorption of UGX.1.2 billion which may have led to non payment of eligible employees and pensioners \uf0b7 I noted that UGX.3,339,798 was paid to 4 staff who had retired. These were payments for services not rendered to the District, resulting in loss of funds to Government. \uf0b7 I noted that the District made unauthorized loan deductions amounting to UGX.39,469,082 relating to 40 employees that neither existed in the \u201cactive deduction\u201d nor the \u201cmy approval\u201d reports on the PDMS as evidence of approval. \uf0b7 I noted that 3 pensioners delayed to access the pension payroll", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 430, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None"], "type": "table"}}, {"content": "418", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 430, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["during the year with average delay period of 39 days to access the pension payroll. \uf0b7 I noted that the District did not submit quarterly returns on payroll to MoPS. This led to accumulations of arrears, under absorption of wage, pension and gratuity budget and delays in granting clearance to recruit. \uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 5 staff was paid a total of UGX.7, 145,972 off the IPPS. This control weakness created an opportunity for payment of salaries to non-eligible persons. \uf0b7 I noted that the verification form and copies of the verification card for 6 pensioners/beneficiaries were not on their files. I was therefore unable to validate, authenticate the accuracy of the payroll records (salary and pension) on the IPPS. \uf0b7 I noted that the District Development Plan III was still in a draft form and had not yet been approved. \uf0b7 The district did not receive funds worth UGX.14,639,062,373 \uf0b7 The district failed to absorb funds worth UGX. 1,621,646,255 by the end of the financial year and the funds were subsequently swept back to the consolidated fund account that affected construction of roads and bridges, Installation of streetlights; and Construction of Leisure Park among others \uf0b7 The funds were meant for activities that were not fully implemented by the end of the financial year and these include; \uf0b7 A review of the revenue management process revealed that there was no invoice register for the amount billed during the year in place and schedule of debtors detailing debtor\u2019s records. I also noted that the district does not have a streamlined policy to be followed to recover the outstanding revenues/amounts. \uf0b7 I noted outstanding YLP balance of UGX.707, 536,351 that has not been recovered by the district which is affecting the revolution of the funds to other groups in the queue \uf0b7 The district had outstanding unrecovered the UWEP funds worth UGX.406,275,629 by close of the year \uf0b7 I noted that the District received a total of UGX. 129,300,127. I reviewed the bank statements sampled schools and noted that the funds were still on the school accounts by 30th September, 2021 and had hence not been utilized.", null, null], ["15.", "Pakwach DLG", "\uf0b7 I noted that the District did not submit wage estimates to MoPs"], ["", "", "by 30th September of the preceding year a required"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 431, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None", "None"], "type": "table"}}, {"content": [["during the year with average delay period of 39 days to access the pension payroll. \uf0b7 I noted that the District did not submit quarterly returns on payroll to MoPS. This led to accumulations of arrears, under absorption of wage, pension and gratuity budget and delays in granting clearance to recruit. \uf0b7 From a comparison of the payroll register and IFMS payment file, I noted that 5 staff was paid a total of UGX.7, 145,972 off the IPPS. This control weakness created an opportunity for payment of salaries to non-eligible persons. \uf0b7 I noted that the verification form and copies of the verification card for 6 pensioners/beneficiaries were not on their files. I was therefore unable to validate, authenticate the accuracy of the payroll records (salary and pension) on the IPPS. \uf0b7 I noted that the District Development Plan III was still in a draft form and had not yet been approved. \uf0b7 The district did not receive funds worth UGX.14,639,062,373 \uf0b7 The district failed to absorb funds worth UGX. 1,621,646,255 by the end of the financial year and the funds were subsequently swept back to the consolidated fund account that affected construction of roads and bridges, Installation of streetlights; and Construction of Leisure Park among others \uf0b7 The funds were meant for activities that were not fully implemented by the end of the financial year and these include; \uf0b7 A review of the revenue management process revealed that there was no invoice register for the amount billed during the year in place and schedule of debtors detailing debtor\u2019s records. I also noted that the district does not have a streamlined policy to be followed to recover the outstanding revenues/amounts. \uf0b7 I noted outstanding YLP balance of UGX.707, 536,351 that has not been recovered by the district which is affecting the revolution of the funds to other groups in the queue \uf0b7 The district had outstanding unrecovered the UWEP funds worth UGX.406,275,629 by close of the year \uf0b7 I noted that the District received a total of UGX. 129,300,127. I reviewed the bank statements sampled schools and noted that the funds were still on the school accounts by 30th September, 2021 and had hence not been utilized.", null, null], ["15.", "Pakwach DLG", "\uf0b7 I noted that the District did not submit wage estimates to MoPs"], ["", "", "by 30th September of the preceding year a required"], [null, "Opinion", ""], [null, "Unqualified", "\uf0b7 I reviewed funds absorption and noted that UGX. 10.209 Bn"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 431, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None", "None"], "type": "table"}}, {"content": "419", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 431, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "(94%) was spent out of the total receipts of UGX.10.885 Bn,"], [null, "resulting in an unabsorbed balance of UGX. 0.676 Million. The"], [null, "unabsorbed balance was subsequently swept back to the"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 432, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None"], "type": "table"}}, {"content": [["", "(94%) was spent out of the total receipts of UGX.10.885 Bn,"], [null, "resulting in an unabsorbed balance of UGX. 0.676 Million. The"], [null, "unabsorbed balance was subsequently swept back to the"], [null, "consolidated fund account"], [null, ""], [null, "\uf0b7 I reviewed funds absorption and noted that UGX.19.4 billion"], [null, "(94%) was spent out of the total receipts of UGX.20.6 billion,"], [null, "resulting in an under absorption of UGX.1.2 billion. I further"], [null, "noted an unexplained under absorption of salaries funds totaling"], [null, "UGX. 235,934,838 and under absorption of pension and gratuity"], [null, "totaling UGX.930, 294,356."], [null, ""], [null, "\uf0b7 I noted that UGX.3, 339,798 was paid to 4 staff who had retired."], [null, "These were payments for services not rendered to the District,"], [null, "resulting in loss of funds to Government."], [null, ""], [null, "\uf0b7 I further noted that loan deductions for a sample of 10"], [null, "employees lacked letters of undertaking and did not have"], [null, "evidence of consent."], [null, ""], [null, "\uf0b7 I also noted loan deductions for twenty-eight (28) staff, totaling"], [null, "UGX.33,119,091, were above the approved deduction amount"], [null, "and Loans for fifteen (15) staff totaling UGX.132,794,500 had"], [null, "unreasonable loan end-dates."], [null, ""], [null, "\uf0b7 I noted that the District did not submit quarterly returns on"], [null, "payroll to MoPS. This led to accumulations of arrears, under"], [null, "absorption of wage, pension and gratuity budget and delays in"], [null, "granting clearance to recruit."], [null, ""], [null, "\uf0b7 From a comparison of the payroll register and IFMS payment file,"], [null, "I noted that 5 staff were paid a total of UGX.7, 145,972 off the"], [null, "IPPS. This control weakness created an opportunity for payment"], [null, "of salaries to non-eligible persons"], ["16\\. ARUA MC Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX. 7,083,040,397 constituted 25% of the Municipal Council\u2019s budget for 2020/2021 of 28.3Bn. \uf0b7 I noted that the Municipal Council delayed to submit wage estimates to MoPs, as required. \uf0b7 I reviewed funds absorption and noted that UGX.6.7 billion (98%) was spent out of the total receipts of UGX.6.9 billion for salaries, pension and gratuity \uf0b7 I noted that whereas UGX.1,510,024,063 was deducted from employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,502,519,098 was remitted leading to an under remittance amounting to UGX.7,504,965 \uf0b7 I noted that the entity did not include political leaders\u2019 gratuity of UGX.8,939,400 in the computation of PAYE leading to under deduction of PAYE of UGX.2,681,820", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 432, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None"], "type": "table"}}, {"content": "420", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 432, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that the verification form and copies of the verification card for 09 pensioners/beneficiaries were not on their files \uf0b7 I further noted that the Municipal Council Development Plan III was still in a draft form and had not yet been approved \uf0b7 I noted that the Municipal Council had off-budget receipts totaling UGX.1, 069,848,174 during the year. \uf0b7 I noted a number of issues in the implementation of approved budget suchas as failure to fully quantify outputs, partial and non-implementation of planned activities; over absorption of UGX.761,755,708; revenue underperformance of UGX.2,530,484,439 \uf0b7 I noted that UGX.210,033,250 meant for surfacing of Staff Lane and Construction of Municipal Bypass was utilised for supply and installation of solar street lights on Oluko Road \uf0b7 \uf0b7 I noted that the entity submitted performance report for Q4 after the deadline given for submission of the reports \uf0b7 I noted that there were unapproved overpayments of UGX.1,427,380,000 relating to USMID works on School road and Adroa road \uf0b7 I noted that the Municipal Council made advance payment of UGX.333,383,989 to contractors without bank guarantees \uf0b7 I noted low bidder participation in 3 of the 11 sampled procurements \uf0b7 I noted that the Municipal Council did not receive its approved supplementary development budget totaling UGX.14,340,000,000 under Supplementary Expenditure Estimates Supplied Addendum No.1 to Schedule No.2 for F/Y 2020/2021 \uf0b7 I noted that the Municipal Council did not have an approved staff structure/establishment.", null, null], ["", "MBARARA BRANCH", "Summary of Key Findings"], ["01\\. MBARARA DLG Opinion Unqualified \uf0b7 I analyzed the approved budget and releases to Mbarara District for salary, pension and gratuity in the period under review and noted that the wage and Pension Pay roll of UGX.20,650,503,996 constituted 68% of the District\u2019s budget for 2020/2021 of UGX.30.38 Bn \uf0b7 I noted that the District delayed to submit wage estimates to MoPS, contrary to the Establishment Notice. The submission was made on 18th February 2020, which is 140 days after the required date \uf0b7 I reviewed funds absorption and noted that UGX.19.6 billion (95%) was spent out of the total receipts of UGX.20.7 billion, resulting in an unabsorbed balance of UGX.1.1 billion.", null, null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 433, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None", "None"], "type": "table"}}, {"content": "421", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 433, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 I noted that the District made unauthorised loan deductions totalling UGX.11.8 million. The deductions were from 40 employees that neither existed in the \u201cactive deduction\u201d nor the \u201cmy approval\u201d reports on the Payroll Deduction Management System (PDMS), operated by Payroll Consults Africa (PCA) \uf0b7 I noted that the District made payroll deductions of UGX. 813,620,096, but did not remit concurrently with the salary payments in 11 out of 12 months. The delay ranged from 5 to 84 days \uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2 months of November 2020 and January 2021 of six (06) and eighty (08) days respectively \uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX. 16,304,260 to the computation of PAYE in IPPS, leading to an under deduction of UGX.4,891,278 \uf0b7 I noted that of the 29 newly recruited/transferred, 13 employees delayed to access payroll, with delays ranging between 6 to 12 weeks \uf0b7 pensioners delayed to access the pension payroll, with delays ranging between 7-10 months \uf0b7 Gratuity and pensions of UGX. 601,669,910 was charged on Salary account which did not reflect the nature of the expenditure \uf0b7 I noted that the District prepared monthly wage, pension and gratuity performance analysis but did not submit quarterly returns on payroll to MoPS \uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect UGX.1,293,851,871 during the year but collected UGX.974,341,070 representing (75%) performance. \uf0b7 The Entity budgeted to receive UGX.2,077,267,871 as transfers from other Government Units. However, only UGX.583,148,567 (28%) was received. Revenue shortfalls affected the implementation of planned activities \uf0b7 The District budgeted to receive UGX.693,590,000 as external/donor financing out of which UGX.53,180,000 (7.7%), was received \uf0b7 I noted that management did not submit quarterly monitoring reports to the Office of the Prime Minister and Mofped as required", null, null], ["02.", "RUBANDA DLG Opinion Unqualified", "\uf0b7 I analysed the approved budget and releases to Rubanda District for salary, pension and gratuity in the period under review and noted that the wage and Pension Pay roll of UGX.17,152,929,012"], [null, null, "constituted 49% of the District\u2019s budget for 2020/2021 of"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 434, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None", "None"], "type": "table"}}, {"content": [["\uf0b7 I noted that the District made unauthorised loan deductions totalling UGX.11.8 million. The deductions were from 40 employees that neither existed in the \u201cactive deduction\u201d nor the \u201cmy approval\u201d reports on the Payroll Deduction Management System (PDMS), operated by Payroll Consults Africa (PCA) \uf0b7 I noted that the District made payroll deductions of UGX. 813,620,096, but did not remit concurrently with the salary payments in 11 out of 12 months. The delay ranged from 5 to 84 days \uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2 months of November 2020 and January 2021 of six (06) and eighty (08) days respectively \uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX. 16,304,260 to the computation of PAYE in IPPS, leading to an under deduction of UGX.4,891,278 \uf0b7 I noted that of the 29 newly recruited/transferred, 13 employees delayed to access payroll, with delays ranging between 6 to 12 weeks \uf0b7 pensioners delayed to access the pension payroll, with delays ranging between 7-10 months \uf0b7 Gratuity and pensions of UGX. 601,669,910 was charged on Salary account which did not reflect the nature of the expenditure \uf0b7 I noted that the District prepared monthly wage, pension and gratuity performance analysis but did not submit quarterly returns on payroll to MoPS \uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect UGX.1,293,851,871 during the year but collected UGX.974,341,070 representing (75%) performance. \uf0b7 The Entity budgeted to receive UGX.2,077,267,871 as transfers from other Government Units. However, only UGX.583,148,567 (28%) was received. Revenue shortfalls affected the implementation of planned activities \uf0b7 The District budgeted to receive UGX.693,590,000 as external/donor financing out of which UGX.53,180,000 (7.7%), was received \uf0b7 I noted that management did not submit quarterly monitoring reports to the Office of the Prime Minister and Mofped as required", null, null], ["02.", "RUBANDA DLG Opinion Unqualified", "\uf0b7 I analysed the approved budget and releases to Rubanda District for salary, pension and gratuity in the period under review and noted that the wage and Pension Pay roll of UGX.17,152,929,012"], [null, null, "constituted 49% of the District\u2019s budget for 2020/2021 of"], [null, null, "UGX.34.85 Bn"], [null, null, "\uf0b7 I reviewed the wage funds absorption and noted that UGX.17.29"], [null, null, "billion(96) was spent out of the total receipts of UGX18.02 billion,"], [null, null, "resulting in an unabsorbed balance of UGX.0.73 billion"], [null, null, "\uf0b7 A review of the payroll data (IPPS) and IFMS payments revealed"], [null, null, "variances between amounts on the approved payroll and"], [null, null, "payments to individual employees, leading to over payment of"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 434, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None", "None"], "type": "table"}}, {"content": "422", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 434, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "UGX. 12,101,332"], [null, "\uf0b7 I noted that 15 employees on the IPPS payroll did not receive"], [null, "salary of UGX. 37,502,687"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 435, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None"], "type": "table"}}, {"content": [["", "UGX. 12,101,332"], [null, "\uf0b7 I noted that 15 employees on the IPPS payroll did not receive"], [null, "salary of UGX. 37,502,687"], [null, "\uf0b7 A comparison of base pay in the IPPS payroll registers with the"], [null, "salary structure for 2020/21, revealed that June payments were"], [null, "made using wrong salary scales, leading to over payments of"], [null, "UGX. 3,197,252, and under payments of UGX. 978,860"], [null, "\uf0b7 I noted that whereas UGX. 4,119,399,533 was deducted from"], [null, "employees\u2019 salaries to be remitted to different beneficiaries, UGX."], [null, "4,110,103,755 was remitted, leading to an over and under"], [null, "remittance amounting to UGX.(234,929,994) and"], [null, "UGX.244,225,772 respectively"], [null, "\uf0b7 I noted that the District made unauthorised loan deductions"], [null, "totalling UGX. 41,736,635 from 22 employees that neither had"], [null, "letters of undertaking nor existed in the \u201cactive deduction\u201d or the"], [null, "\u201cmy approval\u201d reports on the Payroll Deduction Management"], [null, "System (PDMS)"], [null, "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity"], [null, "totalling to UGX. 30,155,400 to the computation of PAYE in IPPS,"], [null, "leading to an under deduction of UGX. 9,113,820 I noted that 9"], [null, "pensioners delayed to access the pension payroll, with delays"], [null, "ranging between 6-15 months"], [null, "\uf0b7 I noted that the District did not prepare monthly wage, pension"], [null, "and gratuity performance analysis and thus did not submit"], [null, "quarterly returns on payroll to MoPS"], [null, "\uf0b7 I observed that there were variances of UGX. 5,667,077 and"], [null, "UGX.7.076,946 between the MoPS IPPS and entity payroll"], [null, "registers availed by the core FTP system"], [null, "\uf0b7 I noted that at the time of audit October 2021 the district"], [null, "strategic plan was not approved by NPA."], [null, "\uf0b7 I noted that the district had planned to collect local revenue of"], [null, "UGX0.587Million but was only able to collect 0.351 million"], [null, "representing 60% performance."], [null, "\uf0b7 Of the UGX.10.13Bn budgeted as transfers from other"], [null, "Government Units, only UGX.0.8 Bn was received representing"], [null, "8% performance"], [null, "\uf0b7 The district did not receive any external/donor financing despite"], [null, "having a budget of UGX0.89Bn"], ["03\\. KAZO DLG Opinion Unqualified \uf0b7 I analysed the approved budget and releases to Kazo district for salary, pension and gratuity in the period under review and noted that the wage and Pension Pay roll of UGX.10,993,531,909 constituted 64.1% of the District\u2019s budget for 2020/2021 of UGX.17,131,504,889 \uf0b7 A comparison of base pay in the IPPS payroll registers with the salary structure for 2020/21, revealed that 20 staff were paid using wrong salary scales, leading to over payments of", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}], "page": 435, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["was completed and ready for use, the building was redundant and had not yet been put to use five months after completion", "None"], "type": "table"}}, {"content": "423 \nUGX269,392 \n\uf0b7 I noted that UGX.1,605,867 was paid to 3 staff who had either \nabsconded or died \n\uf0b7 I noted that the District made unauthorised loan deductions \ntotalling UGX.43,661,032. The deductions were from 12 employees that neither had letters of undertaking nor existed in \nthe \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the \nPDMS-Payroll Deduction Management System, operated by PCA- Payroll Consults Africa. \n\uf0b7 I further noted that loan deductions relating to 12 employees did \nnot have evidence of consent \n\uf0b7 I noted that the District made payroll deductions but did not \nremit concurrently with the salary payments in 7 out of 8 \nmonths. On average, it delayed by 7 days \n\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity \ntotalling to UGX.29,166,600 to the computation of PAYE in IPPS, \nleading to an under deduction of UGX.8,652,480 \n\uf0b7 I noted that the District did not prepare monthly wage, pension \nand gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \n\uf0b7 I noted that the district was implementing a strategic plan (2020/21- 2024/25) that had not been approved by National \nPlanning Authority \n\uf0b7 I noted that the district only managed to collect local revenue of \nUGX327,102,266 of the budgeted UGX 824,355,800 representing 40% performance \n\uf0b7 I noted that Transfers received from the consolidated fund \nperformed at 90% \n\uf0b7 I noted the district did not receive any external financing despite \nhaving a budget of UGX 33,504,000 \n\uf0b7 I noted that the District received off-budget financing of UGX.552,762,500 which was never paid into the consolidated \nfund as required by the law \n\uf0b7 Out of the total receipts for the financial year of UGX.15.12bn \n(including opening balance of UGX.367,655,139) UGX.14.46bn was spent by the entity resulting in an unspent balance of UGX.0.65 Bn representing absorption level of 96% \n\uf0b7 I assessed the implementation of twenty two (22) outputs that \nwere fully quantified with a total of twenty-one (22) activities \nworth UGX 1.83Bn and noted that Eighteen (18) outputs with total expenditure amounting to UGX 1.16 Bn were fully implemented representing 70.6% of the outputs, Four (4) outputs with total expenditure amounting to UGX.0.67 Bn were \npartially implemented representing 29.4% of the outputs. \n\uf0b7 I noted that the entity submitted performance reports for Q1, \nQ2, Q3, Q4 after the deadline given for submission of the reports \n424", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the Bamure HC III General ward facility", "page": 428, "level": 3}}, [{"headings_0": {"content": "UGX269,392", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.1,605,867 was paid to 3 staff who had either", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.1,605,867 was paid to 3 staff who had either", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorised loan deductions", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorised loan deductions", "page": 436, "level": 3}}], [{"headings_0": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 436, "level": 2}}], [{"headings_0": {"content": "the \u201cactive deduction\u201d or the \u201cmy approval\u201d reports on the", "page": 436, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I further noted that loan deductions relating to 12 employees did", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I further noted that loan deductions relating to 12 employees did", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions but did not", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions but did not", "page": 436, "level": 3}}], [{"headings_0": {"content": "months. On average, it delayed by 7 days", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 436, "level": 2}}], [{"headings_0": {"content": "totalling to UGX.29,166,600 to the computation of PAYE in IPPS,", "page": 436, "level": 3}}], [{"headings_0": {"content": "totalling to UGX.29,166,600 to the computation of PAYE in IPPS,", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district was implementing a strategic plan (2020/21- 2024/25) that had not been approved by National", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district was implementing a strategic plan (2020/21- 2024/25) that had not been approved by National", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district only managed to collect local revenue of", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district only managed to collect local revenue of", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that Transfers received from the consolidated fund", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that Transfers received from the consolidated fund", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted the district did not receive any external financing despite", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted the district did not receive any external financing despite", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District received off-budget financing of UGX.552,762,500 which was never paid into the consolidated", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District received off-budget financing of UGX.552,762,500 which was never paid into the consolidated", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of UGX.15.12bn", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of UGX.15.12bn", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I assessed the implementation of twenty two (22) outputs that", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I assessed the implementation of twenty two (22) outputs that", "page": 436, "level": 3}}], [{"headings_0": {"content": "worth UGX 1.83Bn and noted that Eighteen (18) outputs with total expenditure amounting to UGX 1.16 Bn were fully implemented representing 70.6% of the outputs, Four (4) outputs with total expenditure amounting to UGX.0.67 Bn were", "page": 436, "level": 3}}], [{"headings_0": {"content": "worth UGX 1.83Bn and noted that Eighteen (18) outputs with total expenditure amounting to UGX 1.16 Bn were fully implemented representing 70.6% of the outputs, Four (4) outputs with total expenditure amounting to UGX.0.67 Bn were", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 436, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 436, "level": 3}}]], "page": 435, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "4. INSINGIRO DLG", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 436, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nOpinion Unqualified \n\uf0b7 I analysed the approved budget and releases to the District for \nsalary, pension and gratuity in the period under review and noted that the wage and Pension Pay roll of UGX.25,700,415,566 \nconstituted 29.4% of the District\u2019s budget for 2020/2021 of \nUGX.87.35 Bn \n\uf0b7 I noted that the District delayed to submit wage estimates to MoPs, as required. The submission was made after 30th September 2020. This may lead to wage shortfalls/over provision \ndue to lack of clarity and analysis of wage estimates by MoPS \n\uf0b7 The District paid out a total of UGX.14,568,696 to 12 non- existent staff. These were not on the IPPS payroll register and \nalso lacked the necessary documentation to support their existence \n\uf0b7 A comparison of base pay in the IPPS payroll registers with the \nsalary structure for 2020/21 revealed that seventeen (17) staff were paid using wrong salary scales, leading to under payment of UGX.189,881 \n\uf0b7 I noted that UGX.9,922,552 was paid to five (5) staff who had \neither retired, transferred, absconded or died", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 436, "level": 3}}, [{"headings_0": {"content": "Opinion Unqualified", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I analysed the approved budget and releases to the District for", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I analysed the approved budget and releases to the District for", "page": 437, "level": 3}}], [{"headings_0": {"content": "constituted 29.4% of the District\u2019s budget for 2020/2021 of", "page": 437, "level": 2}}], [{"headings_0": {"content": "constituted 29.4% of the District\u2019s budget for 2020/2021 of", "page": 437, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I noted that the District delayed to submit wage estimates to MoPs, as required. The submission was made after 30th September 2020. This may lead to wage shortfalls/over provision", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District delayed to submit wage estimates to MoPs, as required. The submission was made after 30th September 2020. This may lead to wage shortfalls/over provision", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The District paid out a total of UGX.14,568,696 to 12 non- existent staff. These were not on the IPPS payroll register and", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The District paid out a total of UGX.14,568,696 to 12 non- existent staff. These were not on the IPPS payroll register and", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 A comparison of base pay in the IPPS payroll registers with the", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.9,922,552 was paid to five (5) staff who had", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.9,922,552 was paid to five (5) staff who had", "page": 437, "level": 3}}]], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.5,426,888,768 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.9,922,552 was paid to five (5) staff who had", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nemployees\u2019 salaries to be remitted to different beneficiaries, \nUGX.4,951,234,873 was remitted, leading to an under remittance of UGX.475,653,895 \n\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity \ntotalling to UGX.42,781,000 to the computation of PAYE in IPPS, \nleading to an under deduction of UGX.12,900,150 \n\uf0b7 I noted that one retiree who was last paid in October, 2020 had \nnot yet accessed the pension payroll by the time of audit \n\uf0b7 I noted that UGX.12,152,847 was diverted to Bangirana Josaphat M employee no 524376) as residual pension arrears from April 2015 to October 2019. However, these had not been verified and therefore not part of schedule provided by MoFPED \n\uf0b7 I noted that 05 employees were paid a total of UGX.9,087,270 \nwithout signed pay change reports \n\uf0b7 I noted that the District did not prepare monthly wage, pension \nand gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \n\uf0b7 I noted that twelve (12) staff and 02 pensioners were paid a \ntotal of UGX.32,785,938 off the IPPS \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.9,922,552 was paid to five (5) staff who had", "page": 437, "level": 3}}, [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries,", "page": 437, "level": 2}}], [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries,", "page": 437, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 437, "level": 2}}], [{"headings_0": {"content": "totalling to UGX.42,781,000 to the computation of PAYE in IPPS,", "page": 437, "level": 3}}], [{"headings_0": {"content": "totalling to UGX.42,781,000 to the computation of PAYE in IPPS,", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that one retiree who was last paid in October, 2020 had", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that one retiree who was last paid in October, 2020 had", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.12,152,847 was diverted to Bangirana Josaphat M employee no 524376) as residual pension arrears from April 2015 to October 2019. However, these had not been verified and therefore not part of schedule provided by MoFPED", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 05 employees were paid a total of UGX.9,087,270", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 05 employees were paid a total of UGX.9,087,270", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that twelve (12) staff and 02 pensioners were paid a", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that twelve (12) staff and 02 pensioners were paid a", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that twelve (12) staff and 02 pensioners were paid a", "page": 437, "level": 3}}]], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I observed that there were variances of UGX.12,355,491", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that twelve (12) staff and 02 pensioners were paid a", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "between the figures in the MoPS IPPS and entity payroll registers \n\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect \nUGX.1,029,300,000 during the year but collected UGX. 778,835,482 representing (83%) performance \n", "metadata": {"headings": [{"headings_0": {"content": "between the figures in the MoPS IPPS and entity payroll registers", "page": 437, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}]], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- The entity budgeted to receive UGX.39,034,900,000 as transfers", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "425 \nfrom other Government Units. However, only UGX.16,417,071,378 (42%) was received \n\uf0b7 The District budgeted to receive UGX.3,112,206,100 as \nexternal/donor financing out of which UGX.1,226,592,425 \n(39.4%) \n\uf0b7 Out of the total receipts for the financial year of \n(UGX.61,860,404,265 \u2013 1,313,798,884), UGX.61,310,829,945 (89%) was spent by the entity resulting in an unspent balance of UGX.764,224,564 (08%). \n\uf0b7 I assessed the implementation of thirty two (32) outputs that \nwere fully quantified with a total of thirty two (32) activities worth UGX.3.505 Bn and noted the following \n\uf0b7 Thirty (30) outputs with a total of thirty (30) activities worth \nUGX.2.771 Bn were fully implemented. \n\uf0b7 Two (02) outputs with a total of two (02) activities worth UGX.0.734 Bn were partially implemented by the time of audit \n\uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required. \n\uf0b7 The entity had not also submitted quarterly monitoring reports to \nthe Office of the Prime Minister and Moped as required by the \ntime of audit 10th of September 2021 I noted that Management submitted performance reports for Q1, Q2, Q3 and 4 after the \ndeadline given for submission of the reports \n\uf0b7 I audited the Construction of Ruborogota seed school under UgIFT and I observed that no liquidated damages were charged \nto the contractor by management as stipulated in terms and \nconditions of the agreement. I further noted that overall physical \nprogress was at 75.2% and the financial progress was at 68% as \nper monthly progress report of July 2021 implying \nUGX.667,629,755 were lying idle on the account \n\uf0b7 I noted that taxes amounting to UGX.3,344,640 were never paid \nto URA as summarised in the table I inspected various prices of \nland owned by the District and noted that most of it lacked land \ntitles and three pieces of land (6.6 acres) had been encroached on by private developers \n\uf0b7 I noted that most of the District land did not have certificates of \ntitle \n\uf0b7 I noted that as per quarter 2nd 2020/2021 Youth Livelihood Programme Performance Report by the focal person to the \nAccounting Officer, dated 30st December 2020, that \nUGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving \nUGX.1,367,353,783 unrecovered \n426", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I reviewed the approved Local revenue estimates for the financial year 2020/2021 and noted that the District budgeted to collect", "page": 437, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.3,112,206,100 as", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The District budgeted to receive UGX.3,112,206,100 as", "page": 438, "level": 3}}], [{"headings_0": {"content": "(39.4%)", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Out of the total receipts for the financial year of", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I assessed the implementation of thirty two (32) outputs that", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I assessed the implementation of thirty two (32) outputs that", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Thirty (30) outputs with a total of thirty (30) activities worth", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Thirty (30) outputs with a total of thirty (30) activities worth", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Two (02) outputs with a total of two (02) activities worth UGX.0.734 Bn were partially implemented by the time of audit", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required.", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The entity had not also submitted quarterly monitoring reports to", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The entity had not also submitted quarterly monitoring reports to", "page": 438, "level": 3}}], [{"headings_0": {"content": "time of audit 10th of September 2021 I noted that Management submitted performance reports for Q1, Q2, Q3 and 4 after the", "page": 438, "level": 3}}], [{"headings_0": {"content": "time of audit 10th of September 2021 I noted that Management submitted performance reports for Q1, Q2, Q3 and 4 after the", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I audited the Construction of Ruborogota seed school under UgIFT and I observed that no liquidated damages were charged", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I audited the Construction of Ruborogota seed school under UgIFT and I observed that no liquidated damages were charged", "page": 438, "level": 3}}], [{"headings_0": {"content": "conditions of the agreement. I further noted that overall physical", "page": 438, "level": 3}}], [{"headings_0": {"content": "conditions of the agreement. I further noted that overall physical", "page": 438, "level": 3}}], [{"headings_0": {"content": "per monthly progress report of July 2021 implying", "page": 438, "level": 3}}], [{"headings_0": {"content": "per monthly progress report of July 2021 implying", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that taxes amounting to UGX.3,344,640 were never paid", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that taxes amounting to UGX.3,344,640 were never paid", "page": 438, "level": 3}}], [{"headings_0": {"content": "land owned by the District and noted that most of it lacked land", "page": 438, "level": 3}}], [{"headings_0": {"content": "land owned by the District and noted that most of it lacked land", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that most of the District land did not have certificates of", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that most of the District land did not have certificates of", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that as per quarter 2nd 2020/2021 Youth Livelihood Programme Performance Report by the focal person to the", "page": 438, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that as per quarter 2nd 2020/2021 Youth Livelihood Programme Performance Report by the focal person to the", "page": 438, "level": 3}}], [{"headings_0": {"content": "UGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving", "page": 438, "level": 3}}], [{"headings_0": {"content": "UGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving", "page": 438, "level": 3}}], [{"headings_0": {"content": "UGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving", "page": 438, "level": 3}}]], "page": 437, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "5. BUHWEJU DLG", "metadata": {"headings": [{"headings_0": {"content": "UGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving", "page": 438, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nOpinion Unqualified \n\uf0b7 I noted that the wage and pension pay roll of UGX.9,342,366,801 \nconstituted 54% of the District\u2019s budget for 2020/2021 of \nUGX.17,438,067,437. \n\uf0b7 I noted that the District did not to submit wage estimates to \nMoPs, as required \n\uf0b7 I reviewed payroll funds absorption and noted that UGX.9.34 billion (107%) was spent out of the total receipts of UGX.8.57 billion, resulting in an excess expenditure of UGX.0.64 billion", "metadata": {"headings": [{"headings_0": {"content": "UGX.1,599,889,519 had been disbursed to various youth groups in the district but UGX.331,883,100 had been recovered leaving", "page": 438, "level": 3}}, [{"headings_0": {"content": "Opinion Unqualified", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the wage and pension pay roll of UGX.9,342,366,801", "page": 439, "level": 3}}], [{"headings_0": {"content": "constituted 54% of the District\u2019s budget for 2020/2021 of", "page": 439, "level": 2}}], [{"headings_0": {"content": "UGX.17,438,067,437.", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.9.34 billion (107%) was spent out of the total receipts of UGX.8.57 billion, resulting in an excess expenditure of UGX.0.64 billion", "page": 439, "level": 3}}]], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted a salary over payment of UGX.278,550,496\n- I noted a salary under payment of UGX.36,127,180", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.9.34 billion (107%) was spent out of the total receipts of UGX.8.57 billion, resulting in an excess expenditure of UGX.0.64 billion", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n\uf0b7 I was not availed with the pension payroll data and I was unable to compare pension and gratuity payroll amount with IFMS \npayments of UGX.608,581,426 and UGX.302,628,319 for gratuity and pension respectively \n\uf0b7 I noted that 116 staff were paid salary using wrong salary scales, \nleading to over payments of UGX.72,081,318 \n\uf0b7 I was not availed with information on staff departures and I \ncould not ascertain the duration of the delayed deletions", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I reviewed payroll funds absorption and noted that UGX.9.34 billion (107%) was spent out of the total receipts of UGX.8.57 billion, resulting in an excess expenditure of UGX.0.64 billion", "page": 439, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I was not availed with the pension payroll data and I was unable to compare pension and gratuity payroll amount with IFMS", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I was not availed with the pension payroll data and I was unable to compare pension and gratuity payroll amount with IFMS", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 116 staff were paid salary using wrong salary scales,", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 116 staff were paid salary using wrong salary scales,", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I was not availed with information on staff departures and I", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I was not availed with information on staff departures and I", "page": 439, "level": 3}}]], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that UGX.756,742,653 was deducted from employees\u2019", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I was not availed with information on staff departures and I", "page": 439, "level": 3}}], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nsalaries to be remitted to Uganda Consumer Lenders' \nAssociation/Uganda Bankers' Association, and UGX.756,916,127 was remitted, leading to an over remittance of UGX.173,474 \n\uf0b7 I noted that the District made payroll deductions of UGX.756,742,653, but did not remit concurrently with the salary payments in all the 6 months. On average, it delayed by 41 days \n\uf0b7 I noted delays in the remittance of PAYE deductions to URA \nranging from 2 \u2013 46 days \n\uf0b7 I was not availed with lists of new staff and leavers, I could \ntherefore not establish the timing of accessibility to the payroll by the new staff. \n\uf0b7 I noted that salary entries amounting to UGX.184,483,367 to \nseveral employees were not supported by signed pay change reports \n\uf0b7 I noted that the District did not prepare monthly wage, pension \nand gratuity performance analysis and did not submit quarterly returns on payroll to MoPS \n\uf0b7 I noted that 102 staff were paid a total of UGX.499,116,733 off \nthe IPPS \n\uf0b7 I noted that the verification form and copies of the verification \ncard for employees and pensioners/beneficiaries on their files were not availed for audit review \n\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID \nstaff/pensioner/beneficiaries\u2019 verification interface and noted the \nfollowing; \n427", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I was not availed with information on staff departures and I", "page": 439, "level": 3}}, [{"headings_0": {"content": "salaries to be remitted to Uganda Consumer Lenders'", "page": 439, "level": 3}}], [{"headings_0": {"content": "Association/Uganda Bankers' Association, and UGX.756,916,127 was remitted, leading to an over remittance of UGX.173,474", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.756,742,653, but did not remit concurrently with the salary payments in all the 6 months. On average, it delayed by 41 days", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I was not availed with lists of new staff and leavers, I could", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I was not availed with lists of new staff and leavers, I could", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that salary entries amounting to UGX.184,483,367 to", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that salary entries amounting to UGX.184,483,367 to", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not prepare monthly wage, pension", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 102 staff were paid a total of UGX.499,116,733 off", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 102 staff were paid a total of UGX.499,116,733 off", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the verification form and copies of the verification", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the verification form and copies of the verification", "page": 439, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I reviewed the effectiveness and reliability of the IPPS/NID", "page": 439, "level": 3}}], [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}], [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}], [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}]], "page": 439, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["\uf0b7 In-adequate sensitization and training in the use and navigation of the system \uf0b7 System was not reliable and effective \uf0b7 Operational challenges were encountered; \uf0b7 E.g. Un-reliable network in Buhweju where HR staff had to physically travel to the neighbouring Districts to be able to download documents such as pension payroll registers. \uf0b7 Inadequate staffing of the HR department \uf0b7 I noted that the district budgeted to collect UGX.155,201,000 during the year but collected UGX.136,282,651 representing (88%) performance. The shortfalls in Local Revenue collections of UGX. 18,918,349 (12%) were recorded in Local Service Tax, Land Fees and Application Fees \uf0b7 I noted that entity budgeted to receive UGX.758,657,000 as transfers from other Government Units. However, only UGX.537,760,298 (70.9%) was received \uf0b7 I assessed the implementation of seven (7) outputs that were fully quantified with a total of seven (7) activities worth UGX 1.6 Bn and noted the following. \uf0b7 Five (05) outputs with a total of five (05) activities worth UGX.1.03Bn were fully implemented. The entity implemented all the five (05) activities (100%) within these outputs. \uf0b7 Two (02) outputs with a total of two (02) activities worth UGX.0.5 Bn were partially implemented. \uf0b7 I noted that the district had commenced implementation of two (2) UgIFT projects namely; Upgrading of Engaju HC II to HC III and Upgrade of Rushambya HC II to HC III and noted the following; \uf0b7 Upgrading of Rushambya Health Centre II to Health Centre III; The medical facility had been completed but lacked medical equipment to enable functionality and service delivery \uf0b7 Upgrade of Engaju HC II to HC III; The project stalled but medical equipment had been procured and an advance payment of UGX. 211,119,458 was made during the year", null, null], ["06.", "BUSHENYI DLG Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Pay roll of UGX.21,998,865,997 constituted 54% of the District\u2019s budget for 2020/2021 of UGX.40,645,826,438."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}], "page": 440, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "428", "metadata": {"headings": [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}], "page": 440, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.1,504,757,075 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nemployees\u2019 salaries to be remitted to different beneficiaries, UGX.1,517,190,079 was remitted, leading to an over/ under \nremittance of UGX.12,433,004 and UGX.6,100,834 \n\uf0b7 I noted that the District made payroll deductions but did not \nremit concurrently with the salary payments in 5 out of 7 \nmonths. On average, it delayed by 7 days \n\uf0b7 I noted that the district had outstanding salary arrears from \nprevious years\u2019 worth UGX.34,719,743 that remained unpaid at \nthe end of the financial year \n\uf0b7 I carried out a survey to establish the effectiveness and reliability \nof the IPPS/NID staff/pensioner/beneficiaries\u2019 verification \ninterface and noted the following; \n", "metadata": {"headings": [{"headings_0": {"content": "staff/pensioner/beneficiaries\u2019 verification interface and noted the", "page": 439, "level": 2}}, [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,517,190,079 was remitted, leading to an over/ under", "page": 441, "level": 2}}], [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.1,517,190,079 was remitted, leading to an over/ under", "page": 441, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions but did not", "page": 441, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions but did not", "page": 441, "level": 3}}], [{"headings_0": {"content": "months. On average, it delayed by 7 days", "page": 441, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district had outstanding salary arrears from", "page": 441, "level": 3}}], [{"headings_0": {"content": "previous years\u2019 worth UGX.34,719,743 that remained unpaid at", "page": 441, "level": 2}}], [{"headings_0": {"content": "previous years\u2019 worth UGX.34,719,743 that remained unpaid at", "page": 441, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I carried out a survey to establish the effectiveness and reliability", "page": 441, "level": 3}}], [{"headings_0": {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "page": 441, "level": 2}}], [{"headings_0": {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "page": 441, "level": 2}}], [{"headings_0": {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "page": 441, "level": 2}}]], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Operational challenges were encountered;", "metadata": {"headings": [{"headings_0": {"content": "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification", "page": 441, "level": 2}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "\uf0b7 Mismatches of names that take long to be corrected by NIRA and \naffects ability to timely access people on payroll.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Mismatches of names that take long to be corrected by NIRA and", "page": 441, "level": 3}}, [{"headings_0": {"content": "\uf0b7 Mismatches of names that take long to be corrected by NIRA and", "page": 441, "level": 3}}]], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- In some cases, the status under IPPS remain \u201cNOT VERIFIED\u201d", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Mismatches of names that take long to be corrected by NIRA and", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \neven when the record is verified and approved. This again \nrequires one to contact Ministry of Public service for an \nintervention. \n\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Mismatches of names that take long to be corrected by NIRA and", "page": 441, "level": 3}}, [{"headings_0": {"content": "even when the record is verified and approved. This again", "page": 441, "level": 3}}], [{"headings_0": {"content": "requires one to contact Ministry of Public service for an", "page": 441, "level": 3}}], [{"headings_0": {"content": "requires one to contact Ministry of Public service for an", "page": 441, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "page": 441, "level": 3}}]], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that Bushenyi District budgeted to collect", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nUGX.630,746,210 in the year under review however the entity \nonly collected UGX.393,072,939 representing 62% performance.", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted at the time of audit (June 2020/2021) the strategic plan had not been approved by NPA for implementation", "page": 441, "level": 3}}, [{"headings_0": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}], [{"headings_0": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}]], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The entity budgeted to receive UGX.29,905,844,709 from the consolidated fund out of which UGX.28,011,829,956 was received representing causing a shortfall of UGX.1,894,014,753 representing 94% performance", "metadata": {"headings": [{"headings_0": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \n", "metadata": {"headings": [{"headings_0": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}, [{"headings_0": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}]], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- The entity budgeted to receive UGX.9,669,035,803 as transfers", "metadata": {"headings": [{"headings_0": {"content": "UGX.630,746,210 in the year under review however the entity", "page": 441, "level": 3}}], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "from other Government Units out of which UGX.1,522,149,995 \nwere received representing 16% performance leading to a shortfall of UGX. 8,146,885,809 (84%) \n\uf0b7 The entity budgeted to receive UGX.440,199,716 as \nexternal/donor financing out of which UGX.86,160,000 was received representing 6% performance \n\uf0b7 I assessed the implementation of Twenty two (22) outputs that were fully quantified with a total of Twenty two (22) activities worth UGX 3.13 Bn and noted the following; \n\uf0b7 Fifteen (15) outputs with a total of fifteen (15) activities worth \nUGX.2.38 Bn were fully implemented. \n\uf0b7 Five(05) outputs with a total of Five(05) activities worth UGX 0.70 Bn were partially implemented by the time of audit. \n\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit. \n429", "metadata": {"headings": [{"headings_0": {"content": "from other Government Units out of which UGX.1,522,149,995", "page": 441, "level": 3}}, [{"headings_0": {"content": "from other Government Units out of which UGX.1,522,149,995", "page": 441, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The entity budgeted to receive UGX.440,199,716 as", "page": 441, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The entity budgeted to receive UGX.440,199,716 as", "page": 441, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I assessed the implementation of Twenty two (22) outputs that were fully quantified with a total of Twenty two (22) activities worth UGX 3.13 Bn and noted the following;", "page": 441, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Fifteen (15) outputs with a total of fifteen (15) activities worth", "page": 441, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Fifteen (15) outputs with a total of fifteen (15) activities worth", "page": 441, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Five(05) outputs with a total of Five(05) activities worth UGX 0.70 Bn were partially implemented by the time of audit.", "page": 441, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit.", "page": 441, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit.", "page": 441, "level": 3}}]], "page": 441, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["", null, "\uf0b7 I noted that the entity submitted performance reports for Q1,"], [null, null, "Q2, Q3, Q4 after the deadline given for submission"], [null, null, "\uf0b7 A total of 261.4km at an estimated cost of UGX.94,152,000 was"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit.", "page": 441, "level": 3}}], "page": 442, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", null, "\uf0b7 I noted that the entity submitted performance reports for Q1,"], [null, null, "Q2, Q3, Q4 after the deadline given for submission"], [null, null, "\uf0b7 A total of 261.4km at an estimated cost of UGX.94,152,000 was"], [null, null, "planned to be undertaken, I noted that UGX.75,588,000 was"], [null, null, "received and all used for maintaining 209.9 Km implying a"], [null, null, "shortfall of UGX.18,564,000 which affected implementation of"], [null, null, "51.5Km of roads"], ["07\\. IBANDA DLG Opinion Unqualified \uf0b7 I noted the wage and Pension Pay roll of UGX.13,873,913,709 constituted 56% of the District\u2019s budget for 2020/2021 of UGX.24,675,034,751 \uf0b7 I reviewed payroll funds absorption and noted that UGX.11.6 billion (90.6%) was spent out of the total receipts of UGX.12.8 billion, resulting in an unabsorbed balance of UGX.1.1 billion. \uf0b7 I noted that the District made payroll deductions but did not remit it concurrently with the salary payments in 6 months. The delays ranged from 5 to 28 days \uf0b7 I noted that 191 newly recruited/transferred employees delayed to access payroll, with delays ranging between 1-9 months \uf0b7 I noted that only eight (8) pensioners delayed to access the pension payroll, with delays ranging between 2-7 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that although the entity had prepared a strategic plan that at the time of audit, it had not yet been approved as aligned to the NDP-III \uf0b7 I noted that the entity budgeted to receive UGX.22.11Bn as grants from the Treasury. However, only UGX.19.45Bn was received representing 88% performance leading to budget shortfall of UGX.2.66 Bn (12%). \uf0b7 I noted that the entity budgeted to receive UGX.1.48Bn as transfers from other Government Units. However, only UGX.1.22Bn was received representing 82.4% performance leading to revenue shortfall of UGX. 0.26Bn (17.6%). \uf0b7 I noted that the entity budgeted to receive UGX. 0.39Bn as external/donor financing out of which UGX.0.14Bn was received representing 36% performance leading to revenue shortfall of UGX.0.25Bn (63%). \uf0b7 The entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required. \uf0b7 The entity also did not submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED as required", null, null], ["08.", "KABALE DLG Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Pay roll of UGX.23,557,107,073 constituted 49.6% of the District\u2019s budget for 2020/2021 of UGX.47,484,993,193,"], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 Two (02) outputs with a total of two(02) activities worth UGX 0.05 Bn were not implemented by the time of audit.", "page": 441, "level": 3}}], "page": 442, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": [["", "resulting in an unspent balance of UGX.0.63 Bn (0.8%)."], [null, "\uf0b7 I noted that Management submitted performance reports for Q1,"], [null, "Q2, Q3 and Q4 after the deadline given for submission of the"], [null, "reports"], ["09\\. KANUNGU DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.28,863,148,598 constituted 66% of the District\u2019s budget for 2020/2021 of UGX.43.7 Bn \uf0b7 I noted that the District delayed to submit wage estimates to MoPs, as required \uf0b7 I reviewed Payroll funds absorption and noted that UGX.27 billion (95%) was spent out of the total receipts of UGX.28 billion, resulting in an unabsorbed balance of UGX.1 billion \uf0b7 I noted under payment of salary amounting to UGX 84,270,346 \uf0b7 I noted that 116 staff were paid using wrong salary scales, leading to over payments of UGX.33,520,148, \uf0b7 I noted that UGX.13,922,650 was paid to 11 staff who had either retired, transferred, absconded or died \uf0b7 I noted that the District made payroll deductions of UGX.6,465,198,289, but did not remit concurrently with the salary payments in 11 out of 12 months. On average, it delayed by 11 days \uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2 months \uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX.58,306,246 to the computation of PAYE in IPPS, leading to an under deduction of UGX.17,588,374 \uf0b7 I noted that 11 newly recruited/ transferred employees delayed to access payroll, with delays ranging between 1-6 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that 11 staff were paid a total of UGX.6,647,285 off the IPPS \uf0b7 I carried out a survey to establish the effectiveness and reliability of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification interface and noted the following; \uf0b7 In-adequate sensitization and training in the use and navigation of the IPPS. As a result, the HR team was unable to obtain pension payrolls for the financial year under review and the interface files for both salary and pension for the month of October 2020. \uf0b7 Lack/inadequate verification and ineffectiveness of the system may affect the integrity of the IPPS payroll \uf0b7 I noted that the District budgeted to collect UGX. 969,000,605", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}], "page": 444, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "432", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}], "page": 444, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["during the year but collected UGX.349,340,889 representing (36%) performance \uf0b7 I noted that the Entity budgeted to receive UGX.2,914,268,788 as transfers from other Government Units. However, only UGX.1,346,142,527 (46%) \uf0b7 I noted that the District budgeted to receive UGX.958,677,000 as external/donor financing out of which UGX.121,361,000(14%), was received \uf0b7 I noted that out of the total receipts for the financial year of UGX.37,438,548,600, UGX.36,912,545,231 (99%) was spent by the entity resulting in an unspent balance of UGX.526,003,369 (1%). \uf0b7 I noted that UGX.66,181,436 was charged on items which did not reflect the nature of the expenditure as shown in \uf0b7 I noted an irregular payment of VAT UGX 28,258,475 to contractors for the upgrade of Ntungamo HC II to HC III in Butogata Subcounty despite aid-funded projects being VAT exempt . The irregular payment was attributed to the irregular inclusion of the VAT amount in the contract price during the procurement process. \uf0b7 I noted that the District budgeted to receive UGX.931,475,272 from Uganda Road Fund for maintenance of 256.9 km of district roads, and UGX.900,073,304 (97%) was received and was utilised on maintenance of 242.5 km of roads, with a shortfall of UGX.31,401,970(3%) which left 14.4 km of roads not worked on.", null, null], ["10.", "KIRUHURA DLG Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Pay roll of UGX.12,779,567,829 constituted 50% of the District\u2019s budget for 2020/2021 of UGX.25.49 Bn"], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}], "page": 445, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "resulting in an unspent balance of UGX.0.63 Bn (0.8%)."], "type": "table"}}, {"content": "433 \nnot have evidence of consent by the employees \n\uf0b7 I noted that the District made payroll deductions of UGX.919,811,264, but did not remit the deductions concurrently \nwith the salary payments in 5 out of 9 months \n\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity \ntotalling to UGX 30,692,400 to the computation of PAYE in IPPS, \nleading to an under deduction of UGX.8,941,216 \n\uf0b7 I noted that 38 newly recruited/transferred employees delayed to \naccess the payroll, with delays ranging between 1-2 months \n\uf0b7 I noted that only five(5) out a sample of 52 pensioners delayed \nto access the pension payroll, with delays ranging up to a month \n\uf0b7 I noted that 15 staff were paid a total of UGX 12,719,746 \nrespectively off the IPPS \n\uf0b7 I noted that although the entity had prepared a strategic plan \nthat at the time of audit, it had not yet been approved as aligned to the NDP-III \n\uf0b7 I noted that Kiruhura District budgeted to collect UGX.1.19Bn during the year under review. The entity collected UGX.0.43Bn \nrepresenting 36.16% performance \n\uf0b7 I noted that the entity budgeted to receive UGX.2.78 Bn as \ntransfers from other Government Units. However, only UGX.1.53Bn was received representing 55.14% performance \n\uf0b7 I noted that the entity budgeted to receive UGX.0.85Bn as external/donor financing out of which UGX.0.065Bn was received \nrepresenting 7.75% performance \n\uf0b7 I noted that Out of the total warrants for the financial year of UGX.22.39 Bn, UGX.20.25Bn was utilized and spent by the entity resulting in an unspent balance of UGX.2.14 Bn representing an \nabsorption level of 90%. \n\uf0b7 I assessed the implementation of eight (8) outputs that were \nfully quantified with a total of twenty-one (21) activities worth UGX.2.96Bn and noted the following. \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted that Out of the total receipts for the financial year of UGX.35.51 Bn, UGX.34.88 Bn (98.2%) was spent by the entity", "page": 443, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.919,811,264, but did not remit the deductions concurrently", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.919,811,264, but did not remit the deductions concurrently", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 446, "level": 2}}], [{"headings_0": {"content": "totalling to UGX 30,692,400 to the computation of PAYE in IPPS,", "page": 446, "level": 3}}], [{"headings_0": {"content": "totalling to UGX 30,692,400 to the computation of PAYE in IPPS,", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 38 newly recruited/transferred employees delayed to", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 38 newly recruited/transferred employees delayed to", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that only five(5) out a sample of 52 pensioners delayed", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that only five(5) out a sample of 52 pensioners delayed", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 15 staff were paid a total of UGX 12,719,746", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 15 staff were paid a total of UGX 12,719,746", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that Kiruhura District budgeted to collect UGX.1.19Bn during the year under review. The entity collected UGX.0.43Bn", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that Kiruhura District budgeted to collect UGX.1.19Bn during the year under review. The entity collected UGX.0.43Bn", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.2.78 Bn as", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.2.78 Bn as", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.0.85Bn as external/donor financing out of which UGX.0.065Bn was received", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.0.85Bn as external/donor financing out of which UGX.0.065Bn was received", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that Out of the total warrants for the financial year of UGX.22.39 Bn, UGX.20.25Bn was utilized and spent by the entity resulting in an unspent balance of UGX.2.14 Bn representing an", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that Out of the total warrants for the financial year of UGX.22.39 Bn, UGX.20.25Bn was utilized and spent by the entity resulting in an unspent balance of UGX.2.14 Bn representing an", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I assessed the implementation of eight (8) outputs that were", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I assessed the implementation of eight (8) outputs that were", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I assessed the implementation of eight (8) outputs that were", "page": 446, "level": 3}}]], "page": 445, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- Three (3) outputs with total expenditure amounting to", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I assessed the implementation of eight (8) outputs that were", "page": 446, "level": 3}}], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "UGX.0.688Bn were fully implemented representing 37.5% of the \noutputs. \n\uf0b7 Five (5) outputs with total expenditure amounting to UGX.2.27Bn \nwere partially implemented representing 62.45% of the outputs \n\uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required. \n\uf0b7 I noted that the entity also did not submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED as \nrequired \n\uf0b7 I noted that the entity submitted performance reports for Q1, \nQ2, Q3, Q4 after the deadline given for submission of the reports \n\uf0b7 I noted variances in performance from my review of the Annual \n434", "metadata": {"headings": [{"headings_0": {"content": "UGX.0.688Bn were fully implemented representing 37.5% of the", "page": 446, "level": 3}}, [{"headings_0": {"content": "UGX.0.688Bn were fully implemented representing 37.5% of the", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Five (5) outputs with total expenditure amounting to UGX.2.27Bn", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 Five (5) outputs with total expenditure amounting to UGX.2.27Bn", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity did not prepare and submit the annual monitoring plans to MoFPED, MoLG and NPA as required.", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity also did not submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED as", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity also did not submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED as", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}]], "page": 446, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": [["", "cumulative performance reports and physical"], [null, "inspections/verification of performance."], [null, "\uf0b7 I reviewed the implementation of Uganda Road Fund and noted"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}], "page": 447, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": [["", "cumulative performance reports and physical"], [null, "inspections/verification of performance."], [null, "\uf0b7 I reviewed the implementation of Uganda Road Fund and noted"], [null, "the following;"], [null, "\uf0b7 A total of UGX.726,279,445 was budgeted for however the"], [null, "District Council received UGX.1,148,526,601 (158%)"], [null, "\uf0b7 A total of 221.90 km at an estimated cost of UGX.31,213,190"], [null, "was planned to be undertaken. However, audit revealed that no"], [null, "work was actually undertaken. Thus the entire 221.90 km were"], [null, "not maintained"], [null, "\uf0b7 A total of 6 km at an estimated cost of UGX.17,983,012 was"], [null, "planned to be undertaken. Audit revealed that 34.6 km was"], [null, "undertaken at a cost of UGX.187,493,520. I noted that the initial"], [null, "plan (budget) was not revised when additional funds were"], [null, "received."], ["11\\. KISORO DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.29,217,966,405 constituted 72% of the District\u2019s budget for 2020/2021 of UGX.40.68 Bn \uf0b7 I noted that the District did not submit wage estimates to MoPs, as required. \uf0b7 I noted an over payment of Pension of UGX.5,223,859 \uf0b7 I also noted that the District made payroll deductions of UGX2.595 billion, but did not remit concurrently with the salary payments in 6 out of 6 months sampled. On average, it delayed by 13.5 days \uf0b7 I noted delays in the remittance of PAYE deductions to URA ranging from 3 \u2013 32 days \uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX.419,638,073 \\` to the computation of PAYE in IPPS, leading to an under deduction of UGX.125,070,214 \uf0b7 I noted that 7 pensioners delayed to access the pension payroll, with delays ranging between 1-4 months \uf0b7 I noted that the Districts prepared monthly wage, pension and gratuity performance analysis but did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that 15 staff were paid a total of UGX.47,243,693 off the IPPS \uf0b7 I observed that there were variances of UGX.29,495,726 between the figures in the interface files and entity payroll registers \uf0b7 Some information on the NIRA interface is sometimes not visible/available for instance date of birth and the photo which delays the verification exercise \uf0b7 I noted that Kisoro DLG budgeted to collect UGX.461,618,300 during the year under review. The entity collected", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}], "page": 447, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_3"], "type": "table"}}, {"content": "435", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}], "page": 447, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["UGX.256,912,576 representing 55.7% performance. \uf0b7 I noted that the entity budgeted to receive UGX.1.10Bn as transfers from other Government Units out of which UGX.0.73Bn was received representing 66.2% performance \uf0b7 I noted thata the entity budgeted to receive 1.5Bn from external assistance but received 0.11Bn representing 7.6%. \uf0b7 I assessed the implementation of fifteen (15) outputs that were fully quantified with a total of fifteen (15) activities worth UGX.3.81Bn and noted the following; \uf0b7 Thirteen (13) outputs with Thirteen (13) activities worth UGX.3.808 Bn were fully implemented representing 58.6% of the outputs. \uf0b7 Two (2) outputs with two activities(2) worth UGX.0.54 Bn were not implemented representing 3.6% of the outputs(included in the schedule at UGX.0 because no funds were spent) \uf0b7 I noted that the entity submitted performance reports for Q1, Q2, Q3 and Q4 after the deadline given for submission of the reports \uf0b7 I noted the delayed completion of Nyakinama Seed School (UGIFT project) worth 2,331,850,894 \uf0b7 I noted that the District budgeted and received funds worth UGX.344,284,000 under UGIFT program for the construction of Mwumba Progressive SS. However, this project did not take off due to delays in the procurement process and at the time of audit in August, 2021, the project had not started with a delay of 12 months.", null, null], ["12.", "MBARARA CITY Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Payroll of UGX.17,869,060,735 constituted 39.4% of the Municipal Council\u2019s budget for 2020/2021 of UGX.45,355,732,366."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}], "page": 448, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["", "None", "cumulative performance reports and physical"], "type": "table"}}, {"content": "436 \nto access payroll, with delays ranging between 1-2 months \n\uf0b7 I noted that 22 pensioners delayed to access the pension payroll, \nwith delays ranging between 1 to 10 months \n\uf0b7 I noted that the Municipal Council did not prepare monthly wage, \npension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \n\uf0b7 I observed that there were variances of UGX.7,662,578 between \nthe MoPS IPPS and Entity payroll registers \n\uf0b7 The merger of both IPPS and NIRA system have not been fully \ndone in that when there is a system error each entity has to clear an error in its jurisdiction thus time consuming and affecting timely service delivery. \n\uf0b7 The system has not been fully decentralized to the extent that system errors under Employee verification system (issues) with NIRA have to be handled at the Headquarter and this contributes \nto multiple negative factors such delayed clearance of technical issues at least a period of three month or more. \n\uf0b7 I noted that although the entity had prepared a strategic plan, at \nthe time of audit, it had not yet been approved as aligned to the \nNDP-III. \n\uf0b7 I noted that the entity collected local revenue of UGX.3.54Bn of \n6.42Bn representing 55.25% performance \n\uf0b7 I noted that the entity budgeted to receive UGX.37.49Bn as grants from the Treasury. However, UGX.31.59 Bn was received, \nrepresenting 84.26% performance \n\uf0b7 I noted that the entity budgeted to receive UGX.1.45Bn as \ntransfers from other Government Units. However, UGX.7.65Bn was received representing 527.59% performance \n\uf0b7 I noted that out of the total receipts for the financial year of UGX.42.84Bn, UGX 36.68Bn was spent by the entity resulting in an unspent balance of UGX 6.15 Bn representing an absorption \nlevel of 85.6%. \n\uf0b7 I noted that the management submitted performance reports for Q1, Q2, Q3, Q4 after the deadline given for submission \n\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14) \nmonths after the expected/ contracted end date \n\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the \nprogress report revealed that planned works were completed on 22/08/2020, eleven (11) months outside the contract period without approval. \n437", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I noted variances in performance from my review of the Annual", "page": 446, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 22 pensioners delayed to access the pension payroll,", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 22 pensioners delayed to access the pension payroll,", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the Municipal Council did not prepare monthly wage,", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the Municipal Council did not prepare monthly wage,", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I observed that there were variances of UGX.7,662,578 between", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I observed that there were variances of UGX.7,662,578 between", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The merger of both IPPS and NIRA system have not been fully", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The merger of both IPPS and NIRA system have not been fully", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The system has not been fully decentralized to the extent that system errors under Employee verification system (issues) with NIRA have to be handled at the Headquarter and this contributes", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 The system has not been fully decentralized to the extent that system errors under Employee verification system (issues) with NIRA have to be handled at the Headquarter and this contributes", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan, at", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that although the entity had prepared a strategic plan, at", "page": 449, "level": 3}}], [{"headings_0": {"content": "NDP-III.", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity collected local revenue of UGX.3.54Bn of", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity collected local revenue of UGX.3.54Bn of", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.37.49Bn as grants from the Treasury. However, UGX.31.59 Bn was received,", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.37.49Bn as grants from the Treasury. However, UGX.31.59 Bn was received,", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1.45Bn as", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1.45Bn as", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.42.84Bn, UGX 36.68Bn was spent by the entity resulting in an unspent balance of UGX 6.15 Bn representing an absorption", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.42.84Bn, UGX 36.68Bn was spent by the entity resulting in an unspent balance of UGX 6.15 Bn representing an absorption", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the management submitted performance reports for Q1, Q2, Q3, Q4 after the deadline given for submission", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the contract for the upgrade of Kyarwabuganda HCII to HCIII worth UGX.540,531,906 was completed fourteen (14)", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}]], "page": 448, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["13\\. MITOOMA DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.18,505,405,927 constituted 63% of the District\u2019s budget for 2020/2021 of UGX.29,350,754,495. \uf0b7 I noted that the District did not to submit wage estimates to MoPS, as required \uf0b7 I noted delays in the remittance of PAYE deductions to URA of up to 100 days \uf0b7 I noted that 47 newly recruited/transferred employees delayed to access payroll, with delays ranging between 2-14 months \uf0b7 I noted that 7 pensioners delayed to access the pension payroll, with delays ranging between 1-14 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that 6 pensioners were paid a total of UGX.26,607,195 off the IPPS \uf0b7 I observed that there were variances of UGX.514,103,048 between the figures in the MoPS IPPS and entity payroll registers, \uf0b7 Operational challenges were encountered; E.g. Un-reliable network in Mitooma where HR staff had to physically travel to the neighbouring Bushenyi District to be able to download documents such as pension payroll registers. \uf0b7 I noted that the upgrade of Mayanga HC II to HC III contracted to Khalsa (U) Ltd was still under construction and only at roofing stage by the time of audit inspection on 13th October, 2021. However, the medical equipment had already been procured and delivered under a separate contract to M/s Rodrisa Supplies Limited who was expected to supply, deliver, instal, train and commission the medical equipment. Procurement of medical equipment for a health facility still at foundation stage may lead to obsolescence, pilferage and physical damage leading to nugatory expenditure.", null, null], ["14.", "NTUNGAMO DLG Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Pay roll of UGX.35,484,605,345 constituted 56% of the District\u2019s budget for 2020/2021 of UGX.63,733,887,733."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}], "page": 450, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "438", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}], "page": 450, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["", "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity"], [null, "totalling to UGX.60,526,800 to the computation of PAYE in IPPS,"], [null, "leading to an under deduction of UGX.14,374,090"]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}], "page": 451, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["13\\. MITOOMA DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.18,505,405,927 constituted 63% of the District\u2019s budget for 2020/2021 of UGX.29,350,754,495. \uf0b7 I noted that the District did not to submit wage estimates to MoPS, as required \uf0b7 I noted delays in the remittance of PAYE deductions to URA of up to 100 days \uf0b7 I noted that 47 newly recruited/transferred employees delayed to access payroll, with delays ranging between 2-14 months \uf0b7 I noted that 7 pensioners delayed to access the pension payroll, with delays ranging between 1-14 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that 6 pensioners were paid a total of UGX.26,607,195 off the IPPS \uf0b7 I observed that there were variances of UGX.514,103,048 between the figures in the MoPS IPPS and entity payroll registers, \uf0b7 Operational challenges were encountered; E.g. Un-reliable network in Mitooma where HR staff had to physically travel to the neighbouring Bushenyi District to be able to download documents such as pension payroll registers. \uf0b7 I noted that the upgrade of Mayanga HC II to HC III contracted to Khalsa (U) Ltd was still under construction and only at roofing stage by the time of audit inspection on 13th October, 2021. However, the medical equipment had already been procured and delivered under a separate contract to M/s Rodrisa Supplies Limited who was expected to supply, deliver, instal, train and commission the medical equipment. Procurement of medical equipment for a health facility still at foundation stage may lead to obsolescence, pilferage and physical damage leading to nugatory expenditure.", "None"], "type": "table"}}, {"content": [["", "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity"], [null, "totalling to UGX.60,526,800 to the computation of PAYE in IPPS,"], [null, "leading to an under deduction of UGX.14,374,090"], [null, "\uf0b7 I noted that the entity did not prepare monthly wage, pension"], [null, "and gratuity performance analysis, and did not submit quarterly"], [null, "returns on payroll to MoPS"], [null, "\uf0b7 I noted that 29 staff were paid a total of UGX.91,713,882 off the"], [null, "IPPS"], [null, "\uf0b7 I carried out a survey to establish the effectiveness and reliability"], [null, "of the IPPS/NID staff/pensioner/beneficiaries\u2019 verification"], [null, "interface and noted the following;"], [null, "\uf0b7 I noted that the entity had no approved a strategic plan at the"], [null, "time of audit"], [null, "\uf0b7 I noted that the District budgeted to collect UGX.1,554,984,179"], [null, "during the year but collected UGX.1,127,109,918 representing"], [null, "(72%) performance"], [null, "\uf0b7 I noted that the entity budgeted to receive UGX.8,698,586,134"], [null, "as transfers from other Government Units out of which"], [null, "UGX.1,307,013,923 was received representing 15% performance"], [null, "leading to a shortfall of UGX.7,391,572,211(85%)"], [null, "\uf0b7 I noted that the entity budgeted to receive UGX.1,901,504,814"], [null, "as external/donor financing out of which UGX.267,332,705 was"], [null, "received representing 14% performance"], [null, "\uf0b7 Out of the total receipts for the financial year of UGX. 53.52,"], [null, "UGX. 51.85 (97%) was spent by the entity resulting in an"], [null, "unspent balance of UGX. 1.67 (3%)."], [null, "\uf0b7 I carried out an audit inspection of the Construction of Kihanga"], [null, "seed Secondary school (UGX.718,168,225) in September 2021,"], [null, "and noted that the project had been abandoned and behind"], [null, "schedule by 20 months"], [null, "\uf0b7 I noted that most of the District land did not have certificates of"], [null, "land titles"], ["15\\. RUKIGA DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.15,291,042,432 constituted 50.4% of the District\u2019s budget for 2020/2021 of UGX.30,313,124,744 \uf0b7 I noted that the District did not submit wage estimates to MoPS, as required \uf0b7 I reviewed payroll funds absorption and noted that UGX.13.167 billion (86%) was spent out of the total receipts of UGX.15.29 billion, resulting in an unabsorbed balance of UGX 2.12 billion \uf0b7 I noted that whereas UGX.909,840,551 was deducted from employees\u2019 salaries to be remitted to different beneficiaries, UGX.909,338,143 was remitted, leading to an over/under remittance of UGX.153,842 and UGX.656,250 respectively \uf0b7 I noted that the District made payroll deductions of UGX 0.844", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}], "page": 451, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["13\\. MITOOMA DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.18,505,405,927 constituted 63% of the District\u2019s budget for 2020/2021 of UGX.29,350,754,495. \uf0b7 I noted that the District did not to submit wage estimates to MoPS, as required \uf0b7 I noted delays in the remittance of PAYE deductions to URA of up to 100 days \uf0b7 I noted that 47 newly recruited/transferred employees delayed to access payroll, with delays ranging between 2-14 months \uf0b7 I noted that 7 pensioners delayed to access the pension payroll, with delays ranging between 1-14 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that 6 pensioners were paid a total of UGX.26,607,195 off the IPPS \uf0b7 I observed that there were variances of UGX.514,103,048 between the figures in the MoPS IPPS and entity payroll registers, \uf0b7 Operational challenges were encountered; E.g. Un-reliable network in Mitooma where HR staff had to physically travel to the neighbouring Bushenyi District to be able to download documents such as pension payroll registers. \uf0b7 I noted that the upgrade of Mayanga HC II to HC III contracted to Khalsa (U) Ltd was still under construction and only at roofing stage by the time of audit inspection on 13th October, 2021. However, the medical equipment had already been procured and delivered under a separate contract to M/s Rodrisa Supplies Limited who was expected to supply, deliver, instal, train and commission the medical equipment. Procurement of medical equipment for a health facility still at foundation stage may lead to obsolescence, pilferage and physical damage leading to nugatory expenditure.", "None"], "type": "table"}}, {"content": "439", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}], "page": 451, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["billion, but did not remit concurrently with the salary payments in 11 out of 12 months. On average, it delayed by 6.5 days \uf0b7 I noted that the District did not subject political leaders\u2019 gratuity totalling to UGX.34,918,061 to the computation of PAYE in IPPS, leading to an under deduction of UGX.10,880,299 \uf0b7 I noted that 6 newly recruited/transferred employees delayed to access payroll, with delays ranging between 1- 3.5 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis nor submitted quarterly returns on payroll to MoPS \uf0b7 I noted that UGX.24,681,002 was paid to 16 staffs that were off the IPPS payroll register \uf0b7 I observed that there were variances of UGX30,377,765 between the figures in the interface files and entity payroll registers \uf0b7 I noted that the entity prepared a strategic plan but was not yet approved. \uf0b7 I noted that Rukiga DLG budgeted to collect UGX. 285,061,188 during the year under review. The entity collected UGX.155,082,884 representing 54% performance. \uf0b7 I noted that the entity budgeted to receive UGX.8.77Bn as transfers from other Government Units out of which UGX.0.68Bn was received representing 11% performance \uf0b7 I noted that the entity budgeted to receive 1.02Bn from external assistance but received 0.05Bn representing 5%. \uf0b7 I noted that out of UGX.21,252,068,152 warrants to finance the council\u2019s budget, only UGX.18,677,785,569 (88%) was spent leaving a balance of UGX.2,574,282,583 (14%) un utilized \uf0b7 I noted that the entity did not also submit quarterly monitoring reports to the Office of the Prime Minister and MoFPED as required. \uf0b7 I noted that the entity submitted performance reports for Q3, and Q4 after the deadline given for submission of the reports \uf0b7 I noted that the District Council budgeted to receive UGX.467,373,000 (Excluding funds to be transferred to LLGs) from Uganda Road Fund for maintenance of 80.9kms of District roads, and UGX.252,363,000 (54%%) was received and was utilised on maintenance of 74.7kms of roads, installation of culverts, equipment repairs and supervision with a shortfall of UGX.215,010,000 (46%) As a result of revenue shortage, 6.2KMs of roads were not maintained under periodic maintenance as planned", null, null], ["16.", "RUKUNGIRI DLG Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Pay roll of UGX.30,042,268,241 constituted 66.8% of the District\u2019s budget for 2020/2021 of UGX.44.95 Bn."], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}], "page": 452, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["13\\. MITOOMA DLG Opinion Unqualified \uf0b7 I noted that the wage and Pension Pay roll of UGX.18,505,405,927 constituted 63% of the District\u2019s budget for 2020/2021 of UGX.29,350,754,495. \uf0b7 I noted that the District did not to submit wage estimates to MoPS, as required \uf0b7 I noted delays in the remittance of PAYE deductions to URA of up to 100 days \uf0b7 I noted that 47 newly recruited/transferred employees delayed to access payroll, with delays ranging between 2-14 months \uf0b7 I noted that 7 pensioners delayed to access the pension payroll, with delays ranging between 1-14 months \uf0b7 I noted that the District did not prepare monthly wage, pension and gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS \uf0b7 I noted that 6 pensioners were paid a total of UGX.26,607,195 off the IPPS \uf0b7 I observed that there were variances of UGX.514,103,048 between the figures in the MoPS IPPS and entity payroll registers, \uf0b7 Operational challenges were encountered; E.g. Un-reliable network in Mitooma where HR staff had to physically travel to the neighbouring Bushenyi District to be able to download documents such as pension payroll registers. \uf0b7 I noted that the upgrade of Mayanga HC II to HC III contracted to Khalsa (U) Ltd was still under construction and only at roofing stage by the time of audit inspection on 13th October, 2021. However, the medical equipment had already been procured and delivered under a separate contract to M/s Rodrisa Supplies Limited who was expected to supply, deliver, instal, train and commission the medical equipment. Procurement of medical equipment for a health facility still at foundation stage may lead to obsolescence, pilferage and physical damage leading to nugatory expenditure.", "None", "None"], "type": "table"}}, {"content": "440 \nas required \n\uf0b7 I noted that two Education Officers (Twinomuhwezi Julius IPPS no.328279 and Abaho Besigye Gerald IPPS no. 326667) under U4 who were erroneously captured as Assistant Education Officers and paid under U5 thus an over payment of UGX 304,295 \n\uf0b7 I noted that UGX.28,077,304 was paid to 19 staff who had either \nretired, transferred, absconded or died \n", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}, [{"headings_0": {"content": "\uf0b7 I also noted that another contract of UGX.279,324,596 was awarded to M/s Twinka Enterprises (U) Ltd to construct three units of Doctors houses with planned commencement date of 26/12/2019, and completion date by 26/06/2020. A review of the", "page": 449, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that two Education Officers (Twinomuhwezi Julius IPPS no.328279 and Abaho Besigye Gerald IPPS no. 326667) under U4 who were erroneously captured as Assistant Education Officers and paid under U5 thus an over payment of UGX 304,295", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.28,077,304 was paid to 19 staff who had either", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.28,077,304 was paid to 19 staff who had either", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.28,077,304 was paid to 19 staff who had either", "page": 453, "level": 3}}]], "page": 452, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": "- I noted that whereas UGX.6,307,960,826 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.28,077,304 was paid to 19 staff who had either", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX \n6,304,814,535 was remitted, leading to an over/ under remittance of UGX.5,128,867 and UGX.8,275,158 respectively \n\uf0b7 I noted that the District made payroll deductions of UGX.2.259 \nbillion, but did not remit concurrently with the salary payments in 10 out of 12 months. On average, it delayed by 6.5 days \n\uf0b7 I noted delays in the remittance of PAYE deductions to URA \nranging from 2 \u2013 22 days \n\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity \ntotalling to UGX.11,718,959 to the computation of PAYE in IPPS, \nleading to an under deduction of UGX.3,715,200 \n\uf0b7 I noted that 7 newly recruited/ transferred employees delayed to \naccess payroll, with delays ranging between 1-5 months \n\uf0b7 I noted that 1 pensioner delayed to access the pension payroll, \nwith delays of over of 6 months \n\uf0b7 I noted that the Districts prepared monthly wage, pension and \ngratuity performance analysis but did not submit quarterly returns on payroll to MoPS \n\uf0b7 I observed that there were variances of UGX 190,771,973 \nbetween the figures in the interface files and entity payroll registers \n\uf0b7 I noted that the entity had not approved a strategic plan that is aligned to the NDP-III at the time of audit \n", "metadata": {"headings": [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX", "page": 453, "level": 2}}, [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX", "page": 453, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.2.259", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made payroll deductions of UGX.2.259", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 453, "level": 2}}], [{"headings_0": {"content": "totalling to UGX.11,718,959 to the computation of PAYE in IPPS,", "page": 453, "level": 3}}], [{"headings_0": {"content": "totalling to UGX.11,718,959 to the computation of PAYE in IPPS,", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 7 newly recruited/ transferred employees delayed to", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 7 newly recruited/ transferred employees delayed to", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 1 pensioner delayed to access the pension payroll,", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 1 pensioner delayed to access the pension payroll,", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the Districts prepared monthly wage, pension and", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the Districts prepared monthly wage, pension and", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I observed that there were variances of UGX 190,771,973", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I observed that there were variances of UGX 190,771,973", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity had not approved a strategic plan that is aligned to the NDP-III at the time of audit", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity had not approved a strategic plan that is aligned to the NDP-III at the time of audit", "page": 453, "level": 3}}]], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- I noted Rukungiri DLG budgeted to collect UGX.776,944,000", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that the entity had not approved a strategic plan that is aligned to the NDP-III at the time of audit", "page": 453, "level": 3}}], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "during the year under review. However the entity collected \nUGX.625,618,740 representing 81% performance. \n\uf0b7 I noted that the entity budgeted to receive UGX.1,411,248,710 as transfers from other Government Units out of which \nUGX.888,876,678 was received representing 63% performance \n\uf0b7 I noted that the entity budgeted to receive 1.05Bn from external \nassistance but received 0.116 Bn representing 11%. \n\uf0b7 I noted that out of UGX.42,031,304,808 warrants to finance the \ncouncil\u2019s budget, only UGX.40,435,316,368 (96%) was spent \nleaving a balance of UGX.1,595,988,440 (4%) un utilized \n\uf0b7 I noted that the entity submitted performance reports for Q2, \nQ3, and Q4 after the deadline \n\uf0b7 I noted the delayed completion of Kebisoni Seed School (UGIFT \n441 \n", "metadata": {"headings": [{"headings_0": {"content": "during the year under review. However the entity collected", "page": 453, "level": 3}}, [{"headings_0": {"content": "during the year under review. However the entity collected", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1,411,248,710 as transfers from other Government Units out of which", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive UGX.1,411,248,710 as transfers from other Government Units out of which", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive 1.05Bn from external", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity budgeted to receive 1.05Bn from external", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that out of UGX.42,031,304,808 warrants to finance the", "page": 453, "level": 3}}], [{"headings_0": {"content": "council\u2019s budget, only UGX.40,435,316,368 (96%) was spent", "page": 453, "level": 2}}], [{"headings_0": {"content": "leaving a balance of UGX.1,595,988,440 (4%) un utilized", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q2,", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q2,", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted the delayed completion of Kebisoni Seed School (UGIFT", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted the delayed completion of Kebisoni Seed School (UGIFT", "page": 453, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted the delayed completion of Kebisoni Seed School (UGIFT", "page": 453, "level": 3}}]], "page": 453, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "17. RWAMPARA DLG", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted the delayed completion of Kebisoni Seed School (UGIFT", "page": 453, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": "Opinion Unqualified \nproject). Project behind schedule by four(04) months \n\uf0b7 I noted that The District received UGX.499,963,986 (96.3%) of its Uganda Road fund and as a result was not able to maintain \n14.2 Km of roads as planned \n\uf0b7 I noted that the wage and Pension Pay roll of \nUGX.12,530,332,963 constituted 62% of the District\u2019s budget for \n2020/2021 of UGX.20,291,699,406. \n\uf0b7 I noted that the District did not to submit wage estimates to \nMoPS, as required \n\uf0b7 I noted salary overpayment of UGX 6,766,726 \n\uf0b7 I further noted that there was an under payment of UGX.30,357,501 \n\uf0b7 I noted pension and gratuity overpayment of UGX 2,144,892 \n\uf0b7 I noted that UGX.4,580,492 was paid to 4 staff who had either \nretired or died", "metadata": {"headings": [{"headings_0": {"content": "Opinion Unqualified", "page": 454, "level": 3}}, [{"headings_0": {"content": "Opinion Unqualified", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that The District received UGX.499,963,986 (96.3%) of its Uganda Road fund and as a result was not able to maintain", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that The District received UGX.499,963,986 (96.3%) of its Uganda Road fund and as a result was not able to maintain", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the wage and Pension Pay roll of", "page": 454, "level": 3}}], [{"headings_0": {"content": "UGX.12,530,332,963 constituted 62% of the District\u2019s budget for", "page": 454, "level": 2}}], [{"headings_0": {"content": "UGX.12,530,332,963 constituted 62% of the District\u2019s budget for", "page": 454, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not to submit wage estimates to", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted salary overpayment of UGX 6,766,726", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I further noted that there was an under payment of UGX.30,357,501", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted pension and gratuity overpayment of UGX 2,144,892", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.4,580,492 was paid to 4 staff who had either", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that UGX.4,580,492 was paid to 4 staff who had either", "page": 454, "level": 3}}]], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "heading"}}, {"content": "- I noted that whereas UGX.2,342,683,197 was deducted from", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.4,580,492 was paid to 4 staff who had either", "page": 454, "level": 3}}], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "list"}}, {"content": " \nemployees\u2019 salaries to be remitted to different beneficiaries, UGX.2,336,599,219 was remitted, leading to an over remittance \nof UGX.1,549,064 and under remittance of UGX.7,633,042 \n\uf0b7 I noted that the District made unauthorized loan deductions totalling UGX.48 million. The deductions were from 28 employees \nthat had no letters of undertaking however existed in the \u201cactive deduction\u201d and the \u201cmy approval\u201d reports on the PDMS-Payroll Deduction Management System, operated by PCA-Payroll Consults Africa \n\uf0b7 I noted that deductions to UCLA/UBA were not remitted concurrently with salary payments for 12 out 12 months. I also \nnoted that there was an average delay to remit deductions to \nUCLA/UBA of 21.3 days \n\uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2 \nmonths. I also noted that there was an average delay to remit deductions to URA of 0.5 days \n\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity \ntotalling to UGX.3,114,720 to the computation of PAYE in IPPS, \nleading to an under deduction of UGX.934,416 \n\uf0b7 I noted that 51 newly recruited/ transferred employees delayed \nto access payroll, with delays ranging between 9 weeks \n\uf0b7 I noted that 15 pensioners delayed to access the pension payroll, \nwith delays ranging between 3-4 months \n\uf0b7 noted that the District did not prepare monthly wage, pension \nand gratuity performance analysis and thus did not submit quarterly returns on payroll to MoPS, \n\uf0b7 I noted that although the district had prepared a strategic plan \nthat at the time of audit, it had not yet been approved as aligned \n442", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that UGX.4,580,492 was paid to 4 staff who had either", "page": 454, "level": 3}}, [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.2,336,599,219 was remitted, leading to an over remittance", "page": 454, "level": 2}}], [{"headings_0": {"content": "employees\u2019 salaries to be remitted to different beneficiaries, UGX.2,336,599,219 was remitted, leading to an over remittance", "page": 454, "level": 2}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totalling UGX.48 million. The deductions were from 28 employees", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District made unauthorized loan deductions totalling UGX.48 million. The deductions were from 28 employees", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that deductions to UCLA/UBA were not remitted concurrently with salary payments for 12 out 12 months. I also", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that deductions to UCLA/UBA were not remitted concurrently with salary payments for 12 out 12 months. I also", "page": 454, "level": 3}}], [{"headings_0": {"content": "UCLA/UBA of 21.3 days", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted delays in the remittance of PAYE deductions to URA for 2", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the District did not subject political leaders\u2019 gratuity", "page": 454, "level": 2}}], [{"headings_0": {"content": "totalling to UGX.3,114,720 to the computation of PAYE in IPPS,", "page": 454, "level": 3}}], [{"headings_0": {"content": "totalling to UGX.3,114,720 to the computation of PAYE in IPPS,", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 51 newly recruited/ transferred employees delayed", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 51 newly recruited/ transferred employees delayed", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 15 pensioners delayed to access the pension payroll,", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that 15 pensioners delayed to access the pension payroll,", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 noted that the District did not prepare monthly wage, pension", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 noted that the District did not prepare monthly wage, pension", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "page": 454, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "page": 454, "level": 3}}]], "page": 454, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}, {"content": [["to the NDP-III \uf0b7 I noted that Rwampara District budgeted to collect UGX.0.392bn during the year under review. The entity collected UGX.0.379bn representing 96.68% performance. \uf0b7 I noted that the entity budgeted to receive UGX.1.51 Bn as transfers from other Government Units. However, only UGX.0.68 Bn was received representing 45% performance leading to revenue shortfall of UGX. 0.83Bn (55%).", null, null], ["18.", "SHEEMA DLG Opinion Unqualified", "\uf0b7 I noted that the wage and Pension Pay roll of UGX.18,356,082,529 constituted 65% of the District\u2019s budget for 2020/2021 of UGX.27,950,550,703"], [null, "", null]], "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "page": 454, "level": 3}}], "page": 455, "document_name": "Annual Consolidated OAG audit reports 2021", "columns": ["column_0", "column_1", "column_3"], "type": "table"}}, {"content": "443 \ntransfers from other Government Units out of which \nUGX.892,442,495 was received representing 93% performance. \n\uf0b7 I noted that the district budgeted to receive UGX.279,500,000 as \nexternal/donor financing out of which UGX.130,287,709 million was received representing 47% performance \n\uf0b7 I noted that out of the total receipts for the financial year of UGX.26.95Bn,) UGX.25,32Bn was spent by the entity resulting in an unspent balance of UGX.1.63 Bn representing an absorption \nlevel of 94%. \n\uf0b7 I noted that the entity submitted performance reports for Q1, \nQ2, Q3, Q4 after the deadline given for submission of the reports \n444", "metadata": {"headings": [{"headings_0": {"content": "\uf0b7 I noted that although the district had prepared a strategic plan", "page": 454, "level": 3}}, [{"headings_0": {"content": "transfers from other Government Units out of which", "page": 456, "level": 3}}], [{"headings_0": {"content": "transfers from other Government Units out of which", "page": 456, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district budgeted to receive UGX.279,500,000 as", "page": 456, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the district budgeted to receive UGX.279,500,000 as", "page": 456, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.26.95Bn,) UGX.25,32Bn was spent by the entity resulting in an unspent balance of UGX.1.63 Bn representing an absorption", "page": 456, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that out of the total receipts for the financial year of UGX.26.95Bn,) UGX.25,32Bn was spent by the entity resulting in an unspent balance of UGX.1.63 Bn representing an absorption", "page": 456, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 456, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 456, "level": 3}}], [{"headings_0": {"content": "\uf0b7 I noted that the entity submitted performance reports for Q1,", "page": 456, "level": 3}}]], "page": 455, "document_name": "Annual Consolidated OAG audit reports 2021", "type": "paragraph"}}], "table_of_contents": [{"content": ["LIST OF ACRONYMS - ix", "GLOSSARY OF TERMS - xi", "FOREWORD BY THE AUDITOR GENERAL - xii", "PART 1: INTRODUCTION AND PURPOSE OF THE REPORT - 1", " 1.0 INTRODUCTION AND PURPOSE - 1", " 1.1 General Introduction - 1", " 1.2 Purpose - 1", " 1.3 Summary of Audit Results - 2", " 1.3.1 General Performance - 2", " 1.3.2 Summary of Opinions - 3", "PART 2: CONSOLIDATED FINANCIAL STATEMENTS - 4", "REPORT OF THE AUDITOR GENERAL ON THE CONSOLIDATED FINANCIAL STATEMENTS - 4", "2.0", "2.1 REPORT AND OPINION OF THE AUDITOR GENERAL ON THE GOVERNMENT OF UGANDA", "CONSOLIDATED FINANCIAL STATEMENTS FOR THE YEAR ENDED 30 TH JUNE 2021 - 4", "Opinion\u2026 .\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026 - 4", "Basis for Opinion - 4", "Key Audit Matter - 4", "Implementation of the approved budget - 4", "2.1.1.", "COVID 19 expenditure - 11", "2.1.2.", "Compensations/Acquisition of Right of Way for Selected Transmission Lines Projects - 14", "2.1.3.", "Emphasis of Matter - 16", "Other Matter - 17", " 2.1.4 Tax policy - 17", "Audit of public debt - 19", "2.1.5.", "Management of ICT in government - 25", "2.1.6.", "Audit of public investments - 27", "2.1.7.", "Continued expenditure off the IFMS \u2013 UGX 695,372,792,876 - 30", "2.1.8.", "Other Information - 31", "Responsibilities of Management for the Consolidated Financial Statements - 31", "Auditor\u2019s Responsibilities for the Audit of the Consolidated Financial Statements - 32", "Other Reporting Responsibilities - 33"], "page": 3}, {"content": ["JUSTICE LAW AND ORDER SECTOR - 65", "Management of cases and Case backlog - 65", "3.4.1.", "Operationalisation of the Joint Venture Agreement - 66", "3.4.2.", "INFORMATION COMMUNICATION TECHNOLOGY SECTOR - 67", "3.5.", "Absence of a National IT Governance/Oversight System - 67", "3.5.1.", "Failure by MDAs to Pay for National Backbone Infrastructure Services - 67", "3.5.2.", "Uncollected Revenue from Media Operators - 67", "3.5.3.", "Lack of a Communications Tribunal - 68", "3.5.4.", " 3.6 ACCOUNTABILITY SECTOR - 69", "Approval of supplementary funding without matching revenue - 69", "3.6.1.", "Underperformance in Revenue Collection - 69", "3.6.2.", "3.6.3.", "Overstay of projects in the Public Investment Plan (PIP)-UGX.39.01Tn - 69", "Un recovered Advances; UGX.2,819,193,074 - 70", "3.6.5.", "Absence of a monitoring and evaluation framework for impact assessment for tax exemptions - 70", "3.6.6.", " 3.7 ENERGY SECTOR - 71", "Capitalization of Uganda National Oil Company and its Subsidiary Companies - 71", "3.7.1.", "Implementation of the Electricity Connection Policy(ECP) - 71", "3.7.2.", "Vandalism and Theft of UETCL Grid Assets - 72", "3.7.3.", "Deemed Energy Purchases: UGX.87.7 Billion and Power Evacuation Losses UGX.15.29 Billion - 72", "3.7.4.", "Delayed Commissioning of Karuma HPP - 73", "3.7.5.", "3.7.6.", "GENDER AND SOCIAL DEVELOPMENT SECTOR - 75", "Labour Externalization Inadequacies - 75", "3.8.1.", "Implementation of the Uganda Women Entrepreneurship Programme - 76", "3.8.2.", " 3.9 LAND SECTOR - 77", "Management of Government Land Matters - 77", "3.9.1.", " 3.10 EDUCATION SECTOR - 77", " 3.10.1 Management of Bilateral Scholarships - 77", "Management of Research Grants by Public Universities in Uganda - 78", "3.10.2.", "WATER & ENVIRONMENT SECTOR - 80", "3.11.", "Afforestation and Restoration of Selected Central Forest Reserves (CFRS) by the (NFA) - 80", "3.11.1.", " 3.12 WORKS SECTOR - 81", "Uganda National Roads Authority - 81", "3.12.1.", "Ministry of Works and Transport - 82", "3.12.2.", "v"], "page": 5}, {"content": [" 3.12.3 Uganda Railways Corporation - 83", "Uganda Civil Aviation Authority - 83", "3.12.4.", " 3.13 HEALTH SECTOR - 85", " 3.13.1 Mulago National Referral Hospital - 85", " 3.13.2 National Drug Authority - 86", "SCIENCE, TECHNOLOGY AND INNOVATION SECTOR - 86", "3.14.", "Closure of the Ministry of Science, Technology and Innovation - 86", "3.14.1.", "Un-deployed Staff upon the abolition of the Ministry - 87", "3.14.2.", "Progress on the COVID-19 Vaccine, Diagnostics and Treatment Projects - 87", "3.14.3.", " 3.15 TRADE SECTOR - 88", " 3.16 TOURISM SECTOR - 89", "HIGHLIGHTS FROM THE AUDIT OF LOWER LOCAL GOVERNMENTS FOR THE PERIOD 2019/2020 - 90", "3.17.", " 3.17.1 Under staffing - 90", "Budget implementation in sample LLGs for FY 2018/2019 and 2019/2020 - 91", "3.17.2.", " 3.17.3 Quality of Financial Statements - 92", "Land Management in Local Governments - 92", "3.17.4.", "Lack of Urban Physical Planning Committees - 93", "3.17.5.", "HIGHLIGHTS FROM THE ENGINEERING AUDITS - 94", "4.0.", "4.1.", "Engineering Audit of Selected Road and Building Projects in Kampala Capital City Authority (KCCA) - 98", " 5.0 INFORMATION SYSTEMS AUDITS - 100", "Information Systems Audit of Civil Aviation Authority - 100", "5.1.", "Information Systems Audit of the Academic Management Information System (AIMS) - 102", "5.2.", "Information Systems Audit of Uganda National Land Information System (Ug-NLIS) - 105", "5.3.", " 6.0 SPECIAL VERIFICATIONS - 108", "Verification of Assets and Liabilities for Uganda Telecom (In-Administration) - 108", "6.1.", "Verification of Terminal Benefits/Pension of former Employees UPTC - 109", "6.2.", "HIGHLIGHTS OF VALUE FOR MONEY AUDIT RESULTS - 111", "7.0.", "Value for Money Audit on the Management of Government Investments by UDC - 111", "7.1.", "7.2 A Value for Money Audit on The Afforestation and Restoration of Selected Central Forest Reserves", "(CFRs) by the National Forestry Authority (NFA) - 113", "7.3 A Value for Money Audit on the Implementation of the Uganda Women Entrepreneurship Programme", "\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026\u2026.115", "A Value for Money Audit Report on the Management of Research Grants by Public Universities - 117", "7.4.", "vi"], "page": 6}, {"content": ["Value for Money Audit on The Management Of MATIP-1 Markets by Municipalities - 121", "Prevention and Response to Incidents of Fire by Uganda Police Force - 122", "7.6.", "Value for Money Audit on the Performance of the Agriculture Cluster Development Project - 125", "7.7.", "7.8 Follow up on the Value for Money Audit on the Compensation of Project Affected Persons under the", "Refinery Project by the Ministry of Energy and Mineral Development - 126", "7.9 VFM Audit on the Implementation of the Uganda Reproductive Maternal and Child Health Services", "Improvement Project (URMCHSIP) - 127", "ANNEXURES - 129", "ANNEXURE I: SUMMARY OF ENTITY FINDINGS AND OPINIONS FOR MDAs, COMMISSIONS, STATUTORY", "CORPORATIONS AND STATE ENTERPRISES AND PROJECTS - 129", "ANNEXURE II: SUMMARY OF ENTITY FINDINGS AND OPINIONS FOR LOCAL GOVERNMENTS - 316", "ANNEXURE III: REPORTS AND CONSOLIDATED GOVERNMENT OF UGANDA FINANCIAL STATEMENTS - 445"], "page": 7}, {"content": ["Table 1: Status of audit performance for audit year 2021 - 2", "Table 2: Summary of Current Year Opinions - 3", "Table 3: Trend of Opinions for MDAs, Higher Local Governments for the last three years - 3", "Table 4: Tax arrears - 19", "Table 5: Debt portfolio analysis - 20", "Table 6: Total revenue ratio - 22", "Table 7: Tax to GDP ratio - 23", "Table 8: Noncompliance with the 70% capital threshold - 28", "Table 9: Absorption of fund - 29", "Table 10: Showing Level of Absorption for Wage, Pension and Gratuity - 36", "Table 11: Entities with unsupported expenditure - 45", "Table 12 Un-consolidated local governmentsSn - 46", "Table 13: Status of implementation of UgIFT projects - 47", "Table 14: UgIFT projects without land titles - 48", "Table 15: Entities not Consolidated, but Disclosed in summary statement - 53", "Table 16: Entities neither reported nor Disclosed in the consolidated summary statement - 53", "Table 17: Entities not assessed - 54", "Table 18: Profitability of Public Corporation and State Enterprises - 55", "Table 19: Returns on Assets - 56", "Table 20: Enterprise Liquidity - 57", "Table 21: Liquidity assessment for financial institutions - 58", "Table 22: Loans and Advances performance - 59", "Table 23: Enterprises' ability to service loan obligations - 59", "Table 24: Comparison of consolidated quantities of production inputs - 63", "Table 25: Information Systems within the JLOS Sector - 65", "Table 26: Understaffing in Lower Local Government - 90", "Table 27: Performance of Central Government Grant - 91", "Table 28: Performance of Local Revenue - 91", "Table 29: Unjustified Payments and Overpayments - 99", "Table 30: Creditors Verified - 108", "Table 31: Summary of claims presented for Verification - 110", "Table 32: Summary of Verified claims payable - 110", "Table 33: Challenges of Project Implementation - 112"], "page": 8}]} \ No newline at end of file